ONTARIO COLLEGE OF ART AND DESIGN UNIVERSITY REQUEST FOR QUOTATION FOR General Contracting Services for Interior Renovations for Level 7 & 11 of 230 Richmond St W, Toronto, Ontario, M5V 1V3 RFQ Ref No: 2015- 101 Closing Date and Time: Dec 01, 2015 at 2:00 pm EST Procurement Contact: Sahil Chishti, Procurement Specialist schishti@ocadu.ca Tel: 416-977-6000, ext. 213 November 2015 Table of Contents 1. SUMMARY OF MANDATORY REQUIREMENTS ............................................................. 4 2. DEFINITIONS .................................................................................................................... 5 3. INTRODUCTION ................................................................................................................ 8 4. BACKGROUND AND OVERVIEW .................................................................................... 8 5. PROJECT DESCRIPTION ................................................................................................. 9 5.1 5.2 5.3 5.4 5.5 5.6 5.7 5.8 5.9 5.10 Scope of Work ........................................................................................................ 9 Working Hours .......................................................................................................10 Commencement and Completion Date ..................................................................11 Notice of Project ....................................................................................................11 Designated Subcontractors: ...................................................................................11 Coordination with Owners’ Subcontractors ............................................................12 Record Drawings, And As Built: .............................................................................12 Security of the Site While Work Is Being Performed...............................................13 Existing Utilities and Systems ................................................................................13 Schedule of Timeline and Deliverables ..................................................................13 6. MANDATORY SITE VISIT AND INFORMATION SESSION .............................................13 7. QUALIFICATION OF THE BIDDER: .................................................................................14 7.1 7.2 8. RESPONSES SUBMITTED ONLY IN PRESCRIBED MANNER.......................................14 8.1 8.2 8.3 8.4 8.5 8.6 8.7 8.8 8.9 8.10 8.11 8.12 9. The bidder shall provide qualification information which shall include:- ..................14 To qualify for award of the contract, the bidder:- ....................................................14 Submission Requirements - Preparation Of Bid Response ....................................15 Mandatory Requirements: ......................................................................................15 Revisions and Withdrawals of Bids ........................................................................16 Changes to RFQ ....................................................................................................16 Enquiries................................................................................................................17 One Response .......................................................................................................17 Oral Information .....................................................................................................17 Incomplete Responses ..........................................................................................17 Verification .............................................................................................................17 Misleading Information ...........................................................................................17 Bid Validity Period ..................................................................................................18 Bid Deposit ............................................................................................................18 CONFLICT OF INTEREST ................................................................................................18 10. EVALUATION AND ACCEPTANCE OF BIDS..................................................................18 11. AWARD OF PROJECT .....................................................................................................19 12. LITIGATION ......................................................................................................................20 Facilities Planning & Management Page 2 o Request for Quotation RFQ # 2015-101 Interior Renovations for Level 7 & 11 of 230 Richmond St W, Toronto, ON M5V 1V3 13. BUSINESS INFORMATION AND REQUIREMENTS ........................................................20 13.1 13.2 13.3 13.4 13.5 13.6 13.7 13.8 13.9 13.10 13.11 13.12 13.13 Form and Term of Agreement ................................................................................20 OCAD University Purchasing Policies and Procedure ............................................21 OCAD University Health & Safety Requirements ...................................................21 Occupational Health and Safety Review & Audit ....................................................21 No Guarantee of Volume of Work or Exclusivity .....................................................21 Materials and Copyright .........................................................................................21 Indemnity ...............................................................................................................22 Compliance with Laws, Regulations and Standards ...............................................22 Insurance ...............................................................................................................23 WSIB Clearance ....................................................................................................23 Confidential Information .........................................................................................24 Assignment and Subcontracting.............................................................................24 Accessibility Standards for Customer Service ........................................................24 14. SHIPPING INFORMATION ...............................................................................................26 15. INVOICES .........................................................................................................................26 APPENDIX A: PROPOSAL SUBMISSION FORM ...................................................................27 APPENDIX B: BID BONDS ......................................................................................................28 APPENDIX C: BID SUBMISSION FORM .................................................................................30 APPENDIX D: CONFLICT OF INTEREST DECLARATION .....................................................31 APPENDIX E: SUB-CONTRACTORS & SUPPLIERS .............................................................32 APPENDIX F: QUALIFICATION INFORMATION .....................................................................33 APPENDIX G: ACKNOWLEDGEMENT FORM .......................................................................34 APPENDIX H: CERTIFICATE OF INSURANCE ......................................................................35 APPENDIX I: ARCHITECTURAL, MECHANICAL, ELECTRICAL DRAWING AND SPECIFICATIONS PACKAGE ..........................................................................................36 APPENDIX J: PROJECT MANUAL ........................................................................................37 APPENDIX K ............................................................................................................................38 Facilities Planning & Management Page 3 of 46 Request for Quotation RFQ # 2015-101 Interior Renovations for Level 7 & 11 of 230 Richmond St W, Toronto, ON M5V 1V3 1. SUMMARY OF MANDATORY REQUIREMENTS Following is a list of requirements that must be satisfied in order for a Bid Submission in response to this RFQ to be considered. Please check and confirm the following before submitting the Bid Sl No 1 Page No Items to be checked 13 Mandatory site visit attendance (Section 6) on November 17, 2015 at 1:30pm Project Manager with Five years’ experience (Section 7) Minimum Annual volume of construction work of $2,400,000.00 in any of the last three years (Section 7) Completed as prime contractor in the construction of at least two similar works during the last five years value of minimum $ 950,000 each (Section 7) Electronic Bid Submission (EBS) through the use of MERX (Section 8) Bid is valid up to 90 days from date of tender closing date (Section 8.11) Contractor’s Appendixes has been signed by Director (Top Management) of the Company 2 3 4 13-14 5 14 6 17 7 Appendixes A, C, D,E, F &G Yes / No Documents to be submitted with the Bid Sl No 1 Page No 2 3 4 23 Appendix A Appendix B 5 6 7 8 Appendix C Appendix D Appendix E Appendix F 9 10 Appendix G Appendix H Documents 13-14 Yes / No Project Manager Resume with Five years’ experience in works of an equivalent nature and volume (Section 7) Current valid WSIB clearance certificate (Section 13.10) Proposal Submission Form Bid Bond for the value of 10% of the contract value, valid for a period of One-Hundredth-five (105) days following the bid closing date Bid Submission Form Conflict of Interest Declaration Form List of Sub-Contractors Qualification Information; List of Projects executed in last Five years, showing Value of the project. (Please fill up the form carefully and completely) Health & Safety Acknowledgement Form Valid certificate of Insurance demonstrating the required insurance coverages (Section 13.9) NOTES: Please read the RFQ for the full list of documents to be submitted. This may not be a complete list. PLEASE DO NOT SUBMIT THIS CHECKLIST WITH YOUR BID Facilities Planning & Management Page 4 of 46 Request for Quotation RFQ # 2015-101 Interior Renovations for Level 7 & 11 of 230 Richmond St W, Toronto, ON M5V 1V3 2. DEFINITIONS The terms listed below shall have the following meanings in this document: “Addendum” or “Addenda” means written amendment(s) to this RFQ issued by OCAD University. “Award” means to accept the offer of the Preferred Respondent for the provision of the goods and/ or services contemplated by this RFQ. “Bid” means a price quotation (in $CAD) included as part of a submission in response to this RFQ. “Conditional Award” means an award that is not finalized unless any attached conditions, such as OCAD U Board of Governors approval, are met to the satisfaction of OCAD U acting in its sole discretion. “Consultant” means the person or entity engaged by OCAD U and identified as such in the Contract Agreement and may be an Architect, an Engineer or any such other professional entity licensed to practice in the Province of Ontario. The term Consultant also means the Consultant’s authorized representative. “Contract Agreement” means the contract signed by OCAD U and the Successful Respondent, including any Purchase Order submitted by OCAD U to the Successful Respondent, for the provision of the goods and/ or services contemplated by this RFQ. “Contract Price” means the dollar amount stipulated in the Contract Agreement for completion of the Work, excluding applicable taxes. “Contractor” means the legal entity bound by a Contract Agreement with OCAD U to provide the goods and/ or services contemplated by this RFQ. “Evaluation Team” means individuals designated by OCAD U to review all valid Bids and assess, in their sole discretion, the compliance and viability of all received Bids and identify the Preferred Respondent yielding the best offer to the benefit of OCAD U. “Financial Viability” means the assessment of the Evaluation Team, acting in its sole discretion, of the positive financial condition of a Respondent that supports the Respondent’s ability to deliver on the performance requirements of the RFQ Documents. “GC” means General Contractor. “HST” means Harmonized Sales Tax as applied in the Province of Ontario. “HVAC” means Heating, Ventilation and Air Conditioning. “Itemized Price” means a price, exclusive of applicable taxes, attached