EDUCATION INFRASTRUCTURE GRANT PRESENTATION TO THE SELECT COMMITTEE ON APPROPRIATIONS 02 JUNE 2015 Education Infrastructure Grant Expenditure for 2014/15 Financial Year • A total of R6, 928, 908m was allocated to the sector to supplement infrastructure budgets in 2014/15 financial year and was all transferred to respective PEDs in five installments. • The Western Cape allocation was adjusted by the AISIDI allocation for 2014/15 which was converted from a schedule 7 to a schedule 4 grant amounting to R397, 676 million. • The spending as at end of 2014/15 financial year was R7, 041, 826 million or 93% of the adjusted allocation. This spending is 6% less than the 99% spending reported at end of 2013/14 financial year. • The highest spending provinces on the grant are KZN, MP NC all at 100%. While MP has spent the entire budget, it underspent the Equitable Share portion of their infrastructure allocation. • Free State and Eastern Cape were the lowest spending provinces on the grant at 76% and 77% respectively. Education Infrastructure Grant Expenditure for 2014/15 Financial Year Education Infrastructure Grant Projected Province Allocated Budget Adjusted 2014/15 Adjustments Budget Eastern Cape R 1 177 914 R Free State R 554 313 R Gauteng R 623 602 R KwaZulu-Natal R 1 385 781 R Limpopo R 1 108 625 R Mpumalanga North West R 623 602 R R 623 602 R Northern Cape R Western Cape R TOTAL Transferred as at Total Spent as at end March 2015 end March 2015 Over/Under % of Budget Spent Spending - R 53 268 R 1 177 914 R 607 581 R 1 177 914 R 554 313 R 904 590 77% R 273 324 459 638 76% R 147 943 - R - R 623 602 R 1 385 781 R 623 602 R 1 385 781 R 617 784 99% R 5 818 - R - R 1 108 625 R 623 602 R 1 108 625 R 623 602 R 1 096 322 695 787 R 346 445 R 623 602 R 346 445 R 599 271 346 445 R 72 185 R - R 485 024 R 536 310 R 1 021 334 R 882 700 R 1 008 420 99% R 12 914 R 7 041 826 93% R 548 845 R 6 928 908 R 661 763 R 7 590 671 R 7 326 584 1 385 781 623 601 346 419 100% 99% R 12 303 100% 86% R 96 516 100% Education Infrastructure Grant Expenditure for 2014/15 Financial Year Eastern Cape • The PED had cited a number of reasons which led to the under spending. •Coega Development sanitation programme had reported low spending expenditure due to a 2 to 3 month delay with procurement of contractors. CDC (Coega) were allocated projects amounting to R100m (subsequently reduced to R65m) on which their appointment of PSPs and contractors took extremely long due to internal procurement issues. •Delays in implementation of some of Department of Public Works’ large projects due to labour unrest & strikes, examples are that of Jeffreys Bay Primary School, Sunshine Special School, and Jubilee Park Primary School. •Also delays in replacing terminated contracts at Klipfontein Primary School & St Matthews Senior Secondary School due to non-performance. Free State •The PED had cited delays in supply chain management processes where delays in the appointment of some projects led to re-advertisement. This had adverse consequences as multiple projects were clustered to ease management. •Amongst others, cash flow management measures introduced to control the anticipated general over-expenditure of the Department of Education budget. Education Infrastructure Grant Expenditure for 2014/15 Financial Year North West The PED had cited challenges which led to under spending as follows: • New schools implemented by DoE were delayed due to SCM (Supply Chain Management Unit) taking long time evaluate, adjudicate and awarding contracts to successful bidders on time. These processes result into late appointment of contractors. •There were disruptions by the communities on 2 major projects. These protests were as a result of sub-contractors who were demanding that they be paid more from the contract. They demanded to be paid 30% of the contract value of the project thus causing more delay to the actual progress to be registered.