MINNESOTA STATE COLLEGES AND UNIVERSITIES DIVISION 27 00 00 INTEGRATED AUDIOVISUAL SYSTEMS AND EQUIPMENT – TABLE OF CONTENTS SECTION TITLE Section 27 05 26 GROUNDING BONDING AND RF SUPPRESSION Section 27 05 28 HANGERS AND SUPPORT HARDWARE Section 27 05 53 IDENTIFICATION Section 27 41 00 GENERAL CONDITIONS AND REQUIREMENTS OF AUDIOVISUAL SYSTEMS Section 27 41 01 TRAINING FOR AUDIOVISUAL SYSTEMS Section 27 41 16 INTEGRATED AUDIOVISUAL SYSTEMS AND EQUIPMENT END OF TABLE OF CONTENTS SM&W Project No. 09031 – Integrated Audiovisual Systems - Table of Contents MSU, M Project No. 79613 Section 27 00 00 – Page 1 of 1 MINNESOTA STATE COLLEGES AND UNIVERSITIES SECTION 27 05 26 GROUNDING BONDING AND RF SUPPRESSION PART 1 - GENERAL 1.1 SUMMARY A. B. C. 1.2 Section Includes: 1. Grounding System for Audiovisual Systems 2. Bonding System for Audiovisual Systems Description 3. RF Suppression for Audiovisual Systems Description Definitions: 1. Grounding: A conducting connection between an electrical circuit or equipment and earth having sufficient current-carrying capacity to prevent buildup of voltages that may result in undue hazards to connected equipment or persons. 2. Bonding: The permanent joining of metallic parts to form an electrically conductive path that ensures electrical continuity and the capacity to conduct safely current likely to be imposed. 3. RF Suppression: The process of effectively protecting audio and video circuits from Radio Frequency transmissions and the suppression of the those transient signals to ground by means of a proper bonding path. Responsibilities 1. The Grounding System is to be performed by the Division 26 Electrical Contractor. 2. The Bonding and RF Suppression System is to be performed by the Division 27 Audiovisual Contractor. DESCRIPTION A. B. GROUNDING SYSTEM DESCRIPTION 1. Grounding of all components and electrical distribution items for protection of personnel to be by UL and NEC means. 2. AC Power receptacles mounted in equipment racks to be isolated ground type with supplemental grounding conductor to the electrical distribution panel board. The receptacles to be mounted in metal box that is to be bonded to the equipment rack at the bonding bar. 3. Power Strips mounted internal to equipment rack to be served from isolated ground receptacles. BONDING SYSTEM DESCRIPTION 1. Bonding of components with three prong grounded power cords. Components to be securely mounted to equipment rack utilizing rack rail and screws. SM&W Project No. 09031 – Grounding Bonding and RF Suppression MSU, M Project No. 79613 Section 27 05 26 – Page 1 of 3 MINNESOTA STATE COLLEGES AND UNIVERSITIES C. 2. Bonding of components with two prong non-grounded power cords. Components to securely mounted to equipment rack utilizing rack rail and screws. Where items are NOT rack mounted. A #14 AWG insulated stranded copper conductor to be installed from metal equipment chassis to equipment rack bonding bar. Utilize crimp style connectors. 3. All equipment racks to be provide with bonding stud in base of rack. A #12 AWG insulated copper stranded conductor to be run to a bonding bar located at accessible location at side of each rack. RF SUPPRESSION SYSTEM DESCRIPTION 1. AV Cable shield to be terminated at designated “ground” pin. 2. Audio Video Contractor to test each designated AV circuit “ground” pin for continuity with equipment metal enclosure. If no continuity is found (Pin 1 problem) the shield ground to be disconnected from the connector and connected directly to the equipment metal enclosure via an isolated equipment wire. PART 2 - PRODUCTS 2.1 MATERIALS A. EQUIPMENT BONDING CONDUCTORS 1. B. Material: Type THHN insulated stranded copper conductors. BONDING BAR 1. Configuration: Bus bar to allow screw termination of multiple equipment bonding conductors 2. Product: a. Square D Model No. PK15GTAL b. For connection 12 bonding conductors c. Provided with lug for cable connection to Rack Bonding Stud PART 3 - EXECUTION 3.1 PREPARATION A. 3.2 3.3 Remove paint, mill oils, surface contaminants at connection points. EXISTING WORK A. Modify existing grounding and bonding system to maintain continuity to accommodate renovations. B. Extend existing grounding and bonding system using materials and methods as specified. INSTALLATION SM&W Project No. 09031 – Grounding Bonding and RF Suppression MSU, M Project No. 79613 Section 27 05 26 – Page 2 of 3 MINNESOTA STATE COLLEGES AND UNIVERSITIES A. Coordinate installation of isolated grounding conductor for circuits supplying AV equipment in accordance with IEEE 1100. END OF SECTION SM&W Project No. 09031 – Grounding Bonding and RF Suppression MSU, M Project No. 79613 Section 27 05 26 – Page 3 of 3 MINNESOTA STATE COLLEGES AND UNIVERSITIES SECTION 27 05 28 HANGERS AND SUPPORT HARDWARE PART 1 - GENERAL 1.1 SUMMARY A. 1.2 1.3 Section Includes: 1. Loudspeaker rigging hardware. 2. Conduit supports. 3. Cable supports 4. Formed steel channel. 5. Sleeves. 6. Mechanical sleeve seals. REFERENCES A. ASME B30 Safety Standards B. NFPA 70 National Electrical Code. SUBMITTALS A. Furnish submittals in accordance with general requirements specified in Division 1, PART 2 - PRODUCTS 2.1 LOUDSPEAKER RIGGING HARDWARE A. Configuration: 1. Center Channel Loudspeakers Type LS01 a. 2. Dead hung from structure Subwoofer Type SW01 a. Dead hung from structure B. All loudspeakers to be suspended from factory internal rigging points C. All loudspeaker rigging to be complete kits provided by a rigging manufacturer D. Shop built rigging is not approved. E. Manufacturers: 1. Polar Focus 2. Substitutions: Section 01600 - Product Requirements SM&W Project No. 09031 – Hangers and Support Hardware MSU, M Project No. 79613 Section 27 05 28 – Page 1 of 4 MINNESOTA STATE COLLEGES AND UNIVERSITIES 2.2 2.3 CABLE SUPPORTS A. Individual Cable Runs: Cable Ties – High strength nylon temperature rated to 185 degrees F. Self locking. Plenum rated where required. B. Non-Continuous Pathway: Caddy Cablecat Series. C. Cable Ladders: Middle Atlantic CLB series FORMED STEEL CHANNEL A. B. 2.4 2.5 Manufacturers: 1. Allied Tube & Conduit Corp. Model. 2. B-Line Systems Model. 3. Midland Ross Corporation, Electrical Products Division Model. 4. Unistrut Corp. Model. 5. Substitutions: Section 01600 - Product Requirements Product Description: Galvanized 12 gage steel. With holes 1-1/2 inches on center. SLEEVES A. Sleeves for Through Non-fire Rated Floors: 18 gage thick galvanized steel. B. Sleeves for Through Non-fire Rated Walls, Footings, and Potentially Wet Floors: Steel pipe or 18 gage thick galvanized steel. C. Sleeves for Through Fire Rated and Fire Resistive Floors and Walls, and Fire Proofing: Prefabricated fire rated sleeves including seals, UL listed. D. Stuffing Fire-stopping Insulation: Glass fiber type, non-combustible. MECHANICAL SLEEVE SEALS A. B. Manufacturers: 1. Thunderline Link-Seal, Inc. Model. 2. NMP Corporation Model. 3. Substitutions: Section 01600 - Product Requirements Not Permitted. Product Description: Modular mechanical type, consisting of interlocking synthetic rubber links shaped to continuously fill annular space between object and sleeve, connected with bolts and pressure plates causing rubber sealing elements to expand when tightened, providing watertight seal and electrical insulation. PART 3 - EXECUTION 3.1 EXAMINATION SM&W Project No. 09031 – Hangers and Support Hardware MSU, M Project No. 79613 Section 27 05 28 – Page 2 of 4 MINNESOTA STATE COLLEGES AND UNIVERSITIES 3.2 3.3 A. Section 01300 - Administrative Requirements: Verification of existing conditions before starting work. B. Verify openings are ready to receive sleeves. PREPARATION A. Remove incompatible materials affecting bond. B. Obtain permission from Architect/Engineer before using powder-actuated anchors. C. Obtain permission from Architect/Engineer before drilling or cutting structural members. INSTALLATION - HANGERS AND SUPPORTS A. B. C. Anchors and Fasteners: 1. Concrete Structural Elements: Provide precast inserts, expansion anchors, powder actuated anchors and preset inserts. 2. Steel Structural Elements: Provide beam clamps, spring steel clips, steel ramset fasteners, and welded fasteners. 3. Concrete Surfaces: Provide self-drilling anchors and expansion anchors. 4. Hollow Masonry, Plaster, and Gypsum Board Partitions: Provide toggle bolts and hollow wall fasteners. 5. Solid Masonry Walls: Provide expansion anchors and preset inserts. 6. Sheet Metal: Provide sheet metal screws. 7. Wood Elements: Provide wood screws. Inserts: 1. Install inserts for placement in concrete forms. 2. Install inserts for suspending hangers from reinforced concrete slabs and sides of reinforced concrete beams. 3. Provide hooked rod to concrete reinforcement section for inserts carrying pipe over 4 inches. 4. Where concrete slabs form finished ceiling, locate inserts flush with slab surface. 5. Where inserts are omitted, drill through concrete slab from below and provide through-bolt with recessed square steel plate and nut above flush with top of recessed into and grouted flush with slab. 6. Install cable support and spacing in accordance with NEC. 7. Do not fasten supports to pipes, ducts, mechanical equipment, or conduit. 8. Install multiple cable runs on common hangers. Supports: SM&W Project No. 09031 – Hangers and Support Hardware MSU, M Project No. 79613 Section 27 05 28 – Page 3 of 4 MINNESOTA STATE COLLEGES AND UNIVERSITIES 3.4 3.5 Fabricate supports from structural steel or formed steel channel. Install hexagon head bolts to present neat appearance with adequate strength and rigidity. Install spring lock washers under nuts. 2. Install surface mounted cabinets and racks with minimum of four anchors. 3. In wet and damp locations install steel channel supports to stand cabinets 1 inch off wall. INSTALLATION - SLEEVES A. Exterior watertight entries: Seal with adjustable interlocking rubber links. B. Conduit penetrations not required to be watertight: Sleeve and fill with silicon foam. C. Set sleeves in position in forms. Provide reinforcing around sleeves. D. Size sleeves large enough to allow for movement due to expansion and contraction. Provide for continuous insulation wrapping. E. Extend sleeves through floors 1 inch above finished floor level. Caulk sleeves. F. Where conduit or raceway penetrates floor, ceiling, or wall, close off space between conduit or raceway and adjacent work with stuffing fire stopping insulation and caulk airtight. Provide close fitting metal collar or escutcheon covers at both sides of penetration. FIELD QUALITY CONTROL A. 3.6 1. Section 01400 - Quality Requirements 01700 - Execution Requirements: Field inspecting, testing, adjusting, and balancing. PROTECTION OF FINISHED WORK A. Section 01700 - Execution Requirements: Requirements for protecting finished Work. B. Protect adjacent surfaces from damage by material installation. END OF SECTION SM&W Project No. 09031 – Hangers and Support Hardware MSU, M Project No. 79613 Section 27 05 28 – Page 4 of 4 MINNESOTA STATE COLLEGES AND UNIVERSITIES SECTION 27 05 53 IDENTIFICATION PART 1 - GENERAL 1.1 SUMMARY A. 1.2 Section Includes: 1. Nameplates. 2. Engraving. 3. Labels. 4. Wire markers. ENVIRONMENTAL REQUIREMENTS A. Section 01600 - Product Requirements: Environmental conditions affecting products on site. B. Install labels nameplates only when ambient temperature and humidity conditions for adhesive are within range recommended by manufacturer. PART 2 - PRODUCTS 2.1 MATERIAL A. Engraving 1. Configuration: a. B. Name Plate 1. C. Configuration: a. 1/8” Laminated three-layer plastic b. Engraved letters on contrasting background color c. Black material with white reveal color Embossed Label 1. D. Machined engraving into the physical plate or rack panel material Configuration: a. Embossed adhesive tape b. 1/8” inch white letters on black background. Wire Marker 1. Configuration: a. Computer printed or preprinted type b. 1/8” inch white letters on black background. SM&W Project No. 09031 – Identification MSU, M Project No. 79613 Section 27 05 53 – Page 1 of 4 MINNESOTA STATE COLLEGES AND UNIVERSITIES 2.2 ENGRAVING A. Technical and Rack Panels 1. 2.3 Configuration: a. Provide an identifier for each technical or rack panel b. Provide an identifier for each connector on the technical or rack panels. c. The contractor is responsible for the labeling scheme. d. Text size to be as indicated on plan e. Engraved letters to include paint fill. NAMEPLATES A. B. C. D. Major Equipment and Rack Identification 1. Including but not limited to Equipment Racks, Carts and Cases 2. Configuration: a. 1-1/2” tall nameplate with equipment Name and ID text centered in two rows: b. Provide identification at front and rear of equipment Individual Component Identification 1. Including but not limited to Amplifiers, Processors, and Switchers 2. Configuration: a. 1/4” tall nameplate with equipment Name and ID text centered in two rows: b. Label to be located on left hand top corner of component. Provide a uniform placement throughout rack. c. Provide nameplates at front and rear of each component. Control Identification 1. Including but not limited to items with individual control to be adjusted by the end user. 2. The label to identify control as it relates to this project and the desired adjustment. 3. Configuration: a. 3/8” tall nameplate b. 1/8” tall text c. Where multiple controls are located on a component, provide a single nameplate with properly spaced label to correspond with appropriate knob, switch or button. Equal Manufacturers: 1. Brady 2. 3M SM&W Project No. 09031 – Identification MSU, M Project No. 79613 Section 27 05 53 – Page 2 of 4 MINNESOTA STATE COLLEGES AND UNIVERSITIES 2.4 3. Identity Engraving 4. Proco 5. Rapco 6. Whirlwind 7. Substitutions: By approved substitution request means. LABELS A. Non-rack mount components 1. B. 2.5 Product: 1. Manufacturers: Brady 2. Substitutions: By approved substitution request means. WIRE MARKERS A. B. 2.6 Including but not limited to power supplies and non rack mounted components Cables 1. Including but not limited to power, audio, video, control cables 2. Provide label at each end of all cables 3. Contractor to develop wire numbering scheme 4. Not accepted: Hand written markers Product: 1. Manufacturers: Brady 2. Substitutions: By approved substitution request means. RECOGNITION A. Configuration: 1. Engraved Rack Panel 2. All installations shall bear the following identification rack panel, supplied by this contractor, mounted on the front of the main rack at the top: SYSTEMS DESIGNED BY: SHEN MILSOM & WILKE, INC. 2 N. Riverside Plaza, Suite 1460, Chicago, IL 60606 Tel: 312-559-4585 SYSTEMS FABRICATED & INSTALLED BY: (Contractor name address and contact information) SM&W Project No. 09031 – Identification MSU, M Project No. 79613 Section 27 05 53 – Page 3 of 4 MINNESOTA STATE COLLEGES AND UNIVERSITIES PART 3 - EXECUTION 3.1 PREPARATION A. 3.2 3.3 Degrease and clean surfaces to receive adhesive for identification materials. EXISTING WORK A. Install identification on existing equipment to remain in accordance with Related Sections. B. Install identification on unmarked existing equipment and wires. C. Replace lost nameplates labels markers. INSTALLATION A. B. Nameplate and label Installation: 1. Install nameplate parallel to equipment lines. 2. Install nameplate for each equipment rack, component, and control with adhesive. Wire Marker Installation: 1. Install wire marker for each cable at equipment connections, each intermediate termination and each device connection. END OF SECTION SM&W Project No. 09031 – Identification MSU, M Project No. 79613 Section 27 05 53 – Page 4 of 4 MINNESOTA STATE COLLEGES AND UNIVERSITIES SECTION 27 41 00 GENERAL CONDITIONS FOR INTEGRATED AUDIOVISUAL SYSTEMS PART 1 - GENERAL 1.1 SUMMARY A. This Audiovisual project is in direct connection to the 2009 Ostrander Auditorium Renovation project. Refer to plans and specifications prepared by RL Engebretson Architects for information. B. The Audiovisual systems reference the systems specifically identified for the Ostrander Auditorium. These systems are identified as: 1. Display Systems a. 2. 2) Video Projectors 3) Projection Screens Including but not limited to: 1) Input equipment 2) Distribution equipment 3) Audio and Video conferencing equipment 4) Wire and cable Including but not limited to: 1) Input equipment 2) Distribution equipment 3) Power amplifiers 4) Loudspeakers 5) Recording equipment 6) Production Intercom equipment 7) Wire and cable Control Systems a. 5. Flat Panel Displays Audio Systems a. 4. 