to any specified component of the Bid Price. Facilities Planning & Management Page 5 of 46 Request for Quotation RFQ # 2015-101 Interior Renovations for Level 7 & 11 of 230 Richmond St W, Toronto, ON M5V 1V3 “Letter of Intent” means the written confirmation from OCAD U issued to the Preferred Respondent that confirms the intent of OCAD U to enter into a Contract Agreement with the Preferred Respondent. “Mandatory Requirement” means a condition that must be met or fulfilled, failure of which shall result in the Disqualification of the Bid. “MUA” means Make-up Air, ventilation and air conditioning unit. “OCAD University” or “OCAD U” means Ontario College of Art & Design University. “OEM” means Original Equipment of Manufacturer. “Owner” means OCAD University. “Preferred Respondent” means the Respondent achieving the highest Bid Score from the Evaluation Team. “Prime Cost Sum” means a fixed dollar amount included in the Contract Price (inclusive of all labour, material, equipment and supervision, but exclusive of applicable taxes) to cover a particular portion of the Work to be carried out by a nominated Supplier/ Vendor or trade contractor. “Project” means the entirety of the goods and/ or services contemplated by OCAD U of which the Work may be the whole or a part. “Project Manager” means a designated OCAD U representative or the person or entity engaged by OCAD U to oversee implementation of the entire Project including the Work. “Project Team” means the designated OCAD U representative(s), the Project Manager, the Consultants and any additional professionals engaged by OCAD U to oversee execution of the Project. “Respondent” means any corporation, partnership, individual or joint venture responding to this RFQ. “Respondent Team Member(s)” means any member of the group proposed by the Respondent, including individuals and/ or subcontractors/ suppliers/ vendors, identified in the Respondent’s Bid submission to execute the Work. “Bid Opening” means the opening by the Evaluation Team of all Bids received in accordance with the requirements of the RFQ Documents. “Bid Package” means the parcel (envelope or box) containing all the documents and information the Respondent is submitting in response to this RFQ. “Bid Score” means the aggregate of all Rated Criteria points achieved by each individual Bid. “Bid Submission Form” means Appendix A included with the RFQ Documents. Facilities Planning & Management Page 6 of 46 Request for Quotation RFQ # 2015-101 Interior Renovations for Level 7 & 11 of 230 Richmond St W, Toronto, ON M5V 1V3 “Rated Criteria” means those criteria described in the RFQ Documents that will be scored by the Evaluation Team to assess the Bid of each Respondent. Respondents must demonstrate they can meet all Rated Criteria. “RFQ” means this Request for Quotation, including all attached Appendices, Schedules and/ or Drawings. “RFQ Closing Date” means the latest date by which all Bids must be delivered to OCAD U in the prescribed manner in order to be considered. “RFQ Closing Time” means the specific time in Toronto, Canada on the RFQ Closing Date by which all Bids must be delivered to OCAD U in the prescribed manner in order to be considered. “RFQ Documents” means this complete RFQ with all attached Appendices and all issued Addenda. “Successful Respondent” means the Respondent selected by OCAD U as a result of the evaluation and award process, to enter into a Contract Agreement with OCAD U to provide the goods and/ or services contemplated by the RFQ Documents. “Supplier” means any legal entity from which OCAD U may purchase goods and/ or services. “University” means Ontario College of Art & Design University. “Vendor” means any legal entity from which OCAD U may purchase goods and/ or services. “Work” means the entirety of goods and/ or services required by the RFQ Documents. “Work Delivery Approach” means the approach described by the Respondent in its Bid that it intends to apply in executing the Work. “WSIB” means The Workplace Safety and Insurance Board (of Ontario). Note: all times listed in this RFQ shall be local time in Toronto, Ontario, Canada. Facilities Planning & Management Page 7 of 46 Request for Quotation RFQ # 2015-101 Interior Renovations for Level 7 & 11 of 230 Richmond St W, Toronto, ON M5V 1V3 3. INTRODUCTION OCAD University solicits offers on the attached Bid Form for our Interior Renovation for Level 7 & 11 of 230 Richmond St W project. The Facilities Planning & Management office of OCAD University seeks a General Contractor to provide all labour, materials, equipment and supervision to construct approximately 6,000 sq. ft. on the 7th floor + approximately 6,000 sq. ft. on the 11th floor interior office renovation project of 230 Richmond St. W. Toronto, ON, In accordance with the drawings and specifications including any addenda issued during the time of bidding. The successful Respondent will work with the OCAD U consultant and OCAD University’s designated Project Manager to deliver the project in accordance with the drawings and specifications included with this document. This RFQ is intended to assist Respondents in gaining an understanding of the particular requirements of the Project for OCAD U. However, each Respondent is responsible for verifying all the information required for its Bid. Please be advised that OCAD U is under no obligation to proceed with the Project after receiving and evaluating Bids, and that under no circumstances will any Respondent receive payment of any kind from OCAD U for the preparation and submission of any Bid in response to this RFQ. 4. BACKGROUND AND OVERVIEW OCAD University (www.ocadu.ca) is Canada’s “university of the imagination.” The University, founded in 1876, is dedicated to art and design education, practice and research and to knowledge and invention across a wide range of disciplines. OCAD University is building on its traditional, studio-based strengths, adding new approaches to learning that champion cross-disciplinary practice, collaboration and the integration of emerging technologies. In the Age of Imagination, OCAD University community members will be uniquely qualified to act as catalysts for the next advances in culture, technology and quality of life for all Canadians. OCAD University is occupying an additional 40,000 square feet at 230 Richmond St. W., a former commercial office building which already houses the university’s Marketing and Communications, Development & Alumni Relations, Imagination Catalyst, Visual Resources & Archives, and the Admissions & Recruitment teams. This expansion is enabled, in part, through a recently concluded joint-venture arrangement with Hullmark Developments, in which Hullmark and OCAD U will share the ownership of 230 Richmond St. W. and the adjacent brick-and-beam building at 240 Richmond St. W. The arrangement clears the way for several important space-use opportunities, such as this project, which involves the relocation of, Payroll/HRIS, Human Resources, Finance, Facilities Planning & Management Page 8 of 46 Request for Quotation RFQ # 2015-101 Interior Renovations for Level 7 & 11 of 230 Richmond St W, Toronto, ON M5V 1V3 and IT Enterprise onto the 7th floor, from a variety of different locations throughout the University, and the Offices of the President and Vice Presidents onto 11th floor of 230 Richmond St. W. The 7th and 11th floors are currently vacated and demolished. The objective of the project is to consolidate, the administrative functions of the University into one location. The Facilities Planning & Management office now seeks a General Contractor to provide the professional services required to work with OCAD U staff, an Architect, and Engineering Consultants to bring the Project to completion on time as per Deliverables listed in Section 5.10. The Successful Respondent, if any, shall be awarded a CCDC-2 (2008) form of Stipulated Price Contract. 5. PROJECT DESCRIPTION 5.1 Scope of Work The Contractor shall furnish all labour, materials, equipment and supervision to implement this project at 230 Richmond St. W 7th & 11th floors, Toronto, in accordance with the drawings and specifications including any addenda issued during the time of bidding. Refer to the attached; Architectural, Mechanical, Electrical drawings, and Specifications and Project Manual. The Successful Respondent shall provide professional General Contractor services to manage the renovation process in accordance with the tender drawings and specifications. These services shall include but not be limited to the following: This scope is high level information only and is intended to compliment all drawings, specifications and other documentation in support of this work. It is not intended to be a complete and comprehensive list. 5.1.1 5.1.2 5.1.3 5.1.4 Contractor is responsible to check, confirm and coordinate all site measurements and conditions, including plumb of the existing surfaces. Contractor is expected to be able to perform the work during regular business hours and/or after hours as required, being mindful that the work area is adjacent to occupied offices and/or classrooms. Appropriate measures shall be employed to protect adjacent areas from dust and intrusive noise Contractor shall perform the work as per the requirements of OCAD U Contractor duties and responsibilities, as outlined in the OCAD U Health and Safety requirements for Contractors (see Section 13.3 & 13.4), including loading, debris removal, hours of work, coordination of elevator and other facilities as required. Any surplus doors, hardware and light fixtures shall be offered to OCAD U for their inventory prior to disposal. If OCAD U deems the material to Facilities Planning & Management Page 9 of 46 Request for Quotation RFQ # 2015-101 Interior Renovations for Level 7 & 11 of 230 Richmond St W, Toronto, ON M5V 1V3 5.1.5 5.1.6 5.1.7 be re-useable, the Contractor shall relocate the materials to the storage room identified by OCAD U. Contractor shall provide daily morning spot cleaning/dusting, and protect existing equipment and finishes from damage and/or dust for the duration of the work. Contractor shall remove all debris and material from the site upon completion of the work, and provide a thorough cleaning and dusting, so that the renovated spaces are ready for use. Contractor to enclose work area in clear Poly to eliminate the travel of dust to other areas of the building. 5.1.8 Contractor to notify OCAD U of loud noise and smells that are deemed to affect adjacent occupied offices and classrooms. 5.1.9 Contractor shall manage all sub-contractors and coordinate work as required with the OCAD U Facilities Planning & Management departments. 5.1.10 Removal and disposal of any existing materials not part of the current scope of work as indicated in the attached construction documents. Patching and making good of existing finishes to match new work as indicated in the attached Construction Documents and any areas damaged by trades during the work. Cooperate with Owner and/or Owner's agents for general work and maintaining regular building functions for the duration of the construction period. Prior approval must be obtained where any systems are to be shut down that may affect the operation of the building. Any and all associated costs for shutdowns are the sole responsibility of the Contractor. Apply and pay for all necessary right of way permits to accommodate the work as required and/or specified on the contract documents. Furniture and Equipment (Nil) 5.1.11 5.1.12 5.1.13 Note: Any and all associated costs for the contractor to provide a fire watches will be at the sole cost of the contractor. 5.2 Working Hours 5.2.1 Working hours for project work are at the discretion of the Contractor. The owner reserves the right to stop any disruptive work during the hours shown below in section 5.2.2, and request to have this work completed at a different time at no cost to OCAD University. 5.2.2 Normal business hours are 8:00 am to 5:00 pm Monday to Friday. 