Document 15382927

advertisement
FORM A-1
TECHNICAL PROPOSAL LETTER
PROPOSER: ________
Technical Proposal Date: _____________, 2015
Texas Department of Transportation
7600 Chevy Chase Drive, Building 2, 4th Floor
Austin, Texas 78752
Attn: Mr. Dieter Billek, P.E.
The undersigned (“Proposer”) submits this detailed technical proposal (this “Technical Proposal,” and
together with the Financial Proposal to be submitted on or before the Financial Proposal Due Date, the
“Proposal”) in response to that certain Request for Proposals (the “RFP”) issued by the Texas
Department of Transportation (“TxDOT”), an agency of the State of Texas, dated January 31, 2014, as
amended, to develop, design, construct, finance, operate and maintain the TxDOT Toll Lanes Project in
Harris County (the “Project”), as more specifically described herein and in the documents provided with
the RFP (the “RFP Documents”). Initially capitalized terms not otherwise defined herein shall have the
meanings set forth in the RFP and the RFP Documents.
In consideration for TxDOT supplying us, at our request, with the RFP Documents and agreeing to
examine and consider the Proposal, the undersigned undertakes [jointly and severally] [if Proposer is a
joint venture or association other than a corporation, limited liability company or a partnership, leave in
words “jointly and severally,” and delete the brackets; otherwise delete the entire phrase]:
a)
to keep the Proposal open for acceptance initially for 210 days after the Financial
Proposal Due Date, without unilaterally varying or amending its terms and without any member or partner
withdrawing or any other change being made in the composition of the partnership/joint venture/limited
liability company/consortium on whose behalf the Proposal is submitted, without first obtaining the prior
written consent of TxDOT, in TxDOT’s discretion; and
b)
if the Proposal is accepted, to provide security for the due performance of the
Comprehensive Development Agreement (“CDA”) as stipulated in the CDA and the RFP.
If selected by TxDOT, Proposer agrees to do the following or to cause Developer to do the following: (a)
if requested by TxDOT in its discretion, enter into good faith negotiations with TxDOT regarding the
terms of the CDA, in accordance with the requirements of the RFP; (b) enter into the CDA without
varying or amending its terms (except for modifications agreed to by TxDOT in its discretion), and satisfy
all other conditions to award of the CDA; and (c) perform its obligations as set forth in the ITP and CDA,
including compliance with all commitments contained in this Proposal.
The following individual is designated as Proposer’s designated representative in accordance with Section
2.2.2 of the ITP:__________________________________________________
Enclosed, and by this reference incorporated herein and made a part of this Technical Proposal, are the
following:
•
Executive Summary
Texas Department of Transportation
SH 288 Toll Lanes Project in Harris County
December 18, 2014
-1-
Addendum #8 to Request for Proposals
Instructions to Proposers, Form A-1
•
Technical Proposal, including Proposer Information, Certifications and Documents
Proposer acknowledges receipt of the following Addenda and sets of questions and responses:
[List all Addenda by number and date issued. For example, “Addendum No. 1 issued
February 10, 2014”]
[List dates on which TxDOT responded to Proposers’ questions regarding the RFP
Documents or this procurement.]
Proposer certifies that its Technical Proposal is submitted without reservation, qualification, assumptions
or conditions. Proposer certifies that it has carefully examined and is fully familiar with all of the
provisions of all of the RFP Documents, has reviewed all materials posted on the secure file transfer site
for the Project, the Addenda (if any) and TxDOT’s responses to questions, and is satisfied that the RFP
Documents provide sufficient detail regarding the obligations to be performed by Developer and do not
contain internal inconsistencies; that it has carefully checked all the words, figures and statements in this
Technical Proposal; that it has conducted such other field investigations and additional design
development which are prudent and reasonable in preparing this Technical Proposal; and that it has
notified TxDOT of any deficiencies in or omissions from any RFP Documents or other documents
provided by TxDOT and of any unusual site conditions observed prior to the date hereof.
Proposer represents that all statements made in the QS previously delivered to TxDOT (as amended and
resubmitted) are true, correct and accurate as of the date hereof, except as otherwise specified in the
enclosed Technical Proposal and Technical Proposal forms. Proposer agrees that such QS, except as
modified by the enclosed Technical Proposal and Technical Proposal forms, is incorporated as if fully set
forth herein.
Proposer understands that TxDOT is not bound to accept the Proposal offering the highest payment to
TxDOT, requesting the least public funds or any Proposal TxDOT may receive.
Proposer further understands that all costs and expenses incurred by it in preparing the Proposal and
participating in the RFP process will be borne solely by Proposer, except any payment for work product
that may be paid in accordance with the RFP.
Proposer consents to TxDOT’s disclosure of its Proposal pursuant to Section 223.204(a), Texas
Transportation Code, to any Persons in TxDOT’s discretion after Conditional Award. Proposer
acknowledges and agrees to the disclosure terms described in ITP Section 2.6. Proposer expressly waives
any right to contest such disclosures under Texas Transportation Code Section 223.204(a).
Proposer agrees that TxDOT will not be responsible for any errors, omissions, inaccuracies or incomplete
statements in the Proposal.
The Proposal shall be governed by and construed in all respects according to the laws of the State of
Texas.
Proposer’s business address:
(No.)
Texas Department of Transportation
SH 288 Toll Lanes Project in Harris County
December 18, 2014
(Street)
(Floor or Suite)
-2-
Addendum #8 to Request for Proposals
Instructions to Proposers, Form A-1
(City)
(State or Province)
(ZIP or Postal Code)
(Country)
State or Country of Incorporation/Formation/Organization:
[Insert appropriate signature block from following page. Note: signatures should be in blue ink. Evidence
of signature authorization for all individuals executing Proposal forms must be attached.]
Texas Department of Transportation
SH 288 Toll Lanes Project in Harris County
December 18, 2014
-3-
Addendum #8 to Request for Proposals
Instructions to Proposers, Form A-1
1.
Sample signature block for corporation or limited liability company:
[Insert Proposer’s name]
By:
Print Name:
Title:
2.
Sample signature block for partnership or joint venture:
[Insert Proposer’s name]
By: [Insert general partner’s or member’s name]
By:
Print Name:
Title:
[Add signatures of additional general partners or members as appropriate]
3.
Sample signature block for attorney in fact:
[Insert Proposer’s name]
By:
Print Name:
Attorney in Fact
Texas Department of Transportation
SH 288 Toll Lanes Project in Harris County
December 18, 2014
-4-
Addendum #8 to Request for Proposals
Instructions to Proposers, Form A-1
ADDITIONAL INFORMATION TO BE PROVIDED WITH TECHNICAL PROPOSAL LETTER:
A.
B.
Describe in detail the legal structure of Proposer/Developer and Equity Members. If any entity is
not yet formed or if a modification is contemplated prior to award, so state and provide a brief
description of the proposed legal structure of each such entity.
1.
If Proposer/Developer/Equity Member is a corporation or includes a corporation as a joint
venture member, partner or member, provide articles of incorporation and bylaws for
Proposer/Developer and each corporation certified by an appropriate individual. If any entity
is not yet formed or if a modification to existing articles of incorporation and/or bylaws is
contemplated prior to award, so state, indicate that these documents will be provided prior to
award and provide applicable draft documents for each such entity.
2.
If Proposer/Developer/Equity Member is a partnership or includes a partnership as a joint
venture member, partner or member, attach full names and addresses of all partners and the
equity ownership interest of each entity, provide the incorporation, formation and
organizational documentation for Proposer/Developer/Equity Member (partnership
agreement and certificate of partnership for a partnership, articles of incorporation and
bylaws for a corporation, operating agreement for a limited liability company and joint
venture agreement for a joint venture) certified by an appropriate individual. If any entity is
not yet formed or if a modification to the organization documents is contemplated prior to
award, so state, indicate that these documents will be provided for such entity prior to award
and provide applicable draft documents for each such entity.
3.
If Proposer/Developer/Equity Member is a joint venture or includes a joint venture as a joint
venture member, partner or member, attach full names and addresses of all joint venture
members and the equity ownership interest of each entity, provide the incorporation,
formation and organizational documentation for Proposer/Developer/Equity Member
(partnership agreement and certificate of partnership for a partnership, articles of
incorporation and bylaws for a corporation, operating agreement for a limited liability
company and joint venture agreement for a joint venture) certified by an appropriate
individual. If any entity is not yet formed or if a modification to the organization documents
is contemplated prior to award, so state, indicate that these documents will be provided prior
to award and provide applicable draft documents for each such entity.
4.
If Proposer/Developer/Equity Member is a limited liability company or includes a limited
liability company as a joint venture member, partner or member, attach full names and
addresses of all members and the equity ownership interest of each entity, provide the
incorporation, formation and organizational documentation for Proposer/Developer/Equity
Member (partnership agreement and certificate of partnership for a partnership, articles of
incorporation and bylaws for a corporation, operating agreement for a limited liability
company and joint venture) certified by an appropriate individual. If any entity is not yet
formed or if a modification to the organization documents is contemplated prior to award, so
state, indicate that these documents will be provided prior to award and provide applicable
draft documents for each such entity.
Attach evidence to the Technical Proposal that the person(s) signing the Technical Proposal
Letter has (or have) authority to do so and that execution and delivery of the Technical Proposal
is authorized and the Technical Proposal is valid. If Proposer is a corporation, it shall provide
evidence in the form of a resolution of its governing body certified by an appropriate officer of
the corporation. If Proposer is a partnership, such evidence shall be in the form of a partnership
Texas Department of Transportation
SH 288 Toll Lanes Project in Harris County
December 18, 2014
-5-
Addendum #8 to Request for Proposals
Instructions to Proposers, Form A-1
resolution and a general partner resolution (as to each general partner) providing such
authorization, in each case, certified by an appropriate officer of the general partner. If Proposer
is a limited liability company, such evidence shall be in the form of a limited liability company
resolution and a managing member(s) resolution providing such authorization, certified by an
appropriate officer of the managing member(s). If there is no managing member, each member
shall provide the foregoing information. If Proposer is a joint venture, such evidence shall be in
the form of a resolution of each joint venture member, certified by an appropriate officer of such
joint venture member. If Proposer is a joint venture or a partnership, the Technical Proposal must
be executed by all joint venture members or all general partners, as applicable.
C.
Developer’s organizational documents, including an agreement to which all equity owners, either
directly or through intermediaries, are a party (partnership agreement, limited liability company
operating agreement, and joint venture agreement, as applicable), must include an express
provision satisfactory to TxDOT, in its discretion, stating that, in the event of a dispute between
or among joint venture members, partners or members, as applicable, no joint venture member,
partner or member, as applicable, shall be entitled to stop, hinder or delay work on the Project.
Proposer shall submit the applicable organizational documents (or draft organizational documents
if Developer is not yet formed) and identify on a cover page where in the agreement the provision
can be found. If Developer is wholly owned by a single entity but has more than one equity
owner through one or more intermediaries, Proposer shall submit organizational documents for
Developer, the entity that is directly held by the ultimate equity owners of Developer and for each
intermediary. For purposes of this paragraph C, the term “equity member” shall mean any entity
having a direct or indirect through intermediaries equity interest in Developer of at least 10%.
Texas Department of Transportation
SH 288 Toll Lanes Project in Harris County
December 18, 2014
-6-
Addendum #8 to Request for Proposals
Instructions to Proposers, Form A-1
FORM A-2
FINANCIAL PROPOSAL LETTER
PROPOSER: ________
Financial Proposal Date: _____________, 2015
Texas Department of Transportation
7600 Chevy Chase Drive, Building 2, 4th Floor
Austin, Texas 78752
Attn: Mr. Dieter Billek, P.E.
The undersigned (“Proposer”) submits this detailed financial proposal (this “Financial Proposal,” and
together with the Technical Proposal submitted on [___], 2015, this “Proposal”) in response to that
certain Request for Proposals (the “RFP”) issued by the Texas Department of Transportation
(“TxDOT”), an agency of the State of Texas, dated January 31, 2014, as amended, to develop, design,
construct, finance, operate and maintain the TxDOT Toll Lanes Project in Harris County (the “Project”),
as more specifically described herein and in the documents provided with the RFP (the “RFP
Documents”). Initially capitalized terms not otherwise defined herein shall have the meanings set forth in
the RFP and the RFP Documents.
In consideration for TxDOT supplying us, at our request, with the RFP Documents and agreeing to
examine and consider this Proposal, the undersigned undertakes [jointly and severally] [if Proposer is a
joint venture or association other than a corporation, limited liability company or a partnership, leave in
words “jointly and severally,” and delete the brackets; otherwise delete the entire phrase]:
a)
to keep this Proposal open for acceptance initially for 210 days after the Financial
Proposal Due Date, without unilaterally varying or amending its terms and without any member or partner
withdrawing or any other change being made in the composition of the partnership/joint venture/limited
liability company/consortium on whose behalf this Proposal is submitted, without first obtaining the prior
written consent of TxDOT, in TxDOT’s discretion; and
b)
if this Proposal is accepted, to provide security for the due performance of the
Comprehensive Development Agreement (“CDA”) as stipulated in the CDA and the RFP.
If selected by TxDOT, Proposer agrees to do the following or to cause Developer to do the following: (a)
if requested by TxDOT in its discretion, enter into good faith negotiations with TxDOT regarding the
terms of the CDA, in accordance with the requirements of the RFP; (b) enter into the CDA without
varying or amending its terms (except for modifications agreed to by TxDOT in its discretion), and satisfy
all other conditions to award of the CDA; and (c) perform its obligations as set forth in the ITP and CDA,
including compliance with all commitments contained in this Proposal.
The following individual is designated as Proposer’s designated representative in accordance with Section
2.2.2 of the ITP:__________________________________________________
Proposer incorporates into this Proposal by reference, the Technical Proposal submitted by Proposer on
[___], 2015. In addition, enclosed, and by this reference incorporated herein and made a part of this
Proposal, is the Financial Proposal, including the Proposal Security.
Proposer acknowledges receipt of the following Addenda and sets of questions and responses:
Texas Department of Transportation
SH 288 Toll Lanes Project in Harris County
December 18, 2014
-7-
Addendum #8 to Request for Proposals
Instructions to Proposers, Form A-2
[List all Addenda by number and date issued. For example, “Addendum No. 1 issued
February 10, 2014”]
[List dates on which TxDOT responded to Proposers’ questions regarding the RFP
Documents or this procurement.]
Proposer certifies that its Proposal is submitted without reservation, qualification, assumptions or
conditions. Proposer certifies that it has carefully examined and is fully familiar with all of the provisions
of all of the RFP Documents, has reviewed all materials posted on the secure file transfer site for the
Project, the Addenda (if any) and TxDOT’s responses to questions, and is satisfied that the RFP
Documents provide sufficient detail regarding the obligations to be performed by Developer and do not
contain internal inconsistencies; that it has carefully checked all the words, figures and statements in this
Proposal; that it has conducted such other field investigations and additional design development which
are prudent and reasonable in preparing this Proposal; and that it has notified TxDOT of any deficiencies
in or omissions from any RFP Documents or other documents provided by TxDOT and of any unusual
site conditions observed prior to the date hereof.
Proposer represents that all statements made in the QS previously delivered to TxDOT (as amended and
resubmitted) are true, correct and accurate as of the date hereof, except as otherwise specified in the
enclosed Proposal and Proposal forms. Proposer agrees that such QS, except as modified by the enclosed
Proposal and Proposal forms, is incorporated as if fully set forth herein.