1) Video Systems a. 3. Including but not limited to: Including but not limited to: 1) Control Panels 2) Control processors 3) Control Programming 4) Wire and Cable Miscellaneous SM&W Project No. 09031 – General Conditions for Audiovisual Systems MSU, M Project No. 79613 Section 27 41 00 – Page 1 of 27 MINNESOTA STATE COLLEGES AND UNIVERSITIES a. 1.2 1.4 1) Equipment Racks 2) Technical and Rack panels 3) Equipment Carts 4) Power distribution and conditioning REFERENCE TO MNSCU GENERAL CONDITIONS A. 1.3 Including but not limited to: The MNSCU General Conditions shall be considered part of this Specification. Unless this Section contains statements, which are more definitive or more restrictive than those contained in the Owner’s General Conditions, this Specification shall not be interpreted as waiving or overruling any requirements expressed in the General Conditions. RELATED WORK A. AV Contractor shall coordinate with Renovation Electrical Contractor on raceway/junction box locations for audio visual equipment and routing of audio, video, control, and power cables/raceway from equipment, terminal and pull boxes to system equipment racks. B. Related Work: Equipment and materials provided and installed by others, unless otherwise shown in this Section or the Drawings, shall include but are limited to: 1. Renovation items, refer to plans and specification prepared by RL Engebretson. 2. Telecommunications items, Separate Contract issued by MNSCU. DEFINITIONS A. The following shall serve as general identifiers as specified herein. 1. Owner – Minnesota State Colleges and Universities. 2. Renovation project Architect – RL Engebretson 3. Renovation MEP Consultant – Kako Engineering 4. Consultant – Shen Milsom & Wilke, USA. 5. Contractor – The Contractor is the firm submitting a proposal to furnish and install the Work as defined within this Specification. 6. Project – The Project is 2009 Ostrander Auditorium AV Renovations 7. Work – The term “Work” means all construction and services specified within this document. The Work includes all related labor, materials, equipment, and services provided, or to be provided, by the Systems Contractor to fulfill the proposal’s obligations. 8. Drawings – The term “Drawings” means all Audio Visual Systems Drawings and associated sketches, details, riser diagrams, etc. 9. As used in the Drawings and Specifications for the Work, certain nontechnical words and phrases shall be understood to have specific meanings as follows, regardless of indications to the contrary in the General Conditions or other documents governing the Work. SM&W Project No. 09031 – General Conditions for Audiovisual Systems MSU, M Project No. 79613 Section 27 41 00 – Page 2 of 27 MINNESOTA STATE COLLEGES AND UNIVERSITIES 10. a. “Furnish” – Purchase and deliver to the project site complete with every necessary appurtenance and support, all as part of the Audio Visual Systems Work. Purchasing shall include payment of all sales taxes and other surcharges as may be required to assure that purchased items are free of all liens, claims, or encumbrances. b. “Install” – Unload at the delivery point at the site and perform every operation necessary to establish secure mounting and correct operation at the proper location in the project, all as part of the Work. c. “New” – Manufactured within the past year and never before used. d. “Provide” – Furnish and Install. Regardless of their usage in codes or other industry standards, certain words or phrases as used in the Drawings or Specifications for the Work, shall be understood to have the specific meanings as ascribed to them in the following list: a. “Circuit” – Any specific run of circuitry b. “Circuitry” – Any Work which consists of wires, cables, raceways, and/or specialty wiring method assemblies complete with associated junction boxes, pull boxes, outlet boxes, joints, couplings, splices, and connections except where limited to a lesser meaning by specific description. c. “Concealed” (as applied to circuitry) – Covered completely by building materials, except for penetrations (by boxes and fittings) to a level flush with the surface as necessitated by functional or specified accessibility requirements. d. “Exposed” (as applied to circuitry) – Not covered in any way by building materials. e. “Normal Work Conditions” – Locations within building confines that are not damp, wet, or hazardous and that are not used for air handling. f. “Patch Panel” – A System of terminal blocks, patch cords, and backboards that facilitate administration of cross-connecting cables. g. “Raceway” – Any pipe, duct, extended enclosure, or conduit (as specified for a particular System) which is used to contain wires and which is of such nature as to require that the wires be installed by a “pulling in” procedure. h. “Riser” – Shall refer to the portion of the installation that transmits between building floors (or between Audio Visual Systems rooms), also referred to as “Backbone Cabling”. i. “Audio Visual Closet” – The enclosed area or room specifically designated for the routing, termination, and/or cross connecting of Audio Visual Systems cable (i.e. riser cable) to other Audio Visual Systems cable and/or equipment. j. “AV Systems Control Room” and/or “AV Systems Headend” – The enclosed area or room specifically designated for the routing, termination, and/or cross connecting of Audio Visual SM&W Project No. 09031 – General Conditions for Audiovisual Systems MSU, M Project No. 79613 Section 27 41 00 – Page 3 of 27 MINNESOTA STATE COLLEGES AND UNIVERSITIES System cable (i.e. riser cable) to other Audio Visual System cable, and/or equipment and racks. 1.5 k. “AV System(s)” – Audio Visual System(s), includes all components contained herein that work in conjunction to create and completely integrated and fully functioning system as described within the Drawings and Specifications l. “Audio Visual Systems Wiring” – see “Circuitry” m. “Audio Visual Systems Work” – See “Work” n. “Standard” (as applied to wiring devices) – Not of a separately designated individual type. o. “Subject to Mechanical Damage” – Exposed within 6 feet of the floor in mechanical rooms, manufacturing spaces, vehicular spaces, or other spaces where heavy items are moved around or rigged as a common practice or as required for replacement purposes. p. “System” – See “AV Systems” q. “Wiring” – see “Circuitry” r. “AVC” – Audio Visual Systems Contractor 11. Where the word “conduit” is used without specific reference to type, it shall be understood to mean “raceway”. 12. Reference to “U.L. (Materials Construction) Standards” shall mean the “Standards for Safety” published by Underwriters Laboratories, Inc. SCOPE OF WORK A. B. General: 1. Provide audio visual systems design, engineering, and installation within all phases and spaces of the Project. Systems are to include all devices, equipment, installation, programming and commissioning in accordance with requirements of the contract documents and drawings. 2. The Work detailed within the Contract Documents has been specified to meet certain requirements for performance, appearance, and costs. It shall be the responsibility of the Contractor to implement the guidelines and requirements contained in the Contract Documents and translate them into a complete design package containing all elements necessary for a complete, operational, and functionally integrated Audio Visual System(s). 3. Provide all work as detailed in the Contract Documents as a turnkey installation including all material, labor, engineering, warranties, taxes, freight, and permits. Only items and requirements specifically stated to be provided by others shall not be a requirement for this Section of the Work. Work Included: 1. C. Refer to Sections contained in 27 41 16 for Scope requirement and System descriptions. Work Specified Elsewhere SM&W Project No. 09031 – General Conditions for Audiovisual Systems MSU, M Project No. 79613 Section 27 41 00 – Page 4 of 27 MINNESOTA STATE COLLEGES AND UNIVERSITIES D. 1.6 1. Installation of raceway, pull-boxes, plywood backboards and floor-boxes (provided under electrical Work). Coordination is required within the design to verify the appropriate raceways are in place. 2. Installation of Cable Tray 3. Installation and termination of Data and Communication Structured Cabling and RF distribution systems. 4. Cutting, patching and painting of walls, unless damaged performing the work described herein. 5. Lighting Control systems 6. Demolition of Existing Audiovisual Systems Coordinated Work 1. Coordinate with related trades to schedule the Work and ensure a complete installation in accordance with the schedule outlined by the Owner. 2. Coordinate all IP device requirements with the Data vendor, Owner, and Contractor. 3. Coordinate all network connectivity requirements with the low voltage cabling contractor and Owner. ALTERNATES A. Bidders to identify the following alternate items in the RFP Response. B. The cost of base bid items to be included in the base bid price and the alternate items to be identified individually. C. Alternate Description: 1. 2. Alternate #1 – Digital Media System a. Base Bid: include all components for a complete operating system as described on the construction documents. b. Deduct Alternate: Omit all components, labor and materials for the digital media system, this to include: 1) Items shown on AV Sheet AV 5-0 2) All associated wiring 3) All associated connectors shown on technical and rack panels detailed on sheet AV 6-0 and AV 6-1 4) All associated Digital Media components located within the Media Cart MC-01 Alternate #2 – Confidence Monitor a. Base Bid: Include the confidence monitor and related mounting hardware and labor. b. Deduct Alternate: Omit the confidence monitor and related mounting hardware and labor. 1) Cabling from systems to associated wall plate not to be omitted. SM&W Project No. 09031 – General Conditions for Audiovisual Systems MSU, M Project No. 79613 Section 27 41 00 – Page 5 of 27 MINNESOTA STATE COLLEGES AND UNIVERSITIES 3. 1.7 Alternate #3 – Media Cart a. Base Bid: Include all components for a complete operating Media Cart as described in the construction documents. b. Deduct Alternate: Omit all components, labor and materials for the Media Cart, this to include: 1) All items relating to the media cart shown on AV Sheet AV5-3 2) The physical Media Cart GENERAL CONDITIONS A. Work Experience Coordination and Compliance 1. The Contractor represents that they are familiar with, and have expertise in the Work of this nature and scope. The Contractor further agrees that they shall provide all Work as may be required to make a complete job of that which may not be fully defined in the Programmatic Documents. 2. The Contractor shall comply with all of the regulations, including safety regulations of national, city, local and other government agencies having jurisdiction concerning the work of the Contractor. The Contractor shall give all notices and comply with all laws, ordinances, codes, rules, and regulations bearing on the conduct of the Work. If the Contractor performs any work, which is contrary to such laws, ordinances, codes, rules and regulations, they shall make all changes for compliance and bear all associated costs. 3. The Contractor warrants that both they and their subcontractors are licensed as required by the authorities having jurisdiction and as required by local ordinances. 4. The Contractor must state if they intend to utilize a subcontractor, and provide said subcontractor's name and address. The subcontractor shall comply with all the same rules, regulations, laws and codes, licenses, etc. as required by the Contractor and as specified herein. The Owner reserves the right to approve or disapprove any subcontractor proposed by Contractor. 5. All of the Contractor's work shall be tested and inspected by all authorities having jurisdiction and in accordance with all Specifications. The Contractor shall coordinate and cooperate fully and shall provide at no additional cost to the Owner, manpower, blueprints, facilities, scaffolds, etc. to reasonably assist the inspectors. 6. All permits required for any part of the Contractor's work shall be procured and paid for by the Contractor. The Contractor shall determine all permits required and transmit this information to the Owner. 7. The Work called for under this Contract shall be simultaneously with the Work of other trades and Owner such a manner as to not delay the overall progress of the project. The Contractor is responsible for all coordination with other trades. 8. Include in the Work all necessary supervision and issuing of all coordination information to any other trades who are supplying work to accommodate the Audio Visual Systems installation. SM&W Project No. 09031 – General Conditions for Audiovisual Systems MSU, M Project No. 79613 carried on functions in construction of the Work Section 27 41 00 – Page 6 of 27 MINNESOTA STATE COLLEGES AND UNIVERSITIES 9. B. C. Structured cabling is specified to be provided by the low voltage cable contractor, the Audio Visual Systems Contractor shall identify the cable types, quantities, lengths, and final locations to be terminated and provide them to the Owner and the low voltage cable contractor to be provided and installed. It is the Contractor’s responsibility to ensure that the information is complete and accurate. Any errors or omissions in the ordering information will be the responsibility of the Contractor. Quality of Workmanship 1. The Contractor, upon receiving notice from Owner that the Contractor has furnished inferior, improper or unsound work or materials (including equipment), or work or materials at variance with that which is specified, will, within 24 hours, proceed to remove such work or materials and make good all other work or materials damaged thereby, and, at the option of the Owner, the Contractor shall immediately replace such work or materials with work or materials as specified. The removal, replacement, and repair shall be performed at such times and with manpower sufficient, in the judgment of the Owner, so as to avoid disturbance to occupants, or other ongoing work for the Project. 2. If the Contractor does not remove such unsound Work within a reasonable time, the Owner may remove it and may store the material at the expense of the Contractor. If the Contractor does not pay the expenses of such removal within ten (10) days time thereafter, the Owner may, upon written notice, sell such materials at auction or at private sale and shall account for the net proceeds thereof, after deducting all the costs and expenses that should have been borne by the Contractor and all expenses of the sale. 3. The Owner shall have the authority at all times, until final completion and acceptance of the Work, to inspect and reject work and materials which in its judgment are not in conformity with the Drawings and Details, Room Data Sheets and Specifications, and its decision in regard to character and value of Work shall be final and conclusive on both contracting parties. If the Owner permits said Work or materials to remain, the Owner shall be allowed the difference in value or shall at its election have the right to have said Work or materials repaired or replaced, as well as the damage caused thereby, at the expense of the Contractor, at any time within one (1) year after the completion of the entire project, or within such longer period as may be covered by any guaranty; and neither payments made to the Contractor, nor any other acts of the Owner, shall be construed as evidence of acceptance, waiver, or estoppels. 4. Any expense incurred by the Owner in connection with the foregoing, shall be borne by the Contractor, and the Owner may withhold money due to the Contractor or recover money already paid to the Contractor, to the extent of such expense. On-Site Storage 1. The Contractor shall be responsible coordinate and maintain a storage space. 2. If this storage space is required to be on-site it shall be the Contractor's responsibility to coordinate the size and spatial requirements with the Owner. SM&W Project No. 09031 – General Conditions for Audiovisual Systems MSU, M Project No. 79613 Section 27 41 00 – Page 7 of 27 MINNESOTA STATE COLLEGES AND UNIVERSITIES D. 3. The Contractor shall assume full responsibility for the storage space and all contents, unless otherwise indicated by the Owner. 4. The Contractor shall examine the site and the Programmatic Documents and review with the Owner the designated areas of access, delivery, and storage for the Contractor's use. The Contractor agrees that such areas are satisfactory and sufficient for their needs in the completion of their work and in conformance with the terms of this Contract. Protection from Damage 1. E. Owner Furnished Equipment 1. The Owner reserves the right to furnish any materials necessary for the Project. 2. For items of equipment which are to be installed but not purchased as part of the Work, the Work shall include: 3. F. The Contractor shall provide all protection necessary to safeguard their work from damage by their operations and the operations of others. Unless the Contractor proves to the Owner’s satisfaction that the Work has been damaged by others, the Contractor shall promptly repair, adjust, and clean all defective installations and bear all associated costs. a. Coordination of delivery b. Unloading from delivery trucks c. Safe handling and field storage up to the time of permanent placement in the project d. Correction of any damage to the item(s) e. Mounting in place and connection(s) as specified Items which are to be installed, but not purchased as part of the Work shall be carefully examined upon delivery to the project. Claims that any of these items have been received in such condition that their installation will require procedures beyond the reasonable scope of the Work will be considered only if presented in writing within one (1) week of the date of delivery to the project of the items in question. The Work includes all procedures necessary to put in satisfactory operation all items for which no claims have been submitted as outlined above. Design Intent 1. The project documentation is, in general, diagrammatic and/or developed to communicate design intent. The Contractor shall coordinate the installation of all devices and/or equipment with the Owner prior to installation based on the existing field conditions. 