City of Thunder Bay Section 00800 C.C.D.C. 4 - Supplementary General Conditions for use with C.C.D.C. General Conditions for Unit Price Contracts Contract No. Page 1 of 24 The Canadian Construction Documents Committee [CCDC] #4 Unit Price Contract -General Conditions of the Unit Price Contract, 1982 is modified as follows: ARTICLES A-1 to A-8 INCLUSIVE Delete all references in the General Conditions to these Articles. The CCDC Agreement Form is not part of this Contract. Refer to Definitions Definitions The definition of "Consultant" in definition 4 is deleted and replaced by the following: "Consultant or Engineer" means the Contract Administrator solely in charge of this Contract. The definition of "Subcontractor" in definition 6 is deleted and replaced by the following: "Subcontractor" means a person, firm or corporation undertaking the execution of a part of the Work by virtue of an agreement with the Contractor, which has been approved by the Owner. The definition of "Substantial Performance" in definition 13 is deleted and replaced by the following: 01) The Work is substantially performed: 1) when the Work, or a substantial part thereof has passed inspection and testing and is ready for use or is being used for the intended purposes; and 2) when the work to be performed under the Contract is capable of completion or, where there is a known defect, correction is a cost of not more than 02) i 3% of the first $500,000 of the Contract price, ii 2% of the next $500,000 of the Contract price, and iii 1% of the balance of the Contract price For the purposes of this Contract where the Work or a substantial part thereof is ready for use or is being used for the purposes intended and the remainder of the Work cannot be completed expeditiously for reasons City of Thunder Bay Section 00800 C.C.D.C. 4 - Supplementary General Conditions for use with C.C.D.C. General Conditions for Unit Price Contracts Contract No. Page 2 of 24 beyond the control of the Contractor or, where the Owner and the Contractor agree not to complete the Work expeditiously, the price of the services or materials remaining to be supplied and required to complete the work shall be deducted from the Contract price in determining substantial performance. Revise definition 14, TOTAL PERFORMANCE of the WORK, by adding the following: In addition to all prior requirements, Total Performance will not occur until the Work has passed all inspections and testing requirements. Add the following definitions: 17. Addendum "Addendum" means an addition to or a change in the Contract Documents that is issued by the Contract Administrator prior to the tender closing. 18. Final Acceptance a) 19. In addition to all other prior requirements, Final Acceptance will not occur until the Work has passed all inspections and testing requirements Major Item “Major Item” means any tender item that has a value, calculated on the basis of its actual or estimated tender quantity whichever is the larger, multiplied by its tender unit price, which is equal to or greater than the lesser of a) b) $100,000, or 5% of the total tender value calculated on the basis of the total of all the estimated tender quantities and the tender unit prices. Note to Project Engineer - If these General Conditions are to apply to work included in the ICI sector, add the following definition: 20. Fair Wage Policy and Schedule References to Fair Wage Policy and Schedule means the Fair Wage Policy for Industrial Commercial Institutional (ICI) Contracts as approved by Council of the City of Thunder Bay. Fair Wage Schedule means the schedule of wages, benefits, and hours of work as determined by the Fair Wage Committee and as amended from time to time. City of Thunder Bay Contract No. Section 00800 C.C.D.C. 4 - Supplementary General Conditions for use with C.C.D.C. General Conditions for Unit Price Contracts Page 3 of 24 Section GC1 - DOCUMENTS Subsection GC1.6 is deleted, and replaced by the following: GC1.6 In the event of conflicts between the Contract Documents, the following shall apply a) constructed works take precedence over drawing dimensions and details. Prior to fabrication of any item dependent upon accurate dimensions or details of the constructed works, the Contractor shall take field measurements of such constructed works, b) figured dimensions shown on a drawing shall govern even though they may differ from dimensions scaled on the same drawing, c) drawings of a later date shall govern over those of an earlier date, d) detailed drawings shall govern over general drawings. e) specifications shall govern over drawings, f) the Supplementary General Conditions shall govern over the General Conditions, and g) the executed agreement between the Owner and Contractor shall govern over all documents. Notwithstanding the foregoing, documents of later date shall always govern. Subsection GC 3.6.1 is deleted and replaced with the following paragraphs: GC 3.6.1 The Contractor shall be solely responsible for construction health and safety within the working areas and for compliance with the Occupational Health and Safety Act and Regulations. So as to avoid any misunderstanding as to the extent of the Contractor’s responsibility, the Contractor, by executing the Contract unequivocally acknowledges that the Contractor is the Constructor within the meaning of the Act. GC 3.6.2 The Contractor shall also work in accordance with the City of Thunder Bay’s Policy on Contractor Safety: CITY OF THUNDER BAY POLICY ON CONTRACTOR SAFETY POLICY STATEMENT City of Thunder Bay Contract No. Section 00800 C.C.D.C. 4 - Supplementary General Conditions for use with C.C.D.C. General Conditions for Unit Price Contracts Page 4 of 24 All contractors of land developers working on municipal projects are required to work in compliance with the Ontario Occupational Health and Safety Act and Regulations. All contractors working on city streets and roads shall comply with the Ministry of Transportation – Traffic Control Manual for Roadway Work Operations. Failure to comply shall be considered a breech of contract and may result in work stoppage, Ministry of Labour involvement, or in termination of the contract. CONTRACTOR SAFETY DEFICIENCIES WILL BE ADDRESSED BY THE CITY IN THE FOLLWING PROGRESSIVE STEPS: 1. The problem shall be identified to the contractor (site supervisor). 2. The contractor’s head office shall be contacted about the problem orally and, later, in writing. 3. If the problem remains unresolved then the Ministry of Labour shall be notified of the violation and if necessary the work shall be stopped until the problem is corrected. 