GAUTENG DEPARTMENT OF HUMAN SETTLEMENTS 17 MARCH 2015 CONTENT 1. Gauteng Department of Human Settlements Report 2. Reports for Metropolitan Municipalities a) Johannesburg metropolitan Municipality b) Tshwane Metropolitan Municipality c) Ekurhuleni Metropolitan Municipality INTRODUCTION • The National Department of Human Settlements presented Section 32 Reports to the Portfolio Committee on Human Settlements • The Department and its Metropolitan Municipalities were found to be underperforming • The Portfolio Committee invited the Department and its Metropolitan Municipalities to present the challenges relating to: – Delivery and expenditure on the Human Settlements Development Grant (HSDG) – Delivery and expenditure on the Urban Settlements Development Grant (USDG) – Performance on Social and Rental Housing – Performance Mining Towns – Delivery performance on rectification – Delivery performance on other milestones on the Operational Expenditure Budget in support of the implementation of National and Provincial Housing Programmes (OPSCAP) 1. DELIVERY AND EXPENDITURE ON THE HSDG Total Allocation 2014/15 R’000 HSDG 4 417 641 Total Expenditure as at 31 Dec 2014: Quarter 3 R’000 HSDG 4 417 641 EXPENDITURE 2 786 556 TOTAL BALANCE 1 631 085 Total Expenditure as at 12 Mar 2015 Jan 2015 R’000 Feb 2015 R’000 Mar R’000 HSDG 4 417 641 4 417 641 4 417 641 EXPENDITURE 2 961 406 3 399 732 3 785 316 TOTAL BALANCE 1 456 235 1 017 909 632 325 DELIVERY AND EXPENDITURE ON HSDG [Cont.] Annual Delivery Targets - Original Annual Delivery Targets - Revised Sites Units/ Houses Total Sites 10 407 24 261 34 668 7 728 Units/ Houses 17 678 Actual Performance as at 31 December 2014 Total Sites 25 406 2 293 Units/ Houses 10 340 Total 12 633 % % Sites Units/ Houses 30% 71% ACTUAL PERFORMANCE AS AT 12 MARCH 2015 Targets Achieved Sites 7 728 2 534 Units/Houses 17 678 12 477 Work in Progress Completed Units awaiting Quality Assurance 1195 Wall plate/ Roof level 964 Foundation 680 CHALLENGES EXPERIENCED IN HSDG DELIVERY • Budget revision and revision of targets by 9262 housing opportunities due to expenditure on items that were not on the Business Plan like rectification of hailstorm damaged houses and asbestos assessment by R1,1 billion • Regularization of expired and invalid contracts • For 2015/16 an allocation has been made for emergencies and disasters will be referred to COGTA • There will be no further assessment done for asbestos roofs PERFORMANCE ON SOCIAL AND RENTAL HOUSING Annual Delivery Targets - Original Annual Delivery Targets - Revised Actual Performance as at 31 Dec 2014 Actual Performance as at 12 March 2015 2 265 616 181 261 • GPF is the delivery agent for the Department for affordable rental and Social housing • GPF was not included in the original approved departmental budget and got allocated during the budget revision process • For the new financial year provision has been made for GPF and allocation will be in terms of the approved 5 year strategic plan PERFORMANCE ON MINING TOWNS PERFORMANCE ON MINING TOWNS PERFORMANCE ON MINING TOWNS PERFORMANCE ON MINING TOWNS PERFORMANCE ON OTHER MILESTONES: OPSCAP • OPSCAP used for shack fire disasters • Costs relating to rates and taxes • Security costs for completed houses and hostels not yet handed over • Rental costs for regional offices • Legal costs incurred to prevent illegal invasion, to obtain eviction orders • Lease costs for temporal residential units and portable ablution facilities. CONCLUSION • Our delivery model is underpinned by the connection between all elements of the human settlements: – Delivery of Gauteng Human Settlements Mega Projects – Refining the finance model to suit our new trajectory – Capacity of the Province to be improved - Industry specific qualifications – Strengthening the capacity of the PMO and Regions – Service Delivery Model will change to a teamwork approach – Integrated Planning (Intergovernmental Relations Strengthened) – Explore models to incentivise private sector investment in mega project – Unqualified Audit outcome CONCLUSION • Programmes to improve our delivery model will include • • • • • • • • • Infill sites Fully serviced sites Employer assisted housing Revised rental housing model Social Housing Accelerated CRU Improved Approach - Hybrid Private Sector Partnerships Urban Renewal Revitalisation of mining towns CONCLUSION END USDG PRESENTATION FOR EKURHULENI METROPOLITAN MUNICIPALITY 13.03.15 FINANCIAL PERFORMANCE: CAPITAL BUDGET BREAKDOWN • The Ekurhuleni Metropolitan Municipality’s USDG Budget for the 2014/15 financial is 1 985 130 282, which includes the R 31 566 282 roll-over amount for the Human Settlement USDG. • The total USDG expenditure as on the 06th of March 2015 is R 640 686 572 . • The expenditure represents 32.27% of the total budget for the 2014/15 • The total expenditure plus commitments was R 695 061 768 • The expenditure plus commitments represents 35.01% of the budget • The unspent funds as on the 09th of March 2015 is R 1 235 768 514. 17 FINANCIAL PERFORMANCE: PER SERVICE/DEPARTMENT Department Budget Actual Expenditure to Date 09/03/2015 Not Updated (Invoices Captured and not paid as yet) Expenditure Commitment s on Venus (Stores Orders, etc.) Disaster & Emergency Management Services 46,336,000 12,749,716 - - Economic Development 29,200,000 3,784,628 - EMPD 10,916,066 5,428,545 - Energy 272,750,000 68,383,210 Environmental Resources Management 1,500,000 125,710 - 371,228 Health & Social Development 56,750,000 27,768,914 - Human Settlements 322,942,435 92,979,416 Real Estate 29,546,314 8,036,175 Roads and Stormwater 285,450,000 SRAC Transport Total Actual Expenditure + Commitments on Venus (Stores Orders, etc.) Total % Actual spent vs Budget Total % spent (with commitment) Unspent Funds 09/03/2015 12,749,716 27.52% 27.52% 33,586,284 288,596 4,073,225 12.96% 13.95% 25,126,775 - 5,428,545 81,078,804 25.07% 29.73% 191,671,196 496,938 8.38% 33.13% 1,003,062 1,553,469 29,322,382 48.93% 51.67% 27,427,618 14,182,271 107,328,096 28.79% 33.23% 215,614,339 - 3,257,586 11,293,761 27.20% 38.22% 18,252,553 61,716,610 - - 61,716,610 21.62% 21.62% 223,733,390 32,476,084 9,039,565 - 179,498 9,219,063 27.83% 28.39% 23,257,021 257,901,244 77,946,081 - - 77,946,081 30.22% 30.22% 179,955,163 732,100 166,410 11,963,494 5,487,521 18 Department Budget Actual Expenditure to Date 09/03/2015 Not Updated (Invoices Captured and not paid as yet) Expenditure Commitments on Venus (Stores Orders, etc.) Waste Management 4,600,000 136,500 Water & Sanitation 314,344,991 130,414,547 Erwat - Wastewater treatment (1326202566030) 50,000,000 50,000,000 Chemical Toilets (1326202566031) 184,550,866 80,938,555 Human Settlement USDG (1450202566037) 31,566,282 11,238,401 - - Human Settlement USDG (1450302566037) 54,300,000 - - - Total 1,985,130,282 - 640,686,572 341,568 20,382 288,808 - - 17,453,495 3,576,293 4,816,370 49,558,827 Total Actual Expenditure + Commitments on Venus (Stores Orders, etc.) Total % Actual spent vs Budget Total % spent (with commitment) Unspent Funds 09/03/2015 156,882 2.97% 3.41% 131,044,923 41.49% 41.69% 50,000,000 100.00% 100.00% 101,968,342 43.86% 55.25% 82,582,524.12 11,238,401 35.60% 35.60% 20,327,881.36 0.00% 0.00% 54,300,000.00 32.27% 35.01% 1,235,768,514 - 695,061,768 4,443,118 183,300,068 - CHALLENGES & REMEDIAL MEASURES The Municipality has experience challenges that resulted in poor expenditure including amongst others as follows: • Review of the City’s procurement processes and introduction of new committees which slowed down the finalization of bids • Loss of technical capacity, which includes engineers and project managers • The Institutional Review is in the process of being approved by Council, and this will result in the augmentation of the organisational structure with appropriate levels of technical skills Remedial Measures • The EPMO set up for the Metro is complete with all top management positions filled. The set up of departmental PMO’s has commenced with more than 8 departmental PMO’s already operational. • EMM is working on implementing a project management system that will assist in planning and monitoring of projects • EMM has sourced external service provider to carry out an Implementing Agent Role for the substantial part of the Infrastructure Building Programme. 