Proposer understands that TxDOT is not bound to accept the Proposal offering the highest payment to
TxDOT, requesting the least public funds or any Proposal TxDOT may receive.
Proposer further understands that all costs and expenses incurred by it in preparing this Proposal and
participating in the RFP process will be borne solely by Proposer, except any payment for work product
that may be paid in accordance with the RFP.
Proposer consents to TxDOT’s disclosure of its Proposal pursuant to Section 223.204(a), Texas
Transportation Code, to any Persons in TxDOT’s discretion after Conditional Award. Proposer
acknowledges and agrees to the disclosure terms described in ITP Section 2.6. Proposer expressly waives
any right to contest such disclosures under Texas Transportation Code Section 223.204(a).
Proposer agrees that TxDOT will not be responsible for any errors, omissions, inaccuracies or incomplete
statements in this Proposal.
This Proposal shall be governed by and construed in all respects according to the laws of the State of
Texas.
Proposer’s business address:
(No.)
(City)
(Street)
(Floor or Suite)
(State or Province)
(ZIP or Postal Code)
(Country)
State or Country of Incorporation/Formation/Organization:
Texas Department of Transportation
SH 288 Toll Lanes Project in Harris County
December 18, 2014
-8-
Addendum #8 to Request for Proposals
Instructions to Proposers, Form A-2
[Insert appropriate signature block from following page. Note: signatures should be in blue ink. Evidence
of signature authorization for all individuals executing Proposal forms must be attached.]
Texas Department of Transportation
SH 288 Toll Lanes Project in Harris County
December 18, 2014
-9-
Addendum #8 to Request for Proposals
Instructions to Proposers, Form A-2
1.
Sample signature block for corporation or limited liability company:
[Insert Proposer’s name]
By:
Print Name:
Title:
2.
Sample signature block for partnership or joint venture:
[Insert Proposer’s name]
By: [Insert general partner’s or member’s name]
By:
Print Name:
Title:
[Add signatures of additional general partners or members as appropriate]
3.
Sample signature block for attorney in fact:
[Insert Proposer’s name]
By:
Print Name:
Attorney in Fact
Texas Department of Transportation
SH 288 Toll Lanes Project in Harris County
December 18, 2014
- 10 -
Addendum #8 to Request for Proposals
Instructions to Proposers, Form A-2
ADDITIONAL INFORMATION TO BE PROVIDED WITH FINANCIAL PROPOSAL LETTER:
A.
Attach evidence to the Proposal that the person(s) signing the Financial Proposal Letter has (or
have) authority to do so and that execution and delivery of the Proposal (including both the
Financial Proposal and the Technical Proposal) is authorized and the Proposal is valid. If
Proposer is a corporation, it shall provide evidence in the form of a resolution of its governing
body certified by an appropriate officer of the corporation. If Proposer is a partnership, such
evidence shall be in the form of a partnership resolution and a general partner resolution (as to
each general partner) providing such authorization, in each case, certified by an appropriate
officer of the general partner. If Proposer is a limited liability company, such evidence shall be in
the form of a limited liability company resolution and a managing member(s) resolution
providing such authorization, certified by an appropriate officer of the managing member(s). If
there is no managing member, each member shall provide the foregoing information. If Proposer
is a joint venture, such evidence shall be in the form of a resolution of each joint venture member,
certified by an appropriate officer of such joint venture member. If Proposer is a joint venture or a
partnership, the Proposal must be executed by all joint venture members or all general partners, as
applicable.
Texas Department of Transportation
SH 288 Toll Lanes Project in Harris County
December 18, 2014
- 11 -
Addendum #8 to Request for Proposals
Instructions to Proposers, Form A-2
FORM B-1
IDENTIFICATION OF PROPOSER AND EQUITY MEMBERS
NAME OF
ENTITY AND
CONTACT
INFORMATION
(address,
representative,
phone, fax, email)
ROLE IN
ORGANIZATION
DESCRIPTION OF
WORK/SERVICES
TO BE
PERFORMED BY
ENTITY (if
applicable)
The above information is true, correct and accurate.
[Insert Proposer’s name]
By:
Name:
Title:
Texas Department of Transportation
SH 288 Toll Lanes Project in Harris County
December 18, 2014
______
-1-
Addendum #8 to Request for Proposals
Instructions to Proposers, Form B-1
FORM B-2
INFORMATION ABOUT PROPOSER ORGANIZATION
1.
Name of Proposer:
Name of Developer:
2.
Type of entity:
Proposer:
Developer:
3.
Proposer’s address:
Telephone
4.
Facsimile
How many years has Proposer, Developer and each Equity Member been in its current line of
business, and how many years has each entity been in business under its present name?
Name
5.
No. of years in business
No. of years under present
name
Under what other or former names have Proposer, Developer and Equity Members operated?
Proposer:
:
:
:
:
6.
Proposer shall review its QS previously submitted to TxDOT and list below any Key Personnel
and other key staff members and their relevant experience that have been approved by TxDOT
since the submission of the QS. Except as updated by the following information, Proposer’s QS is
hereby incorporated as if set forth in full and Proposer represents and warrants to TxDOT that the
information set forth in the QS, except as set forth herein, is true, complete and accurate in all
Texas Department of Transportation
SH 288 Toll Lanes Project in Harris County
December 18, 2014
-1-
Addendum #8 to Request for Proposals
Instructions to Proposers, Form B-2
respects and does not contain any misleading or incorrect information. Attach separate sheets if
necessary.
7.
List all Texas professional licenses held by Proposer, Developer and any Equity Members. Attach
copies of all Texas licenses. Attach a separate sheet if necessary.
8.
The Proposal shall include the following information regarding the Surety/Bonding companies
committing to provide the Payment and Performance Bonds in accordance with CDA Section
26.2:
(a) Name(s), address(es) and phone number(s) of the Surety(ies) that will provide the abovereferenced surety bonds (must be rated in the top two categories by two nationally
recognized rating agencies or at least A minus (A-) or better and Class VIII or better by
A.M. Best and Company, Inc.), and the name(s), address(es) and phone number(s) of the
designated agent(s).
(b) Whether or not each listed Surety has defaulted on any obligation within the past ten years,
and, if so, a description of the circumstances and the outcome of such default.
Texas Department of Transportation
SH 288 Toll Lanes Project in Harris County
December 18, 2014
-2-
Addendum #8 to Request for Proposals
Instructions to Proposers, Form B-2
STATE OF
)
)
)
COUNTY OF
Each of the undersigned, being first duly sworn, deposes and says that
is
the
of
and
is the
of
, which entity(ies) are
the
of
, the entity making the foregoing Proposal, and that the answers to the
foregoing questions and all other statements therein are true and correct.
(Signature)
(Signature)
(Name Printed)
(Name Printed)
(Title)
(Title)
Subscribed and sworn to before me this ____ day of __________, 2014.
____________________________________________
Notary Public in and for
said County and State
[Seal]
My commission expires:
Texas Department of Transportation
SH 288 Toll Lanes Project in Harris County
December 18, 2014
-3-
Addendum #8 to Request for Proposals
Instructions to Proposers, Form B-2
FORM B-3
INFORMATION ABOUT MAJOR PARTICIPANTS, MAJOR PROFESSIONAL SERVICES
FIRMS AND IDENTIFIED SUBCONTRACTORS
[This form will be used to provide information about any Major Participants (excluding Equity Members
that do not fall into categories (a) through (g) of the definition of Major Participants) and Major
Professional Services Firms and any other subcontractors that have been identified as of the Technical
Proposal Due Date.]
Proposer Name
Entity Name /
Contact
Address of Head
Office
Telephone / Fax
Specialty /
Assignment
Subcontractor
/ Major
Participant
Add additional sheet(s) as necessary.
The undersigned Proposer hereby certifies that it has not entered into any substantive negotiations with
Major Participants and/or Major Professional Services Firms resulting in an agreement to enter into any
Subcontracts with respect to the Project, except for those listed above. Proposer agrees that it will follow
applicable CDA requirements with respect to Subcontractors. Proposer further declares that it has
carefully examined the RFP Documents and acknowledges that TxDOT has determined that a Proposer’s
efforts to obtain participation by Subcontractors could reasonably be expected to produce 12% DBE
participation for the professional services and construction portions of the Work.
I declare under penalty of perjury under the laws of the State of Texas that the foregoing declaration is
true and correct.
Texas Department of Transportation
SH 288 Toll Lanes Project in Harris County
December 18, 2014
-1-
Addendum #8 to Request for Proposals
Instructions to Proposers, Form B-3
Executed:
, 2014.
____________________________________________
(Signature)
____________________________________________
(Name printed)
____________________________________________
(Title)
____________________________________________
(Signature)
____________________________________________
(Name printed)
____________________________________________
(Title)
____________________________________________
(Proposer)
Texas Department of Transportation
SH 288 Toll Lanes Project in Harris County
December 18, 2014
-2-
Addendum #8 to Request for Proposals
Instructions to Proposers, Form B-3
STATE OF
)
)
)
COUNTY OF
Each of the undersigned, being first duly sworn, deposes and says that
is
the
of
and
is the
of
, which entity(ies) are
the
of
, Proposer identified in the foregoing questionnaire, and that the answers
to the foregoing questions and all other statements therein are true and correct.
(Signature)
(Signature)
(Name Printed)
(Name Printed)
(Title)
(Title)
Subscribed and sworn to before me this ____ day of __________, 2014.
____________________________________________
Notary Public in and for
said County and State
[Seal]
My commission expires:
Texas Department of Transportation
SH 288 Toll Lanes Project in Harris County
December 18, 2014
-3-
Addendum #8 to Request for Proposals
Instructions to Proposers, Form B-3
FORM B-4
KEY CONTRACTORS
Name of Proposer:
List of Key Contractors by discipline or role:
Texas Department of Transportation
SH 288 Toll Lanes Project in Harris County
December 18, 2014
-1-
Addendum #8 to Request for Proposals
Instructions to Proposers, Form B-4
FORM C
RESPONSIBLE PROPOSER QUESTIONNAIRE
PROPOSER’S NAME:
NAME OF ENTITY ON WHOSE BEHALF FORM IS PROVIDED: _________________
1.
Questions
Proposer/Equity Member shall respond either “yes” or “no” to each of the following questions. If
the response is “yes” to any question(s), a detailed explanation of the circumstances shall be
provided in the space following the questions. Proposer/Equity Member shall attach additional
documentation as necessary to fully explain said circumstances. Failure to either respond to the
questions or provide adequate explanations may preclude consideration of the proposal and
require its rejection. For Proposer, the term “affiliate” shall mean Developer, any Equity Member
or any entity which owns a substantial interest in or is owned in common ownership with
Proposer, Developer or any Equity Member, or any such entity in which Proposer, Developer or
any Equity Member owns a substantial interest. For all other entities providing this form, the term
“affiliate” shall mean the entity signing the form, any entity which owns a substantial interest in
or is owned in common with the entity signing the form, or any entity in which the entity signing
the form owns a substantial interest.
Within the past ten years, has the identified entity, any affiliate, or any officer, director,
responsible managing officer or responsible managing employee of such entity or affiliate who
has a proprietary interest in such entity:
a)
Been disqualified, debarred, removed or otherwise prevented from bidding or proposing on
or completing a federal, state or local contract anywhere in the United States or any other
country because of a violation of law or safety regulation?
If yes, please explain the circumstances. If no, so state.
Yes _____ No _____
b)
Been convicted by a court of competent jurisdiction of any criminal charge of fraud, bribery,
collusion, conspiracy or any act in violation of state, federal or foreign antitrust law in
connection with the bidding or proposing upon, award of or performance of any public
works contract with any public entity?
If yes, please explain the circumstances. If no, so state.
Yes _____ No _____
c)
Had filed against it, him or her, any criminal complaint, indictment or information alleging
fraud, bribery, collusion, conspiracy or any action in violation of state or federal antitrust law
in connection with the bidding or proposing upon, award of or performance of any public
works contract with any public entity?
If yes, please explain the circumstances. If no, so state.
Texas Department of Transportation
SH 288 Toll Lanes Project in Harris County
December 18, 2014
-1-
Addendum #8 to Request for Proposals
Instructions to Proposers, Form C
Yes _____ No _____
d)
Had filed against it, him or her, any civil complaint (including but not limited to a crosscomplaint) or other claim arising out of a public works contract, alleging fraud, bribery,
collusion, conspiracy or any act in violation of state or federal antitrust law in connection
with the bidding or proposing upon, award of or performance of any public works contract
with any public entity?
Yes _____ No _____
e)
Been found, adjudicated or determined by any federal or state court or agency (including,
but not limited to, the Equal Employment Opportunity Commission, the Office of Federal
Contract Compliance Programs and any applicable Texas governmental agency) to have
violated any laws or Executive Orders relating to employment discrimination or affirmative
action, including but not limited to Title VII of the Civil Rights Act of 1964, as amended (42
U.S.C. Sections 2000e et seq.); the Equal Pay Act (29 U.S.C. Section 206(d)); and any
applicable or similar Texas law.
If yes, please explain the circumstances. If no, so state.
Yes _____ No _____
f)
Been found, adjudicated, or determined by any state court, state administrative agency,
including, but not limited to, the Texas Department of Labor (or its equivalent), federal court
or federal agency, to have violated or failed to comply with any law or regulation of the
United States or any state governing prevailing wages (including but not limited to payment
for health and welfare, pension, vacation, travel time, subsistence, apprenticeship or other
training, or other fringe benefits) or overtime compensation?
If yes, please explain the circumstances. If no, so state.
Yes _____ No _____
g)
Been convicted of violating a state or federal law respecting the employment of
undocumented aliens?
If yes, please explain the circumstances. If no, so state.
Yes _____ No _____
h)
Been assessed liquidated or other damages for failure to complete any contract on time?
If yes, please explain the circumstances. If no, so state.
Yes _____ No _____
Explain the circumstances underlying any “yes” answers for the aforementioned questions
on separate sheets attached hereto.
Texas Department of Transportation
SH 288 Toll Lanes Project in Harris County
December 18, 2014
-2-
Addendum #8 to Request for Proposals
Instructions to Proposers, Form C
2.
Verification / Declaration
I declare under penalty of perjury under the laws of the State of Texas that the foregoing
declaration is true, correct and accurate to the best of my knowledge following due inquiry.
Executed _______________, 2014.
____________________________________________
(Signature)
____________________________________________
(Name Printed)
____________________________________________
(Title)
____________________________________________
(Name of Organization)
[Evidence of signature authorization for such individual must be provided with the Proposal Letter]
Texas Department of Transportation
SH 288 Toll Lanes Project in Harris County
December 18, 2014
-3-
Addendum #8 to Request for Proposals
Instructions to Proposers, Form C
FORM D
PERSONNEL WORK ASSIGNMENT FORM
Name of Proposer:
Key Personnel Assignment
Name of Individual Assigned
Project Manager*
Financial Manager
Public Information Coordinator
Design Manager*
Superintendent or Construction Manager*
Lead Quality Manager*
Environmental Compliance Manager*
Safety Manager*
Operations Manager or O&M Manager*
Maintenance Manager or O&M Manager*
* Key Personnel position was previously identified in the RFQ.