5.2.3 The Contractor must work around the Owners existing delivery dates and storage requirements. The area of construction is to be clearly delineated and signed for safety purposes at all times, including access to exits, and clear paths of travel. Facilities Planning & Management Page 10 of 46 Request for Quotation RFQ # 2015-101 Interior Renovations for Level 7 & 11 of 230 Richmond St W, Toronto, ON M5V 1V3 5.2.4 Saturday and Sunday work is permitted with prior notification to the owner. No additional payment for Saturday and Sunday and after hours work will be permitted. The General Contractor must schedule accordingly and include afterhours work within their bid price. Note: The 230 Richmond St. W. building is partially occupied, and undergoing other renovations projects at the same time. As a result, it is critical that the General Contractor coordinate the use of the loading dock and freight elevator for delivery and removal of all material and equipment with OCAD U designate. 5.3 Commencement and Completion Date 5.3.1 The start date of this Contract is within seven days of purchase order issuance and signed CCDC2 by the Owner. Award is conditional on all approvals being in place. Continuous and progressive operation shall be carried out until the work is completed. 5.3.2 Completion date of the Contract may be extended subject to the required approvals being obtained. 5.3.3 The Contractor and all Subcontractors will be required to sign in with the security desk at 100 McCaul St. where they will be issued Contractor cards to access the site. 5.3.4 The anticipated completion date for all work under this Contract is to be May 04, 2016. 5.3.5 The General Contractor is responsible to provide any and all the forces necessary to complete the work within the specified timeframe. 5.4 Notice of Project Contractor shall file a Notice of Project (Form 0175) with the Province of Ontario Ministry of Labour and provide a copy of that Notice to the OCAD University Facilities Planning & Management Department. 5.5 Designated Subcontractors: The following are sub-contractors for work indicated. Include their work into the base Contract Price. Door Hardware, Locks and Stops: Lock-up Services Attn: Chris Wright 2977A Lakeshore Blvd W Toronto, ON M8V 1J8 T: (416) 255-3500 F: (416) 255-8492 M: (416) 553-0570 Facilities Planning & Management Page 11 of 46 Request for Quotation RFQ # 2015-101 Interior Renovations for Level 7 & 11 of 230 Richmond St W, Toronto, ON M5V 1V3 Security Devices: AC Technical Systems Attn: Guy DiGiorgio, Account Representative 2100 Forbes St. Unit 8-10 Whitby, ON L1N 9T3 T. (905) 666-8676 F. (905) 666-9795 M (905) 261-1617 Fire Safety ProFire Safety Services Attn: Satish Patel #1 - 15 Kenview Blvd Brampton, ON L6T 5G5 T. (416) 410-7221 F. (905) 799-6439 info@profire.ca 5.6 Coordination with Owners’ Subcontractors 5.6.1 5.6.2 5.6.3 5.7 The contractor will cooperate with maintenance personnel and security personnel to facilitate the work of the contract. The Owner will not coordinate any work of the designated subcontractors. All designated subcontractors to be the responsibility of the general contractor and be co-ordinated accordingly to perform the work of the contract. The contractor will co-operate with the Owner's sub-trades and staff to facilitate any on-going work within the building. Record Drawings, And As Built: 5.7.1 Maintain a complete set of record drawings and specifications throughout the duration of the work of the contract on site. 5.7.2 The project close out documents (including as-built) and the Operations and Maintenance manuals must be submitted by the general contractor and accepted by the Project Administrator before the Certificate of Substantial Performance can be certified by the Prime Consultant. 5.7.3 Refer to technical specifications for additional requirements regarding as-built drawings and Substantial Performance. Facilities Planning & Management Page 12 of 46 Request for Quotation RFQ # 2015-101 Interior Renovations for Level 7 & 11 of 230 Richmond St W, Toronto, ON M5V 1V3 5.8 Security of the Site While Work Is Being Performed While work is being performed access to the facility will be granted to the General Contractor. The General Contractor is solely responsible for securing the site and protecting their equipment while trades are working at all times. 5.9 Existing Utilities and Systems The Contractor is fully responsible for the protection of all utilities and operating systems either shown on the drawings or which are existing and/or any utility locates. 5.10 Schedule of Timeline and Deliverables Following are the dates for milestones and deliverables expected of the Successful Respondent for this important and time sensitive Project. These dates are subject to change at the sole discretion of OCAD U: 6. Action or Deliverable Milestone / Completion Date RFQ # 2015-101 for GC Issued November 06, 2015 Mandatory Site Visit and Information Session November 17, 2015 @ 1:30 p.m. Last date for enquiries November 24, 2015 @ 3:00 p.m. Enquiry responses forwarded to all Bidders November 27, 2015 @ 4:00 p.m. RFQ # 2015-101 Closing December 01, 2015 @ 2:00 p.m. General Contractor selection December 15, 2015 Commencement of the Work January 04, 2016 Substantial Completion May 04, 2016 Complete deficiency correction May 11, 2016 MANDATORY SITE VISIT AND INFORMATION SESSION On [November 17, 2015] at 1:30 p.m. all Respondents must attend a mandatory site visit at OCAD U, meeting in the lobby of the 230 Richmond St W, Toronto, ON M5V 1V3. Disqualification shall result for any Respondents who do not attend this meeting. Respondents are requested to carefully review all documents issued or associated with this RFQ prior to attending this meeting. The purpose of this meeting is to review the site conditions and answer any questions, clarify and/ or correct any error, inconsistency Facilities Planning & Management Page 13 of 46 Request for Quotation RFQ # 2015-101 Interior Renovations for Level 7 & 11 of 230 Richmond St W, Toronto, ON M5V 1V3 or omission, and to provide explanation or correct any interpretation of the RFQ documents. OCAD University will not reimburse Respondents for any cost incurred by attending this mandatory meeting. 7. QUALIFICATION OF THE BIDDER: 7.1 The bidder shall provide qualification information which shall include:7.1.1 7.1.2 7.1.3 Total monetary value of construction works performed for each year of the last 3 years; List of similar works (similar to brief description of works described in Introduction (Section 3)) satisfactorily completed as a prime contractor, member of Joint Venture or subcontractor during the last five years A Resume of the Project Manager. Note: - In the reference to work from a joint venture the submission should indicate the Lead Partner and the proportionate share of the bidder. 7.2 To qualify for award of the contract, the bidder:7.2.1 Should have executed the minimum required annual volume of construction work of $ 2,400,000 in any of the last three years. 7.2.2 Should have completed as prime contractor in the construction of at least two similar works during the last five years value of minimum $ 950,000 each. A Project Manager with five years of experience. 7.2.3 Note: - Should the bidder provided the requested information to the OCAD U in confidence while indicating that the disclosed information is confidential, than the OCAD U will treat the information in confidential manner. 8. RESPONSES SUBMITTED ONLY IN PRESCRIBED MANNER Respondents must submit a Response in accordance with the manner described below. All responses are to be submitted to OCAD University through the use of MERX Electronic Bid Submission (EBS). Applicants shall be solely responsible for the delivery of their response in the manner and time prescribed. Questions concerning submitting through MERX should be addressed to: MERX Customer Support Phone 1-800-964-6379 Email merx@merx.com Facilities Planning & Management Page 14 of 46 Request for Quotation RFQ # 2015-101 Interior Renovations for Level 7 & 11 of 230 Richmond St W, Toronto, ON M5V 1V3 For assistance in using MERX, please watch the online Electronic Bid Submission tutorial: http://www.youtube.com/watch?v=To0fqSccw3M . Alternatively, you can contact MERX directly at 1-800-964-MERX or visit the MERX website at www.merx.com IMPORTANT NOTE: It is extremely important that you obtain and retain the PIN number assigned to you by MERX in order to upload electronic proposal documents. OCAD University will not be liable for: (i) any costs incurred by any Bidder in the preparation and submission of a Bid including, (ii) any expenses, costs, losses or any direct or indirect damages incurred or suffered by any Bidder as a result of participating in, or otherwise in connection with, this RFQ. 8.1 8.2 Submission Requirements - Preparation of Bid Response 8.1.1 The Bid shall be submitted on the original Bid Form and specified Appendices issued by OCAD University. The Bid form and specified Appendices shall not be altered in any way including, but not limited to, write-ins, strike-outs or any qualifying statements. Any Bid submitted containing such alterations may be disqualified. 8.1.2 Fill in all blanks in the Bid Form and specified appendices as instructed. Bid Documents not completed in full may be rejected. Mandatory Requirements: Each Bid must include at time of closing the following: a) b) c) d) e) f) g) h) i) Appendix A Proposal Submission form Appendix B Bid Bond form Appendix C Bid Submission form Appendix D Conflict of Interest Declaration form Appendix E List of subcontractors form Appendix F Qualification information Appendix G Acknowledgement Form Appendix H Certificate of Insurance demonstrating the required insurance coverages noted in Section 13.9 Current valid WSIB clearance certificate 8.2.1 Proposal Submission form and Bid Form must be executed with an original signature by an individual with authority to bind the Bidder. Failure to submit a signed Proposal Submission and Bid Form specified Appendices and all the required forms above will result in disqualification of the Bid. 8.2.2 Every Bid shall be accompanied by an Electrical Bid Bond as per CCDC-220 provided format – Appendix B in the specified amount (refer to Section 8.12 Bid Deposit) signed by a guarantee surety company Facilities Planning & Management Page 15 of 46 Request for Quotation RFQ # 2015-101 Interior Renovations for Level 7 & 11 of 230 Richmond St W, Toronto, ON M5V 1V3 8.2.3 8.2.4 8.2.5 8.3 8.4 lawfully doing business in the Province of Ontario, Failure of a Bidder to submit a fully completed Electrical Bid Bond via MERX in the form enclosed in Appendix B, shall result in the Bid being rejected as noncompliant. (Scan copy of the regular Non-Electrical Bid Bond is Not Acceptable) Bid Submission form – Appendix `C’ must be completed in full and include a monetary amount on all the line items. If any line item is left blank or contains an entry other than a monetary amount, the bid will be disqualified. $0.00 qualifies as an entry. The list of subcontractors form - Appendix `E’ shall be submitted by each Bidder. OCAD University reserves the right to review the list of subcontractors provided by each Bidder and in its sole discretion, request the substitution of any subcontractor proposed. Qualification Information – Appendix `F’ shall be completed and submitted to OCAD U. Qualification information will be a base for evaluation of the bids. Failure of a Bidder to submit a fully completed Qualification Information via MERX in the form enclosed in Appendix F shall result in the Bid being rejected as non-compliant. Revisions and Withdrawals of Bids 8.3.1 Revisions to a submitted Bid will be permitted if the revision is received prior to Bid Closing and signed by a duly authorized officer of the Bidder. Revisions are to be submitted via MERX prior to the Bid closing. 