20 Non Financial Performance for Human Settlements - USDG funded projects Project name Acquisition of Land for New Human Settlements Ptn 32 Modderfontein 76 IR, Alliance EXT 2 Acquisition of Portion 402 of the Farm Driefontein 85 IR, ERPM VILLAGE Non financial progress The following specialist studies have been completed: Phase1 Geotechnical report, Traffic Impact Assessment based on 2500 dwelling units, EIA was submitted with GDARD: record of decision is available, Feasibility report for intermodal transport facility. The Private Property Acquisition Form was signed by the Human Settlements HOD on the 24 June 2014 and submitted to Real Estate Department. On the 05 August 2014, Transnet confirmed Board approval for the acquisition. The valuation of the property was 16,200,000 completed on the 29 September 2014. The Deed of Sale has been commented upon by EMM Corporate Legal Services on the 5 of December 2014 and is ready to be signed. The Council Item has been prepared for Council approval. The budget was adjusted from R7 million to R16,2 million. A guarantee has been issued in this respect and the spending is in the suspense account a journal entry is being prepared against this 32,000,000 vote to close the matter Matter finalized. Property registered in favour of EMM 77,030,000 Project Name Budget Non financial progress report Servicing of stands in Balmoral and alliance settlements 35,000,000 The two projects will be used as pilot projects of the Department in provision of the essential services in the creation of human settlements. The package will include provision of roads and storm water infrastructure, electrification, and water and sanitation networks for Balmoral and alliance settlements. The DBSA technical capacity will be utilized for the designs in the current financial year and implementation in 2015/16. The development project plans and issue of IPWs is currently being undertaken Delville and fire station Social Housing Project installation of services and construction of buildings Awaiting SLA’s to be signed with DBSA so that can proceed with 54,000,000 design and construction project management. Human Settlements, Pre Planning Fees Milestones were not met due the capping of the contract value that has been allocated to the three Professional Service Providers. For pre-planning payments are made when certain milestones have been achieved and most the milestone will be achieved in the fourth 44,826,345 quarter of the financial year. To expedite the approval processes HS dept. had number of meetings with City Planning and other relevant departments Project name Budget Non financial progress report 99% complete, ahead of target Refurbishment of Rental Property Wattville-Actonville Urban Renewal Project Katorus Urban Renewal Project Leeupoort Development (Bulk Infrastructure) 37,212,435 Milestones were not met due the capping of the contract value that has been allocated to the three Professional Service Providers. Awaiting SLA’s to be signed with DBSA so that the 2,824,000 dept. can proceed with detailed planning and design Milestones were not met due the capping of the contract value that has been allocated to the three Professional Service Providers. Awaiting SLA’s to be signed with DBSA so that the 2,500,000 dept. can proceed with detailed planning and design Commencement of the project delayed. Public participation process and signing of service level agreements with