Texas Department of Transportation
SH 288 Toll Lanes Project in Harris County
December 18, 2014
-1-
Addendum #8 to Request for Proposals
Instructions to Proposers, Form D
FORM E
NON-COLLUSION AFFIDAVIT
STATE OF
)
)
)
COUNTY OF
Each of the undersigned, being first duly sworn, deposes and says that:
A.
__________ is the __________ of __________ (the “Entity”) which entity is the __________ of
__________, the entity making the foregoing Proposal.
B.
The Proposal is not made in the interest of, or on behalf of, any undisclosed person, partnership,
company, association, organization, joint venture, limited liability company or corporation; the
Proposal is genuine and not collusive or a sham; Entity has not directly or indirectly induced or
solicited any other Proposer to put in a false or sham Proposal, and has not directly or indirectly
colluded, conspired, connived or agreed with any Proposer or anyone else to put in a sham
Proposal or that anyone shall refrain from proposing; Entity has not in any manner, directly or
indirectly, sought by agreement, communication or conference with anyone to fix the prices of
Proposer or any other Proposer, or to fix any overhead, profit or cost element included in the
Proposal, or of that of any other Proposer, or to secure any advantage against TxDOT or anyone
interested in the proposed agreement; all statements contained in the Proposal are true; and,
further, Entity has not, directly or indirectly, submitted its prices or any breakdown thereof, or the
contents thereof, or divulged information or data relative thereto, or paid, and will not pay, any
fee to any corporation, partnership, company, association, joint venture, limited liability
company, organization, Proposal depository or any member, partner, joint venture member or
agent thereof to effectuate a collusive or sham Proposal.
C.
Entity will not, directly or indirectly, divulge information or data regarding the price or other
terms of its Proposal to any other Proposer, or seek to obtain information or data regarding the
price or other terms of any other Proposal, until after award of the Agreement or rejection of all
Proposals and cancellation of the RFP.
(Signature)
(Signature)
(Name Printed)
(Name Printed)
(Title)
(Title)
Texas Department of Transportation
SH 288 Toll Lanes Project in Harris County
December 18, 2014
-1-
Addendum #8 to Request for Proposals
Instructions to Proposers, Form E
Subscribed and sworn to before me this _____ day of _______________, 2014.
____________________________________________
Notary Public in and for said County and State
[Seal]
My commission expires:______________.
[Duplicate or modify this form as necessary so that it accurately describes the entity submitting the
affidavit. Each member of the Proposer team shall submit an executed Form E.]
Texas Department of Transportation
SH 288 Toll Lanes Project in Harris County
December 18, 2014
-2-
Addendum #8 to Request for Proposals
Instructions to Proposers, Form E
FORM F
BUY AMERICA CERTIFICATION
(To be signed by authorized signatory(ies) of Developer)
The undersigned certifies on behalf of itself and all proposed subcontractors that only domestic steel and
iron will be used in the Project.
A. To be considered domestic, all steel and iron used and all products manufactured from steel and
iron must be produced in the United States and all manufacturing processes, including application
of a coating, for these materials must occur in the United States. Coating includes all processes
which protect or enhance the value of the material to which the coating is applied. This
requirement does not preclude a minimal use of foreign steel and iron materials, provided the cost
of such materials does not exceed 0.1% of the Price.
B. A false certification is a criminal act in violation of 18 U.S.C. 1001. Should this CDA be
investigated, Proposer has the burden of proof to establish that it is in compliance.
C. At Proposer’s request, TxDOT may, but is not obligated to, see a waiver of Buy American
requirements if grounds for the waiver exist. However, Proposer certifies that it will comply with
the applicable Buy American requirements if a waiver of those requirements is not available or
not pursued by TxDOT.
Date: _______________, 2014
____________________________________________
Signature
____________________________________________
Title
Texas Department of Transportation
SH 288 Toll Lanes Project in Harris County
December 18, 2014
-1-
Addendum #8 to Request for Proposals
Instructions to Proposers, Form F
FORM G
DBE CERTIFICATION
Control
Project
Highway
County
DISADVANTAGED BUSINESS ENTERPRISES
REQUIREMENTS
The following goal for participation by Disadvantaged Business
Enterprises is established for professional services and
construction work under the Comprehensive Development
Agreement (“CDA”):
DBE
12%
DBE Certification
By signing the Proposal, Proposer certifies that (1) the above
DBE goal will be met by obtaining commitments equal to or
exceeding the DBE percentage or that Developer will provide a
good faith effort to substantiate the attempt to meet the goal; and
(2) if awarded the CDA, Developer will submit a DBE
Performance Plan meeting the requirements set forth in the DBE
Special Provisions attached as Exhibit 13 to the CDA.
Failure to submit the DBE Performance Plan will be considered
a breach of the requirements of the RFP. As a result, the
Proposal Security provided by Proposer will become property of
the Department and Proposer will be precluded from
participating in any reprocurement of the CDA for the project.
____________________________________________
[name]
____________________________________________
[title]
Texas Department of Transportation
SH 288 Toll Lanes Project in Harris County
December 18, 2014
-1-
Addendum #8 to Request for Proposals
Instructions to Proposers, Form G
FORM H
CHILD SUPPORT STATEMENT FOR
STATE GRANTS, LOANS AND CONTRACTS
Under Section 231.006, Family Code, the vendor or applicant certifies that the individual
or business entity named in this contract, bid, or application is eligible to receive the
specified grant, loan, or payment and acknowledges that this contract may be terminated
and payment may be withheld if this certification is inaccurate.
Proposer Name: ________________
List below the name and social security number of the individual or sole proprietor and each partner,
shareholder or owner with an ownership interest of at least 25% of the entity identified below.
Section 231.006, Family Code, specifies that a child support obligor who is more than 30 days delinquent
in paying child support and a business entity in which the obligor is a sole proprietor, partner,
shareholder, or owner with an ownership interest of at least 25 percent is not eligible to receive payments
from state funds under a contract to provide property, materials, or services; or receive a state-funded
grant or loan.
A child support obligor or business entity ineligible to receive payments described above remains
ineligible until all arrearage have been paid or the obligor is in compliance with a written repayment
agreement or court order as to any existing delinquency.
Except as provided by Section 231.302(d), Family Code, a social security number is confidential and may
be disclosed only for the purposes of responding to a request for information from an agency operating
under the provisions of Parts A and D of Title IV of the federal Social Security Act (42 U.S.C. Section
601-617 and 651-669).
Date: _______________, 2014
Company Name:
Signature
Title
[Duplicate or modify this form as necessary so that it accurately describes the entity making the Proposal
and so that it is signed on behalf of Proposer and each Major Participant.]
Texas Department of Transportation
SH 288 Toll Lanes Project in Harris County
December 18, 2014
-1-
Addendum #8 to Request for Proposals
Instructions to Proposers, Form H
FORM I
CONFLICT OF INTEREST DISCLOSURE STATEMENT
Proposer’s attention is directed to 23 CFR Part 636 Subpart A and in particular to Subsection 636.116
regarding organizational conflicts of interest. Section 636.103 defines “organizational conflict of interest”
as follows:
Organizational conflict of interest means that because of other activities or relationships with
other persons, a person is unable or potentially unable to render impartial assistance or advice to
the owner, or the person’s objectivity in performing the contract work is or might be otherwise
impaired, or a person has an unfair competitive advantage.
Proposers are advised that in accordance with TxDOT’s Conflicts of Interest Policy, certain firms will not
be allowed to participate on any Proposer’s team for the Project because of their work with TxDOT in
connection with the Project procurement and document preparation and the CDA program.
1.
Disclosure Pursuant to Section 636.116(2)(v)
In the space provided below, and on supplemental sheets as necessary, identify all relevant facts
relating to past, present or planned interest(s) of Proposer’s team (including Proposer, Developer,
the Major Participants, proposed consultants and proposed subcontractors and their respective
chief executives, directors and key project personnel) which may result, or could be viewed as, an
organizational conflict of interest in connection with this RFP.
Proposer should disclose (a) any current contractual relationships with TxDOT, (b) any past,
present or planned contractual or employment relationships with any TxDOT member, officer or
employee; and (c) any other circumstances that might be considered to create a financial interest
in the contract by any TxDOT member, officer or employee if Proposer is awarded the contract.
Proposer should also disclose matters such as ownership of 10% or more of the stock of, or
having directors in common with, any of the RFP preparers. Proposer should also disclose
contractual relationships with an RFP preparer in the nature of a joint venture, as well as
relationships wherein the RFP preparer is a contractor or consultant (or subcontractor or
subconsultant) to Proposer or a member of Proposer’s team. The foregoing is provided by way of
example, and shall not constitute a limitation on the disclosure obligations.
Texas Department of Transportation
SH 288 Toll Lanes Project in Harris County
December 18, 2014
-1-
Addendum #8 to Request for Proposals
Instructions to Proposers, Form I
2.
Explanation
In the space provided below, and on supplemental sheets as necessary, identify steps that have
been or will be taken to avoid, neutralize, or mitigate any organizational conflicts of interest
described herein.
3.
Certification
The undersigned hereby certifies that, to the best of his or her knowledge and belief, no interest
exists that is required to be disclosed in this Conflict of Interest Disclosure Statement, other than
as disclosed above.
Signature
Name
Title
Company Name
, 2014
Date
Texas Department of Transportation
SH 288 Toll Lanes Project in Harris County
December 18, 2014
-2-
Addendum #8 to Request for Proposals
Instructions to Proposers, Form I
FORM J-1
PRICE PROPOSAL
Proposer Name:
Provide the Concession Payment in nominal U.S. dollars, rounded to the nearest dollar, in Box 1(a),
payable pursuant to the terms set forth in Section 4.1 of the CDA. Provide the net present value of such
Concession Payment as of the Financial Proposal Due Date, calculated at a 5% discount rate assuming a
Financial Close Date of 300 days after the Financial Proposal Due Date, in Box 1(b). See Exhibit C,
Section 7 for additional explanation and requirements. If Public Funds Payments are required, indicate $0
for the Concession Payment (or an equivalent expression).
Box 1
(a) Concession Payment
$____________
(b) Net Present Value of
Concession Payment
$____________
Provide any Public Funds Payments that are required, each in nominal U.S. dollars, rounded to the nearest
dollar, in Box 2, payable pursuant to the terms set forth in Section 4.6 of the CDA. Such payments should
be indicated as negative numbers. Also provide the net present value of such payments, calculated at a 5%
discount rate as of the Financial Proposal Due Date, in Box 3. See Exhibit C, Section 7 for additional
explanation and requirements. Multiple Public Funds Payments may be requested; provided, however that
the last date for payment must be no later than the date of Substantial Completion for the last Project
Segment. Include as many rows as necessary to reflect the number of Public Funds Payments required.
Do not include the TMC Public Funds Payment in the chart. If no such payments are required, indicate so
by listing “None” (or an equivalent expression).
Box 2
Public Funds Payment
Payable Not Prior To
[Insert amount of payment]
$____________
[Insert amount of payment]
[Insert earliest payment date]
____ months after NTP2
[Insert payment date]
Box 3
Net Present Value of Public
Funds Payments
Texas Department of Transportation
SH 288 Toll Lanes Project in Harris County
December 18, 2014
– $____________
-1-
Addendum #8 to Request for Proposals
Instructions to Proposers, Form J-1
FORM J-2
PRICE PROPOSAL
(ALLOCATION OF REVENUE PAYMENT FOR FEDERAL INCOME TAX)
Proposer Name:
Provide the allocation of Revenue Payment between the right to toll Toll Lanes and rent for the Project
Right of Way in Box 1. Such allocation will be included in Section 4.2.3 of the CDA.
Box 1
Right to toll the Toll Lanes
___%
Rent for the Project
Right of Way
___%
Texas Department of Transportation
SH 288 Toll Lanes Project in Harris County
December 18, 2014
-1-
Addendum #8 to Request for Proposals
Instructions to Proposers, Form J-2
FORM J-3
PRICE PROPOSAL
(GENERAL PURPOSE LANE CAPACITY IMPROVEMENT PAYMENTS)
Table A
GPLCI Payment: Component A
Component A
The initial lump-sum, fixed-price amount for the
GPLCI Design-Build Contract, which amount is
subject to adjustment pursuant to Section 25.1.7(c)
of the CDA
Amount
Table B
GPLCI Payment: Component B
Component B
Texas Department of Transportation
SH 288 Toll Lanes Project in Harris County
December 18, 2014
Amount
-1-
Addendum #8 to Request for Proposals
Instructions to Proposers, Form J-3
FORM K-1
PROPOSAL BOND
Bond No. ______
STATED EXPIRATION DATE: August 28, 2015 [Note: This date is 220 days after the Financial
Proposal Due Date.]
KNOW ALL PERSONS BY THESE PRESENTS, that the _______________ [NOTE: insert
name of Proposer as the Principal and delete this bracketed text], as Principal and _______________,
as Surety or as Co-Sureties, each a corporation duly organized under the laws of the State indicated on the
attached page, having its principal place of business at the address listed on the attached page, in the State
indicated on the attached page, and authorized as a surety in the State of Texas, are hereby jointly and
severally held and firmly bound unto the Texas Department of Transportation (“TxDOT”), in the sum of
$10,000,000 (the “Bonded Sum”).
WHEREAS, the Principal is herewith submitting its Proposal for furnishing the development,
design and construction of the TxDOT SH 288 Toll Lanes Project in Harris County, which Proposal is
incorporated herein by this reference and has been submitted pursuant to TxDOT’s Request for Proposals
dated as of _________ (as amended or supplemented, the “RFP”), in accordance with the Instructions to
Proposers thereto (“ITP”) included in the RFP, to develop, design, construct, finance, operate and
maintain the TxDOT SH 288 Toll Lanes Project in Harris County through a Comprehensive Development
Agreement (the “CDA”);
NOW, THEREFORE,
1.
The condition of this Proposal Bond is such that, upon occurrence of any of the following
events, then this obligation shall be null and void; otherwise it shall remain in full force and effect, and
the Bonded Sum will be forfeited to TxDOT as liquidated damages and not as a penalty, upon receipt by
Principal and Surety or by Principal and Sureties listed on the attached page (the “Co-Sureties”) of notice
of such forfeiture by TxDOT:
(a)
Principal's receipt of written notice from TxDOT that either (i) no CDA for the
Project will be awarded by TxDOT pursuant to the RFP, or (ii) TxDOT has awarded the CDA for the
Project, has received the executed CDA and other required documents, and does not intend to award the
CDA to Principal; or
(b)
If TxDOT has not previously delivered notice of forfeiture hereunder, failure of
TxDOT to conditionally award the CDA to Principal within 210 days (or 270 days if TxDOT has
extended the 210 day period to 270 days pursuant to the terms of the ITP) after the Financial Proposal
Due Date.
2.
The Principal agrees to pay to TxDOT the full Bonded Sum hereinabove set forth, as
liquidated damages and not as a penalty, within ten days after occurrence of any of the following events:
(a)
Principal withdraws all or any part of its Proposal prior to 210 days following the
Financial Proposal Due Date, without TxDOT’s consent, except as specifically permitted in the ITP; or
Texas Department of Transportation
SH 288 Toll Lanes Project in Harris County
December 18, 2014
-1-
Addendum #8 to Request for Proposals
Instructions to Proposers, Form K-1
(b)
Principal is selected for negotiations and fails to engage in good faith
negotiations with TxDOT as set forth in ITP Section 5.11.1 or fails to deliver Closing Security as set forth
in ITP Section 5.12.2(c); or
(c)
Principal withdraws, repudiates or otherwise indicates in writing that it will not
meet all or any part of its commitments made in its Proposal prior to the time allowed for execution of the
CDA under the ITP without TxDOT’s consent (after receiving Conditional Award).