4. The contract may be terminated by the City. SECTION GC4 - Delays Section GC4 is amended by the addition of the following: GC4.7 If the Contractor is delayed in the performance of the Work by: a) abnormal inclement weather; or b) archaeological finds then the Contractor shall not be reimbursed by the Owner for any costs incurred by the Contractor as the result of such delay. Any delay in the performance of the work shall be considered for the extension of Contract Time only. In the case of an application for an extension due to abnormal inclement weather, the Contractor shall, with the Contractor's application, submit evidence from Environment Canada in support of such application. Extension of Contract Time will be granted in accordance with subsection GC4.3. City of Thunder Bay Contract No. GC4.8 Section 00800 C.C.D.C. 4 - Supplementary General Conditions for use with C.C.D.C. General Conditions for Unit Price Contracts Page 5 of 24 If the Contractor's operations expose any items which may indicate an archaeological find, such as building remains, hardware, accumulations of bones, pottery, or arrowheads: a) The Contractor shall immediately notify the Contract Administrator and suspend operations within the area identified by the Contract Administrator. Work shall remain suspended within that area until otherwise directed by the Contract Administrator in writing. b) Any delay in the completion date of the Contract that is caused by such a cessation of construction operations will be considered to be beyond the Contractor's control in accordance with of Subsection GC4.3. c) Any work directed or authorised by the Contract Administrator with an archaeological find will be considered as Extra Work in accordance with Section GC4.3. GC4.9 The Contractor shall not have any claims for compensation or damages against the Corporation for any stoppage or delay from any cause whatever, whether such stoppage or delay shall be caused by or result from the action or neglect of any other Contractor, or shall be caused by or result from the work being taken out of the hands of the Contractor, or any other Contractor, by the Corporation under the provisions of this Contract made with such other Contractor. GC4.10 The Owner is not liable to pay Standby Time for any labour or equipment rental under this Contract. GC4.11 Time shall be strictly of the essence of this Contract. GC4.12 The Contractor shall complete this Contract in its entirety by the completion date specified in the Tender Form. If the time limit specified is not sufficient to permit completion of the Work by the Contractor working a normal number of hours each day or week on a single daylight shift basis, it is expected that additional and/or augmented daylight shifts will be required throughout the life of the Contract to the extent deemed necessary by the Contractor to ensure that the Work will be completed within the time limit specified. Any additional costs occasioned by compliance with these provisions will be considered to be included in the prices bid for the various items of Work and no additional compensation will be allowed therefore. City of Thunder Bay Contract No. Section 00800 C.C.D.C. 4 - Supplementary General Conditions for use with C.C.D.C. General Conditions for Unit Price Contracts Page 6 of 24 GC4.13 An extension of time may be granted in writing by the Contract Administrator in his sole discretion in the event of the Work being delayed beyond the prescribed time for completion. Such extension shall be for such time as the Contract Administrator may prescribe and the Contract Administrator shall fix the terms on which such an extension may be granted. An application for an extension of time shall be made in writing by the Contractor to the Owner at least 15 days prior to the date of completion fixed by the Contract. The date of expiry of all Bonds and other Surety furnished to the Owner by the Contractor shall be extended at the expense of the Contractor. GC4.14 Any extension of time that may be granted to the Contractor shall be so granted and accepted without prejudice to any rights of the Owner whatsoever under this Contract and all of such rights shall continue in full force and effect after the time limited in this Contract for completion of the work and whenever in this Contract, power or authority is given to the Owner or the Contract Administrator or any person to take any action consequent upon the act, default, neglect, delay, breach, non-observance or non-performance by the Contractor in respect of the Work or Contract of any portion thereof, such powers or authorities may be exercised from time to time, and not only in the event of the happening of such contingencies before the time limited in this Contract for the completion of the Work but also in the event of the same happening after the time so limited in the case of the Contractor being permitted to proceed with the execution of the Work under an extension of time granted by the Owner. In the event of the Owner granting an extension of time, time shall continue to be deemed strictly of the essence of this Contract. GC4.15 Liquidated Damages It is agreed by the Parties to the Contract that in case all the Work called for under the Contract is not finished by the completion date specified in the Tender Form or as amended by the Contract Administrator, damage will be sustained by the Owner, and that it is and will be impracticable and extremely difficult to ascertain and determine the actual damage which the Owner will sustain in the event of and by reason of such delay and the Parties therefore agree that the Contractor will pay to the Owner the sum of $___________1 per day for Liquidated Damages for each and every calendar day's delay in completing the Work beyond the date of completion prescribed and it is agreed that amount is an estimate of actual damage to the Owner which will accrue during the period in excess of the prescribed date of completion. 