BID
FOR WORK
INCLUDED IN CONTRACT DOCUMENTS TITLED
SOUTH SHORE WASTEWATER TREATMENT PLANT
BLOWER & ENGINE-GENERATOR SYSTEM UPGRADE
CONTRACT NO. S02004C01
To:
Milwaukee Metropolitan
Sewerage District
Address:
260 West Seeboth Street
Milwaukee, Wisconsin 53204
Bidder :
_________________________________________
Address:
_________________________________________
Date:
_________________________________________
Bidder’s person to contact for information on this Bid:
Name:
_________________________________________
Title
_________________________________________
Telephone
_________________________________________
BIDDERS DECLARATIONS
The undersigned “Bidder” declares that the only person or parties interested in this Bid are those
named herein; that the Bid is, in all respects, fair and without fraud; that it is made without
collusion with any official of the Owner, and that the Bid is made without any connection or
collusion with any person submitting another Bid on this Contract.
The Bidder further declares that it has carefully examined the Contract Documents for the
construction of the project; that it has personally inspected the site; and that it has satisfied itself
as to the quantities of materials, equipment and conditions of the work involved.
The Bidder further declares that it understands that the description of the quantities of work and
materials, as included herein, is brief and intended only to indicate the general nature of the work
and to identify the said quantities with the detailed requirements of the Contract Documents, and
that this Bid is made according to the provisions and under the terms of the Contract Documents,
which Contract Documents are hereby made a part of this Bid, by reference.
Attachment No. 1 to Addendum No. 3
REVISED BID – CONTRACT NO. S02004C01
1
The Bidder further declares that it has exercised its own judgment regarding the interpretation of
subsurface data; has not relied on any interpolation, interpretation, opinion, or conclusion of the
Engineer or Owner with respect to such data; and has utilized all data which it believes pertinent,
these data having been obtained from the Engineer, Owner, and other sources in arriving at its
conclusions.
Bidders are cautioned that in the event the Owner considers that the Bidder will not be
performing a significant portion of the work, taking into account both the trade of the Bidder and
the type and amount of the work being performed, the Owner will conduct a thorough
investigation of the Bidder and its subcontractors to determine whether or not the Bidder can
successfully complete the Contract. Particular emphasis will be placed on the qualifications
(including experience, organization, management, and technical skill) of the Bidder and its
subcontractors.
CLEAN WATER FUND LOAN REQUIREMENTS
By signing this Bid, the Bidder agrees to full compliance with NR 162.09 of the Wisconsin
Administrative Code. The Bidder certifies that it has exercised all options available to it toward
complying with the requirements for Small, Minority and Women’s Business Enterprise
utilization specified in these Contract Documents.
EXECUTION OF CONTRACT
The Bidder agrees that if this Bid is accepted, it shall, within ten (10) days, not including
Sundays and legal holidays, after receiving Notice of Award, sign and deliver two (2) copies of
the Contract to the Owner together with the required Performance Bond, Payment Bond, and
Certificate of Insurance. See Article “AWARD OF CONTRACT AND NOTICE TO
PROCEED” in the INSTRUCTIONS TO BIDDERS.
SBE/WBE/MBE DOCUMENTS
The Bidder agrees that if this Bid is accepted, he/she shall submit to the Owner fully
acknowledged copies of all SBE/WBE/MBE related subagreements, subcontracts, purchase
orders, or similar commercial transaction documents at the pre-construction meeting for this
project. If no pre-construction meeting is scheduled for this project, said documents shall be
submitted within ten (10) days, not including Sundays and legal holidays, after receiving the
Notice of Award. The Bidder to whom a contract is awarded shall also include all activities to
be performed by Small, Women’s and Minority Businesses in the schedule required by Section
01311.
