The Do’s and Don’ts of Government Construction Contracts Or David Letterman’s Top Ten Traps for the Unwary Joseph C. Kovars, Esq. Ober|Kaler 100 Light Street Baltimore, MD 21202 jckovars@ober.com | 410.347.7343 Barbara G. Werther, Esq. Ober|Kaler 1401 H Street, N.W. Washington, DC 2005 bwerther@ober.com | 202.326.5015 www.ober.com Top Ten Traps 1. 2. 3. 4. 5. 6. 7. 8. 9. 10. Authority to bind the Government Funding of contract—Anti-Deficiency Act Recognizing constructive changes Notice requirements Bilateral modification releases Documentation: letter in/letter out Updating schedules Cure notices/show cause Claim certification False claims 2 www.ober.com Federal Acquisition Regulation (FAR) Provides uniform policies and procedures for acquisitions by Federal Gov’t agencies Parts 1-51 are policies and instructions Part 52 is standard form clauses Part 53 is forms FAR clauses apply to the extent they are incorporated into the contract, either full text or by reference. The Christian Doctrine 3 www.ober.com Procurement Methods for Construction Sealed bidding – FAR Part 14 Only used where price is sole basis for award Contracting by Negotiation – FAR Part 15 Used when factors other than price are considered Used for “Best Value” procurements “Negotiation” is a term of art – its not a real negotiation! 4 www.ober.com Sealed Bidding Invitation for Bid (IFB) is used Bids are publicly opened Award goes to lowest price, responsive bid by a responsible bidder “Responsive” bid means complies in every respect with the requirements of the IFB (FAR 14.404-2) “Responsible” bidder refers to financial resources, integrity, organization and skills, ability to meet schedule, and past performance (FAR Part 9.1) Firm, fixed-price contract results. 5 www.ober.com Contracting By Negotiation Request for Proposals is used (RFP) Tradeoff between price and other factors (Best Value) Evaluation factors and significant sub-factors must be clearly stated (Section M of RFP) Must state whether all other factors are more important, less important or equally important as price Separate technical and price proposals submitted (separate volumes) 6 www.ober.com Contracting By Negotiation - 2 Technical evaluation by technical team Price evaluation by price team Technical & price kept separate until final selection decision Oral presentations can be used Can typically award on basis of initial proposals without “discussions” Or can hold “discussions”, followed by BAFO 7 www.ober.com Contracting By Negotiation - 3 If discussions are held with one offeror, must hold discussions with all within competitive range Discussions must indicate deficiencies, significant weaknesses and adverse past performance information Exceptions may be taken, but are risky Additional features and enhancements may be offered 8 www.ober.com Contracting By Negotiation - 3 Debriefing of unsuccessful offerors available on request When to protest? What’s the likelihood of winning a protest? 9 www.ober.com Funding – Anti-Deficiency Act Procurements are funded through appropriations. The appropriation is listed on the contract form; should be checked. Anti-Deficiency Act prohibits: Making or authorizing an expenditure or creating or authorizing an obligation in excess of the amount available in the appropriation or fund unless authorized by law. (31 U.S.C. s. 1341(a)(1)(B)) 10 www.ober.com Funding – Anti-Deficiency Act Anti-Deficiency Act -- Government’s representatives cannot make any payment or a commitment to make payment for work unless there are sufficient funds “in the bank” (in the appropriation) to cover the cost in full. What does this mean in terms of the multiyear construction project? 11 www.ober.com Funding – Anti-Deficiency Act Limitation of Funds clause (FAR 52.232-22) - Monitor costs and notify at 75%. Right to stop work. Availability of Funds clause (FAR 52.232-19) – “Funds are not presently available for performance beyond ______. . .” Implied right to stop work. What happens when the Government runs out of money and there is no new appropriation? 12 www.ober.com Changes FAR 52.243-4 CHANGES (JUNE 2007) (a) The Contracting Officer may, at any time, without notice to the sureties, if any, by written order designated or indicated to be a change order, make changes in the work within the general scope of the contract, including changes -(1) In the specifications (including drawings and designs); (2) In the method or manner of performance of the work; (3) In the Government-furnished property or services; or (4) Directing acceleration in the performance of the work. 13 www.ober.com Changes (b) Any other written or oral order (which, as used in this paragraph (b), includes direction, instruction, interpretation, or determination) from the Contracting Officer that causes a change shall be treated as a change order under this clause; provided, that the Contractor gives the Contracting Officer written notice stating (1) the date, circumstances, and source of the order and (2) that the Contractor regards the order as a change order. (c) Except as provided in this clause, no order, statement, or conduct of the Contracting Officer shall be treated as a change under this clause or entitle the Contractor to an equitable adjustment. 