Principal agrees and acknowledges that such liquidated damages are reasonable in order to
compensate TxDOT for damages it will incur as a result of Principal’s failure to satisfy the obligations
under the RFP to which Principal agreed when submitting its Proposal. Such damages include potential
harm to the credibility and reputation of TxDOT’s transportation improvement program, including the
CDA program, with policy makers and with the general public, delays to the Project and additional costs
of administering this or a new procurement (including engineering, legal, accounting, overhead and other
administrative costs). Principal further acknowledges that these damages would be difficult and
impracticable to measure and prove, are incapable of accurate measurement because of, among other
things, the unique nature of the Project and the efforts required to receive and evaluate proposals for it,
and the unavailability of a substitute for those efforts. The amounts of liquidated damages stated herein
represent good faith estimates and evaluations as to the actual potential damages that TxDOT would incur
as a result of Principal’s failure to satisfy the obligations under the RFP to which Principal agreed when
submitting its Proposal and do not constitute a penalty. Principal agrees to such liquidated damages in
order to fix and limit Principal’s costs and to avoid later Disputes over what amounts of damages are
properly chargeable to Principal.
3.
The following terms and conditions shall apply with respect to this Proposal Bond:
(a)
The ITP is incorporated by reference herein. Capitalized terms not separately
defined herein have the meanings assigned such terms in the ITP.
(b)
This Proposal Bond shall not be subject to forfeiture in the event that TxDOT
disqualifies the Proposal based on a determination that it is non-responsive or non-compliant.
(c)
If suit is brought on this Proposal Bond by TxDOT and judgment is recovered,
Principal and Surety or Co-Sureties shall pay all costs incurred by TxDOT in bringing such suit,
including, without limitation, reasonable attorneys’ fees and costs as determined by the court.
(d)
Any extension(s) of the time for award of the CDA that Principal may grant in
accordance with the CDA or otherwise, shall be subject to the reasonable approval of Surety or CoSureties.
(e)
Correspondence or claims relating to this Proposal Bond should be sent to Surety
at the following address:
Texas Department of Transportation
SH 288 Toll Lanes Project in Harris County
December 18, 2014
-2-
Addendum #8 to Request for Proposals
Instructions to Proposers, Form K-1
SIGNED and SEALED this __________ day of ____________________, 2014
____________________________________________
Principal
By: _________________________________________
____________________________________________
Co-Surety
By: _________________________________________
Attorney in Fact
By: _________________________________________
____________________________________________
Co-Surety
By: _________________________________________
Attorney in Fact
By: _________________________________________
Co-Surety
By: _________________________________________
Attorney in Fact
[ADD APPROPRIATE SURETY ACKNOWLEDGMENTS]
Texas Department of Transportation
SH 288 Toll Lanes Project in Harris County
December 18, 2014
-3-
Addendum #8 to Request for Proposals
Instructions to Proposers, Form K-1
CO-SURETIES
SURETY NAME
Texas Department of Transportation
SH 288 Toll Lanes Project in Harris County
December 18, 2014
SURETY ADDRESS
-4-
INCORPORATED IN
Addendum #8 to Request for Proposals
Instructions to Proposers, Form K-1
FORM K-2
PROPOSAL LETTER OF CREDIT
IRREVOCABLE STANDBY LETTER OF CREDIT
ISSUER:
PLACE FOR PRESENTATION OF DRAFT: [Name and Address of Bank/Branch]
APPLICANT:
BENEFICIARY:
Texas Department of Transportation
7600 Chevy Chase Drive,
Building 2, 4th Floor,
Austin, Texas 78752
LETTER OF CREDIT NUMBER:
PLACE AND DATE OF ISSUE:
AMOUNT: $10,000,000
STATED EXPIRATION DATE: August 28, 2015 [Note: This date is 220 days after the Financial
Proposal Due Date.]
The Issuer hereby issues this Irrevocable Standby Letter of Credit in favor of TxDOT, for the amount of
$10,000,000, available by draft at sight drawn on the Issuer. Any draft under this Credit shall be in the
amount of $10,000,000 and shall:
1.
Identify this Irrevocable Standby Letter of Credit by the name of the Issuer, and the Letter of
Credit number, amount, and place and date of issue; and
2.
Be accompanied by the Beneficiary’s signed and dated statement stating one of the following:
(a) “This drawing is due to
_______________’s withdrawal of all or any part of its Proposal
prior to 210 days following the Financial Proposal Due Date, without TxDOT’s consent,
except as specifically permitted under the ITP.”
or
(b) “This drawing is due to _____________’s failure to engage in good faith negotiations with
TxDOT as set forth in ITP Section 5.11.1 or _________’s failure to deliver Closing
Security as required by ITP Section 5.12.2(c).”
or
(c) “This drawing is due to
_______________’s withdrawal, repudiation or other indication
that it will not meet any commitments made in its Proposal prior to the time allowed for
TxDOT’s execution of the CDA (after receiving Conditional Award).”
Texas Department of Transportation
SH 288 Toll Lanes Project in Harris County
December 18, 2014
-1-
Addendum #8 to Request for Proposals
Instructions to Proposers, Form K-2
All drafts will be honored if presented to
(Bank/Branch - Name & Address)
on or before the Stated Expiration Date described above.
If a Demand for Payment is made by you hereunder at or prior to 10:00 a.m., central time, on any
weekday (i.e., Monday through Friday, excluding Texas state holidays and U.S. federal holidays (a
“Business Day”), and provided that such Demand for Payment conforms to the terms and conditions
hereof, payment shall be made by us to you in immediately available funds free and clear of and without
deduction for any taxes, duties, fees, liens, set-offs or other deductions of any kind and regardless of any
objection by any third party (subject to any court order or judgment), to the account designated below or
such other account at a national bank in the United States of America that you may designate in the
Demand for Payment on the next Business Day after demand is made. If a Demand for Payment is made
by you hereunder after 10:00 a.m., central time, on a Business Day, and provided that such Demand for
Payment conforms to the terms and conditions hereof, such payment shall be made no later than the close
of business, local time of the location of the account designated below or such other account at a national
bank in the United States of America that you may designate in the Demand for Payment, on the second
Business Day after demand is made. Payment under this Letter of Credit shall be made in same day funds,
by wire transfer to your account described below or such other account as you may designate in writing.
Financial Institution:
Routing Number:
Account Name:
Account Number to Credit:
Reference:
Attention:
All bank charges and commissions incurred in connection with the issuance, administration, advisement,
confirmation, negotiation or any other fees associated with this Letter of Credit (including any drawings
hereunder) shall be for the account of the applicant.
The Instructions to Proposers (the “ITP”) is incorporated by reference herein. Capitalized terms not
separately defined herein have the meanings assigned such terms in the ITP. For the avoidance of doubt,
any reference to the ITP within this Letter of Credit is for informational purposes and in no way obligates
[name of issuing bank] in accordance with the ITP terms nor is the document to be examined for
compliance purposes.
Except so far as otherwise expressly stated, this Letter of Credit is subject to the International Standby
Practices (“ISP98”), International Chamber of Commerce Publication No. 590 (the “Uniform Customs”),
which shall in all respects be deemed a part hereof as fully as if incorporated herein except as modified
hereby.
This Letter of Credit is issued under the laws of the State of Texas and applicable U.S. federal law, and
shall, as to matters not governed by Uniform Customs, be governed by and construed in accordance with
the laws of the State of Texas, including the Uniform Commercial Code, Chapter 5, Texas Business and
Commerce Code, without regard to principles of conflicts of law.
Any failure by you to draw upon this Letter of Credit as permitted hereunder shall not cause this Letter of
Credit to be unavailable for any future drawing, provided that this Letter of Credit has not expired prior to
such future drawing and that all requirements of this Letter of Credit are independently satisfied with
respect to any such future drawing.
Texas Department of Transportation
SH 288 Toll Lanes Project in Harris County
December 18, 2014
-2-
Addendum #8 to Request for Proposals
Instructions to Proposers, Form K-2
If legal proceedings are initiated by any party with respect to payment of the Letter of Credit, we agree
that such proceeding shall be subject to Texas courts and law.
Communications with respect to this Letter of Credit shall be in writing and shall be addressed to us at
____________________________________________________________,
Attention:
_________________________, specifically referring to the number of this Letter of Credit.
Issuer:
By:
(Authorized signature of Issuer)
FORM K-3
CLOSING BOND
Bond No. ______
STATED EXPIRATION DATE: November 26, 2015 [Note: This date is ten days after the Financial
Close Deadline]
KNOW ALL PERSONS BY THESE PRESENTS, that the _______________ [NOTE: insert
name of Proposer as the Principal and delete this bracketed text], as Principal and _______________,
as Surety or as Co-Sureties, each a corporation duly organized under the laws of the State indicated on the
attached page, having its principal place of business at the address listed on the attached page, in the State
indicated on the attached page, and authorized as a surety in the State of Texas, are hereby jointly and
severally held and firmly bound unto the Texas Department of Transportation (“TxDOT”), in the sum of
$30,000,000 (the “Bonded Sum”).
WHEREAS, the Principal has submitted its Proposal for furnishing the development, design and
construction of the TxDOT SH 288 Toll Lanes Project in Harris County, which Proposal is incorporated
herein by this reference and has been submitted pursuant to TxDOT’s Request for Proposals dated as of
January 31, 2014 (as amended or supplemented, the “RFP”), in accordance with the Instructions to
Proposers thereto (“ITP”) included in the RFP, to develop, design, construct, finance, operate and
maintain the TxDOT SH 288 Toll Lanes Project in Harris County through a Comprehensive Development
Agreement (the “CDA”);
WHEREAS, the Principal was selected as the preferred Proposer to enter into the CDA;
NOW, THEREFORE,
1.
The Principal agrees to pay to TxDOT the full Bonded Sum hereinabove set forth, as
liquidated damages and not as a penalty, within ten days of any of the following events:
(a)
After receiving Conditional Award, Principal fails to execute and deliver to TxDOT the
CDA and all other documents required under ITP Section 6.1 by the deadline set forth in ITP Section
1.6.2, without excuse under ITP Section 4.8.2; or
Texas Department of Transportation
SH 288 Toll Lanes Project in Harris County
December 18, 2014
-3-
Addendum #8 to Request for Proposals
Instructions to Proposers, Form K-2
(b)
Principal’s withdrawal of all or any part of its Proposal prior to 210 days following the
Financial Proposal Due Date, without TxDOT’s consent, except as specifically permitted in the ITP; or
(c)
Principal is selected for negotiations and fails to engage in good faith negotiations with
TxDOT as set forth in ITP Section 5.11.1; or
(d)
Principal withdraws, repudiates or otherwise indicates in writing that it will not meet all
or any part of its commitments made in its Proposal prior to the time allowed for execution of the CDA
under the ITP without TxDOT’s consent (after receiving Conditional Award); or
(e)
Principal’s failure to achieve Financial Close by the deadline set forth in ITP Section
1.6.3 (unless such failure is directly attributable to an event set forth in Section 3.4.2 of the CDA) and, if
applicable, pay the Concession Payment, in accordance with the requirements of the CDA and the ITP.
Principal agrees and acknowledges that such liquidated damages are reasonable in order to
compensate TxDOT for damages it will incur as a result of Principal’s failure to satisfy the obligations
under the RFP to which Principal agreed when submitting its Proposal. Such damages include potential
harm to the credibility and reputation of TxDOT’s transportation improvement program, including the
CDA program, with policy makers and with the general public, delays to the Project and additional costs
of administering this or a new procurement (including engineering, legal, accounting, overhead and other
administrative costs). Principal further acknowledges that these damages would be difficult and
impracticable to measure and prove, are incapable of accurate measurement because of, among other
things, the unique nature of the Project and the efforts required to receive and evaluate proposals for it,
and the unavailability of a substitute for those efforts. The amounts of liquidated damages stated herein
represent good faith estimates and evaluations as to the actual potential damages that TxDOT would incur
as a result of Principal’s failure to satisfy the obligations under the RFP to which Principal agreed when
submitting its Proposal and do not constitute a penalty. Principal agrees to such liquidated damages in
order to fix and limit Principal’s costs and to avoid later Disputes over what amounts of damages are
properly chargeable to Principal.
2.
The following terms and conditions shall apply with respect to this Closing Bond:
(a)
The ITP is incorporated by reference herein. Capitalized terms not separately
defined herein have the meanings assigned such terms in the ITP.
(b)
If suit is brought on this Closing Bond by TxDOT and judgment is recovered,
Principal and Surety or Co-Sureties shall pay all costs incurred by TxDOT in bringing such suit,
including, without limitation, reasonable attorneys’ fees and costs as determined by the court.
(c)
Correspondence or claims relating to this Closing Bond should be sent to Surety
at the following address:
Texas Department of Transportation
SH 288 Toll Lanes Project in Harris County
-2-
Addendum #8 to Request for Proposals
Instructions to Proposers, Form K-3
SIGNED and SEALED this __________ day of ____________________, 2014
____________________________________________
Principal
By: _________________________________________
____________________________________________
Co-Surety
By: _________________________________________
Attorney in Fact
By: _________________________________________
____________________________________________
Co-Surety
By: _________________________________________
Attorney in Fact
By: _________________________________________
Co-Surety
By: _________________________________________
Attorney in Fact
[ADD APPROPRIATE SURETY ACKNOWLEDGMENTS]CO-SURETIES
SURETY NAME
Texas Department of Transportation
SH 288 Toll Lanes Project in Harris County
SURETY ADDRESS
-3-
INCORPORATED IN
Addendum #8 to Request for Proposals
Instructions to Proposers, Form K-3
FORM K-4
CLOSING LETTER OF CREDIT
IRREVOCABLE STANDBY LETTER OF CREDIT
ISSUER:
PLACE FOR PRESENTATION OF DRAFT: [Name and Address of Bank/Branch] APPLICANT:
BENEFICIARY:
Texas Department of Transportation
7600 Chevy Chase Drive,
Building 2, 4th Floor,
Austin, Texas 78752
LETTER OF CREDIT NUMBER:
PLACE AND DATE OF ISSUE:
AMOUNT: $30,000,000
STATED EXPIRATION DATE: November 26, 2015 [Note: This date is ten days after the Financial
Close Deadline]
The Issuer hereby issues this Irrevocable Standby Letter of Credit in favor of TxDOT, for the amount of
$30,000,000, available by draft at sight drawn on the Issuer. Any draft under this Letter of Credit shall be
in the amount of $30,000,000 and shall:
1.
Identify this Irrevocable Standby Letter of Credit by the name of the Issuer, and the Letter of
Credit number, amount, and place and date of issue; and
2.
Be accompanied by the Beneficiary’s signed and dated statement stating one of the following:
(a) “This drawing is due to
_______________’s withdrawal of all or any part of its Proposal
prior to 210 days following the Financial Proposal Due Date, without TxDOT’s consent,
except as specifically permitted under the ITP.”
or
(b) “This drawing is due to _____________’s failure to engage in good faith negotiations with
TxDOT as set forth in ITP Section 5.11.1.”
or
(c) “This drawing is due to
_______________’s withdrawal, repudiation or other indication
that it will not meet any commitments made in its Proposal prior to the time allowed for
TxDOT’s execution of the CDA (after receiving Conditional Award).”
or
(d) “This drawing is due to
_______________’s failure, after Conditional Award, to execute
and deliver to TxDOT the CDA and all other documents required under ITP Section 6.1 by
the deadline set forth in ITP Section 1.6.2, without excuse under ITP Section 4.8.2.”
