STANDARD CONDITIONS FOR GOULBURN VALLEY WATER CONSTRUCTION CONTRACTS CLIENT HANDBOOK FOR CONSULTANTS November 2011 GOULBURN VALLEY REGION WATER CORPORATION Standard Conditions for Goulburn Valley Water Construction Contracts Client Handbook for Consultants Client Handbook Revisions Note: with each edit to this document, the following must be completed in the next available blank row. Date Aug 2010 Sept 2010 Description of Change Item 2 Annexure B – Clause 8.8 Precedence added to AS2124 and AS4300 Item 10 OH&S – Model OHS Specification and Tender Document Requirements revised Initiator of Change Date Updated JX Aug 2010 JX Sept 2010 Oct 2010 Item 12 Consultant Monthly Reports deleted JX Oct 2010 Nov 2011 Authorised delegate text amended SM Nov 2011 GOULBURN VALLEY REGION WATER CORPORATION Standard Conditions for Goulburn Valley Water Construction Contracts Client Handbook for Consultants CONTENTS - ITEM 1 ANNEXURE A – GENERAL CONDITIONS OF CONTRACT 1 - ITEM 2 ANNEXURE B – GENERAL CONDITIONS OF CONTRACT 11 - ITEM 3 ASSET REGISTER 25 - ITEM 4 RECIPIENT CREATED TAX INVOICE AGREEMENT (RCTI) FORM 29 - ITEM 5 INSTRUMENT OF AGREEMENT 31 - ITEM 6 OPERATIONS & MAINTENANCE MANUALS 34 - ITEM 7 PRACTICAL COMPLETION OF WORKS 35 - ITEM 8 PROVISIONAL AMOUNT FOR CONTINGENCIES 37 - ITEM 9 TENDERING 38 - ITEM 10 OCCUPATIONAL HEALTH & SAFETY 67 - ITEM 11 INSURANCE REQUIREMENTS 103 - ITEM 13 VICTORIAN INDUSTRY PARTICIPATION POLICY 105 - ITEM 14 CLERK OF WORKS 117 - ITEM 15 INDUSTRIAL RELATIONS 123 - ITEM 16 ENVIRONMENTAL POLICY 124 - ITEM 17 SUSTAINABILITY POLICY 127 - ITEM 18 EXPERT DETERMINATION 129 2 GOULBURN VALLEY REGION WATER CORPORATION Standard Conditions for Goulburn Valley Water Construction Contracts Client Handbook for Consultants ITEM 1 ANNEXURE A – GENERAL CONDITIONS OF CONTRACT The attached Annexures Part A are to be inserted in all Contracts where AS2124 – 1992 and AS 4300-1995 are used. These are default requirements with the Consultant to advise of any amendments proposed. 1 GOULBURN VALLEY REGION WATER CORPORATION Standard Conditions for Goulburn Valley Water Construction Contracts Client Handbook for Consultants PART A ANNEXURE to the Australian Standard General Conditions of Contract, AS2124 - 1992 This Annexure shall be issued as part of the Tender Documents and is to be attached to the General Conditions of Contract and shall be read as part of the Contract. The law applicable is that of the state or Territory of: (Clause 1) Victoria Payments under the contract shall be made at: (Clause 1) Shepparton, Victoria The Principal: (Clause 2) Goulburn Valley Region Water Corporation The address of the Principal 104 - 110 Fryers Street SHEPPARTON 3630 (PO Box 185 Shepparton 3632) Phone: 5832 0400 Fax: 5831 1467 The Superintendent: (Clause 2) Name of the Individual The address of the Superintendent: Limits of accuracy applying to quantities for which the Principal accepted a rate or rates: (Clause 3.3 b) Contractor solely responsible for determining quantities of all items (Lump sum contract only). Bill of Quantities – the alternative applying: (Clause 4.1) Alternative 1 (Lump sum contract only). The time for lodgement of the priced copy of the Bill of Quantities: (Clause 4.2) A priced bill of quantities must be lodged with the tender (where applicable). # Contractor shall provide security in the amount of: (Clause 5.2) # Principal shall provide security in the amount of: (Clause 5.2) 5% of the contract sum payable to the principal # The period of notice required of a party’s intention to have recourse to retention moneys and/or convert security (Clause 5.5) 14 Days Nil 2 GOULBURN VALLEY REGION WATER CORPORATION Standard Conditions for Goulburn Valley Water Construction Contracts Client Handbook for Consultants The percentage to which the entitlement to security and retention moneys is reduced: (Clause 5.7) Security 50%; Retention 50 % Interest on retention moneys and security-the alternative applying: (Clause 5.9) Alternative 2 The number of copies to be supplied by the Principal: (Clause 8.3) 2 copies of the Drawings and specifications. The number of copies to be supplied by the Contractor: (Clause 8.4) 3 copies of the Drawings and specifications. The time within which the Superintendent must give a decision and return the Contractor’s copies: ] (Clause 8.4) 14 Days Work which cannot be subcontracted without approval: (Clause 9.2) Any work to be subcontracted requires Superintendent approval. The percentage for profit and attendance: (Clause 11 b) 10% The amount or percentage for profit and attendance: (Clause 11 c) 10% Insurance of Works- the alternative applying: (Clause 18) Alternative 2 The assessment for insurance purposes of the costs of demolition and removal of debris: (Clause 18 ii) Not applicable The assessment for insurance purposes of the consultants’ fees: (Clause 18 iii) The value of the materials to be supplied by the Principal: (Clause 18 iv) Not applicable The additional amount or percentage: (Clause 18 v) Nil Nil 3 GOULBURN VALLEY REGION WATER CORPORATION Standard Conditions for Goulburn Valley Water Construction Contracts Client Handbook for Consultants Public Liability Insurance- the alternative applying: (Clause 19) Alternative 2 The amount of Public Liability Insurance shall be not less than: (Clause 19) $10,000,000 per single occurrence. The time for giving possession of the site; (Clause 27.1) 14 days # The time for Practical Completion (Clause 35.2) To be completed (Calendar Weeks) # Liquidated Damages per day (Clause 35.6) To be completed # Limit of Liquidated Damages (Clause 35.7) Clause deleted # Bonus per Completion: (Clause 35.8) day for early Practical Clause deleted # Limit of Bonus: (Clause 35.8) Clause deleted # Compensation for Delay Costs: (Clause 36) Nil # The Defects Liability Period: (Clause 37) 12 months The charge for overheads, profit etc. for Day work: (Clause 41 f) 10% Times for payment claims: (Clause 42.1) Middle of each month Unfixed Plant and Materials for which payment claims may be made notwithstanding that they are not incorporated in the Works: (Clause 42.1 ii) Nil 4 GOULBURN VALLEY REGION WATER CORPORATION Standard Conditions for Goulburn Valley Water Construction Contracts Client Handbook for Consultants Retention Moneys on: (Clause 42.3) (a) Work incorporated into the Works and any work or items for which a different amount of retention is not provided, 10% of the value until 5% of the Contract Sum is held; (b) (c) Items on Site but not yet incorporated into the Works 100% Items off site but in Australia 100%; (d) Items not in Australia 100%; and (e) Disbursements incurred by the Contractor for customs duties, freight, marine insurance, primage, landing and transport in respect of the work under the contract. 100%. Unfixed Plant or Materials- the alternative applying: (Clause 42.4) Alternative 2 The rate of interest on overdue payments: (Clause 42.9) Commonwealth Bank, Australia, commercial overdraft rate prevailing at time of payment. The delay in giving possession of the Site which shall be a substantial breach: (Clause 44.7) 21 days The alternative required in proceeding with dispute resolution: (Clause 47.2) Clause deleted The person to nominate an arbitrator: (Clause 47.3) Not applicable Location of Arbitration (Clause 47.3) Not applicable 5 GOULBURN VALLEY REGION WATER CORPORATION Standard Conditions for Goulburn Valley Water Construction Contracts Client Handbook for Consultants PART A ANNEXURE to the Australian Standard General Conditions of Contract for Design and Construct, AS4300 - 1995 This Annexure shall be completed and issued as part of the tender documents and subject to any amendments to be incorporated into the Contract, is to be attached to these General Conditions of Contract and shall be read as part of the Contract. 1 The law applicable is that of the State or Territory of: (Clause 1) Victoria 2. Payments under the Contract shall be made at: (Clause 1) Shepparton, Victoria 3 The Principal: (Clause 2) Goulburn Valley Corporation 4 The address of the Principal: 104 – 110 Fryers Street Shepparton, Vic, 3630 Region Water (PO Box 185 Shepparton 3632) Phone: 5832 0400 Fax: 5831 1467 5 The Contractor: (Clause 2) 6 The address of the Contractor: 7 The Superintendent: (Clause 2) 8 The address of the Superintendent: 9 #The Date for Practical Completion: (Clause 2) OR # The period of time for Practical Completion: (Clause 2) 10 Name of the Individual Preliminary Design: (Clause 2) To be completed – Calendar Weeks (A) A Preliminary Design is/is not included in the Principal’s Project Requirements 6 GOULBURN VALLEY REGION WATER CORPORATION Standard Conditions for Goulburn Valley Water Construction Contracts Client Handbook for Consultants 11 The Principal’s Project Requirements are described in the following documents (additional to those listed in the Annexure item for Preliminary Design): (Clause 2) Documents describing the Principal’s Project Requirements are: Specification No. Drawings listed in Specification Contractor’s documentation for accepted design as listed in the Letter of Acceptance. 12 Limits of accuracy applying to quantities for which the Principal accepted rates: (Clause 3.3 b) Upper limit Lower limit 13 #Contractor shall provide security in the amount of: (Clause 5.2) 5% of Contract Sum made payable to the Principal 14 # Principal shall provide security in the amount of: (Clause 5.2) Nil 15 Retention moneys shall be deducted progressively as follows: (Clauses 5.5 and 42.1) 10 per cent of the value of the work incorporated into the Works until 5 per cent of the Contract Sum is reached 16 The period of notice required of a party’s intention to Not applicable – Clause convert security into cash or to have recourse to replaced in Annexure Part B security or retention moneys: (Clause 5.6) 17 The percentage to which the Principal’s entitlement to security and retention moneys is reduced: (Clause 5.8) Security 50%, Retention 50% 18 The percentage to which the Contractor’s entitlement to security is reduced: (Clause 5.8) Not applicable 19 Holding of and interest on cash security and retention moneys – The alternative applying: (Clause 5.10) Alternative 2 20 The number of copies of documents to be supplied by the principal: (Clause 8.3) Two copies of drawings and specifications. 7 Not applicable Not applicable GOULBURN VALLEY REGION WATER CORPORATION Standard Conditions for Goulburn Valley Water Construction Contracts Client Handbook for Consultants 21 Documents, number of copies, and the times or design stages at which they are to be supplied to the Contractor: (Clause 8.4) Documents No. of Copies Time/design Stage As per Specification No. 22 The time within which the Superintendent must give a decision as to the suitability of documents: (Clause 8.4) 14 days 23 Work which cannot be subcontracted without approval: (Clause 9.2) WORK BY WORK BY CONSULTANTS CONTRACTORS All work All work 24 Subcontractors or Selected Subcontractors whose contracts the Principal may direct be novated: (Clause 10) Not applicable 25 The percentage for profit and attendance (Clause 11 b) Ten percent 26 Intellectual property rights granted to the Principal – the Alternative applying: (Clause 13.2) Alternative 1 27 Legislative requirements not required to be satisfied by contractor: (Clause 14.1) None 28 Insurance of the work under the Contract – the alternative applying: (Clause 18) Alternative 2 If Alternative 1 applies (a) The amount for demolition and removal of debris (Clause 18 ii) Not applicable (b) The amount for consultant’s fees: (Clause 18 iii) Not applicable (c) The value of materials or things to be supplied by the Principal: (Clause 18 iv) Nil (d) The additional amount of percentage: (Clause 18 v) Nil 8 GOULBURN VALLEY REGION WATER CORPORATION Standard Conditions for Goulburn Valley Water Construction Contracts Client Handbook for Consultants 29 Public liability policy of insurance – the Alternative applying: (Clause 19) Alternative 2 30 If Alternative 1 applies the amount of public liability insurance shall not be less than: (Clause 19) Not applicable 31 Amount of Contractor’s professional indemnity insurance shall not be less than: (Clause 21) $5,000,000 32 Period for which Contractor’s professional indemnity insurance shall be maintained after issue of the Final Certificate: (Clause 21) 10 years or Victorian statutory minimum limit, whichever is longest 33 Categories of Consultants and amounts of Consultant’s professional indemnity insurance: (Clause 21) CATEGORY 34 Period for which each Consultant’s professional indemnity insurance shall be maintained after issue of the Final Certificate: (Clause 21) 10 years or Victorian statutory minimum limit, whichever is longest 35 The time by which access to the Site shall be given: (Clause 27.1) 14 days after the Date of Acceptance of Tender 36 The time for giving possession of the Site to enable the commencement of further work: (Clause 27.1) 14 days after the Date of Acceptance of Tender 37 The times by, or periods within which the Superintendent is to furnish information, materials, documents or instructions to the Contractor: (Clause 33.1) Refer Specification 38 Events causing delay: Clause replaced in Annexure Part B - industrial conditions (Clause 35.5 a i) Not applicable inclement weather (Clause 35.5 a ii) # Rate of liquidated damages: (Clause 35.6) Not applicable # Limit of Liquidated damages (Clause 35.7) No limit 39 40 AMOUNT $ Every Consultant $5,000,000 To be completed ($ per day) 9 GOULBURN VALLEY REGION WATER CORPORATION Standard Conditions for Goulburn Valley Water Construction Contracts Client Handbook for Consultants 41 # Bonus for early Practical Completion: (Clause 35.8) Clause deleted 42 # Limit of bonus: (Clause 35.8) Clause deleted 43 # Other events for which extra costs for delay or disruption are payable: (Clause 36) OTHER EVENTS 44 # The Defects Liability Period: (Clause 37) 12 months 45 The charge for overheads, administrative costs, site supervision, establishment costs, attendance and profit for daywork: (Clause 41 f) Not applicable 46 (a) Times under the Contract for payment claims (Clause 42.1) OR (b) Stages of the work under the Contract for payment claims: (Clause 42.1) Middle of each month 47 Unfixed plant and materials for which payment claims may be made before they are incorporated in the Works: (Clause 42.2) Nill 48 The amount of additional security for unfixed plant and materials: (Clause 42.2) N/A 49 The rate of interest on overdue payments: (Clause 42.7) Commonwealth Bank, Australia Commercial Overdraft rate prevailing at time of late payment 50 The delay in giving access to the Site which shall be a substantial breach: (Clause 44.7 c) 21 days 51 The delay in giving possession of the Site or sufficient of the Site which shall be a substantial breach (Clause 44.7 d) 21 days 52 Further steps required before proceeding – the Alternative applying: (Clause 47.2) Clause deleted 53 The person to nominate an arbitrator: (Clause 47.3) Not applicable 10 Not applicable N/A GOULBURN VALLEY REGION WATER CORPORATION Standard Conditions for Goulburn Valley Water Construction Contracts Client Handbook for Consultants ITEM 2 ANNEXURE B – GENERAL CONDITIONS OF CONTRACT The attached Annexures Part B are to be inserted in all Contracts where AS2124 – 1992 , AS 4300-1995 and AS 4305-1996 are used. These are default requirements with the Consultant to advise of any amendments proposed. 11 GOULBURN VALLEY REGION WATER CORPORATION Standard Conditions for Goulburn Valley Water Construction Contracts Client Handbook for Consultants ANNEXURE to the Australian Standard General Conditions of Contract, AS 2124 -1992 PART B This Annexure shall be issued as part of the Tender Documents and is to be attached to the General Conditions of Contract and shall be read as part of the Contract. DELETIONS, AMENDMENTS AND ADDITIONS 1. The following Clauses or parts have been deleted from the General Conditions in AS 21241992: Clause 35.7 Clause 35.8 Clause 45 Clause 47.3 2 The following provisions replace or amend as stated the corresponding provisions of the General Conditions in AS 2124-1992: 5.4 Time for provision of Security In Clause 5.4 the number 28 is replaced with the number 14. 5.5 Recourse to Retention Moneys and Conversion of Security Clause 5.5 is replaced with: 5.5 Conversion of Security The Contractor may not take any proceeding to enjoin or prevent the Principal from exercising its rights under any unconditional undertaking. 7. SERVICE OF NOTICES Clause 7 is amended by inserting the following additional paragraphs at the conclusion of the clause:Service of a notice by post will be deemed to have been effected within 3 days on the date of posting; and Service of a notice by facsimile will be deemed to have been effected at the time shown on the transmission print-out by the facsimile machine transmitting the notice. 12 GOULBURN VALLEY REGION WATER CORPORATION Standard Conditions for Goulburn Valley Water Construction Contracts Client Handbook for Consultants 8.1 Discrepancies Clause 8.1 is amended by inserting the following additional paragraph at the conclusion of the clause:Despite any other provision of the Contract the Contractor shall not be entitled to claim or to recover any payment from the Principal for extra costs, expenses or losses resulting from the resolution of any ambiguity or discrepancy which should reasonably have been identified by the Contractor at the time of preparation of its tender for the Works. 8.6 Confidential Information In Clause 8.6 the word “agreement” where it first appears is replaced with the words:“consent, which consent must not be unreasonably withheld”. 9.1 Assignment The paragraph in Clause 9.1 is replaced with the following:(a) The Contractor shall not assign mortgage charge otherwise encumber or declare itself trustee or purport to so assign mortgage charge otherwise encumber or declare itself trustee of or in relation to any of its rights under the Contract without the prior written consent of the Principal. (b) For the purposes of this clause, a change in shareholding of the Contractor such that a change in control of the Contractor occurs (whether occurring at the one time or through a series of transfer;s or issues of securities) or a change or alteration occurs in the corporate structure of the Contractor or the group of companies of which the Contractor is a member which results in a person (including a corporation) other than the shareholders of the Contractor at the date of this Contract: (i) controlling the composition of the board of directors; (ii) controlling the voting power of the board of directors or any class of shareholders or both; or (iii) holding more than one half of the issued share capital (either beneficially or otherwise). Shall be deemed to be an assignment of the Contract, and furthermore where the Contractor is a subsidiary of a listed public company and a change in control of that listed public company is effected solely by transfer of shares in the capital of that listed public company, that change in control shall also be deemed to be an assignment of the Contract. (c) The Principal may at any time freely assign all or any part of its rights and/or obligations under the Contract to any other person without the need to obtain the consent of the Contractor. The Contractor agrees at its own expense, on the request of the Principal, to do everything reasonably necessary to give effect to any such assignment including, but not limited to, the execution of documents. 13 GOULBURN VALLEY REGION WATER CORPORATION Standard Conditions for Goulburn Valley Water Construction Contracts Client Handbook for Consultants 9.2 Subcontracting The following is added to the end of clause 9.2:Despite this Clause 9.2, the Contractor must comply with the requirements in the Schedule of Incorporated Documents.” 15 PROTECTION OF PEOPLE AND PROPERTY The words before “the Contractor shall” are deleted. 35.5 Extensions of Time for Practical Completion Clause 35.5 (a) is deleted and replaced by: (a) delay occurring on or before the Date for Practical Completion limited to:- strikes not limited to the Site and not caused by any act or omission of the Contractor; inclement weather at the Site. 40.1 Variations to the Works Under the Contract The last paragraph is deleted. 40.5 Valuation The last paragraph in Clause 40.5 is deleted. 42.7 Final Payment Claim After the works “the last to expire” in Clause 42.5 the following works are inserted:“and upon completion to the reasonable satisfaction of the Superintendent of all remedial work.” 47.2 Alternative 1 Delete “Within 14 days after service ….. refer such dispute to arbitration or litigation.” 47.2 Alternative 2 Delete “A party served with a notice …… refer such dispute to arbitration or litigation” and replace with: “A party served with a notice of dispute may give a written response to the notice to the other party and the Superintendent within 28 days of the receipt of the notice. 14 GOULBURN VALLEY REGION WATER CORPORATION Standard Conditions for Goulburn Valley Water Construction Contracts Client Handbook for Consultants Within 42 days of service on the other party and the Superintendent of a notice of dispute or within 14 days of the receipt by the other party and the Superintendent of the written response, whichever is the earlier, the parties at project level shall, confer at least once to attempt to resolve the dispute. At any such conference, each party shall be represented by a person having authority to agree to a resolution of the dispute. If no resolution of the dispute is achieved the parties shall refer the dispute to the directors of the parties who within 14 days of the referral, shall confer at least once to attempt to resolve the dispute. If no resolution of the dispute is achieved either party may refer the dispute to an expert in accordance with, and subject to, The Institute of Arbitrators & Mediators Australia Expert Determination Rules.” 3. The following Clauses have been added to those of AS 2124-1992: 8.8 Precedence If the Contract contains any discrepancy or inconsistency then the order of precedence is:(a) Post tender correspondence and tender in full; (b) Annexure to the Australian Standard General Conditions of Contract AS 2124–1992, Part B; (c) General Conditions of Contract AS 2124–1992; (d) The General Specification; (e) The Technical Specification; (f) Appendices; and (g) Drawings and Schedule of Drawings. 14.5 Indemnity The Contractor shall indemnify the Principal against any loss, cost or damage sustained by the Principal as a result of the Contractor failing to comply with requirements of clause 14.1. 27.6 Contractor to Inform Itself The Contractor has inspected and reviewed all information relevant to the Works, has examined the Site and its surroundings, and accepts that the rates and lump sums specified in the Contract includes the costs of complying will all its obligations under the Contract. 35.9 Conditions Precedent Service by the Contractor on the Superintendent of notice claiming an extension of time within the respective times stipulated in Clause 35.5 is a condition precedent to the Contractors right to an extension of time for the relevant event or delay. 15 GOULBURN VALLEY REGION WATER CORPORATION Standard Conditions for Goulburn Valley Water Construction Contracts Client Handbook for Consultants 42.12 Program and Payment In addition to any other rights under the Contract the Principal may withhold 10% of any progress payment or payments if: (a) the Contractor fails to provide a Contractor’s Program as required under the Contract; and (b) if the Superintendent has served a notice on the Contractor stating its intention to withhold payment until the Contractor provides a Contractor’s Program, and the Contractor has not done so within 14 days of the date after the notice. 49 GOODS AND SERVICES TAX (GST) (i) GST Definitions For the purpose of this Clause: “GST” means GST within the meaning of the GST Act. “GST Act” means the A New Tax System (Goods and Services Tax) Act 1999 (as amended). “GST Related Tax Reform” includes any changes, reductions or abolition of any State, Territory or Commonwealth taxes, excises, fees or imposts including, but not limited to, financial transactions tax, wholesale sales tax, stamp duty, debits tax, associated with the introduction of the GST Act. Expressions set out in italics in this clause bear the same meaning as those expressions in the GST Act. (ii) Amounts Otherwise Payable Do Not Include GST To the extent that a party makes a taxable supply in connection with this Contract, except where express provision is made to the contrary, and subject to this Clause, the consideration payable by a party under this Contract represents the value of the taxable supply for which payment is to be made. (iii) Liability to Pay GST Subject to Clause 49 (iv) if a party makes a taxable supply in connection with this Contract for a consideration which, under Clause 49 (ii), represents its value, then the party liable to pay for the taxable supply must also pay, at the same time and in the same manner as the value is otherwise payable, the amount of any GST payable in respect of the taxable supply. (iv) Input Tax Credits The Contractor must do all things reasonably available to it to ensure that the amount of GST payable is minimised and the Principal’s ability to claim input tax credits is not impeded in any way, including submitting payment claims in relation to supplies made under this Contract as and when required by the Principal. 