1 This figure should be calculated by the Project Engineer. $500 is appropriate for the cost of inspection for routine City projects. City of Thunder Bay Contract No. Section 00800 C.C.D.C. 4 - Supplementary General Conditions for use with C.C.D.C. General Conditions for Unit Price Contracts Page 7 of 24 The Owner may deduct any amount under this paragraph from any monies that may be due or payable to the Contractor on any account whatsoever. The Liquidated Damages payable under this paragraph are in addition to and without prejudice to any other remedy, action or other alternatives that may be available to the Owner. GC4.16 The Contractor shall not be assessed with Liquidated Damages for any delay caused by Acts of God, or of the Public Enemy, Act of the Corporation, the Contract Administrator, or of any Foreign State, Fire, Epidemics, Quarantine Restrictions, Embargoes, or Delays of Sub-Contractors due to such causes. If the Contractor is delayed by reason of alterations or changes made under Section GC11 of the General Conditions, the time of completion shall be extended as determined by the Contract Administrator in his sole discretion. SECTION GC5 - OWNER’S RIGHT TO PERFORM WORK OR STOP THE WORK OR TERMINATE CONTRACT Subsections GC5.2 and GC5.3 are amended as follows: GC5.2 change reference from five [5] to three [3] working days. GC5.3 change reference from five [5] to three [3] working days. Section GC5 is amended by the addition of the following paragraphs: GC5.8 The Contract Administrator may stop any portion of the Work, if in his judgement the weather is such as to prevent the Work being properly done. No compensation of any kind will be made for such stoppage except an extension of time for the completion of the Work as provided in GC4. GC5.9 The Contractor shall, upon written notice from the Contract Administrator, discontinue or delay any or all Work of base, foundation, or paving construction on any section of any road or highway, if in the opinion of the Engineer, the foundation is not sufficiently compacted or settled for surfacing of the Work in question, and the Work shall not be resumed until the Contract Administrator shall in writing so direct, and the Contractor shall not be entitled to any compensation for such stoppage or delay to the Work, other than an extension of time. SECTION GC8 - ASSIGNMENT OF CONTRACT Subsection GC8.1 is amended by the addition of the following paragraph: No assignment of this Contract in whole or in part shall be valid unless it shall contain a provision that the funds to be paid to the assignee under the assignment are subject to the City of Thunder Bay Contract No. Section 00800 C.C.D.C. 4 - Supplementary General Conditions for use with C.C.D.C. General Conditions for Unit Price Contracts Page 8 of 24 prior lien for services rendered or material supplied for the performance of the work called for in the Contract in favour of persons, firms, or corporations rendering such services or supplying such materials. SECTION GC12 - VALUATION AND CERTIFICATION OF CHANGES IN THE WORK Subsection GC12.2 of is deleted and replaced by the following: GC12.2 The valuation of additions to, and deductions from the Contract shall be made as follows: a) The prices in the Schedule of Prices or Provisional Items shall apply where appropriate as determined by the Contract Administrator. b) If the prices in Clause (a) are not appropriate, valuation will be made by one the following methods: i] Contract Administrator may ask the Contractor for a Quotation for the proposed work. ii] If the Quotation referred to in i] above is not accepted by the Contract Administrator, the actual cost of the work will be determined on a Time and Material Basis in accordance with GC12.11. c) Whenever extra work is being performed under Subsection (b) ii] above, the Contractor shall submit daily reports in writing, to the Contract Administrator, indicating the total chargeable costs incurred, for the day. Valuation of the extra work being so performed will be made only by the Contract Administrator on the basis of approved daily reports. GC 12 is amended by the addition of the following: GC12.11 The cost plus percentage method of payment for work carried out on a time and material basis shall be calculated by the Contract Administrator as follows: a) b) c) d) Contractor’s Own Work: 15%; Sub-contractor’s Own Work: 15%; Sub-contractor’s Work: Contractor’s mark-up is 5%; The cost of the work shall include the following and shall apply to extra work only; .1 Expenditures for wages and for salaries of workmen, Engineers, superintendents, draftsmen, foremen, timekeepers, accountants, City of Thunder Bay Contract No. Section 00800 C.C.D.C. 4 - Supplementary General Conditions for use with C.C.D.C. General Conditions for Unit Price Contracts Page 9 of 24 expediters, clerks, watchmen and such other personnel as may be approved by the Engineer, employed directly under the Contractor (or Subcontractor) and while engaged on the work at the site, and expenditures for travelling of such employees, or when covered by trade agreements and when approved by the Engineer; .2 Expenditures for material used in or required in connection with the construction of work; .3 Expenditures for preparation, inspection, delivery, installation and removal of materials, plant, tools and supplies; .4 The cost of erecting, and maintaining, and removing, if required, temporary offices, sheds and other similar structures, stationary or mobile, required for the performance of the Contract; .5 Travelling expenses properly incurred by the Contractor (or Subcontractor) in connection with the inspection and supervision of the work or in connection with the inspection of materials prepared or in course of preparation for the work in expediting their delivery. .6 Rentals of all construction plant or parts thereof, whether rented from the Contractor (or Subcontractor) or in accordance with rental agreements approved by the Engineer, and expenditures for transportation to and from the site of said construction plant, costs of loading and unloading, cost of installation, dismantling and removal thereof and repairs and replacements during its use on the work, exclusive of any repairs which may be necessary because of defects in the plant and equipment when brought to the work or appearing within thirty (30) days thereafter; e) The cost of all expendable materials, supplies and tools (other than tools customarily provided by tradesmen) less the salvage value thereof at the completion of the work; f) Assessment under the Worker's Safety & Insurance Board Act, the Employment Insurance Act, statutes providing for vacations with pay, government hospitalisation or any similar statutes of Canada or a province thereof, or payments on account of usual vacations made by the Contract (or Subcontractor) to his employees engaged on the work at the site, to the extent which such assessments or payments for vacations with pay relate to the work covered by this Contract; and all sales taxes or other taxes where applicable; City of Thunder Bay