Texas Department of Transportation
SH 288 Toll Lanes Project in Harris County
December 18, 2014
-1-
Addendum #8 to Request for Proposals
Instructions to Proposers, Form K-4
or
(e) “This drawing is due to
_______________’s failure to achieve Financial Close by the
deadline set forth in ITP Section 1.6.3 (unless such failure is directly attributable to an event
set forth in CDA Section 3.4.2) and, if applicable, pay the Concession Payment, in
accordance with the requirements of the CDA and the ITP.”
All drafts will be honored if presented to
(Bank/Branch - Name & Address)
on or before the Stated Expiration Date described above.
If a Demand for Payment is made by you hereunder at or prior to 10:00 a.m., central time, on any
weekday (i.e., Monday through Friday, excluding Texas state holidays and U.S. federal holidays) (a
“Business Day”), and provided that such Demand for Payment conforms to the terms and conditions
hereof, payment shall be made by us to you in immediately available funds free and clear of and without
deduction for any taxes, duties, fees, liens, set-offs or other deductions of any kind and regardless of any
objection by any third party (subject to any court order or judgment), to the account designated below or
such other account at a national bank in the United States of America that you may designate in the
Demand for Payment on the next Business Day after demand is made. If a Demand for Payment is made
by you hereunder after 10:00 a.m., central time, on a Business Day, and provided that such Demand for
Payment conforms to the terms and conditions hereof, such payment shall be made no later than the close
of business, local time of the location of the account designated below or such other account at a national
bank in the United States of America that you may designate in the Demand for Payment, on the second
Business Day after demand is made. Payment under this Letter of Credit shall be made in same day funds,
by wire transfer to your account described below or such other account as you may designate in writing.
Financial Institution:
Routing Number:
Account Name:
Account Number to Credit:
Reference:
Attention:
All bank charges and commissions incurred in connection with the issuance, administration, advisement,
confirmation, negotiation or any other fees associated with this Letter of Credit (including any drawings
hereunder) shall be for the account of the applicant.
The Instructions to Proposers (the “ITP”) is incorporated by reference herein. Capitalized terms not
separately defined herein have the meanings assigned such terms in the ITP. For the avoidance of doubt,
any reference to the ITP within this Letter of Credit is for informational purposes and in no way obligates
[name of issuing bank] in accordance with the ITP terms nor is the document to be examined for
compliance purposes.
Except so far as otherwise expressly stated, this Letter of Credit is subject to the International Standby
Practices (“ISP98”), International Chamber of Commerce Publication No. 590 (the “Uniform Customs”),
which shall in all respects be deemed a part hereof as fully as if incorporated herein except as modified
hereby.
This Letter of Credit is issued under the laws of the State of Texas and applicable U.S. federal law, and
shall, as to matters not governed by Uniform Customs, be governed by and construed in accordance with
the laws of the State of Texas, including the Uniform Commercial Code, Chapter 5, Texas Business and
Commerce Code, without regard to principles of conflicts of law.
Texas Department of Transportation
SH 288 Toll Lanes Project in Harris County
December 18, 2014
-2-
Addendum #8 to Request for Proposals
Instructions to Proposers, Form K-4
Any failure by you to draw upon this Letter of Credit as permitted hereunder shall not cause this Letter of
Credit to be unavailable for any future drawing, provided that this Letter of Credit has not expired prior to
such future drawing and that all requirements of this Letter of Credit are independently satisfied with
respect to any such future drawing.
If legal proceedings are initiated by any party with respect to payment of the Letter of Credit, we agree
that such proceeding shall be subject to Texas courts and law.
Communications with respect to this Letter of Credit shall be in writing and shall be addressed to us at
____________________________________________________________,
Attention:
_________________________, specifically referring to the number of this Letter of Credit.
Issuer:
By:
(Authorized signature of Issuer)
Texas Department of Transportation
SH 288 Toll Lanes Project in Harris County
December 18, 2014
-3-
Addendum #8 to Request for Proposals
Instructions to Proposers, Form K-4
FORM L
OPINION OF COUNSEL
[LETTERHEAD OF INDEPENDENT LAW FIRM OR IN-HOUSE COUNSEL – SEE SECTION
6.1.2(b) OF THE ITP FOR LEGAL COUNSEL REQUIREMENTS]
Texas Department of Transportation
7600 Chevy Chase Drive
Building 2, Suite 400
Austin, Texas 78752
Re:
Comprehensive Development Agreement (“CDA”) for TxDOT SH 288 Toll Lanes Project in
Harris County dated as of __________, 201_, by and between Texas Department of Transportation, and
__________________ (the “Developer”)
Gentlemen:
[Describe relationship to Developer and its joint venture members, general partners, members, as
applicable, and any other entities whose approval is required in order to authorize delivery of the proposal
and execution of the CDA.] This letter is provided to you pursuant to Section 6.1.3(b) of the Instructions
to Proposers of that certain Request for Proposals issued by the Texas Department of Transportation
(“TxDOT”) on _______________, as amended.
In giving this opinion, we have examined __________________________________. We have also
considered such questions of law and we have examined such documents and instruments and certificates
of public officials and individuals who participated in the procurement process as we have deemed
necessary or advisable. [if certificate used/obtained from Developer or Guarantor, such certificate should
also run in favor of TxDOT and should be attached to opinion]
In giving this opinion, we have assumed that all items submitted to us or reviewed by us are genuine,
accurate and complete, and if not originals, are true and correct copies of originals, and that all signatures
on such items are genuine.
Subject to the foregoing, we are of the opinion that:
1.
[opinion regarding organization/formation and existence of Developer and that
Developer has corporate power to own its properties and assets, carry on its business, make the Proposal,
enter into the CDA and to perform its obligations under the CDA;] [if Developer is a partnership/joint
venture, these opinions are also required for each of its joint venture members and general partners]
2.
[opinion regarding good standing and qualification to do business in State of
Texas for Developer;] [if Developer is a partnership/joint venture, these opinions are also required for
each of its joint venture members and general partners]
3.
[opinion regarding organization/formation and existence of Guarantor and that
Guarantor has corporate power to own its properties and assets, to carry on its business, to enter into the
Guaranty and to perform its obligations under the Guaranty;] [if Guarantor is a partnership/joint venture,
these opinions are also required for each of its joint venture members and general partners] [if there is no
Guaranty, this opinion may be omitted]
Texas Department of Transportation
SH 288 Toll Lanes Project in Harris County
December 18, 2014
-1-
Addendum #8 to Request for Proposals
Instructions to Proposers, Form L
4.
[opinion that Proposal and CDA have been duly authorized by all necessary
corporate action on the part of Developer and the Proposal and CDA have been duly executed and
delivered by Developer;] [if Developer is a partnership/joint venture, add: and its joint venture
members/general partners after the first and second “Developer”]
5.
[opinion that Guaranty has been duly authorized by all necessary corporate action
on the part of Guarantor and the Guaranty has been duly executed and delivered by Guarantor;] [if
Guarantor is a partnership/joint venture, add: and its joint venture members/general partners after the first
and second “Guarantor”] [if there is no Guaranty, this opinion may be omitted]
6.
[opinion that the CDA constitutes a legal, valid and binding obligation of
Developer enforceable against Developer in accordance with its terms;] [if Developer is a
partnership/joint venture, add: and its joint venture members/general partners after the second
“Developer”]
7.
[opinion that the Guaranty constitutes a legal, valid and binding obligation of the
Guarantor enforceable against the Guarantor in accordance with its terms;] [if Guarantor is a
partnership/joint venture, add: and its joint venture members/general partners after the second
“Guarantor”] [if there is no Guaranty, this opinion may be omitted]
8.
[opinion that all required approvals have been obtained with respect to execution,
delivery and performance of the Proposal and the CDA; and that neither the Proposal nor the CDA
conflict with any agreements to which Developer is a party [if Developer is a partnership/joint venture,
add: and its joint venture members/general partners are a party] or with any orders, judgments or decrees
by which Developer is bound;] [if Developer is a partnership/joint venture, add: and its joint venture
members/general partners are bound]
9.
[opinion that all required approvals have been obtained with respect to execution,
delivery and performance of the Guaranty; and that the Guaranty does not conflict with any agreements to
which Guarantor is a party [if Guarantor is a partnership/joint venture, add: and its joint venture
members/general partners are a party] or with any orders, judgments or decrees by which Guarantor is
bound;] [if Guarantor is a partnership/joint venture, add: and its joint venture members/general partners
are bound] [if there is no Guaranty, this opinion may be omitted]
10.
[opinion that execution, delivery and performance of all obligations by
Developer under the Proposal and the CDA do not conflict with, and are authorized by, the articles of
incorporation and bylaws of Developer;] [if Developer is a partnership, replace articles of incorporation
and bylaws with partnership agreement and (if applicable) certificate of limited partnership); if Developer
is a joint venture, replace articles of incorporation and bylaws with joint venture agreement; if Developer
is a limited liability company, replace articles of incorporation and bylaws with operating agreement and
certificate of formation]
11.
[opinion that execution, delivery and performance of all obligations by Guarantor
under the Guaranty does not conflict with, and is authorized by, the articles of incorporation and bylaws
of Guarantor;] [if Guarantor is a partnership, replace articles of incorporation and bylaws with partnership
agreement and (if applicable) certificate of limited partnership); if Guarantor is a joint venture, replace
articles of incorporation and bylaws with joint venture agreement; if Guarantor is a limited liability
company, replace articles of incorporation and bylaws with operating agreement and certificate of
formation] [if there is no Guaranty, this opinion may be omitted]
Texas Department of Transportation
SH 288 Toll Lanes Project in Harris County
December 18, 2014
-2-
Addendum #8 to Request for Proposals
Instructions to Proposers, Form L
12.
[opinion that execution and delivery by Developer of the Proposal and the CDA
do not, and Developer’s performance of its obligations under the Proposal and the CDA will not, violate
any current statute, rule or regulation applicable to Developer or to transactions of the type contemplated
by the Proposal or the CDA;]
13.
[opinion that execution and delivery by the Guarantor of the Guaranty do not,
and the Guarantor’s performance of its obligations under the Guaranty will not, violate any current
statute, rule or regulation applicable to the Guarantor or to transactions of the type contemplated by the
Guaranty;] [if there is no Guaranty, this opinion may be omitted]
14.
[opinion that the Lease, the Tolling Services Agreement, the Direct Agreement
and D&C Direct Agreement, and the Independent Engineer Agreement have been duly authorized by all
necessary corporate action on the part of Developer and the Agreements have been duly executed and
delivered by Developer;] [if Developer is a partnership/joint venture, add: and its joint venture
members/general partners after the first and second “Developer”]
15.
[opinion that the Lease, the Tolling Services Agreement, the Direct Agreement
and D&C Direct Agreement, and the Independent Engineer Agreement constitute legal, valid and binding
obligations of Developer enforceable against Developer in accordance with their terms;] [if Developer is a
partnership/joint venture, add: and its joint venture members/general partners after the second
“Developer”]
16.
[opinion that execution and delivery by Developer of the Lease, the Tolling
Services Agreement, the Direct Agreement and D&C Direct Agreement, and the Independent Engineer
Agreement do not, and Developer’s performance of its obligations under such agreements will not, violate
any current statute, rule or regulation applicable to Developer or to transactions of the type contemplated
by the agreements.]
Texas Department of Transportation
SH 288 Toll Lanes Project in Harris County
December 18, 2014
-3-
Addendum #8 to Request for Proposals
Instructions to Proposers, Form L
FORM M
COMPLETION DEADLINES
The Proposal Commitment Date for Service Commencement set forth below shall be no later than the
milestone date specified in Exhibit 8 of the CDA.
Description
Service Commencement Date
Proposal Commitment Date for the Last Service NTP2 plus ______ calendar days
Commencement of the Initial Configuration
Texas Department of Transportation
SH 288 Toll Lanes Project in Harris County
December 18, 2014
-1-
Addendum #8 to Request for Proposals
Instructions to Proposers, Form M
FORM N
DETAILED COSTING FORM
Fill out Form N as follows:

For each line item on pages 2-6, enter the total cost of construction.

Enter all non-reimbursable costs other than operations and maintenance costs on page 4.

The amount entered into the total cost field shall be sub-divided in the adjacent fields to
represent how much is planned to be spent on the specific line item for each quarter.
Texas Department of Transportation
SH 288 Toll Lanes Project in Harris County
December 18, 2014
-1-
Addendum #8 to Request for Proposals
Instructions to Proposers, Form N
ITEM
Total
Cost
I. Design Build Costs
Roads
$
Drainage
$
Structures
$
Building & Enclosed Facilities
$
Traffic Management & Sequencing
$
Mobilization – Refer to the definition of Payment Activity in Exhibit 1 to the CDA to apply
mobilization cost in the appropriate quarter and for mobilization cost limitations.