8.3.2 Revisions received after the Bid Closing will not be considered 8.3.3 Bids may be withdrawn at any time prior to the Bid Closing via MERX 8.3.4 Bidders submitting a revised Bid must re-submit all documentation stated in Section 8.2 prior to the Bid closing. Failure to submit all required forms as indicated in Section 8.2 will result in disqualification. Changes to RFQ Any changes or revisions to the RFQ will be issued as a formal addendum to all Respondents via MERX. . Each addendum shall form an integral part of this RFQ. If any addendum is issued, OCAD University may, in its discretion, extend the Response submission deadline for a reasonable period of time. 8.4.1 8.4.2 Respondents are advised to check the tender listing on MERX regularly for any such Addenda, which will be consecutively numbered and shall form an integral part of the RFQ Documents. Respondents shall insert, in the space provided in the RFQ Response Form, the Addenda numbers of all Addenda issued prior to the RFQ Closing, including any Addenda bound into the Specifications. Failure to acknowledge receipt of all Addenda issued on the RFQ Response Form will result in disqualification of such Bid. Facilities Planning & Management Page 16 of 46 Request for Quotation RFQ # 2015-101 Interior Renovations for Level 7 & 11 of 230 Richmond St W, Toronto, ON M5V 1V3 8.5 Enquiries No Respondent may claim any advantage from any error, inconsistency or omission in this RFQ. Any Respondent who has questions as to the meaning of any part of this RFQ or the project, or who believes the RFQ contains any error, inconsistency or omission, must make a written enquiry prior to Nov 24, 2015 at 3:00 pm requesting clarification, interpretation or explanation in writing to the attention of; Sahil Chishti, Procurement Specialist schishti@ocadu.ca OCAD University will not be required to respond to late or verbal enquiries. OCAD University reserves the right to distribute any and all questions and answers to all other Respondents. Respondents are requested NOT to make verbal inquiries of OCAD University staff and are reminded that oral information provided to any Respondent will not be binding on OCAD University. 8.6 One Response Respondents may not submit more than one Response. 8.7 Oral Information No information given orally by OCAD University or by means of telephone or email will be binding nor will it be construed as to change the requirements of the RFQ in any way. 8.8 Incomplete Responses OCAD University reserves the right to reject any Response whether or not completed properly and whether or not it contains all required information. Without prejudice to this right, OCAD University may request clarification, including supplementary information related to the clarification, where any Respondent's intent is unclear and may waive or request amendment where in the opinion of OCAD University there is a MINOR irregularity or omission in the information that is to be submitted in a required document. Any response by the Respondent to such a request shall, if accepted by OCAD University, form an integral part of the Respondent’s Response. 8.9 Verification The Respondent agrees OCAD University may, if deemed necessary, verify any information provided in any Response. 8.10 Misleading Information If there is any evidence of misleading or false information having been given, OCAD University may, at its sole discretion, reject the Response. Facilities Planning & Management Page 17 of 46 Request for Quotation RFQ # 2015-101 Interior Renovations for Level 7 & 11 of 230 Richmond St W, Toronto, ON M5V 1V3 8.11 8.12 9. Bid Validity Period 8.11.1 Unless otherwise specified in the RFQ, tenders are to remain firm and in effect for a period of ninety (90) days following the Tender Closing Time. 8.11.2 Notwithstanding Article 8.11.1, in the event the OCAD U deems it necessary to extend the ninety (90) day period for acceptance of tenders for a further ninety (90) day period, the OCAD U shall, prior to the expiration of such period, notify the tenderer by written notice to that effect, whereupon the tenderer shall have fifteen (15) days from the date of receipt of such written notice to, in writing, either accept the requested extension as referred to in the OCAD U notice or withdraw its tender. 8.11.3 In the event tender security was provided and in the event of withdrawal of tender as herein provided, the Tender Security Deposit shall be reimbursed or returned without penalty or interest. In the event the tenderer accepts the requested extension, the acceptance period shall be extended as referred to in the OCAD U notice. In the event the tenderer does not respond to the OCAD U notice hereinabove referred to, the tenderer shall be conclusively deemed to have accepted the extension referred to in the OCAD U notice. Bid Deposit 8.12.1 Each Bidder shall include a Bid deposit in the form of an Electrical-Bid Bond payable to the OCAD U in the amount of 10% of the Bid price. 8.12.2 Electrical-Bid Bonds shall be submitted on CCDC-220 Form and shall remain valid for a period of One-Hundredth-five (105) days following the Bid closing date. 8.12.3 Should the successful Bidder fail to enter into a Contract with the OCAD U or fail to start work as directed, the bid deposit will be forfeited to the OCAD U. CONFLICT OF INTEREST The Respondent is required to disclose any real, apparent or potential conflict of interest that comes to its attention in preparing its Response, during the evaluation or during the term of any subsequent agreement. The Respondent shall accept any determination by OCAD University, including any requirements to withdraw from the bidding or agreement. 10. EVALUATION AND ACCEPTANCE OF BIDS 10.1 OCAD U will evaluate and compare the bids determined to be substantially responsive i.e. which 10.1.1 Meet the qualification criteria and mandatory requirements specified in section 7 and 8.2 above; Facilities Planning & Management Page 18 of 46 Request for Quotation RFQ # 2015-101 Interior Renovations for Level 7 & 11 of 230 Richmond St W, Toronto, ON M5V 1V3 10.1.2 10.1.3 10.2 Are properly signed (Proposal and Bid submission forms) ; and Conform to the terms and conditions, Specification and drawings without material deviations. In evaluating the bids, OCAD U will determine for each proposal the evaluated price bid by adjusting the price bid by making any correction for any arithmetic errors as follows: 10.2.1 If there is a discrepancy between words and figures, the amount in words shall prevail. 10.2.2 If a Contractor refuses to accept the correction, his bid will be rejected. 10.3 OCAD U shall not be obliged to accept any bid in response to this tender call. 10.4 OCAD U may modify and/or cancel this tender call prior to accepting any bid. 10.5 Bids may be accepted or rejected in total or in part. 10.6 The lowest quoted price may not necessarily be accepted by OCAD U. 10.7 In determining which bid provides the best value to OCAD U, consideration may be given to the past performance of any bidder. 10.8 OCAD U reserves the right to request clarifications of information submitted in the bid and may reject any bid where, in OCAD U’s sole estimation, the contents appear to be incorrect, inaccurate or inappropriate based on responses to the request for clarification. 10.9 OCAD U reserves the right to request clarifications to assess the ability of the bidder to perform the contract and may reject any bid where, in OCAD U’s sole estimation, the personnel and/or resources of the bidder are insufficient based on responses to the request for clarification. 10.10 OCAD U reserves the right to request clarifications from any bidder that appears to have underestimated the value of the goods and/or services to be provided as reflected in its submitted price/fee, OCAD U may reject its bid as unbalanced (i.e., not representative of the scope of the goods and/or services). OCAD U may reject a bid if it determines, in its sole discretion that the bid is materially unbalanced following response to the request for clarification. 11. AWARD OF PROJECT OCAD University will have the right to select from among the Responses received, one or more Respondents to whom the project will be awarded. OCAD University reserves the right in its sole discretion and for any reason whatsoever: To accept or to reject any or all Responses in whole or in part; Not to proceed with all or any part of the project; Facilities Planning & Management Page 19 of 46 Request for Quotation RFQ # 2015-101 Interior Renovations for Level 7 & 11 of 230 Richmond St W, Toronto, ON M5V 1V3 The acceptance of a Bid and the award of the contract or any part thereof will be made by OCAD University in writing and only in writing, in the form of a Purchase Order and CCDC2 (2008) contract with OCAD U supplementary conditions for the CCDC2 (2008) contract. In the event that the successful Respondent fails or refuses to enter into and duly execute an agreement acceptable to OCAD University within ten (10) business days after OCAD University gives notice of the award of an agreement, or such other time as is stipulated by OCAD University, OCAD University reserves the right, at its sole discretion, to award the agreement to another Respondent, not to accept any Response, or to call for a new response, and the defaulting Respondent shall be liable for all losses, damages, costs and expenses (including consequential losses and damages, and legal fees on a solicitor and client basis) suffered or incurred by OCAD University as a direct or indirect result thereof, including but not limited to any increase in the price of performance over the price submitted by the defaulting Respondent in its Response. 12. LITIGATION OCAD University may, in its absolute discretion, reject a Respondent’s Response if the Respondent, or any officer or director of the Respondent, is or has been involved within five (5) years of the date of this RFQ, either directly or indirectly through another corporation, (i) in a legal action taken by OCAD University, any of its Board members, officers or employees in connection with any matters related to OCAD University, or (ii) in a legal action against OCAD University, any of its Board members, officers or employees, in connection with any matter related to OCAD University, including without limitation, arising from OCAD University’s exercise of its powers, duties or functions. 13. BUSINESS INFORMATION AND REQUIREMENTS The following Section 13 Business Requirements and all the sections found in Appendix “A” - Proposal Submission Form are requirements that are non-negotiable. Respondents submitting a Response with alterations, revisions, changes, and/or conditions to any of part of this Section and/or any parts of the sections found in Appendix “A” - Proposal Submission Form will not be considered and the Response will be disqualified. 13.1 Form and Term of Agreement The Successful Respondent shall be required to enter into a Contract Agreement with OCAD U, based on the CCDC 2 (2008) Stipulated Price Agreement with Supplementary Conditions as specified by the University. 13.1.1 Where the provisions of this RFQ conflict with those included in the Contract Agreement, the provisions of this RFQ shall supersede. 13.1.2 OCAD U reserves the right to renew the term of the Contract Agreement awarded under this RFQ for up to one (1) month at its sole discretion, upon thirty (30) days prior written notice to the Successful Respondent. OCAD University reserves the right to cancel such contract for convenience upon thirty days (30) prior written notice to the Successful Respondent. 13.1.3 Payments terms will be set out in contract terms and conditions. Facilities Planning & Management Page 20 of 46 Request for Quotation RFQ # 2015-101 Interior Renovations for Level 7 & 11 of 230 Richmond St W, Toronto, ON M5V 1V3 13.2 OCAD University Purchasing Policies and Procedure It is the responsibility of all Respondents to be cognisant of the OCAD U Purchasing Policies & Procedure, copy of which can be found on the OCAD U website under About OCAD U, Administrative Policies, Section 9000 Finance, Policy # 9001 (click the following link or copy & paste in browser). OCAD U Purchasing Policies & Procedures Manual.pdf 13.3 OCAD University Health & Safety Requirements It is the responsibility of all Respondents to be cognisant of and satisfy the OCAD U Health & Safety Requirements for Contractors, copy of which can be found on the OCAD U website under Administrative Policies, Section 5000 Risk Management / Health & Safety, Policy # 5006 (click the following link or copy & paste in browser). OCAD U Health & Safety Requirements for Contractors.pdf Respondents should complete the Acknowledgement Form Included in this RFQ document as APPENDIX G and include it with their Bid Submission. 