services departments are underway to enable the city to meet the section 80,000,000 33 requirements and commence with installation of bulk LINK BETWEEN USDG & HSDG Grants alignment – 2011 to 2015 Project Name Sites Units Palm Ridge 6146 1299 Alra Park 290 600 Eden Park West and Ext 1 860 782 Etwatwa 34 1461 1423 Etwatwa 37 1395 2100 Mayfield 1 353 600 Kwa Thema 3 856 1247 Vlakfontein Ptn 36 1620 600 Payneville 1 115 600 Moleleki 1 & 2 75 280 24 EMM HSDG PROGRAMME OVERVIEW Name of Project Total No. Units Units Per Delivered of Project Project Balance 2013/14 Units Budgeted No. Budgeted as per GP GP DHS DHS Units APP APP 2014/15 as % of Balance of Project 2014/15 Magagula Heights 313 12 301 0 0% Moleleki Ext 1 & 2 746 0 746 0 0% Alra Park Ext 3 674 100 574 100 17% Etwatwa Ext 35 334 0 334 75 22% Eden Park West & Ext 1 693 0 693 130 19% 2 760 112 2 648 305 12% TOTAL The table above, illustrates that only a budget of 12% of active projects were considered by the GP DoHS. The funds (approximately 305 x R102, 000 per unit = R31.1 million) are yet to be made available to the EMM, despite the first quarter of the current financial year gone. 2 455 unfunded units that can be delivered – only 305 are funded 25 EMM HSDG PROGRAMME OVERVIEW The listed projects are being serviced by the EMM Water & Sanitation Department and can be made available for construction, subject to funding availability: Project Number of Stands Payneville Ext 1 1 115 Etwatwa Ext 18 762 Etwatwa Ext 19 320 Langaville Ext 10 Masechaba View Ext 4 Cool breeze TOTAL 1 561 252 50 4 060 Should funding be made available, the EMM would be able to expand its performance beyond the five (5) projects that are currently active. 26 END USDG Progress Report for Quarter 2 CITY OF TSHWANE FINANCIAL PERFORMANCE Budget Allocation Allocation : R 1 469 450 000.00 Expenditure as at 31/12/2014 : R 528 021 782.00 35.9 % overall spent as at 31 December 2014 USDG 2014/15 Strategic Departments Approved Budget 2014/15 Roll over from 2013/14 Housing and Human Settlement Electricity 837 804 764 23 853 359 Water and Sanitation 248 046 236 Transport 123 599 000 260 000 000 Cemeteries in Tshwane North Region Total USDG 2014/15 1 469 450 000 Total per department % of allocatio n 861 658 123 56.90% 260 000 000 17.17% 252 627 024 16.68% 123 599 000 8.16% 16 395 610 16 395 610 1.08% 44 829 757 1 514 279 757 4 580 788 30 USDG 2014/15 31 FINANCIAL PERFORMANCE: HOUSING AND HUMAN SETTLEMENTS Project Name Project Budget 2014/15 Expenditure % of expenditure 0% Roads & Storm water - Low Cost Housing 120 759 904.51 - Sewerage - Low Cost Housing 318 649 957.33 70 728 064.81 Project Linked Housing - Water Provision 289 047 863.25 40 215 619.39 Acquisition of land 109 847 039.00 29 952 000.00 28% TOTAL HOUSING 837 804 764.00 140 895 684.20 17% 22% 14% 32 FINANCIAL PERFORMANCE: WATER AND SANITATION Project Name Budget 2014/15 Replacement, Upgrade and Construct Waste Water Treatment Works Facilities 44 000 000.00 Refurbishment of Water Networks and Backlog Eradication 177 546 236.00 expenditure 40 425 322.80 91 186 548.27 % of expenditure 92% 51% 0% Bulk Sewer Supply- Franspoort 1 500 000.00 - Total USDG Service Infrastructure 223 046 236.00 131 611 871.07 59% 33 FINANCIAL PERFORMANCE: ELECTRICITY Project Name Project number Budget 2014/15 Electricity for All 710178 260 000 000.00 Tshwane Public Lighting Program 710556 25 000 000.00 Total USDG Electricity 285 000 000.00 expenditure 159 886 887.65 % of expenditure 61% 5 003 031.56 20% 164 889 919.21 58% 34 FINANCIAL PERFORMANCE: TRANSPORT Project Name Budget 2014/15 expenditure % of expenditure 97 599 000.00 65 272 303.58 67% Flooding Backlogs: Sosh & Winterveldt Area 26 000 000.00 25 352 003.82 98% Total USDG Transport 123 599 000.00 90 624 307.40 73% Internal Roads: Northern Areas 35 FINANCIAL PERFORMANCE: 28 February 2015 Allocation R1,469,450,000.00 Expenditure to date R630,973,302.00 Which