Attachment No. 1 to Addendum No. 3
REVISED BID – CONTRACT NO. S02004C01
2
APPRENTICES
The Bidder agrees that if this Bid is accepted, it shall, (1) in the performance of this Contract and
(2) in the performance of all Subcontracts, at any tier, employ apprentices or see to it that
apprentices will be employed, at all times, in accordance with the maximum ratio of apprentices
to journeymen as established by the Department of Workforce Development, Bureau of
Apprenticeship Standards. A Listing of such utilization of apprentices shall be set forth in the
Apprentice Utilization Form, included as Attachment No. 1 to Addendum No. 1. Any
deviation from such employment or change in the listing shall not be made without the prior
written approval of the Owner.
In order to gain a meaningful training experience, it is the Owner’s goal that apprentices should
be utilized for a minimum of ten percent of the labor hours for the project. Apprentices currently
employed by the prime and subcontractors may satisfy this requirement.
Work should be scheduled so that at a minimum two (2) apprentices are used.
The prime and subcontractors are encouraged to utilize graduates of the Owner’s sponsored
Apprentice Training & Placement Program operated by WRTP / BIGSTEP in collaboration with
the Joint Apprenticeship Training Committees in hiring new or additional apprentices. The prime
and subcontractors should request these graduates when contacting the Joint Apprenticeship
Training Committees for apprentices.
The Owner can provide the Contractor a wage reimbursement ($5 per hour for a maximum 500
hours per candidate) for utilizing Apprentices that were graduates of the Owners’ sponsored
Apprentice Training & Placement Program operated by WRTP/BIGSTEP.
The total
reimbursement shall not exceed $2,500.00 per apprentice.”
SUBSTANCE ABUSE PREVENTION PROGRAM
By signing this Bid, the Bidder certifies to the Owner that it has, or will have prior to Contract
award, a substance abuse prevention program which complies with the Owner’s policy on
substance abuse (contained herein as a SPECIAL ATTACHMENT). The program must cover
all union and non-union employees who work on the Owner’s construction sites. Failure to
implement such a program prior to award shall result in the Bidder being held to be nonresponsible. Following award of the Contract if the Contractor breaches the District Policy by
failing to have or to effectively implement the policy, the Owner shall consider this a breach of
the Contract by the Contractor and may terminate the Contract. This requirement shall be
applicable to all subcontractors with subcontracts in excess of one percent (1%) of the bid.
INSURANCE AND SAFETY REQUIREMENTS FOR ASBESTOS ABATEMENT WORK
The Bidder agrees to provide insurance and to comply with the safety requirements for asbestos
abatement work as specified in Section 13280, ASBESTOS ABATEMENT.
Attachment No. 1 to Addendum No. 3
REVISED BID – CONTRACT NO. S02004C01
3
START OF CONSTRUCTION AND CONTRACT COMPLETION TIME
The Bidder agrees to begin work within ten (10) days after the date the Owner issues the Notice
to Proceed and to complete the construction, in all respects, within one thousand seven
(1,007) days from the date the Owner issues the Notice to Proceed.
Submittals required under this Contract that would affect the start of actual construction can be
submitted by the Contractor at any time after the Owner issues the Notice of Award,
notwithstanding the fact that the Contract has not been executed or the Notice to Proceed issued.
Notwithstanding the Contractor’s right to make early submittals, no cause for delay or time
extension shall arise under the Contract unless the Engineer fails to respond to such submittals
within thirty (30) days after issuance of the Notice to Proceed and the delay impacts the Contract
Completion Date. The time for completion of this Contract shall begin on the day the Notice to
Proceed is issued by the Owner.
LIQUIDATED DAMAGES
In the event the Bidder is awarded a Contract and shall fail to meet the Contract Completion
Date within the time limits or extended time limits agreed upon, as more particularly set forth in
the Contract Documents, liquidated damages shall be paid to the Owner as set forth below until
such date is reached. Liquidated damages for failure to meet the Contract Completion Date shall
be paid at the daily rate of one thousand nine hundred dollars ($1,900) until the work shall have
been finished as provided by the Contract Documents.