Contract No. Section 00800 C.C.D.C. 4 - Supplementary General Conditions for use with C.C.D.C. General Conditions for Unit Price Contracts Page 10 of 24 g) Premiums on all insurance policies and bonds not called for under this Contract; h) Royalties for the use of any patented invention on the work at the site; i) Fees for licenses and permits in connection with the work at the site; j) Such other expenditure in connection with the work as may be approved by the Owner; provided always that except with the consent of the Owner, the above items of cost shall be at rates comparable with those prevailing in the locality of the work; and k) The Owner is not liable to pay Standby Time for any labour or equipment rental under this Contract. SECTION G13 - APPLICATIONS FOR PAYMENT Subsection GC13.1 is deleted and replaced with the following: GC13.1 01) Applications for payment on account may be made monthly as the Work progresses. Three [3] copies of each progress payment certificate shall be delivered by the Contract Administrator to the Contractor. The Contractor shall present to the Contract Administrator two [2] copies of the estimate certified to be correct. Upon receipt of the progress payment certificate verified as aforesaid and upon its approval by the Contract Administrator, the Owner will process the payment to the Contractor. 02) Notwithstanding Paragraph 01) the Owner may withhold any or all payments to the Contractor or portions thereof in circumstances where the Contractor is considered by the Owner or Contract Administrator to be unreasonable in default of specified times for completion of the work. 03) The Contractor shall furnish the Contract Administrator with satisfactory evidence in the form of a W.S.I.B. Certificate of Clearance that he has made suitable provision for meeting any liability under the Workman’s Compensation Act of Ontario, prior to the release of any monthly progress payment. 04) The Contractor shall furnish the Contract Administrator with a Statutory Declaration that all liabilities incurred by the Contractor and its Subcontractors in carrying out the Contract have been City of Thunder Bay Contract No. Section 00800 C.C.D.C. 4 - Supplementary General Conditions for use with C.C.D.C. General Conditions for Unit Price Contracts Page 11 of 24 discharged and that all liens in respect of the Contract have expired or have been satisfied, discharged or provided for by payment. The Statutory Declaration shall be provided prior to all monthly progress payments except the first one. SECTION G14 - CERTIFICATES AND PAYMENTS Subsection GC14.2 is deleted and replaced by the following: The Owner shall make payment to the Contractor on account in accordance with the provisions of Article A-4 – PAYMENT no later than thirty (30) days after the issuance of a certificate for payment by the Consultant. Notwithstanding the provisions of Article A4 - Payment, Subsection GC14.2 is amended by the addition of the following paragraphs: a) Notwithstanding the preceding paragraph, the Owner may withhold any or all payments to the Contractor or portions thereof in circumstances where the Contractor is considered by the Owner or Contract Administrator to be unreasonably in default of specified times for completion of the work. b) The Contractor shall furnish the Contract Administrator with satisfactory evidence in the form of a W.S.I.B. Certificate of Clearance that he has made suitable provision for meeting any liability under The Workman's Compensation Act of Ontario, prior to the release of any monthly progress payment. c) The Contractor shall furnish the Contract Administrator with a Statutory Declaration that all liabilities incurred by the Contractor and its sub-Contractors in carrying out the Contract have been discharged and that all liens in respect of the Contract have expired or have been satisfied, discharged or provided for by payment. The Statutory Declaration shall be provided prior to all monthly progress payments except the first one. d) In addition to any other holdback required by statute or otherwise agreed by the Parties, the Owner will retain, until expiry of the warranty referred to in GC24, money in the amount calculated pursuant to paragraphs (b) and (c) hereof which money may be applied by the Owner in whole or in part in order to reimburse the Owner for losses, costs incurred or funds expended by the Owner as a result of default by the Contractor respecting the warranty obligations of the Contractor set out in the Contract. e) The said holdback for warranty obligations referred to in the preceding paragraph shall be first retained by the Owner when the Contract Administrator certifies that Work to the value of 70% of the Contract Price has been performed and shall be calculated and shown as an amount to be retained in the monthly applications for City of Thunder Bay Section 00800 C.C.D.C. 4 - Supplementary General Conditions for use with C.C.D.C. General Conditions for Unit Price Contracts Contract No. Page 12 of 24 payment by the Contractor in succeeding applications, commencing when the Contractor makes his first application for payment on the basis that work to the value of 70% of the Contract price has been performed. f) A Maintenance Security Holdback will be calculated in accordance with the following Table: Contract Value Amount of Maintenance Security Holdback less than $300,000 $300,000 - 800,000 $800,000 - 1,500,000 greater than $1,500,000 2% of Contract value $10,000 $15,000 1% of Contract value The Maintenance Security Holdback is in addition to any other rights or remedies of the Owner in respect to the correction of the Contractor's default of the Contractor's warranty obligations. g) Some portions of the Work have an extended warranty. A proportionate amount of the Maintenance Security Holdback will be retained until expiry of the extended portions. Section GC14 is amended by the addition of the following paragraph: GC14.15 Notwithstanding the provisions of Article A4 Payment, paragraph d), the Owner is not liable to pay interest on any amount which may at any time become payable to the Contractor under this Contract whether or not the payment is in default and whether or not any action or other proceeding has been commenced in respect thereof. SECTION GC16 - LAWS, NOTICES, PERMITS AND FEES Subsection GC16 is amended by the addition of the following paragraphs: GC16.6 When construction affects railway property, the Owner will pay the costs of all flagging and other traffic control measures required and provided by the railway