is 43% of 14/15 USDG allocation as at 28.02.2015 36 FINANCIAL PERFORMANCE: PER DEPARTMENT AS AT 28 FEBRUARY 2015 Department Approved Budget 2014/15 Projected expenditure at Q2 Expenditure at 28 Feb 2015 % of expenditure Housing and Human Settlements 837 804 764 292 645 447 220 972 206 27% Electricity 285 000 000 142 499 994 205 972 206 72% Water and Sanitation 223 046 236 127 923 114 151 899 664 68% Transport 123 599 000 123 599 000 120 403 759 97% 1 469 450 000 686 667 555 630 973 302 43% Total USDG 37 CHALLENGES • Issues with Land Claims and re-opening of land claims process • Delays with finalization of LAAs • Land invasion • Disruptions on site by local labourers & Political interference • Huge boulders underground requiring blasting 38 MITIGATION PLAN • Regular Meetings with Land Claims Commissioner, Province and land claimants • Final LAA’s submitted to the City in February 2015 • Eviction of people illegally occupying land • Political Intervention • Increase resources on site 39 END 40 CITY OF JOHANNESBURG 13 March 2015 2014/15 QUARTER 2 FINANCIAL PERFORMANCE & FORECAST TO JUNE’15 Department / Budget YTD Commit- Total % Quarter Quarter Total % of Entity 2014/15 Exp ments Exp Spent 3 4 Cost Budget R'000 R'000 R'000 Community Development 23 300 1 523 Health 60 000 422 792 862 92 961 90 000 25 403 222 411 71 822 14 000 437 349 027 57 366 4 558 54 000 15 129 24 254 69 589 18 706 20 000 2 699 Total USDG: 1 695 189 286 469 Housing City Power Johannesburg Water Pikitup Jhb Roads Agency Jhb City Parks and Zoo Jhb Development Agency JOSHCO 20 168 - R'000 21 691 R'000 93% 1 609 R'000 R'000 - 23 300 100% 422 1% 24 700 34 878 60 000 100% 9 680 102 641 13% 251 670 438 551 792 862 100% 5 760 31 163 35% 33 534 25 303 90 000 100% - 71 822 32% 75 072 75 517 222 411 100% - 437 3 563 10 000 14 000 100% 61 924 18% 143 115 143 988 349 027 100% 39 383 73% 14 617 54 000 100% - 18 706 27% 20 860 30 023 69 589 100% - 2 699 13% 4 000 13 301 20 000 100% 21% 572 740 771 561 1 695 189 42 100% 64 420 350 888 3% - FINANCIAL PERFORMANCE PER SERVICE DELIVERY AREA Service Delivery Area Budget R'000 Land Acquisition Actual Total Percentage Commitments Expenditure Expenditure Spent R'000 R'000 R'000 40 000 – 9 680 9 680 24% 835 362 114 366 – 114 366 14% 349 727 57 366 4 558 61 924 18% 89 367 901 – 901 1% Sanitation 133 044 70 921 – 70 921 53% Electricity 90 000 25 403 5 760 31 163 35% Waste Management 14 229 437 – 437 3% 143 460 17 074 44 422 61 496 43% 1 695 189 286 469 64 420 350 888 21% Housing Internal Services Roads and Stormwater Water Social Amenities TOTAL: 43 DETAILED PROJECT PROGESS Project Name Areas & No of Households benefitting Annual Target outputs Non-Financial Actual Progress Budget Expenditure R’000 R’000 40 000 9 680 LAND ACQUISITION Land Purchases N/A Purchase Univille land and Rabie Ridge Land To date CoJ has settled with 23 farmers( Lufhereng ), with 13 settlements still in dispute/ unresolved. CoJ Housing and Group Legal aim to finalise all matters by 01 April 2015. CoJ is in process of negotiations with the owner of Unaville land and Rabie Ridge land. offer to purchase (done ) 44 DETAILED PROJECT PROGESS Project Name Areas & Budget ExpendiAnnual Target Non-Financial Actual No of ture outputs Households Progress R’000 benefitting R’000 HOUSING: INTERNAL SERVICES Devland Ext 1,27,30,31&33 Region D Diepsloot Redevelopment Renewal RDP Flats DIEPSLOOT WES Region A Construction of roads and stormwater in Ext 1/30/31 is at 100% completion because the works was carried over from Construction of 7,2km of 2013/14 fin year, Construction of JAN de surfaced roads and 0.84km Nicker is at 90% completion also carried stormwate drainage system, over from 2013/14 fin year, Internal installation of water and sewer water, sewer and reservoir for Lindelani to 252 stands and construction commenced in Nov 2014. The budget for of 15ml bulk reservoir this project will be increased by R38.3 m in the adjustment budget, to accelerate this project. Water, Sewer, roads and stormwater for Complete Roads & stormwater Ph1 is 98% complete. The sewer pump , Link Water and sewer station upgrade is at construction phase including the internal services and will be completed in March 2015. for phase 1. 