CONTRACT COMPLETION RETENTION ACCOUNT
The Owner has established three (3) milestones dates which are important to the Owner
to complete early in the project. In the event that the Bidder is awarded a contract and
fails to complete any required milestone work by the date established for that milestone,
it is agreed by the Bidder and the Owner that the Contract Completion date is in
jeopardy, and liquidated damages, in the amount specified below, will be withheld by the
Owner, over and above the statutory required retainage.
Liquidated damages in the amount of $1,900/day will be withheld for each calendar day
(taking into account any Contract extension of time) that the Bidder is late in meeting the
specified milestone date. For each successive milestone date, additional liquidated
damages will be retained only to the extent that the number of calendar days by which the
milestone date is missed is in excess of the number of calendar days by which the
preceding milestone was missed.
In the event a successive milestone is met or is exceeded by the number of calendar days
less than the number of calendar days by which the preceding milestone was exceeded
and liquidated damages withheld for such preceding milestone date, an adjustment will
be made in the “Contract Completion Retention Account” and any excess retainage of
liquidated damages will be returned to the Bidder.
Attachment No. 1 to Addendum No. 3
REVISED BID – CONTRACT NO. S02004C01
4
The milestones are as follows:
•
Milestone No. 1
Complete construction of the suspended concrete slab
that forms the floor of Filter Room (the ceiling of the
Blower Control Room) in the Blower and Generator
Building within 253 days from the date the Owner
issues the Notice to Proceed.
•
Milestone No. 2
Substantially complete all of the work for Blower
System No. 1 within 510 days from the date the Owner
issues the Notice to Proceed.
•
Milestone No. 3
Substantially complete all of the work for Blower
System No. 2 within 671 days from the date the Owner
issues the Notice to Proceed.
LIQUIDATED DAMAGES FOR FAILURE TO COMPLETE ENGINE GENERATOR WORK
Section 01311, SCHEDULE AND SEQUENCE OF OPERATIONS, requires that Engine
Generators No. 2, 3, 4, and 5 shall be substantially complete not more than two hundred seventy
six (276) days after existing Engine Generator No. 5 has been taken out of service for the
Contractor to complete work. Failure to complete the engine generator work will cause the
Owner financial damage in having to purchase electric power. In the event the Bidder is
awarded a Contract and shall fail to complete the engine generator work within the time limits or
extended time limits agreed upon, as more particularly set forth in the Contract Documents,
liquidated damages shall be paid to the Owner at the daily rate of three thousand dollars ($3,000)
until the engine generator work shall have been finished as provided by the Contract Documents.
SALES AND USE TAXES
The Bidder agrees that all sales and use taxes, where applicable, are included in the stated bid
prices for the work.
LUMP SUM AND/OR UNIT PRICE WORK
The Bidder further agrees to accept as full payment for the work proposed herein the amounts
computed under the provisions of the Contract Documents and based on the following lump sum
and/or unit price amounts, it being expressly understood that the unit prices are independent of
the exact quantities involved, except as stipulated in Article “PAYMENT FOR
MODIFICATIONS” in the GENERAL CONDITIONS. The Bidder agrees that the lump sum
prices and/or unit prices represent a true measure of the labor and materials required to perform
the work, including all allowances for overhead and profit for each type and unit of work called
for in these Contract Documents. The amount shall be shown in both words and figures in the
spaces provided. In case of a discrepancy, the amount shown in words shall govern. The Bidder
acknowledges that the Owner has the right to reject any Bid which, in its sole judgment, is
unbalanced.
Attachment No. 1 to Addendum No. 3
REVISED BID – CONTRACT NO. S02004C01
5
The Bid also contains lump sum allowance items to facilitate payment for work performed under
this Contract by Rockwell Automation. The lump sum allowance items are estimates of the
work to the Owner and do not include any markup for the Bidder. Any markup should be
included in Bid Item No. 1.
UNIT PRICE AND LUMP SUM BID
NOTE TO BIDDERS: All blank spaces requiring input below must be filled in, in black ink.