16 GOULBURN VALLEY REGION WATER CORPORATION Standard Conditions for Goulburn Valley Water Construction Contracts Client Handbook for Consultants (v) Payment Claims The Principal being the recipient of the supply will issue a Recipient Created Tax Invoice (RCTI). The RCTI will be issued to the Contractor after the Contractor has submitted a payment claim to the Superintendent. The Contractor is registered for GST purposes and will notify the Principal in writing if the Contractor ceases to be so registered. The Contractor will not issue tax invoices in respect to any payment claims made under the Contract. The Principal is registered for GST purposes and will notify the Contractor in writing if the Principal ceases to be so registered, or ceases to be eligible to issue a RCTI. The Principal indemnifies the Contractor for any liability for GST and penalty that may arise from an under statement of the GST payable on any supply for which it issues an RCTI. (vi) Contractor to Pass on Cost Savings From the date the GST is imposed, and at any time thereafter that the GST Related Tax Reform takes effect as law, the Contractor will reduce the Contract Sum (with consequential reductions to further payment to the Contractor under this Contract) to the extent that the cost to the Contractor of making a supply under this Contract is reduced, directly or indirectly, by the GST Related Tax Reform. The Principal may, at any time, require the Contractor to submit evidence of the financial impact of GST Related Tax Reform on the cost of making supplies under this Contract. The Contractor will give the Principal access to such information and records as the Principal reasonably requires to enable the Principal to make its own assessment of such financial impact. 50 AMOUNTS INCLUDED IN CONTRACT SUM (a) The Contractor must allow for and ensure the payment of: (b) (i) all customs duties, tariffs, goods and services taxes and similar taxes and charges paid or payable on all plant and materials and the Works; (ii) all royalties, licence fees and similar and payments for intellectual property rights in respect of all plant and materials and the Works; and (iii) all fluctuations in the value of the Australian dollar against other currencies. All of the amounts which the Contractor must allow and pay under this clause are included in the Contract Sum and the Contractor may not claim any adjustment to the Contract Sum for any of those amounts. 17 GOULBURN VALLEY REGION WATER CORPORATION Standard Conditions for Goulburn Valley Water Construction Contracts Client Handbook for Consultants ANNEXURE to the Australian Standard General Conditions of Contract for Design and Construct, AS 4300 -1995 PART B This Annexure shall be issued as part of the Tender Documents and is to be attached to the General Conditions of Contract and shall be read as part of the Contract. DELETION, AMENDMENTS AND ADDITIONS 1. The following Clauses or parts of Clauses have been deleted from the General Conditions in AS 4300 – 1995: Clause 35.7 Clause 35.8 Clause 45 Clause 47.3 2 The following provisions replace or amend as stated the corresponding provisions of the General Conditions in AS 4300 – 1995: 5.4 Time for Provision of Security In Clause 5.4 the number 28 is replaced with the number 14. 5.6 Conversion of Security and Recourse to Retention Moneys Clause 5.6 is replaced with: 5.6 Conversion of Security The Contractor may not take any proceedings to enjoin or prevent the Principal from exercising its rights under any unconditional undertaking. 7 SERVICE OF NOTICES Clause 7 is amended by inserting the following additional paragraphs at the conclusion of the clause: Service of a notice by post will be deemed to have been effected within 3 days of the date of posting; and Service of a notice by facsimile will be deemed to have been effected at the time shown on the transmission print out by the facsimile will be deemed to have been effected at the time shown on the transmission print-out by the facsimile machine transmitting the notice. 18 GOULBURN VALLEY REGION WATER CORPORATION Standard Conditions for Goulburn Valley Water Construction Contracts Client Handbook for Consultants 8.1 Discrepancies Clause 8.1 is amended by inserting the following additional paragraph at the conclusion of the clause: Despite any other provision of the Contract, the Contractor shall not be entitled to claim or to recover any payment from the Principal for extra costs, expenses or losses resulting from the resolution of any ambiguity or discrepancy which should reasonably have been identified by the Contractor at the time of preparation of its tender for the Works. 8.6 Confidential Information In Clause 8.6, the word “agreement” where it first appears is replaced with the words: Consent, which consent must not be unreasonably withheld, 9.1 Assignment The paragraph in clause 9.1 is replaced with the following: (a) The Contractor shall not assign mortgage charge otherwise encumber or declare itself trustee or purport to so assign mortgage charge otherwise encumber or declare itself trustee of or in relation to any of its rights under the Contract without the prior written consent of the Principal. (b) For the purposes of this clause, a change in shareholding of the Contractor such that a change in control of the Contractor occurs, (whether occurring at the one time or through a series of transfers or issues of securities), or a change or alteration occurs in the corporate structure of the Contractor or the group of companies of which the Contractor is a member which results in a person (including a corporation) other than the shareholders of the Contractor at the date of this Contract: (i) controlling the composition of the board of directors; (ii) controlling the voting power of the board of directors or any class of shareholders or both; or (iii) holding more than one half of the issued share capital (either beneficially or otherwise), shall be deemed to be an assignment of the Contract, and furthermore where the Contractor is a subsidiary of a listed public company and a change in control of that listed public company is effected solely by transfer of shares in the capital of that listed public company, that change in control shall also be deemed to be an assignment of the Contract. (c) The Principal may at any time freely assign all or any part of its rights and/or obligations under the Contract to any other person without the need to obtain the consent of the Contractor. The Contractor agrees at its own expense, on the request of the Principal, to do everything reasonably necessary to give effect to any such assignment including, but not limited to, the execution of documents. 19 GOULBURN VALLEY REGION WATER CORPORATION Standard Conditions for Goulburn Valley Water Construction Contracts Client Handbook for Consultants 9.2 Subcontracting The following is added at the end of clause 9.2: Despite this clause 9.2, the Contractor must comply with the requirements in the Schedule of Incorporated Documents. 15 PROTECTION OF PEOPLE AND PROPERTY The words before “the Contractor shall” are deleted. 35.5 Extension of Time for Practical Completion Clause 35.5(a) is deleted and replaced by: (a) delay occurring on or before the Date for Practical Completion limited to: - strikes not limited to the Site and not caused by any act or omission of the Contactor; - inclement weather at the Site. 40.1 Variations to the Works Under the Contract The last paragraph is deleted. 40.5 Valuation The last paragraph in Clause 40.5 is deleted. 42.5 Final Payment Claim After the words “the last to expire” in clause 42.5 the following words are inserted: And upon completion to the reasonable satisfaction of the Superintendent of all remedial work. 47.2 Alternative 1 Delete “Within 14 days after service ….. refer such dispute to arbitration or litigation.” 47.2 Alternative 2 Delete “A party served with a notice …… refer such dispute to arbitration or litigation” and replace with: “A party served with a notice of dispute may give a written response to the notice to the other party and the Superintendent within 28 days of the receipt of the notice. 20 GOULBURN VALLEY REGION WATER CORPORATION Standard Conditions for Goulburn Valley Water Construction Contracts Client Handbook for Consultants Within 42 days of service on the other party and the Superintendent of a notice of dispute or within 14 days of the receipt by the other party and the Superintendent of the written response, whichever is the earlier, the parties at project level shall, confer at least once to attempt to resolve the dispute. At any such conference, each party shall be represented by a person havi ng authority to agree to a resolution of the dispute. If no resolution of the dispute is achieved the parties shall refer the dispute to the directors of the parties who within 14 days of the referral, shall confer at least once to attempt to resolve the dispute. If no resolution of the dispute is achieved either party may refer the dispute to an expert in accordance with, and subject to, The Institute of Arbitrators & Mediators Australia Expert Determination Rules.” 3. The following Clauses have been added to those of AS 4300 – 1995: 8.8 Precedence If the Contract contains any discrepancy or inconsistency then the order of precedence is:(a) Post tender correspondence and tender in full; (b) Annexure to the Australian Standard General Conditions of Contract for Design and Construct, AS 4300–1995, Part B; (c) General Conditions of Contract for Design and Construct, AS 4300–1995; (d) The General Specification; (e) The Technical Specification; (f) Appendices; and (g) Drawings and Schedule of Drawings. 14.3 Indemnity This Contractor shall indemnify the Principal against any loss, cost or damage sustained by the Principal as a result of the Contractor failing to comply with requirements of Clause 14.1. 27.6 Contractor to Inform Itself The Contractor has inspected and reviewed all information relevant to the Works, has examined the Site and its surroundings, and accepts that the rates and lump sums specified in the Contract includes the cost of complying with all its obligations under the Contract. 21 GOULBURN VALLEY REGION WATER CORPORATION Standard Conditions for Goulburn Valley Water Construction Contracts Client Handbook for Consultants 35.9 Conditions Precedent Service by the Contractor on the Superintendent of notice claiming an extension of time within the respective times stipulated in Clause 35.5 is a condition precedent to the Contractor’s right to an extension of time for the relevant event or delay. 42.10 Program and Payment In addition to any other rights under the Contract the Principal may withhold 10% of any progress payment or payments if: (a) the Contractor fails to provide a Contractor’s program as required under the Contract; and (b) if the Superintendent has served a notice on the Contractor stating its intention to withhold payment until the Contractor provides a Contractor’s Program, and the Contractor has not done so within 14 days of the date after the notice. 49 GOODS AND SERVICES TAX (GST) (i) GST Definitions For the purpose of this Clause: “GST” means GST within the meaning of the GST Act. “GST Act” means the A New Tax System (Goods and Services Tax) Act 1999 (as amended). “GST Related Tax Reform” includes any changes, reductions or abolition of any State, Territory or Commonwealth taxes, excises, fees or imposts including, but not limited to, financial transactions tax, wholesale sales tax, stamp duty, debits tax, associated with the introduction of the GST Act. Expressions set out in italics in this clause bear the same meaning as those expressions in the GST Act. (ii) Amounts Otherwise Payable Do Not Include GST To the extent that a party makes a taxable supply in connection with this Contract, except where express provision is made to the contrary, and subject to this Clause, the consideration payable by a party under this Contract represents the value of the taxable supply for which payment is to be made. (iii) Liability to Pay GST Subject to Clause 49 (iv) if a party makes a taxable supply in connection with this Contract for a consideration which, under Clause 49 (ii), represents its value, then the party liable to pay for the taxable supply must also pay, at the same time and in the same manner as the value is otherwise payable, the amount of any GST payable in respect of the taxable supply. (iv) Input Tax Credits 22 GOULBURN VALLEY REGION WATER CORPORATION Standard Conditions for Goulburn Valley Water Construction Contracts Client Handbook for Consultants The Contractor must do all things reasonably available to it to ensure that the amount of GST payable is minimised and the Principal’s ability to claim input tax credits is not impeded in any way, including submitting payment claims in relation to supplies made under this Contract as and when required by the Principal. (vii) Payment Claims The Principal being the recipient of the supply will issue a Recipient Created Tax Invoice (RCTI). The RCTI will be issued to the Contractor after the Contractor has submitted a payment claim to the Superintendent. The Contractor is registered for GST purposes and will notify the Principal in writing if the Contractor ceases to be so registered. The Contractor will not issue tax invoices in respect to any payment claims made under the Contract. The Principal is registered for GST purposes and will notify the Contractor in writing if the Principal ceases to be so registered, or ceases to be eligible to issue a RCTI. The Principal indemnifies the Contractor for any liability for GST and penalty that may arise from an under statement of the GST payable on any supply for which it issues an RCTI. (viii) Contractor to Pass on Cost Savings From the date the GST is imposed, and at any time thereafter that the GST Related Tax Reform takes effect as law, the Contractor will reduce the Contract Sum (with consequential reductions to further payment to the Contractor under this Contract) to the extent that the cost to the Contractor of making a supply under this Contract is reduced, directly or indirectly, by the GST Related Tax Reform. The Principal may, at any time, require the Contractor to submit evidence of the financial impact of GST Related Tax Reform on the cost of making supplies under this Contract. The Contractor will give the Principal access to such information and records as the Principal reasonably requires to enable the Principal to make its own assessment of such financial impact. 50 AMOUNTS INCLUDED IN CONTRACT SUM (a) (b) The Contractor must allow for and ensure the payment of: (i) all customs duties, sales tax, tariffs, goods and services tax and similar taxes and charges paid or payable on all plant and materials and the Works; (ii) all royalties, licence fees and similar payments for intellectual property rights in respect of all plant and materials and the Works; and (iii) all fluctuations in the value of the Australian dollar against other currencies. All of the amounts which the Contractor must allow and pay under this clause are included in the Contract Sum and the Contractor may not claim any adjustment to the Contract Sum for any of those amounts. 23 GOULBURN VALLEY REGION WATER CORPORATION Standard Conditions for Goulburn Valley Water Construction Contracts Client Handbook for Consultants ANNEXURE TO AS 4305 – 1996 MINOR WORKS CONTRACT CONDITIONS AMENDMENTS/DELETIONS Clause 31 is replaced by: “A party served with a notice of dispute may give a written response to the notice to the other party and the Superintendent within 28 days of the receipt of the notice. Within 42 days of service on the other party and the Superintendent of a notice of dispute or within 14 days of the receipt by the other party and the Superintendent of the written response, whichever is the earlier, the parties at project lev el shall, confer at least once to attempt to resolve the dispute. At any such conference, each party shall be represented by a person having authority to agree to a resolution of the dispute. If no resolution of the dispute is achieved the parties shall refer the dispute to the directors of the parties who within 14 days of the referral, shall confer at least once to attempt to resolve the dispute. If no resolution of the dispute is achieved either party may refer the dispute to mediation by a mediator to be agreed between the parties or failing agreement within 5 days of the referral, by a mediator chosen by the President of the Institute of Arbitrators and Mediators Australia. If the dispute is referred to mediation, the parties agree that: (a) each shall bear their respective costs of the mediation save that the mediator’s fees, fees for mediation rooms and costs of shared equipment, facilities and services of the mediation shall be shared equally between the parties; (b) the venue for the mediation shall be agreed between the parties or failing such agreement, shall be nominated by the mediator appointed; (c) the parties may not be legally represented in the mediation unless the parties agree otherwise; (d) complete confidentiality will be preserved in respect of the mediation and any documents and information used at or in relation to the mediation; and (e) mediation proceedings shall not be used as evidence in any subsequent legal proceedings or litigation. In the event that the dispute cannot be resolved after the conclusion of the mediation, either party may commence litigation in respect of it. If litigation is not commenced within 28 days of the conclusion of the mediation, the party who served the notice of dispute (if that party is the Contrac tor) shall be deemed to have waived all of its rights in connection with the subject matter of the dispute and shall be absolutely barred from making any claim against the Principal in connection with the subject matter of the dispute and this Clause 31 ma y be pleaded by the Principal as a bar to any such claim.” GOULBURN VALLEY REGION WATER CORPORATION Standard Conditions for Goulburn Valley Water Construction Contracts Client Handbook for Consultants ITEM 3 ASSET REGISTER The contractor is to provide an Asset Register at the completion of works to Practical Completion using the sample format provided. The Certificate of Practical Completion will not be issued until this information is provided. Building assets listed in the Asset Register are to include area in square metres, building materials used for floor, walls and roof and the buildings purpose. The total value of the assets listed on the Asset Register including contractor installation costs is to equal the final Contract Sum. GOULBURN VALLEY REGION WATER CORPORATION Standard Conditions for Goulburn Valley Water Construction Contracts Client Handbook for Consultants SAMPLE ASSET REGISTER Tag Number Description Further Details Type Manufacturer Model No. Nominal Size Serial No. Connection Details Supplier Details BACKWASH WATER SYSTEM VALVES V061 V062 V063 V064 V065 V066 V067 PUMPS P009 Backwash Water Inlet Modulating Butterfly Keystone Valve Backwash Water Pump 1 Isolation Valve Backwash Pump 1. Backwash Water Pump 1 Isolation Valve Backwash Water Pump 2 Isolation Valve Backwash Pump 2. Backwash Water Pump 2 Isolation Valve Backwash Pump 1. Motor F1CLE2AE500mm 3.5UC/F79U091DA/F793EP -LS F1CLE2AE/F42 500mm 7 Flanged Table D Keystone Manual Butterfly Keystone N/A Manual Check John Valves Butterfly Keystone John Fig. 420 500mm F1CLE2AE/F42 600mm 7 John Valves Flanged Table D Keystone Manual Butterfly Keystone F1CLE2AE/F42 500mm 7 Flanged Table D Keystone N/A Manual Check John Valves Butterfly Keystone John Fig. 420 500mm F1CLE2AE/F42 600mm 7 John Valves Flanged Table D Keystone Mech. Seal MVE400x400380L F280MK06 124H Thompson Kelly Lewis Western Electric Flanged Table D Keystone MV00110 6410526 Thompson Kelly Lewis Western Electrical Approx Cost GOULBURN VALLEY REGION WATER CORPORATION Standard Conditions for Goulburn Valley Water Construction Contracts Client Handbook for Consultants Tag Number P010 Description Further Details Backwash Pump 2. Motor Type Mech. Seal Manufacturer Model No. Thompson Kelly MVE400x400Lewis 380L Western Electric F280MK06 124H Nominal Size Serial No. MV00111 6402833 Connection Details Supplier Details Thompson Kelly Lewis Western Electrical MISCELLANEOUS 4 x Backwash Troughs & Installation PF Engineering PF Engineering PUMPS P011 P012 Washwater Transfer Washwater Transfer PUMPS P013 P014 Filtered Water Cell 1 Filtered Water Cell 2 Samples Pumps 2HM54 Samples Pumps 2HM54 Raw Water Turbidity Analyser ABB 4670-401 Instrumentation Filtered Water Turbidity Analyser Floated Water Turbidity Analyser pH Great Lakes INSTRUMENTATION AE038 AE039 AE040 AE069 Submersible ITT Flygt Submersible ITT Flygt Great Lakes CP3067.18HT CP3067.18HT 95T5A0B1N / 8224T2A0C3N 95T5A0B1N / 8224T2A0C3N 50 x 50mm Discharge 50 x 50mm Discharge 3612 3613 ITT Flygt ITT Flygt Lowara Lowara ABB Instrument ation Combined Instruments Combined Instruments Approx Cost GOULBURN VALLEY REGION WATER CORPORATION Standard Conditions for Goulburn Valley Water Construction Contracts Client Handbook for Consultants Tag Number Description COMPRESSORS C001 Compressor No. 1. C002 Compressor No. 2. Further Details Type Rotary Screw Rotary Screw Manufacturer Model No. Nominal Size Serial No. Connection Details Supplier Details Approx Cost Champion Compressors Champion Compressors CSA7 31.7 cfm Champion Compressors CSA7 31.7 cfm Champion Compressors Champion Compressors Champion Compressors 3211 MISCELLANEOUS Vertical Air Receiver Refrigerated Air Drier CED 103 Champion Compressors 52 cfm Champion Compressors 10m x 6m x 3m High (60m2) Telfords Building Systems EXAMPLE OF BUILDING DESCRIPTION RAW WATER PUMP STATION Building - Tilt Slab Concrete Walls, Colourbond Steel Roof, Concrete floor 28 GOULBURN VALLEY REGION WATER CORPORATION Standard Conditions for Goulburn Valley Water Construction Contracts Client Handbook for Consultants ITEM 4 RECIPIENT CREATED TAX INVOICE AGREEMENT (RCTI) FORM All contractors are required to sign the attached RCTI form as part of the contract. 29 GOULBURN VALLEY REGION WATER CORPORATION Standard Conditions for Goulburn Valley Water Construction Contracts Client Handbook for Consultants RECIPIENT CREATED TAX INVOICE AGREEMENT TO BE SIGNED BY CONTRACTORS Supplier Details Supplier Name: Supplier ABN: Supplier Address: Recipient Details Recipient Name: Recipient ABN: Recipient Address: Goulburn Valley Water 84 578 076 056 PO Box 185 SHEPPARTON 3632 SUPPLIER AUTHORISATION We the supplier as listed above hereby authorise Goulburn Valley Water to issue Recipient Created Tax Invoices on our behalf for any progress claims in connection with any of our contracts with Goulburn Valley Water. We the supplier will not issue Tax Invoices in respect of amounts invoiced by Goulburn Valley Water on our behalf. We are registered for GST when signing this agreement and will notify Goulburn Valley Water should we cease to be registered. Signed on behalf of the supplier Authorised Officer RECIPIENT STATEMENT Goulburn Valley Water acknowledges that it is registered for GST when it has entered into this agreement. We will notify the supplier if we cease to satisfy any of the requirements to issue Recipient Created Tax Invoices in accordance with the GST Ruling on Recipient Created Tax Invoices (GSTR 2000/10) Signed on behalf of Goulburn Valley Water Authorised Officer Dated:……………………. 30 GOULBURN VALLEY REGION WATER CORPORATION Standard Conditions for Goulburn Valley Water Construction Contracts Client Handbook for Consultants ITEM 5 INSTRUMENT OF AGREEMENT The Form of Formal Instrument Agreement shall have the format provided as follows. 31 GOULBURN VALLEY REGION WATER CORPORATION Standard Conditions for Goulburn Valley Water Construction Contracts Client Handbook for Consultants FORM OF FORMAL INSTRUMENT OF AGREEMENT FOR CONTRACTS OVER $1,000,000 AGREEMENT made ……………………….day of ………………………..2010 BETWEEN …………… ……………. ……………. AND Goulburn Valley Region Water Corporation 104-110 Fryers St Shepparton 3630 IT IS AGREED that the annexed documents marked as follows: TITLE Letter of Acceptance dated ……… Post Tender correspondence per Attachment 1 of the Letter of Acceptance. Tender dated ……… AS (Insert appropriate standard) General Conditions of Contract AS (Insert appropriate standard) Annexure to General Conditions of Contract - Part A. AS (Insert appropriate standard) Annexure to General Conditions of Contract - Part B The Specification shall together comprise Contract ………. between the parties AND if the contractor or Principal is two or more persons they shall be bound jointly and severally. Signed by the contractor: THE COMMON SEAL OF …………………………………………….. …………………………………………….. in the presence of …………………………………………….. OR SIGNED (SEALED AND DELIVERED by the said …………………….. …………………………………………….. IN THE PRESENCE OF …………………………………………….. Signed by the Principal: The COMMON SEAL of the Goulburn Valley Region Water Corporation was hereto affixed in the presence of: ……………………………………………………………. Chair/Non-Executive Director ……………………………………………………………. Secretary/Managing Director 32 GOULBURN VALLEY REGION WATER CORPORATION Standard Conditions for Goulburn Valley Water Construction Contracts Client Handbook for Consultants FORM OF FORMAL INSTRUMENT OF AGREEMENT FOR CONTRACTS LESS THAN $1,000,000 AGREEMENT made ……………………….day of ………………………..2010 BETWEEN ........................................................ ........................................................ ........................................................ AND Goulburn Valley Region Water Corporation 104-110 Fryers St Shepparton 3630 IT IS AGREED that the annexed documents marked as follows: TITLE Letter of Acceptance dated ……… Post Tender correspondence per Attachment 1 of the Letter of Acceptance. Tender dated ……… AS (Insert appropriate standard) General Conditions of Contract AS (Insert appropriate standard) Annexure to General Conditions of Contract - Part A. AS (Insert appropriate standard) Annexure to General Conditions of Contract - Part B The Specification shall together comprise Contract ………. between the parties AND if the contractor or Principal is two or more persons they shall be bound jointly and severally. Signed by the contractor: THE COMMON SEAL OF …………………………………………….. …………………………………………….. in the presence of …………………………………………….. OR SIGNED (SEALED AND DELIVERED by the said …………………………………. …………………………………………….. IN THE PRESENCE OF …………………………………………….. Signed by the Principal: SIGNED for and on behalf of, and with the authority of, the GOULBURN VALLEY REGION WATER CORPORATION, by its authorised delegate in the exercise of a power conferred by an instrument of Delegation dated 1 May 2013 in the presence of: ) ) ) ) ) ............................................................ Witness Signature 33 ………………………………………………… (Signature) ………………………………………………… Print Name (authorised delegate) Position: …………………………………. GOULBURN VALLEY REGION WATER CORPORATION Standard Conditions for Goulburn Valley Water Construction Contracts Client Handbook for Consultants ITEM 6 OPERATIONS & MAINTENANCE MANUALS Standard O&M Manual documents may be downloaded from the Goulburn Valley Water website www.gvwater.vic.gov.au under the Business – Contractors & Consultants section. 34 GOULBURN VALLEY REGION WATER CORPORATION Standard Conditions for Goulburn Valley Water Construction Contracts Client Handbook for Consultants ITEM 7 PRACTICAL COMPLETION OF WORKS The following clauses shall be included in the Tender/Contract document. 35 GOULBURN VALLEY REGION WATER CORPORATION Standard Conditions for Goulburn Valley Water Construction Contracts Client Handbook for Consultants Practical Completion of Works Practical Completion shall not be granted until the Contractor has completed successful testing and commissioning, submitted “as-built” drawings, the Asset Register and Operations & Maintenance Manual. Defect Rectification All defects noted at the time of issuing the Certificated of Practical Completion shall be completed within 28 days or a mutually agreed timeframe as determined by the Superintendent. Failure to rectify the works within the timeframe shall result in the works being carried out by others at the Contractors cost. These costs shall include all costs associated with the rectification work. 36 GOULBURN VALLEY REGION WATER CORPORATION Standard Conditions for Goulburn Valley Water Construction Contracts Client Handbook for Consultants ITEM 8 PROVISIONAL AMOUNT FOR CONTINGENCIES No contingency amounts are to be allowed for in the Contract Schedules. However, consultants are to allow for a contingency amount in the report on tenders with allowances made generally to the following limits. 25% for projects that are at the concept stage. 15% for projects after the functional design is complete. 10% for projects (Contract Amount: 0 – $1,000,000) after the detailed design is complete $100,000 + 5% for any dollar in excess of $1,000,000 for projects (Contract Amount: $1,000,000 – $2,500,000) after the detailed design is complete. $175,000 + 21/2% for every dollar in excess of $2,500,000 for projects (Contract Amount: $2,500,000 - $5,000,000) after the detailed design is complete 37 GOULBURN VALLEY REGION WATER CORPORATION Standard Conditions for Goulburn Valley Water Construction Contracts Client Handbook for Consultants ITEM 9 TENDERING No projects are to be tendered without all relevant statutory approvals and conditions being confirmed in writing and included, where appropriate, into the Tender documents. Exceptions to this rule may be permitted where written confirmation is received from the Corporation. The following section includes the Corporation’s General Conditions of Tendering and a generic Tender Booklet for incorporation into tender documents. These documents have been compiled to reflect the Corporation’s tendering policy. The General Conditions of Tendering shall be amended only in line with the embedded notes and then the Annexure completed. The Tender Booklet shall be modified to reflect the works, including the standard form of contract and the General Conditions of Tendering. These are default requirements with the Consultant to advise the Corporation’s Project Manager of any amendments proposed 38 GOULBURN VALLEY REGION WATER CORPORATION Contract insert contract number insert contract title CONDITIONS OF TENDERING Invitation to Tender The Goulburn Valley Region Water Corporation invites Tenders from suitably qualified Contractors for the performance of a Contract is a Lump Sum Contract Not Subject to Rise & Fall or a Schedule of Rates Contract Not Subject to Rise & Fall. (delete the type that does not apply – and this text) Tenders subject to variation in prices and rates will be deemed as non-conforming. Tender Documents and Enquires Tender documents can be http://www.gvwater.vic.gov.au/ . obtained from the Goulburn Valley Water website Enquiries in relation to the Tender should be addressed in the first instance to the person nominated in Annexure A to Conditions of Tendering. Tender documents may be inspected during business hours at the Fryers Street, Shepparton, office of the Corporation. Lodgement of Tenders Tenders shall be lodged in the Tender Box at the Shepparton office of the Corporation and the Tender shall comprise, at a minimum, the lodgement of the Tender Booklet. Tenderers that fail to include the Tender Booklet in full will be deemed to be non-conforming. The Tender shall be enclosed in a sealed envelope endorsed with “Tender Box” and the Corporation’s Contract Number. Tender documents are to be printed double sided, and binding if used, shall be easily removable. Tenders submitted by mail are to be sent for delivery in the ordinary course of mail before the closing time for lodgement of tenders. Tenders transmitted by facsimile or email and received before the Tender closing time will be accepted. The Corporation cannot guarantee the availability of its facsimile or email facilities to receive transmissions at any time, so the Tenderer is solely responsible for the successful transmission of the Tender prior to the close of the Tender. If transmitted by facsimile or email, the Tenders must include the Tender Booklet in full and the original completed Tender Booklet must be received by the Corporation within two working days of the closing time for lodgement of tenders. The facsimile number and email details are in Annexure A to Conditions of Tendering. The Tender Box is located at the following address: 104-110 Fryers Street PO Box 185 SHEPPARTON Vic 3630 Tenders transmitted by facsimile or email Facsimile – (03) 5831 1467 Email – tenders@gvwater.vic.gov.au The Corporation is not responsible for any costs or expenses incurred by the Tenderer in preparing and lodging its tender. 39 GOULBURN VALLEY REGION WATER CORPORATION Contract insert contract number insert contract title Tenderer to Become Informed The Tenderer shall: (a) Become fully informed of the contents of the Contract documents, the potential site conditions and circumstances under which the Works are to be executed and without in any way affecting the generality of the foregoing; to have carefully examined the Drawings, Specifications, Schedules, and General Conditions of Contract and any reports, maps, diagrams, drawings or other information which, not being part of the Specifications or Drawings, are nevertheless available to the Tenderer from the Corporation. (b) Form conclusions, before submitting the Tender, as to the type and condition of ground and services that are to be encountered at any Site. (c) Assess all aspects of the Works and make provision for any out of "usual hours" of work. "Usual hours" of work means the hours between 8.00 am and 5.00 pm from Monday to Friday inclusive, but excluding statutory public holidays. (d) For any unscheduled "out of hours" work, the Corporation shall provide supervision and/or assistance, as required and will recover all reasonable costs, as assessed by the Superintendent, from the Contractor. The requirement for the Tenderer to inspect the site of the work prior to submitting the Tender is detailed in Annexure A to Conditions of Tendering. A site inspection may be arranged by contacting the person nominated in Annexure A to Conditions of Tendering. Should any tenderer be unable to attend at the specified time alternative inspection arrangements may be made at the Corporation’s discretion. No claims will be considered for extra costs arising from: (a) Failure on the part of the Tenderer to become fully informed of the contents of the Contract documents. (b) The nature of the Corporation’s assets being different from that anticipated by the Contractor at the time of Tendering. If the Tenderer has any doubt as to the meaning or completeness of any portion of the Tender Documents, the Corporation’s Contact identified above shall be asked for clarification, which when given, shall only be valid if issued in writing. Any clarification given pursuant to this clause may also be issued to all other prospective Tenderers. Non-conforming Tenders A non-conforming Tender is any tender which does not comply with all the requirements herein and the Corporation may, in sole discretion, consider a non-conforming tender. Any non-conforming tender shall fully detail all variances with the tender documents in the Schedule "Statement of Conformance" contained within the Tender Booklet. No conditions or qualifications will be considered by the Corporation unless clearly stated in the Schedule or the body of any letter accompanying the Tender. Printed conditions on the reverse side of any tender letter shall be specifically excluded unless repeated in the Schedule or body of the tender letter. The Corporation will not negotiate prices in relation to non-conformances. Tendered prices will not be increased if non-conformance or conditions are deemed unacceptable unless they are priced with the tender. Where unacceptable non-conformances are not priced the non-conforming tender will not be further considered. 40 GOULBURN VALLEY REGION WATER CORPORATION Contract insert contract number insert contract title Post Tender Submission Notwithstanding any other requirements of the Tender Documents, the Corporation may require a Tenderer to submit additional information concerning the Tender before any Tender is accepted. Should the Tenderer fail to submit the information so required by the date and time stipulated, the Tender may be deemed as non-conforming. Acceptance of Tenders The Corporation shall not be bound to accept the lowest or any Tender for the Work under the Contract. The Corporation reserves the right to accept part or the whole of any offer received. A Tender shall be accepted only by a notice in writing advising acceptance of the Tender by the Corporation, which may be handed to, or posted by prepaid post to, or left at the address notified on the Tender Form. The successful Tenderer shall be deemed to have received such notice if posted by prepaid post at the time it would normally be received in the ordinary course of the post at the address to which it is directed. The Date of Acceptance of Tender shall be deemed to be the date, which appears on the notice in writing of acceptance of Tender. Withdrawal of Tenders A tender may not be withdrawn prior to the expiration of 90 days following the date of closing of Tenders, as notified in the advertisement or other instrument inviting the submissions of Tenders, unless with the agreement of the Corporation. Disclosure of Information The Freedom of Information Act 1982 gives the public rights of access to information in the possession of Government and its agencies, limited only by exemptions and exceptions required for the protection of essential public interests and private and business affairs of persons, in respect of whom information is collected and held by Government and its agencies. Notwithstanding, until the Contract is awarded, the Corporation shall endeavour to maintain confidentiality of price and other information submitted by the Tenderer. Following award of Tender, unsuccessful tenderers will, on request, be notified of the name of the successful tenderer. No other information regarding the successful tender will be provided. No information will be released regarding unsuccessful tenders. Ownership of Tender Documents Tender documents are provided to prospective tenderers on a “Commercial in Confidence” basis, the information contained herein is confidential and shall not be distributed or made public without the written consent of the Corporation. Notwithstanding that a document deposit may be required the documents shall remain the property of the Corporation. Code of Practice for Tendering All Tenderers must comply with the Victorian Government Code of Practice for the Building and Construction Industry. Lodgement of a Tender shall be evidence of the Tenderer’s agreement to comply with the Code throughout the tendering process and for the duration of any Contract that may be awarded. Failure to comply with the Code may be taken into account by the Corporation when considering this or any subsequent tender and may result in this or any subsequent tender being passed over. 41 GOULBURN VALLEY REGION WATER CORPORATION Contract insert contract number insert contract title Taxes and Duties The Tender sum is deemed to be inclusive of all expenses of the Contractor, insurance, duties, imposts and taxes, which shall be paid by the Contractor, but are exclusive of any GST. The GST payable by the contractor under the GST law on the Contract sum, invoiced to the Corporation under this Contract shall be paid by the Corporation to the Contractor. Payroll tax shall be deemed to be included in the Tender prices. The Tender prices shall be deemed to include any customs duty and any pri-mage applicable on all imported materials, plant and equipment required in connection with the works under the Contract. Review of Tenders The Corporation is seeking to select the best value for money tender and the principal selection criteria upon which tenders will be assessed, and the weighting to be given to each criterion, are indicated in Annexure A to Conditions of Tendering. (Note the following paragraph is to deleted if the Victorian Government’s “Victorian Industry Participation Policy” does not apply – delete this text) Assessment of the VIPP in the Evaluation Process will occur where there are two or more Tenders that offer similar value for money, where the VIPP Statements may be used to differentiate between the value and benefit of the tenders. Capacity to Undertake Works Tenderers are required to demonstrate their capacity to undertake the works and the number staff that will be engaged on each project. Schedules for Relevant Experience, Management/Supervisory Personnel, Sub-Contractors and Materials and Suppliers are contained within the Tender Booklet. Time for Completion of Works Tenderers are required to submit an outline Program of Works in the form of a time-based bar chart in weeks from the date of Letter of Acceptance. A detailed program will be required at the time of acceptance. A template for the outline program of works is contained within the Tender Booklet. It is expected that the successful contractor will be able to commence work within the period indicated in Annexure A to Conditions of Tendering of the tender being awarded, subject to the approval of plans and receipt of any necessary clearances. Tenderer OHS Management System Questionnaire Tenderers shall complete the Tenderer OH&S Management System Questionnaire contained within the Tender Booklet. Tenderers shall be required to verify their responses noted in the questionnaire by providing evidence of their ability and capacity in relevant matters. By submission of the tender and questionnaire the Tenderer acknowledges and confirms as accurate all details contained in the questionnaire and any verifying documents. Financial Assessments & Referee Checks The Corporation may use an independent Assessor to conduct financial assessments and referee checks. For this assessment to be completed, a representative from one of these organisations may contact you requesting financial or other information. The independent assessment is specifically for use by the Corporation for the purpose of evaluating tenders and will be treated as strictly confidential. Submission of a Tender will be taken as agreement that the Tenderer agrees that it will co-operate with an independent assessor during the conduct of financial assessments and referee checks. 42 GOULBURN VALLEY REGION WATER CORPORATION Contract insert contract number insert contract title Collusive Tendering To ensure that the tenderer has not entered into any inappropriate contract arrangement or understanding to pay any monies to a trade association or with any other prospective tenderer, and that the tenderer has no knowledge of the tender price or intended tender price of any other tenderer or prospective tenderer, the tenderer shall complete the Statutory Declaration form included in the Tender Booklet. Industrial Relations No claims by the Contractor for site allowance conditions that may apply to the project including those existing from the Victorian Building Industry Agreement or any other industrial relations conditions or disputes will be allowed by the Superintendent. It shall be the responsibility of the Contractor to negotiate these aspects with the relevant Unions and bear any associated costs. Victorian Industry Participation Policy (Note this clause “Victorian Industry Participation Policy” is to deleted if the Victorian Government’s contribution the contract is estimated to be less than $1million – delete this text) The Tenderer is to provide a Victorian Industry Participation Policy (VIPP) Statement prepared in accordance with the Guidelines for Preparation of VIPP Statements. A pro-forma for the submission of the VIPP Statement is contained within the Tender Booklet. The final method of ensuring Victorian Industry Participation will be negotiated with the best value for money Tenderer and the approved method will be included in the successful Tenderers contract. This may be used by the Department of State and Regional Development for future VIPP compliance auditing. 43 GOULBURN VALLEY REGION WATER CORPORATION Contract insert contract number insert contract title Annexure A to Conditions of Tendering Nominated Person for Tender Enquiries (Clause 0) Nominated Person Phone Mobile Fax Email Inspection of Site (Clause 0) Lodgement of Tenders (Clause 0) Tender Close Time & Date Selection Criteria (Clause 0) Time for Commencement (Clause 0) A compulsory site inspection with representatives of the Corporation is required. Location: Date & Time: or A compulsory site inspection is not required. Delete which ever is not applicable (and this text) By 2.00pm on Tuesday insert closing date (day month year) Criteria Weighting Initial Price % Relevant Experience & Track Record % Project Team & Management % OH&S System % Time Management % (Insert criteria and weighting – delete % this text) (insert the number of weeks) Weeks 44 GOULBURN VALLEY REGION WATER CORPORATION Contract insert contract number insert contract title INSERT CONTRACT TITLE CONTRACT NO. XX/XXXX/XX TENDER BOOKLET Goulburn Valley Region Water Corporation 104 – 110 Fryers Street (PO Box 185) SHEPPARTON VIC 3630 45 GOULBURN VALLEY REGION WATER CORPORATION Contract insert contract number insert contract title THIS PAGE IS BLANK Tenderer Signature of Tenderer Date of Tender ....................................................................................................................................... ......................................................... Name .................................................................. ......................................................... 46 GOULBURN VALLEY REGION WATER CORPORATION Contract insert contract number insert contract title This Tender Booklet comprises the following Tender Schedules - Tender Form 49 - Schedule 1 – Tenderer Information 50 - Schedule 2 - Statutory Declaration 51 - Schedule 3 - Dissection of Lump Sum 52 - Schedule 4 - Schedule of Rates 53 - Schedule 5 – Personnel, Plant & Equipment 54 - Schedule 6 - Relevant Experience 56 - Schedule 7 - Management/Supervisory Personnel 57 - Schedule 8 - Sub-Contractors 58 - Schedule 9 - Materials and Suppliers 59 - Schedule 10 - Program of Works 60 - Schedule 11 - Tenderer OH&S Questionnaire 61 - Schedule 12 - Receipt of Addenda 62 - Schedule 13 - Tender Conformance 63 - Schedule 14 - Recipient Created Tax Invoice Agreement 64 - Schedule 16 - Victorian Industry Participation Policy (VIPP) Statement 65 Tenderer Signature of Tenderer Date of Tender ....................................................................................................................................... ......................................................... Name .................................................................. ......................................................... 47 GOULBURN VALLEY REGION WATER CORPORATION Contract insert contract number insert contract title THIS PAGE IS BLANK Tenderer Signature of Tenderer Date of Tender ....................................................................................................................................... ......................................................... Name .................................................................. ......................................................... 48 GOULBURN VALLEY REGION WATER CORPORATION Contract insert contract number insert contract title Tender Form (Insert tender form relevant to the general conditions of contract – delete this text) Tenderer Signature of Tenderer Date of Tender ........................................................ ............................................................................. ........................................................ Name ................................................................. ........................................................ 49 GOULBURN VALLEY REGION WATER CORPORATION Contract insert contract number insert contract title Schedule 1 – Tenderer Information Tenderers are required to provide contact information as follows: Business Name ABN Number Address Contact Details Name Address Telephone No. Fax No. Mobile No. Email Alternative Contact Name Address Telephone No. Fax No. Mobile No. Email ............................................................................................................................................ ............................................................................................................................................ ............................................................................................................................................ ............................................................................................................................................ ............................................................................................................................................ ............................................................................................................................................ ............................................................................................................................................ ............................................................................................................................................ ............................................................................................................................................ ............................................................................................................................................ ............................................................................................................................................ ............................................................................................................................................ ............................................................................................................................................ ............................................................................................................................................ ............................................................................................................................................ ............................................................................................................................................ ............................................................................................................................................ ............................................................................................................................................ ............................................................................................................................................ ............................................................................................................................................ Tenderer Signature of Tenderer Date of Tender ........................................................ ............................................................................. ........................................................ Name ................................................................. ........................................................ 50 GOULBURN VALLEY REGION WATER CORPORATION Contract insert contract number insert contract title Schedule 2 - Statutory Declaration This Statutory Declaration forms part of a tender submitted by __________________________ for Contract No. insert contract number of Goulburn Valley Water for the insert contract title. I,__________________________________________________________________________ of _____________________________________________ in the State of ________________ sincerely declare THAT 1. I hold the position of ___________________________________________ and am duly authorised by _______________________________________________ ("the Tenderer") to make this declaration on its behalf. 2. * Neither the Tenderer nor any of its servants or agents has entered into any contract, arrangement or understanding to pay monies to any trade association, apart from the normal amount (annual subscription, turnover or contract fee) imposed by that trade association or * the Tenderer has agreed to pay a special fee to a trade association of $_____________ if it is successful in the tender. (* Delete and initial as may be appropriate) 3. Neither the Tenderer nor any of its servants or agents had any knowledge of the price of any other tenderer prior to submitting its tender nor has the Tenderer or any of its servants or agents disclosed to any rival tenderer the Tenderer's price prior to the closing of tenders. 4. The Tenderer submitted its tender in good faith and has not deliberately set its tender price above the level of rival tenderers. 5. As at the date of this declaration, the Tenderer intends to do the work set out in the tender. 6. Neither the Tenderer nor any of its servants or agents has entered into any contract, arrangement or understanding for the purpose or one of the purposes being that, in the event that it is successful in the tender, it will pay to any unsuccessful tenderer any moneys in respect of or in relation to the tender or any contract resulting there from. AND I make this solemn declaration conscientiously believing the same to be true and by virtue of the provisions of an Act of the Parliament of Victoria rendering persons making a false declaration punishable for wilful and corrupt perjury. DECLARED at ______________in the in the State of _____________ this day of ______________ Two thousand and Seven_____________ Before ___________________________ Tenderer Signature of Tenderer Date of Tender ........................................................ ............................................................................. ........................................................ Name ................................................................. ........................................................ 51 GOULBURN VALLEY REGION WATER CORPORATION Contract insert contract number insert contract title Schedule 3 - Dissection of Lump Sum (Note this schedule is only required where the works are a Lump Sum contract – if not delete this schedule – delete this text) The Tenderer shall provide a priced breakdown of the various components of work and activities. Tenderers may, if desired, add addition items to the Dissection to more fully describe the work offered. The Dissection of Lump Sum will be used for tender assessment, to assess progress of the works, for the determination of progress payments and for the assessment of variation claims. Item Description Unit Quantity Unit Price $¢ Amount $¢ Total Sum (Excluding GST) The dissection amounts shown above shall be exclusive of any Goods and Services Tax whether levied on inputs to the work under the Contract or on the work under the Contract. Any such Goods and Services Tax costs so levied shall be to the account of the Corporation. Tenderer Signature of Tenderer Date of Tender ........................................................ ............................................................................. ........................................................ Name ................................................................. ........................................................ 52 GOULBURN VALLEY REGION WATER CORPORATION Contract insert contract number insert contract title Schedule 4 - Schedule of Rates (Note this schedule is only required where the works are a Schedule of Rates contract – if not delete this schedule – delete this text) The Schedule of Rates shall be used for tender assessment, to assess progress of the works, for the determination of progress payments and for the assessment of variation claims. Tenderers shall make all allowances in the rates for all temporary facilities, site establishment, equipment servicing and maintenance, power, fuel and other consumables, transport fees, overheads, complying with the General Conditions of Contract, the specification, insurances, fees and profit. Item Description Unit Quantity Unit Price $¢ Amount $¢ Total Sum (Excluding GST) Tenderer Signature of Tenderer Date of Tender ........................................................ ............................................................................. ........................................................ Name ................................................................. ........................................................ 53 GOULBURN VALLEY REGION WATER CORPORATION Contract insert contract number insert contract title Schedule 5 – Personnel, Plant & Equipment The Tenderer shall provide a list of the resources to be used on this contract and the working rate (and, where applicable, the standby rate) sought for the use of the resource on any additional works requested and approved by the Superintendent including dayworks. The rates shall include all overhead administrative costs, all operator costs including site allowances, mobilisation costs, fuel, servicing, profits and taxes etc., but excluding supervision costs for the resource and excluding GST. Tenderers are also required to provide the charge (expressed as a percentage of cost) to be applied to the actual cost of materials, services and subcontract work to cover the Contractor's overheads, administrative costs, site supervision, establishment costs, attendance, taxes and profit. The rates nominated below will be used by the Superintendent to make evaluations under the General Conditions of Contract. Personnel The unit rates of personnel and labour are to be inclusive of all costs to the Principal irrespective of the number of hours worked each week. Where appropriate, rates shall include the cost of vehicles, travelling and accommodation. This Schedule is for the purpose of assessing variations and also for use if daywork is ordered by the Superintendent. Labour rates per man-hour shall include the supply of all necessary tools and consumables incidental to the work and a percentage on cost for overheads and profit. Normal Overtime Classification Hourly Hourly Rate Rate Tenderer Signature of Tenderer Date of Tender ........................................................ ............................................................................. ........................................................ Name ................................................................. ........................................................ 54 GOULBURN VALLEY REGION WATER CORPORATION Contract insert contract number insert contract title Plant The provision for the mobilisation of plant to site is to be included in the equipment hourly rate. Rates shall include all costs including mobilisation costs, fuel, servicing, profits and taxes excluding GST. Payment for equipment on daywork will be based on actual equipment working hours. Item Description (ie. make, model, HP, capacity etc.) Normal Hourly Rate Overtime Hourly Rate Materials, Services and Sub-Contracts Tenderers are to provide the percentage to be added to the actual cost of materials and services supplied for dayworks to cover overheads and profits. Materials ........................................................... % Services ........................................................... % Sub-Contracts ........................................................... % Tenderer Signature of Tenderer Date of Tender ........................................................ ............................................................................. ........................................................ Name ................................................................. ........................................................ 55 GOULBURN VALLEY REGION WATER CORPORATION Contract insert contract number insert contract title Schedule 6 - Relevant Experience The Tenderer is to list comparable works or significant works completed within the last five years. Ref No. Project and Principal Value of Project Value of Works to Complete Scheduled Completion Date 1. 2. 3. 4. 5. 6. Tenderer Signature of Tenderer Date of Tender ........................................................ ............................................................................. ........................................................ Name ................................................................. ........................................................ 56 GOULBURN VALLEY REGION WATER CORPORATION Contract insert contract number insert contract title Schedule 7 - Management/Supervisory Personnel The Tenderer is to list management and supervisory personnel. Personnel Name Experience & Qualifications Contract Commitment (FT/PT Percentage) 1. Project Manager 2. Site Manager / Foreman 3. Quality Management Representative 4. Environmental Management Representative 5. First Aid Officer Tenderer Signature of Tenderer Date of Tender ........................................................ ............................................................................. ........................................................ Name ................................................................. ........................................................ 57 GOULBURN VALLEY REGION WATER CORPORATION Contract insert contract number insert contract title Schedule 8 - Sub-Contractors The Tenderer is required to provide the names of the firms to whom the tenderer, if its tender is successful, would subcontract works or supply materials required for the works. The tenderer will be deemed to have satisfied itself that each of the proposed subcontractors and suppliers is fully competent to execute those portions of the work that would be allocated to them, in full compliance with the Contract. If the tender is subsequently accepted by Goulburn Valley Water such acceptance will not constitute approval by the Superintendent pursuant to the General Conditions of Contract. The tenderer acknowledges that any change or addition to this list that the Contractor may desire will be subject to the prior approval of the Superintendent. Component of Work to be Sub-Contracted Tenderer Signature of Tenderer Date of Tender Name(s) and Address(es) of Sub-Contractors for Each Component to be Sub-Contracted ........................................................ ............................................................................. ........................................................ Name ................................................................. ........................................................ 58 GOULBURN VALLEY REGION WATER CORPORATION Contract insert contract number insert contract title Schedule 9 - Materials and Suppliers The Tenderer is to advise the proposed materials and suppliers to be used for the projects. Name(s) and Address(es) of Supplier for each material Proposed Material Tenderer Signature of Tenderer Date of Tender ........................................................ ............................................................................. ........................................................ Name ................................................................. ........................................................ 59 GOULBURN VALLEY REGION WATER CORPORATION Contract insert contract number insert contract title Schedule 10 - Program of Works Item Description 1 2 3 4 5 6 7 8 9 10 Week 11 12 13 14 15 16 17 18 19 20 The Tenderer shall provide a program of works. The Program of Works submitted with the tender shall conform to all requirements of the Specification. Tenderer Signature of Tenderer Date of Tender ........................................................ ............................................................................. ........................................................ Name ................................................................. ........................................................ 60 GOULBURN VALLEY REGION WATER CORPORATION Contract insert contract number insert contract title Schedule 11 - Tenderer OH&S Questionnaire This questionnaire forms part of the Corporation’s tender evaluation, which must be completed by tenderers and submitted with a tender offer. GVW has a responsibility to ensure contractors that perform works can adequately manage their own health and safety. This questionnaire provides us with an overview of your organisation’s OHS management system. The answers to the questionnaire will be reviewed by GVW as part of the tender evaluation. Answers must be correct and able to be verified. Tenderers may be required to verify their responses before or at the tender interview. Yes 1. Do you have a documented health and safety policy? If yes provide a copy 2. Do you have an OH&S manual or plan? If yes provide a copy of contents page(s). 3. Are health and safety responsibilities clearly identified for all levels of staff? 4. Have safe operating procedures or specific safety instructions been prepared relevant to your operations? If yes, provide a summary listing of procedures or instructions. 5. Do you have any permit to work systems? If yes, provide examples of permits: 6. Do you have a documented incident investigation procedure? If yes provide a copy of a standard incident report form. 7. Are there procedures for maintaining, inspecting and assessing the hazards of plant operated/owned by the company? If yes provide copies of sample procedures 8. Are there procedures for storing and handling hazardous substances? If yes provide copies of sample procedures 9. Are there procedures for identifying, assessing and controlling risks associated with manual handling? If yes provide copies of sample procedures No 10. Is a record maintained of all training and induction programs undertaken for employees in your company? If yes, provide examples of safety training records 11. Are regular health and safety inspections at worksites undertaken? If Yes, provide details of when and by whom: 12. Are standard workplace inspection checklists used to conduct health and safety inspections? If yes, provide an example: 13. Are toolbox meetings regularly held where health and safety issues may be raised and discussed 14. Has the company ever been convicted of an offence by the Victorian WorkCover Authority or an Authority in another State? If yes provide details. Tenderer Signature of Tenderer Date of Tender ........................................................ ............................................................................. ........................................................ Name ................................................................. ........................................................ 61 N/A GOULBURN VALLEY REGION WATER CORPORATION Contract insert contract number insert contract title Schedule 12 - Receipt of Addenda The Tenderer is to acknowledge that it received the addenda listed below during the tender period and that the tender has been prepared having regard to these addenda. Addenda No. Brief Description (e.g. Specification page No., clause No., Schedule No.) Date Received This Tender has been prepared having regard to the addenda listed above. Tenderer Signature of Tenderer Date of Tender ........................................................ ............................................................................. ........................................................ Name ................................................................. ........................................................ 62 GOULBURN VALLEY REGION WATER CORPORATION Contract insert contract number insert contract title Schedule 13 - Tender Conformance The Tenderer is to signify whether or not its Tender conforms to the requirements of the Tender documents by striking out below ** that which is not applicable. This Tender ** does / does not ** conform. Should the Tender not conform with the requirements of the Tender Documents, the Tenderer shall list below all areas of non-conformance and the reasons for such non-conformance. Specification Clause Details of Non-Conformance …………………………….. ………………………………………………………………………………………………………. ……………………………… ……………………………………………………………………………………………………….. ……………………………… ……………………………………………………………………………………………………….. ……………………………… ………………………………………………………………………………………………………... ……………………………… ………………………………………………………………………………………………………… ……………………………… ………………………………………………………………………………………………………… ……………………………… ………………………………………………………………………………………………………… Tenderer Signature of Tenderer Date of Tender ........................................................ ............................................................................. ........................................................ Name ................................................................. ........................................................ 63 GOULBURN VALLEY REGION WATER CORPORATION Contract insert contract number insert contract title Schedule 14 - Recipient Created Tax Invoice Agreement Supplier Details Supplier Name: Supplier ABN: Supplier Address: ................................................................................................................... ................................................................................................................... ................................................................................................................... Recipient Details Recipient Name: Goulburn Valley Water Recipient ABN: 84 578 076 056 Recipient Address: PO Box 185, Shepparton Vic 3632 Supplier Authorisation We the supplier as listed above hereby authorise Goulburn Valley Water to issue Recipient Created Tax Invoices on our behalf for any progress claims in connection with any of our contracts with Goulburn Valley Water. We the supplier will not issue Tax Invoices in respect of amounts invoiced by Goulburn Valley Water on our behalf. We are registered for GST when signing this agreement and will notify Goulburn Valley Water should we cease to be registered. Signed on behalf of the supplier .................................................................. Authorised Officer Recipient Statement Goulburn Valley Water acknowledges that it is registered for GST when it has entered into this agreement. We will notify the supplier if we cease to satisfy any of the requirements to issue Recipient Created Tax Invoices in accordance with the GST Ruling on Recipient Created Tax Invoices (GSTR 2000/10) Signed on behalf of Goulburn Valley Water ............................................................. Authorised Officer Tenderer Signature of Tenderer Date of Tender ........................................................ ............................................................................. ........................................................ Name ................................................................. ........................................................ 64 GOULBURN VALLEY REGION WATER CORPORATION Contract insert contract number insert contract title Schedule 15 - Victorian Industry Participation Policy (VIPP) Statement (Note this schedule “Victorian Industry Participation Policy” is to deleted if the Victorian Government’s contribution the contract is estimated to be less than $1million – delete this text) Tenderers are required to demonstrate that they have considered the industry development implications of their tender according to the Victorian Government’s Industry Participation Policy. 1. Value Added Activity Tenderers should specify the level of local (Victorian/Australian/NZ) value added activity, expressed as a percentage of the overall contract price. (A definition of value added is provided in the “Guidelines for Preparation of VIPP Statements”). Tenderer’s Response 2. Employment Tenderers should provide details of actual new employment opportunities to be created and the proportion of these opportunities, which will be filled by people from the local communities involved. Tenderer’s Response 3. Skills and Technology Transfer Tenderers should identify opportunities for increasing the skills of Victorians and Australians and the potential to undertake the innovation, research and development of technology. Tenderer’s Response Tenderer Signature of Tenderer Date of Tender ........................................................ ............................................................................. ........................................................ Name ................................................................. ........................................................ 65 GOULBURN VALLEY REGION WATER CORPORATION Contract insert contract number insert contract title Tenderers are also to nominate the method of assessment to ensure that contractor compliance with the VIPP Statement is achieved during the contract duration. The method of assessment should set out how and how often the achievement of local industry participation levels would be monitored and reported. VIPP Performance Standards (Note: these are indicative only of the methodology to be applied. A timeline and measured milestones may be more appropriate in some cases). Benefit Outcome Measure The final method of assessment will be negotiated and the approved method will be included in the successful tenderers contract. This may be used by the DSRD for future VIPP compliance auditing. Tenderer Signature of Tenderer Date of Tender ........................................................ ............................................................................. ........................................................ Name ................................................................. ........................................................ 66 GOULBURN VALLEY REGION WATER CORPORATION Standard Conditions for Goulburn Valley Water Construction Contracts Client Handbook for Consultants ITEM 10 OCCUPATIONAL HEALTH & SAFETY The following section includes clauses relating to OHS requirements of tenderers to be incorporated into specification and tender documents. The requirements should then be specifically incorporated into the contract. This can be easily achieved by a suitable clause in the contract that references the OHS specification requirements. Also included are guidelines for the preparation of risk assessments and health and safety plans which are to be included in the tender documents. Guidelines for the review of the risk assessments, health and safety plans. Tenderer OH & S questionnaires and sample OH & S site inspection checklist are provided for the Consultants information. 