130 000 10 647 50 000 23 191 45 HOUSING: INTERNAL SERVICES (CONT.) Elias Motsoaledi Region D Construction of Bulk and Internal Roads Including Curlver Bridge New Bulk Fleurhof Mixed Development (Bulk and internal infrastructure) Region C New Bulk Infrastructure FLEURHOF Electricity Sub-Station including 4 Km of road Klipspruit/Kliptown Ext 11 Bulk Services New Region D Bulk Infrastructure KLIPSPRUIT EXT.11 Construction of Bulk and Internal Roads The site camp has been established. The first batch of material was delivered in November. The contractor has started clearing on site. The tender for construction of a bridge was advertised in December. The budget will be fully spent by June 2015. Construction of Electricity Sub-Station is continuing from 2013/14 fin year, progress at 50%. Electrification of additional 1000 Houses is underway. Construction of remainder of Fleurhof Drive, to Meadowlands, as well as bulk and internal services, bulk sewer outfall and stormwater canal to Ext. 18 - 21 all commenced in August 2014 and are due for completion March - June 2015. The budget for this project will be increased by R76 m in the adjustment budget to accelerate this project. Construction of bulk stormwater and access road commenced in September 2014 and construction is at an advanced stage. The tender document for construction of roads and stormwater at Klipspruit Ext 11 and Klipspruit Ext7 are ready for advertisement. Construction is planned to commence beginning of the 3rd quarter. The total budget for the project will be adjusted by R20 m due to delayed start. 20 000 287 6 500( USDG) 83 500 (COJ) 8 688 50 000 4 193 HOUSING: INTERNAL SERVICES (CONT.) Lehae Ext 1 Bulk Water Line New Bulk RegionG Infrastructure LEHAE EXT.1 This project is at construction phase 88/11KV Substation and and is well on track to fully spend electrification of 1518 houses the budget by June 2015. 114 027 18 755 Lufhereng Mixed Development (Bulk Infrastructure Roads, Stormwater Management Systems, Region D Sewer & Water for 24 000 houses) New Bulk Infrastructure DOORNKOP EXT.1 C Regional CoJ appointed a Turnkey Developer for installation of water, sewer, roads and stormwater services for Lufhereng Ext 5. Overall progress for Construction of various bulk, this project is 28%. The construction link and internal services of electrical sub-station will start in February 2015. This project requires an additional R45 m, which cannot be granted due to financial constraints. 156 000 15 108 HOUSING: INTERNAL SERVICES (CONT.) Nancefield Station Precinct Development New Precinct Klipspruit Redevelopment KLIPSPRUIT 100% Completion roads & stormwater Construction of Phase 2 is progressing well and is 60% complete. The designs for Phase 3 were approved in October 2014, currently planning for the project is underway. The project is on schedule to fully spend the budget by June 2015. 60 000 10 671 DETAILED PROJECT PROGESS Project Name Areas & No of Households benefitting Annual Target outputs Non-Financial Actual Progress Budget Expendi -ture R’000 R’000 WATER Basic Water Service New Basic Lawley Ext 2, Lawley Water and Sewer Services station, Tshepisong West, N/A ORANGE FARM EXT.8 G Regional Randleases, Ennerdale: Lenasia high level Reservoir New Reserviors LENASIA EXT.1 Lenasia Ext 1 Ennerdale: Orange Farm high level reservior New Reserviors ORANGE FARM Orange Farm Roodepoort/Diepsloot: Diepsloot Reservoir New Reserviors Diepsloot DIEPSLOOT WES Project in construction phase and is on track with the construction programme. Project in design phase. The budget will be adjusted by Increase water capacity R3.5 m in the adjustment to accommodate the revised programme. Project in design phase. The budget will be reduced by Increase water capacity R11.5 m to accommodate the revised programme. The budget for this project will be adjusted by R16.9 m in the Land acquisition adjustment budget to accommodate only the planning for this project. 