TABLE OF CONTENTS Solution 01 ...................................................................................................................................... 2 Solution 03 ...................................................................................................................................... 4 Solution 04 ...................................................................................................................................... 6 Solution 06 ...................................................................................................................................... 8 CONCLUSION ................................................................... Ошибка! Закладка не определена. BIBLIOGRAPHY ......................................................................................................................... 10 Solution 01 a) Letters of intent are in different forms, such as expressing hope, ensuring no legal consequences and also to pre-tell the contract to agree to it, while some present contracts occur in between the information in the contract1. The letter of intent is generally a document which presents, the employer’s statement to entering a contract with the contractor for a work to be done later or the instructions or authorization for the contractor to start mobilization work. When considering any problems created by the “letter of intent” can be stated as below. The main problems created by the letter of intent is due to the misunderstanding of the content by the lawyers or the users2. It creates problems such as: The parties of the contract may work according to their own assumptions which are not similar at all. Both of them think they work according to the properly signed and approved contract, but the original document may still have pending completion and under negotiations3. According to the case of Walford v Miles, negotiations should prevent a contract coming into being. It further states that no legal content is relevant for an agreement to negotiate. Another problem that may be created by letter of intent is that the parties of the contract may not know on what terms and conditions are applied in the contract4. In the case of RTS V Molkere, the parties have initiated a project without proper contract but with a letter of intent which should have expired. Finally, the decision came as “The different decisions in the courts below and the arguments in this court demonstrate the perils of beginning work without agreeing the precise basis upon which it is to be done. The moral of the story to is to agree first and to start work later”. Next problem is that the temptations for a conclusion of a formal contract are not enough to create any distractions for the project and results in the termination of the negotiations. As in the case of HHJ Coulson in Cunningham v Collett5, a risk is there for the failure of the agreement to create a full building contract and further, if no agreement is created, no 1 HHJ Humphrey Lloyd QC said, in ERDC v Brunel University [2006] EWHC 687 (TCC) Fontaine,M and De Ly, F (2009). Drafting International Contracts. Martinus Nijhoff 3 Walford v Miles, [1992] AC 128, HL. 4 RTS Flexible Systems Ltd v Molkerei Alois Müller GmbH & Co KG [2010] UKSC 38, Lord Clarke 5 HHJ Coulson QC, Cunningham v Collet & Farmer [2006] EWHC 1771 (TCC) 2 main contract will be created too. “It seems to me that that is an inevitable risk of any letter of intent which creates respective rights and obligations, no matter how carefully it is drafted”. Another problem created is that, the employer may get an illusion that he will be benefitted by the early start of the project (McGuiness, 1998). b) Effective drafting of the letter of intent may drove away these problems and drawbacks. For effective drafting, certain provisions should be made with the letter of intent. They are as follows. 1. Certainty: Ensure certainty by including essential terms in it which are compulsory to enforce the contract without them. In the case of Cunningham v Collett6, the judge recommended that a letter of intent should only be sent when the following terms are agreed: Dates of commencement and completion, Terms of the contract Work scope Price. 