67 GOULBURN VALLEY REGION WATER CORPORATION Standard Conditions for Goulburn Valley Water Construction Contracts Client Handbook for Consultants Model OHS Specification and Tender Document Requirements Clauses for All Contracts (Cut and paste the relevant clauses into the contract documentation – delete this text) Clause 1 General Occupational Health & Safety Requirements The Principal is obliged to provide and maintain, so far as is practicable, a working environment for its employees and members of the public, that is safe and without risk to health. As a condition of this Contract, the Principal requires that any Contractors or subcontractors that may be engaged to perform works on its behalf shall at all times identify and exercise all necessary precautions for the health and safety of all persons including Contractor employees, the Principal’s employees and members of the public who may be affected by the services. The Contractor shall inform itself of all occupational health and safety policies, procedures or measures implemented or adopted by the Principal and/or the occupiers of any premises at or within which the Contractor will perform Works under this Contract. The Contractor shall comply with all such policies, procedures or measures; and in the event of any inconsistency, will comply with such procedures or measures as they produce the highest level of health and safety. For Principal managed work sites the Contractor’s occupational health and safety representative must be inducted to the specific work site by the Principal. The Principal provided induction training shall be integrated into the Contractor’s health and safety documentation prior to commencing the Works under the Contract. The Contractor shall forthwith comply with any and all directions by the Principal relating to occupational health and safety. All Contractors and their employees must have a Construction Induction Card issued by WorkSafe. Clause 2 Legislative Compliance The Contractor shall comply with and ensure that its employees, subcontractors and agents comply with any Acts, regulations, local laws and by-laws, Codes of Practice, Australian Standards and the Principal’s relevant occupational health and safety policies and procedures which are in any way applicable to this Contract or the performance of the Works under this Contract. Clause 3 Contractor Health and Safety Co-ordination Plan (Delete this clause if Works are not Major Works – and this text) The Contractor, must as a minimum requirement, demonstrate compliance with all duties of an employer specified in the Occupational Health and Safety Act 2004. Prior to commencing the Works under the Contract on site the Contractor shall submit to the Superintendent, for approval, a Health and Safety Co-ordination Plan specific to the Works under the Contract. The Health and Safety Co-ordination Plan shall consider and respond to the specific occupational health and safety hazards and issues relevant to the Works under the Contract and shall document the systems and methods to be implemented for the term of the Contract. The Contractor shall complete the Health and Safety Co-ordination Plan in conformance with 68 GOULBURN VALLEY REGION WATER CORPORATION Standard Conditions for Goulburn Valley Water Construction Contracts Client Handbook for Consultants requirements set out in the Principal Guidelines for Preparing Health and Safety Co-ordination Plans (Appendix XX). The Contractor’s Health and Safety Co-ordination Plan shall include as a minimum the following: a) Company OHS policy and objectives; b) Organisation structure & responsibilities - list of the names, positions and responsibilities of all persons whom will have specific responsibilities for health and safety; c) Arrangements for the co-ordination of the health and safety of persons engaged to perform construction work; d) Arrangements for Incident Management; e) Site Safety Rules, with the arrangements for ensuring that all persons at the workplace are informed of the rules; f) Risk Assessments, Safe Work Method Statements, practices and procedures; g) OHS Training and Induction; h) OHS Auditing and Inspection procedures; i) OHS Consultation procedures; j) Arrangements for preventing and responding to bullying in the workplace; k) Arrangements for the Plan to be monitored, maintained and kept up to date; and l) OHS Performance monitoring. A copy of the Health and Safety Co-ordination Plan and of any revisions to the Plan are to be available at site for the duration of the Works under the Contract. The Health and Safety Co-ordination Plan must available for inspection by all persons involved in the Work under the Contract. Clause 4 Risk Assessment The Contractor shall prepare and submit Risk Assessments prior to commencing the Works under the Contract. The Principal’s Job Safety and Environmental Assessment (JSEA) Form (or similar) shall be used to record the risk assessment and risk control methods to be employed by the Contractor. The Contractor shall prepare and submit Safe Work Method Statements for all high risk construction Works under the Contract. The completed Risk Assessment and Safe Work Method Statements shall be submitted to the Superintendent for approval prior to commencement of Works under the Contract. A preliminary risk assessment of the Works has identified the following possible risks associated with the Works: Project Team is to compile a list of potential risks (add additional risks that are identified and delete those risks that do not apply – and this text) Manual handling; High Risk Construction works; o Excavations – trenches and shafts; o Working near overhead and underground services; 69 GOULBURN VALLEY REGION WATER CORPORATION Standard Conditions for Goulburn Valley Water Construction Contracts Client Handbook for Consultants Working with asbestos; Working on or near roadways; Working on or near railways; Hot works activities; Works in a confined space; Working at height; Powered mobile plant; Works in, over or adjacent to water or other liquids where there is a risk of drowning; o Works involving diving; o Works involving demolition; Exposure to hazardous substances; Ultra violet radiation and sun; Working with electrical tools; Provision of sanitary facilities; First aid management; Public access; o o o o o o o o The Contractor shall include assessment of these risks when completing the Risk Assessments and Safe Work Method Statements for the Works under the Contract. The Principal’s requirements for minimising risks associated with exposure to ultra violet radiation when working in sunlight are that all Contractor employees, including subcontractors, must wear long sleeved shirts with a collar and long trousers. The Contractor shall also given consideration to providing broad brimmed hats, brim attachments or neck flaps for hard hats, sunglasses and sunscreen. Note - The specific requirements of the Principal related to the management of the preliminary risks identified that are different then that would be normally expected by WorkSafe shall be incorporated into the tender/contract documentation in the way of appendices. (Delete this text) Clause 5 Incident Notification If the Contractor is required by the section 38(1) of the Occupational Health and Safety Act 2004 and or by any other regulations to give any notice of an accident occurring during the performance by the Contractor of Works under the Contract, the Contractor shall at the same time or as soon thereafter as possible in the circumstances give a copy of the notice to the Principal. The Contractor must promptly notify the Superintendent and Principal of any accident, injury, property or environmental damage which occurs during the performance of the Works under the Contract. All lost time incidents shall be immediately notified to the Principal. The Contractor must and within three days of any such incident provide a report giving complete details of the incident, including results of investigations into its cause, and any recommendations or strategies for prevention in the future. This requirement extends to the provision of information and documentation provided to the contractor in relation to the Works under the Contract by another statutory, government or municipal authority. Clause 6 Non Compliance If during the performance of Works under the Contract the Superintendent or the Principal informs the Contractor that it is the opinion of the Superintendent or the Principal that the Contractor is: 70 GOULBURN VALLEY REGION WATER CORPORATION Standard Conditions for Goulburn Valley Water Construction Contracts Client Handbook for Consultants not conducting the Work in compliance with the Contractor’s Health and Safety Co-ordination Plan, health and safety management procedures, relevant legislation or health and safety procedures provided by the Principal from time to time, or conducting the Work in such a way as to endanger the health and safety of Contractors employees or the Principal’s or its Contractors’ and subcontractors’ employees, plant, equipment or materials, the Contractor shall promptly remedy that breach of health and safety. Clause 7 Signage (Delete this clause if works are not Major Works – and this text) The Contractor must place signs that are clearly visible from the outside of the Work site that show the name and contact numbers of the Contractor. These signs are to remain for the duration of the Works under the Contract. Clause 8 Visitors Visitors to the Work site, including persons temporarily at the Work site to deliver plant, supplies or materials, shall not be required by the Principal to have a Construction Induction Card or undergo an induction if they are accompanied at all times by a person who has received induction training specific to the Works under the Contract. The Contractor shall keep a register of all visitors which includes the date and time, the visitor’s name, the company they represent, the purpose for the visit and the accompanying person. 71 GOULBURN VALLEY REGION WATER CORPORATION Standard Conditions for Goulburn Valley Water Construction Contracts Client Handbook for Consultants Contractor Information to Assist Them to Complete Risk Assessments and Safe Work Method Statements Contractor Information Completing Risk Assessments / Job Safety & Environmental Assessment (JSEA’s) and Safe Work Method Statements Rev 2 June 2009 Job Safety & Environment Risk Assessment Forms must be completed by the contractor and submitted to GVW for approval prior to commencement of works. Assessing Risks Each major task or activity must be assessed for hazards. Each hazard is then assessed for risk and classified using the risk matrix displayed on the JSEA form or on the contractors own risk assessment tool. If their own risk assessment tool is used, as a minimum it must include the information as GVW’s JSEA form. An example JSEA is included for guidance, contractors must ensure that Important Notes: All risk assessments are required to be reviewed by GVW or the Superintendents Representative including risk assessments completed throughout the works. Safe Work Method Statements / Safe Operating Procedures Where risks are identified you may include detail in the control column of the JSEA or develop a Safe Work Method Statements which outlines the works with detail on methods of controlling the risks (as per those identified on the JSEA). 72 EXAMPLE JSEA FORM 73 74 Contractor Information to Assist in Preparing Health and Safety Plans CONTRACTOR INFORMATION GUIDELINES FOR PREPARING HEALTH AND SAFETY PLANS Rev 2 June 2009 Introduction This document provides information to assist contractors when preparing a Site Specific Health and Safety Management Plan. Prior to commencement of contract works you must submit the Plan which details the health and safety systems and procedures applying during the term of the contract. The Health and Safety Plan will be reviewed by GVW prior to commencement of the contract and will be subject to approval by GVW. The Plan will also be audited by GVW or its nominated representative during the works. 1. Contract Description A brief description of the scope of work which must include as a minimum the following details: Summary of major activities and types of work to be performed. List tasks or specialist procedures requiring special consideration from a health and safety perspective eg: 2. - Presence of public - Traffic management - Work restrictions (work times, confined spaces) - Exposure to hazards (noise, dust, elevated heights) Contract OHS Structure and System You must outline your management structure and responsibilities applicable to OHS which should include as a minimum the following information: A copy of your Company health and safety policy, (this to be displayed at worksites). An outline of your OH&S management structure, i.e. names and/or positions of those with specific health and safety responsibilities. Position and/or name of senior person who will liaise with GVW on health and safety matters. 75 3. Contract Induction and Safety Training You must provide GVW with information on health and safety induction and any other relevant safety training relevant to the contract works which should include as a minimum the following information: An outline of the induction process for employees and subcontractors. Sample register of personnel who have satisfactorily completed the contract induction. Provide a register of names and/or positions of contract employees with authorisations, permits, competency certificates, licences etc who may be required to supervise or undertake specialist work activity. 4. Safe Work Practices and Procedures Safe Work Method Instructions / Statements or procedures must be developed. Where possible existing health and safety company procedures should be used. However, contract specific safe work procedures may need to be developed. These may be identified when undertaking the Risk Assessment. The following information must be provided: A list and copies of company safe work procedures / instructions relevant to the contract. Detail site operations which will be subject to permit to work systems. 5. Job Safety and Environmental Assessment Risk Assessment is an integral part of the Health and Safety Plan and considers the following: Identifies hazards associated with contract tasks and activities. Determines the level of risk. Establishes appropriate risk control measures. Each major task or activity must be assessed for hazards. Each hazard is then assessed for risk and classified using the risk matrix displayed on the JSEA form (available from GVW) or on the contractors own risk assessment tool. If their own risk assessment tool is used, as a minimum it must include the information as GVW’s JSEA form. Additional risk assessments may be undertaken during the course of the contract as required but these, where possible, must be reviewed by GVW or the Superintendent. 6. Workplace Health and Safety Inspections The Health and Safety Plan should outline the how the work site shall be inspected which should include as a minimum the following information: 7. - Checklists to be used. - Frequency of inspections. - Team members involved. - Actioning of inspection findings Health and Safety Consultation Information must be provided on how the contractor will resolve any health and safety issues that arise during the works 76 8. Emergency Procedures There is the potential for a range of emergency situations to occur both on-site and off-site in relation to contract works. These situations need to be identified and emergency procedures developed and made known to all persons working on the site. The following information should be documented: 9. Emergency procedures including relevant telephone numbers for contract. Register of emergency equipment and locations i.e. first aid equipment, fire extinguishers. Register of current qualified First Aiders. Incident Recording & Investigation All incidents involving personal injury, medical treatment or property damage must be recorded and investigated. The following should be provided in the plan: Information of incident reporting and investigation system and procedures. 77 Information to Assist with Reviewing Contractor Risk Assessments Background GVW is responsible for reviewing Risk Assessments to ensure that: the Contractor has identified hazards associated with activities; the Contractor has indicated control measures which have considered the degree of risk associated with the task Step 1 - Identify Tasks Check works have been separated into significant tasks or activities. Tasks may be identified by the likely hazards associated with each task. Hazards may arise as a result of: the nature and type of services performed; the location of the work; materials, chemicals or equipment used; the time of the work; proximity to the public or other Contractors; the work environment. Step 2 – Identify Hazards Contractors shall identify the range of hazards associated with each task. A hazard can be defined as the potential to cause injury or illness to one or more people. When determining hazards the hazard types below may be considered: Physical Hazards, eg. noise, plant related hazards, working at height, manual handling, ergonomic, traffic hazards, collapse, falling objects etc; Chemical Hazards, eg. inhalation, skin contact with chemicals, ingestion of chemicals; Electrical Hazards, eg. direct electrocution, contact with overhead or underground cables; Biological Hazards, eg infection, needle stick injury, handling of wastes; Radiation Hazards, eg. UV light, lasers; Psychological, eg. Workplace conditions leading to stress. The attached Hazard Identification and Control Table lists a variety of hazards and examples of control measures which may be considered. This hazard list is not exhaustive and other controls may be considered for the hazards listed. 78 Step 3 - Assess the Risk Risk is defined as the probability of a hazard causing injury or illness. Risk is a combination of the length and time of exposure to the hazard and the likelihood of the hazard being realised. The hazards should be assessed according to the risk matrix displayed on the GVW Job Safety & Environmental Assessment form (or similar). A primary goal shall be to eliminate Extreme, Very High and High risks associated with the contract and should be a major focus of the Risk Assessment. Contractors should detail risk control measures which adequately address all identified risks. When determining risk control strategies, the hierarchy of controls should be considered. The assignment of risk rating may take into consideration: Past accident/incident WorkCover claims data; reports; Personal experience and professional judgement. Industry experience and data; Step 4 - Control Measures GVW must ensure that the Contractor has identified suitable control measures for each hazard. In some cases the Contractor will have a greater understanding of the technical requirements of the works and in these cases GVW would not be expected to make a judgement as to whether the control strategy chosen by the Contractor is the best available safe system of work. Where the specific task does not involve specialty technical expertise, GVW should provide feedback to the Contractor if they feel the identified control measure is in any way inadequate. Further guidance regarding the selection of the most suitable control methods is provided in Appendix 2, Document 3 Risk Assessment Form. In summary the selection of suitable control measures should take into consideration: Level of risk Hierarchy of controls Practicability of implementation 79 GOULBURN VALLEY REGION WATER CORPORATION Standard Conditions for Goulburn Valley Water Construction Contracts Client Handbook for Consultants Hazard Identification and Control Table The following table provides examples of control measures for a range of generic hazards. These examples are provided as a guide only and important site specific factors must also be considered. Note also that this table of examples does not include all possible hazards. Hazard Possible Cause Control Measure 1. Traffic Hazards 1.1 Trucks entering, exiting a work site 1.2 Working in close proximity to roads 2.2 Use of heavy hand held tools eg grass slasher 2.3 Handling of heavy objects 3.1 3.2 Hot Materials Fire in the Workplace 3.3 Exposure to sun 4.1 4.2 Faulty electric leads and tools No earth leakage detectors 4.3 4.4 4.5 4.6 Electric leads on ground Electrical leads in damp areas Electric leads tied to metal rails Faulty plant not isolated Use of traffic signalmen Installation of temporary traffic signals Use of Safety Signs Speed restriction signs displayed and enforced Use of witches hats or temporary barriers to cordon off sections of road Closure of road Use of Safety Signs Speed restriction signs displayed and enforced Use of support harness Limits on duration of use Provide mechanical aids Redesign object or task Provide appropriate protective clothing and training Keep workplace clear of waste materials Issue of hot work permit Remove flammable materials or store correctly Provide adequate fire fighting equipment Employee fire fighting training Eliminate ignition sources from flammable atmospheres Provide protective clothing and sunscreen Reduce exposure time Tools and leads inspected and tagged Residual current devices in all circuits Residual current devices tested regularly Electrical leads kept elevated and clear of work areas All electric leads kept dry All electric leads are kept insulated Ensure permit to work system followed Lock-out and equipment tag procedure 4.7 Contact with underground or overhead cables 2. Manual Handling 3. Contact with Heat 4. Contact with Electricity 80 Location of services to be established Overhead cables to be protected Services to be isolated when working in proximity Establish safe clearance distances and use of spotters GOULBURN VALLEY REGION WATER CORPORATION Standard Conditions for Goulburn Valley Water Construction Contracts Client Handbook for Consultants Hazard 5. Exposure to Noise Possible Cause 5.1 Plant and equipment not silenced 5.2 Not wearing appropriate protection 5.3 Excessive exposure time to noisy areas Control Measure Fit noise suppression to noisy plant and equipment All personnel to wear appropriate PPE (hearing protectors) Regulate employee exposure to noise 6. Contact with High Pressure 6.1 6.2 6.3 6.4 6.5 7.1 7.2 7.3 7.4 7.5 Burst air lines Hoses becoming uncoupled Using compressed air to clean clothing Improper handling of gas cylinders Defective pressure gauges Incorrect handling procedures Lack of information Not wearing appropriate PPE Incorrect storage Elevated exposure levels 8.1 8.2 8.3 8.4 Exposure to arc welding Not wearing appropriate PPE Exposure during radiography operations Exposure to lasers 9.Struck Against 8.5 9.4 Exposure to sun Protruding objects in access routes 10. Struck By Object 9.5 9.6 10.1 Not wearing appropriate PPE Personnel running in the workplace Objects falling from work platforms 10.2 Debris from grinding operations 10.3 Wind blown particles Air hoses in good condition and regularly inspected All hose couplings fitted with pins or chains Prohibit and instruct employees on dangers Cylinders stored upright and secured All pressure gauges inspected regularly for defects All employees trained in MSDS requirements Review Material Safety Data Sheet and assess risks All personnel provided with appropriate PPE Hazardous substances stored and labelled correctly Provide mechanical ventilation All personnel provided with appropriate PPE Welding operations shielded All personnel wear appropriate PPE Correct procedures developed and followed Regular equipment check Follow documented safe work procedure for laser Provide protective clothing and sunscreen Protruding objects are removed or marked Provide appropriate PPE (hard hat, safety boots) Provide appropriate PPE & training Personnel exercise restraint and walk All work platforms fitted with toe-boards Fence off areas below to prevent access Materials stacked securely All personnel wear appropriate PPE (hard hats) Secure loose objects to structure Personnel wear appropriate PPE Shield grinding operations All personnel wear appropriate PPE 10.4 Loads slung from cranes 7. Contact with Chemicals 8. Contact with Radiation Loads not slung over personnel Taglines are used to prevent loads swinging Loads slung correctly 81 GOULBURN VALLEY REGION WATER CORPORATION Standard Conditions for Goulburn Valley Water Construction Contracts Client Handbook for Consultants Hazard 11. Fall from Height Possible Cause 11.1 No handrails 11.2 Working outside handrails 11.3 Floor penetrations not covered 11.4 Ladders not secured 11.5 12.1 12.2 12.3 12.4 12.5 13.1 Unsafe area Access routes obstructed by materials Leads and hoses across access routes Slippery surfaces Safety footwear not appropriate Poor visibility Operating plant 13.2 Moving plant 14. Overstress 13.3 13.4 13.5 14.1 Moving loads Loads tipping or swinging Materials being positioned SWL exceeded during lifting operations 15. Ergonomic Hazards 14.2 15.1 Sprains and strains Poor work posture 15.2 Use of excessive force 15.3 Repetitive movements 16.Asbestos Hazards 16.1 Accidental disturbance or contact 17.Biological Hazards 17.1 Needlestick injury 12.Slips and Falls 13.Caught Between 82 Control Measure All work platforms have secure handrails Persons wear full fall arrest type harness All floor penetrations covered or barricaded All ladders secured to prevent movement Ladders to extend at least 1m above landings Tag and fence to prevent access All access routes kept clear of materials and debris All leads kept clear of ground or covered All surfaces used for access kept dry and in good condition Personnel wear appropriate safety footwear Provide adequate lighting Guarding of rotating plant and hand tools Safe work procedures to be followed Provide roll over cage protection Pre-start daily safety inspection Personnel kept clear when operating plant Fit reverse alarms to plant and check operation All personnel kept clear during crane operations Load slings properly secured Safe Work Procedures for moving heavy loads Compliance with SWL and radius charts on cranes All lifting gear checked regularly All personnel trained in manual handling techniques Workstation to conform with ergonomic standards Seating to conform with ergonomic standards Training of employees Provide adequate task lighting Provide mechanical aids Modify workplace design Modify task requirements Job rotation Asbestos materials identified and labelled Asbestos materials removed from workplace Safe work procedures developed Provide appropriate waste disposal containers Provide employees with PPE Develop safe work procedures and train staff GOULBURN VALLEY REGION WATER CORPORATION Standard Conditions for Goulburn Valley Water Construction Contracts Client Handbook for Consultants Hazard 18. Excavation/ Trenching 19.Plant Overturn Possible Cause 17.2 Potential exposure to HIV, hepatitis 17.3 Potential exposure to legionella bacteria 18.1 Collapse of earth 18.2 18.3 18.4 19.1 19.2 Fall into excavation Asphyxiation Inadequate access to excavation Crane overturn Mobile plant overturn 83 Control Measure Develop safe work procedures and train staff Immunisation program Provide employees with PPE Implement microbial control procedures Shoring to be provided in accordance with Code of Practice Shoring to be inspected regularly Provide barricades around excavation Provide exhaust ventilation and test atmosphere Provide safe access by steps or ladders Cranes to be set up on solid ground and away from edge of excavation Plant to be fitted with roll over cage protection Safe work procedures developed GOULBURN VALLEY REGION WATER CORPORATION Standard Conditions for Goulburn Valley Water Construction Contracts Client Handbook for Consultants A Checklist for Project Officer Reviewing Tenderer OH & S Questionnaires GUIDELINES FOR REVIEW OF TENDER OHS MANAGEMENT SYSTEM QUESTIONNAIRE Use the checklist to review the completed questionnaire which establishes the level of competency of the tenderer with regard to health and safety. Review of Tenderer OHS Management System Questionnaire Project Name: Project reference Number: Company Name: Date review Completed: Person Reviewing Position of person reviewing Indicate in the following manner: Acceptable Not Acceptable N/A Not Applicable 84 GOULBURN VALLEY REGION WATER CORPORATION Standard Conditions for Goulburn Valley Water Construction Contracts Client Handbook for Consultants 1. Company Health and Safety Policy Provided 2. OHS Management System or Plan – Contents Pages Provided The company OHS Manual or Plan should include as a minimum: Occupational health and safety policy Management OH&S responsibilities General occupational health and safety procedures Safe work procedures relevant to the company operations Public safety procedures Induction and training procedures Issue resolution and OHS consultation mechanisms 3. Health and Safety Responsibilities Health and Safety responsibilities in the company should be documented and may comprise: OHS responsibility statements part of employee’s job description part of formal and informal performance appraisal Line managers and supervisors should be formally held accountable for health and safety performance of their employees. 