13.4 Occupational Health and Safety Review & Audit At all times, while working at any OCAD University property, the successful Bidder will be responsible for all aspects of Health and Safety including, the strict adherence to all applicable provisions of the Ontario Occupational Health and Safety Act (OHSA) and the applicable regulations. The successful Bidder shall submit to OCAD University, upon request by OCAD University, a copy of the Bidder’s Occupational Health and Safety Policy and program developed to implement its Occupational Health and Safety Policy. The successful Bidder’s Occupational Health and Safety Policy and program shall comply with all requirements of Ontario Regulation 213/91, Regulations for Construction Projects, under the Occupational Health and Safety Act (Ontario), as amended from time to time. 13.5 No Guarantee of Volume of Work or Exclusivity OCAD University makes no representation or guarantee as to the value or volume of work to be assigned to the successful Respondent. The contract that will be executed with the successful Respondent will not be an exclusive contract for the supply of the services described in this RFQ. OCAD University may contract with other Respondents for the same or similar services as those described in this RFQ. 13.6 Materials and Copyright All designs, drawings, sketches, graphic representations, specifications, computer generated designs, papers, data, reports, plans and other materials and documents created by the Successful Respondent to carry out the services Facilities Planning & Management Page 21 of 46 Request for Quotation RFQ # 2015-101 Interior Renovations for Level 7 & 11 of 230 Richmond St W, Toronto, ON M5V 1V3 to be performed for OCAD U (the Materials) will be the property of OCAD U and the Successful Respondent shall not make any use of the same, except with prior written approval of OCAD U. The Successful Respondent agrees that all right, title and interest in the Materials prepared for OCAD U will vest in OCAD U and that OCAD U will have the right to copy such Materials and to use them for any purpose. The Successful Respondent shall deliver all Materials to OCAD U after completion of the projects or at termination of the Contract unless otherwise specified. 13.7 Indemnity 13.7.1 13.7.2 13.8 The Successful Respondent will indemnify and hold harmless, and upon OCAD U’s request defend OCAD U, its officers, agents, and employees from any and all losses, expenses, demands, actions, suits, claims or liabilities of whatsoever nature (including reasonable legal fees and expenses (Losses) resulting from: any injury or death to any person or any property damage caused by the Successful Respondent, its employees, agents or subcontractors; any grossly negligent act or omission, or wilful misconduct of the Successful Respondent in the performance of the Contract Agreement; or, The Successful Respondent's failure to comply with applicable law or any OCAD U policies and procedures; OCADU will indemnify and hold harmless, and upon the Successful Respondent's request, defend the Successful Respondent from any and all Losses resulting from: any injury or death to any person or any property damage caused by OCAD U; any grossly negligent act or omission, or wilful misconduct of OCAD U in the performance of the Contract Agreement; or, OCAD U's failure to comply with applicable law or any OCAD U policies and procedures. Compliance with Laws, Regulations and Standards The Successful Respondent shall comply with all applicable federal, provincial, and municipal laws, regulations, codes, ordinances, policies, directives and orders, and carry on its business in compliance with the highest professional standards prevailing in its industry. The Successful Respondent shall be responsible for providing services in a professional and competent manner by persons qualified and skilled in their occupations. If any of the services or deliverables provided are not in accordance with the requirements of the Contract Agreement, the Successful Respondent shall make the necessary corrections at its own expense. Facilities Planning & Management Page 22 of 46 Request for Quotation RFQ # 2015-101 Interior Renovations for Level 7 & 11 of 230 Richmond St W, Toronto, ON M5V 1V3 13.9 Insurance Respondents shall provide OCAD U, by inclusion with their Bid Submission, one copy of a valid Certificate of Insurance from a financially sound and reputable insurance company showing that the required liability coverages are in force. At the sole cost and expense of the Successful Respondent, the insurance policies must be maintained in full force and effect at all times throughout the term of the Contract Agreement. Required insurance coverages are as follows: 13.9.1 Comprehensive General Liability insurance in the amount of at least $5,000,000 (five million) that protects the Successful Respondent and its employees and agents, from all claims, demands, actions, and causes of action that may be taken or made against the Successful Respondent for any loss of or damage to property, or personal injury including bodily injury or death, that may arise with respect to the Successful Respondent’s performance of work as set out in the Agreement. This policy must also include contractual liability, nonowned automobile liability, completed operations coverage as well as a cross liability clause. This policy must add OCAD University as an additional insured but only with respect to and during the Successful Respondent’s performance of its obligations as set out in the Contract Agreement; 13.9.2 Automobile Liability insurance with limits of not less than $1,000,000 (one million) per occurrence, which must include legal liability for damage to non-owned automobiles. This policy must provide coverage for bodily injury or property damage arising out of the ownership, use or operation of all owned and/ or leased automobiles. 13.9.3 Errors and Omissions Liability insurance with limits of not less than $1,000,000.00. 13.9.4 These policies must provide OCAD University with thirty (30) days’ notice of cancellation or material change. Certificate(s) of Insurance evidencing the insurance coverage required in 13.9.1, 13.9.2 and 13.9.3 above, must be submitted within ten (10) days of the contract award. The insuring company must originally sign the Certificate(s). The insurance policies must be maintained in full force and effect at all times throughout the term of the contract. Note: Certificates of Insurance shall include the RFQ Document number and name. A copy of OCAD University standard Certificate of Insurance is available as a fillable form at Appendix H. 13.10 WSIB Clearance Respondents shall submit with their Bid Submission a valid WSIB Clearance Certificate. In addition, the Successful Respondent shall from time to time provide additional WSIB Clearance Certificates for the duration of the Contract Agreement (each pay draw must be accompanied by WSIB certificate). The Successful Respondent and each of its subcontractors or consultants shall Facilities Planning & Management Page 23 of 46 Request for Quotation RFQ # 2015-101 Interior Renovations for Level 7 & 11 of 230 Richmond St W, Toronto, ON M5V 1V3 remain in good standing with the WSIB. Failing this, OCAD U shall have the right to suspend or terminate the Contract Agreement until such time as a valid WSIB Clearance Certificate is provided. 13.11 Confidential Information This RFQ and the terms, conditions and pricing contained herein and in a Respondent’s submission are confidential and shall not be disclosed orally or in writing by either party without the consent of the other. The Successful Respondent (if any) acknowledges that all substantive information that may come into its possession while performing the specified work is confidential unless otherwise specifically noted and agrees to keep such information in confidence, having regard to the sensitive nature of the information and the fact that OCAD U, as a public educational institution, may be held to a higher standard of confidentiality than a non-educational institution. 13.12 Assignment and Subcontracting The Successful Respondent shall agree not to assign or subcontract ANY portion of its rights or obligations under the Contract Agreement without the prior written consent of OCAD U. The Successful Respondent shall designate in writing to OCAD U all subcontractors and shall not subsequently change such subcontractors without OCAD U's prior written approval. This provision shall be binding on the successors and permitted assigns of the Successful Respondent. 13.13 Accessibility Standards for Customer Service OCAD University is committed to improving accessibility for its students, employees, alumni, and others. While part of the impetus for this commitment is the importance of meeting the requirements of legislation related to people with disabilities (e.g., the Accessibility for Ontarians with Disabilities Act (AODA), Ontario Human Rights Code), OCAD University also recognizes that enhancing accessibility is an opportunity to improve the usability and efficiency of its built environment, communication systems and procedures for everyone. (i) Accessibility Standards for Customer Service All Respondents of this RFQ must be capable of delivering goods and services consistent with the Ontario Human Rights Code (OHRC), the Ontarians with Disabilities Act, 2001 (ODA) and the Accessibility for Ontarians with Disabilities Act, 2005 (AODA) and its regulations. In accordance with Ontario Regulation 429/07 made under the Accessibility for Ontarians with Disabilities Act, 2005, Accessibility for Customer Service, it is expected that policies and procedures are in place as outlined in the regulation by January 1, 2012. Furthermore it is expected that the Respondents may be requested to provide their policies and procedures upon request, to demonstrate compliance with the regulation. Respondents will be requested to provide their accessibility plan to ensure compliance with regulation. Ontario Higher Education institutions must be compliant with the AODA Accessibility criteria found here: Making Ontario Accessible. This includes, but not limited to - WCAG 2.0 Accessibility Standard for Information compliance for Facilities Planning & Management Page 24 of 46 Request for Quotation RFQ # 2015-101 Interior Renovations for Level 7 & 11 of 230 Richmond St W, Toronto, ON M5V 1V3 all online content, and accessibility training for all Respondent employed staff who are working on campus. Accessibility audits will be required throughout the duration of the implementation. During the Term of the Agreement, including any extensions, Suppliers shall comply with any future additions or modifications to legislation as they become enacted to accessibility standards and regulations. For more information on the ODA, please visit: Making Ontario Accessible (ii) Accessibility and Customer Service The Suppliers providing services will: 1. Ensure appropriate employees have completed the following government computer based self-passed training courses prior to the start of any work; AODA (Accessibility for Ontarians with Disabilities Act) customer service training; 2. 