company within the Working Area. GC16.7 The Contractor will notify, obtain inspections and approvals from, and cooperate with other organizations involved or affected by the Work, such as telephone, light and power, gas, railway companies, government agencies. City of Thunder Bay Section 00800 C.C.D.C. 4 - Supplementary General Conditions for use with C.C.D.C. General Conditions for Unit Price Contracts Contract No. Page 13 of 24 SECTION GC18 – WORKERS’ COMPENSATION INSURANCE This section is deleted in its entirety. SECTION GC19 – INDEMNIFICATION Subsection 19.2 is deleted. SECTION GC20 - INSURANCE Subsection 20.1 is amended as follows: Amend all clauses/paragraphs of Section GC20.1 to provide a minimum limit of not less than five million dollars ($5,000,000.00) per occurrence. All forms of insurance to be endorsed to provide the owner with not less than thirty (30) days written notice in advance of any cancellation, change or amendment restriction coverage. Prior to the commencement of any work under this Contract the Contractor shall file with the City, to the attention of the City Clerk, Certificates evidencing full compliance with the above clauses, in accordance with the prescribed Certificate which is located after the "Tender Form" in the documents. Paragraph (a) (b) and (e) of Subsection GC20.1 are deleted and replaced with the following: a) General Liability Insurance The Contractor shall obtain and maintain Comprehensive General Liability Insurance against Bodily Injury and Property Damage claims with respect to all work to be performed under this Contract. Such Insurance shall: a) be in the joint names of the Contractor, the Corporation of the City of Thunder Bay, the Consultant, and all Subcontractors of the above employed directly or indirectly in the work to be performed; *Project Engineer to add additional agencies if appropriate. b) contain a Cross Liability Clause; c) include coverage for: i] ii] iii] Completed Operations, which coverage shall be maintained continuously in force for a period of not less than 24 months from the date of the Certificate of Total Performance of the Work, and thereafter to be maintained for a further period of four (4) years Blanket Contractual Liability Contingent Employers Liability City of Thunder Bay Contract No. Section 00800 C.C.D.C. 4 - Supplementary General Conditions for use with C.C.D.C. General Conditions for Unit Price Contracts iv] v] vi] d) Non-owned Automobile Liability Broad Form Property Liability Excavation where applicable, include coverage for: i] ii] iii] iv] v] vi] e) Page 14 of 24 Underpinning, shoring Demolition Building raising or moving Blasting or the Use of Explosives Tunnelling Pile driving, caisson work Five million dollars ($5,000,000.00) inclusive per occurrence. Subsection GC20.1 (d) Property and Boiler Insurance is amended by the addition of the following paragraph: (8) Property and Boiler insurance is required only if the Contract includes the construction of, or alterations to, a bridge, dam, culvert or building. Subsection GC20.5 is added as follows: a) It shall be the duty of the Contractor to fully comply with the terms and conditions of the Liability Insurance coverage, including, without limiting the generality of the foregoing, the requirement to promptly report claims to the Insurer. b) The Contractor shall also promptly notify the Contract Administrator of all such claims in writing. c) If a claim is settled, the Contractor shall thereupon provide the Contract Administrator with a copy of the Claimant's Release. d) If a claim is rejected, the Contract Administrator shall be notified at the time of rejection. e) The Contract Administrator shall be provided full information as to such claims at all times as the Contract Administrator may require and in any event should 30 days elapse after the claim has been received by the Contractor and the Contractor is not able to report settlement or rejection of the claim, the Contractor will provide a full report to the Contract Administrator as to the status of and steps being taken with respect to the claim. City of Thunder Bay Contract No. Section 00800 C.C.D.C. 4 - Supplementary General Conditions for use with C.C.D.C. General Conditions for Unit Price Contracts Page 15 of 24 SECTION GC21 - PROTECTION OF WORK, PERSONS AND PROPERTY Section GC21 is amended by the addition of the following subsections: GC21.4 When carrying out excavation work, the Contractor may encounter such underground utilities as sewers, gas mains, telephone cables, power cables, and watermains. The Contractor shall be fully responsible for any breakage or damage to such utilities, and the Contractor shall pay the full cost of repairing such damages and making good any losses or damages which are caused as a result of his operation in carrying out this Contract. GC21.5 It shall be the Contractor's responsibility to obtain written permission and to make any required arrangements with the Owners of any adjacent properties which the Contractor may encroach. GC21.6 The Contractor shall furnish and bear the cost of any watchman he may require for protection to perform this Contract except as provided in paragraph GC16.6. SECTION GC23 - BONDS Section GC23 is deleted and replaced by the following: GC23.1 The Contractor, together with a surety company approved by the Owner and authorised by law to carry on business in the Province, shall furnish a 50% Labour and Materials Payment Bond to the Owner using CCA Document(s) 22. The bond shall remain inn effect until 12 months after the date the Contract Administrator accepts the entire work. GC23.2 The Contractor, together with a surety company, approved by the Owner and authorised by law to carry on business in the Province in which the work is to be performed, shall furnish a Performance Bond to the Owner using CCA Document(s) 21 in the amount of 100% of the Contract price. GC23.3 In lieu of the bonds specified in paragraphs GC23.1 and GC23.2 the Contractor may provide unconditional Irrevocable Letters of Credit, in a form acceptable to the Owner and/or a certified cheque made out to the Owner. SECTION GC24 - WARRANTY Subsection GC24.2 is amended by adding the following paragraph: The Contractor shall be responsible for the maintenance of all trenches for a period of 2 years from the date of substantial completion. Any shrinkage or settlement during this City of Thunder Bay Contract No. Section 00800 C.C.D.C. 4 - Supplementary General Conditions for use with C.C.D.C. General Conditions for Unit Price Contracts Page 16 of 24 