$
SH 288 Construction Costs $ (Box A)
Of the total Construction Costs in Box A, indicate the amount for the (i) direct connector that
connects BW 8 westbound to SH 288 northbound and (ii) the direct connector that connects
BW 8 eastbound to SH 288 northbound
Of the total Construction Costs in Box A, indicate the amount for the (i) direct connector that
connects BW 8 southbound to SH 288 westbound and (ii) the direct connector that connects
BW 8 southbound to SH 288 eastbound
Texas Department of Transportation
SH 288 Toll Lanes Project in Harris County
December 18, 2014
-2-
Post NTP2
Year 1 Year 2
1st Qtr
2nd Qtr
3rd Qtr
4th Qtr
1st Qtr
2nd Qtr
3rd Qtr
4th Qtr
1st Qtr
2nd Qtr
3rd Qtr
4th Qtr
1st Qtr
2nd Qtr
3rd Qtr
4th Qtr
1st Qtr
2nd Qtr
3rd Qtr
4th Qtr
1st Qtr
2nd Qtr
3rd Qtr
4th Qtr
1st Qtr
2nd Qtr
Year 3
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
3rd Qtr $
4th Qtr $
$
$
$
$
$
$
Addendum #8 to Request for Proposals
Instructions to Proposers, Form N
Of the total Construction Costs in Box A, indicate the amount for the (i) direct connector that
connects BW 8 northbound to SH 288 westbound and (ii) the direct connector that connects
BW 8 northbound to SH 288 eastbound
Of the total Construction Costs in Box A, indicate the amount for the (i) direct connector that
connects BW 8 westbound to SH 288 southbound and (ii) the direct connector that connects
BW 8 eastbound to SH 288 southbound
Texas Department of Transportation
SH 288 Toll Lanes Project in Harris County
December 18, 2014
-3-
$
$
Addendum #8 to Request for Proposals
Instructions to Proposers, Form N
Total
Cost
ITEM
Post NTP2
Right-of-Way Costs
Year 1
Right-of-Way (Additional Properties)
$ (Box B)
Year 2
Year 3
1st Qtr $
$
$
2nd Qtr $
$
$
3rd Qtr $
$
$
4th Qtr $
$
$
Of the total Right-of-Way costs in Box B, indicate the amount for the (i) direct connector
that connects BW 8 westbound to SH 288 northbound and (ii) the direct connector that
$
connects BW 8 eastbound to SH 288 northbound
Of the total Right-of-Way costs in Box B, indicate the amount for the (i) direct connector $
that connects BW 8 southbound to SH 288 westbound and (ii) the direct connector that
connects BW 8 southbound to SH 288 eastbound
Of the total Right-of-Way costs in Box B, indicate the amount for the (i) direct connector $
that connects BW 8 northbound to SH 288 westbound and (ii) the direct connector that
connects BW 8 northbound to SH 288 eastbound
Of the total Right-of-Way costs in Box B, indicate the amount for the (i) direct connector
that connects BW 8 westbound to SH 288 southbound and (ii) the direct connector that
$
connects BW 8 eastbound to SH 288 southbound
Utility Relocation (Utility Adjustments)
$ (Box C)
Of the total Utility Relocation costs in Box C, indicate the amount for the (i) direct
connector that connects BW 8 westbound to SH 288 northbound and (ii) the direct
connector that connects BW 8 eastbound to SH 288 northbound
Of the total Utility Relocation costs in Box C, indicate the amount for the (i) direct
connector that connects BW 8 southbound to SH 288 westbound and (ii) the direct
connector that connects BW 8 southbound to SH 288 eastbound
Of the total Utility Relocation costs in Box C, indicate the amount for the (i) direct
connector that connects BW 8 northbound to SH 288 westbound and (ii) the direct
connector that connects BW 8 northbound to SH 288 eastbound
Of the total Utility Relocation costs in Box C, indicate the amount for the (i) direct
connector that connects BW 8 westbound to SH 288 southbound and (ii) the direct
connector that connects BW 8 eastbound to SH 288 southbound
Texas Department of Transportation
SH 288 Toll Lanes Project in Harris County
December 18, 2014
-4-
1st Qtr $
$
$
2nd Qtr $
$
$
3rd Qtr $
$
$
4th Qtr $
$
$
$
$
$
$
Addendum #8 to Request for Proposals
Instructions to Proposers, Form N
ITEM
Other Associated Costs
Pre NTP2
Total Cost
Quality Assurance/Quality Control
$
$
Design
$
Survey
$
Insurance
Other Non-reimbursable Costs
Independent Engineer (Cannot exceed 50% of total Independent
Engineer cost)
$
$
Sub-Total Other Associated Costs $ (Box E)
Of the total other costs in Box E, indicate the amount for the (i)
direct connector that connects BW 8 westbound to SH 288
northbound and (ii) the direct connector that connects BW 8
eastbound to SH 288 northbound
Texas Department of Transportation
SH 288 Toll Lanes Project in Harris County
December 18, 2014
Post NTP2
Year 0
Year 1
Year 2
Year 3
1st Qtr $
$
$
$
2nd Qtr $
$
$
$
3rd Qtr $
$
$
$
4th Qtr $
$
$
$
1st Qtr $
$
$
$
2nd Qtr $
$
$
$
3rd Qtr $
$
$
$
4th Qtr $
$
$
$
1st Qtr $
$
$
$
2nd Qtr $
$
$
$
3rd Qtr $
$
$
$
4th Qtr $
$
$
$
1st Qtr $
$
$
$
2nd Qtr $
$
$
$
3rd Qtr $
$
$
$
4th Qtr $
$
$
$
1st Qtr $
$
$
$
2nd Qtr $
$
$
$
3rd Qtr $
$
$
$
4th Qtr $
$
$
$
1st Qtr $
$
$
$
2nd Qtr $
$
$
$
3rd Qtr $
$
$
$
4th Qtr $
$
$
$
1st Qtr $
$
$
$
2nd Qtr $
$
$
$
3rd Qtr $
$
$
$
4th Qtr $
$
$
$
$
-5-
Addendum #8 to Request for Proposals
Instructions to Proposers, Form N
Of the total other costs in Box E, indicate the amount for the (i)
direct connector that connects BW 8 southbound to SH 288
westbound and (ii) the direct connector that connects BW 8
southbound to SH 288 eastbound
Of the total other costs in Box E, indicate the amount for the (i)
direct connector that connects BW 8 northbound to SH 288
westbound and (ii) the direct connector that connects BW 8
northbound to SH 288 eastbound
Of the total other costs in Box E, indicate the amount for the (i)
direct connector that connects BW 8 westbound to SH 288
southbound and (ii) the direct connector that connects BW 8
eastbound to SH 288 southbound
Texas Department of Transportation
SH 288 Toll Lanes Project in Harris County
December 18, 2014
$
$
$
-6-
Addendum #8 to Request for Proposals
Instructions to Proposers, Form N
ITEM
II. Maintenance and Operations Costs
Maintenance
(Routine and Life Cycle)
Roads
$
Drainage
$
Structures
$
Building & Enclosed Facilities
$
Traffic Management & Sequencing
$
Fleet & Equipment
$
Sub-Total Maintenance Costs
Texas Department of Transportation
SH 288 Toll Lanes Project in Harris County
December 18, 2014
$ (Box G)
Year
(m+1)
Year (m)
Total Cost
Year
(m+2)
Year
(m+3)
Year
(m+x)
1st Qtr
2nd Qtr
3rd Qtr
4th Qtr
1st Qtr
2nd Qtr
3rd Qtr
4th Qtr
1st Qtr
2nd Qtr
3rd Qtr
4th Qtr
1st Qtr
2nd Qtr
3rd Qtr
4th Qtr
1st Qtr
2nd Qtr
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
3rd Qtr
4th Qtr
$
$
$
$
$
$
$
$
$
$
1st Qtr
2nd Qtr
$
$
$
$
$
$
$
$
$
$
3rd Qtr
4th Qtr
$
$
$
$
$
$
$
$
$
$
1st Qtr
2nd Qtr
$
$
$
$
$
$
$
$
$
$
3rd Qtr
4th Qtr
$
$
$
$
$
$
$
$
$
$
-7-
Addendum #8 to Request for Proposals
Instructions to Proposers, Form N
ITEM
II. Maintenance and Operations Costs
Maintenance
(Routine and Life Cycle)
Of the total maintenance costs in Box G, indicate the amount for
the (i) direct connector that connects BW 8 westbound to SH
$
288 northbound and (ii) the direct connector that connects BW 8
eastbound to SH 288 northbound
$
Of the total maintenance costs in Box G, indicate the amount
for the (i) direct connector that connects BW 8 southbound to
SH 288 westbound and (ii) the direct connector that connects
BW 8 southbound to SH 288 eastbound
$
Of the total maintenance costs in Box G, indicate the amount
for the (i) direct connector that connects BW 8 northbound to
SH 288 westbound and (ii) the direct connector that connects
BW 8 northbound to SH 288 eastbound
Of the total maintenance costs in Box G, indicate the amount
for the (i) direct connector that connects BW 8 westbound to
SH 288 southbound and (ii) the direct connector that connects
BW 8 eastbound to SH 288 southbound
Note:
Year (m)
Total Cost
$
Year
(m+1)
Year
(m+2)
Year
(m+3)
Year
(m+x)
1st Qtr
2nd Qtr
3rd Qtr
4th Qtr
1st Qtr
2nd Qtr
3rd Qtr
4th Qtr
1st Qtr
2nd Qtr
3rd Qtr
4th Qtr
1st Qtr
2nd Qtr
3rd Qtr
4th Qtr
Provide maintenance and operations costs for each year of the Term of the Agreement (i.e., in the columns above, m = the first year after NTP2 and x = 4, 5, 6,….final
year of Term)
Texas Department of Transportation
SH 288 Toll Lanes Project in Harris County
December 18, 2014
-8-
Addendum #8 to Request for Proposals
Instructions to Proposers, Form N
ITEM
Total Cost
Operations
Toll Operations
$
Customer Service
$
Incident Management
$
Lane Availability Management
$
Sub-Total Operations Costs
Note:
Year
(m+1)
Year (m)
$ (Box H)
Year
(m+2)
Year
(m+3)
Year
(m+x)
1st Qtr
2nd Qtr
3rd Qtr
4th Qtr
1st Qtr
2nd Qtr
3rd Qtr
4th Qtr
1st Qtr
2nd Qtr
3rd Qtr
4th Qtr
1st Qtr
2nd Qtr
3rd Qtr
4th Qtr
1st Qtr
2nd Qtr
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
3rd Qtr
4th Qtr
$
$
$
$
$
$
$
$
$
$
Provide maintenance and operations costs for each year of the Term of the Agreement (i.e., in the columns above, m = the first year after NTP2 and x = 4, 5, 6,….final
year of Term)
Texas Department of Transportation
SH 288 Toll Lanes Project in Harris County
December 18, 2014
-9-
Addendum #8 to Request for Proposals
Instructions to Proposers, Form N
Expenditure Plan
ITEM
SH 288 Interim Configuration Construction Costs
$ (Box A)
Right-of-Way (Additional Properties)
$ (Box B)
Utility Relocation (Utility Adjustments)
$ (Box C)
Total Project Construction Costs
$ (Box D)
(Box A + Box B + Box C)
Other Associated Costs
Pre NTP2
Year 0
Total Cost
$ (Box E)
Total Project Design-Build Costs
$ (Box F)
(Box D +Box E)
Year 1
Post NTP2
Year 2
Year 3
$
$
$
$
$
$
$
$
$
$
$
$
$
1st Qtr
2nd Qtr
3rd Qtr
4th Qtr
1st Qtr
2nd Qtr
3rd Qtr
4th Qtr
1st Qtr
2nd Qtr
3rd Qtr
4th Qtr
1st Qtr
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
2nd Qtr
$
$
$
3rd Qtr
4th Qtr
$
$
$
$
$
$
1st Qtr
2nd Qtr
3rd Qtr
4th Qtr
1st Qtr
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
2nd Qtr
$
$
$
$
3rd Qtr
$
$
$
$
$
$
$
$
4th Qtr
Total Maintenance and Operations Costs
$ (Box I)
(Box G +Box H)
Total Project Costs
$ (Box J)
(Box F +Box I)
Note:
Pre NTP2 costs shall not be included in the Total Project Construction Costs shown in Box H of Form N-2.
Texas Department of Transportation
SH 288 Toll Lanes Project in Harris County
December 18, 2014
- 10 -
Addendum #8 to Request for Proposals
Instructions to Proposers, Form N
FORM O
TERMINATION FOR CONVENIENCE AMOUNTS
Date of Effectiveness of Termination
Occurs on or after:
And before:
Service Commencement Date1
The 2nd anniversary of Service Commencement Date
The 2nd anniversary of Service Commencement Date
The 4th anniversary of Service Commencement Date
th
The 4 anniversary of Service Commencement Date
The 6th anniversary of Service Commencement Date
The 6th anniversary of Service Commencement Date
The 8th anniversary of Service Commencement Date
The 8th anniversary of Service Commencement Date
The 10th anniversary of Service Commencement Date
th
The 10 anniversary of Service Commencement Date
The 12th anniversary of Service Commencement Date
th
The 12 anniversary of Service Commencement Date
The 14th anniversary of Service Commencement Date
The 14th anniversary of Service Commencement Date
The 16th anniversary of Service Commencement Date
The 16th anniversary of Service Commencement Date
The 18th anniversary of Service Commencement Date
th
The 18 anniversary of Service Commencement Date
The 20th anniversary of the Service Commencement Date
The 20th anniversary of the Service Commencement Date The 22nd anniversary of the Service Commencement Date
The 22nd anniversary of the Service Commencement Date The 24th anniversary of the Service Commencement Date
The 24th anniversary of the Service Commencement Date The 26th anniversary of the Service Commencement Date
The 26th anniversary of the Service Commencement Date The 28th anniversary of the Service Commencement Date
The 28th anniversary of the Service Commencement Date The 30th anniversary of the Service Commencement Date
The 30th anniversary of the Service Commencement Date The 32nd anniversary of the Service Commencement Date
The 32nd anniversary of the Service Commencement Date The 34th anniversary of the Service Commencement Date
The 34th anniversary of the Service Commencement Date The 36th anniversary of the Service Commencement Date
The 36th anniversary of the Service Commencement Date The 38th anniversary of the Service Commencement Date
The 38th anniversary of the Service Commencement Date The 40th anniversary of the Service Commencement Date
The 40th anniversary of the Service Commencement Date The 42nd anniversary of the Service Commencement Date
The 42nd anniversary of the Service Commencement Date The 44th anniversary of the Service Commencement Date
The 44th anniversary of the Service Commencement Date The 46th anniversary of the Service Commencement Date
The 46th anniversary of the Service Commencement Date The 48th anniversary of the Service Commencement Date
The 48th anniversary of the Service Commencement Date The end of the Term
Termination
Compensation Amount
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
$
Provide the net present value of the Termination for Convenience Amounts set forth above as of the Financial Proposal Due Date, to the nearest
dollar, in the box below. The net present value must be calculated at a 5% discount rate and assuming that the termination is effective and payment
is made as of the last day of each period (e.g., in the case of the first period, as of the day immediately prior to the second anniversary of the
Service Commencement Date).
Net Present Value of Termination for Convenience Amounts
1
$____________
To the extent Developer’s Project Segment Plan contemplates multiple Project Segments, the Service Commencement Date refers to the first Service Commencement Date.
Texas Department of Transportation
SH 288 Toll Lanes Project in Harris County
December 18, 2014
-1-
Addendum #8 to Request for Proposals
Instructions to Proposers, Form O
FORM P
EQUAL EMPLOYMENT OPPORTUNITY CERTIFICATION
[To be executed by Proposer, Major Participants and proposed subcontractors]
The undersigned certifies on behalf of ____________________________, that:
(Name of entity making certification)
[check one of the following boxes]
It has developed and has on file at each establishment affirmative action programs pursuant to 41
CFR Part 60-2 (Affirmative Action Programs).
It is not subject to the requirements to develop an affirmative action program under 41 CFR Part
60-2 (Affirmative Action Programs).
[check one of the following boxes]
It has not participated in a previous contract or subcontract subject to the equal opportunity clause
described in Executive Orders 10925, 11114 or 11246.
It has participated in a previous contract or subcontract subject to the equal opportunity clause
described in Executive Orders 10925, 11114 or 11246 and, where required, it has filed with the
Joint Reporting Committee, the Director of the Office of Federal Contract Compliance, a Federal
Government contracting or administering agency, or the former President’s Committee on Equal
Employment Opportunity, all reports due under the applicable filing requirements.
Signature: ____________________________________
Title: ________________________________________
Date: ________________________________________
If not Proposer, relationship to Proposer: ___________________________________________________
Note: The above certification is required by the Equal Employment Opportunity Regulations of the
Secretary of Labor (41 CFR 60-1.7(b)(1)), and must be submitted by Proposers and proposed
subcontractors only in connection with contracts and subcontracts which are subject to the equal
opportunity clause. Contracts and subcontracts that are exempt from the equal opportunity clause are set
forth in 41 CFR 60-1.5. (Generally, only contracts or subcontracts of $10,000 or under are exempt.)
Currently, Standard Form 100 (EEO-1) is the only report required by Executive Orders or their
implementing regulations.
Proposers, Major Participants and proposed subcontractors who have participated in a previous contract
or subcontract subject to the Executive Orders and have not filed the required reports should note that 41
CFR 60-1.7(b)(1) prevents the award of contracts and subcontracts unless such contractor submits a
report covering the delinquent period or such other period specified by the Federal Highway
Administration or by the Director, Office of Federal Contract Compliance, U.S. Department of Labor.