14 www.ober.com Changes (d) If any change under this clause causes an increase or decrease in the Contractor's cost of, or the time required for, the performance of any part of the work under this contract, whether or not changed by any such order, the Contracting Officer shall make an equitable adjustment and modify the contract in writing. However, except for an adjustment based on defective specifications, no adjustment for any change under paragraph (b) of this clause shall be made for any costs incurred more than 20 days before the Contractor gives written notice as required. In the case of defective specifications for which the Government is responsible, the equitable adjustment shall include any increased cost reasonably incurred by the Contractor in attempting to comply with the defective 15 www.ober.com specifications. Changes (e) The Contractor must assert its right to an adjustment under this clause within 30 days after (1) receipt of a written change order under paragraph (a) of this clause or (2) the furnishing of a written notice under paragraph (b) of this clause, by submitting to the Contracting Officer a written statement describing the general nature and amount of proposal, unless this period is extended by the Government. The statement of proposal for adjustment may be included in the notice under paragraph (b) above. (f) No proposal by the Contractor for an equitable adjustment shall be allowed if asserted after final payment under this contract. 16 www.ober.com Changes The contractor is required to perform the changed work as directed and make claim under the Disputes Clause if not paid. (Constructive change or dispute over unilateral amount granted). FAR 52.233-1(i) Permissible scope of changes Drawings and specifications Method or manner of performance GFM/GFP Directed acceleration Time of performance (nights, weekends) Place of performance 17 www.ober.com Changes Types of Changes » Formal » Constructive Formal/Express Changes Directed change or CCD – unilateral from Government Bilateral – supplemental modification to contract Accord and satisfaction Reservation of rights Who may initiate? Either party 18 www.ober.com Changes Constructive Changes: Conduct by C.O. or authorized representative which has the effect of causing the Contractor to perform work different from that set forth in the contract, Even when not described or acknowledged as a change. 19 www.ober.com Changes Elements of a Change Direction to do something different from existing contract Within the general scope of the contract Issued by C.O. (or duly authorized representative) 20 www.ober.com Changes What does “within the general scope” of the contract mean? No exact formula 99.99% of every change you will ever see. Prohibition on issuing changes outside the general scope because significantly different work should be put out for bid. Changes beyond general scope are “cardinal changes.” 21 www.ober.com Changes Cardinal change 1965, Wunderlich Constructing Co. v. U.S., Court of Claims says changes beyond the general scope of the contract are “cardinal changes” The number of changes, in and of itself, is not necessarily a cardinal change More of the same kind of work (i.e., more asbestos abatement) not a cardinal change Direction to build an airstrip when the contract was for the terminal probably is a cardinal change 22 www.ober.com Changes - Authority Who has authority to issue changes to the Contract? (FAR 1.603-3(a)) Only the C.O. (or authorized representative) has authority to bind the Government and modify the contract Who is the C.O. ? What is authority of COTR?, ROICC?, etc. 23 www.ober.com Changes - Authority The Government is not legally bound by unauthorized acts or acts of unauthorized agents Apparent Authority is NOT AVAILABLE AGAINST THE GOVERNMENT. Contractor’s duty to assure authority behind direction. Don’t be a “Volunteer.” 24 www.ober.com Changes - Authority When is the Government bound by unauthorized actions? Implied Authority/Course of Conduct Ratification Equitable Estoppel 25 www.ober.com Changes - Authority Who does not have authority? Inspectors Contract administrators Getting confirmation: If you are “directed” by a Government representative, send a letter to the C.O. and ask the C.O. if you are to comply with the directive, i.e., have the C.O. ratify the “directive.” 