period will be made good by the Contractor at his own expense. This shall also include making good any other works affected. SECTION GC25 - CONTRACTOR’S RESPONSIBILITIES AND CONTROL OF THE WORK Subsection GC25.2 is deleted, and replaced with the following paragraphs: GC25.2 (a) The Contractor shall be solely responsible for construction health and safety within the working areas and for compliance with the Occupational Health and Safety Act and Regulations. So as to avoid any misunderstanding as to the extent of the Contractor’s responsibility, the Contractor, by executing the Contract unequivocally acknowledges that the Contractor is the Constructor within the meaning of the Act. (b) The Contractor shall also work in accordance with the City's Contractor Safety Policy. (c) CITY OF THUNDER BAY POLICY ON CONTRACTOR SAFETY POLICY STATEMENT: All Contractors or Land Developers working on municipal projects are required to work in compliance with the Ontario Occupational Health and Safety Act and Regulations. All Contractors working on City streets and roads will comply with the Ministry of Transportation – Traffic Control Manual for Roadway Work Operations. Failure to comply shall be considered a breech of contract and may result in work stoppage, Ministry of Labour involvement, or in termination of the contract. CONTRACTOR SAFETY DEFICIENCIES WILL BE ADDRESSED BY THE CITY IN THE FOLLOWING PROGRESSIVE STEPS: 1. 2. 3. 4. The problem will be identified to the Contractor (site supervisor). The Contractor’s head office will be contacted about the problem, orally, and later in writing. If the problem remains unresolved then the Ministry of Labour shall be notified of the violation and, if necessary, the work will be stopped until the problem is corrected. The Contract may be terminated by the City. Section GC25 is amended of the addition of the following: City of Thunder Bay Contract No. Section 00800 C.C.D.C. 4 - Supplementary General Conditions for use with C.C.D.C. General Conditions for Unit Price Contracts Page 17 of 24 GC25.7 The Contractor shall commence the Work within 7 days after receiving Notice from the Contract Administrator. The Contractor will not commence the work until the Contract has been officially accepted by the Corporation, the Insurance Certificates and the Labour and Materials Payment Bonds and the Performance Bonds are satisfactory to the Corporation, and the Contractor has received Notice from the Contract Administrator to commence the work. GC25.8 The Contractor shall provide for efficient drainage of all sections of the work during all stages of construction at his own expense. The Contractor will be held responsible for all damage which may be caused through his failure to provide proper drainage facilities. The Contractor shall restore any existing drainage works which are disturbed as a result of his construction activities. GC25.9 In order to assist the Corporation in inspecting the progress of the work, the Contractor shall prepare a Schedule of Work prior to starting the Contract and shall revise the schedule weekly for any changes throughout the Contract. Prior to commencement of construction the Consultant and the Contractor will locate on site those property bars, baselines and benchmarks which are necessary to delineate the Working Area and to lay out the Work, all as shown on the Contract Drawings. The Contractor shall be responsible for the preservation of all property bars while the Work is in progress, except those property bars which must be removed to facilitate the Work. Any property bars disturbed, damaged or removed by the Contractor’s operations shall be replaced under the supervision of an Ontario Land Surveyor, at no extra cost to the Owner GC25.10 The Contractor will give the Contract Administrator at least 48 hours notice in writing before requiring any baselines or benchmarks in connection with the work. The Contractor shall clearly state in such notice the exact location where levels, lines, or stakes are required. The Contractor must satisfy himself before commencing any work as to the meaning and correctness of all stakes and marks, and no claim will be entertained by the Corporation for or on account of any alleged inaccuracies, unless the Contractor notified the Contract Administrator of such inaccuracies in writing before commencing the work. The Contractor will be held responsible for the preservation of all stakes and marks in their proper positions, and where any of them are disturbed, lost or destroyed, it shall at once notify the Contract Administrator in writing, and all expenses incurred in replacing such stakes or marks will be billed against City of Thunder Bay Contract No. Section 00800 C.C.D.C. 4 - Supplementary General Conditions for use with C.C.D.C. General Conditions for Unit Price Contracts Page 18 of 24 the Contractor and if not paid by the Contractor will be deducted from any monies due the Contractor under the Contract. All stakes and marks set will not in every case represent all the grades, levels, lines, angles or surfaces in the finished work and in this regard the Contractor shall ensure that such stakes and marks are read correctly and used in a manner consistent with the plans, details, specifications and directions of the Contract Administrator. Should the Contractor discover or suspect any errors in stakes, lines, and grades which have been established for its use, the Contractor shall at once discontinue the work until such suspicions are investigated and any errors or misunderstanding rectified, but no claims shall be made or allowed on this account, or because of any resulting delay. The Contractor shall assume full responsibility for alignment, elevations, and dimensions of each and all parts of the Work, regardless of whether the Contractor’s layout work has been checked by the Contract Administrator. The Contractor shall furnish the Contract Administrator or any of his assistants with all reasonable help which may be required at any time in driving stakes or laying out the work. The Contractor will receive no additional compensation for this. GC25.11 Maintaining Roadways and Detours Where an existing Roadway is affected by construction, it shall be kept open to traffic, and the Contractor shall, except as otherwise provided in this subsection, be responsible for providing and maintaining for the duration of the Work, a road through the Work, whether along an existing Highway, including the road under construction, or on detours within or adjacent to the Highway, in accordance with the