4. Safe Work Procedures The tenderer should be able to demonstrate safe work procedures which: are relevant to company operations contain a description of the tasks and associated hazards outline control measures and methods to minimise health and safety risks make reference to any relevant Legislation, Codes of Practice or Australian Standards 5. Safe Work Permits Where relevant, the tenderer should be able to demonstrate safe work permits for the following types of work: Work in Confined Spaces (Confined Space Entry Permits) Hot Work (Hot Work Permit) Lockout permits (plant, electrical systems, steam) 6. Incident Reporting and Investigation Tenderers should be able to provide evidence of the following: incident report and investigation form 85 GOULBURN VALLEY REGION WATER CORPORATION Standard Conditions for Goulburn Valley Water Construction Contracts Client Handbook for Consultants evidence of completed investigation forms 86 GOULBURN VALLEY REGION WATER CORPORATION Standard Conditions for Goulburn Valley Water Construction Contracts Client Handbook for Consultants 7. Plant Safety The tenderer should have mechanisms in place to identify hazards, assess their risks and the implement control measures associated with plant. This may include: Completion of risk assessments. plant maintenance and inspection forms pre-start daily safety inspection forms for plant plant fault reporting system and forms 8. Hazardous Substances The tenderer should provide evidence demonstrating safe handling and storage of hazardous substances: manifest or register of chemicals used by the company Material Safety Data Sheets for chemicals used safe handling procedures, including personal protective equipment relevant training documentation 9. Manual Handling The tenderer should be able to demonstrate evidence of: Completion of risk assessments systems used to control manual handling risks (eg: lifting aids, work procedures) 10. Training Tenderer should be able to demonstrate evidence of: records of training and competencies of employees (licences, permits, certificates) records of any ‘on the job’ training tool box meetings conducted induction training program 11. Regular Inspections Tenderer should provide evidence of: workplace inspection schedules types of inspections undertaken 12. Standard Inspection Checklists Copies of inspection checklists used. 13. Hazard Reporting from tenderer Evidence may include: Toolbox meeting proformas or other documented hazard reporting procedures and forms. 14. Conviction of Health and Safety Offence If conviction reported, determine: 87 GOULBURN VALLEY REGION WATER CORPORATION Standard Conditions for Goulburn Valley Water Construction Contracts Client Handbook for Consultants nature and circumstances of incident corrective actions undertaken 88 GOULBURN VALLEY REGION WATER CORPORATION Standard Conditions for Goulburn Valley Water Construction Contracts Client Handbook for Consultants Tenderer OH & S Questionnaire Goulburn Valley Water Tenderer OHS - Management System Questionnaire This questionnaire forms part of GVW’s tender evaluation which must be completed by tenderers and submitted with a tender offer. GVW has a responsibility to ensure contractors that perform works can adequately manage their own health and safety. This questionnaire provides us with an overview of your organisation’s OHS management system. The answers to the questionnaire will be reviewed by GVW as part of the tender evaluation. Answers must be correct and able to be verified. Tenderers may be required to verify their responses before or at the tender interview. 89 GOULBURN VALLEY REGION WATER CORPORATION Standard Conditions for Goulburn Valley Water Construction Contracts Client Handbook for Consultants Project Name: Project Reference Number: Company Name: Date questionnaire completed: Person Completing Questionnaire Name: Position: Signed: Yes 1. Do you have a documented health and safety policy? If yes provide a copy 2. Do you have an OH&S manual or plan? If yes provide a copy of contents page(s). 3. Are health and safety responsibilities clearly identified for all levels of staff? 4. Have safe operating procedures or specific safety instructions been prepared relevant to your operations? If yes, provide a summary listing of procedures or instructions. 5. Do you have any permit to work systems? If Yes, provide examples of permits: 6. Do you have a documented incident investigation procedure? If Yes provide a copy of a standard incident report form. 7. Are there procedures for maintaining, inspecting and assessing the hazards of plant operated/owned by the company? If yes provide copies of sample procedures 8. Are there procedures for storing and handling hazardous substances? If yes provide copies of sample procedures 9. Are there procedures for identifying, assessing and controlling risks associated with manual handling? If yes provide copies of sample procedures 10. Is a record maintained of all training and induction programs undertaken for employees in your company? If Yes, provide examples of safety training records 11. Are regular health and safety inspections at worksites undertaken? f Yes, provide details of when and by whom: 12. Are standard workplace inspection checklists used to conduct health and safety inspections? If Yes, provide an example: 13. Are toolbox meetings regularly held where health and safety issues may be raised and discussed 14. Has the company ever been convicted of an offence by the Victorian WorkCover Authority or an Authority in another state. If yes provide details. 90 No N/A GOULBURN VALLEY REGION WATER CORPORATION Standard Conditions for Goulburn Valley Water Construction Contracts Client Handbook for Consultants 91 92 Goulburn Valley Water Major Projects OH&S Information and Requirements for Consultants This information has been developed to provide guidance to consultants when developing specifications and designs for GVW major projects. Some projects may require specialist OH&S advice and further assistance should be sought before specifications are submitted to GVW for review Plant and Equipment (pumps, motors, generators, mixers, etc, and associated pipework, valves, controls) Health and Safety Matter Designer, Manufacturer and Supplier Requirements Consultant Requirements General plant and equipment Hazards Identify and assess plant and equipment hazards at the design stage of the project. Where possible Eliminate risks Contractor and consultant to review equipment for safety. Ensure machine guarding is implemented as per the following hierarchy: Fixed guarding (where access is not generally required) Interlocked guarding (where access is required for cleaning or maintenance) Physical barrier which requires the use of a tool to remove. Presence sensing device Ensure devices are appropriately: Identified and labelled Readily and conveniently located Located so as to prevent unintentional activation Able to be locked in the off position to enable the disconnection of the power source. Emergency stops are coloured red Controls allowing operation during maintenance and cleaning have been assessed for risk a. Review design to ensure guarding is appropriate and that control hierarchy has been followed. b. Where a more effective guarding system is available but has not been used provide information to GVW for assessment. Reference: OH&S Regs 2007 – Section 3.5.3 Hazard identification. Machinery Guarding Reference: OH&S Regs 2007 – Section 3.5.4 Guarding Operators controls, emergency stops and warning devices Reference: OH&S Regs 2007 – Section 3.5.5 Operator’s Controls Review design to ensure plant hazards and risks are, where possible eliminated or reduced as far as possible Review design to ensure devices conform to legal requirements. Noise (Generated by plant and equipment and processes) Health and Safety Matter Designer, Manufacturer and Supplier Requirements 92 Consultant Requirements 93 General Noise Reference: OH&S Regs 2007 – Section 3.2.1 Designers, Section 3.2.2 Manufacturers Ensure noise for plant and equipment is identified and designed so that its noise level is as low as practicable Where noise may exceed 85dBA determine the sound level and provide a record of the level. Review the design of the plant and equipment to ensure that the noise level has been taken into account in the design of the project Review information and records of noise measurement and provide recommendations and feedback to GVW Where noise exceeds 85 dBA identify and assess effective measures to reduce noise to below 85dBA, may include: Isolation and Separation form the work area Sound insulations, noise barriers, mufflers Minimising vibration noise Hearing Protector Signs and Labels Where levels of noise may exceed 85dBA signage in the form of mandatory hearing protective signs (minimum size 300 x 450 mm) are required to be installed at all entrances to the area. Signs shall state the following: “HEARING PROTECTION MUST BE WORN IN THIS AREA” 93 Ensure mandatory hearing protection signage has been installed at all entrance to area where noise levels may exceed 85 dBA 94 Pressure Vessels (Air Compressors / Receivers, Air Dispersion Vessels,) Health and Safety Matter Designer, Manufacturer and Supplier Requirements Consultant Requirements Registration of Pressure Vessels Boiler and pressure vessels (other than gas cylinders) categorised as hazard level A, B or C are required to be registered with the WorkSafe Victoria. Ensure all relevant pressure vessels are registered with WorkSafe Victoria in the name of GVW Reference: OH&S Regs 2007 – Section 3.5.50 Registration of Plant Note: smaller pressure equipment ie. some air compressors and receivers are not required to be registered with WorkSafe Victoria. Australian Standard – AS3920 part 1 – Assurance of product quality, pressure equipment manufacture. Australian Standard – AS 3788:1996 Pressure equipment – in-service inspection Documentation in the form of a pressure vessel hazard identification and risk assessment is required to be completed for all boiler and pressure vessels. Ensure hazard identification and risk assessment documentation is provided to GVW. Labelling of Piping, Tanks, Containers and Chemical Storage Areas Health and Safety Matter Designer, Manufacturer and Supplier Requirements Consultant Requirements Pipe Labels Where possible ensure all pipes are labelled as per AS 1345. Review design and project specification to ensure all pipework is labelled with labelling as per AS 1345 Reference: Dangerous Goods (Storage and Handling) Regs 2000, Reg 441 – Marking of Pipework. Examples include: Australian Standard – AS1345, Identification of the contents of pipes conduits and ducts. Ensure all tanks / container are marked and labelled accordingly Reference: Dangerous Goods (Storage and Handling) Regs 2000, Reg 429 and 430 Ensure tanks are marked with the following: Identification of the contents (black lettering on white label, minimum label size 600 x 150mm). Maximum volume of the tank / container Maximum safe fill volume of the tank / container Where required relevant dangerous goods placarding including: outer warning placards and bulk placards Labelling of Chemical SDorage Areas Ensure a chemical storage area is marked with the following: Type of chemical storage area (eg. Sodium hypochlorite Ensure all chemical storage areas are marked and labelled accordingly Labelling / Marking of Tanks 94 95 Labelling of Piping, Tanks, Containers and Chemical Storage Areas Health and Safety Matter Reference: Dangerous Goods (Storage and Handling) Regs 2000, Reg 429 and 430 Safety Signs Generally Designer, Manufacturer and Supplier Requirements Ensure that explanatory safety signage is assessed and where required provided common examples include: Signage for personal protective clothing and equipment. Chlorine Gas Installations Reference: AS/NZS 2927 – The storage and Handling of Liquefied Chlorine gas. Consultant Requirements storage area, etc.) (black lettering on white label, minimum label size 600 x 150mm. Where required dangerous goods placarding including outer warning placards and package storage placards Liaise with GVW to identify relevant additional safety signage required for chemical storage areas. Danger – No Smoking, No Ignition Sources Signs Liaise with Goulburn Valley Water to ensure compliance with relevant signage requirements of AS/NZS 2927 – The storage and Handling of Liquefied Chlorine gas Ensure liaison with Goulburn Valley Water regarding the signage requirements of AS/NZS 2927 Chemical Storage Areas (Dangerous Goods Storage and Handling) Health and Safety Matter Designer, Manufacturer and Supplier Requirements Consultant Requirements Hazard Identification and Risk Assessment In consultation with Goulburn Valley Water’s representative hazards associated with the chemical storage area must be identified and assessed in regard to the following: Types and properties of chemicals (dangerous goods) to be used Storage and handling structures and plant Provide documentation to Goulburn Valley Water to confirm that chemical storage areas comply with relevant Dangerous Goods regulatory requirements and Australian Standards Reference: Dangerous Goods (Storage and 95 96 Chemical Storage Areas (Dangerous Goods Storage and Handling) Health and Safety Matter Designer, Manufacturer and Supplier Requirements Handling) Regs 2000, Reg 404, 405, 407. Safety Information Compliance with relevant Australian Standards Location and layout of storage and handling areas Adverse reaction and interaction between other chemicals stored at the location. The following safety information is required to be provided to Goulburn Valley Water representative for chemical storage areas: Relevant material safety data sheets Where required a dangerous goods manifest Ensure relevant standards have been reviewed and requirements incorporated into the design of the chemical storage areas including the following standards: Consultant Requirements Follow up with designer to ensure all safety information is provided and forward on to GVW Review to ensure designer has taken into account the relevant standards for the storage of various dangerous goods classes in the design of the dangerous goods storage area. AS 3780 – The storage and handling of corrosive substances AS/NZS 2927 – The storage and handling of liquefied chlorine gas. AS 4326 – The storage and handling of oxidising agents AS/NZS 4452 – The storage and handling of toxic substances. AS 2507 – The storage and handling of agricultural and veterinary chemicals AS/NZS 3833 – The storage and handling of mixed classes of dangerous goods in packages and intermediate bulk containers AS/NZS 1596 – The storage and handling of LG Gas Specific Control Requirements Dangerous Goods (Storage and Handling) Regs 2000, Division 3 & 4 Dangerous Goods Notification to WorkSafe Victoria Ensure specific requirements of the Dangerous Goods Regulations are reviewed and incorporated into the design of the project including: Ensure all relevant requirements are reviewed and incorporated into the design of the storage area. Security of premises Isolation and interaction with other substances, plant and processes The condition and repair of structures and plant Pipework Protection form impact Spill containment Adequate ventilation Control of ignition sources Equipment for the clean up of dangerous goods Fire protection equipment Where required dangerous goods notification shall be made on behalf of Goulburn Valley Water Dangerous Goods (Storage and 96 Ensure, where required that dangerous goods notification is made on behalf of Goulburn Valley Water to WorkSafe Victoria. 97 Chemical Storage Areas (Dangerous Goods Storage and Handling) Health and Safety Matter Designer, Manufacturer and Supplier Requirements Handling) Regs 2000, Reg 506 97 Consultant Requirements Fixed Platforms, Elevated Walkways, Stairways and Ladders Health and Safety Matter Designer, Manufacturer and Supplier Requirements Consultant Requirements General Ensure that an initial assessment is made to determine if works cannot be carried out at ground level this may include: Relocation of valves and equipment Installation of sight glasses, and measuring tape that can be read from the ground, etc. All guard railing to conform to AS 1657. Gates within guard railing span to be spring loaded and inward swinging (unable to be accidentally pushed open by person accessing platform). Inward swinging gates to be installed in positions where foreseeable periodic maintenance is required. Elevated platforms conforming to AS 1657 to be provided at the top of tanks and water towers. Elevated walkways to be provided with fully enclosed guard railing. Ladder landings to be provided every 6 metres (where possible, if not possible additional safety devices must be fitted) Internal ladder systems where the access is normally closed may be provided with retractable handgrip stanchions or where possible permanent stiles or handrails shall extend above the opening. Fixed rung ladders to be installed where foreseeable periodic maintenance is required. Ladder cages to be fitted to all ladders in excess of 6 metres in height (some exception for certain pump stations where rescue access is required). Where possible stairways shall be installed in preference to step ladders. Where Step ladders are proposed these shall be discussed with Goulburn Valley Water. Ensure an initial assessment is carried out and feedback is provided to Goulburn Valley Water on the outcome of the assessment. Access Hatches and openings A review design drawing to ensure that AS 1657 is being complied with fully. Where Fixed Fall Prevention Structures cannot be Implemented. I.e. guard railing, elevated walkways, ladder, stairways Placement of Plant and Equipment Elevated Walkways and Platforms including Guard Railing Reference: AS 1657 – Fixed Platforms, walkways, stairways and ladders – design, construction and installation. Ladders and Landings Reference: AS 1657 – Fixed Platforms, walkways, stairways and ladders – design, construction and installation. Where possible suitable guard railing is required around access hatches. An inward swinging gate shall be provided for side or through access to the ladder. Identify and assess the fall hazard and determine the safest method for working at height. Consult with Goulburn Valley Water and their representative to determine what type of fall prevention or protection method can be installed. Ensure, where possible, all items of plant and equipment required to be accessed by employees when working at height is provided inside the elevated work area. 98 Review design drawings to ensure that AS 1657 is being complied with fully. A review design drawing to ensure that AS 1657 is being complied with fully. A review design drawing to ensure that AS 1657 is being complied with fully. A review design drawing to ensure that AS 1657 is being complied with fully. Safe Access and Egress Health and Safety Matter Designer, Manufacturer and Supplier Requirements Consultant Requirements General Assess the requirement for safe access and egress by operators, visitors and contractors to carry out foreseeable tasks including: Maintenance Cleaning and inspection Ensure designer has assessed the provision for safe access and egress from and around plant and equipment and the site. Provide safe permanent access to ensure employees can safely access spill containment or bunded areas. Review design to ensure safe access is provided to spill containment areas. Reference: OH&S Act 2004, Section 21 and 23 Spill Containment and Chemical Storage Areas Reference: OH&S Act 2004, Section 21 and 23 Sampling and Inspection Points Reference: OH&S Act 2004, Section 21 and 23 Lighting Slips / Trips Reference: OH&S Act 2004, Section 21 and 23 For example: access over bunding may require a permanent step ladder. Provide made access to all chemical storage rooms where chemicals may be loaded into store or service Minimise steps when transferring chemical packages into stores through providing ramps Provide sufficient space to load chemical safely Provide sufficient space to decant mix and pour chemicals safely Where possible provide made access to routine sampling and plant and equipment inspection locations. Identify if routine sampling or inspection is required and assess how task can be performed safely by employees. Review design to ensure safe access to sampling and inspection points is provided. Assess and discuss with Goulburn Valley Water the need for adequate night time lighting. Discuss provision for night time lighting with Goulburn Valley Water and where required design lighting accordingly. Identify potential slipping or tripping hazards in the project and where possible engineer out. Examples include: Slippery gravel Large aggregate Steps and stairs of varying rises, treads or goings Review design to ensure safe access is provided and hazards are engineered out of the project. 