(Examples. Alabama and Oukassie Primary Schools) •Community unrests at Schweizer Reneke Primary with members of the community demanding to be employed without meeting proper requirements. •There had also been challenges related to Tribal authorities - land disputes between tribal authority and Local municipality. •Transfer of projects to DPW as implementing agent led to delays in implementation of the programme. This followed the decision by EXCO to have infrastructure projects implemented by Public Works in the province. •Poor performance of contractors and consultants and thus delays in submitting invoices. SCHOOL BUILD PROGRAMME • The Provincial Schools Build Programme targets new schools, additions to existing schools, new and upgrading of services and maintenance • 12 299 projects are in the pipeline, which commences with identification, feasibility, design, tender, construction, retention and hand-over stages • As at end March 2015, 3 477 projects are in construction, with 3 463 in practical and final completion phases. EASTERN CAPE PROJECT PIPELINE Project Status movement Eastern Cape Q4 Q1 Q2 Q3 Q4 2013/14 2014/15 2014/15 2014/15 2014/15 0 0 0 0 0 Pre-Feasibility 760 660 660 653 653 Feasibility 410 337 337 399 402 Design 6 15 15 13 12 Tender 21 42 42 43 45 Project Initiation 0 0 0 2 2 790 869 609 465 609 465 590 498 583 507 Final Completion 0 569 569 564 568 On Hold 0 2 2 3 4 4 4 6 6 Site Hand Over to contractors Construction Practical Completion Terminated Status not captured Total 0 0 0 0 0 2856 2703 2703 2771 2782 11 projects were added into the system in the fourth quarter. The movement of project pipeline from the third to fourth quarter is almost insignificant. A significant number of projects are still sitting in both identified and feasibility stages and not filtering to design and tender and thus getting ready for implementation. The PED can be commended for closing out most of the projects which were sitting in retention at end of 2013/14 financial year. FREE STATE PROJECT PIPELINE Project Status movement Free State Q4 Q1 Q2 Q3 Q4 2013/14 2014/15 2014/15 2014/15 2014/15 Project Initiation 0 0 0 0 0 Pre-Feasibility 4 0 0 0 0 Feasibility 0 0 0 0 0 Design 0 558 558 558 558 Tender 0 0 0 0 0 Site Hand Over to contractor 0 5 5 5 5 186 0 33 0 33 0 38 0 38 0 Final Completion 0 0 0 0 0 On Hold 0 0 0 0 0 Terminated 0 0 0 0 0 Status not captured 0 0 0 0 0 190 596 596 601 601 Construction Practical Completion Total It was observed that the PED had maintained a stagnant pipeline throughout the financial year and in the next financial year would need to ensure that the projects sitting in design stage filter through to tender, and then construction . GAUTENG PROJECT PIPELINE Project Status movement Gauteng Q4 Q1 Q2 Q3 Q4 2013/14 2014/15 2014/15 2014/15 2014/15 0 0 0 0 278 18 182 423 423 1 6 4 2 2 3 Design 102 275 100 105 35 Tender 47 182 116 119 54 0 0 0 0 92 235 97 275 58 122 58 122 328 98 Final Completion 0 0 0 0 58 On Hold 0 0 22 22 47 Terminated Status not captured 0 0 1 1 0 0 0 0 0 9 500 1015 844 852 911 Project Initiation Pre-Feasibility Feasibility Site Hand Over to Contractors Construction Practical Completion Total A total of 59 projects were added into the system in the last quarter of the financial year. The PED reported that a total of 58 projects were closed out in the last quarter of the financial year. The PED needs to ensure that the huge number of projects at pre-feasibility stage filters through and thus getting ready for