Bid Item No. 1:
Total Bid Amount minus Bid Items 2 through 9
Lump Sum:
Dollars
and
Cents
(Amount in words )
$
(Amount in figures)
SECTION 04900, MASONRY RESTORATION
Bid Item No. 2:
Masonry Repair of Face Brick
Quantity:
540
Unit:
Square Foot
Unit Price:
$ ___________________________________________/ Square Foot
(Unit Amount in figures)
Unit Price:
____________________________________________Dollars
And ________________________________________Cents/ Square Foot
(Unit Amount in words)
EXTENDED TOTAL AMOUNT: $______________________
(Total Amount in figures)
Attachment No. 1 to Addendum No. 3
REVISED BID – CONTRACT NO. S02004C01
6
Bid Item No. 3:
Masonry Repair of Backup Brick
Quantity:
200
Unit:
Square Foot
Unit Price:
$ __________________________________________/ Square Foot
(Unit Amount in figures)
Unit Price:
____________________________________________Dollars
And ________________________________________Cents/ Square Foot
(Unit Amount in words)
EXTENDED TOTAL AMOUNT: $______________________
(Total Amount in figures)
Bid Item No. 4:
Tuck Pointing
Quantity:
520
Unit:
Square Foot
Unit Price:
$ __________________________________________/ Square Foot
(Unit Amount in figures)
Unit Price:
____________________________________________Dollars
And ________________________________________Cents/ Square Foot
(Unit Amount in words)
EXTENDED TOTAL AMOUNT: $______________________
(Total Amount in figures)
Attachment No. 1 to Addendum No. 3
REVISED BID – CONTRACT NO. S02004C01
7
SECTION 09300, TILE
Bid Item No. 5:
Quarry Floor Tile Restoration
Quantity:
2000
Unit:
Square Foot
Unit Price:
$ __________________________________________/ Square Foot
(Unit Amount in figures)
Unit Price:
____________________________________________Dollars
And ________________________________________Cents/ Square Foot
(Unit Amount in words)
EXTENDED TOTAL AMOUNT: $______________________
(Total Amount in figures)
SECTION 13280, ASBESTOS ABATEMENT
Bid Item No. 6:
Asbestos Abatement Work
Dollars
Lump Sum:
and
Cents
(Amount in words )
$
(Amount in figures)
Attachment No. 1 to Addendum No. 3
REVISED BID – CONTRACT NO. S02004C01
8
SECTION 13460, PROGRAMMABLE CONTROLLERS AND SOFTWARE
Bid Item No. 7:
PLC Hardware and Software
Lump Sum Allowance:
and
Two Hundred Ninety Five Thousand Eighty
Dollars
Twenty Six
Cents
(Amount in words )
$
Bid Item No. 8:
295,080.26
(Amount in figures)
Rockwell Manufacturer Training
Lump Sum Allowance:
and
Thirty Seven Thousand Six Hundred Eighty Seven
Dollars
Fifty
Cents
(Amount in words )
$
Bid Item No. 9:
37,687.50
(Amount in figures)
Rockwell Manufacturer Services
Lump Sum Allowance:
Thirty Nine Thousand Five Hundred Twenty
and
Zero
Dollars
Cents
(Amount in words )
$
Attachment No. 1 to Addendum No. 3
REVISED BID – CONTRACT NO. S02004C01
9
39,520.00
(Amount in figures)
The Bidder agrees to accept as full payment for the work proposed under this project, herein
specified and as shown on the Plans and based upon the undersigned’s own estimate of
quantities and costs, the following sum of extended unit price items plus lump sum items plus
lump sum allowance items:
*************************************************************************
*
*
*
*
* ____________________________________________________________ Dollars
*
*
*
* and ________________________________________________________ Cents
*
*
(Amount in words)
*
*
*
*
$ ______________________
*
*
(Amount in figures)
*
*
*
* This sum comprises the total bid amount for determination of lowest base bid.