2. It shall be understood that the Specifications and Drawings are complementary. Where there are conflicts within the documents, the overall design intent shall govern. 3. To the extent that they govern the Work, the Program documents, Specifications and Drawings also govern change order Work, if any. 4. The Drawings for the Work utilize symbols and schematic diagrams that have no dimensional significance. The Work shall be installed to fulfill SM&W Project No. 09031 – General Conditions for Audiovisual Systems MSU, M Project No. 79613 Section 27 41 00 – Page 8 of 27 MINNESOTA STATE COLLEGES AND UNIVERSITIES the diagrammatic intent expressed on the Drawings, field layouts, and shop drawings of all trades. 1.8 5. Certain details appear on the Drawings for the Work that are specified with regard to the dimensioning and positioning of the Work. These are intended only for general information purposes. They do not obviate field coordination for individual items of the indicated Work. 6. Information as to general construction and architectural general construction and architectural features and finishes shall be derived from the structural and architectural drawings and specifications, are may require ongoing coordination with the Architect. 7. Ratings of devices, materials, and equipment specified without reference to specific performance criteria shall be understood to be nominal or nameplate ratings established by means of industry standard procedures. 8. It is the intent of the Drawings and Specifications to provide complete operating Audio Visual Systems. All Work necessary to provide such a System shall be performed. Any discrepancies shall be brought to the Consultant’s attention. PROJECT MANAGEMENT A. Project Manager 1. The Contractor shall provide a Project Manager to oversee and coordinate all activities on the Project 2. Project Manager’s Duties and Responsibilities: a. The Contractor shall provide to the Owner, as a part of the prefabrication submittal, the name of the Project Manager that will provide all duties and responsibilities as specified herein, during the term of the project. b. The Project Manager shall maintain the ability of making all managerial decisions on behalf of the Contractor on a day-to-day basis, and shall retain the authority of accepting notices of deduction, inspection reports, payment schedules and any other project related correspondence on behalf of the owner. c. The Project Manager shall schedule and attend project management meetings, during which time all System related issues are discussed, scheduled, confirmed, and/or resolved. d. The Project Manager shall be available during normal business hours during the term of the project. e. After normal business hours, the Project Manager shall be available within four (4) hours by telephone during the term of the project. 1) In the event that the Project Manager is not available within the allotted time frame, the Contractor may designate another employee to temporarily act as the Project Manager in all correspondence with the Owner. 2) The Contractor shall ensure that any individual temporarily assuming the duties of the Project Manager SM&W Project No. 09031 – General Conditions for Audiovisual Systems MSU, M Project No. 79613 Section 27 41 00 – Page 9 of 27 MINNESOTA STATE COLLEGES AND UNIVERSITIES is at equal or higher level in the Contractor’s managerial chain of command. 3. 4. 1.9 Upon notification by the Owner, of any project related installation issue, or issue that may contradict the Specifications as stated herein, the Project Manager shall respond to such issue, verbally and/or in writing within an eight (8) hour period. a. Responses to such issues as stated above shall include a clear understanding of the issue, along with a tentative plan of action, reflecting milestones and/or deadlines to resolve the issue. b. Where appropriate, based on the overall importance of the project issue, the Project Manager shall follow-up their initial response with a written response to the issue within 24 hours of identification of the issue. Prior to the initiation of the Work, the Project Manager shall submit a schedule reflecting key milestones of the Work, including but not limited to the following: a. Bid award b. Kick-off meeting c. Master Plan submittal d. Prefabrication submittal e. Ordering, delivery, equipment f. Field equipment delivery g. Project management schedule h. Payment schedule i. Installation completion date j. System training k. Delivery of As-Built documentation l. Delivery of Operations & Maintenance Manuals m. Final System test n. Acceptance of System and installation of head-end System 5. The Project Manager shall update the schedule on a weekly basis to reflect the status of each key milestone as the Work progresses. 6. As the System installation progresses, the Project Manager shall be capable of discussing any/or all of the above mentioned items at the request of the Owner, and shall address each item, as it relates to the current status of the Work. REFERENCES A. The Audio Visual Systems shall be installed in accordance with the latest applicable revisions pertaining to all applicable national, state, and local codes and standards including, but not limited to the following: 1. National Electrical Code (NEC), current state recognized edition. SM&W Project No. 09031 – General Conditions for Audiovisual Systems MSU, M Project No. 79613 Section 27 41 00 – Page 10 of 27 MINNESOTA STATE COLLEGES AND UNIVERSITIES 1.10 2. Uniform Building Code (UBC), current state recognized edition. 3. Local Governing Authorities Having Jurisdiction SUBMITTALS A. Sequence 1. Shop Drawings - Upon award of Contract, submittals shall be prepared and submitted for review by the Owner, Architect and AV Consultant prior to commencement of any work. 2. Record Documents - Upon completion of systems and Contractor System Check Out, Record Documents to be created and submitted for review prior to system final acceptance. 3. Operation and Maintenance Manuals– Shall be produced for review prior to Owner Training. B. Furnish submittals in accordance with general requirements specified in Division 1, SUBMITTAL PROCEDURES C. Prefabrication Submittals D. 1. Submit pre-fabrication submittals in accordance with the Owner’s construction schedule. 2. Pre-fabrication submittals shall consist of product data, shop drawings, samples, and a detailed completion schedule. Partial submittals will not be accepted without prior written approval from the Architect. 3. Pre-fabrication submittals shall be furnished in electronic formats as defined by the General Conditions under Part 1 of the Project Specifications. 4. No portion of the Work shall commence nor shall any equipment be procured until the Architect has approved the pre-fabrication submittals in writing. 5. A letter of transmittal identifying the name of the Project, Contractor’s name, date submitted for review, shall accompany pre-fabrication submittals and a list of items transmitted. 6. Product data required as part of the pre-fabrication submittal shall include the following: Product Submittals 1. Equipment schedules listing all System components, manufacturer, model number and the quantity of each 2. Submit manufacturer’s product data sheets for all materials and equipment proposed for use on the project sorted by room and indexed. a. 3. Mark each product data sheet to show applicable choices and options (sheets containing more than one device or component model number shall be clearly marked to delineate items included in the Work) Submit manufacturer's product data sheets for all fire stopping materials proposed for use on the project. SM&W Project No. 09031 – General Conditions for Audiovisual Systems MSU, M Project No. 79613 Section 27 41 00 – Page 11 of 27 MINNESOTA STATE COLLEGES AND UNIVERSITIES E. 4. A complete list of finishes and sample graphics, including custom art work and custom graphics (if applicable) 5. DSP Program Matrix drawings or program print out. Project Calculations 1. Verification of the focal lengths of projection lenses to achieve the specified image sizes. 2. Cable run sheets denoting cable type, signal type, termination type, cable number designation, start point and end point. 3. F. Training Syllabus – provide an outline of the contents for the training curriculum. G. Shop Drawings H. I. 1. Detailed plan views and elevations of AV Control and/or Headend rooms (in addition to relevant telecommunications rooms) showing raceway, sleeves, cable tray, cable paths, equipment racks, equipment cabinets, termination blocks, power receptacles and grounding bus bars. 2. Cable termination schedules showing cable transmission and device location. Provide schedules in printed and electronic format. 3. Floor plan drawings indicating device locations with device legends 4. System riser diagram with all devices, wire runs, and wire designations 5. Schematic block diagrams for each System showing all equipment, interconnects, data flow, etc. 6. Fabrication shop drawings for all custom equipment (if applicable) 7. Plans and elevations of the Audiovisual equipment racks and/or custom furniture (including consoles, desks, and lecterns) quantifying all equipment to be mounted therein 8. It is the responsibility of the Contractor to confirm all dimensions, quantities, and the coordination of materials and products supplied by the Contractor with other trades. Approval of shop drawings containing errors does not relieve the Contractor from making corrections at their expense. Samples 1. The Contractor shall submit samples of any equipment components upon request of the Owner. 2. Samples submitted shall be the latest version of equipment. Record Documentation 1. Shall include all information required in the Pre-fabrication Submittals but revised to reflect “as installed” conditions. 2. General Description and Requirements a. Submit Record Documentation in accordance with the Architect’s construction schedule. SM&W Project No. 09031 – General Conditions for Audiovisual Systems MSU, M Project No. 79613 Section 27 41 00 – Page 12 of 27 MINNESOTA STATE COLLEGES AND UNIVERSITIES 3. b. Provide a letter of transmittal with Record Documentation identifying the name of the Project, Contractor’s name, date submitted for review, and a list of items transmitted. c. Prior to the final acceptance of the Work, submit two draft sets of the Record Drawings portion of Record Documentation to the Architect. The draft copy shall be used during the final acceptance testing by the Architect. d. Update all record documentation to reflect changes or modifications made during final acceptance testing as required and submit three blue/black lines and one reproducible set. e. Provide cable test results for all cables installed under this Work, tested and documented as described herein. f. Provide Owner with all systems programming on electronic media. The Owner is granted the rights to use and modify the code for the systems specified within this scope of work. Record Drawings a. 4. Produce all Record “as-built” Drawings using the latest version of AutoCAD and in PDF format. Record drawings shall, at a minimum, include the following: 1) Floor plan drawings indicating device locations, with device legends indicating manufacturers and model numbers for each device 2) Floor plan drawings indicating wire routing, wire routing shall be delineated in straight line runs and be tagged with cable identification and terminal strip numbers to coincide with the installation 3) Mounting details for all equipment and hardware 4) Functional block diagrams for each subsystem 5) Wiring details showing rack elevations, equipment wiring and terminations, and inter-rack wiring 6) Wiring diagrams for all custom circuitry including interfaces to various control output controlled devices, lighting control interfaces, projections screens, operable window treatments, motorized doors/partitions, etc. 7) Wiring diagrams for each System, wiring diagrams shall be identical to those laminated and located within the door of 8) Typical point-to-point wiring diagrams for each piece of equipment and groups of equipment within the System 9) Layout details for each riser location, including Audiovisual panels, power supplies, junction boxes, conduit, and any other Audiovisual related equipment Operation and Maintenance Manuals a. Operation and Maintenance Manuals shall apply to all Audio Visual related devices, equipment and software modules. SM&W Project No. 09031 – General Conditions for Audiovisual Systems MSU, M Project No. 79613 Section 27 41 00 – Page 13 of 27 MINNESOTA STATE COLLEGES AND UNIVERSITIES b. c. d. Operation and Maintenance Manuals shall be formatted as follows: 1) Bind each manual in a hard-back loose-leaf binder. 2) Identify each manual’s contents on the cover. 3) Provide a table of contents and tabulated sheets for each manual. Place tab sheets at the beginning of each chapter or section and at the beginning of each appendix if applicable. 4) Any hardware manual demonstrating more than one model number of device on any one page shall be clearly marked as to delineate which model has been implemented in the Work. Operation and Maintenance Manuals shall include, at a minimum, the following: 1) Operational description of each subsystem 2) Detailed programming descriptions for each subsystem 3) Explanations of subsystem interrelationships 4) Electrical schematics for each piece of equipment specified 5) Power-up and subsystem 6) Description of all diagnostic procedures 7) A menu tree for each subsystem 8) Setup procedures subsystems 9) A list of manufacturers, their local representatives, and subcontractors that have performed Work on the Project 10) Installation and service manuals for each piece of equipment 11) Maintenance schedules for all installed components power-down for procedures each component for each of the Operation and Maintenance Manuals shall include a separate section for each software program incorporated into the Project. The software section shall include, at a minimum, the following information: 1) Definitions of all software related terms and functions 2) Description of required sequences 3) Directory of all disk files 4) Description of all communications protocols, including data formats, command characters, and a sample of each type of data transfer 5) Instructions for manufacturer supplied report generation 6) Instructions for custom report generation 7) Database format and data entry requirements SM&W Project No. 09031 – General Conditions for Audiovisual Systems MSU, M Project No. 79613 Section 27 41 00 – Page 14 of 27 MINNESOTA STATE COLLEGES AND UNIVERSITIES 8) 5. e. Make corrections or changes in O & M and/or Record Drawings as required by the Architect and resubmit when the Architect’s stamp requires re-submittal. f. Clearly identify changes made other than those specifically requested by the Architect when resubmitting Record Drawings. Changes shall be clouded or similarly highlighted as coordinated with the Architect. Only changes that have been specifically requested by the Architect or have been clouded by the Contractor will be reviewed on resubmittals. g. Any drawing sheets added to the resubmittal shall be clearly identified and clouded, and shall not change the sheet numbering scheme for previously issued Record Drawings. h. The Contractor shall be responsible for any delays caused by the re-submittal process. Re-submittal Review Fees a. 1.11 Procedure for Resubmitting If the Architect rejects the Contractor’s Record Submittal (Rejected, Revise, and Resubmit) more than two times, the Architect will be compensated for all subsequent reviews, whether partial or comprehensive. The amount of such compensation will be incorporated by Change Order and withheld from the Contractor’s Application for Payment. QUALITY ASSURANCE A. Contractor Qualifications 1. Work specified herein shall be the responsibility of a single Audio Visual Systems Contractor. Bid submission shall document a minimum of five (5) years experience in the fabrication, assembly, and installation of Systems of similar complexity as specified herein. The documentation shall include the names, locations, and points of contact for at least three (3) installations of the type and complexity specified herein. 2. Installer Training Process: – Contractor’s labor force shall have certified installers who attended training programs of the proposed system preparing them to perform the work. 3. The Installer for this Project is to be certified by all manufacturers of the installed equipment that the Contractor proposes. 