implementation. KWAZULU-NATAL PROJECT PIPELINE Project Status movement KwaZulu Natal Q4 Q1 Q2 Q3 Q4 2013/14 2014/15 2014/15 2014/15 2014/15 0 1 1 6 6 Pre-Feasibility 258 223 222 219 219 Feasibility 930 875 875 869 869 Design 420 475 474 474 474 Tender 179 166 166 161 161 0 2 2 2 2 Practical Completion 2167 789 1489 784 1505 779 836 858 836 858 Final Completion 148 93 95 694 694 0 1 1 1 1 27 6 6 6 6 0 1 0 0 0 4918 4116 4126 4126 4126 Project Initiation Site Hand Over to Contractors Construction On Hold Terminated Status not captured Total The PED does show a smooth pipeline of projects; however, for the last two quarters of the financial year the pipeline has been stagnant. The PED has maintained just above 474 projects in design stage throughout the financial year. The PED can be commended for closing out 694 projects in the financial year. LIMPOPO PROJECT PIPELINE Project Status movement Limpopo Q4 Q1 Q2 Q3 Q4 2013/14 2014/15 2014/15 2014/15 2014/15 0 0 1 0 0 1072 0 0 0 0 1 1 1 1 1 Design 87 128 218 209 177 Tender 16 11 9 7 7 1 1 0 0 252 230 1117 311 1209 320 1307 382 1245 464 Final Completion 1 0 0 0 90 On Hold 0 0 0 0 0 Terminated Status not captured 0 0 1 2 2 0 0 0 0 0 1659 1569 1760 1908 1986 Project Initiation Pre-Feasibility Feasibility Site Hand Over to Contractors Construction Practical Completion Total The province added a total of 76 projects into the system in the last quarter of the financial year. The pipeline did not show any projects prior design stage. A total of 90 projects were closed out in the last quarter. The projects sitting at design stage would need to filter through to tender stage and thus getting ready for implementation. The province added a total number of 327 projects since the beginning of the financial year. MPUMALANGA PROJECT PIPELINE Project Status movement Mpumalanga Q4 Q1 Q2 Q3 Q4 2013/14 2014/15 2014/15 2014/15 2014/15 0 78 76 75 74 45 0 0 0 0 Feasibility 0 1 4 1 0 Design 6 0 0 1 2 Tender 5 4 27 19 9 0 2 1 14 49 229 39 83 35 85 56 110 41 136 71 38 62 89 91 On Hold 0 22 21 17 8 Terminated 1 1 2 2 2 Status not captured 0 0 0 0 0 406 266 314 371 377 Project Initiation Pre-Feasibility Site Hand Over to Contractors Construction Practical Completion Final Completion Total A total of 91 projects were closed out in the financial year. The project pipeline shows that the PED identified some projects at the beginning of the financial year; however these seem not to have filtered through and thus getting ready for implementation. NORTH WEST PROJECT PIPELINE Project Status movement North W est Q4 Q1 Q2 Q3 Q4 2013/14 2014/15 2014/15 2014/15 2014/15 0 0 0 73 64 316 274 246 243 241 1 1 0 0 0 Design 15 5 5 5 5 Tender 96 58 53 49 50 1 2 2 1 129 33 201 38 202 68 211 70 215 75 1 0 0 0 0 1 1 1 3 Project Initiation Pre-Feasibility Feasibility Ste Hand Over to Contractors Construction Practical Completion Final Completion On Hold Terminated 5 0 0 0 0 Status not captured 0 0 0 0 0 596 579 577 654 654 Total There hasn’t been any project reported as closed out in the entire financial year. The PED shows a smooth movement of projects within the system, though more of the identified projects should filter through to feasibility stage. NORTHERN CAPE PROJECT PIPELINE Project Status movement Northern Cape Q4 Q1 Q1 Q3 Q4 2013/14 2014/15 2014/15 2014/15 2014/15 Project Initiation 0 252 219 211 193 Pre-Feasibility 0 5 1 0 0 Feasibility 0 10 2 2 2 Design 138 12 11 10 7 Tender 8 4 9 7 5 Site Hand Over to Contractors 0 9 7 3 2 113 46 188 39 219 90 231 118 230 114 Final Completion 0 0 2 47 108 On Hold 0 0 1 1 1 Terminated 1 2 2 2 2 Status not captured 0 0 0 0 0 306 521 563 632 664 Construction Practical completion Total The province added a total of 32 projects into the