3. Be aware and sensitive to accessibility, disability, diversity and inclusion issues. Suppliers are to ensure that training records are maintained; this includes dates when training is provided, the number of personnel who received training and individual training records. Suppliers are to ensure that this information is available to OCAD U any time during the Term of the Contract. (iii) Definitions Accessibility: a general term used to describe the degree of ease that something (e.g., device, service, and environment) can be used and enjoyed by persons with a disability. The term implies conscious planning, design and/or effort to ensure it is barrier-free to persons with a disability, and by extension, highly usable and practical for the general population as well. Accessible: that which can be easily reached or obtained; a facility that can be easily entered; posing no obstacles to persons with a disability. Barrier-free: a quality or characteristic of environments, policies, processes or practices that enables the full participation by all members of society. Diversity: the presence of a wide range of human qualities and attributes within a group or an organization. The dimensions of diversity include, but are not limited to age, gender, race, ethnicity, physical and intellectual ability, religion, sexual orientation, educational background, and expertise. Inclusive: means an environment that accepts, utilizes, accommodates and appreciates the talents, skills, abilities, perspectives and leadership styles of all employees and clients, including all aspects of their diversity. Facilities Planning & Management Page 25 of 46 Request for Quotation RFQ # 2015-101 Interior Renovations for Level 7 & 11 of 230 Richmond St W, Toronto, ON M5V 1V3 14. SHIPPING INFORMATION The Successful Respondent may make prior arrangements with the primary OCAD U Project contact person to have required materials shipped directly to the site at the following address: OCAD University Attn: Robert Sage, Building Project Coordinator 230 Richmond St. W Toronto, ON M5V 1V3 15. INVOICES OCAD University Facilities Planning & Management Attn: Robert Sage, Building Project Coordinator 100 McCaul Street Toronto, ON M5T 1W1 Note that all invoices for this project must reference the number of the Purchase Order issued to the Contractor for the Project and show a break out of labour and materials for each invoice submitted for payment. Facilities Planning & Management Page 26 of 46 Request for Quotation RFQ # 2015-101 Interior Renovations for Level 7 & 11 of 230 Richmond St W, Toronto, ON M5V 1V3 APPENDIX A: PROPOSAL SUBMISSION FORM Full Legal Name of Proponent: Click here to enter text. ____________________________________________________________________________ Please print clearly Address: Click here to enter text. Telephone: Click here to enter text. Email: Click here to enter text. I, the undersigned, declare that I/ we have carefully examined all of the RFQ documents and Addenda # Click here to enter text. Through # Click here to enter text. As issued, visited and investigated the site, and examined all conditions and aspects affecting the Project. I/ we will complete the Works described in the RFQ within the required completion period given in the Clause 5.3.4 of the RFQ. I/ we will complete the works as per specifications and drawings enclosed to this RFQ without any deviations. I/ we understand that you are not bound to accept the lowest or any bid you receive. I/ we hereby confirm that this bid is valid for 90 days as required in Clause 8.11 of the RFQ. If notified in writing of the acceptance of this Proposal within 30 (thirty) days of the latest date specified in the RFQ document for receipt of Proposals, I/ we agree to provide all materials and perform all the services and/ or work shown and described in the RFQ document. I have the authority to bind the above named Proponent: _______________________________________________ Signature _______________________ Date __________________________________________________________ Name (please print) ____________________________________________________________________________ Title End of APPENDIX A Facilities Planning & Management Page 27 of 46 Request for Quotation RFQ # 2015-101 Interior Renovations for Level 7 & 11 of 230 Richmond St W, Toronto, ON M5V 1V3 APPENDIX B: BID BONDS BID BOND Standard Construction Document CCDC 220 - 2002 No. _ Bond Amount $ _ as Principal, hereinafter called the Principal, and a corporation created and existing under the laws of and duly authorized to transact the business of Suretyship in ----------as Surety, hereinafter called the Surety, are held and firmly bound unto as Obligee, hereinafter called the Obligee, in the amount of Dollars ($ ) lawful money of Canada, for the payment of which sum the Principal and the Surety bind themselves, their heirs, executors, administrators, successors and assigns, jointly and severally. WHEREAS, the Principal has submitted a written bid to the Obligee, dated in the year _ for _ day of , The condition of this obligation is such that if the Principal shall have the bid accepted within the time period prescribed in the Obligee's bid documents, or, if no time period is specified in the Obligee's bid documents, within ( ) days from the closing date as specified in the Obligee's bid documents, and the Principal enters into a formal contract and gives the specified security, then this obligation shall be void; otherwise, provided the Obligee takes all reasonable steps to mitigate the amount of such excess costs, the Principal and the Surety will pay to the Obligee the difference in money between the amount of the bid of the Principal and the amount for which the Obligee legally contracts with another party to perform the work if the latter amount be in excess of the former. The Principal and Surety shall not be liable for a greater sum than the Bond Amount. It is a condition of this bond that any suit or action must be commenced within seven (7) months of the date of this Bond. No right of action shall accrue hereunder to or for the use of any person or corporation other than the Obligee named herein, or the heirs, executors, administrators or successors of the Obligee. IN WITNESS WHEREOF, the Principal and the Surety have Signed and Sealed this Bond dated _ in the year _ SIGNED and SEALED ATTORNEY IN FACT Principal in the presence of Facilities Planning & Management Page 28 of 46 day of Request for Quotation RFQ # 2015-101 Interior Renovations for Level 7 & 11 of 230 Richmond St W, Toronto, ON M5V 1V3 Signature Name of person signing Surety Signature Name of person signing Copyright 2002 Canadian Construction Documents Committee (CCDC 220 -2002 has been approved by the Surety Association of Canada) Standard Construction Document End of APPENDIX-B Facilities Planning & Management Page 29 of 46 Request for Quotation RFQ # 2015-101 Interior Renovations for Level 7 & 11 of 230 Richmond St W, Toronto, ON M5V 1V3 APPENDIX C: BID SUBMISSION FORM Full Legal Name of Proponent: Click here to enter text. ____________________________________________________________________________ Please print clearly Address: Click here to enter text. Telephone: Click here to enter text. Email: Click here to enter text. I/ we, the Respondent, understand that this Bid Form is submitted in response to this RFQ and agree to provide the materials and services described in this RFQ and Addenda # Click here to enter text. Through # Click here to enter text. Inclusive. It is agreed and understood that the following price will apply to the complete contract documents. Included in the price is all overheads, profits and statutory charges as applicable (HST excluded). Item 1. Amount in $ (in word) Description Amount in $ (in figures) 7th floor Work Specified. Include all work required in order to successfully implement the work of the project identified in the specifications and drawings $________________ 11th floor Work Specified. Include all work required in order to successfully implement the work of the project identified in the specifications and drawings $________________ 3. HST @ 13% $________________ 4. Total Quoted Bid Price (including HST) $________________ 2. _______________________________________________ Signature _______________________ Date ____________________________________________________________________________ Name (please print) ____________________________________________________________________________ Title End of APPENDIX C Facilities Planning & Management Page 30 of 46 Request for Quotation RFQ # 2015-101 Interior Renovations for Level 7 & 11 of 230 Richmond St W, Toronto, ON M5V 1V3 APPENDIX D: CONFLICT OF INTEREST DECLARATION Conflict of Interest related to any Proposal submitted in respect of these RFQ documents includes the following conditions: participation of the Proponent in preparation and/ or assistance with a work statement or specifications used in acquiring any of the goods and/ or services contemplated in these RFQ Documents; participation in the evaluation of products or advisory assistance with the goods and/ or services contemplated in thee RFQ Documents; and, the Proponent shall use best efforts to ensure that any employee, agent or subcontractor shall not, during the course of performance of its obligations under any Contract Agreement resulting from its selection and related designation as the Successful Proponent, engage in any activity or obtain any interest likely to conflict with or restrict the Proponent in performing its obligations fairly and independently, and shall immediately notify OCAD University in writing of any conflict or risk of conflict. The Proponent hereby warrants that to the best of its knowledge, no Conflict of Interest exists or is likely to arise in the performance of its obligations under any Contract Agreement resulting from its selection and related designation as the Successful Proponent, either by itself or by its employees, agents or any subcontractors. Proponent Name (please print) Contact Name (please print) Contact Title __________________________________________ Signature _____________________________ Date End of APPENDIX D Facilities Planning & Management Page 31 of 46 Request for Quotation RFQ # 2015-101 Interior Renovations for Level 7 & 11 of 230 Richmond St W, Toronto, ON M5V 1V3 APPENDIX E: SUB-CONTRACTORS & SUPPLIERS The Respondent proposes that the Subcontractors and Suppliers listed below shall be used to carry out the Work for the Project. It is agreed that no substitution shall be made without the express written approval of OCAD University. The Respondent understands that where it plans on using its own forces for any of section(s) of the Work, it will indicate such in the spaces provided by inserting its own name. Use blank lines to enter additional information as required providing a complete list of Descriptions and providers. Sub-Trade Company Name of Subcontractor Address of Subcontractor Mechanical Electrical General Labour Security AC Technical Systems 2100 Forbes St, Unit 8-10 Whitby, ON L1N 9T3 ProFire Safety Services #1 - 15 Kenview Blvd Brampton, ON L6T 5G5 Lock-up Services 2977A Lakeshore Blvd W Toronto, ON M8V 1J8 Drywall Data/Voice Cabling Fire Safety Flooring General Carpentry Painting Cable Reels Door Hardware, Locks and Stops Other _______________________________________________ _______________________ Signature Date ___________________________________________________________________________ Name (please print) ____________________________________________________________________________ Title End of APPENDIX E Facilities Planning & Management Page 32 of 46 Request for Quotation RFQ # 2015-101 Interior Renovations for Level 7 & 11 of 230 Richmond St W, Toronto, ON M5V 1V3 APPENDIX F: QUALIFICATION INFORMATION 1 1.1 For Individual Bidders Principal place of business: 1.2 Total value of Construction work performed in the last three years (in CA$) ______________________________ 2012-2013 ___________________ 2013-2014 ___________________ 2014-2015 ___________________ 1.3 Work performed as prime contractor (in the same name) on projects of a similar nature over the last five years. Remarks Date Key explainin Stipulate Actua of Staff/ g Name of Descrip Value of d period l date Project Contrac issue Role on reasons Employ -tion of contract of of Name t No. of this for delay (CA$) er work complecompl work assignm and work tion e-tion order ent complete d (1) (2) (3) (4) (5) (6) (7) (8) (9) (10) 1.4. Resume of the Project Manager with at least 3 years of experience. 1. For Bid From Joint Venture 2.1 In case of bid from joint venture a joint venture agreement or letter of intent form Joint Venture should be submitted clearly indicating the Lead Partner and that all the member of JV are jointly and severely responsible. 