2. Incentives: Further, three separate limits are used in the letter of intent in terms of work scope, money and time. The City of London Law Society’s Standard Form Letter of Intent7 provides for following three limitations. Limit on work Limit on employer’s liability for costs Limit on time 3. Intention The letter of intent should not: marked as “subject to contract”, refer negotiations or entering of a formal contract in a standard form. 6 7 (A Firm) (TCC) [2006] EWHC 1771 (TCC) Available from the City of London Law Society website Solution 03 A contract administrator means the responsible party of the client with two main responsibilities in a contract. One is to act as the responsible agent of the employer and the other advantage is to having the judicial capacity which is mostly apparently given the right to administrate the justice. Considering the first role: in any case the administrator was unable to meet any provided obligations as in the main contract, the employer needs to bear the responsibility. There includes provision of any information and issuing any instructions. The other important role is to maintaining the main contract on line by making relevant decisions; the decisions must be in the main contract as it is. As concluded in the case of Devlin LJ in Minster Trust Ltd v Traps Tractors Ltd8, the role is “intended to embody a decision that is final and binding on the parties”. Further, in the case Sutcliffe v Thackrah9, Load Reid stated about the duties of the architect as the contract administrator to exercise due care and also to fairly reach the decisions by balancing both the client and the contractor. But on the other hand, the contract administrator cannot go beyond her authority and as example, she would ask for due permission before signing any contract, make any changes in the contract or to terminate the contract. When the administrator goes beyond her authority, the parties can refuse complying, by following Stockport MBC v O’Reilly10 they can refuse to pay and also the partners can agree on varying the contract separately. But if the employer knew about the decision taken by the administrator, the administrator is treated an authorized person and the employer pays the loss to the contractor. In such case, as in Sika Contracts v Gil & Closegen Properties11, the contract administrator becomes personally liable for the cost. During construction, the contract administrator has duties relevant for the identification of visible defects before completion. Therefore, in any contract the powers are set out for the administrator such as having the power to issue instructions to require the removal from site of work or materials 8 [1954] 3 All ER 136 Amec Civil Engineering Ltd v Secretary of State for Transport [2005] EWCA Civ 291 10 [1978] 1 Ll Rep 595 11 (1978) 9 BLR 11 9 not in accordance with the contract (JCT 2011 SBC clause 3.18.1) or other instructions as appropriate (JCT clause 3.19). In another case, considering the role of a contract administrator on the completion of a contract, the administrator should know what the contract states on the completion. If the provided definition is not clear enough, it provides the contract administrator the power and authority to act. If the ractical project completion is enough, the administrator can provide a letter mentioning for a proect completion, but no any guarantee is provided for a third party on satisfactory standards and therforethe administrator does not intend the third parties to rely upon the issued letter. If any time extention to be provided for a contract, the administrator should have information confirming, if there is an event happening which causes the project a delay, or whether the delay is caused by th proect contractor. As in the case of The Royal Brompton Hospital NHS Trust v FA Hammond12, it was confirmed that the delay of issuing any information or drawings within the schedule can not be considered as a rason to delay the completion of a contract. In any case, the role of a contract administrator is to approach the process with logically analysis the impacts of any event by the contractor as stated in the case of John Barker Construction Ltd v London Portman Hotel Ltd13, mathematically calculated assessment on time required for various items, properly applying provisions as in the contract and finally reasonable and logical allowance on the delay and the corresponding item. Further, as in the case of Dyson J in Henry Boot v Malmaison14, contract administrator is not precluded when considering any effects by an event in determining whether it make any delay for works which are beyond completion. As the contract administrator can make a proper assessment on delaying the completion, she does not have any authority to bring the completion date any forward. 12 (No. 7) (2001) 76 Con LR 148 (1996) 83 BLR 31 14 (1999) EMHC 1773 13 Solution 04 Liquidated damages are used by a party of the contract when the actual damages are difficult to prove, even when they are actually happened (School, n.d.). It is normally a sum of money which is fixed in a contract in order to be paid in a breach. The amount is a fair estimate on probable consequences of breach (University, 1991) The approach of the courts to liquidated damages clauses, once viewed with caution if not open distaste, has become increasingly favorable and now better reflects commercial realities15. When discussing about the completion of a contract, it means the completion of all work and further addressing all defects, so that liquidated damages are not further provided as stated in the case of Judge