system in the fourth quarter. The PED needs to filter projects sitting in design stage through to tender to ensure that there is a pool of projects ready for implementation. The PED can be commended for closing out 108 projects as at end of the financial year. WESTERN CAPE PROJECT PIPELINE Project Status movement Western Cape Q4 Q1 Q2 Q3 Q4 2013/14 2014/15 2014/15 2014/15 2014/15 Project Initiation 0 2 1 2 2 Pre-Feasibility 0 8 1 0 0 Feasibility 19 33 11 11 16 Design 23 42 33 24 25 Tender 4 15 19 24 21 Site Hand Over to Contractors 0 9 2 0 0 Practical Completion 52 40 80 15 64 18 71 19 58 37 Final Completion 11 0 0 0 0 On Hold 0 0 37 36 32 Terminated 0 0 0 0 0 Status not captured 0 0 1 1 1 149 204 187 188 192 Construction Total The PED does not did not report any projects in the initial stages of project implementation. About 37 projects were completed in the financial year. The PED did not report any projects under final completion stage. HR Capacitation for School Infrastructure Delivery • The education sector has identified lack of appropriate capacity as a impeding factor in school infrastructure delivery. The process of strengthening Infrastructure delivery capacity in the Provincial Education Infrastructure units has been ongoing, with the key objective of recruiting and appointing of built environment and finance personnel for improving school infrastructure delivery in our provinces. A total of 153 vacancies have been filled. Provicial Town & Ed. Infrastructure Quantity Elec.Engi Civil GIS Regional Facility Works Finance Unit Surveyors Architects neers Engineers Specialists Planners Planners Inspectors Posts Eastern Cape 4 4 0 0 1 1 0 1 3 Free State 1 3 2 0 0 0 0 2 3 Gauteng 3 3 1 1 0 1 2 6 2 KwaZulu0 0 0 0 0 0 0 25 12 Natal Limpopo 0 2 0 0 1 0 0 0 2 Mpumalanga 6 4 0 2 0 0 0 8 4 Northern 2 Cape 1 0 0 0 1 1 4 6 North West 2 1 0 0 0 1 0 5 3 Western 0 Cape 2 0 0 0 1 1 8 4 Total 18 20 3 3 2 5 4 59 39 Total 14 11 19 37 5 24 15 12 16 153 HR Capacitation for School Infrastructure Delivery • Provinces have been provided a maximum of R26 million from the Education Infrastructure Grant in the 2014/15 financial year for the appointment of public servants to their infrastructure units. • This funding has been increased to R32.9 million in the 2015/16 financial year for the process to be taken through to district level. The Initiatives aimed at capacitating district offices are also being addressed as building operational capacity at these levels as infrastructure needs and progress is monitored at district level. • The sector has continued to engage with the Department of Public Service and Administration in working out market competitive remunerative strategies to ensure that the posts are attractive for the more experienced candidates to take up in all nine provinces. Monitoring Infrastructure Delivery in the Education Sector • DBE has established a PSU within the DBE to monitor the implementation of infrastructure and services provision by the various Professional Service Providers (PSP’s) and Implementing Agents (IA’s) that the Department of Basic Education and provinces are utilizing for the implementation of the infrastructure programme. • The PSU is responsible for continuously tracking progress on projects; inspecting work in progress and in completed projects to evaluate quality of work as well as monitoring expenditure per project on a monthly basis • DBE has also increased its monitoring capacity and monitoring visits are conducted twice annually where planning, budgetting , expenditure, monitoring, project management and procurement issues are interrogated and a sample of projects are visited. Based on the findings from these visits, remedial actions