*
*
*
*************************************************************************
If the Owner, at its sole discretion, elects to accept an Alternate, it will be awarded to the
responsive, responsible Bidder with the lowest bid price determined by the sum of the bid
amount for the base bid plus the price of the accepted Alternate.
BID ITEM FOR ALTERNATE 1 – SINGLE VANE CONTROL AERATION BLOWER
EQUIPMENT
The Bidder further agrees that if the Owner accepts Alternate 1 – Single Vane Control Aeration
Blower Equipment as described in Section 01012, ALTERNATES, with necessary changes in
construction as required to complete the work, based on undersigned’s own estimate of
quantities and cost, the total bid amount will be adjusted by the following amount:
An (increase) (decrease) of:
___________________________________________________ Dollars
and ________________________________________________ Cents
(Amount in words)
$ _____________________
(Amount in figures)
(Note: if neither “(increase)” or “(decrease)”is crossed out above, an increase will be assumed.)
Attachment No. 1 to Addendum No. 3
REVISED BID – CONTRACT NO. S02004C01
10
Blower Manufacturer
(Name of Proposed Blower Manufacturer)
Bidders must submit with the Bid documentation that shows compliance with the Plans and
Specifications. Documentation shall include:
1.
2.
3.
4.
5.
Product data, specifications, and other descriptive literature;
Process and instrumentation drawings;
General arrangement drawings;
Complete description of equipment and materials of construction.
Performance data, performance curves, and motor shaft horsepower at specified
Maximum Operating Condition and at each specified Operating Point;
6. Installation List. List shall include at least ten (10) installations in North America of
design equal to that proposed for this Project that have been operating successfully for at
least five (5) years. List shall include contact information (entity name, name of contact
person, phone number, address) for each installation.
If documentation is incomplete, or if documentation does not show that the proposed equipment
is in compliance with the Plans and Specifications, or if the Engineer determines that the
proposed equipment is not equal to the equipment specified, then the Bidder agrees to provide
the equipment as manufactured by Turblex as specified in Section 11373 - SINGLE VANE
CONTROL AERATION BLOWER EQUIPMENT for the total bid amount as adjusted for Bid
Item for Alternate 1.
The right is reserved for the Owner to accept or reject the Bid Item for Alternate 1 – Single Vane
Control Aeration Blower Equipment as is in the best interests of the Owner. Alternate 1 and
Alternate 2 are mutually exclusive; if the Owner accepts Alternate 1, then Alternate 2 is rejected.
BID ITEM FOR ALTERNATE 2 – DUAL VANE CONTROL AERATION BLOWER
EQUIPMENT
The Bidder further agrees that if the Owner accepts Alternate 2 – Dual Vane Control Aeration
Blower Equipment as described in Section 01012, ALTERNATES, with necessary changes in
construction as required to complete the work, based on undersigned’s own estimate of
quantities and cost, the total bid amount will be adjusted by the following amount:
An (increase) (decrease) of:
___________________________________________________ Dollars
and ________________________________________________ Cents
(Amount in words)
$ _____________________
(Amount in figures)
Attachment No. 1 to Addendum No. 3
REVISED BID – CONTRACT NO. S02004C01
11
(Note: if neither “(increase)” or “(decrease)”is crossed out above, an increase will be assumed.)
Blower Manufacturer
(Name of Proposed Blower Manufacturer)
Bidders must submit with the Bid documentation that shows compliance with the Plans and
Specifications. Documentation shall include:
1.
2.
3.
4.
5.
Product data, specifications, and other descriptive literature;
Process and instrumentation drawings;
General arrangement drawings;
Complete description of equipment and materials of construction.
Performance data, performance curves, and motor shaft horsepower at specified
Maximum Operating Condition and at each specified Operating Point;
6. Installation List. List shall include at least ten (10) installations in North America of
design equal to that proposed for this Project that have been operating successfully for at
least five (5) years. List shall include contact information (entity name, name of contact
person, phone number, address) for each installation.