4. Registered and Certified supervisors- Contractor must have all supervisory personnel certified for the type of work they are overseeing (installation and design) from Infocomm International. 5. Quality assurances for audio visual systems includes a multi-step program consisting of pre-qualification procedure for manufacturers and installation specialists; products phase; installation; operating instruction and training; and the submission of maintenance and operating manuals. 6. The Contractor shall have local in-house engineering and project management capabilities consistent with the requirements of the Work. 7. By submitting a bid, the Contractor thereby certifies that it is qualified in all areas pertaining to, directly or indirectly, the Work. In the event the Contractor becomes unable to complete the Work in accordance with the SM&W Project No. 09031 – General Conditions for Audiovisual Systems MSU, M Project No. 79613 Section 27 41 00 – Page 15 of 27 MINNESOTA STATE COLLEGES AND UNIVERSITIES Contract Documents, or the satisfaction of the Owner, it shall be the responsibility of the Contractor to retain the services of applicable manufacturers’ representatives to expeditiously complete the Work in accordance with the Owner’s construction schedule with no additional cost to the Owner. B. 8. The Contractor shall maintain, or establish and maintain, a fully staffed office including a service center capable of providing maintenance and service to the Project. The Contractor shall staff the service center with factory trained technicians and adequately equip the office to provide emergency service within seventy-two (72) hours after being called, 24 hours per day. 9. The Contractor shall provide factory-certified technicians to install, commission, and maintain the Work. All installing personnel shall be licensed as required by local and/or state jurisdictions. 10. The Contractor shall ensure compliance with, and have a thorough understanding of, all local codes and contract conditions pertaining to this Project. 11. The Contractor shall maintain an inventory of spare parts and other items critical to System operation and as necessary to meet the emergency service requirements of this Project within the local service center. Product Standards 1. All equipment and materials for contained herein shall be the products of recognized manufacturers and shall be new. 2. New equipment and materials shall: a. Be Underwriters Laboratories, Inc. (U.L.) listed and approved where specifically called for; or where normally subject to such U.L. labeling and/or listing services. b. Be without blemish or defect. c. Be products that meet with the acceptance of the agency inspecting the Audio Visual Systems work. 3. It is the intent of these specifications that wherever a manufacturer of a product is specified, and the terms “other approved” or “approved equal” are used, the substituted item must conform in all respects to the specified item. Consideration will not be given to claims that the substituted item meets the performance requirements with lesser construction. Performance as delineated in schedules and in the specifications shall be interpreted as minimum performance. 4. Substituted equipment or optional equipment, where permitted and approved, must conform to space requirements. Any substituted equipment that cannot meet space requirements, whether approved or not, shall be replaced at the Contractor’s expense. Any modifications of related Systems as a result of substitutions shall be made at the Contractor’s expense. 5. The approval of shop drawings, or other information submitted in accordance with the requirements hereinbefore specified, does not ensure that the Audiovisual Consultant, Architect, or the Owner attests to the dimensional accuracy, dimensional suitability of the material, or mechanical performance of equipment. Approval of shop drawings does not invalidate the Drawings and Specifications. SM&W Project No. 09031 – General Conditions for Audiovisual Systems MSU, M Project No. 79613 Section 27 41 00 – Page 16 of 27 MINNESOTA STATE COLLEGES AND UNIVERSITIES 1.12 6. Substitutions of equipment shown on the schedules or designated by model number in the specifications will not be considered if the item is not a regular catalogued item carried by the manufacturer. 7. Within the Specifications, certain manufacturers have been listed. These manufacturers are listed for example purposes (unless followed by “No Exceptions”). The Contractor may substitute manufacturers and models that may be more cost effective or readily available than that specified. However, all substitutions shall meet or exceed the specified functional and technical requirements. Acceptance of such substitutions is at the discretion of the Consultant and/or Owner. WARRANTY AND MAINTENANCE A. Systems Contractor shall provide a one (1) year warranty for the Work. The warranty shall cover all Work, Systems, and subsystems against defects in materials and workmanship. The Work as specified herein, including all materials and labor, but excepting any existing devices and equipment which are incorporated in the completed Work, shall be warranted to be free from defects in design, workmanship, and materials. Further, the Contractor shall warrant that the completed Systems, including all components (except those, which are existing or provided by others), are of sufficient size and capacity to fulfill the requirements of the Specifications. B. The warranty shall be valid for a period of one (1) year following the date of System acceptance by the Owner. System acceptance shall commence when all parts, components, sub-Systems, and Systems have been tested, shown to be working in accordance with the Specification, and approved by the Owner C. In cases where the manufacturer’s warranty period is greater than twelve months, the contractor must be prepared to honor that warranty for the full extent of the manufacturer’s warranty period. This shall exclude any labor costs incurred by the contractor removing and re-installing the defective items. D. In cases where the manufacturer’s warranty period is less than 12 months, the contractor is liable for defects in the item up to-but not exceeding-the first twelvemonth period on any contractor provided items. E. To maintain certain manufacturer’s warranties, said equipment must be installed, aligned and serviced by those installers authorized by said manufacturer to perform those duties. If the contractor is not authorized, by said manufacturer, it is his sole responsibility to make the appropriate arrangements and bear all cost and consequences thereof. F. All manufacturers’ equipment warranties shall be activated in the Owner’s name and shall commence on the date of system acceptance. In the case of Contractor-modified equipment, the manufacturer’s warranty is normally voided. In such cases, the Contractor shall provide the Owner with a warranty equivalent to that of the original manufacturer. G. Warranty Service: 1. In the event that defects in the materials and/or workmanship are identified during the warranty period, the Contractor shall provide all labor and materials as may be required for prompt correction of the defect. SM&W Project No. 09031 – General Conditions for Audiovisual Systems MSU, M Project No. 79613 Section 27 41 00 – Page 17 of 27 MINNESOTA STATE COLLEGES AND UNIVERSITIES 2. Provide written notice to the Owner documenting any Work performed during the warranty period, including any preventative maintenance Work performed. 3. Provide loaner equipment that is fully compatible with the Audio Visual Systems for any equipment not field repairable. 4. Loaner equipment for components that must be shipped to/from the manufacturer or distributor shall be on site and operational within 48 hours of the component failure. Furnish lists of equipment that will require shipment from the manufacturer or distributor and lead times associated with that equipment. PART 2 - PRODUCTS 2.1 MATERIALS A. 2.2 Refer to Sections under 27 41 00 for Equipment Specifications by individual Room and System type. ALL ELECTRONIC PRODUCTS A. Shall operate on 120 to 240 VAC at 50/60 Hz. B. Shall be capable of operating continuously for 12 hours over the external ambient temperature range of +10°C to +65°C (20% to 95% humidity, non-condensing) without permanent damage. PART 3 - EXECUTION 3.1 EXAMINATION A. 3.2 Verification of Conditions: Examine the areas to receive the work and the conditions under which the Work would be performed. Contractor shall remedy conditions detrimental to the proper and timely completion of the Work. Do not proceed until unsatisfactory conditions have been corrected. INSTALLATION A. General 1. All installation practices shall be in accordance with, but not limited to, these specifications and drawings. Installation shall be performed in accordance with the applicable standards, requirements, and recommendations of National and Local authorities having jurisdiction. 2. If, in the opinion of the Contractor, an installation practice is desired or required, which is contrary to these specifications or drawings, a written request for modification shall be made to the Consultant. Modifications shall not commence without written approval from the Consultant. Every effort will be made to respond to all written requests, in a timely manner, as to not delay the installation or completion of the project. 3. Prior to ordering equipment, the contractor shall coordinate the frequencies of all wireless devices to prevent unwanted interaction between devices and rooms. This includes, but is not limited to, wireless SM&W Project No. 09031 – General Conditions for Audiovisual Systems MSU, M Project No. 79613 Section 27 41 00 – Page 18 of 27 MINNESOTA STATE COLLEGES AND UNIVERSITIES microphones, assisted listening system devices, wireless control panels, etc. B. C. D. 4. All accessories, including rack mounting hardware, power supplies, etc., shall be obtained from the original equipment manufacturer. Unless otherwise noted or specified, third party accessories shall not be used. 5. All installation practices shall be in accordance with, but not limited to, these specifications and drawings. Installation shall be performed in accordance with the applicable standards, requirements, and recommendations of National and Local authorities having jurisdiction. 6. If, in the opinion of the Contractor, an installation practice is desired or required, which is contrary to these specifications or drawings, a written request for modification shall be made to the Consultant. Modifications shall not commence without written approval from the Consultant. Every effort will be made to respond to all written requests, in a timely manner, as to not delay the installation or completion of the project. 7. During the installation, and up to the date of final acceptance, the Contractor shall be under obligation to protect his finished and unfinished work against damage and loss. In the event of such damage or loss, the damage shall be replaced or repaired at no cost to the Owner. Physical Installation 1. All equipment shall be firmly secured in place unless requirements of portability dictate otherwise. 2. All equipment shall have an engraved plaque permanently affixed, denoting its function. 3. Fastenings and supports shall be adequate to support their loads with a safety factor of at least five. All boxes, equipment, etc., shall be secured plumb and square. 4. In the installation of equipment and cable, consideration shall be given not only to operational efficiency, but also to overall aesthetic factors. Trim and Escutcheon Components 1. To insure a proper finished appearance, the AV Contractor shall furnish and install trim/escutcheon components at all conditions where A/V components pass through the finished ceilings. This would include but not be limited to video projector supports, flat-panel display supports and any other component which is not specifically supplied with integral flanges/trim components; i.e. speaker mounts, assistance listening devices, etc. 2. All trim components at the ceiling plane shall be finished to match the approved ACT ceiling grid system components. The audiovisual contractor should obtain a sample from the General Contractor, including any custom color information, or standard color numbers. All trim components shall be submitted to the Architect for review and approval prior to fabrication. Cable Installation 1. All wire bundles are to be neat and combed free of cable crossovers. SM&W Project No. 09031 – General Conditions for Audiovisual Systems MSU, M Project No. 79613 Section 27 41 00 – Page 19 of 27 MINNESOTA STATE COLLEGES AND UNIVERSITIES E. 2. All cables, regardless of length, shall be marked with a permanent, selflaminating wrap-around number or letter cable marker at both ends, similar to the Panduit “Pan-Code” system. Labels must be computergenerated for legibility. Wire labels done by hand in the field must be replaced with computer generated labels. There shall be no unmarked cables at any place in the system. Marking codes used on cables shall correspond to codes shown on drawings and or run sheets. 3. All cables shall be grouped according to the signals being carried. In order to reduce signal contamination, separate groups shall be formed for the following cable families: a. Power cables b. Control cables c. Video cables d. Audio cables carrying signals less than – 20 dBm e. Audio cables carrying signals between – 20 dBm and +20 dBm f. Audio cables carrying signals above +20 dBm 4. As a general practice, all power cables, control cables, and high level cables shall be run on the left side of an equipment rack as viewed from the rear. All other cables shall be run on the right side of an equipment rack, as viewed from the rear. 5. Cables ties shall be placed at appropriate intervals of no greater than six inches for vertical bundles, two inches for horizontal bundles. 6. All vertical cable bundles shall be attached to the rack frame. Wire Terminations 1. All cables shall be continuous lengths without splices. 2. All system wire, after being cut and stripped, shall have the wire strands twisted back to their original lay and be terminated by approved soldered or mechanical means. 3. Except where noted otherwise in the specifications, NO BARE WIRE TERMINATIONS WILL BE ACCEPTED. Heat-shrink tubing shall be used to insulate the ground or drain wire. 4. Unused wires at the end of a cable shall remain unstripped and shall be laid back and held in place with wire ties. 5. All solder connections shall be made with rosin-core solder using temperature-controlled solder stations. Care shall be taken to avoid cold or cracked solder joints. Any connections that do not appear to be clean and shiny, or which show signs of cracking, shall be re-soldered by the contractor before final acceptance of the system. 6. Mechanical connections using insulated, crimp-type connectors shall be bonded to the connector by soldering the wire to the metal part of the connector. 7. Connections made with screw actuated pressure type terminal strips shall be made by stripping approximately 1/4 inch of insulation from the stranded conductor. Then the un-tinned wire shall be inserted into the terminal and the screw tightened using a secure fitting precision screwdriver. SM&W Project No. 09031 – General Conditions for Audiovisual Systems MSU, M Project No. 79613 Section 27 41 00 – Page 20 of 27 MINNESOTA STATE COLLEGES AND UNIVERSITIES F. 3.3 8. Terminal blocks, boards, strips or connectors shall be furnished for all cables which interface with racks, cabinets, consoles, or equipment modules. No audio cables shall run directly to the audio patch panel jacks. Each audio patch panel shall be furnished with an audio terminal block, and all audio cables to and from the audio patch panel shall terminate on this block. 9. Unless otherwise noted, all video and computer video cables are to be terminated using seventy-five ohm (75 Ohm) connectors, with a captive center pin. Cable Management 1. All wire markers shall face a common direction. 2. All cables shall have proper connector housing. 3. Cables shall not protrude from the back of racks. 4. All cable entry shall be through the tops of racks or through entrance holes in the base of the rack. No cable shall enter racks through front, rear or side panel openings. 5. Cables running in plenum areas without conduit shall be plenum rated cable, and match the specified cable above. It is the responsibility of the Bidder to inspect the electrical drawings, and verify in what spaces plenum cable shall be used. No claims for additional monies, based on the use of plenum cable, will be allowed. 6. All cables (except video and pulse cables, which must be cut to an electrical length) shall be cut to the length dictated by the run. No splices shall be permitted in any pull boxes without prior permission of the Consultant. For equipment mounted in drawers or on slides, the interconnecting cables shall be provided with a service loop of appropriate length. 