Manual of Uniform Traffic Control Devices The Contractor shall not be required to maintain a road through the Working Area until such time as the Contractor has commenced operations or on any part of the Contract that has been accepted in accordance with these General Conditions. Where localized and separated sections of the Highway only are affected by the Contractor's Operations, the Contractor will not be required to maintain intervening sections of the Highway until such times as these sections are located within the limits of the Highway affected by the Contractor's general operations under the Contract. The Contractor shall not be required to apply deicing chemicals or abrasives or carry out snowplowing. City of Thunder Bay Contract No. Section 00800 C.C.D.C. 4 - Supplementary General Conditions for use with C.C.D.C. General Conditions for Unit Price Contracts Page 19 of 24 Where the Contract Document provides for or the Contract Administrator requires detours at specific locations, payment for the construction of the detours, and if required, for the subsequent removal of the detours, will be made at the Contract prices appropriate to such work. The Contractor will bear the cost of maintaining, in a satisfactory condition for traffic, a road through the working area. The road through the Work will include any detour constructed in accordance with the Contract Documents or required by the Contract Administrator. Compensation for all labour, equipment and materials to do this work and to maintain the road, shall be considered to be included in the prices bid for the various tender items and no additional payment will be made. Where work under the Contract is discontinued for any extended period including seasonal shutdown, the Contractor shall, when directed by the Contract Administrator, open and place the roadway and detours in a passable, safe and satisfactory condition for public travel. Where the Contractor constructs a detour which is not specifically provided for in the Contract Document, or required by the Contract Administrator, the construction of the detour and, if required, the subsequent removal shall be performed at the Contractor's expense. The detour shall be constructed and maintained to structural and geometric standards approved by the Contract Administrator. Removal shall be performed as directed by the Contract Administrator. Where, with the written approval of the Contract Administrator, the Highway is closed and the traffic diverted entirely off the Highway to any other Highway, the Contractor shall, at no extra cost to the Owner, supply and erect traffic control devices in accordance with the MUTCD. Compliance with the foregoing provisions shall in no way relieve the Contractor of obligations under subsection GC21, Protection of Work and Property, dealing with the Contractor's responsibility for damage claims, except for claims arising on sections of Highway within the Working Area that are being maintained by others. In order to satisfy the Corporation that the Contractor has addressed concerns regarding traffic control and safety it will be required to submit a sketch indicating its proposed method of barricades and/or signage for each of the work sites included in the Contract. This information shall be available for review and approval by the Contract Administrator at the Contract preconstruction meeting. City of Thunder Bay Contract No. GC25.12 Section 00800 C.C.D.C. 4 - Supplementary General Conditions for use with C.C.D.C. General Conditions for Unit Price Contracts Page 20 of 24 Accessibility for Ontarians with Disability Act, Reg. 429/07 Subsection GC25.12 is added: Prior to the commencement of work under this contract, the Contractor shall also furnish evidence of compliance with requirements of the Accessibility for Customer Service Regulation 429/07, Section 6; Training for Staff. The City may, at its discretion, provide such training if the contractor is required to meet the requirements of Regulation 429/07 on and after January 1, 2012. SECTION GC26 - SUPERINTENDENCE Section GC 26 is amended by adding the following paragraph: GC26.4 To co-ordinate the work, the Contractor or a person authorized to act for the Contractor will attend regular meetings with the Contract Administrator or his representative during the period over which the work under the Contract is carried out, at a time and place to be decided by the Contract Administrator. SECTION GC27 - LABOUR AND PRODUCTS Section GC27 is amended by the addition of the following paragraphs: GC27.4 The Contractor shall not employ or hire any City employees who are employed in the Infrastructure & Operations Department. GC27.5 The labour conditions in this Contract are subject to The Industrial Standards Act and the Regulations made thereunder. The wage rates set out in the Roads and Structures and Sewer and Watermain Fair Wage Schedule have been established for a 1 year period commencing on the first day of April and are subject to change annually on that date. Any increase in costs incurred by a change in the wage rates shall be borne by the Contractor. GC27.6 For the purpose of these Labour Conditions "Work on Roads" includes the preparation, construction, finishing and construction maintenance of roads, streets, highways, and parking lots and includes all work incidental thereto other than work on structures. or "Work on Structures" includes the construction, reconstruction, repair, alteration, remodelling, renovation or demolition of any bridge, tunnel or retaining wall and includes the preparation for and the laying of the City of Thunder Bay Contract No. Section 00800 C.C.D.C. 4 - Supplementary General Conditions for use with C.C.D.C. General Conditions for Unit Price Contracts Page 21 of 24 foundation of any bridge, tunnel or retaining wall and the installation of equipment and appurtenances incidental thereto, provided, however, that the Minister of Labour, Ontario, may at their sole discretion determine whether any particular Work is to be classified as "Work on Roads" or as "Work on Structures" and such decision may be made notwithstanding the definition herein. GC27.7 The regular Work week for a person employed on Work being done under this Contract shall not exceed 55 hours and all time worked by such person in excess of 55 hours a week shall be overtime except that part of the hours of Work in excess of 55 hours a week which, together with the hours worked in the preceding week, do not exceed 55 hours. GC27.8 Every person employed by the Contractor or a sub-Contractor