30 000 – 10 000 – 20 000 854 25 411 – 49 DETAILED PROJECT PROGESS Project Name Areas & No of Households benefitting Budget ExpendiAnnual Target Non-Financial ture outputs Actual Progress R’000 R’000 SANITATION Bushkoppies Works: Replacement of Aerotion System Renewal Bulk Waste Water DEVLAND Soweto Driefontein Works: Extension New Bulk Waste Water Roodepoort COSMO CITY EXT.2 C Regional Project in construction phase and is on track with the construction programme, Increase treatment capacity progress at 55%. This project will be increased by R7.2 m in the adjustment budget. Project in construction phase and is on track with the Build reators, balancing tank construction programme, and head of works progress at 87%. This project will be increased by R14.8 m in the adjustment budget. 24 091 16 26 000 23 370 50 SANITATION (CONT.) Northern Works: desludge Dam 01 and 02 Renewal Bulk Waste Water Diepsloot DIEPSLOOT WES EXT.5 A Regional Project in construction phase and is on track with the To reduce the rate of future construction programme, sludge ingress progress at 6%. This project will be increased by R10.8 m in the adjustment budget. 20 000 958 DETAILED PROJECT PROGESS Project Name Areas & No of Households benefitting Annual Target Non-Financial outputs Actual Progress Budget Expenditure ROADS & STORMWATER BRID 05 - Naledi/Protea Bridge (Between Wards 20 Areas surrounding 100% and 14). New Bridges the Naledi Train (60% of bridge) (Pedestrian and Vehicles) Station NALEDI Total expenditure to date is R 15 698 948.81 against a budget of R20 million (79.8%). Additional funds have been requested in the adjusted budget. Expected expenditure R38million by the end of June 2015. 20 000 16 181 52 DETAILED PROJECT PROGESS ROADS & STORMWATER (CONT.) MISCL - Emergency, Critical and Urgent Depot Stormwater Improvements. Various New Stormwater Management Projects JOHANNESBURCity Wide Projects are at various stages: ten projects at consultant procurement % of Project completed stage as per project plan sixteen at contractor procurement stage, three projects at construction stage. 40 000 8 220 MISCL - Gravel Roads: Bram Fischerville. New Roads: Bram Construction and Upgrades Fischerville BRAM FISCHERVILLE New contractor has been appointed and the old contractor is proceeding % of Project completed with work. as per project plan Consultant's tender for phase 2 has been advertised and will be fast tracked. 35 000 5 346 53 DETAILED PROJECT PROGESS ROADS & STORMWATER (CONT.) MISCL - Gravel Roads: Diepsloot. New Roads: Diepsloot Construction and Upgrades DIEPSLOOT WEST EXT.3 MISCL - Gravel Roads: Doornkop/Thulani. New Roads: Construction and Upgrades DOORNKOP Doornkop / Thulani % of Project completed as per project plan % of Project completed as per project plan The new contractor has been appoint ans site establishment is complete, the old contractor is proceeding with work. Consultant's tender for phase 2 tenders closed on 18 December 2014. Appointment of contractor is at evaluation stage and process will be fast tracked. Consultant's tender Bid specification was approved and the tender will be readvertised in January 2015. It is anticipated that the expenditure to end of June 2015 will be R9.5 million. The budget has been adjusted accordingly. 46 060 5 794 16 100 4 458 54 DETAILED PROJECT PROGESS ROADS & STORMWATER (CONT.) MISCL - Tarring of Gravel Roads: % of Project Orange Farm and Surrounding Orange Farm completed as per Areas. project plan The contractor has been appointed and site establishment is complete, the old contractor is executing work Consultant's tender for phase 2 is at adjudication and evaluation stage. It is anticipated that with two contractors on site simultaneously the expenditure by the end of June 2015 will be R39.34 millon. The budget has been adjusted accordingly. 