Newey in Emson Eastern v EME Developments16. As discussing on the extension of the time period of the contract also, liquidated damages plays a great role as there is a misunderstanding as it benefits the contractor to reduce the exposure of liquidated damages by giving more time to complete the project. Further, there is a legal problem which occurs considering the extension of time. In the contract, the stated damages should be therefore a genuine pre-estimate done as the result of the delay incurred by the employer. But if the contractor is able to prove that any penalty should be given for the damages, it avoids the deductions which happens automatically. In that case, the employer has to prove the losses he encountered and recover the damages by presenting in a court. Considering the contractor remedies, as in the case of City Inn v Shepherd, even if the [contractors] were entitled to an extension of time to resist liability for liquidated and ascertained damages, they were not automatically entitled to prolongation costs for an identical period17. In the case of Multiplex Construction (UK) Limited v Honeywell Control Systems Limited18 disagreed with the decision of the Supreme Court case of Gaymark Investments Pty Ltd v Walter Construction Group Ltd19 and concluded to held that a provision of a notice was not absolute and setting of time had not been large. The prevention principle after Multiplex v Honeywell’, SCL paper (1991) 55 BLR 114 17 [2010] at [59] 18 (No.2) [2007] EWHC 447 (TCC) 19 (2005) 21 Const LJ 71. Supreme Court of Northern Territory of Australia 15 16 When delaying claims also, liquidated damages are accounted. For claiming for the breach of the contract, causation of damages is taken into account and damages which are reasonably foreseeable and arising naturally as a result of the breach are considered as instances for claiming for breach of contract. When considering the recovery, the contractor cannot recover twice for the same loss20 the choice of the contractor does not affect for the amount of recovery. According to the court in Wraight Ltd v PH & T21, grounds are not relevant for direct losses or determining any damages caused to contractor. The court decides any claim is acceptable in instances such as the responsibility of the employer is eliminated on any loss and expense22, proved at a trial any link between event and the claimed money and finally, determination of impossible circumstances 23 Below given are some cases regarding liquidated damages and penalties by the court. In the case of Philips Hong Kong Ltd v A-G Hong Kong24, Lord Wolf stated that “the court should not adopt an approach to provisions as to liquidated damages which could…defeat their purpose.” In the case of Azimut-Benetti v Healey25, The High Court held that there can be a half-way house, where the sum represents neither a genuine pre-estimate of loss likely to be suffered from the delay, nor a penalty. Also in the case of Temloc Ltd v Errill Properties Ltd26, LADs provision was marked as ‘n/a’ and on the facts this was consistent with the parties’ agreement that no damages, liquidated or unliquidated, were to be payable for late completion. Finally, as in the case of Alfred McAlpine v Tilebox27, the rule about penalties is an anomaly within the law of contract, the courts are predisposed and also according to that case only four cases out of all were struck down for penalty. 20 Temloc Ltd v Errill Properties Ltd (1987) 39 BLR 30, CA Wraight Ltd v PH & T (Holdings) Ltd 1968 13 BLR 26 22 John Doyle v Laing [2004] ScotCS 141 23 London Borough of Merton v Stanley Hugh Leach Ltd (1985) 32 BLR 51 24 Philips Hong Kong Ltd v The Attorney General of Hong Kong Co (Hong Kong) [1993] UKPC 3a 25 Azimut-Benetti Spa (Benetti Division) v Healey [2010] EWHC 2234 (Comm) 26 (1987) 39 BLR 30 27 Alfred McAlpine Capital Projects Ltd v Tilebox Ltd [2005] EWHC 281 (TCC) 21 Solution 06 Mediation means the collaboration of a neutral person in promoting the communication between two disputant parties. It starts when the negotiation fails or when a mutual agreement is needed between two disputant parties before staring any negotiation. When deciding the amount of costs in accordance with Part 44 of the Civil Procedure Rules, mediation is considered effectively important as the penalties may be used by the court for unreasonable parties by limiting recovery of legal costs. When considering any differences between the ADR methods such as mediation with litigation methods, mediation methods are future-oriented and it aims at determining the interests of the parties. Further, it is flexible and less structured than litigation procedure. Further, the third party and the two main parties are voluntarily articipating and at any stage of the process, any arty can withdraw form the process, if it is uncomfortable for that party. Further, when considering advantages of mediation over other ADR