If documentation is incomplete, or if documentation does not show that the proposed equipment
is in compliance with the Plans and Specifications, or if the Engineer determines that the
proposed equipment is not equal to the equipment specified, then the Bidder agrees to provide
the equipment as manufactured by Turblex as specified in Section 11374 - DUAL VANE
CONTROL AERATION BLOWER EQUIPMENT for the total bid amount as adjusted for Bid
Item for Alternate 2.
The right is reserved for the Owner to accept or reject the Bid Item for Alternate 2 – Dual Vane
Control Aeration Blower Equipment as is in the best interests of the Owner. Alternate 2 and
Alternate 1 are mutually exclusive; if the Owner accepts Alternate 2, then Alternate 1 is rejected.
BIDDER BREAKDOWN OF SPECIFIC ITEMS
Bidder(s) being considered for award may be required to provide a further detailed breakdown of
the work regarding specific bid items within three (3) business days following receipt of the
request from the Owner. Refer to Section 01300 of Division 1, GENERAL REQUIREMENTS.
The price breakdown shall be fairly apportioned to the items listed. If so requested, the Bidder
shall substantiate any price or prices with additional detailed price breakdown.
Attachment No. 1 to Addendum No. 3
REVISED BID – CONTRACT NO. S02004C01
12
SMALL, WOMEN'S AND MINORITY BUSINESS ENTERPRISE
BREAKDOWN FORM
On the Bidder’s Signature And Sworn Statement of this Bid, the Bidder's stated goal for
S/W/MBE participation is
%, expressed as a percent of the total contract price. That
percentage is comprised of the firms listed on this form. It is understood that the failure to list
firms to equal the percentage stated is a material aspect of the Bid and therefore the failure to
complete the following information will render the bidder non-responsible.
Bidders must also submit, with the Bid or within three (3) business days of receipt of notice from
the Owner, one completed copy of the S/W/MBE Listing (see SPECIAL ATTACHMENT No. 2)
for each SBE, WBE, or MBE subcontractor or supplier of goods and services.
FIRM NAME
AMOUNT
S/W/MBE
1.
______________________________
_____________
________
2.
______________________________
_____________
________
3.
______________________________
_____________
________
4.
______________________________
_____________
________
5.
______________________________
_____________
________
6.
______________________________
____________
________
7.
______________________________
____________
________
8.
____________
________
9.
____________
________
____________
________
10.
______________________________
Please use additional pages if more than ten (10) S/W/MBEs will be utilized as subcontractors.
Attachment No. 1 to Addendum No. 3
REVISED BID – CONTRACT NO. S02004C01
13
SUBCONTRACTOR LISTING
Excluding Small, Women’s, and Minority Business Enterprises listed on the S/W/MBE
Breakdown Form above, the Bidder shall identify all proposed subcontractors who will be
performing work that has a value in excess of one percent (1%) of the total amount of this Bid.
The Bidder certifies that the following subcontracting firms or businesses will be awarded
subcontracts for the indicated portions of the work in the event that the Bidder is awarded the
Contract. See Article SUBCONTRACTING in the GENERAL CONDITIONS.
Firm Name
Address
Street
City
State
Amount of
Subcontract:
Type of Work
Firm Name
Address
Street
City
State
Amount of
Subcontract:
Type of Work
Firm Name
Address
Street
City
State
Amount of
Subcontract:
Type of Work
Firm Name
Address
Street
City
State
Amount of
Subcontract:
Type of Work
Please use additional pages if more than four (4) non-S/W/MBEs will be utilized as
subcontractors.
Attachment No. 1 to Addendum No. 3
REVISED BID – CONTRACT NO. S02004C01
14
LIST OF EQUIPMENT AND/OR MATERIALS (3/06) (1/07)
For each item listed below, the Bidder shall indicate the name of the manufacturer or supplier
and model or type of equipment and/or materials to be provided. The Bidder certifies that the
following firms or businesses will be used by the Bidder to provide the equipment and/or
materials indicated below. The Bidder agrees that, after the opening of bids, no changes in the
Bidder’s selection will be allowed without the written approval of the Owner. Requests for such
changes shall be made in writing with appropriate documentation and reasons included. It is the
responsibility of the Contractor to furnish materials and equipment meeting the requirements of
the Specifications, and acceptance of the Bid does not constitute nor imply approval of items
proposed. The Owner reserves the right to deny approval of any equipment or materials that do
not comply with the Specifications, even though listed herein.