are 18 devised with the province and monitored by the DBE. Monitoring Infrastructure Delivery in the Education Sector • • - Monitoring deals with both programme and project matters; Programme matters include; The pattern of overall expenditure being achieved; Comparisons of expenditure to projected cash flows; Progress being made with key groups of projects [eg. Water, sanitation, libraries, laboratories, Grade R] • At the Project level the focus is on ensuring : - that planning and design processes are progressing; - that the tender process for the appointment of contractors is progressing, that construction is progressing satisfactorily, [i.e. on programme, on budget, at acceptable quality…]; - that projects are being handed over and closed out and that final accounts are being wrapped up Approach to Monitoring • Projects that have been implemented over a long period of time, especially those in excess of 12 to 18 months. • Projects that are in critical phases of construction so that workmanship could be monitored and evaluated. • Projects that have had significant cost variation. • Projects that have not had showed progress on delivery in relation to the finances progress • Projects with a high monetary value; • Special Schools; Projects Strengthen Planning and visited Monitoring capacity Provicial Infrastructure Unit Number of Projects Eastern Cape 14 Free State 6 Gauteng 6 KwaZulu-Natal 5 Limpopo 11 Mpumalanga 7 Northern Cape 5 North West 6 Western Cape 10 Total 70 Cumulative Monetary value of Projects '000 R 207 688 R 103 421 R 490 606 R 410 363 R 339 014 R 489 180 R 78 221 R 411 375 R 401 765 R 2 931 633 Monitoring Infrastructure Delivery (Photographs) Progress on Delivery TOTAL CPMPLETED PROGRESS 18 3 9 12 14 18 2 10 10 32 5 24 12 13 19 0 2 14 178% 167% 267% 100% 93% 106% 0% 20% 140% 96 121 126% TOTAL FOURTH QUARTER THIRD QUARTER SECOND QUARTER TARGETS TOTAL REPLACEMENT SCHOOLS FOURTH QUARTER THIRD QUARTER SECOND QUARTER FIRST QUARTER TARGETS Number of new & additional facilities completed NEW SCHOOLS FIRST QUARTER Infrastructure Projects Completed TOTAL SCHOOLS TARGETED SUMMARY OF PROJECTS COMPLETED FOR THE 2014-2015 FINANCIAL YEAR Number of Schools Eastern Cape Free State Gauteng KwaZulu Natal Limpopo Mpumalanga Northern Cape North West Western Cape Total Number of Schools 4 3 9 8 9 13 2 8 7 11 3 3 0 2 0 0 0 0 63 19 8 2 4 17 10 6 1 1 2 3 19 3 24 10 10 5 0 2 4 39 77 4 11 8 14 0 0 4 5 5 0 2 3 1 0 0 0 0 0 0 0 0 33 1 12 1 9 13 2 0 2 3 14 0 0 10 5 36 44 2 2 1 1 2 2 13 Progress on Delivery 21 17 47 50 49 18 0 1 5 0 30 2 6 1 0 4 0 0 0 0 5 5 3 4 9 12 3 4 13 12 0 1 1 6 Administrative space 231 4 16 35 64 161 4 12 26 53 72 4 9 15 12 36 0 0 6 2 66 4 9 14 11 96 0 1 9 8 21 0 0 5 1 66 4 9 14 11 45 3 5 6 7 4 10 28 32 8 6 177 121 140 67 0 7 26 13 5 3 8 2 10 1 119 95 40 8 38 18 6 38 21 776 339 215 184 208 172 1 208 127 61 44 12 9 13 18 7 20 6 27 33 4 1 4 3 0 4 3 TOTAL 6 119 288 19 68 1 14 TOTAL 76 42 2 FOURTH QUARTER 143 66 20 Teaching space 1905 271 270 248 397 1186 85 28 20 16 23 87 51 4 8 25 8 45 THIRD QUARTER 2598 560 118 TOTAL FOURTH QUARTER THIRD QUARTER SECOND QUARTER SECOND QUARTER of offices of storerooms of safes / strongrooms of photocopying rooms of staffrooms of sickrooms of tuckshops of kitchen for staff of nutrition centres FIRST QUARTER Number Number Number Number Number Number Number Number Number EXISTING SCHOOLS TARGET 2014/15 Number of ordinary classrooms Number of Grade R classrooms Number of multi purpose classrooms Number of multi media centres (Library+ computer) Number of Technical workshops Number of Laboratories Number of Libraries Number of computer rooms Number of halls / forums FIRST QUARTER Number of new & additional facilities completed