or other person to do any part of the Work contemplated by this Contract shall be paid while employed on such Work at not less than the wage rates set out in the Roads and Structures Fair Wage Schedule for the appropriate classification of such Work or not less than such other wage rates as, during the continuance of the Work, are fixed by the Minister of Labour, Ontario, for hours of Work that are not overtime and shall be paid not less than 1 1/2 times such wages for all hours of Work that are overtime. GC27.9 Notwithstanding that a Contractor pays wages in excess of the wage rates set out in the Roads and Structures Fair Wage Schedule hereunder, he shall not, in computing overtime wages payable to an employee, set off against such overtime wages any part of the wages earned by the employee in respect of his/her regular work period. GC27.10 Decision by Minister of Labour Where there is no appropriate classification set out in the Roads and Structures Fair Wage Schedule for any particular class of Work, the Minister of Labour, Ontario, may designate or establish the appropriate classification and the wage rate. The Contractor, upon receipt of Notice of any decision of the Minister of Labour, Ontario made under this Contract, shall immediately adjust the wage rates, hours and classification of Work so as to give effect to such decision. GC27.11 Fair Wage Schedule to be Posted The Contractor shall post prominently and maintain on the site of the Work legible copies of these Labour Conditions, including the Roads and Structures Fair Wage Schedule and any amendments thereto. City of Thunder Bay Contract No. GC27.12 Section 00800 C.C.D.C. 4 - Supplementary General Conditions for use with C.C.D.C. General Conditions for Unit Price Contracts Page 22 of 24 Contractor to keep Records which are to be Open for Inspection The Contractor shall keep proper books and records showing the names, trades, addresses and hourly wage rates of all employees in his employ and the wages paid to and time worked by such employees both at regular wage rates and at overtime wage rates, and the books or documents containing such records shall be open for inspection by Officers of the Ministry of Labour, Ontario, at any time it may be expedient to the Minister of Labour to have the same inspected. Note to Project Engineer If tese General Conditions are to apply to work included in the ICI Sector, add the following clause: GC27.13 Fair Wage Policy – ICI Sector Projects The labour conditions in this Contract are subject to the City of Thunder Bay Fair Wage Policy and associated Fair Wage Schedule current at the time tenders are closed for this contract. Copies of both the current Fair Wage Policy and Schedule are available from the Transportation and Works Department and/or from the City’s web site. The Contractor is responsible for ensuring that all Sub-Contractors are aware of and have received a copy of the Fair Wage Policy and Schedule. Notwithstanding that a Contractor pays wages in excess of the wage rates set out in the Fair Wage Schedule hereunder, he shall not, in computing overtime wages payable to an employee, set off against such overtime wages any part of the wages earned by the employee in respect of his/her regular work period. Fair Wage Schedule to be Posted … The Contractor shall post prominently and maintain on the site of the Work, legible copies of the Fair Wage Policy and Fair Wage Schedule and any amendments thereto. Contractor to keep Records which are Open for Inspection … The Contractor shall keep proper books and records as prescribed in the Fair Wage Policy and make these records available for inspection by the City if requested in accordance with the Policy. SECTION GC29 - USE OF THE WORK GC29 is amended by the addition of the following subsections: City of Thunder Bay Contract No. Section 00800 C.C.D.C. 4 - Supplementary General Conditions for use with C.C.D.C. General Conditions for Unit Price Contracts Page 23 of 24 GC29.3 The Contractor shall maintain the Working Area in a tidy condition and free from the accumulation of debris, other than that caused by the Owner, or others. GC29.4 The Contractor shall ensure that during night work the site of the Work is adequately floodlit to the Contract Administrator's satisfaction for Work operations, inspections and advance warning to traffic. GC29.5 Streets beyond the limits of the work and other construction areas shall be kept clean. Dusty materials shall be transported in covered haulage vehicles. Wet materials shall be transported in suitable watertight haulage vehicles. GC29.6 The Contractor shall take such steps as may be required to prevent dust nuisance resulting from its operations either within the limits of the work or elsewhere or by public traffic where it is the Contractor's responsibility to maintain a roadway through the Work. GC29.7 Where the Work requires the sawing of asphalt or the sawing or grinding of concrete, blades and grinders of the wet type shall be used together with sufficient water to prevent the incidence of dust, wherever dust would affect traffic or wherever dust would be a nuisance to residents of the area where the Work is being carried out. GC29.8 Permitted dust control measures may include the application of calcium chloride, oil or water. In general, the use of calcium chloride and oil shall be kept to a minimum and is restricted to vehicle rights-of-way. More frequent applications of water in close proximity to watercourses. The Contract Administrator's acceptance shall be obtained before chemicals or oil for dust control are used. SECTION GC34 - SHOP DRAWINGS Replace paragraph 34.4 with the following: GC34.4 Shop Drawings which require review by the Contract administrator or consultant should be submitted in accordance with Section 01300 Submittals. ADDITIONS TO THE GENERAL CONDITIONS The following clauses are additional conditions of the Contract: SECTION GC37 - RECORD DRAWINGS City of Thunder Bay Contract No. Section 00800 C.C.D.C. 4 - Supplementary General Conditions for use with C.C.D.C. General Conditions for Unit Price Contracts Page 24 of 24 The Contractor shall keep one set of Contract drawings on the site at all times. As the work progresses, he shall record, in a neat legible manner, all changes in the work. The following information shall be recorded for each change: i) Full Description of change ii) Date iii) Authority At the completion of work, this set of drawings shall be forwarded to the Engineer for incorporation in a set of “RECORD” drawings for this project.