RELATIONAL CONTRACT IN CONSTRUCTION INDUSTRY IN MALAYSIA NURUL ALIFAH BINTI JATARONA A project report submitted in partial fulfillment of the requirements for the award of the degree of Master of Science (Construction Management) Faculty of Civil Engineering Universiti Teknologi Malaysia NOVEMBER, 2007 iii To my beloved father, mother, husband, siblings and friends iv ACKNOWLEDGEMENT Praise is to the Almighty Allah the God of the Universe who gave me chances to live this beautiful life. This piece of work would not become possible without the contributions from many people and organizations. In this segment, I would like to acknowledge each and every person who has contributed their effort in this study by whatever means directly or indirectly. Most importantly, I would like to acknowledge my supervisor, PM Dr. Aminah bt. Md. Yusof for her kind assistance and advice, beneficial criticisms and observations throughout this master project. I would also like to thank the respondents of this study that I had interviewed and asked for help in improving my questionnaire survey form. Their precious comments and ideas have provided me with very useful background data and information. Not forgetting to all the contractors that help me by completing the questionnaire survey, a special thanks to all of you. Your kind and generous help will always be in my mind. Many thanks go to my relatives back home especially to my beloved father and mother, Mr. Jatarona b. Mohd Nor and Mrs. Zainab bt. Kulub M.Nasir. Not to forget, my loving husband, Mr. Mohd Afdhal who has been supported me throughout my study and to all my friends from whom I have received a great deal of support while conducting this research as well as studying at UTM. For the rest of the persons who had not been mention here, who have participated in various ways to ensure my research succeeded, thank you to all of you. v ABSTRACT For many years, the construction industry has relied on formal contracts to define and enforce the obligations and rights of contracting parties. Nonetheless, existing formal contracts are subject to some disadvantages hence and alternative is required to address the issue. The objectives of this study are to study the current practice of construction contract, to analyze problems associated with the application of traditional contract in Malaysia and to appraise the knowledge and the application of Relational Contract in Malaysia. The data used in this study was collected through literature study and questionnaire survey from Class A contractor in Johor Bahru. Data was analyzed using Statistical Package for Social Sciences Software (SPSS) and the results analyses were presented in frequency and average index value. The finding shows that traditional contract has been identified to be the most frequently used contract in Malaysia due to its familiarity to works with but there are problem associated to the traditional contract. Potential barrier such as lack of client knowledge also being identified in this study and lack of client knowledge is found to be the most critical reason in adopting relational contract. The traditional contract can be improved through the incorporation of Relational contract’s element such as clearly defined scope, integrated project team, alignment of goals and open honest communication. It can be concluded that relational contract is still new in Malaysia. Many of the practitioners in the industry are not aware of this approach. However, they agree that some of the elements in relational contract can be adopted in order to overcome the weaknesses in traditional contract. vi ABSTRAK Industri pembinaan di Malaysia buat sekian lama bergantung pada kontrak tradisional dalam mementukan tanggungjawab dan hak pihak –pihak yang berkontrak. Walau bagaimanapun terdapat beberapa kelemahan dalam kontrak sedia ada dan suatu pembaharuan diperlukan dalam menangani isu ini. Objektif yang digaris dalam kajian ini ialah mengkaji jenis kontrak yang digunakan dalam industri pembinaan dalam masa kini, menganalisa masalah yang berkaitan dengan penggunaan kontrak di Malayasia dan untuk mengkaji pengetahuan serta aplikasi Kontrak Perhubungan di Malaysia. Data dalam kajian ini diperoleh daripada kajian literatur dan melalui borang soal selidik. Borang soal selidik ini telah diedarkan kepada kontraktor kelas A di sekitar bandaraya Johor Bahru. Statistical Package for Social Sciences Software (SPSS) telah digunakan dalam menganalisa data-data tersebut. Hasil analisis telah dibuat dengan menggunakan dua kaedah iaitu data frekensi dan nilai purata