2.2 (a) The information of 1.1 to 1.3 above should be provided for each of the partner of JV. (b) With respect of 1.2 & 1.3 above evaluation will be done after adding the figure of each of the partners. End of APPENDIX F Facilities Planning & Management Page 33 of 46 Request for Quotation RFQ # 2015-101 Interior Renovations for Level 7 & 11 of 230 Richmond St W, Toronto, ON M5V 1V3 APPENDIX G: ACKNOWLEDGEMENT FORM OCAD University Health & Safety Requirements for Contractors The following will be regarded as the Contact Person(s) for the Contractor, and the person(s) responsible for the health and safety performance of all Contractor and Sub-Contractor employees and the enforcement of these Requirements. (Please print clearly) Name: _____________________________________ Title: ___________________________ Mobile phone #:____________________________________ Name: ______________________________________ Title: __________________________ Mobile phone #:____________________________________ OCAD University Health & Safety Requirements have been read and understood by the Contractor indicated below and shall be followed for the duration of the project. Contractor or Contact Name: _____________________________________________________ Company Name: ______________________________________________________________ Date: _____________________________ Signature: ________________________________ Note: This form must be completed, signed and included as part of any Bid Submission received by OCAD University in response to this RFQ document. End of APPENDIX G Facilities Planning & Management Page 34 of 46 Request for Quotation RFQ # 2015-101 Interior Renovations for Level 7 & 11 of 230 Richmond St W, Toronto, ON M5V 1V3 APPENDIX H: CERTIFICATE OF INSURANCE OCAD UNIVERSITY CERTIFICATE OF INSURANCE (To be completed only by the Insurer or its authorized representative) Contract/Project # THIS IS TO CERTIFY TO: OCAD University 100 McCaul Street TORONTO, ONTARIO M5T 1W1 that Policy(ies) of Insurance as herein described have been issued to the Insured named below and are in force at this date. Insured: Address: TYPE OF INSURANCE POLICY NO. EFFECTIVE EXPIRY LIMIT DEDUCTIBLE Commercial General Liability: Motor Vehicle Liability: Umbrella Liability: Professional Liability: Other: Non-Owned Automobile Other: Other: Site Location/Description of Work/Agreement to which this certificate applies: Provisions of amendments or endorsements of listed Commercial General Liability Policy(ies): 1. Commercial General Liability Policy is extended to include Personal Injury Liability, Contractual Liability, Owner's and Contractor's Protective Coverage, Products Completed Operations, Contingent Employers Liability, Cross-Liability/Severability of Interest, and Non-Owned Automobile Liability. 2. OCAD University, its governors, trustees, officers and employees named as Additional Insured to these policies but only with respect to liability arising out of the operations of the Named Insured. 3. It is agreed and understood that the deductible or self insured retention (SIR) arranged between the Named Insured and the Insurer, must be declared herein and is subject to approval by OCAD University's Insurance & Risk Management Services. It is further understood and agreed that claims arising out of the operations of the above mentioned project which fall within the deductible or SIR limit are the sole responsibility of the Named Insured. 4. If the insurance provided under the said policy(ies) is cancelled or changed to reduce the coverage in a manner as to affect this Memorandum of Insurance, the Insuring Company will give thirty (30) days written notice in advance, by registered mail of such a cancellation or change to: OCAD University 100 McCaul Street, Finance Department, Toronto, Ontario M5T 1W1 Attention: Finance Department 5. The Commercial General Liability Policies identified above shall protect each insured in the same manner and to the same extent as though a separate policy has been issued to each, but nothing shall operate to increase the Limits of Liability as identified above beyond the amount or amounts for which the Company would be liable if there had been only one Insured. 6. The Commercial General Liability policy(ies) identified above shall apply as primary insurance and not excess to any other insurance available to the Additional Insured as set out in Item 2 DATE: NAME, ADDRESS AND TELEPHONE NO. OF INSURANCE COMPANY CERTIFICATION I certify that the insurance is in effect as stated in this certificate and that I have authorization to issue this certificate for and on behalf of the insurer(s). This certificate is valid until the expiration date(s) shown unless notice is given in writing in accordance with item 4. NAME, ADDRESS AND TELEPHONE NO. OF INSURANCE BROKER SIGNATURE AND STAMP OF CERTIFYING OFFICIAL The acceptance of this Certificate by OCAD University does not certify that the limits of liability and terms and conditions of the policy(ies) referred to above meet the specified requirements of the University nor will the acceptance of this Certificate by the University waive the University's rights of action against the Insured and/or insurer for failure to comply with the terms and conditions of the agreement to which this certificate applies. End of APPENDIX H Facilities Planning & Management Page 35 of 46 Request for Quotation RFQ # 2015-101 Interior Renovations for Level 7 & 11 of 230 Richmond St W, Toronto, ON M5V 1V3 APPENDIX I: ARCHITECTURAL, MECHANICAL, ELECTRICAL DRAWING AND SPECIFICATIONS PACKAGE Drawings and Specifications (Attached Separately) End of APPENDIX I Facilities Planning & Management Page 36 of 46 Request for Quotation RFQ # 2015-101 Interior Renovations for Level 7 & 11 of 230 Richmond St W, Toronto, ON M5V 1V3 APPENDIX J: PROJECT MANUAL Project Manual (Attached Separately) End of APPENDIX J Facilities Planning & Management Page 37 of 46 Request for Quotation RFQ # 2015-101 Interior Renovations for Level 7 & 11 of 230 Richmond St W, Toronto, ON M5V 1V3 APPENDIX K Supplementary Conditions for the Stipulated Price Contract – CCDC 2 (2008) April 02, 2013 Facilities Planning & Management OCAD University 100 McCaul Street Toronto, ON M5T 1W1 Facilities Planning & Management Page 38 of 46 Request for Quotation RFQ # 2015-101 Interior Renovations for Level 7 & 11 of 230 Richmond St W, Toronto, ON M5V 1V3 The Standard Construction Document for Stipulated Price Contract, 2008 English version, consisting of the Agreement Between Owner and Contractor, Definitions, and General Conditions of the Stipulated Price Contract, Parts 1 to 12 inclusive, governing same is hereby made part of these Contract Documents, with the following amendments, additions and modifications. Where these amendments, additions, and modifications specifically reference a change to the Agreement, Definitions, or General Conditions, these amendments, additions and modifications shall govern. ARTICLE A-6 — RECEIPT AND ADDRESSES FOR NOTICES IN WRITING Delete Article A-6.1 and substitute new article 6.1: 6.1 Notices in Writing between the parties or between them and the Consultant shall be considered to have been received by the addressee on the date of receipt if delivered by hand or by commercial courier or if sent during normal business hours by fax and addressed as set out below. Such Notices in Writing will be deemed to be received by the addressee on the next business day if sent by fax after normal business hours or if sent by overnight commercial courier. Such Notices in Writing will be deemed to be received by the addressee on the fifth Working Day following the date of mailing, if sent by prepaid registered post, when addressed as set out below. An address for a party may be changed by Notice in Writing to the other party setting out the new address in accordance with this Article. DEFINITIONS Add the following definition: 19a. Submittals Submittals are documents or items required by the Contract Documents to be provided by the Contractor, such as: Shop Drawings, samples, models, mock-ups to indicate details or characteristics, before the portion of the Work that they represent can be incorporated into the Work; and, As-built drawings and manuals to provide instructions to the operation and maintenance of the Work. GENERAL CONDITIONS OF THE STIPULATED PRICE CONTRACT PART 1 GENERAL PROVISIONS Add the following: Where a General Condition or paragraph of the General Conditions of the Stipulated Price Contract is deleted by these Supplementary Conditions, the numbering of the remaining General Conditions or paragraphs shall remain unchanged, and the numbering of the deleted item will be retained, unused. GC 1.1 CONTRACT DOCUMENTS Facilities Planning & Management Page 39 of 46 Request for Quotation RFQ # 2015-101 Interior Renovations for Level 7 & 11 of 230 Richmond St W, Toronto, ON M5V 1V3 .1 Add to the end of subparagraph 1.1.2.2: …, except where the Consultant shall be indemnified as a third party beneficiary as provided in subparagraphs 9.2.7.4, 9.5.3.4 and in 12.1.3. .2 Add new subparagraph 1.1.7.5: 1.1.7.5 In case of discrepancies, noted materials and annotations shall take precedence over graphic indications in the Contract Documents. GC 2.2 ROLE OF THE CONSULTANT .1 Add at the end of paragraph 2.2.9 "The Owner and the Contractor shall waive any claims against the Consultant arising out of the making of such interpretations and findings made in accordance with paragraphs 2.2.7, 2.2.8 and 2.2.9". .2 Delete the comma after the word "submittals" and add the words "which are provided" before the words "in accordance" in paragraph 2.2.14. GC 2.4 .1 DEFECTIVE WORK Add new subparagraphs 2.4.1.1 and 2.4.1.2: 2.4.1.1 The Contractor shall rectify, in a manner acceptable to the Owner and the Consultant, all defective work and deficiencies throughout the Work, whether or not they are specifically identified by the Consultant. 2.4.1.2 The Contractor shall prioritize the correction of any defective work which, in the sole discretion of the Owner, adversely affects the day to day operation of the Owner. GC 3.1 .1 CONTROL OF THE WORK Add new paragraph 3.1.3: 3.1.3 Prior to commencing individual procurement, fabrication and construction activities, the Contractor shall verify, at the Place of the Work, all relevant measurements and levels necessary for proper and complete fabrication, assembly and installation of the Work and shall further carefully compare such field measurements and conditions with the requirements of the Contract Documents. Where dimensions are not included or contradictions exist, or exact locations are not apparent, the Contractor shall immediately notify the Consultant in writing and obtain written instructions from the Consultant before proceeding with any part of the affected work. GC 3.4 DOCUMENT REVIEW Facilities Planning & Management Page 40 of 46 Request for Quotation RFQ # 2015-101 Interior Renovations for Level 7 & 11 of 230 Richmond St W, Toronto, ON M5V 1V3 .1 Delete paragraph 3.4.1 in its entirety and substitute new paragraph 3.4.1: 3.4.1 The Contractor shall review the Contract Documents and shall 'report promptly to the Consultant any error, inconsistency or omission the Contractor may discover. Such review by the Contractor shall comply with the standard of care described in paragraph 3.14.1 of the Contract. Except for its obligation to make such review and report the result, the Contractor does not assume any responsibility to the Owner or to the Consultant for the accuracy of the Contract Documents. The Contractor shall not be liable for damage or costs resulting from such errors, inconsistencies, or omissions in the Contract Documents, which the Contractor could not reasonably have discovered. If the Contractor does discover any error, inconsistency or omission in the Contract Documents, the Contractor shall not proceed with the work affected until the Contractor has received corrected or missing information from the Consultant. GC 3.8 .1 LABOUR AND PRODUCTS Add new paragraph 3.8.4: 3.8.4 The Contractor is responsible for the safe on-site storage of Products and their protection (including Products supplied by the Owner and other contractors to be installed under the Contract) in such ways as to avoid dangerous conditions or contamination to the Products or other persons or property and in locations at the Place of the Work to the satisfaction of the Owner and the Consultant. The Owner shall provide all relevant information on the Products to be supplied by the Owner. GC 3.10 .1 SHOP DRAWINGS Add the words "AND OTHER SUBMITTALS" to the Title after SHOP DRAWINGS. .2 Add "and Submittals" after the words "Shop Drawings" in paragraphs 3.10.1, 3.10.2, 3.10.4, 3.10.7, 3.10.8, 3.10.8.2, 3.10.9, 3.10.10, 3.10.11, and 3.10.12. .3 Delete 3.10.3 in its entirety and substitute new paragraph 3.10.3: 3.10.3 Prior to the first application for payment, the Contractor and the Consultant shall jointly prepare a schedule of the dates for submission and return of Shop Drawings and any Submittals. .4 In paragraph 3.10.12, delete the words "with reasonable promptness so as to cause no delay in the performance of the Work" and replace with "within 10 working days or such longer period as may be reasonably required". GC 3.14 .1 PERFORMANCE BY CONTRACTOR Add new General Condition 3.14.1: 3.14.1 In