99 Safety Information Health and Safety Matter Designer, Manufacturer and Supplier Requirements Consultant Requirements General Ensure safety information is reviewed and passed on to Goulburn Valley Water Reference: OH&S Act 2004, Section 21 All safety information including operating manuals must be in easy to read English Risk assessments should address Victorian OH&S Legislation Where possible safety information and operations manuals should be in electronic format Material safety Data Sheets shall be provided to GVW where chemicals are being used during commissioning of new plant and equipment Where required emergency manifest information shall be provided for the site Confined Spaces Health and Safety Matter Designer, Manufacturer and Supplier Requirements Consultant Requirements Risk Assessment Ensure confined spaces are identified and assessed for risks and where possible entry into confined spaces is engineered out of the project. Examples include: Relocation or replacement of valves, and equipment, etc. Provision for task to be done outside confined space. Ensure designer has identified confined spaces with the projects, assessed their risks and attempted to engineer out the need to enter the confined space. Where it is not possible to engineer out entry to the confined space the following shall be incorporated into the design, where possible: Access to the space via fixed ladder, stairway or other (not relevant for manhole access) Adequate space / provision made for the setting up of confined space entry equipment, including a Tripod and provision for two standby persons to carry out their task without congestion. Provision for fall protection in the form of suitable anchor points for standby personnel for sewer pump stations and similar infrastructure (not relevant for new manholes) Confined space shall be signed with a fixed steel sign or stencil which indicates the following: ‘DANGER CONFINED SPACE – ENTRY BY PERMIT ONLY” (size: 450 x 300mm – where possible) Review design to identify if confined spaces may be engineered out. Where this cannot be achieved ensure that adequate consideration has been made for entering confined spaces safely. Reference: OH&S Regs 2007 Section 3.4.6 and 3.4.7 General Reference: OH&S Regs 2007 Section 3.4.6 and 3.4.7 100 Electrical Safety Health and Safety Matter Designer, Manufacturer and Supplier Requirements Consultant Requirements Flexible Leads Where possible provision shall be made for fixed wiring in preference to flexible leads particularly for chemical transfer pumps. All flexible leads shall have been inspected and tested by a competent person as per AS/NZS 3760 (in-service safety inspection and testing of electrical equipment). All flexible leads shall be marked or tagged with the inspection details and a register of the inspection details provided to GVW. Where possible RCD shall be installed on all electrical circuits. As a minimum circuits with GPO’s must be fitted with RCD. An assessment shall be made by the designer to identify the number and most appropriate location for general power outlets. Sufficient power outlets shall be provided to ensure that the use of power boards, double adaptors, etc. is minimised. Review design to check if fixed wiring can be installed instead of flexible wiring. Check to ensure flexible wiring is appropriately inspected and tested. Health and Safety Matter Designer, Manufacturer and Supplier Requirements Consultant Requirements Lifting Means (beams, gantry’s, etc) Check to ensure lifting means are adequately marked. Cranes (hoists, chain-blocks, motorised gantry cranes, etc.) Lifting Chains Reference: AS 1418.1 – Cranes (including, hoists and winches) – general requirements Inspection and Testing Residual Current Devices (RCD) Adequate Power Outlets Check with GVW as to the number and placement of general power outlets. Lifts and Cranes All lifting equipment must be marked with their Safe Working Load (SWL). Computations which verify the SWL shall be provided to Goulburn Valley Water for their records. All cranes must be marked with their SWL and be rated as per the lifting means whichever is the lesser load as appropriate in accord with AS 1418.1 All lifting chains and lifting components shall be marked with their SWL and be manufactured to AS 1418.1 Marking of lifting beams shall be by black lettering on a yellow background and must be of sufficient size to be seen from the ground. 101 Manual Handling Health and Safety Matter Designer, Manufacturer and Supplier Requirements Consultant Requirements Minimising Manual Handling Hazards Foreseeable hazardous manual handling hazards shall be identified by the designer / supplier. Where hazards are identified these shall be reviewed by Goulburn Valley Water. Hazards identified in the project design shall where possible be: Eliminated or Engineered out Review designs to identify hazardous manual handling and discuss with GVW Where possible these shall be light enough for one person to lift and handle safely without causing a manual handling hazard. Check Pit Lids to ensure they are light enough for one person to lift. Review the design and check the operations and positioning of valves Reference: OHS Regs 2007 Part 3.1 Pit Lids Reference: OHS Regs 2007 Part 3.1 Position of Valves Chemical Storage Where possible valves shall be mechanical. Where this is not possible sufficient space must be provided around the valve to allow for one or two persons to operate it. Where chemicals are to be loaded into store sufficient space shall be provided for this task to be carried out using mechanical aids (i.e. trolley, pallet jack, etc.) Review designs to identify if manual handling hazards can be eliminated. Review the design to ensure there is sufficient space to load chemicals into store. Fire Fighting Equipment Health and Safety Matter Designer, Manufacturer and Supplier Requirements Consultant Requirements Fire Fighting Equipment An assessment must be made to identify the following: Number of portable fire extinguishers Size Type Appropriate Location Compliance requirements with Building Code of Australia Compliance with CFA Dangerous Goods requirements Compliance with local municipality requirements Review the design to ensure fire fighting requirements meet the relevant standard. Reference: Building Code of Australia Section E 1.6, Table 1.6 AS 2444 – Portable fire extinguishers and fire blankets – selection and location 102 GOULBURN VALLEY REGION WATER CORPORATION Standard Conditions for Goulburn Valley Water Construction Contracts Client Handbook for Consultants ITEM 11 INSURANCE REQUIREMENTS The following insurance requirements shall be listed in the Tender/Contract document. 103 GOULBURN VALLEY REGION WATER CORPORATION Standard Conditions for Goulburn Valley Water Construction Contracts Client Handbook for Consultants NOTES ON CONTRACTOR’S INSURANCE Insurance Clause As stated in the Annexure in respect of Works and Public Liability Insurance, the Corporation as the Principal will provide the following insurance with the designated limits: Works Insurance – Building Works - $10,000,000 for any one contract. Works Insurance – Civil Works - $5,000,000 for any one contract. Public Liability - $10,000,000 each and every occurrence. Where a Contractor believes that Goulburn Valley Water’s Contract Works insurance policy does not provide adequate cover for any reason, then they shall be responsible for providing any such additional coverage as they deem necessary, and the costs shall be borne by the Contractor. The Contractor shall ensure that they do not undertake any work in a manner that may void Goulburn Valley Water’s Contract Works Insurance policy. Goulburn Valley Water shall recover from the Contractor any insurance excess that applies to any claim that they initiate, or to any claim that results directly from work under their control. Recovery of such insurance excess shall be out of money due on the Contract where possible, or from payments due on other contracts with the Contractor or by direct invoice. The following excess amounts apply to each and every claim: Material damage - $25,000 for each and every event involving water, subsidence, collapse, landslip, cyclone, storm, tempest, earthquake, testing, commissioning, tunnelling and boring. Material damage - $5,000 each and every event all other claims. Public Liability – Third Party Property damage - $5,000 for each occurrence. Public Liability – Third Party Personal injury to entities of the insured - $25,000 for each occurrence. Public Liability – Third Party Personal injury - $5,000 for each occurrence. Public Liability – Workers on site - $25,000 for each occurrence. A number of exclusions apply. The more specific works related items are: 1. The maximum length of trenches open at any time shall not exceed 500 metres. 2. Any works involving trenches deeper than 5 metres are subject to individual consideration. 3. Construction of dams, reservoirs. Irrigation, flood mitigation works or works in, under or above water. A copy of the insurance policy shall be made available at the request of the Contractor. The Contractor shall provide a complete copy of the Policy, including a certificate of currency, confirming: Professional Indemnity Insurance 1. 2. 3. Currency of Policy. Sums insured as per Contract Condition. Extension to Indemnify the Principal. 104 GOULBURN VALLEY REGION WATER CORPORATION Standard Conditions for Goulburn Valley Water Construction Contracts Client Handbook for Consultants ITEM 13 VICTORIAN INDUSTRY PARTICIPATION POLICY The following section outlines clauses relating to the Victorian Industry Participation Policy (VIPP) to be incorporated into specification and tender documents. 105 GOULBURN VALLEY REGION WATER CORPORATION Standard Conditions for Goulburn Valley Water Construction Contracts Client Handbook for Consultants Victorian Industry Participation Policy In April 2001, the Victorian Government announced the introduction of the Victorian Industry Participation Policy (VIPP). The VIPP requires that all short listed bidders for projects over $3m in metropolitan and $1m in regional Victoria provide a VIPP statement. The VIPP statement requires information on the expected level of local content, the employment opportunities and the opportunities for skills and technology transfer. Guidelines for preparing the statement and a pro forma for your response are attached. The desired outcome of the VIPP is that it will foster industry development by encouraging bidders to genuinely and systematically consider Australian (and New Zealand) supply. Its objectives are to: boost employment and business growth in Victoria by expanding market opportunities for Victorian companies; provide contractors for major projects with increased access to Victorian suppliers that can deliver best value for money; expose Victorian companies to world’s best practice in workplace innovation, e-commerce and use of new technologies and materials; develop industry's international competitiveness and flexibility in responding to changing global markets by giving Victorian companies a fair opportunity to compete against overseas suppliers; and promote a cultural change in Australian business, raising awareness of Victorian suppliers and shifting perceptions from "imports are always best " to "local suppliers are world class". Further information concerning the VIPP can be obtained at the DSRD Web site at http://www.dsrd.vic.gov.au 106 GOULBURN VALLEY REGION WATER CORPORATION Standard Conditions for Goulburn Valley Water Construction Contracts Client Handbook for Consultants Lodgement of VIPP Statement The VIPP Statement is to be provided in a separate sealed envelope and must accompany and be lodged at the same time as the project tender. The conditions of tender lodgement as specified in the project specification will apply to the VIPP Statement. The envelope must be clearly marked as a VIPP Statement and include the applicable contract number and title. VIPP Implementation Plan In addition to the above requirement, all short-listed bidders for projects over $2.5 million will also be required to submit an implementation plan that identifies how those bidders intends to meet their VIPP requirements. In these cases, both VIPP Statements and Implementation Plans must be certified by the Department of Innovation, Industry and Regional Development (DIIRD) or Industry Capability Network Victorian Branch (ICN Vic) 107 GOULBURN VALLEY REGION WATER CORPORATION Standard Conditions for Goulburn Valley Water Construction Contracts Client Handbook for Consultants GUIDELINES FOR PREPARATION OF VIPP STATEMENTS Objectives of VIPP The Victorian Industry Participation Policy (VIPP) is intended to encourage growth in Victorian industry, employment and technology. The desired outcome of the VIPP is that it will foster industry development by encouraging bidders to genuinely and systematically consider Australian (and New Zealand) supply. Its objectives are to: boost employment and business growth in Victoria by expanding market opportunities for Victorian companies; provide contractors for major projects with increased access to Victorian suppliers that can deliver best value for money; expose Victorian companies to world’s best practice in workplace innovation, e-commerce and use of new technologies and materials; develop industry's international competitiveness and flexibility in responding to changing global markets by giving Victorian companies a fair opportunity to compete against overseas suppliers; and promote a cultural change in Australian business, raising awareness of Victorian suppliers and shifting perceptions from "imports are always best " to "local suppliers are world class". Support Services Available Tenderers are advised that the services of the Department of State and Regional Development (DSRD), the Industrial Supplies Office (ISO) and the Building Policy Group (BGP) will be available to assist them in implementing the VIPP. This will involve: the identification of local products and capabilities that meet contract requirements; an assessment and comparison of local products and capabilities with overseas equivalents; the selection of products and services that meet the contract requirements on a best value basis; and monitoring and reporting on the outcomes for Victorian industry involvement. Free ISO services are available to support bidders in identifying and developing the above information, including during the tender process. For projects valued over $50m, it is mandatory for the preferred bidder to consult with the ISO. 108 GOULBURN VALLEY REGION WATER CORPORATION Standard Conditions for Goulburn Valley Water Construction Contracts Client Handbook for Consultants Contact details are: ISO: Level 4, 10 Queens Road Melbourne 3004 Telephone: 9866 6155 DSRD: 4/55 Collins Street Melbourne 3000 Telephone: 9651 9743 Fax: 9651 9743 BPG: Level 27, Casselden Place 2 Lonsdale Street Melbourne 3000 Telephone: 9235 6914 Fax: 9285 6432 Bendigo Regional Office 50 Mitchell Street Bendigo Telephone: 5441 8611 Fax: 5442 5452 Gippsland Regional Office 33 Breed Street Traralgon Telephone: 5176 1901 Fax: 5174 7845 The DSRD is the main contact for general enquiries regarding the VIPP. Pro-Forma for Submission A pro-forma for the submission of the VIPP Statement by the tenderer is attached to this document. Assessment of the VIPP in the Evaluation Process It is required that the short listed tenderers complete a VIPP Statement as part of the evaluation process of this tender. VIPP Statements must be submitted separately in a sealed envelope. The envelope will only be opened and the content of the Statement used in accordance with the following principles: Value for money will remain the primary criterion for the selection process. Where there are two or more Tenders that offer similar value for money, the VIPP Statements may be used to differentiate between the value and benefit of the tenders. Where there is a clear preferred Tenderer based upon value for money selection, the Statement of that tenderer only may be initially opened and considered to determine whether it is a genuine attempt to address the VIPP. Where a Statement does not reflect a genuine attempt to address the VIPP the Corporation may reject the Tender and negotiate with the next preferred Tenderer. The Corporation may negotiate with Tenderers (including the preferred Tenderer) whose Statements have been opened under the above principles, for the purpose of improving the benefits offered under the VIPP. 109 GOULBURN VALLEY REGION WATER CORPORATION Standard Conditions for Goulburn Valley Water Construction Contracts Client Handbook for Consultants VIPP Compliance Where a tender has been awarded and the VIPP Statement has been accepted, the scope of the VIPP benefits will be included in the contract and recorded centrally for assessment of compliance. The DSRD may monitor the Contractor’s compliance to the VIPP Statement accepted and an auditor or other nominated representative of the DSRD shall have access to and be permitted to obtain information from the Contractor’s records and staff. The Contractor must provide authorisation for the DSRD (as part of the VIPP Statement) to obtain information from the persons, firms or corporations nominated in the VIPP Statement. The DSRD’s Representative will exercise reasonable discretion in assessing the Contractor’s performance and shall take into account any issue raised by the Contractor which fairly represents a cause of failure to comply beyond the Contractor’s reasonable control. The results of the measure of performance of the VIPP obligations will also be centrally recorded by the DSRD. Such information will be made available to departments and agencies of the Victorian Government to be used in assessing other tender proposals for VIPP purposes in the future. Definitions Definitions of terms used in this document are given below. Value for money – refers to the acquisition of the appropriate quantity and quality of goods or services at the best price or lowest cost. Wherever possible, whole-of-life costing of projects is assumed. Local – covers Victoria, Australia or New Zealand, so as to be in accord with the Australia New Zealand Government Procurement Agreement entered into by Australian State and Federal Governments and New Zealand. Local content or industry – refers to goods and services sourced from or industry based in Victoria, Australia and New Zealand. Value adding – refers to adding value, usually expressed in dollar terms, to intermediate inputs used by manufacturers or service providers. In respect of products or services, “Australian value add” means the supply price of those products or services less the amount spent on imported products and services. The latter includes all components, embedded software and design, manufacturing, assembly and supply services used for or in the supply of those products or services. In determining the amount spent on imported products or services, all amounts paid (by the Contractor or its Approved Subcontractors) to foreign persons (which do not include New Zealand persons) must be taken into account, including: (i) all licence fees paid for intellectual property rights if those intellectual property rights are owned by a person other than an Australian or New Zealand person; (ii) the cost of all imported products (including components for other products) sourced locally; and (iii) all amounts paid to foreign persons as transfer pricing or as distribution of profits resulting from the supply of the products or services. 110 GOULBURN VALLEY REGION WATER CORPORATION Standard Conditions for Goulburn Valley Water Construction Contracts Client Handbook for Consultants For the purpose of this definition, "foreign person" means any person who is not a resident of Australia or New Zealand. Local content provided by sub-contractors is included in the Australian value add, as is value added to imported content. Regional Victoria – the area within the municipal districts of the councils – excluding Metropolitan Melbourne councils – established under the Local Government Act 1989. 111 GOULBURN VALLEY REGION WATER CORPORATION Standard Conditions for Goulburn Valley Water Construction Contracts Client Handbook for Consultants VIPP Implementation Plan For Projects Over $2.5 Million In addition to completing a VIPP Statement, short-listed bidders for major projects as defined above are required to complete a VIPP Implementation Plan. The Implementation Plan should briefly demonstrate (suggested maximum of 2-3 pages) how the company, if successful in winning a tender where the VIPP applies, intends to achieve the goals detailed in the VIPP Statement. Four key elements are to be covered in the Plan as follows: 1. Identification of local products and capabilities that meet the contract requirements. This could include: A proposal for consulting with the ICN, Government organisations, local industry and other groups to identify the availability of local products to meet the requirements of the project; Detailing the means by which local industry is alerted to upcoming tenders and project requirements; Methods for promoting the concept of local industry participation with consultants, subcontractors and others involved with the contract; A commitment to liaising with international suppliers to increase opportunities for local industry including manufacturing under overseas licensing arrangements and technology transfer; Establishing procedures and policies that encourage local industry participation; and Identification of work packages and items with the potential for import replacement of products or services. 2. Assessment and comparison of local products and capabilities with overseas equivalent This could include: Procedures to be based on ”whole of life” cost parameters and appropriate quality and performance indicators; Benchmarks for the evaluation of proposals and alternatives; Procedures for assessing the local content in a product or service; and Guidelines for ensuring that local products and services are considered alongside imported alternatives. 3. Selection of products and services The Plan should describe the procedures for the selection of products and services that provides the best value solution based on the identification and assessment processes. 112 GOULBURN VALLEY REGION WATER CORPORATION Standard Conditions for Goulburn Valley Water Construction Contracts Client Handbook for Consultants 4. Monitoring and reporting on outcomes for local industry involvement This could include: Dollar value of local industry involvement benchmarked against expected levels; Frequency of monitoring and the reporting mechanism; Procedures for corrective action should inappropriate or ineffective activities for encouraging local industry be identified; Frequency and level of internal assessment of the effectiveness of the implementation of the Plan; Frequency of external assessment of sub-contractor and supplier commitment to local industry participation; and Level of use of ICN and other organisations to assist in the identification of competitive local sources of supply. 113 GOULBURN VALLEY REGION WATER CORPORATION Standard Conditions for Goulburn Valley Water Construction Contracts Client Handbook for Consultants Contract No. ……………………………… Victorian Industry Participation Policy (VIPP) Statement Template TO BE INCLUDED AS PART OF TENDER DOCUMENTATION All short-listed bidders are required to provide a VIPP Statement to demonstrate that they have considered the industry development implications of their tender according to the Victorian Government’s Industry Participation Policy. This seeks to maximise opportunities for local SMEs to compete for government business on the basis of best value for money over the life of the goods or services. (A sample VIPP Statement is provided overleaf.) Short-listed bidders are required to complete the following statement sections: Contract / Project Name: Bidding Company / Organisation: Representative’s Name: Contact Details: Address: Phone: 1. Email: Value Added Activity (local content) Bidders should specify the level of local (Victorian/Australian/NZ) value added, expressed as a percentage of the overall contract price – If possible, bidders should list the main items which are not locally produced below – 114 GOULBURN VALLEY REGION WATER CORPORATION Standard Conditions for Goulburn Valley Water Construction Contracts Client Handbook for Consultants 2. Employment Bidders should provide details, in numbers, of actual new employment opportunities to be created in Australia and New Zealand as a result of the contract and, wherever possible, the location within Australia and New Zealand of these opportunities – 3. Skills and technology transfer Bidders should briefly identify and describe opportunities for increasing the skills of Victorians and Australians and the potential to undertake further innovation and / or research and development of project related technology – (Further Information can be supplied on a separate page.) 4. Industry Bidders should briefly identify the Industry from the list provided in the guidelines and describe the type of project under tender 1. Industry 2. Project Description 115 GOULBURN VALLEY REGION WATER CORPORATION Standard Conditions for Goulburn Valley Water Construction Contracts Client Handbook for Consultants Declaration: The Bidding Company or Organisation states that in submitting the Tender and the VIPP Statement, the identified Bidder: Agrees to take all reasonable steps to comply with the Victorian Industry Participation Policy principles; Agrees that compliance with VIPP commitments will be monitored as part of overall performance management; and Acknowledges that failure to comply with a VIPP Statement will be centrally recorded by the Victorian Government and may be taken into account when considering subsequent tenders for VIPP purposes. Signature of Bidding Company or Organisation’s Representative – Date Support Services Available: Bidders are advised that the services of the Department of Innovation, Industry and Regional Development (DIIRD) and the Industry Capability Network Victoria Branch (ICN Vic) at www.icnvic.org.au are available to assist them implementing the Victorian Government’s Industry Participation Policy (VIPP). Free ICN services are available to support bidders in identifying and communicating the above information, including during the tender process. For projects valued over $10m ($2.5m in Regional Victoria), it is mandatory for the short-listed bidders to consult with the ICN and to obtain certification of their VIPP Statements and Implementation Plans. Contact ICN at www.icnvic.org.au or on Tel. (03) 9864 6734. Tenderers Signature: ………………………………… Date: ………………………………… 116 GOULBURN VALLEY REGION WATER CORPORATION Standard Conditions for Goulburn Valley Water Construction Contracts Client Handbook for Consultants ITEM 14 CLERK OF WORKS A copy of the Corporation’s position on the role of the Clerk of Works is attached. 