A checkmark shall be placed in the appropriate box to indicate the manufacturer whose
equipment and/or material the Bidder is proposing for this project. If the box labeled "Other" is
checked, the name of the manufacturer shall be inserted. Bidders are cautioned that any
equipment or materials listed must comply with Article “OR EQUAL” MATERIALS AND
EQUIPMENT of the GENERAL CONDITIONS.
The Bidder agrees to provide at no additional cost to the Owner the “A” listed equipment if (1)
the Bidder fails to check a box; (2) fails to enter the name of the manufacturer if “Other” is
checked; (3) checks more than one box; (4) checks a box other than “Other” but lists equipment
under “Other”; (5) lists equipment but fails to check the “Other” box; or (6) the “Other” listed
equipment is determined later to not be an “OR EQUAL”.
ITEM
MANUFACTURER OR SUPPLIER
LISTED IN SPECIFICATION
MODEL NO. OR TYPE
SECTION 11385 DIGESTER GAS COMPRESSOR SYSTEM
Digester Gas
Compressor
System Supplier
(A) Enerflex Inc.
[ ]
Per Section 11385
(B) Unison Solutions
[ ]
Per Section 11385
(C) Hy-Bon, Inc.
[ ]
Per Section 11385
(D) Other:
[ ]
Per Section 11385
SECTION 13400 PROCESS INSTRUMENTATION AND CONTROL SYSTEMS –
GENERAL REQUIREMENTS
I&C System
Suppliers
(A) Allan Integrated Control Systems, Inc. [ ]
Per Section 13400
(B) Eclipse Controls, Inc.
[ ]
Per Section 13400
(C) Pieper Electric
[ ]
Per Section 13400
(D) Other:
[ ]
Per Section 13400
Attachment No. 1 to Addendum No. 3
REVISED BID – CONTRACT NO. S02004C01
15
ITEM
MANUFACTURER OR SUPPLIER
LISTED IN SPECIFICATION
MODEL NO. OR TYPE
SECTION 16030 MOTOR CONTROL
Reduced-Voltage
Starters, NEMA
Class A
(A) Allen Bradley
[ ]
Per Section 16030
(B) Square D
[ ]
Per Section 16030
(C) Cutler-Hammer
[ ]
Per Section 16030
(D) Other:
[ ]
Per Section 16030
(A) Allen Bradley
[ ]
Per Section 16030
(B) Eaton/Cutler-Hammer
[ ]
Per Section 16030
(C) Square D
[ ]
Per Section 16030
(D) Other:
[ ]
Per Section 16030
(A) Allen Bradley
[ ]
Per Section 16030
(B) Benshaw
[ ]
Per Section 16030
(C) Eaton/Cutler-Hammer
[ ]
Per Section 16030
(D) Square D
[ ]
Per Section 16030
(E) Other:
[ ]
Per Section 16030
(A) Allen Bradley
[ ]
Per Section 16030
(B) Eaton/Cutler-Hammer
[ ]
Per Section 16030
(C) Square D
[ ]
Per Section 16030
(D) Other:
[ ]
Per Section 16030
SECTION 16030 MOTOR CONTROL
Motor Control
Centers
SECTION 16030 MOTOR CONTROL
Medium Voltage
Solid State Motor
Starters
SECTION 16030 MOTOR CONTROL
Adjustable Speed
Drives
(continued on next page)
Attachment No. 1 to Addendum No. 3
REVISED BID – CONTRACT NO. S02004C01
16
ITEM
MANUFACTURER OR SUPPLIER
LISTED IN SPECIFICATION
MODEL NO. OR TYPE
SECTION 16344 MEDIUM VOLTAGE SWITCHGEAR
Switchgear
Manufacturer
(A) S&C Electric Company
[ ]
Per Section 16344
(B) Other:
[ ]
Per Section 16344
(A) Carte
[ ]
Per Section 16345
(B) Pauwels
[ ]
Per Section 16345
(C) ABB
[ ]
Per Section 16345
(D) Other:
[ ]
Per Section 16345
SECTION 16345 OIL-FILLED TRANSFORMERS
Transformer
Manufacturer
SECTION 16900 ENGINE-GENERATOR SYSTEM – GENERAL REQUIREMENTS
Engine-Generator
System Supplier
(A) FABCO
[ ]
Per Section 16900
(B) Patten Power
[ ]
Per Section 16900
(C) Other:
[ ]
Per Section 16900
SURETY (3/98)
If the Bidder is awarded a Contract(s) based on this Bid, the Surety who provides the
Performance Bond and Payment Bond will be
______________________________________________________________________________
whose address is ________________________________________________________________