26 www.ober.com Constructive Changes What is a constructive change? (Subsection (b) of the changes clause) (1) A directive to the Contractor (2) Requiring the Contractor to perform additional or changed work (3) Contractor relied on the Government direction and incurred increased cost, added time (4) Notice given 27 www.ober.com Changes - Types of Constructive Changes 1. Interpretation of specifications and drawings Ambiguity in the specifications/drawings Patent vs. latent The ambiguity is latent The contractor’s interpretation is reasonable The Government has a different interpretation and tells the contractor to perform in accordance with the Government’s interpretation The contractor incurs additional costs by complying with Government’s interpretation 28 www.ober.com Changes - Types of Constructive Changes 2. Inconsistencies between drawings and specifications FAR 52.236-21: If only in specifications, or only in drawings, treat as if mentioned in both places In case of difference, specifications govern over drawings If the discrepancy is patent, duty to inquire pre-bid If the discrepancy is latent, give notice, segregate costs 29 www.ober.com Changes - Types of Constructive Changes 3. Defective Specification The Government warrants the adequacy of its specifications Must be a design specification (implied warranty on Government under Spearin) Specifications contain errors, omissions, inconsistencies Contractor entitled to costs of attempting to comply and for performing corrective work 30 www.ober.com 31 www.ober.com Changes - Types of Constructive Changes 3. Defective Specification The Government warrants the adequacy of its specifications Must be a design specification (implied warranty on Government under Spearin) Specifications contain errors, omissions, inconsistencies Contractor entitled to costs of attempting to comply and for performing corrective work 32 www.ober.com Changes - Types of Constructive Changes Risk of Specification Problems Design Specifications – Government owns risk Performance Specifications – Contractor owns risk Mixed Specifications – It depends (analyze in detail) 33 www.ober.com 34 www.ober.com Changes – Types of Constructive Changes Risk of Specification Problems (cont’d) Design-Build Contracting Building Information Modeling (BIM) 35 www.ober.com BIM 36 www.ober.com Changes - Types of Constructive Changes 4. Inspection and Testing Government over-inspection Improper or incompetent rejection Government directs a change in testing method or frequency More stringent testing procedure than that set forth in contract Interference by Government in unreasonable inspecting during performance 37 www.ober.com Changes - Types of Constructive Changes 5. Changes In The Method And Manner Of Performance Where C.O. insists on a change in the contractor’s method and manner of performance of the work Contractor can recover the difference in cost between its method and Government’s method Example – change in planned sequence 38 www.ober.com Changes - Types of Constructive Changes 6. Constructive Acceleration When Government effectively requires the contractor to finish earlier than planned 39 www.ober.com Changes - Types of Constructive Changes 7. Duties of Cooperation, Not to Hinder NTP issued, but contractor not permitted to construct road to worksite Work on railroad tracks can only be performed with Owner’s flagmen and at night, but no flagmen work at night C.O. withheld design fix from contractor and charged contractor LDs for not finishing “on time” 40 www.ober.com Changes - Types of Constructive Changes 8. Cumulative Impact Combined impact of a large number of changes Ripple effect Note: Low rate of success in cases. Measurement of damages is “amorphous.” Be careful when signing modifications Bell BCI v. United States (Fed. Cir. 2009) 41 www.ober.com Changes Notice Requirements Notice must be timely Notice must be in writing Notice must be sent to the C.O. Notice must set forth the nature of the claim Constructive changes– notice relates back 20 days, as to costs incurred No time limit for defective specifications 42 www.ober.com Changes Exceptions to Strict Notice Requirements (1) Where the Government knew about the basis of the claim * Actual knowledge can be shown from Government records * * * Presence of Government personnel on jobsite Acts of Government in working with contractor to address issue Meetings (2) Where the Government considers the claim on the merits without complaining about lack of notice (3) Where the Government is not prejudiced by the lack of notice * Government has burden of proving it was prejudiced * Prejudice occurs if Government cannot mitigate expense 43 or elect any one of available options www.ober.com Changes Contractor Duty to Proceed The Contractor must perform the changed work – C.O. can terminate contract for default if contractor does not proceed – Disputes Clause: Contractor can submit its