7. No cable shall be installed with a bend radius less than that recommended by the cable manufacturer. 8. Where cables are installed in architectural niches, ensure that the cables are black, unless otherwise directed, to reduce visibility from the audience. 9. Where cables are installed that is visible, the cables will be sheathed in a color wrap that has been pre-approved for the location. PERFORMANCE STANDARDS A. Unless restricted by the published specifications of a particular piece of equipment, or unless otherwise required under the Detailed Specifications, the following performance standards shall be met be each system: 1. Audio a. Frequency Response 1) b. Within plus or minus 0.5dB, 20 Hz to 20,000 Hz. Signal to Noise Ratio 1) Greater than 90dB (including crosstalk and hum at all input/output levels) SM&W Project No. 09031 – General Conditions for Audiovisual Systems MSU, M Project No. 79613 Section 27 41 00 – Page 21 of 27 MINNESOTA STATE COLLEGES AND UNIVERSITIES c. Total Harmonic Distortion 1) d. Input Levels 1) 2) e. 0.05% maximum from 20 Hz to 20,000 Hz. Microphone (Nominal): -50dbu a) Overload (Minimum gain) : -5dbu b) Maximum Gain: -26dbu Line (Nominal): +4dbu a) Overload (Minimum gain):+24bu b) Maximum Gain: +9dbu c) Input Common Mode Rejection: >100db Output Levels 1) Line (Nominal): +4dbu a) 2. 2) Output Impedance: <0.5 Ohms 3) Load Impedance: >150 Ohms Video (signal) a. Frequency Response: 1) b. c. 2% maximum. Differential Gain: 1) f. 45 dB minimum unweighted DC to 4.2 MHz Line and Field Tilt: 1) e. 55 dB minimum. (peak to RMS) unweighted, DC to 4.2 MHz Crosstalk: 1) d. Within plus or minus 0.5dB, DC to 4.2 MHz. Signal to Noise Ratio: 1) 3% maximum. Differential Gain: 1) B. Maximum: +24dbu 2 degrees maximum. Performance Test Signal Paths 1. The signal paths for the above Performance Standards shall be as follows: 2. Audio: a. 3. From all source inputs (for microphones, audio tape units, video tape units, etc.) through all mixers, switchers, etc., to all signal destinations. Video: SM&W Project No. 09031 – General Conditions for Audiovisual Systems MSU, M Project No. 79613 Section 27 41 00 – Page 22 of 27 MINNESOTA STATE COLLEGES AND UNIVERSITIES a. 4. Optical a. 5. From all sources of the above signal paths. This shall not exempt the Contractor from the responsibility of checking all paths and outlets for appropriate compliance with the Performance Standards, see section below for detailed requirements. All optical projection systems performance standards: shall meet the following 1) The total averaged light output from a projector, in lumens, shall be within plus-or-minus 15% of that specified by the projector manufacturer. 2) The light fall-off from the center of the projected image to all four corners, as measured at the projected image plane, shall not exceed 35% for slide projector images. The light intensity shall be measured at all five positions of the projected image after the projector has been adjusted to provide the light output as specified above. 3) The “corner” location shall be defined as the four points determined by intersecting lines drawn 5% of the distance in from the focused edges of the image. 4) The light meter used for the above measurements shall be a properly calibrated foot-candle (or lux) meter and shall be cosine-corrected. 5) Projectors, lenses, and mirrors shall be solidly mounted and braced, so that there will be no observable movement in the image induced by motor vibration or other mechanical operations. Control System User Interface a. Control system user interfaces pages shall be designed for this project exclusively. While there are a great number of design approaches to designing the user interface, the following guidelines shall be adhered to: b. All panels are to have the time and date as icons, in the same position on every page. c. All panels are to have a title, indicating the piece of equipment and/or functionality being controlled. d. Each individual room type shall be given the same user interface design and layout, throughout the entire campus, to the greatest extent practicable. e. User interface design, shall, to the greatest extent possible – taking into account the variations in system functionality from room type to room type, maintain continuity throughout the campus. f. Final programming shall include capability to remotely control all functions of the Audio system. Individual device controls shall provide full manufacturer’s functionality. g. Devices similar in nature shall be programmed to operate with a common format. SM&W Project No. 09031 – General Conditions for Audiovisual Systems MSU, M Project No. 79613 Section 27 41 00 – Page 23 of 27 MINNESOTA STATE COLLEGES AND UNIVERSITIES 3.4 h. No individual component shall be programmed to function atypically. i. Whenever the same button appears on more than one page, it will be in the same position on each page. j. Functions used during a general presentation shall be accessible with a minimal amount of button presses/page flips. k. Where feasible, multi-level access to controls should be implemented. l. During performance testing, all equipment shall be operated under standard conditions as recommended by the manufacturer. CONTRACTOR SYSTEM CHECKOUT A. B. C. Before Acceptance Tests are scheduled, the Contractor shall perform his own system check-out. He shall furnish all required test equipment and shall perform all work necessary to determine and/or modify performance of the system to meet the requirements of this specification. This work shall include the following: 1. Provide documentation that all Cobranet bundles and audio signal lines have been tested and verified. 2. Test all audio systems for compliance with the Performance Standards, using the following test procedure: 3. Test Equipment: Assemble the following test equipment (or equivalent) on site. Audio check: 1. Signal generator, Leader LAG-120B 2. AC millivoltmeter, Leader LMZ-181A 3. Audio test set, Audio Precision P1PLUS 4. Prerecorded cassette tape 5. Compact Disc 6. Audio cable 7. Set of terminations, adapters etc. Video checks: 1. Video signal generator, Leader 410C 2. DVI signal generator, Sencore 403C-SH 3. Combined waveform monitor/vectorscope, Leader 5872A 4. Professionally prerecorded DVD test 5. RGB cable, Extron BNC-5-6’HR 6. Video cable 7. Set of terminations, ‘T’ pieces etc. 8. Gain Setting SM&W Project No. 09031 – General Conditions for Audiovisual Systems MSU, M Project No. 79613 Section 27 41 00 – Page 24 of 27 MINNESOTA STATE COLLEGES AND UNIVERSITIES 9. D. E. Adjust all systems (starting at source equipment and terminating at the power amplifiers) for maximum gain and minimum distortion. Signal Paths 1. Video/Audio 2. Connect the output of the video signal generator to a floor box/table/rack connector and select the “Full Field Color Bar” signal. Connect the combined waveform monitor/vectorscope to a final output point, e.g. an input to a picture monitor or video projector. Ensure that the test signal is routed to the selected output. 3. Measure and record the signal amplitudes. 4. Repeat item ‘1’ after selecting the “Multiburst, 50 IRE” test signal. 5. Measure and record the signal amplitudes. 6. Repeat item ‘1’ after selecting the “Modulated 5-step” test signal. 7. Measure and record the signal differential phase and gain. 8. Repeat item #’s ‘1’ through ‘6’ for other video signal paths. 9. Repeat item ‘1’ after selecting the Window test signal. 10. Measure and record the signal line and field tilt. 11. Repeat item ‘1’ after connecting the Black Burst signal from a rear mounted connector. 12. Measure and record the signal/noise ratio. 13. Connect the output of the audio test set to a floor box/table/rack program audio connector and connect the input of the audio test set to a final output point, e.g. an input to a program speaker power amplifier. Ensure that the test signal is routed to the selected output, that the volume control is set to 100% and that the equalizers are bypassed. 14. Measure and record the signal/noise ratio, total harmonic distortion and frequency response. 15. Repeat items ‘12’ and ‘13’ for other audio signal paths. 16. Connect the output of the audio test set to a floor box/table/rack speech audio connector and connect the input of the audio test set to a final output point, e.g. an input to a speech speaker power amplifier. Ensure that the test signal is routed to the selected output, that the volume control is set to 100% and that the equalizer is bypassed. 17. Measure and record the signal/noise ratio, total harmonic distortion and frequency response. 18. Repeat items ‘15’ and ‘16’ for other audio signal paths. DVI: Connect the DVI output of the signal generator to a floorbox/table/rack connector and select the SMPTE & PLUGE signal at the various computer scan rates as follows: a. 640 x 480 31.5 kHz H, 60 Hz V b. 640 x 480 37.5 kHz H, 75 Hz V c. 800 x 600 38 kHz H, 60 Hz V SM&W Project No. 09031 – General Conditions for Audiovisual Systems MSU, M Project No. 79613 Section 27 41 00 – Page 25 of 27 MINNESOTA STATE COLLEGES AND UNIVERSITIES 3.5 d. 832 x 624 49.7 kHz H, 75 Hz V e. 1024 x 768 48 kHz H, 60 Hz V f. 1280 x 768 48 kHz H, 60 Hz V g. 1366 x 768 47.8 kHz H, 60 Hz V h. 1280 x 1024 64 kHz H, 60 Hz V i. 1400 x 1050 63.9 kHz H, 60 Hz V j. HD 720p 45 kHz H, 60 Hz V k. HD 1080i 33.75 kHz H, 30/60 Hz V l. HD 1080p 33.75 kHz H, 30/60 Hz V 2. Check that the image is correctly displayed on the picture monitor(s) and/or by the video projector. 3. Repeat item ‘2’ using Crosshatch signal, checkerboard signal and H Pattern signal. 4. Repeat item ‘2’ for other DVI connection locations. 5. Connect the output of the audio signal generator to a floorbox/table/rack ‘Left’ and ‘Right’ connectors and select the 1 kHz tone. Check that the signal is emitted from the left and right program speakers. 6. Repeat item ‘v’ for other audio connection location. 7. Note: Whenever possible, include computer sources provided by the Owner, at the desired resolution, in your testing. 8. At the conclusion of the tests, return all equipment settings to previously calibrated positions. 9. Provide written records of all test results in spreadsheet form. 10. Check all control functions, from all controlling devices to all controlled devices, for proper operations. 11. Adjust, balance, and align all equipment for optimum quality and to meet the manufacturer’s published specifications. Establish and mark normal settings for all level controls, and record these settings in the “System Operation and Maintenance Manual”. 12. Check all optical projection images for average light level, light fall-off, and image alignment and size to comply with the Performance Standards and specifications drawings. Check to determine that all projectors, projector bases, carts, tables, and mirrors are rigid and vibration-less in operation. 13. Maintain documentation of all performance tests for reference by the Consultant during the System Acceptance Tests. SYSTEM ACCEPTANCE TESTS A. System Acceptance Tests will not be performed until the Contractor’s System Checkout has been completed and the test results have been reviewed. The System Acceptance Tests will be supervised by the Consultant and will consist of the following: SM&W Project No. 09031 – General Conditions for Audiovisual Systems MSU, M Project No. 79613 Section 27 41 00 – Page 26 of 27 MINNESOTA STATE COLLEGES AND UNIVERSITIES B. A physical inventory will be taken of all equipment on site and will be compared to equipment lists in the contract documents. C. The operation of all system equipment shall be demonstrated by the Contractor. D. Both subjective and objective tests will be required by the Consultant to determine compliance with the specifications. The Contractor shall be responsible for providing test equipment for these tests. E. All final, “as-built” drawings, run sheets, manuals, and other required documents, as detailed in Part I, shall be on hand. Two complete sets of these documents shall be delivered to the Owner at this time. (One complete set shall have been delivered to the Consultant prior to the scheduling of Acceptance Tests). F. In the event further adjustment is required, or defective equipment must be repaired or re-placed, tests may be suspended or continued at the option of the Consultant. G. Any charge for additional time incurred by the Consultant required to oversee the system tests, due to improper system installation or previous failed systems, shall be the responsibility of, and charged directly to the contractor. END OF SECTION SM&W Project No. 09031 – General Conditions for Audiovisual Systems MSU, M Project No. 79613 Section 27 41 00 – Page 27 of 27 MINNESOTA STATE COLLEGES AND UNIVERSITIES SECTION 27 41 01 TRAINING FOR INTEGRATED AUDIOVISUAL SYSTEMS PART 1 - GENERAL 1.1 SUMMARY A. Section Includes: 1. 1.2 1.3 Training of End User Personnel TRAINING FORMAT A. Presenter: The presenter of the training sessions to have been directly involved with the project and have intimate knowledge of the installed systems and it’s operation. The presenter to be experience operating similar systems of similar complexity. B. Attendees: The End User to determine who shall attend Audio Video Training. Group to be limited to 10 persons. Training to occur at building site and be coordinate with End Users Schedule and Calendar. C. Classroom presentation: PowerPoint Presentation covering items indicated in syllabus. Duration of classroom training not to exceed 4 hours. D. Field Instruction: Hands On presentation covering items indicated in syllabus. Minimum duration of field instruction: 1. Video System Operation – 4 hours 2. Audio System Operation – 4 hours 3. One month follow up – 4 hours AUDIO SYSTEMS TRAINING SYLLABUS A. B. Section 1 - Introduction to Audio Systems 1. Decibels – Explain the concept of Decibels and it’s application in dBu and dBSPL. Provide references of each. 2. Frequency – Explain the concept of Frequencies and a relationship to octaves and musical notes. 3. Voltage – Provide description of microphone, line and speaker levels. 4. Gain Structure – Provide description and example of proper gain structure along with a explanation of clipping and headroom. Section 2 – Introduction to Project Systems (Provide the following for each system in project) 1. Inputs – Present floor plans indicating location of technical panels with brief description of input connectors 2. Controls – Present floor plans indicating location of wall controls and mix locations. SM&W Project No. 09031 – Training for Integrated Audiovisual Systems MSU, M Project No. 79613 Section 27 41 01 – Page 1 of 3 MINNESOTA STATE COLLEGES AND UNIVERSITIES C. 3. Components – Present Schematic diagram (based on shop drawings) indicating brief description of signal flow and components of the system. 4. Loose Equipment – Present list of loose items for each system and use. Section 3 – Microphone Selection and Application 1. 2. D. a. Type of microphone: Boundary, Condenser, Dynamic, etc. b. Type of coverage: Omni, Cardioid, Semi Cardioid, etc. Provide explanation of proper microphone application to include: a. General Handling and placement for handheld applications b. General Handling and placement for stand applications c. 3 to 1 rule with respect to interference d. 3 dB rule with respect to headroom Section 4 – Field Instruction 1. 1.4 Provide explanation of proper microphone selection to include: Mixing Console Operation a. Explanation of signal path b. Review of Aux sends c. Review of Groups d. Explanation of Mute Groups e. Explanation of Matrix f. Review of Main Section g. Review of Metering h. Tie Line Description VIDEO SYSTEM TRAINING SYLLABUS A. B. C. Section 1 – Introduction to Video Systems 1. Provide description of digital and analog video signal types 2. Discuss the properties of a quality video image Section 2 – Introduction to project systems 1. Inputs – Present floor plans indicating location of technical panels with description of input connectors 2. Controls – Present floor plans indicating location of wall controls and mix locations. 3. Components – Present Schematic diagram (based on shop drawings) indicating description of signal flow and components of the system. Section 3 – Field Instruction 1. Demonstrate the process of inputting media 2. Review the process or routing the signals through distribution SM&W Project No. 09031 – Training for Integrated Audiovisual Systems MSU, M Project No. 79613 Section 27 41 01 – Page 2 of 3 MINNESOTA STATE COLLEGES AND UNIVERSITIES 1.5 3. Review the setup and adjustment of the output devices. 