NEW SCHOOLS TARGET 2014/15 Infrastructure Projects Completed 626 195 37 1812 282 82 7 16 22 0 2 1 2 1 0 9 7 13 5 3 26 36 38 12 7 36 64 70 20 0 0 0 0 0 0 0 0 0 84 37 16 9 14 14 3 14 13 172 114 32 19 31 35 10 38 22 291 209 72 27 69 53 16 76 43 Progress on Delivery TARGET 2014/15 FIRST QUARTER SECOND QUARTER THIRD QUARTER FOURTH QUARTER TOTAL 74 46 260 71 24 8 10 18 60 320 0 0 0 0 0 0 247 72 199 29 20 320 320 TOTAL TOTAL 75 THIRD QUARTER 65 FIRST QUARTER FOURTH QUARTER EXIST ING SCHOOLS 204 TARGET 2014/15 Number of new & additional facilities completed NEW SCHOOLS SECOND QUARTER Infrastructure Projects Completed Water No water - number of schools to be provided with water Upgrading of water facilities - number of schools Sanitation No ablution facilities - number of schools to be provided with sanitation Additional & upgrading of sanitation facilities - number of schools 201 46 61 61 29 197 136 42 8 16 58 124 321 0 0 0 0 0 0 205 85 175 43 19 322 322 Energy No source of electricity - number of schools to be provided with electricity Upgrading of electricity - number of schools 134 30 27 27 19 103 144 4 10 5 27 46 149 0 0 0 0 0 0 41 5 11 6 4 26 26 131 20 29 34 21 104 111 15 11 3 1 30 134 0 0 0 0 0 0 77 36 39 6 10 91 91 Fencing No fencing - number of schools to be provided with fencing Upgrading of existing fencing - number of schools Sport facilities No sport facilities - number of schools to be provided with sport facilities Upgrading of sport facilities number of schools 41 0 2 4 5 11 23 0 0 0 0 0 11 0 0 0 0 0 0 29 7 6 12 5 30 30 911 68 391 67 79 605 605 Maintenance, upgrading projects Maintenance / upgrading / renovations number of schools 0 0 0 0 0 0 EIG Allocations -2015/16 MTEF PROVINCE Eastern Cape Allocation MTEF Estimates 2015/16 2016/17 2017/18 R'000 R'000 R'000 1 703 877 1 532 003 1 400 000 R'000 4 635 880 Free State 762 552 707 553 742 931 2 213 036 Gauteng 935 725 1 274 825 1 428 566 3 639 116 KwaZulu-Natal 1 978 684 1 857 648 1 950 530 5 786 862 Limpopo 805 128 845 384 953 589 2 604 101 Mpumalanga 857 247 802 247 842 359 2 501 853 Northern Cape 446 998 359 545 300 000 1 106 543 North West 995 107 853 678 842 359 2 691 144 Western Cape 1 032 237 874 263 860 226 2 766 726 Unallocated 666 546 1 010 002 1 676 548 Total 9 517 555 9 773 692 10 330 562 29 621 809 26 2015-2019 Plans New and replacement schools Shools Build Programme Project Milestones Provincial Education Department Year 1 (2014/2015) 18 Eastern Cape Free State 3 Gauteng 9 KwaZulu Natal 12 Limpopo 14 Mpumalanga 18 Northern Cape 2 North West 10 10 Western Cape Total 96 Year 2 (2015/2016) 20 3 17 11 16 15 6 6 11 105 Year 3 (2016/2017) 27 5 15 9 15 16 1 6 12 106 Year 4 (2017/2018) 33 4 15 11 17 15 2 4 17 118 Total Number of Year 5 Schools per (2018/2019) province 37 135 4 19 15 71 21 64 16 78 4 68 2 13 4 30 16 66 119 544 2015-2019 Plans New and replacement schools New and Replacement Schools Targeted 600 Number of Projects 500 400 300 200 100 0 Eastern Cape Free State Gauten KwaZul Limpop Mpumal Norther North g u Natal o anga n Cape West Wester n Cape Total New Schools 15 9 71 11 30 22 6 5 33 139 Replacement Schools 120 10 0 53 48 46 7 25 33 261 Total Schools built 135 19 71 64 78 68 13 30 66 544 2015/16 Plans Teaching spaces Number of new & additional facilities to be completed NEW SCHOOLS EXISTING SCHOOLS TOTAL 2015/16 TARGET 2015/16 TARGET 2015/16 2949 3202 6151 192 450 642 98 198 296 Number of multi media centres (Library+ computer) 25 22 47 Number of Technical workshops 16 9 25 Number of Laboratories 112 183 295 Number of Libraries Number of computer rooms 95 101 196 101 125 226 78 65 143 Number of ordinary classrooms Number of Grade R classrooms Number of multi purpose classrooms Number of