Texas Department of Transportation
SH 288 Toll Lanes Project in Harris County
December 18, 2014
-1-
Addendum #8 to Request for Proposals
Instructions to Proposers, Form P
FORM Q
FINANCIAL SUMMARY
Proposer Name: ____________________________________________
NOTE: THE INFORMATION IN THIS FORM Q IS SUBJECT TO PUBLIC DISCLOSURE IN
ACCORDANCE WITH SECTION 2.6 OF THE INSTRUCTIONS TO PROPOSERS.
A.
Provide the following information in Table 1, below:

Nominal amount of Concession Payment (Form J-2, Box 1);

Sum of nominal amount of Public Funds Payments (Form J-1, Box 2) (using absolute
value, rather than negative number);

Nominal amount of total development costs, showing breakdown for initial design
costs, construction costs, ROW and ROW acquisition costs and utilities adjustment
costs;

Net present value of total operation and maintenance costs, showing breakdown for toll
operation costs, routine and capital maintenance costs, using a 5% discount rate;

Amount of Equity (all Developer contributions for the Project at risk) and Quasi-Equity
contributions for each one of the Equity Members; and

Expected Nominal Equity IRR.
Texas Department of Transportation
SH 288 Toll Lanes Project in Harris County
December 18, 2014
-1-
Addendum #8 to Request for Proposals
Instructions to Proposers, Form Q
Table 1
Concession Payment to TxDOT
Sum of Public Funds Payments
Total development cost





$________________
(Form J-2, Box 1)
$________________
(Form J-2, Box 2)
Total Development Costs:
$_____________________
Design costs
Construction costs
ROW and ROW acquisition
costs
Utilities adjustments costs
Other (Identify)
 $___________
 $___________
 $___________
 $___________
 $___________
Total operation and maintenance costs Total O&M Costs:
$_________________________
 Toll operation costs (NPV)

$___________
 Routine and capital
maintenance costs (NPV)

$___________
Amount of Developer Equity and
Quasi-Equity contributions for
each Equity Member
A. Total for all Equity Members
$___________________



$ [Equity Member]
$ [Equity Member]
$ [Equity Member]
Nominal Equity IRR
Texas Department of Transportation
SH 288 Toll Lanes Project in Harris County
December 18, 2014
-2-
Addendum #8 to Request for Proposals
Instructions to Proposers, Form Q
B.
Provide the nominal amounts for the sources and uses of funds for the construction period for the
Project, as shown in Table 2, below.
Table 2
Sources of Funds
 Equity
 Subordinated debt
 Bank debt
 TIFIA
 PABs
 Bond
 Other (identify specifics)
Total Sources of Funds
Uses of Funds
 Design costs
 Construction costs
 ROW and ROW
acquisition costs
 Utilities adjustments costs
 Other costs (identify specifics)
Total Uses of Funds
Texas Department of Transportation
SH 288 Toll Lanes Project in Harris County
December 18, 2014
-3-
Addendum #8 to Request for Proposals
Instructions to Proposers, Form Q
FORM R
REVENUE PAYMENT CALCULATION
Proposer Name:
Band
Revenue
Payment (%)
Calculation
Date
Band 1
Band 2
Band 3
Band 4
Band 5
0.0%
12.5%
25.0%
50.0%
75.0%
Floor
Ceiling
Floor
Ceiling
Floor
Ceiling
Floor
Ceiling
Floor
1st
$0
$[___]
$[___]
$[___]
$[___]
$[___]
$[___]
$[___]
$[___]
2nd
$0
$[___]
$[___]
$[___]
$[___]
$[___]
$[___]
$[___]
$[___]
3rd
$0
$[___]
$[___]
$[___]
$[___]
$[___]
$[___]
$[___]
$[___]
[Etc.]
* The first calculation date should be December 31 of the year in which the third anniversary of the first Service Commencement Date occurs. The
subsequent calculation dates should be December 31 of each subsequent year through the end of the Term. The final calculation date should be the
last day of the Term.
Texas Department of Transportation
SH 288 Toll Lanes Project in Harris County
December 18, 2014
-1-
Addendum #8 to Request for Proposals
Instructions to Proposers, Form R
FORM S
GUARANTY
FOR VALUABLE CONSIDERATION, ___________, a ___________ (“Guarantor”),
agrees as follows:
1.
The term “Agreement” refers to the Comprehensive Development Agreement
(the “CDA”) for the TxDOT SH 288 Toll Lanes Project in Harris County dated ___________, as
amended, by and between the TEXAS DEPARTMENT OF TRANSPORTATION, a public agency of the
State of Texas (“TxDOT”), and ___________, a ___________(“Principal”). The Agreement is hereby
incorporated by reference herein. Exhibit A to the Agreement contains the definitions of various terms
used in this Guaranty.
2.
The term “Obligations” refers to all of the obligations of Principal
arising out of, in connection with, under or related to the Contract Documents as they may be amended or
supplemented, including without limitation, liability for damages, indemnities and warranties as specified
in the Agreement. The term “Equity Owner” means an entity or a firm that has a direct equity interest in
the Principal or an indirect equity interest in the Principal through one or more limited liability
intermediaries.
3.
Guarantor irrevocably and unconditionally, as primary obligor and
not merely as surety, guarantees and warrants to TxDOT and its successors and assigns the full and
prompt payment and performance by Principal when due of the Obligations, up to the amount of
$______. [to be included if multiple guarantees are provided: Guarantor and ______________________
shall have joint and several liability for performance of the Obligations, provided that the total liability of
Guarantor and such other entities shall not exceed the foregoing limitation on liability.]
4.
An Obligation may be
further authorization from or notice to Guarantor.
incurred
by
Principal
to
TxDOT
without
5.
In such manner and upon such terms and at such times as it
deems best and with or without notice to Guarantor, TxDOT may alter, compromise, accelerate, extend or
change the time or manner for the performance of any Obligation, or release or add one or more
guarantors or endorsers, accept additional or substituted security, or release or subordinate any security
given to secure the performance of any Obligation. No exercise or non-exercise by TxDOT of any rights
given to it hereby, no dealing by TxDOT with Principal, any of Principal’s members or any entity with
liability for the Obligations, and no change, retirement or suspension of any right or remedy of TxDOT,
shall in any way affect any obligation of Guarantor hereunder or any security furnished by Guarantor or
give Guarantor any recourse against TxDOT.
6.
TxDOT may waive any default or may fail to assert any rights
(including rights of offset), or grant any other indulgence or concession with respect to all or any part of
each Obligation, and may take and deal as herein provided with any bond, letter of credit, guaranty,
instrument, document, collateral security or other property given to TxDOT to secure all or any part of the
Obligations or otherwise available to TxDOT, and may apply any moneys, property or security available
to it in such manner and amounts and at such times to the payment or reduction or performance of any
Obligation as TxDOT may elect. Notwithstanding the foregoing, Guarantor shall remain bound by this
Guaranty.
Texas Department of Transportation
SH 288 Toll Lanes Project in Harris County
December 18, 2014
-1-
Addendum #8 to Request for Proposals
Instructions to Proposers, Form S
7.
Guarantor waives any right to require that any claim or demand be
asserted, any remedy available to TxDOT be enforced, or any action be brought against Principal, any of
the Equity Owners or any other party or to require that resort be had to any security or property available
to TxDOT.
8.
This Guaranty shall not be affected by any full or partial payment or performance
of any Obligation which is required to be returned as a result of or in connection with the insolvency,
reorganization or bankruptcy of Principal or any of its members, the dissolution of Principal or otherwise.
Guarantor agrees that TxDOT may, in the event of a default herein or in any Obligation, proceed against
Guarantor or Principal or any other entity with liability for the Obligations or any combination of the
foregoing, in such order as TxDOT may deem appropriate. Guarantor waives any defenses it may have by
reason of an election of remedies by TxDOT. Guarantor waives any claims of waiver, release, surrender,
alteration, compromise, diligence and filing of claims with any court, provided that the foregoing shall not
be deemed to preclude Guarantor from relying on any waivers or modifications of Agreement
requirements which were previously made by TxDOT during the course of performance of the
Agreement. Notwithstanding anything to the contrary contained herein, no action of TxDOT by way of
compromise or settlement, in the context of any insolvency, reorganization or bankruptcy of Principal or
any of its members, the dissolution of Principal or otherwise, will have any effect on Guarantor’s liability
hereunder.
9.
This Guaranty shall remain in full force and effect irrespective of
any interruptions in the business relations of Principal with TxDOT. The failure by TxDOT to file or
enforce a claim against the estate (either in administration, bankruptcy or other proceedings) of Principal
or any other entity with liability for the Obligations shall not operate to release Guarantor from liability
hereunder.
10.
Guarantor waives:
(a)
contracting of any Obligation;
notice
of
acceptance
hereof
and
of
the
incurring
or
(b)
presentment and demand for payment or performance of any Obligation;
(c)
protest and notice of the dishonor or default to any party with respect to
(d)
all other notices to which Guarantor might otherwise be entitled; and
(e)
any demand for payment hereunder.
any Obligation;
11.
Until all Obligations have been indefeasibly paid in full and
performed, Guarantor waives any claim, right or remedy which it may now have or may hereafter acquire
against the Principal that arises from the performance of the Guarantor hereunder, including, without
limitation, any claim, right or remedy of subrogation, reimbursement, exoneration, contribution or
indemnification against Principal, or participation in any claim, right or remedy of TxDOT against
Principal or any other security or collateral that TxDOT now has or hereafter acquires, whether or not
such claim, right or remedy arises in equity, under contract, by statute, under common law or otherwise.
All existing or future indebtedness of Principal and any Equity Owner to Guarantor, and the right of
Guarantor to withdraw any capital invested by Guarantor in Developer (whether directly or through an
intermediary Equity Owner), are unconditionally subordinated to all of the Obligations. Whenever and for
so long as Principal shall be in default in the performance of an Obligation, Guarantor shall not claim, sue
Texas Department of Transportation
SH 288 Toll Lanes Project in Harris County
December 18, 2014
-2-
Addendum #8 to Request for Proposals
Instructions to Proposers, Form S
for, collect or accept any payment from Developer or any Equity Owner with respect to any such
indebtedness without the prior written consent of TxDOT. Any payment by Principal or any Equity
Owner to Guarantor in violation of this provision shall be deemed to have been received by Guarantor as
trustee for TxDOT.
12.
Guarantor agrees to pay to TxDOT without demand reasonable attorneys’ fees
and all costs and other expenses (including such fees and costs of litigation, including appeals) incurred
by TxDOT in collecting or compromising any Obligation or enforcing this Guaranty against Guarantor or
in attempting to do any or all of the foregoing.
13.
Guarantor represents and warrants as follows:
(a)
Guarantor is a ___________ duly organized, validly existing and in good
standing
under
the
laws
of
___________,
and
Guarantor
is
duly
qualified to transact business in each jurisdiction where the nature of its activities or the ownership of
property makes such qualification necessary;
(b)
Guarantor has full power and authority to transact the business in which
it is engaged and to execute and deliver this Guaranty and perform its obligations hereunder;
(c)
This Guaranty has been duly authorized, executed and delivered by
Guarantor, and is a valid and binding agreement of Guarantor enforceable in accordance with the terms
hereof;
(d)
Neither the execution and delivery of this Guaranty, nor the
fulfillment of or compliance with the terms and provisions hereof, will violate any law, regulation, order,
writ, injunction or decree of any court or governmental instrumentality, or result in a breach of any of the
terms, conditions or provisions of, or constitute a default under, or result in the creation or imposition of
any mortgage, lien or encumbrance of any nature whatsoever upon any of the properties or assets of
Guarantor pursuant to the terms of, Guarantor’s formation documents, or any mortgage, indenture,
agreement or instrument to which Guarantor is a party or by which it is bound;
(e)
No consent or action of, or filing with, any governmental or public
regulatory body or authority is required to authorize, or is otherwise required in connection with, the valid
execution, delivery and performance of this Guaranty; and
(f)
Guarantor will not take any action which will cause Principal to dissolve.
14.
This Guaranty is binding upon and inures to the benefit of the
successors and assigns of Guarantor and TxDOT, but is not assignable by Guarantor without the prior
written consent of TxDOT, which consent may be granted or withheld in TxDOT’s discretion.
15.
Any communication, notice or demand of any kind whatsoever under this
Guaranty shall be in writing and delivered by personal service (including express or courier service), by
facsimile (if confirmed in writing sent by registered or certified mail, postage prepaid, return receipt
requested), or by registered or certified mail, postage prepaid, return receipt requested, addressed as
follows:
Texas Department of Transportation
SH 288 Toll Lanes Project in Harris County
December 18, 2014
-3-
Addendum #8 to Request for Proposals
Instructions to Proposers, Form S
If to TxDOT:
Texas Department of Transportation
7600 Chevy Chase Drive, Building 2, 4th Floor
Austin, Texas 78752
Attn: [____________]
E-mail: TxDOT-HOU-PPP-SH288@txdot.gov
With copies to:
Texas Department of Transportation
Office of General Counsel
125 East 11th Street
Attention: General Counsel
Telephone: (512) 463-8630
Telecopy: (512) 475-3070
If to Guarantor:
Attention:
Telephone:
Facsimile:
Either Guarantor or TxDOT may from time to time change its address for the purpose of notices by a
similar notice specifying a new address, but no such change is effective until it is actually received by the
party sought to be charged with its contents. All notices sent by facsimile shall also be sent by mail on the
same day. All notices and other communications shall be deemed effective upon receipt, if delivered
personally or by express or courier service, upon transmission as shown in the confirmation, if delivered
by facsimile, and five days following deposit in the United States mail, postage prepaid if delivered by
mail.
16.
Any forbearance or failure to exercise, and any delay by TxDOT in
exercising, any right, power or remedy hereunder will not impair any such right, power or remedy or be
construed to be a waiver thereof, nor will it preclude the further exercise of any such right, power or
remedy.
17.
Should any one or more of the provisions of this Guaranty be
determined to be illegal or unenforceable, all other provisions hereof shall be given effect separately
therefrom and shall not be affected by such determination. The rights of TxDOT hereunder are
cumulative and shall not be exhausted by any one or more exercises of said rights against Guarantor or
any other entity with liability for the Obligations or by any number of successive actions until and unless
all Obligations have been fully paid or performed and expiration or termination of the Agreement.
Guarantor agrees to execute, have acknowledged and delivered to TXDOT such other and further
instruments as may be required by TxDOT to effectuate the intent and purpose hereof. No right of action
shall accrue on this Guaranty to or for the use of any person or entity other than TxDOT or its successors
and assigns until TxDOT’s claims have been satisfied in full. All words used herein in the singular shall
be deemed to have been used in the plural when the context or construction so require. This Guaranty
shall be governed by and be construed in accordance with the laws of the State of Texas.
Texas Department of Transportation
SH 288 Toll Lanes Project in Harris County
December 18, 2014
-4-
Addendum #8 to Request for Proposals
Instructions to Proposers, Form S
IN WITNESS WHEREOF, Guarantor has executed this Guaranty as of the date first written
above.