4. Review the maintenance of the video equipment. SUPPORT MATERIALS A. Training Manuals - Provide three ring binder for each attendee with the following: 1. Cover sheet indicating Audio Training 2. Contact information for Audio Contractor and Audio Consultant 3. Table of Contents 4. Printed copy of PowerPoint presentation 5. Copy of Materials List 6. Copy of Loose Equipment Materials List and Product Cut Sheets 7. Owners and Instruction Manuals a. 8. Make Owners and Instruction manuals available and complete for reference during training. Record Documents a. Make Record Document available and complete for reference during training. PART 2 - PRODUCTS PART 3 - EXECUTION 3.1 PREPARATION A. Submit training support material binder to AV Consultant for approval prior to training sessions. END OF SECTION SM&W Project No. 09031 – Training for Integrated Audiovisual Systems MSU, M Project No. 79613 Section 27 41 01 – Page 3 of 3 MINNESOTA STATE COLLEGES AND UNIVERSITIES SECTION 27 41 16 INTEGRATED AUDIO VISUAL SYSTEMS AND EQUIPMENT PART 1 - GENERAL 1.1 SUMMARY A. B. DESCRIPTION 1. Auditorium used for multiple venues with three basic categories of uses; presentation, film and theatrical. 2. The space was scheduled for approximately 5500 hours of use last year, venues can vary from one hour events to week long seminars. 25-30 percent of this time was scheduled as “closed”, a portion of this closed time is used for set-up and tear down. 3. Many University and outside entities utilize the space. Examples ranges from: a. The University Presidents Office b. Film presentations c. All-Greek Meetings d. Science Fair e. Religious Services f. Tax Return Seminars g. Admissions h. Student Orientation 4. CSU Staff and Student Staff are utilized in the setup and operation of the AV systems. The experience level of the student workers are varying and ever changing. 5. The above information established the following goals: a. The space must configure with simple set up control, tools and minor system check out. b. Presets for reoccurring venues to be created c. High quality sound for both spoken word, live music and film presentations to be included. d. High quality video for presentations and film to be included. e. Simple infrastructure with good labeling to allow simple and complex input/output scenarios to be included. f. Control systems to mirror campus standards g. Production Intercom to facilitate production staff communication during setup, rehearsal and events. PRESENTATION VENUES: 1. Voice reinforcement sound system – Voice Range SM&W Project No. 09031 – Integrated Audiovisual Systems MSU, M Project No. 79613 Section 27 41 16 – Page 1 of 30 MINNESOTA STATE COLLEGES AND UNIVERSITIES C. 2. Playback sound system – Full Range 3. Input for media including; Analog computer signals, digital computer signals, DVD media via Computer, DVD media via local player and input 4. The ability to input media from multiple locations, this allows presenters to control their own media or have staff control media from a remote location. 5. Access to Internet is required and will be provided by others 6. Simple control system with touch panel and intuitive GUI controls. 7. A confidence Monitor shall be provided 8. Existing closed caption system to be incorporated into the new system. 9. A lectern/media cart arrangement will facilitate presenters with Laptops and papers. 10. A stand alone lectern may also be utilized for presentations where only a microphone is required. 11. Wired and wireless microphones are to be used. House microphones would also be utilized for recording purposes. 12. Small channel count mic/line stage boxes and snakes to be utilized to extend connectivity to the entire stage area. 13. Press feeds to be included using the Owners existing press box. 14. Video Tele Conferencing capabilities, this is a limited use item and simple input/output capabilities have been included. The Codec would be brought into auditorium for special events by the IT staff. 15. Lighting, screen, front curtain, audio and video items to be controlled via a control system. 16. Recording Capabilities to allow staff to record event audio. Connectivity to be provided for future video recording. FILM VENUES: 1. Left, center right loudspeaker systems with side and rear channels for surround sound to be included. 2. Subwoofer to support the low frequency signals. 3. Surround sound processor to receive the encoded media signals from both the digital and analog sources and output proper signals to the house audio system. 4. Input for media including; Legacy analog VHS media and future digital media. 5. Existing electric projection screen to be reused. Low voltage control to be added. 6. Using a industry recognized standard of calculating screen size. A 10.25’ x 18.22’ (16 x 9 aspect ratio) screen is recommended for this size room based on viewing presentation materials. The existing screen is 20’ x 20’ and would be adequate for viewing in a room of this size. 7. Projector Brightness - "Sufficiently bright" as defined by Society of Motion Picture and Television Engineers (SMPTE) in standard 196M as 12-22 SM&W Project No. 09031 – Integrated Audiovisual Systems MSU, M Project No. 79613 Section 27 41 16 – Page 2 of 30 MINNESOTA STATE COLLEGES AND UNIVERSITIES foot lamberts, though often 16 foot lamberts is taken as the nominal goal. Screen size to brightness calculations indicate the following results. a. D. E. 7000 lumens divided by 225 sf screen material x 1.0 screen gain lumens = 31.11 foot lamberts THEATRICAL VENUES: 1. Center channel sound reinforcement 2. The ability to input to multiple loudspeaker channels for sound effects and personal monitoring. 3. Wireless microphones for multiple cast members. 4. Production intercom for staff communication. BUILDING NEEDS CONSIST OF: 1. Maintenance and servicing of the overhead ceiling projector is a priority. 2. Building Page input with mute and override control to be incorporated, UPS to be utilized to maintain the ability to page into the auditorium during power outages. This ability is not intended to be a life safety operation. 3. Building Fire Alarm input for override of signals during alarm to be incorporated. PART 2 - PRODUCTS 2.1 DISPLAY SYSTEMS A. B. DESCRIPTION: 1. A new video projector located in the control booth will be used to display digital content and high definition analog content in a 16x9 aspect ratio. 2. An existing video projector will be used to display legacy 4x3 aspect ration content. 3. A flat panel display located in the rear of the house will be used as a confidence monitor. 4. An existing electric projection screen will be reused. PROJECTION SCREEN 1. Configuration: a. 2. Existing 20’ x 20’ Non-tensioned motorized projection screen Features: a. Matte White screen material b. Non-tensioned type c. Electric Motorized, 120v operation d. Steel Case SM&W Project No. 09031 – Integrated Audiovisual Systems MSU, M Project No. 79613 Section 27 41 16 – Page 3 of 30 MINNESOTA STATE COLLEGES AND UNIVERSITIES 3. Accessories: a. 4. 1) Provide a new low voltage interface to control the existing screen. Confirm requirements with Factory. 2) Provide the low voltage interface to the electrical contractor for physical installation and 120v operation 3) Control system specified under this section shall provide remote control of the screen, including, raise, lower and stop functions. Equal Manufactures a. C. Low Voltage Interface Dalite VIDEO PROJECTOR 1. Configuration: a. 2. 3. Features: a. Brightness: 6,5000 ANSI lumens b. Resolution: Native HD1080 (1920 x 1080) Minimum c. Display engine: 3-chip DLP (no color wheel), 3-element LCD (or) LCOS (liquid crystal on silicon) d. SD/HD Video Signal Compatibility: 1080p/1080i, 720p, 576p, 576i, 480p, 480i e. Lamp: 2000 lamp life minimum. f. HDCP compatible Digital Media interface, provide HDMI interface g. RS-232 Control h. PC Signal Compatibility VGA, SVGA, XGA, WXGA, WSXGA, SXGA+, WUXGA (1920 x 1200) i. Contrast Ratio: 2000:1 j. Lens Shift: Vertical and horizontal k. Start-up Screen: Programmable, with menu mute/suppress and blue screen off settings, image adjusting/warping software available and included as necessary Accessories: a. 4. 6500 lumen, 3 LCD panel 1920 x 1080 resolution Lens: 1) Focal length sized so lens is zoomed no further than ± 20% from center focal length. 2) Interchangeable 3) Manual Focus 4) horizontal and vertical lens shift Equal Manufacturers: SM&W Project No. 09031 – Integrated Audiovisual Systems MSU, M Project No. 79613 Section 27 41 16 – Page 4 of 30 MINNESOTA STATE COLLEGES AND UNIVERSITIES D. a. Sanyo b. Christie c. Barco d. Sony e. Substitution: By approved substation means. EXISTING VIDEO PROJECTOR 1. Configuration: a. 2. 3. Features: a. Brightness: 6,500 ANSI lumens b. Resolution: Native 1024 x 768 c. RS-232 Control d. Start-up Screen: Programmable, with menu mute/suppress and blue screen off settings, image adjusting/warping software available and included as necessary Accessories: a. E. Existing Sanyo Model No. PLC-XP60 Lens 1) Provide new lens for the existing projector. 2) Focal length sized so lens is zoomed no further than ± 20% from center focal length. 3) Interchangeable 4) Manual Focus 5) Horizontal and vertical lens shift CONFIDENCE MONITOR 1. Configuration: a. 2. 3. 50” High Definition Plasma Display Features: a. Resolution: High Resolution 1920 x 1080 b. PC Signal Compatibility: VGA, SVGA, XGA, WXGA, WSXGA, SXGA+, WUXGA (1920 x 1200) c. RS-232 control d. HDMI interface e. Analog RGBHV, component, s-video and video inputs. Accessories: a. Tilting wall mount bracket 1) 4. Chief Manufacturing: MTRU series. Equal Manufacturers: SM&W Project No. 09031 – Integrated Audiovisual Systems MSU, M Project No. 79613 Section 27 41 16 – Page 5 of 30 MINNESOTA STATE COLLEGES AND UNIVERSITIES 2.2 a. Sony b. Panasonic c. NEC d. View Sonic e. Substitution: By approved substation means. VIDEO SYSTEMS A. B. DESCRIPTION: 1. A systems to accept media and distribute to display and recording devices in support of the events specified in 1.1 Summary. 2. Media Types: a. VHS tape: Magnetic tape type media with 230 to 250 lines resolution using NTSC standards. b. DVD: optical disc read by 650 nm wavelength laser diode players c. Blu-Ray: optical disc read by 405 nm wavelength laser diode players d. Analog PC Signals ranging from VGA, SVGA, XGA, WXGA, WSXGA, SXGA+, and WUXGA (1920 x 1200) e. Digital PC signals ranging from 1080p/1080i, 720p, 576p, 576i, 480p, and 480i f. The above media types shall transport signal utilizing the following connectivity: 1) RCA used for Video, Component Video 2) 4 pin Din used for S-video 3) HD15 4) DVI-I 5) HDMI 6) DisplayPort INPUT DEVICES 1. Combination DVD / VHS Player a. Individual outputs for the DVD and VHS components. 1) 2. Provide rack mounting shelf Blu Ray Disc Player a. HD 1080P/24p Output b. Upscale of DVD media c. Equal Manufacturers: 1) Sony 2) Substitution: By approved substation means SM&W Project No. 09031 – Integrated Audiovisual Systems MSU, M Project No. 79613 Section 27 41 16 – Page 6 of 30 MINNESOTA STATE COLLEGES AND UNIVERSITIES 3. Codec a. C. 1) Provide Rack Shelf for temporary housing of unit while in use. 2) Confirm connectivity of portable unit. 3) Provide adaptor cables to facilitate connectivity from unit to rack panel. DIGITAL MEDIA SYSTEM 1. Configuration: a. 2. 3. 4. a. All routing and management features to be controlled by the Control System specified within this section. b. The Digital Media system to support HDMI 1.3a with Deep Color and 7.1 HD audio bandwidth. c. The system to distribute uncompressed audio and video over UTP and STP cable protocols. d. The system to manage and distribute EDID information (Extended Display Identification Data). e. The system to pass CEC (Consumer Electronic Control) signals. f. The system to manage HDCP digital rights for devices specified with-in this section. Components 16 x 16 Matrix Switcher utilizing 1) Modular Input module configuration. 2) Modular Output Module configuration b. Field Transmitters to accept field digital media devices and convert to UTP/STP transport signals. c. Field Receivers to accept transport signals and output digital media to display devices. Accessories a. 5. Distribution of digital media from field locations to display devices. Features: a. D. Existing portable provided by Owner. Provide necessary power supplies, cables, connectors repeaters, mounting hardware as needed for a complete system. Manufacturers a. Crestron b. Substitution: By approved substitution means ANALOG MEDIA SYSTEM 1. Configuration SM&W Project No. 09031 – Integrated Audiovisual Systems MSU, M Project No. 79613 Section 27 41 16 – Page 7 of 30 MINNESOTA STATE COLLEGES AND UNIVERSITIES a. 2. 3. Features: a. High Bandwidth capabilities – 450 MHz (-3dB) b. Audio and Video signals c. Controlled by the control system specified within this section Components a. b. c. 4. E. 8x8 Matrix Switcher 1) 8x8 of 5-wire and all lesser type analog (RGBHV, Component, S-Video, Composite) video and stereo audio 2) Resolutions up to 1920x1200, including HDTV 1080p/60 3) Source signal presence indication 4) Rack-mountable metal enclosure 5) Stereo audio capable 6) RS-232 Control 7) Internal international power supply included System Switcher 1) 7 x 2 seamless switcher with scaler 2) Rack Mountable metal enclosure 3) RS-232 control 4) Internal International power supply Scaler 1) 2 x 1 scaling of composite or component video to selectable RGB output rates to 1366 x 68 2) Source signal presence indication 3) Rack-mountable metal enclosure 4) RS-232 Control 5) Internal international power supply Accessories a. 5. Distribution of analog media from field locations to display devices. Provide necessary power supplies, cables, connectors repeaters, mounting hardware as needed for a complete system. Manufactures a. Crestron b. Extron c. Substitution: By approved substation means CORDS AND ADAPTORS SM&W Project No. 09031 – Integrated Audiovisual Systems MSU, M Project No. 79613 Section 27 41 16 – Page 8 of 30 MINNESOTA STATE COLLEGES AND UNIVERSITIES F. 1. Provide cords and adaptors as required to accept input and output signals from the specified media types to the system specified there within. 2. Provide three sets of each type cord and adaptor. VIDEO SYSTEM CABLES 1. Digital Media Cable a. Configuration: 1) b. 2. Features: 1) OD = .58 Inch (14.72 mm) 2) Plenum Rated 75 Ohm Coaxial Cable a. Configuration: 1) b. 3. 4. 2.3 Type CMP Composite cable consisting of (1) shielded 4 pair 24 AWG twisted, (1) Unshielded twisted 4 pair 24 AWG, (1) shielded pair 22 AWG, and (1) unshielded pair 18 AWG in overall jacket. Type CM RG6/U coaxial cable 18 AWG (1.02 mm) solid bare copper center conductor Features: 1) 4.23 dB attenuation at 400 MHz per 100 ft 2) OD = .260” 3) Plenum Rated 75 Ohm 5 wire High Resolution a. Configuration: Type CMR multiple coaxial cable 18 AWG solid base copper center conductor b. Features 1) 3.40 dB Attenuation at 360 MHz per 100 ft 2) OD = .180” 3) Plenum Rated Equal Manufacturers a. Belden b. Gepco c. Commscope d. Extron e. Crestron f. Substitution: By approved substitution means. BROADCAST SYSTEMS A. DESCRIPTION: SM&W Project No. 09031 – Integrated Audiovisual Systems MSU, M Project No. 79613 Section 27 41 16 – Page 9 of 30 MINNESOTA STATE COLLEGES AND UNIVERSITIES 1. 2.4 Electrical raceway rough-in to be provided (by the electrical contractor) for future video conferencing cameras. One located at rear of house an one located near the stage. AUDIO SYSTEMS A. DESCRIPTION 1. A system for input, distribution and output of audio signals to facilitate events specified in 1.1 Summary a. B. Signal Types: 1) Microphone level audio 2) Professional line level audio 3) Consumer line level audio 4) Speaker level audio INPUT DEVICES 1. 2. 3. Stage Box a. Configuration: 18 input 4 return stage box with 100’ snake cable b. Features: 1) XLR input connectors and TRS return connectors 2) Snake shall be able to be disconnected through use of multi connector. 3) Provide fan tail termination at wall plate end consisting of XLR and TRS connectors. 4) Provide labeling to identify each connector at each end 5) Provide color coding in pairs of six. 6) Provide cable reel Musical Instrument Direct Boxes a. Configuration: (2) ¼” jack input x (2) XLR 150 ohm output. b. Features 1) Ground Lift Switch 2) 20 dB Pad 3) Loop Through outputs Musical Instrument Direct Boxes a. Configuration: (2) RCA and a 3.5mm jack input x (2) XLR 150 ohm output. b. Features 1) Ground Lift Switch 2) 20 dB Pad 3) Stereo Mono Switch SM&W Project No. 09031 – Integrated Audiovisual Systems MSU, M Project No. 79613 Section 27 41 16 – Page 10 of 30 MINNESOTA STATE COLLEGES AND UNIVERSITIES 4) 4. C. Equal Manufacturers a. Whirlwind b. ProCo c. Substitutions: By approved substation means OUTPUT DEVICES 1. 2. CD Recorder / Cassette Deck a. Configuration: Professional Combination Unit b. Features 1) Digital Coaxial RCA inputs and outputs. 2) Compatible with CD-R, CD-R-DA, CD-RW, and CD-RWDA 3) 44.1 kHz Sample Rate 4) 16 Bit Linear Bit Rate HD Recorder a. Configuration: Professional Minidisc Deck b. Features: c. 1) 320 Minutes Record Time 2) 44.1 kHz Sample Frequency 3) Balanced inputs and outputs Accessories 1) 3. D. Loop Through outputs Rack Mount Kit Equal Manufacturers a. Tascam b. Denon c. Substitutions: By approved substation means WIRED MICROPHONES 1. 2. Handheld Microphones a. Configuration: Cardioid dynamic vocal microphone b. Features: 1) 50 to 15,00 Hz Frequency response 2) On-Off Switch 3) 25’ Cable 4) Mic stand clip Hanging Microphones a. Configuration: Miniature Cardioid condenser microphone SM&W Project No. 09031 – Integrated Audiovisual Systems MSU, M Project No. 79613 Section 27 41 16 – Page 11 of 30 MINNESOTA STATE COLLEGES AND UNIVERSITIES b. 3. 