halls / forums 2015/16 Plans Number of new & additional facilities to be completed NEW SCHOOLS EXISTING SCHOOLS TOTAL 2015/16 TARGET 2015/16 TARGET 2015/16 Number of offices 403 1229 1632 Number of storerooms 649 668 1317 Number of safes / strongrooms 108 298 406 Number of photocopying rooms 60 276 336 Number of staffrooms 87 276 363 Number of sickrooms 183 290 473 Number of tuckshops 31 6 37 Number of kitchen for staff 98 282 380 Number of nutrition centres 70 272 342 2015/16 Plans Number of new & additional facilities to be completed NEW SCHOOLS EXISTING SCHOOLS TARGET 2015/16 TARGET 2015/16 TOTAL TARGET 2015/16 Water No water - number of schools to be provided with water 148 249 397 Upgrading of water facilities number of schools 101 143 244 Sanitation No ablution facilities - number of schools to be provided with sanitation 161 453 614 Additional & upgrading of sanitation facilities - number of schools 192 3617 3809 Energy No source of electricity - number of schools to be provided with electricity 111 105 216 Upgrading of electricity - number of schools 0 43 43 2015/16 Plans NEW SCHOOLS Number of new & additional facilities to be completed TARGET 2015/16 EXISTING SCHOOLS TOTAL TARGET 2015/16 TARGET 2015/16 Sport facilities No sport facilities - number of schools to be provided with sport facilities 90 3 93 Upgrading of sport facilities number of schools 0 23 23 Maintenance, upgrading projects Maintenance / upgrading / renovations - number of schools 0 4488 4488 Provincial status- Provision of furniture Eastern Cape In 2014/15 financial year, there were 845 schools which were not covered in the provincial plan. DBE has committed to provide 845 of these schools with furniture Free Sate Gauteng Schools purchase furniture from their allocations An amount of R24 000 000 is allocated in this financial year. By end of March 2015, 15571 chairs, 3435 tables and 440 lab stools were delivered to 115 schools and to 300 grade R classrooms. The province is in the process of verifying the furniture need for the remaining schools that did not receive furniture Limpopo The province could not spend the budget allocated in 2014, meaning under expenditure of 100% was incurred by the province. The province has a budget cut from R55 596 000.00 to R35 000 000.00 in this financial year. KwaZulu Natal 3885 schools with shortage of school furniture were identified. There is no budget allocation for school furniture in the province. Schools purchase furniture from their allocations. Mpumalanga By end of March 2015 furniture has been delivered to 410 schools of the 661 planned. For this financial year school furniture allocation was increased to R82 000 000.00 North West A total of 225 schools were provided with furniture in the 2014/15 financial year 2014/15. The budget allocation for 2014/15 was R27million. The province has reduced the allocation to R8 500 000.00 in the 2015/16 financial year Northern Cape Schools purchase furniture from the allocated norms and standards funding. However, for 2015/16 the province has allocated a budget of R20million for existing schools. 62 schools have been targeted to receive furniture in the current financial year in the four districts. Furniture for new schools will be included in the contracts and will be funded from the EIG Western Cape By end of March 2015 furniture was delivered to all the schools with only chairs and teachers furniture which is currently being finalized. The budget allocation for this financial year is R16 539 000. Furniture to the value of R10 953 123.92 has been ordered to cater for all the needs 33 Thanks Website: www.education.gov.za Call Centre: 0800 202 933 | callcentre@dbe.gov.za Twitter: @DBE_SA | Facebook: DBE SA