method, the significant points are: wide range of issues and solutions can be discussed and it helps the two main parties to avoid future disputes that will occur in the future. Further, the process is confidential and the neutral third party is normally skilled and provides successful solutions considering all possibilities. In mediation, the most important aspect is the timing. As in Coulson J in Nigel Witham v Smith28, both parties should know of the details of the claim and the relevant response before incurring the costs because settlements are unable to be done after having any costs. Further, the mediation process is private and confidential and it is without prejudice. But, although it is an effective method, the court does not penalize for not attending for mediation process in very few instances as in Hurst v Leeming29. The powers of the court for costs under Part 44 of the CPR provides a connection between mediation and litigation. In the case of Halsey30 in The Court of Appeal, the reasons and the methods for using the powers of the court to settle the disputes are addressed as: not contravening the article 6 of Human Rights Convention by 28 [2008] EWHC 12 [2001] EWHC 1051 (Ch) 30 As set out by the Court of Appeal in PGF v OMFS, [2013] EWCA Civ 1288 29 compelling the parties to mediate using the powers, paying the costs by the unsuccessful party as it refuses to attend to ADR under no reasonable reasons and etc. There are several cases where the mediation was considered as an effective ADR method such as the case of Dunnett v Railtrack plc31. There, the death of several horses has happened as the door was kept open there, mediation was proposed as the best process to address this problem but the Rail track refused this. There, although the rail track won the appeal, the costs order was not made against the unsuccessful horse owner. Likewise, the court has encouraged the public to use the mediation process along with a skilled mediator who would resolve the differences between the two parties and finally achieving a positive result. Further, as in the case of PGF SA v OMFS32, considering the cost sanctions, the court stated that, being silent when inviting for mediation is unreasonable and failure to provide fair reasons destroy the objectives or ADR processes. Moreover, even one party has fair reasons to refuse any invitation to follow an ADR method, a serious invitation should also be sent to engage for an ADR process Further, considering the economic considerations also, following an ADR method can be considered as an appropriate way of emphasizing the message by a sanction, as it is the task of the court to encourage mediation process. 31 32 [2002] EWCA Civ 303 Court of Appeal [2013] EWCA Civ 1288 BIBLIOGRAPHY Cases: Alfred McAlpine Capital Projects Ltd v Tilebox Ltd [2005] EWHC 281 (TCC) Azimut-Benetti Spa (Benetti Division) v Healey [2010] EWHC 2234 (Comm) City Inn v Shepherd [2010] at [59] Coulson J in Nigel Witham v Smith [2008] EWHC 12 Cunningham v Collett (A Firm) (TCC) [2006] EWHC 1771 (TCC) Devlin LJ in Minster Trust Ltd v Traps Tractors Ltd [1954] 3 All ER 136 Dunnett v Railtrack plc [2002] EWCA Civ 303 Court of Appeal Dyson J in Henry Boot v Malmaison (1999) EMHC 1773 Fontaine,M and De Ly, F (2009). Drafting International Contracts. Martinus Nijhoff Gaymark Investments Pty Ltd v Walter Construction Group Ltd (2005) 21 Const LJ 71. Supreme Court of Northern Territory of Australia HHJ Coulson QC, Cunningham v Collet & Farmer [2006] EWHC 1771 (TCC) HHJ Humphrey Lloyd QC said, in ERDC v Brunel University [2006] EWHC 687 (TCC) Hurst v Leeming [2001] EWHC 1051 (Ch) John Barker Construction Ltd v London Portman Hotel Ltd (1996) 83 BLR 31 John Doyle v Laing [2004] ScotCS 141 Judge Newey in Emson Eastern v EME Developments (1991) 55 BLR 114 London Borough of Merton v Stanley Hugh Leach Ltd (1985) 32 BLR 51 Multiplex Construction (UK) Limited v Honeywell Control Systems Limited (No.2) [2007] EWHC 447 (TCC) PGF SA v OMFS [2013] EWCA Civ 1288 Philips Hong Kong Ltd v The Attorney General of Hong Kong Co (Hong Kong) [1993] UKPC 3a RTS Flexible Systems Ltd v Molkerei Alois Müller GmbH & Co KG [2010] UKSC 38, Lord Clarke Sika Contracts v Gil & Closegen Properties (1978) 9 BLR 11 Stockport MBC v O’Reilly [1978] 1 Ll Rep 595 Sutcliffe v Thackrah Amec Civil Engineering Ltd v Secretary of State for Transport [2005] EWCA Civ 291 Temloc Ltd v Errill Properties Ltd (1987) 39 BLR 30, CA The Royal Brompton Hospital NHS Trust v FA Hammond (No. 7) (2001) 76 Con LR 148 Walford v Miles, [1992] AC 128, HL. Wraight Ltd v PH & T (Holdings) Ltd 1968 13 BLR 26 Books and other Documents: McGuiness, J. B., 1998. The Effects of Letters of Intent, s.l.: CIOB. School, C. L., n.d. Cornell Law School. [Online] Available at: https:/www.law.cornell.edu/wex/liquidated_damages [Accessed 07 05 2020]. University, O., 1991. A Concise Dictionary of Law. s.l.:Oxford University Press.