LBB
LAVATORY/ PIPING
CSA-2669
SECTION 01100 - SUMMARY
PART 1 - GENERAL
1.1
RELATED DOCUMENTS
A.
1.2
Drawings and general provisions of the Contract, including General and Supplementary Conditions and
other Division 01 Specification Sections, apply to this Section.
SUMMARY
A.
This Section includes the following:
1.
2.
3.
4.
5.
6.
B.
1.3
Work covered by the Contract Documents.
Products ordered in advance.
Use of premises.
Owner's occupancy requirements.
Work restrictions.
Specification formats and conventions.
Related Sections include the following:
1.
Division 01 Section "Temporary Facilities and Controls" for limitations and procedures governing
temporary use of Owner's facilities.
WORK COVERED BY CONTRACT DOCUMENTS
A.
Project Identification:
PIPING Project
LBB TRACON AND ATCT –REFURBISH LAVATORY AND REPLACE
1.
Project Location: Lubbock Preston Smith International Airport
2.
Owner's Representative: FAA Resident Engineer/COR
a.
All work performed and all materials and equipment used are subject to approval by the
“Contracting Officer Representative” (COR). The drawings make reference to “Resident
Engineer” (RE), which is equivalent to COR/RE.
B.
Designers: Terminal Engineering Services, AJW-C11C.
C.
The Work includes (but not limited to):
REPLACE PIPING;
1.
2.
3.
4.
5.
6.
7.
Remove and replace roof drain plumbing in east side of base building.
Remove and replace the sewer line extending to the base building restrooms and the Janitor Room.
Remove and replace slab on grade as needed in Restrooms, Ready/Break Room, Training
Conference Room, and hallways.
Asbestos abatement and re-tile of Ready Room.
Provide temporary break room facilities.
Remove and replace sewer line in ATCT.
Asbestos abatement and reseal of the ATCT catwalk.
REFURBISH LAVATORY;
SUMMARY
01100 - 1
LBB
LAVATORY/ PIPING
8.
9.
10.
11.
12.
13.
D.
1.4
CSA-2669
In all three Restrooms and Custodial Room: remove all flooring, plumbing fixtures, electrical
fixtures, wall coverings, shelving, partitions, hung ceilings.
Modernize Men's and Women's Restrooms for accessible sinks, toilets, and urinals.
Modernize Tower Restroom.
Modernize Custodial Room.
Provide temporary restroom facilities.
The facility is operational on a 24 hour basis and must remain so with the least amount of noise
and disruption.
Drawing Convention – The contract drawings for this project are revisions to the original construction
drawings for the facility. All dimensions are for informational purposes only and shall be field verified by
the Contractor.
WORK UNDER CONTRACT
A.
1.5
General: a. Contractor must supply a full item by item breakdown of their bid with the following
headings:
1.
ACM removal in Break Room and Catwalk
2.
Restrooms, Break Room, Conference Room, Custodial Room
3.
TRACON piping including concrete floor repair.
4.
Tower piping
5.
Catwalk
6.
Temporary Faculties
USE OF PREMISES
A.
General: Contractor shall have limited and restricted use of the premises for construction operations as
indicated by FAA COR in coordination with Facility Operations personnel.
B.
Use of Existing Building: Maintain existing building in a weather tight condition throughout construction
period. Repair damage caused by construction operations. Protect building and its occupants during
construction period.
1.6
COORDINATION WITH OCCUPANTS
A.
Partial Owner Occupancy: FAA personnel will occupy the premises during the entire construction
period, with the exception of areas under construction. Cooperate with COR/RE during construction
operations to minimize conflicts and facilitate continual usage of facility. Perform the Work so as not to
interfere with facility operations. Maintain existing exits unless otherwise indicated.
1.
Existing Facility Operations: The LBB is a 24-hour, 7 days per week operating facility. It will
be necessary to coordinate all construction activities so as not to interfere with the facility’s
operation. Work must be scheduled and planned by the contractor, and coordinated with the
COR/RE so that normal facility operations may continue WITHOUT disruption and/or
interference.
2.
Maintain access to existing walkways, corridors, and other adjacent occupied or used facilities.