Street
City
State
Zip
Attachment No. 1 to Addendum No. 3
REVISED BID – CONTRACT NO. S02004C01
17
BIDDER'S SIGNATURE AND SWORN STATEMENT (12/01)
State of _______________________________
County of _____________________________
)
) SS
)
I hereby certify that I am submitting this Bid on behalf of
____________________________________________________________________________________________
(Name of Bidder)
a (check one):
___
___
____
Corporation
Sole Proprietorship
Other (Describe)
____
____
Partnership
Joint Venture
of the City of __________________________________________________________________
State of _______________________________________________________________________
I have examined and prepared the foregoing Bid based on the information contained in the
Contract Documents provided with the Bid; that I have checked the same in detail before
submitting this Bid; that I have full authority to make such statements and submit this Bid in
(its)(their)(my) behalf; and that these statements are true and correct.
I further certify that my(our) stated Small/Women's/Minority Business Enterprise participation
for this project is (10) (_____) percent of the total Contract price, such participation meeting this
goal is shown on the Small, Women’s And Minority Business Enterprise Breakdown Form
section of this Bid. I have included documentation of my good faith efforts to secure S/W/MBE
participation and have submitted completed S/W/MBE Listing forms (SPECIAL
ATTACHMENT No. 2) with this Bid. If the above blank is not filled in, my goal is 10%.
I certify that I have read the Milwaukee Metropolitan Sewerage District policy relating to
substance abuse which is an attachment to the contract documents and that I have or will have
prior to contract award a substance abuse program which complies with that policy. I further
certify that all subcontractors on the project have or will have a similar policy prior to their
working on the job-site.
Attachment No. 1 to Addendum No. 3
REVISED BID – CONTRACT NO. S02004C01
18
I certify that the Bidder is not included on the Consolidated List of Debarred Contractors
prepared and issued by the Wisconsin Department of Workforce Development. I further certify
that to the best of my knowledge and belief that no shareholder, officer, or partner of the firm
owns a twenty five percent (25%) or larger share of any other construction business included on
the Consolidated List of Debarred Contractors. Inclusion on this list indicates that the contractor
was found to have committed a “debarrable offense” related to certain labor standard provisions
determined or established for a state or local public works project.
The Bidder hereby acknowledges that it has received Addenda Numbers ___, ___, ___, ___ to
these Contract Documents. (Bidder insert number of each Addendum received.)
NOTE: See next page for signature sheet. Signature MUST be notarized.
Attachment No. 1 to Addendum No. 3
REVISED BID – CONTRACT NO. S02004C01
19
Signature
____________________________________
Title
____________________________________
Subscribed and sworn to before me
this ____ day of ___________________, 20___
_______________________________________
Notary Public - State of ___________________
Commission expires: _____________________
**********
Attachment No. 1 to Addendum No. 3
REVISED BID – CONTRACT NO. S02004C01
20