4. E. Feature: 1) 50 -17,000 Hz Frequency Response 2) Black Finish Rack Page Mic a. Configuration: Handheld compact voice range push to talk type b. Features: 1) 300 – 4000 Hz Frequency Response 2) Carbon type 3) DPST pushbutton Equal Manufacturers a. Shure b. AKG c. Audio Technica d. Substitutions: By approved substation means WIRELESS MICROPHONE SYSTEMS 1. Wireless Handheld Microphone Transmitter a. Configuration: 1) b. 2. Cardioid pattern, condenser/capacitor element in interchangeable capsule Features: 1) UHF wideband, frequency agile operation 2) On/off switch on transmitter unit. Other controls shall be hidden and locked out from user operation 3) Operation on single-use alkaline and/or rechargeable batteries 4) Switchable or automatically variable output power 5) 6 hours minimum operation on set of batteries (or) single charge at full output 6) Include recharging station (or) charger Wireless Body-pack Microphone Transmitter & Microphone a. Configuration: 1) b. Cardioid pattern, condenser/capacitor element in miniature clip-on holder (or) in head-worn in integral molded wire-frame with padding. Features: 1) UHF wideband, frequency agile operation 2) On/off switch on transmitter unit. Other controls shall be hidden and locked out from user operation SM&W Project No. 09031 – Integrated Audiovisual Systems MSU, M Project No. 79613 Section 27 41 16 – Page 12 of 30 MINNESOTA STATE COLLEGES AND UNIVERSITIES 3. 3) Operation on single-use alkaline and/or rechargeable batteries 4) Switchable or automatically variable output power 5) 6 hours minimum operation on set of batteries (or) single charge at full output 6) Include recharging station (or) charger Wireless Microphone Receivers a. Configuration: 1) b. 4. F. Rack-mount receiver units shall be gang-able with rack mounting hardware Features: 1) UHF wideband, frequency agile, true-diversity operation 2) Auto-scan, Auto-set feature to identify un-used frequencies and allocate coordinated frequencies when multiple units in use. 3) Status link to transmitter units and display of status and monitoring remotely 4) Employs noise reduction companding 5) Include remote mounted ½ -wave antennae and mounting accessories 6) Include rack-mount active antennae distribution splitter and hardware for installations of multiple receivers. Equal Manufacturers: a. ElectroVoice b. Beyer c. Shure d. Sennheiser e. Audio Technica f. Substitution: By approved substitution means. AUDIO DIGITAL SIGNAL PROCESSORS 1. 2. Configuration: a. Input/output – As shown on plan b. Programmable and configurable to allow for changes in system functions, features and control. c. Provide 10% input/output spare capacity Features: a. CobraNet or other multi-channel digital audio buss option via UTP cable. b. System management and control via Ethernet LAN SM&W Project No. 09031 – Integrated Audiovisual Systems MSU, M Project No. 79613 Section 27 41 16 – Page 13 of 30 MINNESOTA STATE COLLEGES AND UNIVERSITIES 3. 4. G. c. Routing and mixing of audio signals d. Dynamic and spectral processing of audio signals e. Programmable logic based controls for both contact closure type controls and variable level type controls f. Ability to be controlled by third party processor based control systems. g. Automatic echo canceling for conferencing and distance learning. h. Automatic feedback eliminator. i. Selectable phantom power per channel j. Telephone interface module (audio conference hybrid) Accessories a. Mounting hardware for standard 19” equipment racks b. Power cords and/or power supplies c. External control components as needed to accomplish specified features. Manufacturers a. Clear One b. BSS c. Biamp d. QSC e. Symetrix f. Substitution: By approved substitution means. SURROUND SOUND PROCESSOR 1. Description: Preamplifier for decoding surround sound content and output of 7.1 surround sound audio. 2. Features: 3. a. HDMI inputs and output b. Balanced audio outputs. Accessories: a. 4. H. Rack mount shelf Equal Manufacturers a. B&K b. Substitution: By approved substitution means. MIXING DEVICES 1. Performance Mixer a. Configuration: Control surface with remote input/output DSP engine SM&W Project No. 09031 – Integrated Audiovisual Systems MSU, M Project No. 79613 Section 27 41 16 – Page 14 of 30 MINNESOTA STATE COLLEGES AND UNIVERSITIES b. c. d. I. 1) 20 Fader surface with 8 Inputs, 8 Outputs, 4 ¼” TRS balanced inputs (4) ¼” TRS balanced outputs.(4) RCA line level inputs (2) RCA outputs, (1) Digital Coax SP/DIF input. 2) 32 input 16 output remote DSP engine/Stage Rack including Ace for connection to control surface in 6U rack housing. Manufacturers 1) Allen and Heath 2) Yamaha Substitution: By approved substitution means. DISTRIBUTION 1. 2. 3. 4. J. Features: Patch Panel a. Configuration: Rack mounted distribution panel that shall allow the re-direction if audio signal through the use of patch cords. b. Features: 1) Long Frame type connectors 2) 26 paths 3) Half-normalled configuration to allow monitoring 4) 2U rack space Active Combiner a. Configuration: Two audio input combiner b. Features: 1) Selectable Mic or Line level input 2) Balanced output 3) Level control 70V Speaker Level Interface a. Configuration: Interface for 70V speaker line to line level unbalanced input. b. Features: 1) Trim adjustment 2) 20 – 20 kHz Frequency Response. Equal Manufacturers a. ADC Communications b. Radio Design Labs c. Substitution: By approved substitution means POWER AMPLIFIERS SM&W Project No. 09031 – Integrated Audiovisual Systems MSU, M Project No. 79613 Section 27 41 16 – Page 15 of 30 MINNESOTA STATE COLLEGES AND UNIVERSITIES 1. Configuration: Power amplifiers have been selected based on load per channel. The Contractor may utilize different power amplifier configurations that meet the per channel requirements. 2. Features: 3. 4. 5. K. a. Switch mode power supplies b. -106 signal to noise ratio c. 20Hz to 20kHz frequency response d. Damping Factor less than 500 e. 12k ohm impedance balanced inputs f. Active inrush limiting g. Integrated controls including; clip limiters, high pass filters, bridge and parallel modes. h. Low noise cooling fans i. Rack mounting hardware Low Impedance Amplifier Types: a. Type 200/8 – 2 Ch, 200 watt per channel capacity at 8 ohms b. Type 300/8 – 2 Ch, 300 watt per channel capacity at 8 ohms c. Type 400/8 – 2 Ch, 400 watt per channel capacity at 8 ohms d. Type 500/8 – 2 Ch, 500 watt per channel capacity at 8 ohms e. Type 700/8 – 2 Ch, 700 watt per channel capacity at 8 ohms 70 Volt Amplifier Types: a. Type 200/70 – 2 Ch, 200 watt per channel capacity at 70V b. Type 400/70 – 2 Ch, 400 watt per channel capacity at 70V c. Type 1000/70 – 2 Ch, 1000 watt per channel capacity at 70V Equal Manufacturers a. QSC b. Ashly c. Lab Gruppen C series d. Dynacord PARAMUS series e. Crown CTs series f. Substitution: By approved substitution means. LINEAR ARRAY LOUDSPEAKERS 1. Type LS-1 a. Configuration: 1) b. 2-way full range loudspeaker manufactured with drivers aligned in a vertical arrangement providing narrow vertical coverage and wide horizontal coverage. Features: SM&W Project No. 09031 – Integrated Audiovisual Systems MSU, M Project No. 79613 Section 27 41 16 – Page 16 of 30 MINNESOTA STATE COLLEGES AND UNIVERSITIES c. 2. L. 1) 3.5” (89mm)LF drivers 2) HF ribbon drivers 3) 40 degree vertical x 120 degree horizontal coverage 4) 120 Hz to 20 kHz frequency response ±3 dB 5) Internal threaded mounting points 6) Finish: Textured Black 7) Fabric grill Accessories: 1) Steel Yoke 2) Rigging Hardware Equal Manufacturers a. Innovox Audio b. SLS c. Renkus Heinz d. Substitution: By approved substitution means. WALL SPEAKERS 1. Type WS-1 a. Configuration: Full range compact frequency shaded line array b. Features: c. 1) (6) 4” (100mm) Low frequency drivers 2) (1) High frequency ribbon driver 3) 25 degree vertical x 120 degree horizontal coverage 4) 120 – 20 kHz frequency response 5) Finish: Black Accessories: 1) 2. Provide flush mount millwork adaptor with perforated metal grill. Type WS-2 a. Configuration: Full range compact frequency shaded line array b. Features: c. 1) (6) 4” (100mm) Low frequency drivers 2) (1) High frequency ribbon driver 3) 25 degree vertical x 120 degree horizontal coverage 4) 120 – 20 kHz frequency response 5) Finish: Black Accessories: SM&W Project No. 09031 – Integrated Audiovisual Systems MSU, M Project No. 79613 Section 27 41 16 – Page 17 of 30 MINNESOTA STATE COLLEGES AND UNIVERSITIES 1) 3. Type WS-3 a. Configuration: 2-way ultra slim loudspeaker b. Features: c. 1) (4) 4” (100mm) Low frequency drivers 2) (1) High frequency ribbon driver 3) 90 degree vertical x 120 degree horizontal coverage 4) 120 – 20 kHz frequency response 5) Finish: Black Accessories 1) 4. a. Configuration: Full range 2-way powered near field monitor b. Features: 1) 6.5” (165 mm) Low frequency driver 2) 1” (25mm) Dome tweeter 3) 50 – 20 kHz. Frequency response 4) 20 k ohm impedance balanced input 5) Finish: Black Accessories 1) M. Wall Bracket Type WS-4 c. 5. Provide flush mount millwork adaptor with perforated metal grill. Provide adjustable wall mounting bracket Equal Manufacturers a. Innovox Audio b. SLS c. Renkus Heinz d. Alesis e. Substitution: By approved substitution means. SUBWOOFERS 1. Type SW-1 a. Configuration: Dual 15” Subwoofer with tuned enclosure b. Features: c. 1) Dual 15” (81mm) Low frequency drivers 2) Internal threaded mounting points Accessories: 1) Rigging Hardware SM&W Project No. 09031 – Integrated Audiovisual Systems MSU, M Project No. 79613 Section 27 41 16 – Page 18 of 30 MINNESOTA STATE COLLEGES AND UNIVERSITIES 2. N. 2. Innovox Audio b. Renkus Heinz c. Substitution: By approved substitution means. Type SM-1 a. Configuration: Powered Full range floor wedge b. Features: 1) 15” (300 mm) Low frequency driver 2) 1” (25.4mm) horn loaded compression driver 3) 58 – 18 kHz. Frequency response 4) Injection-molded high-impact polypropylene enclosure 5) 20 k ohm impedance balanced input 6) Finish: Black Equal Manufacturers a. ElectroVoice b. EAW c. Renkus Heinz d. Substitution: By approved substitution means. RECESSED CEILING SPEAKERS 1. 2. P. a. STAGE MONITORS 1. O. Equal Manufacturers Type CS-1 a. Configuration: Voice Range 70v recessed ceiling assembly b. Features: 1) 8” (203mm) 10 oz loudspeaker 2) Round white baffle 3) Multi-tap transformer 4) Backcan 5) Tile bridge support Equal Manufacturers a. Quam b. Atlas Sound c. Misco d. Substitution: By approved substitution means. CORDS AND ADAPTORS AND ACCESSORIES 1. Cords SM&W Project No. 09031 – Integrated Audiovisual Systems MSU, M Project No. 79613 Section 27 41 16 – Page 19 of 30 MINNESOTA STATE COLLEGES AND UNIVERSITIES 2. a. 10’ (3M) Microphone cords b. 25’ (7.5M) Microphone cords c. 50’ (15M) Microphone cords d. 25’ (7.5M) Stage Monitor Cords e. Miscellaneous – Provide cords as needed for input and output of equipment as indicated on the signal flow diagram with length as dictated by field conditions. Adaptors a. 3. 4. Q. R. Miscellaneous – Provide adaptors as needed for input and output of equipment as indicated on the signal flow diagram with length as dictated by field conditions. Microphone Stands a. Configuration: All metal adjustable microphone stand with boom b. Features: 1) 1010 to 1720 mm adjustable height stand 2) 805 mm boom length Equal Manufacturers a. K&M b. Whrildwind c. Proco d. Substitution: By approved substitution means. SNAKE CABLES a. Configuration: Custom built Input/output configuration as indicated on signal flow diagrams b. Features: 1) Overall Length – As determined by field conditions 2) Fan out length – Minimum of 1.5 Meters 3) Provide labeling to identify each connector at each end 4) Provide color coding in pairs of eight. ASSISTED LISTENING SYSTEM 1. 2. Configuration: a. Permanently installed transmitter/receiver system used to distribute an audio signal to those that are hearing impaired. b. The system to conform to ADA recommendations. Features: a. Rack mount FM VHF radio transmitter b. Personal FM VHF Receiver SM&W Project No. 09031 – Integrated Audiovisual Systems MSU, M Project No. 79613 Section 27 41 16 – Page 20 of 30 MINNESOTA STATE COLLEGES AND UNIVERSITIES 3. S. Dual headphone d. Ear Bud headphone option e. Rechargeable batteries f. Inductive neck loop g. Dipole Universal remote antenna h. Storage Case with recharging apparatus built-in, as required by local/national codes i. Appropriate signage, in local language(s) Equal Manufacturers a. Listen Technologies b. Williams Sound c. Substitution: By approved substitution means. PRODUCTION INTERCOM 1. T. c. Configuration: a. Field wiring and connectivity that will be used with the Owners existing masters station, confirm requirements. b. Master station, body packs and headsets are provided by Owner. WIRE AND CABLE 1. 2. 3. 4. 5. Microphone and Line Cable: a. Configuration: Type CMR – 22 AWG (.644mm) (7x30) stranded twisted shielded pair with overall shield b. Plenum Configuration: Type CMP – 22/2 AWG (.644mm) (7x30)stranded twisted shielded Pair with overall shield c. Properties: 17 ohms /M’ with OD = 3.4 mm Wireless Microphone Antenna Cables with-in equipment racks a. Configuration: Type CM 50 ohm RG-58/U 22 AWG (.644mm) solid center conductor. b. Properties: OD = 5 mm Wireless Microphone and Hearing Assistance Antenna Cables outside of equipment racks a. Configuration: Type CM 50 ohm RG-8/U 11 AWG (2.3 mm), (7x19) center conductor b. Properties: OD = 10.2 mm Low Impedance Loudspeaker Cable: a. Configuration: Type CL3 – 12 AWG (2mm) (19x25) stranded twisted pair b. Properties: 1.7 ohms / M’ with OD = 6.8 mm High Impedance Loudspeaker Cable (25V / 100V) SM&W Project No. 09031 – Integrated Audiovisual Systems MSU, M Project No. 79613 Section 27 41 16 – Page 21 of 30 MINNESOTA STATE COLLEGES AND UNIVERSITIES 6. a. Configuration: Type CMR – 18 AWG (1 mm), (7x26) stranded pair b. Properties: 6.2 ohms / M’ with OD = 4 mm DSP Control Cable a. 7. 2.5 Control and communication cable as required for DSP configuration to be verified and included. UTP Cable a. Configuration: Type CMR Category 6, 4 pair, 24 AWG (.5mm) b. Properties: 30.5 dB attenuation at 250 MHz per 100 m with OD = 5.8 mm CONTROL SYSTEMS A. B. DISCRIPTION 1. A custom configured system comprised of a controller that shall communicate with local and remote AV system components to provide recall and manipulation of control features. These control features may be operated through user selection or automated programming. 2. User interface shall be custom programmed for this project and operate as described here within. SYSTEM CONTROLLER 1. Minimum control system requirements: a. Control System shall include: b. Three 2-way RS-232/422/485 ports. c. Eight IR/serial/1-way RS-232 ports. d. Eight isolated low-voltage relays – 30VDC @1A. e. Eight digital/analog I/O ports – TTL In/Out & analog inputs 0 10V. f. Proprietary control port. g. Internal power supply. 2. Control System shall be fully compatible with multi-system management software and third party applications (i.e. Outlook, PowerPoint, etc.). 3. Control System shall include a 10/100 BaseT Ethernet Port that supports all of the following features: a. TCP/IP Communications b. DHCP and DNS Support c. 802.11b and Bluetooth Compatibility d. Native Email Client e. Remote Diagnostics f. Remote Program Loading and Administration g. Built-In Web Server SM&W Project No. 09031 – Integrated Audiovisual Systems MSU, M Project No. 79613 Section 27 41 16 – Page 22 of 30 MINNESOTA STATE COLLEGES AND UNIVERSITIES C. USER INTERFACE 1. Wired Touch Panel a. Configuration: 1) b. c. Features: 1) Minimum resolution of 640 x 480 pixels minimum 2) Support graphic animation on a variety of object styles. 3) Stereo audio input 4) Store and play audio WAV files. 5) Black Finish Accessories 1) 2. D. Rack mount Kit Equal Manufacturers: a. Crestron b. Substitution: By approved substitution means. WIRE AND CABLE 1. 2. E. 5.7” Active matrix color LCD display with hard key buttons. RS-232 Control Cable a. Configuration: Type CL3R, Two Pair twisted shielded with overall shield, 22 AWG (.644 mm), (7x30) b. Properties: 55 pf/ft with OD = 5 mm Specialty Control Cable: a. Configuration: Type CMP Pair twisted shielded 22 AWG and a pair twisted 18 AWG with PVC outer Jacket. b. Properties: Control Pair: 12.5 pF/ft nominal with 100 ohms Z nominal. PROGRAMMING 1. 2. Configuration: a. The system to provide a GUI based on examples from the existing classroom and ballroom touch panels designs. b. Each touch panel to allow for administrative setup of the room, once configured, the panels to lock out admin features and allow only user level features. Features: a. Administrative controls to utilize individual page designs for control of room systems, a page to be provided for: 1) The presentation audio system 2) Digital video routing SM&W Project No. 09031 – Integrated Audiovisual Systems MSU, M Project No. 79613 Section 27 41 16 – Page 23 of 30 MINNESOTA STATE COLLEGES AND UNIVERSITIES 3. 