claim Equitable Adjustment Price: – Bruce Construction v. U.S., 324 F.2d 516 (Ct. Cl. 1963) – “keep [a] contractor whole when the Government modifies the contract.” – “Actual, reasonable cost” ordinarily incurred because of the change » Actual cost plus reasonable OH + P – May include costs incurred for affected work areas not changed Time If the change order implicates work on the critical path, additional time may be required The Request for Equitable adjustment (REA) 44 www.ober.com Delays & Suspension Types of delays Excusable, Compensable, Unexcused Special Cases: –Sovereign vs. contractual acts; –Subcontractors & suppliers; –Bankruptcy & financial inability (unless Government caused) Compensable Special Case: –Differing Site Conditions 45 www.ober.com Delays & Acceleration Concurrent delays – burden on claiming party to untangle Net effect : excusable delay; no damages recoverable by either party Requires two delays on critical path Highly fact intensive The “Hurry Up and Wait” problem 46 www.ober.com Delays & Acceleration Notice requirements: 10 days. Prejudice rule. Boards believe in contemporaneous records. Right to early completion – conceptually accepted, but difficult to prove. Schedule must be realistic and relied upon 47 www.ober.com Delays & Acceleration Proving Delay Claims Sophistication of Boards and Court of Claims for delay claims CPM schedule is normal basis of proof Some cases even say hard to imagine proving claim without CPM analysis Sophisticated in review/analysis of CPM presentations TIA/Windows Impacted as planned, Collapsed as built, 48 www.ober.com Delays & Acceleration Important to use contemporaneous schedules and updates. Have solid schedule as early as possible Update it accurately and honestly. Will have to live with project schedule for claims purposes If Government restricts updates, create shadow schedule 49 www.ober.com Delays & Acceleration Acceleration Well recognized doctrine Actual and constructive Constructive – effect of requiring acceleration 50 www.ober.com Terminations Terminations for Default – FAR 52.249-10 Draconian – a “forfeiture” - disfavored High standard of proof Default termination is discretionary with C.O. Improper default termination is converted to a T for C High stakes – a dispute is “winner take all” 51 www.ober.com Terminations Terminations for Default (cont.) If default sticks, the government recovers its reprocurement costs from the defaulted contractor And, any other rights available to the Government, such as LDs Burden of proof is on the Government to show, by a preponderance of the evidence, that the default termination was proper. 52 www.ober.com Terminations Grounds for Default Termination A. Failure to complete the work within the time for the contract or any extension. B. “Failure to make progress” C. Repudiation by the contractor D. Contractor’s failure to perform its obligations under the contract E. Failure to provide adequate assurances that performance will proceed F. Failure to continue performance during a dispute 53 www.ober.com Terminations Cure Notice (or Show Cause) FAR 49.402-3(e) Required in supply contracts Not required in construction contracts But, Government often issues cure notice Take this very seriously Provide adequate assurances 54 www.ober.com Claims and Disputes Contract Disputes Act Basic statute governing claims Established claims process and forums for disputes Initiation of claim – submitted to CO, request Final Decision Definition of “claim” written assertion, matter of right, payment of sum certain 55 www.ober.com Claims and Disputes Must be Certified if over $100,000 Final Decision is prerequisite to appeal/litigation Final Decision must be provided in 60 days Unless it isn’t – can specify a longer period (usually 60 more) May consider claim as deemed denied” if not timely issued Interest from date of certification 56 www.ober.com Claims and Disputes Certification Requirement Classic trap for unwary Made by authorized person who can bind the company “Claim made in good faith” “Supporting data are accurate and complete to the best of my knowledge and belief” “Amount requested accurately reflects the adjustment for which the contractor believes the Government to be liable” 57 www.ober.com Claims and Disputes Under penalty of perjury False Claims Act liability – criminal and civil, company and personal Subcontractor issues – want subcontractor to certify to you Even if the sub does so, need to do due diligence independently, Can’t rely blindly on sub certification. Pass thru agreements-- need to remain liable to sub for what sub is claiming. 58 www.ober.com Claims and Disputes Appealing Contractor Performance Evaluation Todd Construction v. U. S., 656 F.3d 1306 (Fed. Cir. 2011) Pre-Todd Rule: Unsatisfactory performance evaluations not appealable. Post-Todd contractor may appeal UNSAT because it is a claim “relating to the performance under the contract.” To obtain judicial review, must comply with CDA claim certification requirements. 