47 340 4 916 55 DETAILED PROJECT PROGESS ROADS & STORMWATER (CONT.) MISCL - Gravel Roads: Tshepisong. New Roads: Tshepisong Construction and Upgrades TSHEPISONG RNP003_Westlake Road Extension New Roads: Various Construction and Upgrades RAND LEASES EXT.1 The new contractor has been appointed and site establishment is arranged for January 2015, the old contractor is proceeding with work. % of Project Consultant's tender for phase 2 - Bid spec completed as per document has been approved. It is project plan anticipated that with two contractors on site simultaneously that the expenditure by the end of June 2015 will be R28 million. The budget will be adjusted acordingly. City of Johannesburg (Housing) is implementiing the project on behalf of JRA. This project is jointly funded by USDG ans % of Project CoJ. CoJ funding will only be utilised this completed as per financial year. The expencted expenditure project plan is R0.00 and the budget has been adjusted accordingly. 20 000 8 840 10 000 – 56 DETAILED PROJECT PROGESS Areas & Budget ExpendiAnnual Target Non-Financial No of ture Project Name outputs Households Actual Progress R’000 benefitting R’000 ELECTRICITY Construction material has been ordered. Project is under Lufhereng Substation. Substation Yard,Switching construction and is a Establish new 88/11 kV sub Station, Power Lufhereng Development continuation from last financial station. New Bulk Transformer, auxilary year. This project is on track to Infrastructure LUFHERENG equipments fully utilise the budget by June 2015. 60 000 12 968 57 DETAILED PROJECT PROGESS Project Name Areas & No of Households benefitting Annual Target outputs Non-Financial Actual Progress Budget Expenditure R’000 R’000 WASTE MANAGEMENT 5 Composting Organic Waste New Plant and Citywide Equipment ORANGE FARM EXT.8 City Wide The whole budget will be reallocated in the adjustment budget because composting plants are no Complete 5 composting plants longer a strategic goal for Pikitup. The funds will be re-directed to Garden Sites, Kya Sands Landfill Site and Upgrading of Facilities. 13 500 – 58 CHALLENGES & REMEDIAL MEASURES KEY CHALLENGES REMEDIAL MEASURES Procurement delays. Use of budget adjustment period to reallocate funds to over-performing projects. Lengthy land acquisition processes. Improvements sought from Dept. / Entities in respect of capital planning. Capital planning. Concerted effort by Dept. / Entities to plan projects over the medium term to eliminate the hockey stick spending pattern. 59 DETAILED PROJECT PROGESS Actual Progress No of Annual Name of 1 April Service Househol Expendit Target Informal Budget 2014 to 31 provided ds to ure 2014/15 Settlement December benefit 2014 INFORMAL SETTLEMENT UPGRADING 60 DETAILED PROJECT PROGESS Project Name Number of title deeds Annual Target issued 2014/15 1 June 2014 to 31 December 2014 Budget Expenditure - - TITLE DEEDS ISSUED 3750 791 ( Houses delivered 1800) 61 LINK BETWEEN USDG & HSDG USDG – Housing Internal Services: Project Name Lehae 2014/2015 R 000 HSDG – Top Structure: Project Name 2014/2015 114 027 Lehae 40 300 Fleurhof 90 000 Fleurhof 70 000 Lufhereng 156 000 Lufhereng 23 000 Diepsloot Riverside Development 50 000 Diepsloot Riverside Development 18 000 Elias Motsoaledi 20 000 Elias Motsoaledi Greater Kliptown 50 000 Greater Kliptown 56 000 South Hill 56 335 South Hill 22 000 Devland Ext 130 000 Devland Ext 50 300 46 000 62 Sustainability • The 2014/15 Repairs and Maintenance provision represents more than 9% of the total expenditure. • The following Table is a Consolidation of all Expenditure Associated with Repairs & Maintenance. 63 Sustainability 64 Thank You