____________________________________________
a ___________________________________________
By: _________________________________________
Title: ________________________________________
____________________________________________
a __________________________________________
By: _________________________________________
Title: ________________________________________
Texas Department of Transportation
SH 288 Toll Lanes Project in Harris County
December 18, 2014
-5-
Addendum #8 to Request for Proposals
Instructions to Proposers, Form S
FORM T
PABS AGREEMENT
*****
AGREEMENT AMONG
THE TEXAS DEPARTMENT OF TRANSPORTATION,
THE TEXAS PRIVATE ACTIVITY BOND SURFACE TRANSPORTATION CORPORATION
AND [●]
This Agreement (this “Agreement”) is made by and among the Texas Department of
Transportation (“TxDOT”), an agency of the State of Texas (the “State”), [●], a [●], (“Developer”) and
the Texas Private Activity Bond Surface Transportation Corporation, a Texas public, non-profit
corporation operating pursuant to Chapter 431, Texas Transportation Code (the “Corporation”).
RECITALS
A.
Subchapter E of Chapter 223, Texas Transportation Code (“Subchapter E”), authorizes
TxDOT to enter into a comprehensive development agreement with a private entity to design, develop,
finance, construct, maintain, repair, operate, extend, or expand various types of state highway
improvement projects, including tolled projects, and sets out the process by which TxDOT will evaluate
and enter into such an agreement.
B.
As authorized by Texas Transportation Code §223.2012, on [●], 2015, the Texas
Transportation Commission (the “Commission”), pursuant to Minute Order [●], authorized the TxDOT
Executive Director to enter into a comprehensive development agreement (the “CDA”) between TxDOT
and Developer to develop, design, construct, finance, maintain and operate the State Highway 288 Toll
Lanes Project in Harris County (the “Project”).
C.
TxDOT and Developer entered into the CDA as of [●].
D.
Pursuant to the CDA, Developer anticipates utilizing the proceeds of tax exempt private
activity bonds (the “bonds”) to finance or refinance a portion of the Project.
E.
The Corporation and Developer intend in a single issuance or from time to time to enter
into transactions in which bonds will be issued by the Corporation to finance, in whole or in part, the
costs of the Project, as further set forth in the CDA.
F.
The Corporation is authorized by State law including Chapter 431, Texas Transportation
Code, to issue the bonds and loan the proceeds of the bonds to Developer.
G.
This Agreement is being executed to establish the roles, responsibilities and
understanding of the parties related to the issuance of the bonds referenced above as part of the financing
of the Project.
Texas Department of Transportation
SH 288 Toll Lanes Project in Harris County
December 18, 2014
-1-
Addendum #8 to Request for Proposals
Instructions to Proposers, Form T
ARTICLE I
ISSUANCE OF BONDS
1.1
Security. The bonds will be issued by the Corporation without any recourse to the Commission,
TxDOT, the Corporation or the State and the bonds shall be payable by the Corporation solely from
payments received from Developer under a loan or similar agreement pursuant to which the Corporation
shall make the proceeds of the bonds available to Developer, and as provided in a trust indenture and
other bond documents as further described below. TxDOT shall have no obligation to pay debt service on
any bonds issued or incurred in connection with the Project. The bonds are payable solely from the funds
and secured solely by property furnished and to be furnished and provided by or on behalf of Developer
and are not in any manner payable wholly or partially from any funds or properties otherwise belonging
to the State, TxDOT, the Corporation or the Commission; and that by its issuance thereof, the Corporation
does not in any manner, directly or indirectly, guarantee, warrant or endorse the creditworthiness or credit
standing of Developer or of any guarantor of such obligations or the investment quality or value of the
same.
1.2
Principal Amount, Timing. The Corporation will issue its bonds in one or more series in such
principal amounts and at such times as reasonably requested by Developer in accordance with the plan of
finance for the Project and in compliance with all applicable State and federal laws. Once a reasonable
financing schedule has been agreed upon by TxDOT, the Corporation and Developer, the Corporation
will work diligently and in good faith to accomplish the issuance of the bonds in accordance with the
agreed-upon schedule, provided, that, such financing schedule may be adjusted, as mutually agreed upon
by the parties, from time to time.
1.3
Pricing. TxDOT and the Corporation shall be involved in all aspects of the pricing of the bonds,
including pre-pricing and pricing discussion and selection of pricing dates.
1.4
Terms of Bonds. Except as otherwise provided by State or federal law, Developer, in
consultation with the Corporation and the Corporation’s advisors, shall: (a) select the type and terms of
the bonds issued, including, but not limited to, maturity structure, maximum maturity within applicable
law (currently up to 40 years), security, repayment terms, interest rates, reserve funds, refunding
mechanisms, bond holder put or tender rights, and the manner of payment to the investors; and (b)
determine the method by which the instruments in question are to be sold. The bonds must be fixed rate
and cannot include interest rate swaps.
1.5
Loan Agreement. The Corporation and Developer will enter into a loan agreement or a similar
document pursuant to which the Corporation shall make the proceeds of any bond issuance available to
Developer and pursuant to which Developer will agree unconditionally to pay to the trustee pursuant to a
trust indenture the principal and interest and redemption premiums on any bonds issued, when and as
these amounts become due and payable, and to pay all of the trustee’s reasonable costs relating to the
bonds and, to the extent required by the bond documents, reasonable costs related to the Project. The
proceeds from the sale of any bonds will be applied by Developer only toward the uses permitted under
the CDA and applicable law, pursuant to terms set forth in the loan agreement or similar document
between the Corporation and Developer and the trust indenture pursuant to which such bonds will be
issued and secured.
1.6
Trustee. For each bond issuance, the Corporation, with the prior written approval of Developer
(such approval not to be unreasonably withheld, conditioned or delayed), may select a trustee, paying
agent or escrow agent as needed, as determined by the Corporation. To the extent permitted by law,
customary, reasonable and documented fees for the services of any trustee, paying agent or escrow agent
Texas Department of Transportation
SH 288 Toll Lanes Project in Harris County
December 18, 2014
-2-
Addendum #8 to Request for Proposals
Instructions to Proposers, Form T
shall be paid from bond proceeds. If not paid from bond proceeds, such fees shall be the exclusive
responsibility of Developer, and subject to any fee caps or other fee arrangements set forth in the
applicable engagement letter.
1.7
Bond Documents. Bond documents, such as a trust indenture, loan or similar agreement, and the
bond resolution, shall be prepared by the Corporation’s bond counsel. These documents, and all
documents related thereto, (herein collectively called the “Bond Documents”) shall be subject to
negotiation and comment by all parties to such documents. The responsibility of drafting Bond
Documents not specifically identified in this paragraph shall be as agreed upon by Developer and the
Corporation.
1.8
Underwriter. Developer may select the lead underwriter and other managing underwriters, if
any. After consultation with the Corporation and taking into account the recommendations of the
Corporation (but not subject to the consent of the Corporation) Developer may also select the other
members of the financial team, including other underwriters, remarketing agents and other team members
deemed necessary. Notwithstanding the foregoing, Developer may not select underwriters or other
members of the financial team who are prohibited from or otherwise not qualified to conduct business in
the State. Further, Developer and the lead underwriter may select a law firm or firms to act as
underwriter’s counsel.
1.9
Financial Advisor and Other Consultants. The Corporation may engage a financial advisor or
co-financial advisor, and other such consultants as it determines appropriate, in each case, with the prior
written approval of Developer (such approval not to be unreasonably withheld, conditioned or delayed),
for a bond issue and the customary, reasonable and documented fees charged by the financial advisor and
other consultants may be paid from bond proceeds to the extent permitted by law. Such fees, if or to the
extent not paid from bond proceeds, shall be the exclusive responsibility of Developer, and subject to any
fee caps or other fee arrangements set forth in the applicable engagement letter.
1.10
Bond Counsel and Disclosure Counsel. The Corporation shall select as bond counsel or cobond counsel a firm whose experience in matters relating to the issuance of obligations by states and their
political subdivisions is nationally recognized, and which may include the firms currently (as of the date
hereof) approved by the Commission to act as bond counsel for the Commission. The Corporation, with
the prior written approval of Developer (such approval not to be unreasonably withheld, conditioned or
delayed), may separately select and engage the services of disclosure counsel, who shall be reasonably
acceptable to both the Corporation and Developer. The customary and reasonable fees of all such counsel
may be paid directly from bond proceeds to the extent permitted by law. Such fees, if or to the extent not
paid from bond proceeds, shall be the exclusive responsibility of Developer, and subject to any fee caps
or other fee arrangements set forth in the applicable engagement letter.
1.11
Official Statement. The information in the official statement or other offering document,
including any offering memoranda, private placement memoranda, or other similar disclosure documents,
pertaining to the Corporation, TxDOT, the Commission and the CDA must be approved by the
Corporation prior to release of any such document. Developer and underwriter are otherwise responsible
for the contents of the official statement or other offering document, subject to review by the
Corporation’s bond counsel or disclosure counsel. The Corporation and TxDOT will cooperate with
Developer in the preparation of the official statement, including providing information within their
control. Developer will assist in providing continuing disclosure information, if necessary in accordance
with Rule 15c2-12 of the Securities and Exchange Commission, and in providing customary 10(b)(5)
comfort to the Corporation, TxDOT, the underwriter and Commission for information provided by
Developer for use in the official statement or other offering document, and the Corporation and TxDOT
Texas Department of Transportation
SH 288 Toll Lanes Project in Harris County
December 18, 2014
-3-
Addendum #8 to Request for Proposals
Instructions to Proposers, Form T
will provide customary 10(b)(5) comfort with respect to information provided by them. The Corporation
and TxDOT will comply with any continuing disclosure requirement that may be applicable to them or,
with respect to TxDOT, to the Commission. Developer, and the Corporation, with the prior written
approval of Developer (such approval not to be unreasonably withheld, conditioned or delayed), may hire
such experts and feasibility consultants as may be reasonable or necessary to provide analysis and reports
for the official statement, and the Corporation and TxDOT will cooperate in providing such information
to such experts as is within their control. The customary, reasonable and documented fees of all such
experts and consultants may be paid directly from bond proceeds to the extent permitted by law. Such
fees, if or to the extent not paid from bond proceeds, shall be the responsibility of Developer, subject to
any fee caps or other fee arrangements set forth in the applicable engagement letter.
1.12
Fees. The customary, reasonable and documented fees of the other entities engaged by
Developer, or the Corporation with the prior written approval of Developer (such approval not to be
unreasonably withheld, conditioned or delayed), to assist in the issuance of bonds or otherwise necessary
for the issuance of bonds, and not otherwise explicitly referenced herein, may be paid from bond proceeds
to the extent permitted by law. Such fees, if or to the extent not paid from bond proceeds, shall be the
exclusive responsibility of Developer, and subject to any fee caps or other fee arrangements set forth in
the applicable engagement letter.
1.13
Credit Ratings. Developer shall select the rating agency or agencies for the bonds. Developer
shall coordinate with the Corporation in all discussions with such agency or agencies. Fourteen days, if
practicable, but in any event not less than five Business Days, prior to any meeting with a rating agency in
relation to the bonds to be issued and solely to the extent then available, Developer shall include on its
escrow site the then current draft, if any, of the rating agency presentation that will be presented to the
applicable rating agency. During the course of the week immediately preceding any meeting with a rating
agency in relation to the bonds to be issued, solely to the extent a draft has been created and solely to the
extent that any changes have been made as compared to any prior draft of such presentation that was
already included by Developer on its escrow site, Developer shall include on its escrow site, by no later
than 5:30 p.m. central standard time on each applicable day during such week, the then current draft,
solely to the extent a draft has been created and modified, of the rating agency presentation that will be
discussed at the upcoming rating agency meeting. To the extent that any changes are made to such rating
agency presentation subsequent to 5:30 p.m. central standard time on the day immediately preceding the
day on which the applicable rating agency meeting shall be held, Developer shall notify TxDOT prior to
the presentation to such rating agency. TxDOT shall have the right to comment on the rating agency
presentation described in this Section 1.13.
1.14
Credit Enhancement. Developer shall determine whether to obtain third party credit
enhancement of a bond issuance, and if such credit enhancement is to be obtained or included, Developer
shall select and engage the provider of such enhancement. Developer shall also negotiate all arrangements
with the enhancement provider, but shall keep the Corporation informed of such negotiations and respond
to the Corporation’s reasonable requests regarding information provided to the enhancement provider.
1.15
Bond Documents Control. At the time any bonds are issued the provisions of the Bond
Documents for such issuance shall control over the provisions of this Agreement in the case of any
conflict.
1.16
Term of Agreement. The term of this Agreement shall extend from the date it has been executed
by each of the three parties hereto until the issuance of all of the bonds to be issued by the Corporation
hereunder and under the CDA (including the Project Plan of Finance (as defined in the CDA)) for the
Project, unless otherwise earlier terminated by agreement of all three parties hereto.
Texas Department of Transportation
SH 288 Toll Lanes Project in Harris County
December 18, 2014
-4-
Addendum #8 to Request for Proposals
Instructions to Proposers, Form T
1.17
Indemnity. Developer, to the reasonable satisfaction of the Corporation, shall, in the Bond
Documents, provide customary indemnification to (a) the State, the Commission, TxDOT, the
Corporation and any of their respective directors, officers, employees and agents in connection with the
issuance of the bonds and (b) the Corporation and its directors, officers, employees and agents in
connection with the Project.
1.18
Bond Approvals. The Corporation shall obtain all required approvals of the Texas Bond Review
Board and the Texas Attorney General. Developer will cooperate as needed at the request of the
Corporation in obtaining such approvals, including attending meetings of the Bond Review Board if
requested by the Corporation and providing information that may be requested by the Bond Review
Board.
ARTICLE 2
DEVELOPER, CORPORATION AND TXDOT
2.1
Corporation Cooperation. The Corporation hereby agrees to work diligently and in good faith
in order to complete any bond financing contemplated herein in accordance with the reasonable timetable
established by Developer, including taking all reasonable measures in order to timely obtain necessary
governmental approvals, to provide for the timely approval of bond documents, issuance of the official
statement and pricing, and to ensure timely scheduling of required public hearings or meetings and the
issuance of related meeting notices in accordance with all legal requirements, taking into account
scheduling concerns of Developer.
2.2
TxDOT Cooperation. TxDOT hereby agrees to cooperate with Developer and the Corporation,
to provide necessary administrative and technical support to the Corporation, and to work diligently and
in good faith to assist in the completion of any bond financing contemplated herein in accordance with the
reasonable timetable established by Developer.
2.3
Developer Cooperation. Developer hereby agrees to cooperate with the Corporation and TxDOT
in all reasonable ways to facilitate the timely completion of actions required to be taken by the
Corporation and TxDOT as part of completing any bond financing contemplated herein.
Signature Page Immediately Follows
Texas Department of Transportation
SH 288 Toll Lanes Project in Harris County
December 18, 2014
-5-
Addendum #8 to Request for Proposals
Instructions to Proposers, Form T
IN WITNESS WHEREOF, the parties hereto have executed this Agreement by their officers
thereunto duly authorized as of the date first written above.
Corporation
Texas Private Activity Bond Surface Transportation Corporation
By:
Name: [●]
Title: [●]
Developer
[●]
By:
Name: [●]
Title: [●]
TxDOT
Texas Department of Transportation
By:
Name: [●]
Title: [●]
Texas Department of Transportation
SH 288 Toll Lanes Project in Harris County
December 18, 2014
-6-
Addendum #8 to Request for Proposals
Instructions to Proposers, Form T
Download