Do not close or obstruct walkways, corridors, or other occupied or used facilities without written
permission from the CO and/or COR/RE.
SUMMARY
01100 - 2
LBB
LAVATORY/ PIPING
CSA-2669
3.
The General Contractor (GC) must not block the LBB facility’s main entrance during the entire
construction period, especially during controller shift changes, 06:30AM - 08:00AM and
02:30PM - 04:00PM. Extensive coordination between the general contractor and FAA personnel
(COR/RE) shall be required at all times.
4.
Contractor must coordinate all night and weekend work with COR/RE.
5.
GC must provide, on a weekly basis, a two-week look ahead schedule of work. Schedules must be
submitted by 0500 hrs, every Thursday, to the COR/RE.
6.
Provide not less than seventy-two (72) hours’ notice to COR/RE of activities that will affect the
LBB facility operations.
B.
Project Coordination: The contractor must prepare a detailed schedule of work and work layout to
resolve conflicts and to ensure coordination of the work by different trades. It shall be the duty of the
contractor to resolve all coordination conflicts that arise among his subcontractors. The contractor shall
coordinate all day-to-day schedules in advance with the COR/RE to prevent delays. Specific
coordination may periodically be required. See Section 013100 (Project Management and Coordination)
for more information.
C.
Work Affecting Operational Systems: The contractor must coordinate all work, which has or may
have any impact on any operation of the LBB facility, through the COR/RE. The contractor must
immediately cease any work, which is adversely impacting the operation of the LBB facility, and
must immediately repair or restore any portion of the facility that has been damaged or suffered
diminished performance as a result of the contractor's activities.
D.
Local Permits and Coordination: The Contractor shall be responsible for obtaining permits, payment of
all building fees, inspection fees, utility connection charges and any other fees or charges which may be
incurred in the performance of this contract.
E.
Applicable Documents: The contractor shall comply with all local city, county, and state construction
codes.
1.7
WORK RESTRICTIONS
A.
Duration for this project is 210 calendar days. The contractor shall complete this project, including final
clean-up of the premises and storage and equipment areas within this duration. This shall include
operational testing of systems.
On-Site Work Hours: All work hours, shifts, and overtime work must be coordinated with the COR/RE
fourteen (14) days in advance. This is important due to security requirements. Before commencing
construction, furnish to the COR/RE a statement of hours per day and days per week to normally be worked and
approximate number of persons on the job for a normal work shift. Normal work hours for the project are to
be from 08:00AM – 05:00PM, Monday through Friday.
There is a high potential for night time working hours due to facility disruptions. The extent of the
night work will be discussed at the preconstruction meeting with the COR/RE and the LBB facility.
The contractor must observe all Federal Holidays and no overtime work will be allowed unless a
request has been submitted and approved in writing at least 14 days in advance. Weekend work
must be coordinated with the COR/RE and the LBB facility at least 14 days in advance.
B.
Noise, Vibration, and Odors: Coordinate operations that may result in high levels of noise and vibration,
odors, or other disruption to the LBB facility.
SUMMARY
01100 - 3
LBB
LAVATORY/ PIPING
1.
2.
3.
4.
5.
C.
1.8
Notify COR/RE not less than two (2) days in advance of proposed disruptive operations.
Obtain CO’s written permission before proceeding with disruptive operations.
Submit a Material Safety Data Sheet (MSDS) with samples of all potential vapor emitting
materials to COR/RE. Allow a minimum of seven (7) days for review and approval of
materials submitted.
Night work is permissible but must be coordinated with the COR/RE and approved by the facility
management.
No work shall be performed during the following Holiday Moratoriums:
a.
Thanksgiving Holiday starting 7:00 p.m. (EST) o18 November, 2016 through 3:00 a.m.
(EST), 28 November, 2016.
b.
Christmas/New Year Holiday starting 7:00 p.m. (EST) on 22 December 2016 through 3:00
a.m. (EST), 3 January 2016.
Existing Utility Interruptions: Do not interrupt utilities serving facilities occupied by Owner or others
unless permitted under the following conditions and then only after arranging to provide temporary utility
services according to requirements indicated:
1.