117 GOULBURN VALLEY REGION WATER CORPORATION Standard Conditions for Goulburn Valley Water Construction Contracts Client Handbook for Consultants THE ROLE OF THE CLERK OF WORKS CONDITIONS OF CONTRACT The General Conditions of Contract provides for the appointment of the following persons: Superintendent. Superintendent’s Representative. Clerk of Works or Inspector. The Clerk of Works acts as an inspector under the direction of the Superintendent (or his Representative) but has no power to issue directions under the Contract. REPONSIBILITIES The Clerk of Works is employed by the Water Corporation but is directly responsible to the Superintendent, through the person nominated, for the carrying out of detail supervision to ensure that the works are constructed in accordance with the requirements of the Contract Documents. PRIMARY ROLE The contract between the Principal (Goulburn Valley Water) and the Contractor requires certain works to be performed in accordance with the contract documents. The documents of primary importance to the Clerk of Works are: General Specification Project Specification Drawings He/She should make himself/herself conversant with the drawings, specifications etc. and assist the contractor in his interpretation of these documents. He/She should refer any possible discrepancies in these documents or drawings, or any items that require clarification or are not fully understood to the Superintendent’s Representative. The Clerk of Works’ primary role is to ensure that the Contractor carries out the works in accordance with the requirements of these documents (or as otherwise directed by the Superintendent’s Representative). The Clerk of Works should also make himself/herself aware of the contents of all of the General Specifications. 118 GOULBURN VALLEY REGION WATER CORPORATION Standard Conditions for Goulburn Valley Water Construction Contracts Client Handbook for Consultants The Clerk of Works will therefore carry out: INSPECTIONS To satisfy himself/herself that the Contractor is constructing the works: i) In the correct locations and programmed order. ii) To the correct dimension iii) Using approved construction methods and safe working practises. iv) Using approved materials and components. v) Complying with the Superintendent’s instructions. vi) Doing as little damage as possible to property and vegetation. vii) Complying with the requirements of other Statutory Authorities. viii) The completed works are of a satisfactory standard. Note that inspections should NOT be carried out at the same time every day. MEASURING & TESTING (a) (b) To satisfy himself/herself of the quality of the works in that they are:i) Within the specified tolerance for line, level, dimension and grade. ii) Pipelines meet specified test pressures. iii) Equipment meets specified performance requirements. iv) Materials meet specified density or strength requirements. To determine as constructed details of the works for the purpose of:i) Preparation of quantities for progress payments. ii) Plotting of constructed plans as a permanent record of completed works (where specified). 119 GOULBURN VALLEY REGION WATER CORPORATION Standard Conditions for Goulburn Valley Water Construction Contracts Client Handbook for Consultants KEEPING OF RECORDS including:i) A record of resources (plant labour and materials, when and for what purpose) employed by the contractor on the site. ii) Results of quality control measurements and testing iii) Minutes of meetings and conversations concerning the works. iv) Such items as disputes, accidents, or any incident considered important. v) Amounts of materials and labour in respect of works involving claims for extras or deductions. vi) Receipt of delivery dockets for materials paid for by Principal on a schedule of rates basis. vii) Man hours in connection with overtime work carried out at the cost of the Principal. viii) A check on the contractor’s labour, material and plant returns for all work to be charges on a day – work basis. ix) Photographic and documented records (as and when appropriate) of:(a) The site prior to the commencement of the works; (b) The works in progress, especially critical components buried or covered during the course of the works. (c) Completed sections of the works. This information is required to compare with final reinstatement and to assess validity of complaints by property owners. REPORTING including:i) Informing the Superintendent (or his Representative) either verbally or in writing, of the results of such inspections, tests and measurements. ii) Promptly informing the Superintendent when he is required to give opinions, approvals or directions under the contract. It should be noted that the Clerk of Works shall not; (a) Authorise variations to the Contract and/or previous instructions of the Superintendent without the Superintendent’s prior approval. (b) Issue instructions and/or directions to other than the Contractor’s nominated representative. LIAISON – the Clerk of Works is required to liaise with:i) The Contractor to enable him to carry out his obligations under the contract. ii) Representatives of other Statutory Authorities whose assets are affected by the works (with the Contractor if necessary). iii) Owners and occupiers of properties affected by the works (with the Contractor if necessary). iv) Other Corporation staff with an interest in the progress of the works. v) Members of the general public, emergency services and any other persons affected by the works. 120 GOULBURN VALLEY REGION WATER CORPORATION Standard Conditions for Goulburn Valley Water Construction Contracts Client Handbook for Consultants CUSTOMER SERVICE The Clerk of Works is the Corporation’s primary contact with customers during the construction phase. Clerks of Works should carry out their duties in such a manner as to enhance the Corporation’s public image. Means by which this can be achieved include:i) Meeting with owners and/or occupiers to discuss the proposed works prior to commencement (with the Contractor if necessary). ii) Attend to the reasonable requests and concerns of owners during the construction period. iii) Ensure that properties are correctly reinstated following completion of construction. OCCUPATION HEALTH & SAFETY 1) The Clerk of Works shall satisfy himself/herself that the Contractor has complied with OH&S requirements. The Clerk of Works shall therefore: i) Ensure all site inductions are carried out and are site specific if relative to a GVW work area. ii) Carry out daily inspections on all matters pertaining to OH&S and advise the contractor in writing of any contraventions and provide notice to the Superintendent accordingly. iii) Ensure the Contractor has an approved OH&S management plan in place. iv) Confirm all of the contractors health and safety responsibilities have been fully documented. v) Confirm health and safety systems are displayed/available at the work sites i.e. Accident Report Book vi) Induction Records Workplace Inspection Records Emergency Procedures Copies of Licences and Training Risk Assessments available MSDS available Have the appropriate mechanisms in place to identify plant safety hazards, assess their risks and implement appropriate controls. This may include; Completion of risk assessments Plant maintenance and inspection forms Plant fault reporting systems vii) Ensure regular tool box meetings are carried out by the Contractor. viii) In conjunction with the Contractor carry out weekly/fortnightly site safety walks. Complete a GVW audit, (desktop review) of the Contractors OH&S systems as required 121 GOULBURN VALLEY REGION WATER CORPORATION Standard Conditions for Goulburn Valley Water Construction Contracts Client Handbook for Consultants Environmental Management In regard to environmental duties involving contractors the Clerk of Works is responsible for the following: 1) Ensure the contractors Environmental Management Plan (EMP) submitted for the works has been approved in principal by GVW’s Environment Group. 2) Undertake a risk assessment of the works QF-GVW-050 to ensure all environmental aspects have been identified in regard to the contract and remediation measures are included in the contractor’s EMP. 3) Carry out periodic inspections to ensure environmental aspects relevant to the contract are in accordance with the EMP and advise the contractor in writing of any non conformances. 4) Complete QF-GVW-044 on a monthly basis to ensure contractor works are being undertaken in accordance with the EMP 5) Raise potential adverse environmental issues to ensure remediation actions are implemented promptly to minimise/eliminate potential environmental impacts. 122 GOULBURN VALLEY REGION WATER CORPORATION Standard Conditions for Goulburn Valley Water Construction Contracts Client Handbook for Consultants ITEM 15 INDUSTRIAL RELATIONS The following clause shall be included in all Construction Contract Documents. “Then contractor shall, at its own cost, be responsible for and assume all risks of and incidental to industrial relations with its workforce and those of its subcontractors, consultants and agents.” 123 GOULBURN VALLEY REGION WATER CORPORATION Standard Conditions for Goulburn Valley Water Construction Contracts Client Handbook for Consultants ITEM 16 ENVIRONMENTAL POLICY A copy of the Corporation’s requirements for an EMS is attached. The requirements shall be noted by Consultants and incorporated into specification and tender documents. 124 GOULBURN VALLEY REGION WATER CORPORATION Standard Conditions for Goulburn Valley Water Construction Contracts Client Handbook for Consultants Environmental risk assessment involving contracts Goulburn Valley Water’s Environmental Management System (EMS) is certified to international standard ISO 14001 and has adopted its principles as the framework for its EMS. The focal point of the EMS is the Environment Policy which states the Corporation has a commitment to the continuous improvement of its environmental performance. Contractors working for or on behalf of Goulburn Valley Water have important responsibilities in regard to performing works under the terms and conditions of their contracts. Contractors must assess their potential to impact on the environment and formally identify the environmental aspects and impacts involved in the proposed works. An Environmental Management Plan will be required to be submitted to the Corporation’s Environmental Group for review prior to the start of the proposed work. The Contractor shall, within 14 days of the date of acceptance of tender, submit a Site Environmental Management Plan (SEMP) to Goulburn Valley Water. The SEMP shall identify the environmental risks associated with the works, rate the risks (e.g. high medium or low) and describe the measures proposed by the contractor to reduce such risks. The requirement of an SEMP is designed to make contractors aware of their environmental risks and develop sound practises to minimise potential environmental impacts. The SEMP shall include, as a minimum, a document indicating such matters as, but without limitation: A risk assessment of the works identifying all environmental risks and control measures A staff induction covering environmental aspects of the site and notification procedures in place. Details of training provided to staff in emergency response procedures, spill control and remediation; Details of the placement of site accommodation, toilets and storage compounds; Contractor's vehicle access and areas where access is to be restricted; Protection measures for existing vegetation; Remediation of vegetation; Methods of dust control; Control of discharges from and within the site; Methods of erosion control Methods of controlling surface run off from the site; Methods of controlling noise Hours of operation; Details of monitoring inspections and audits to be undertaken by the contractor A list of chemicals to be held onsite, appropriate storage facilities and spill containment measures used. Material Safety Data Sheet’s for all dangerous goods held onsite Details of recycling and disposal of construction waste It is suggested that the identified environmental aspects, risks and contingencies measures proposed are summarised in a table in the SEMP. See the 1.1 table below. 125 GOULBURN VALLEY REGION WATER CORPORATION Standard Conditions for Goulburn Valley Water Construction Contracts Client Handbook for Consultants Further guidance in regard to the submission of SEMP’s may be located in EPA Publication – Environmental Guidelines for Major Construction Sites. Goulburn Valley Water will undertake audits of the contractors SEMP to ensure management controls are being implemented. The Corporation’s Superintendent and Environment Group will be available to assist contractors with additional information if required. The Corporation’s Superintendent will complete monthly environmental checklists (QF- GVW-044), to ensure compliance with Goulburn Valley Water’s Environmental Management System. 126 GOULBURN VALLEY REGION WATER CORPORATION Standard Conditions for Goulburn Valley Water Construction Contracts Client Handbook for Consultants ITEM 17 SUSTAINABILITY POLICY A copy of the Corporation’s Sustainability Policy is attached. The requirements shall be noted by Consultants and incorporated into specification and tender documents. 127 GOULBURN VALLEY REGION WATER CORPORATION Standard Conditions for Goulburn Valley Water Construction Contracts Client Handbook for Consultants Sustainability Policy Goulburn Valley Water understands that the sustainability and vitality of our regional industries and communities, water resources and natural environment are all intrinsically linked. We believe that to remain a viable, valued and important corporate member of the community, we must provide essential water services to meet changing consumer needs in a way that also contributes to the sustainability of the region as a whole, ensuring that it remains the place where we want to live and work. While we recognise that the task is not simple, we also believe the benefits of acting now are significant. The opportunity clearly exists to: inspire and shape new economic and regional development, secure a range of water sources to support future development while protecting the environment, optimise the long-run investment in water infrastructure and operations, and develop innovative water systems and business solutions that are transferable elsewhere. Goulburn Valley Water’s Sustainability Policy is: The Corporation recognises that we exist in a global environment and we are committed to collaboratively working with our community to foster and shape regional development and resource management; taking account of environmental, social and economic factors. We will achieve this through the following goals: Ensuring ongoing organisational relevance and effectiveness Ongoing improvement in business efficiency Minimising the environmental footprint Delivering integrated community benefits Contractors working for, or on behalf of, Goulburn Valley Water have important responsibilities in regard to incorporating sustainability considerations into their contracts and proposed works. To this end, contractors are encouraged to assess their potential to contribute to sustainability using triple bottom line considerations – economic, environmental and social. The Corporation’s Sustainability Team will be available to assist contractors with additional information if required. 128 GOULBURN VALLEY REGION WATER CORPORATION Standard Conditions for Goulburn Valley Water Construction Contracts Client Handbook for Consultants ITEM 18 EXPERT DETERMINATION A copy of the Expert Determination Agreement is attached. (Not to be bound into Contract) 129 GOULBURN VALLEY REGION WATER CORPORATION Standard Conditions for Goulburn Valley Water Construction Contracts Client Handbook for Consultants EXPERT DETERMINATION AGREEMENT This AGREEMENT is made the day of 2008 BETWEEN: (“the Claimant”) AND: (“the Respondent”) AND: of (“the Expert”) RECITALS: A. The Claimant and the Respondent (collectively “the parties”) are presently in dispute over matters arising out of or in connection with (“the Dispute”). B. The Dispute has been referred by the parties to expert determination by the Expert. C. The Expert has agreed to determine the Dispute on the terms set in this Agreement. THE PARTIES AGREE AS FOLLOWS: 1. APPOINTMENT 1.1 The parties hereby engage the Expert, and the Expert accepts the engagement, to act as an expert in determination of the Dispute. 1.2 The parties agree to participate in good faith in the Process. 1.3 The parties agree that the determination of the dispute by the expert shall be final and binding upon them. 130 GOULBURN VALLEY REGION WATER CORPORATION Standard Conditions for Goulburn Valley Water Construction Contracts Client Handbook for Consultants 2. THE PROCESS 2.1 The Expert shall act as an expert and not as an arbitrator. The Process conducted under or in any connection with this Agreement (“the Process”) is not an arbitration within the meaning of any legislation or rules dealing with commercial, industrial, court-annexed or any other form of arbitration. 2.2 The Process shall commence with the acceptance by the Expert of the appointment by notice in writing to the parties. The Process shall conclude when the Expert has notified the determination of the dispute in writing to the parties. 2.3 The Expert shall make a determination on the Dispute as submitted by the parties in accordance with this Agreement. 2.4 The Expert shall make the determination according to law and shall conduct the Process in accordance with the requirements of procedural fairness. The Expert shall make the determination on the basis of information received from the parties and the Expert’s own expertise. The Expert shall not be bound by the rules of evidence and may receive any information in such manner as the Expert thinks fit. 2.5 The Expert shall disclose all information and documents received from either party to the other party. The Expert shall not consult with a party other than in the presence of the other party except where a party, having received due notice, fails to make a written submission or appear at any conference. 2.6 If the Expert becomes aware of circumstances that might reasonably be considered to adversely affect the Expert’s capacity to act independently or impartially, the Expert shall inform the parties immediately. In such circumstances the Expert shall terminate the Process unless the parties agree otherwise. 2.7 The parties may be required by the Expert to attend a preliminary conference to make such procedural and administrative arrangements as are necessary and appropriate (including the Expert’s terms of appointment) to enable the Process to proceed. At any conference with the Expert a party may have legal or other representation. The conference shall be held in private, but may include authorised representatives or experts for the parties. 2.8 All proceedings and submissions relating to the Process (including the fact that any step in the Process is occurring) shall be kept confidential between the parties and the Expert. No information relating to or arising out of the Process may be divulged to any other person, except with the prior written consent of the parties or as may be required by law or to the extent necessary to enforce the determination by the Expert. 2.9 Any dispute arising between the parties in respect of any matter concerning this Agreement or the Process, (including the Expert’s jurisdiction) shall be submitted to and determined by the Expert. 131 GOULBURN VALLEY REGION WATER CORPORATION Standard Conditions for Goulburn Valley Water Construction Contracts Client Handbook for Consultants 3. PRE-DETERMINATION STEPS [OPTIONAL] 3.1 Within [[ ]] days of the date of the commencement of the Process, the Claimant in the dispute shall provide to the Respondent and the Expert a statement in writing detailing the nature of the dispute, any agreed statement of facts and a written submission on the dispute in support of the Claimant’s contentions of fact and law. 3.2 Within [[ ]] days after the provision of the above submission, the Respondent shall provide to the Expert and to the Claimant a written response to the Claimant’s submission. 3.3 Within [[ ]] days after the provision of the Respondent’s response, the Claimant may provide a written response to the Expert and to the Respondent. 3.4 The Expert may require further written submissions or documents from either or both parties, giving each party a reasonable opportunity to make a written response to the other’s submission, and/or call a conference between the parties and the Expert. 3.5 If the Expert decides that a conference between the parties is necessary, the Expert shall arrange for a conference at a venue and time convenient for the parties and shall notify them accordingly. A conference may take the form of a view. 3.6 At least [[ ]] days prior to the conference the Expert shall inform the parties in writing of any specific matters he wishes to be addressed at the conference. 3.7 At the time and place notified for the conference the parties or their representatives shall appear before the Expert and may make oral representations. 3.8 At the conference the Expert may permit the making of such submissions as may be fair and expedient in the circumstances. 4. DETERMINATION 4.1 As expeditiously as possible after the receipt of the submissions or after a conference, the Expert shall determine the dispute between the parties and notify such determination in writing to the parties. The Expert shall give to the parties a brief statement of the reasons for the determination. 4.2 Where the determination made by the Expert contains a clerical mistake, an error arising from an accidental slip or omission, a material miscalculation of figures or a material mistake in the description of any person, thing or matter, a defect of form, the Expert may correct the determination. 132 GOULBURN VALLEY REGION WATER CORPORATION Standard Conditions for Goulburn Valley Water Construction Contracts Client Handbook for Consultants 5. COSTS OF THE DETERMINATION 5.1 Unless the parties agree otherwise, each party shall bear its own costs and shall share equally the costs of the Expert and the Process. 5.2 6. RELEASE AND INDEMNITY OF THE EXPERT 6.1 Except in the case of fraud, the Expert shall not be liable to any of the parties in relation to any cause of action for anything performed or omitted by the Expert. The parties jointly or individually hereby release and indemnify the Expert against all legal actions, suits, proceedings, disputes, accounts, claims, demands, costs, expenses and damages of any kind, arising out of or in connection with the Process or any other process connected to this Agreement. 7. EXPERT’S FEES 7.1 The parties shall pay for all the time taken by the Expert in the preparation for, the performance of, and in connection with, the Process and any other process arising out of or in connection with this Agreement. The Expert’s fees shall be calculated at the rates set out in Schedule A, including the Expert’s reasonable fees and expenses. 7.2 The parties shall be jointly and severally liable to the Expert and to the security holder for their respective fees and reasonable expenses. 7.3 Upon completion, termination or abandonment of the Process, and the Expert shall instruct the security holder to: 7.3.1 pay the Expert’s fees and expenses from the security; 7.3.2 notify the parties of any balance of security then held, if the Expert is continuing to perform the work under the Agreement; or 7.3.3 relay to the parties any balance of security held, if the Expert’s work has been completed. 7.4 To the extent that the Expert’s invoices are not furnished by security, the parties shall pay the Expert’s fees and expenses within 30 days of the date of the Expert’s invoice. 8. SECURITY FOR THE EXPERT’S FEES 8.1 On or before [[ ]], each party shall lodge with Rialto Adjudications Pty Ltd (“the security holder”) the sum of $[[ ]] (“the security”) as security for the Expert’s fees and expenses. 8.2 The parties shall be jointly or individually responsible to the security holder for its administrative fees in relation to the security. 8.3 Each party shall lodge with the security holder additional security as instructed by the Expert at any time in the amount and within the time stipulated. 8.4 The Expert shall refrain from continuing the Expert Determination or any other process under or in connection with the Agreement until the parties comply with their obligations with respect to security. 133 GOULBURN VALLEY REGION WATER CORPORATION Standard Conditions for Goulburn Valley Water Construction Contracts Client Handbook for Consultants 8.5 Each of the parties authorises the security holder to : 8.5.1 make payment of the Expert’s fees and expenses from security on the Expert’s instructions; 8.5.2 deduct, from the security, the security holder’s administrative fees and expenses in accordance with specific provisions in this Agreement. …………………………………………………. Signed for and behalf of the Claimant …………………………………………………. Signed for and behalf of the Respondent …………………………………………………. Signed by the Expert 134 GOULBURN VALLEY REGION WATER CORPORATION Standard Conditions for Goulburn Valley Water Construction Contracts Client Handbook for Consultants SCHEDULE A SCHEDULE OF FEES The Expert’s Fees shall be calculated at the following rates: 1. per day 2. per hour 3. travelling/accommodation expenses 4. secretarial services, sundries 5. photocopying, fax 6. security holder’s fees 135