performing its services and obligations under the Contract, the Contractor shall exercise a standard of care, skill and diligence that would normally be provided by an experienced and prudent contractor supplying similar services for similar projects. The Facilities Planning & Management Page 41 of 46 Request for Quotation RFQ # 2015-101 Interior Renovations for Level 7 & 11 of 230 Richmond St W, Toronto, ON M5V 1V3 Contractor acknowledges and agrees that throughout the Contract, the Contractor's obligations, duties and responsibilities shall be interpreted in accordance with this standard. The Contractor shall exercise the same standard of due care and diligence in respect of any Products, personnel, or procedures which it may recommend to the Owner. .2 Add new General Condition 3.14.2: 3.14.2 The Contractor further represents, covenants and warrants to the Owner that: .1 The personnel it assigns to the Project are appropriately experienced; .2 It has a sufficient staff of qualified and competent personnel to replace its designated supervisor and project manager, subject to the Owner's approval, in the event of death, incapacity, removal or resignation. GC 4.1 .1 CASH ALLOWANCES Delete paragraph 4.1.4 in its entirety and substitute new paragraph 4.1.4: 4.1.4 Where costs under a cash allowance exceed the amount of the allowance, unexpended amounts from other cash allowances shall be reallocated at the Consultant's direction to cover the shortfall. .2 Delete paragraph 4.1.5 in its entirety and substitute new paragraph 4.1.5: 4.1.5 The net amount of any unexpended cash allowances, after providing for any reallocations as contemplated in paragraph 4.1.4, shall be deducted from the Contract Price by Change Order. .3 Delete paragraph 4.1.7 in its entirety and substitute new paragraph 4.1.7: 4.1.7 At the commencement of the Work, the Contractor shall prepare for the review and acceptance of the Owner and the Consultant, a schedule indicating the times, within the construction schedule referred to in GC 3.5, that items called for under cash allowances and items that are specified to be Owner purchased and Contractor installed or hooked up are required at the site to avoid delaying the progress of the Work. .4 Add new paragraph 4.1.8: 4.1.8 The Owner reserves the right to call, or to have the Contractor call, for competitive bids for portions of the Work, to be paid for from cash allowances. GC 6.1 .1 OWNER’S RIGHT TO MAKE CHANGES Add the following new paragraphs and subparagraphs: Facilities Planning & Management Page 42 of 46 Request for Quotation RFQ # 2015-101 Interior Renovations for Level 7 & 11 of 230 Richmond St W, Toronto, ON M5V 1V3 6.1.3 Where a change in the Work involves additions, deletions, or other revisions to the Work, the Contract Price shall be increased or decreased, as applicable, only by the net actual value of the change in the Work, including taxes, but excluding Value Added Taxes, plus the following: .1 Contractor mark-up for Overhead and Profit on its own work shall be 10%; .2 Contractor mark-up for Overhead and Profit on Subcontractor work shall be 5%; .3 Subcontractor mark-up for Overhead and Profit on its own work shall be 10%; .4 If a Subcontractor retains another Subcontractor (sub-subcontractor), no additional mark-up shall be charged to the Owner for the sub-subcontract work. 6.1.4 Costs for the following items shall be considered to be included in the allowance for overhead: .1 Contractor’s head office expenses; .2 wages of project managers, superintendents, assistants, watchpersons and administrative personnel; .3 temporary site office, including costs for telephone and/or facsimile machine; .4 small tools (valued at less than $2,000.00) .5 insurance and/or bonding premiums; .6 .7 record drawings (per Owner’s CAD layering standard); clean-up and disposal of waste materials. 6.1.5 Overhead and profit may not be charged on changes in the Work where there is a net decrease to the Contract Price. 6.1.6 The Owner reserves the right to call, or to have the Contractor call, for competitive bids for portions of the Work not covered under the Contract Price. GC 6.4 .1 CONCEALED OR UNKNOWN CONDITIONS Add new subparagraph 6.4.5: 6.4.5 The Contractor confirms that, prior to bidding the Project, it carefully investigated the Place of the Work and applied to that investigation the degree of care and skill described in paragraph 3.14.1, given the amount of time provided between the issue of the bid documents and the actual closing of bids, the degree of access provided to the Contractor prior to submission of bid, and the sufficiency and completeness of the information provided by the Owner. The Contractor is not entitled to compensation or to an extension of the Contract Time for conditions which could reasonably have been ascertained by the Contractor by such careful investigation undertaken prior to the submission of the bid. Facilities Planning & Management Page 43 of 46 Request for Quotation RFQ # 2015-101 Interior Renovations for Level 7 & 11 of 230 Richmond St W, Toronto, ON M5V 1V3 GC 6.5 DELAYS .1 Delete the period at the end of paragraph 6.5.1, and substitute the following words: "..., but excluding any consequential, indirect or special damages." .2 Add new subparagraph 6.5.6: 6.5.6 If the Contractor is delayed in the performance of the Work by an act or omission of the Contractor or anyone employed or engaged by the Contractor directly or indirectly, or by any cause within the Contractor's control, then the Contract Time shall be extended for such reasonable time as the Consultant may decide in consultation with the Contractor. The Owner shall be reimbursed by the Contractor for all reasonable costs incurred by the Owner as the result of such delay, including all services required by the Owner from the Consultant as a result of such delay by the Contractor and, in particular, the cost of the Consultant's services during the period between the date of Substantial Performance of the Work stated in Article A-1 herein as the same may be extended through the provisions of these General Conditions and any later, actual date of Substantial Performance of the Work achieved by the Contractor. GC 6.6 CLAIMS FOR A CHANGE IN CONTRACT PRICE .1 Add the words "as noted in paragraph 6.6.3" after the words "of the claim" in paragraph 6.6.5 and add the words "and the Consultant", at the end of paragraph 6.6.5. GC 8.2 .1 NEGOTIATION, MEDIATION AND ARBITRATION Add the following new paragraphs 8.2.9, 8.2.10, 8.2.11, 8.2.12., 8.2.13, and 8.2.14: 8.2.9 Within five days of receipt of the notice of arbitration by the responding party under paragraph 8.2.6, the Owner and the Contractor shall give the Consultant a written notice containing: a) a copy of the notice of arbitration; b) a copy of supplementary conditions 8.2.9 to 8.2.14 of this Contract; and; c) any claims or issues which the Contractor or the Owner, as the case may be, wishes to raise in relation to the Consultant arising out of the issues in dispute in the arbitration. 8.2.10 The Owner and the Contractor agree that the Consultant may elect, within ten days of receipt of the notice under paragraph 8.2.9, to become a full party to the arbitration under paragraph 8.2.6 if the Consultant: a) has a vested or contingent financial interest in the outcome of the arbitration; b) gives the notice of election to the Owner and the Contractor before the arbitrator is appointed; c) agrees to be a party to the arbitration within the meaning of the rules referred to in paragraph 8.2.6; and, d) agrees to be bound by the arbitral award made in the arbitration. 8.2.11 If an election is made under paragraph 8.2.10, the Consultant may participate in the appointment of the arbitrator and, notwithstanding the rules referred to in paragraph 8.2.6, the time period for reaching agreement on the appointment of the arbitrator shall begin to run from the date the respondent receives a copy of the notice of arbitration. Facilities Planning & Management Page 44 of 46 Request for Quotation RFQ # 2015-101 Interior Renovations for Level 7 & 11 of 230 Richmond St W, Toronto, ON M5V 1V3 8.2.12 The arbitrator in the arbitration in which the Consultant has elected under paragraph 8.2.10 to become a full party may: a) on application of the Owner or the Contractor, determine whether the Consultant has satisfied the requirements of paragraph 8.2.10; and, b) make any procedural order considered necessary to facilitate the addition of the Consultant as a party to the arbitration. 8.2.13 The provisions of paragraph 8.2.9 shall apply mutatis mutandis to written notice to be given by the Consultant to any sub-consultant. 8.2.14 In the event of notice of arbitration given by the Consultant to a sub-consultant, the subconsultant is not entitled to any election with respect to the proceeding as outlined in 8.2.10, and is deemed to be bound by the arbitration proceeding. GC 9.1 .1 PROTECTION OF WORK AND PROPERTY Delete subparagraph 9.1.1.1 in its entirety and substitute new subparagraph 9.1.1.1: 9.1.1.1 errors in the Contract Documents which the Contractor could not have discovered applying the standard of care described in paragraph 3.14.1; .2 Delete paragraph 9.1.2 in its entirety and substitute the following new paragraph 9.1.2: 9.1.2 Before commencing any Work, the Contractor shall determine the locations of all underground utilities and structures indicated in the Contract Documents, or that are discoverable by applying to an inspection of the Place of the Work the degree of care and skill described in paragraph 3.14.1. GC 9.2 TOXIC AND HAZARDOUS SUBSTANCES .1 Add to paragraph 9.2.6 after the word "responsible", the following new words: “…or whether any toxic or hazardous substances or materials already at the Place of the Work (and which were then harmless or stored, contained or otherwise dealt with in accordance with legal and regulatory requirements) were dealt with by the Contractor or anyone for whom the Contractor is responsible in a manner which does not comply with legal and regulatory requirements, or which threatens human health and safety or the environment, or material damage to the property of the Owner or others.” .2 Add "and the Consultant" after the word "Contractor" in subparagraph 9.2.7.4. .3 Add to paragraph 9.2.8 after the word "responsible", the following new words: “…or that any toxic or hazardous substances or materials already at the Place of the Work (and which were then harmless or stored, contained or otherwise dealt with in accordance with legal and regulatory requirements) were dealt with by the Contractor or anyone for whom the Contractor is responsible in a manner which does not comply with legal and regulatory requirements, or which threatens human health and safety or the environment, or material damage to the property of the Owner or others.” GC 9.5 MOULD Facilities Planning & Management Page 45 of 46 Request for Quotation RFQ # 2015-101 Interior Renovations for Level 7 & 11 of 230 Richmond St W, Toronto, ON M5V 1V3 .1 Add "and the Consultant" after "Contractor in subparagraph 9.5.3.4. GC 10.2 LAWS, NOTICES, PERMITS, AND FEES .1 Delete from the first line of paragraph 10.2.5 the word, "The" and substitute the words: "Subject to paragraph 3.14.1, the…". GC 12.1 .1 INDEMNIFICATION Add new clause 12.1.1.3: 12.1.1.3 The Contractor shall indemnify and hold harmless the Consultant, its agents and employees from and against claims, demands, losses, costs, damages, actions, suits, or proceedings by third parties that arise out of, or are attributable to, the Contractor's performance of the Contract, provided such claims are attributable to bodily injury, sickness, disease, or death, or to injury to or destruction of tangible property, and caused by negligent acts or omissions of the Contractor or anyone for whose acts the Contractor may be liable, and made in writing within a period of 6 years from the date of Substantial Performance of the Work as set out in the certificate of Substantial Performance of the Work, or within such shorter such period as may be prescribed by any limitation statute or the province or territory of the Place of Work. GC 12.3 WARRANTY .1 Delete from the first line of paragraph 12.3.2 the word, "The" and substitute the words: "Subject to paragraph 3.14.1, the...". Facilities Planning & Management Page 46 of 46