2.6 3) Analog audio routing 4) Projection screen control 5) Lighting presets 6) Display device control b. Each page to feature a tab and allow staff the ability to navigate between pages. c. Generally, the touch screen portion of the touch panel to provide direction, staff would use the touch panel pushbuttons to make a selection, then, the touch screen shall confirm that selection. d. A floor plan background to be utilized to visually represent routing options. Staff could, for example, select a floor box, then select the appropriate input type for routing. This process shall be utilized for output routing as well. e. User level controls to utilize university classroom standard controls. Examples of this control would include: 1) Source selection 2) Source level control 3) Lighting presets 4) Microphone level control 5) Source control ( Play, Pause, Mute, etc.) Design Process a. The successful contractor to gather university standard and ballroom control information b. Meet with staff to review concepts c. The AV contractor to develop touch panel concepts and present a graphical representation of the design for Owner review. d. Upon completion of the AV system and installation of the control system. The AV contractor to review the fully functioning control scheme with the staff and make adjustments necessary to emulate the university standards. e. Six months following substantial completion of the AV systems, the AV contractor to schedule a review meeting with staff and identify any revisions needed. These revisions to be incorporated into the system. MISCELLANEOUS A. DESCRIPTION 1. B. Systems, furniture or components used in support of the display, video, audio, broadcast or control systems described above. RACK POWER DISTRIBUTION 1. Requirements: SM&W Project No. 09031 – Integrated Audiovisual Systems MSU, M Project No. 79613 Section 27 41 16 – Page 24 of 30 MINNESOTA STATE COLLEGES AND UNIVERSITIES a. Sufficient power distribution shall be provided to service the equipment specified within b. 20% future capacity to be provided. c. Transient voltage and surge suppression devices to be provide for all audiovisual equipment. d. Microprocessor based electronic equipment e. f. 1) Provide a 15A rack mounted UPS device with 1 hour battery run time with one outlet for each component served. Total load including future capacity not to exceed 12 Amps. 2) Full running load current to be used for load calculations. 3) Provide additional units as required by load. Non-microprocessor based electronic equipment: 1) Provide a 15A rack mounted power distribution center with one outlet for each component served. Total load including future capacity not to exceed 12 Amps. 2) Multiple power distribution centers may not be daisy chained. Provide a rear rack mounted vertical power distribution strip as needed. Power Amplifiers 1) 2. Power amplifiers to be fed directly from building electrical receptacles. Configuration a. Stand Alone Racks 1) b. Gangable Racks 1) c. Electrical outlets shall be located with in the equipment rack and placed where directed by the AV contractor Wall Mounted Racks 1) d. Electrical outlets shall be located to the rear of the rack and above AV infrastructure outlets. Provide custom length IEC power cords as needed to extend power into the rack and to maintain the service loop. Electrical outlets shall be located with in the equipment rack and placed where directed by the AV contractor Portable Racks and Carts. 1) Internal power distribution to be routed to a flanged male receptacle mounted on the lower rear corner of the rack. a) 2) C. Flanged Receptacle: Hubbell Part No. HBL5278C A black 14/3 type SO power cord of sufficient length to be provide to serve each rack. EQUIPMENT RACKS SM&W Project No. 09031 – Integrated Audiovisual Systems MSU, M Project No. 79613 Section 27 41 16 – Page 25 of 30 MINNESOTA STATE COLLEGES AND UNIVERSITIES 1. Stand Alone Type: a. Configuration: A single equipment rack. b. Features; c. 2. 16 gauge steel fully welded construction with 14 gauge steel top and bottom panels 2) 24” nominal width x 32” nominal depth 3) Lockable front and rear doors 4) Front and rear rack rail. 5) Grounding and bonding lug meeting NEC requirements. 6) Finish: Textured black powder coat. Accessories: 1) Vented top featuring slotted vents 2) Lacing Bars – provide one for each piece of rack mounted equipment. 3) Caster Kit 4) Spare keys – Provide 2 front and rear keys for each rack. Gangable Type: a. Configuration: Multiple equipment racks ganged together an utilizing common sides. b. Features; c. 3. 1) 1) 16 gauge steel fully welded construction with 14 gauge steel top and bottom panels 2) 24” nominal width x 32” nominal depth 3) Lockable front and rear doors 4) Front and rear rack rail. 5) Grounding and bonding lug meeting NEC requirements. 6) Finish: Textured black powder coat. Accessories: 1) Vented top featuring slotted vents 2) Lacing Bars – provide one for each piece of rack mounted equipment. 3) Removable side panels 4) Spare keys – Provide 2 front and rear keys for each rack. Wall Mounted Type: a. Configuration: Wall mounted equipment rack utilizing a back pan and that is hinged to allow access to both the front and rear of equipment mounted within. SM&W Project No. 09031 – Integrated Audiovisual Systems MSU, M Project No. 79613 Section 27 41 16 – Page 26 of 30 MINNESOTA STATE COLLEGES AND UNIVERSITIES b. c. 4. 1) 16 gauge steel fully welded construction 2) 23” nominal width x 20” Usable depth 3) Lockable front door 4) Front and rear rack rail. 5) Grounding and bonding lug meeting NEC requirements. 6) Finish: Textured black powder coat. Accessories: 1) Lacing Bars – provide one for each piece of rack mounted equipment. 2) Spare keys – Provide 2 front and rear keys for each rack. Portable Type: a. Configuration: A single equipment rack with caster base and work surface top used to house equipment intended to be portable. b. Features; c. 5. Features: 1) 16 gauge steel fully welded construction with 14 gauge steel top and bottom panels 2) 24” nominal width x 32” nominal depth 3) Lockable front and rear doors 4) 4” lockable cushion casters. 5) Front and rear rack rail. 6) Grounding and bonding lug meeting NEC requirements. 7) Finish: Textured black powder coat. Accessories: 1) Laminated work surface top 2) Lacing Bars – provide one for each piece of rack mounted equipment. 3) Spare keys – Provide 2 front and rear keys for each rack. Rack Accessories a. b. c. Blank Panels 1) Provide blank panels as detailed on Rack Elevations. 2) Finish: Textured Black Drawers 1) Full extension 2) Finish: Textured Black Shelves SM&W Project No. 09031 – Integrated Audiovisual Systems MSU, M Project No. 79613 Section 27 41 16 – Page 27 of 30 MINNESOTA STATE COLLEGES AND UNIVERSITIES 6. D. 2. Provide shelves with brackets to secure component into place. Determine ventilation requirements to maintain 38 º C maximum temperatures. 1) Provide fans as required each rack. 2) Provide vent blockers to facilitate proper air movement. 3) Provide thermostatic fan control. Equal Manufacturers a. Middle Atlantic Products b. Atlas c. Rittal d. Substitutions: By approved substation means. Mixer Cart a. 30”d x 60”w x 29-1/2” h table with casters. b. Finish: Charcoal Media Cart a. Custom fiber board construction with plastic laminate covering. b. Finish: Matte black. CASES 1. F. 2) CARTS 1. E. Provide Height to match component to nearest rack unit. Ventilation a. 7. 1) Wireless Microphone Case a. 4 Rack Unit. b. Polyethylene molded plastic with casters and pull handle. c. Front and rear access panels. TECHNICAL PANELS 1. Configuration: Custom built outlet box covers used for audiovisual system connectivity. Layout, quantity and details as indicated on plans. 2. Gang Box Cover Plates 3. a. Material: Stainless steel. b. Finish: Natural. c. Engraving: 3.5 mm letters with black fill paint. d. Refer to plan for noted modifications to the above standard configurations. Screw Cover Pull Box Cover Plates SM&W Project No. 09031 – Integrated Audiovisual Systems MSU, M Project No. 79613 Section 27 41 16 – Page 28 of 30 MINNESOTA STATE COLLEGES AND UNIVERSITIES 4. G. H. a. Material: 14 gauge (2mm) steel with three layer lamacoid engraved covering. b. Bevel and remove sharp edges. c. Finish: Black with white interior layer. d. Refer to plan for modifications to the above standard configurations. Equal Manufacturers: a. Proco b. Whirlwind c. Identity Engraving d. Substitutions: By approved substitution means. RACK PANELS 1. Configuration: Custom built rack panels used for audiovisual system connectivity. Layout, quantity and details as indicated on plans. 2. Features; a. Material: 16 gauge flanged steel panels. b. Panel Finish: Flat black anodized alum. 3. Refer to plan for modifications to the above standard configurations. 4. Equal Manufacturers a. ProCo b. Whirlwind c. Identity Engraving d. Substitutions: By approved substitution means. CONNECTORS 1. Configuration: As detailed on plan 2. Features: 3. a. Chassis mounted to utilize universal type metal body b. Connectors to utilize spring retention. c. Provide a color code for all connectors (i.e. Red, Green and Blue chassis shell for RGB type signal. Both Chassis and cable type connectors to utilize this color code. Equal Manufacturers a. Neutrik b. Substitutions: By approved substitution means. PART 3 - EXECUTION 3.1 INSTALLATION SM&W Project No. 09031 – Integrated Audiovisual Systems MSU, M Project No. 79613 Section 27 41 16 – Page 29 of 30 MINNESOTA STATE COLLEGES AND UNIVERSITIES A. COORDINATION 1. Power Distribution a. B. EXECUTION 1. Service Loops a. C. Section 27 41 00 – General Conditions and Requirements of Audiovisual systems MOUNTING HEIGHTS 1. E. Provide a service loop between each stand alone equipment rack and the wall infrastructure serving the rack. The service loop shall allow the rack to be moved away from the wall 2 meters. GENERAL CONDITIONS 1. D. Coordinate power distribution requirements with the Electrical Contractor. AV contractor to provide direction as to location and quantity of base building electrical outlets serving audiovisual equipment. Section 27 41 00 – General Conditions and Requirements of Audiovisual systems APPENDIX A – EQUIPMENT LISTS 1. See attached Appendix for the equipment lists for the audiovisual systems. These lists are provided for the post bidding evaluation process. END OF SECTION SM&W Project No. 09031 – Integrated Audiovisual Systems MSU, M Project No. 79613 Section 27 41 16 – Page 30 of 30 Appendix A - Equipment List Name Description DISPLAY SYSTEMS Mfgr Model No Projection Screen Large Venue Tab Tensioned Low Voltage Interface Existing Datlie TBD 0 1 High Output Projector Lens 6500 Lumen 3-DLP HD Long throw Sanyo Sanyo PLV-HD150 TBD 1 1 Existing Video Projector Existing Sanyo PLC-XF60 1 New Lens Sanyo TBD 1 50" Flat Panel Display Mounting Hardware Panasonic Chief TH-50PF11UK MTRU 1 1 Confidence Monitor Hardware Unit Cost Qty SUBTOTAL Extended Cost $ VIDEO SYSTEMS Input Devices VHS/DVD Blu-Ray DVD CODEC Doc Cam Combination VHS DVD Multi Disc Player Video Conferening Codec Document Camera Sony Sony By Owner By Owner SLV-D360P BDP-S350 --- 2 2 1 1 Digital Distribution HDMI Transmitter DM Matrix DM Receiver Loose Equipment HDMI transmitter 8x8 Digital Matrix Switch Digital Media Reveiver Digital Media Reveiver Crestron Crestron Crestron Crestron DMTX-300 DM-MD8X8 DM-RMC DM-RMC 2 1 5 1 Cable Crestron DigitalMedia Cable Plenum Crestron DM-CBL-P TBD RGBHV Matrix 8x8 RGBHV Matrix Switcher Crestron System Switcher Scaler System Switcher Video to RGBHV Scaler Analog Distribution Cable Cords and Adaptors Misc Cable, Hardware, Connectors, Etc. Extron Extron CENRGBHV8X8 System 7SC IN1502 2 2 Varies Varies TBD -- -- 1 1 SUBTOTAL $ BROADCAST SYSTEMS Wall Camera Ceiling Camera Future Future --- --- 1 1 Press Box Existing Press Box By Owner -- 1 SUBTOTAL $ AUDIO SYSTEMS Inputs Whirlwind Whirlwind Medusa Standard PCDI Direct2 3 3 Combination CD recorder / Cassette Mini Disc Recorder Tascam Tascam CC-222SLmkII MD-350 1 1 Handheld Hanging Compact Handheld Shure Shure Shure SM58 MX200 104C Indoor 4 2 1 Stage box Stage Box with Extension Cable Whirlwind Direct Boxes Direct Boxes Instrument Type Presonal Device Type CD Cassette HD Recorder Microphone Microphone Microphone 2009 Ostrander Auditorium AV Upgrades 1 Shen Milsom and Wilke Wireless Mic Body Pack Lapel Mic Head Worn Mic Handheld Mic Wireless microphone Receiver Body Pack Lapel Mic Cardioid Head Worn Mic Omni Handheld Mic Cardioid Shure Shure Shure Shure Shure ULXP4 ULX1 WL185 WH30TQG ULX2 4 4 4 4 4 Wireless Case Wireless Mic Receiver Case SKB 1SKB-RLX4 1 DSP 01 DSP 02 DSP 03 DSP Processor with CobraNet DSP Processor with CobraNet DSP Processor with CobraNet Symetrix Symetrix Symetrix 1 1 2 DSP 04 Presentation DSP w audio conf ClearOne Express 12x4 Express 12x4 Express 8x8 Converge Pro 880T Sur Proc Surround Sound Processor B&K Reference 70 1 Performance Mixer Mixer Cart 32 Channel Digital Mixing Console I/O DSP Engine Table with Casters Allen and Heath Allen and Heath HON I-Live T80 iDR-32 PR3060A 1 1 1 Patch Panel Patch Cables Mixer Interface 24 Port Patch Panel 3' Patch Cable Active Combiner 70V Interface ADC ADC RDL RDL PPA3-14MKI BK3 ST-MX2 TX-70A A/R 12 4 1 Loudspeaker Hardware Wall Speaker 1 Wall Speaker 2 Wall Speaker 3 Wall Speaker 4 Subwoofer Hardware Stage Monitors Ceiling Speakers Linear Line Array Rigging Hardware Linear Line Array Recessed Linear Line Array Recessed 2-Way Wall Surface Powered Full Range Passive 2-15 Subwoofer Rigging Hardware Powered Full Range Powered Recessed Ceiling Speaker Innovox Polar Focus Innovox Innovox Innovox Alesis Innovox Custom ElectroVoice Quam CLA-9 H4477 SLA 6.1 SLA 4.1 SL 4.1US Active M1 SB215 -ZxA5-90 Solution 1 2 2 2 2 8 4 1 1 4 1 Amplification AMP 01 AMP 02 2 Channel - 200w at 8 ohm 2 Channel - 700w at 8 ohm QSC QSC CX302 CX1102 5 1 Audio Cable Loudspeaker Cabling 22/2 TS Plenum 12/2 Twisted Plenum Belden Belden VFY VFY A/R A/R Listen Listen Listen LT-800-216 LR-300 LA-122 1 A/R 1 -- -- 1 Distribution 1 Loudspeakers Hearing Assist Hearing Assist Hearing Assist Hearing Assist Transmitter Receivers Remote Antenna Misc Cable, Hardware, Connectors, Etc. SUBTOTAL $ PRODUCTION INTERCOM Master Wired Stations Body Packs Headsets Master Station Existing 2 Channel Plate By Owner By Owner By Owner Custom By Owner By Owner -TBD --- 0 A/R 0 0 Cable 2 Pair TS - Plenum Beldon 1325A A/R SUBTOTAL 2009 Ostrander Auditorium AV Upgrades $ Shen Milsom and Wilke CONTROL SYSTEMS Control Systems Cable Programming Control System Master Quote to include: User Interfaces Control Processor(s) Accessories and Cable Crestnet Control Cable Programming Misc Cable, Hardware, Connectors, Etc. Crestron Q43220 1 Crestron Custom CRESTNET-P -- A/R 1 -- -- 1 SUBTOTAL $ Media Cart Power Distribution Drawer MISCELLANEOUS Media Cart Internal 8 Outlet Power Dist 3U Drawer VFI Surgex MAP Custom SX1115 TD3 1 1 1 EFX Rack Power Distribution Drawer 16 Space portable Cart Internal 8 Outlet Power Dist 3U Drawer VFI Surgex MAP RACK-16 SX1115 TD3 1 1 1 Tech Panels Tech Panels Rack Panels Tech Panel at Floor Box Tech Panel at Wall Plate Rack Panel Whirlwind Whirlwind Whirlwind Custom Custom Custom A/R A/R A/R Work Box Portable Cart that contains drawers for mic, cords, stands,etc R&R Cases 4 drawer 30x30x45 1 MAP DWR-24-26 1 Varies Varies 1 Surgex MAP SX1115 TD3 1 1 MAP WRK-SA-4432 1 Equipment Rack 01 Power Distribution Drawer Equipment Rack 02 Power Distribution Drawer Equipment Rack 03 Wall Rack Rack accessories as noted on rack elevations Internal 8 Outlet Power Dist 3U Drawer 44 Space on Caster Rack accessories as noted on rack elevations Internal 8 Outlet Power Dist 3U Drawer Varies Varies 1 Surgex MAP SX1115 TD3 1 1 MAP WRK-SA-4432 1 Varies Varies 1 Power Distribution UPS Drawer 44 Space on Caster Rack accessories as noted on rack elevations Internal 8 Outlet Power Dist Uninterruptable Power Supply 3U Drawer Surgex APC MAP SX1115 TD3 1 1 1 Portable Case Power Distribution Rolling Wireless Mic Case Internal power strip SKB TBD 1SKB-RLX4 TBD 1 1 -- -- 1 Misc Cable, Hardware, Connectors, Etc. SUBTOTAL $ EQUIPMENT SUBTOTAL $ $ $ $ $ $ $ Display Systems Video Systems Broadcast Audio Systems Control Systems Miscellaneous 2009 Ostrander Auditorium AV Upgrades Shen Milsom and Wilke Appendix A Warranty 1 2 3 4 SECOND YEAR WARRANTY PERIOD Preventative Maintenance, Two (2) Visits and Service within 24 hours. Preventative Maintenance, Two (2) Visits and Service within 4 hours. Emergency Service Hourly Rate In Shop Hourly Rate ________ ________ ________ Per/Hr. ________ Per/Hr. 5 6 THIRD YEAR WARRANTY PERIOD Preventative Maintenance, Two (2) Visits and Service within 24 hours. Preventative Maintenance, Two (2) Visits and Service within 4 hours. ________ ________ 7 8 9 10 FOURTH YEAR WARRANTY PERIOD Preventative Maintenance, Two (2) Visits and Service within 24 hours. Preventative Maintenance, Two (2) Visits and Service within 4 hours. FIFTH YEAR WARRANTY PERIOD Preventative Maintenance, Two (2) Visits and Service within 24 hours. Preventative Maintenance, Two (2) Visits and Service within 4 hours. 2009 Ostrander Auditorium AV Upgrades ________ ________ ________ ________ Shen Milsom and Wilke AREA Equipment Engineering Appendix A Master Recap. Pre-Install Install General and Admin Taxes AREA TOTAL Ostrander AV System Total 2009 Ostrander Auditorium AV Upgrades Shen Milsom and Wilke