59 www.ober.com Recovering Costs from the Government Field overhead Can recover as percentage adder to direct costs, or as extended, time-related cost. Not both, and only consistent with general treatment. This generally means go with percentage markup. 60 www.ober.com Recovering Costs from the Government Unabsorbed home office overhead – Eichleay Formula So many restrictions that generally not worth the trouble any longer Among other things, requires essentially complete standby situation, and showing impracticable to take on replacement work 61 www.ober.com False Claims False Statements Act, 18 U.S.C. 1001 False Claims Act, 3729 (a)(1) and (a)(2) (a)(1) imposes contractor liability for knowingly presenting, or causing to be presented, false claims (a)(2) imposes contractor liability knowingly using false records or statements to obtain payment for false claims. Numerous Other Fraud/Falsification Statutes & Penalties 62 www.ober.com False Claims MAIN ELEMENTS: A claim for payment submitted to the Government Falsity (claim itself or records supporting) Knowing conduct 63 www.ober.com False Claims CLAIMS: Requests for progress payments Request for final payment Requests for Equitable Adjustments and Claims Statements Regarding the Quality of the Work 64 www.ober.com False Claims FALSITY: Does the Contractor’s Conduct Comport With Its Contractual, Regulatory, and Statutory Obligations Invoice misrepresenting quantity installed Invoice seeking payment for non-conforming work False certification of payment of Davis Bacon Act wages – Payment and/or proper classification of workers REA’s with factual misrepresentations. 65 www.ober.com False Claims Knowing Conduct: Did Contractor have: actual knowledge of the falsity, deliberately ignore the truth or falsity of the information, or act in reckless disregard of the truth or falsity of the information Did the Government have prior knowledge of the facts allegedly constituting a false claim? 66 www.ober.com False Claims OTHER EXAMPLES: False certifications of compliance with the contract requirements Representations of timely payment to subcontractors Billing amounts not intending to pay subs Seeking or obtaining payment for work the Contractor knows does not conform to the contract requirements Inflated quantities in an invoice 67 www.ober.com False Claims Daewoo v. United States Forfeiture of affirmative claim due to fraud $65 M claim became $50 M adverse judgment Affirmed on appeal Numerous mistakes -- Unclear consequences 68 www.ober.com Ethics/Compliance BASIC ELEMENTS: Written code of business ethics and code of conduct Internal audit of company policies, procedures and controls Mechanism for anonymous reporting of violations Compliance/ethics education program for employees Enforce disciplinary actions for violations Cooperation with government investigations 69 www.ober.com Ethics/Compliance Mandatory Disclosure Rule (FAR 52.203-13) • Contractor shall timely disclose in writing to OIG and CO, when credible evidence that the Contractor has: • Committed a violation of Federal criminal law (fraud, bribery, gratuities, conflict of interest); • Committed a violation of the civil False Claims Act; or • Obtained a significant overpayment from the Government. • Duty continues for 3 years following final payment. • Failure to make required disclosure is grounds for debarment. FAR 3.1003 70 www.ober.com Ethics and Conduct Requirements FAR 52.203-13 requires Contractors (except commercial item contracts and small businesses: Have a written code of ethics and conduct; Exercise due diligence to prevent and detect criminal conduct Encourage ethical conduct and promote a culture of ethical compliance Implement “ongoing business ethics awareness and compliance program” 71 www.ober.com Ethics/Compliance Procurement Integrity Act and FAR 52.203-14 require Contractors to “exercise due diligence” to ensure that no employee gains an unfair competitive advantage by possessing: Proprietary information obtained from a government official without permission, or Source selection information that is not available to all competitors. In the event of an OCI or PCI, Contractor must disclose to the Government. 72 www.ober.com Ethics/Compliance Strategy to Mitigate OCI/PCI Risks: Develop a comprehensive plan that includes detection, mitigation and removal of conflicts of interest. Screen employees and acquisition targets for OCI and PCI risks and avoid acquiring/hiring them, if possible. Assign a senior ranking individual as compliance officer for the firm Assess OCI and PCI risks periodically Prepare OCI and PCI disclosures when necessary. 73 www.ober.com Questions? www.ober.com