2.
D.
CSA-2669
Notify the FAA Resident Engineer 72 Hours prior to proposed utility interruptions or outage.
Do not proceed with utility interruptions without the FAA Resident Engineer written permission.
No work shall be performed during the following Holiday Moratoriums.
1.
Thanksgiving Holiday starting 7:00 p.m. (EST) o18 November, 2016 through 3:00 a.m. (EST), 28
November, 2016.
2.
Christmas/New Year Holiday starting 7:00 p.m. (EST) on 22 December 2016 through 3:00 a.m.
(EST), 3 January 2016.
ACCEPTANCE AND WARRANTIES
A.
Upon substantial completion of work, the FAA will conduct Contractor Acceptance Inspections (CAI).
At the appropriate stage after the CAI, the work will be considered Substantially Complete, and the FAA
will assume occupancy of the work at a date identified as Beneficial Occupancy Date (BOD). Other
contractor acceptance inspections will be conducted prior to partial FAA occupancies. A final inspection,
called Joint Acceptance Inspection (JAI), to determine FAA acceptance of the total work, will then be
conducted.
B.
Contractor must provide written warranty for material and equipment furnished by the various
manufacturers for the following periods:
1.
2.
3.
4.
5.
6.
7.
1.9
General construction: 2-year warranty.
Mirrors: 15 years
Architectural finishes: 2-year warranty.
Structural: 10 years
Mechanical and Plumbing: 2-year warranty, unless otherwise stated.
Electrical: 2-year warranty, unless otherwise stated.
All other equipment and finishes: 2-year warranty
SPECIFICATION FORMATS AND CONVENTIONS
A.
Specification Format: The Specifications are organized into Divisions and Sections using the 16-division
format and CSI/CSC's "MasterFormat" numbering system.
1.
Section Identification: The Specifications use Section numbers and titles to help cross-referencing
in the Contract Documents. Sections in the Project Manual are in numeric sequence; however, the
SUMMARY
01100 - 4
LBB
LAVATORY/ PIPING
2.
B.
sequence is incomplete because all available Section numbers are not used. Consult the table of
contents at the beginning of the Project Manual to determine numbers and names of Sections in
the Contract Documents.
Division 01: Sections in Division 01 govern the execution of the Work of all Sections in the
Specifications.
Specification Content: The Specifications use certain conventions for the style of language and the
intended meaning of certain terms, words, and phrases when used in particular situations. These
conventions are as follows:
1.
2.
Abbreviated Language: Language used in the Specifications and other Contract Documents is
abbreviated. Words and meanings shall be interpreted as appropriate. Words implied, but not
stated, shall be inferred as the sense requires. Singular words shall be interpreted as plural, and
plural words shall be interpreted as singular where applicable as the context of the Contract
Documents indicates.
Imperative mood and streamlined language are generally used in the Specifications. Requirements
expressed in the imperative mood are to be performed by Contractor. Occasionally, the indicative
or subjunctive mood may be used in the Section Text for clarity to describe responsibilities that
must be fulfilled indirectly by Contractor or by others when so noted.
a.
1.10
A.
FAA ESCORT:
Contractor shall provide the building owner with a list of contractor’s personnel who will require
access to the site. The list shall be kept current during project work.
SECURITY INVESTIGATION:
1.
D.
FAA will provide a Resident Engineer to Escort Contractor on a Full Time Basis during work
hours listed above.
PERSONNEL LIST:
1.
C.
The words "shall," "shall be," or "shall comply with," depending on the context, are
implied where a colon (:) is used within a sentence or phrase.
SECURITY REQUIREMENTS
1.
B.
CSA-2669
Contractor’s personnel will have a security investigation by the FAA. Upon request by the
Resident Engineer, the contractor shall promptly complete all security forms provided the by
Resident Engineer.
RIGHT TO SEARCH:
1.
Current procedures at FAA facilities include the “right to search.” If in the judgment of the FAA,
a reason to search a vehicle or person exists, such search will be made.
PART 2 - PRODUCTS (Not Used)
PART 3 - EXECUTION (Not Used)
SUMMARY
END OF SECTION 01100
01100 - 5