index. Analisis, kajian menunjukkan bahawa kontrak yang lazim digunakan dalam industri pembinaan adalah kontrak tradisional. Ini kerana kontrak tersebut mudah digunakan. Namun begitu, masih terdapat beberapa kelemahan yang perlu ditangani. Faktor yang menghalang kontrak perhubungan turut dikaji dan didapati faktor utama yang menghalang kontrak perhubungan ini ialah kerana kurangnya pengetahuan berkaitan kontrak tersebut. Elemen dalam kontrak perhubungan seperti penerangan skop yang jelas, intergrasi dainatra pihak berkontrak, matlamat yang sama bagi setiap pihak dalam sesuatu projek serta mengamalkan komunikasi yang telus dilihat dapat menangani kelemahan dalam kontrak tradisional. Kesimpulannya, kontrak perhubungan ini masih baru di Malaysia dan kebanyakan pihak tidak mengetahui tentang penggunaannya. Walaubagaimanapun kebanyakannya bersetuju bahawa terdapat beberapa elemen didalam kontrak perhubungan yang sesuai digunakan dalam menangani kelemahan kontrak tradisional ini. vii TABLE OF CONTENTS CHAPTER 1 2 TITLE PAGE DECLARATION ii DEDICATION iii ACKNOWLEDGEMENTS iv ABSTRACT v ABSTRAK vi TABLE OF CONTENTS viii LIST OF TABLES xii LIST OF FIGURES xiii INTRODUCTION 1 1.1 Problem Statement 3 1.2 Aim and objectives 4 1.3 Research Methodology 5 1.4 Scope of Study 7 1.5 Importance of this Study 7 1.6 Conclusion 8 CONSTRUCTION CONTRACT 9 2.1 Introduction 9 2.2 Current Practice in Malaysia 9 2.3 Types of Contract Procurement used in Malaysia 10 2.3.1 Traditional Contract 11 2.3.2 Design and Build Contract 13 2.3.3 Management Contract 14 viii 2.4 2.3.4 Construction Management 14 2.3.5 Hybrid 15 2.3.6 Miscellaneous Contracts 16 2.3.7 Term Contract 18 2.3.8 Selection Preferences Type of Contract 18 Traditional Contract 19 2.4.1 Why use Traditional Contract? 19 2.4.2 Criticism on Traditional Contract 21 2.4.3 Advantages and Disadvantages of 27 Traditional Contract 2.4.4 2.5 3 4 Limitation on Traditional Contract Conclusion 30 31 RELATIONAL CONTRACT 32 3.1 Introduction 32 3.2 Relational Contract 32 3.3 Benefits of Relationship Based Contract 35 3.4 Potential Barriers to Adopting Relational Contract 37 3.5 Paradigm Shift from Traditional To Relational Contract 39 3.6 The use of Traditional Contract in Malaysia 40 3.7 Conclusion 41 METHODOLOGY 42 4.1 Introduction 42 4.2 Literature Review 42 4.3 Develop Questionnaire 43 4.4 Survey 44 4.5 Data Analysis 45 4.5.1 Frequency Analysis 45 4.5.2 Average Index Analysis 46 4.6 Conclusion 47 ix 5 PRELIMINARIES ANALYSIS 48 5.1 Introduction 48 5.2 Data Collection 49 5.3 Respondent Background 50 5.3.1 Gender Distribution 50 5.3.2 Age Distribution 51 5.3.3 Position Distribution 52 5.3.4 Experience Distribution 53 5.4 6 Conclusion 54 ANALYSIS AND DISCUSSION 55 6.1 Introduction 55 6.2 Traditional Contract 56 6.2.1 Contract that is regularly used 56 6.2.2 Problems with Traditional Contract 57 6.3 Relational Contracts 64 6.3.1 Knowledge on Relational Contract 64 6.3.2 Potential Barrier in adopting Relational 65 Contract 6.3.3 6.4 7 Element to be added in Traditional Contract 68 Conclusion 72 CONCLUSION AND RECOMMENDATION 73 7.1 Introduction 73 7.2 Objectives 73 7.2.1 Objective 1: To study the current study of 74 Construction Contract 7.2.2 Objective 2: To analyzed problems 74 Associated with the application of Traditional Contract in Malaysia 7.2.3 Objective 3: To appraise the knowledge and the application of relational contract In Malaysia 75 x 7.2.4 Objective 4: To recommend an 75 improvisation of traditional contract through Relational Contract elements 7.3 Conclusion 76 7.4 Recommendations for further study 76 REFERENCES AND BIBLIOGRAPHY 77 xi LIST OF TABLES TABLE NO TITLE PAGE 3.1 Attitudes and Behaviors 37 4.1 The level of Agree for Average Index Analysis 45 6.1 Analyses on Problem with Traditional Contract 57 6.2 Analysis on Potential Barrier in Adopting Relational 65 Contract 6.3 Analysis on added factors for Traditional Contract 68 xii LIST OF FIGURES FIGURE NO TITLE PAGE 1.1 Methodology flow chart 6 2.1 Traditional Delivering Method 11 2.2 Stages in traditional method in delivering project 11 3.1 Partnering / Alliance Curve 38 5.1 Responses Percentage 48 5.2 The percentage of Gender Distribution 49 5.3 The Percentage of Age Distribution 50 5.4 The Percentage of Respondent Position in the company 51 5.5 The Percentage of Respondent Experience Distribution 52 6.1 The practice of contract procurement in the construction 55 Industry 6.2 Problem with traditional contract 56 6.3 Critical Problem with Traditional Contract 60 6.4 Problems with traditional contract: Less critical 62 6.5 Distribution of having problem with Traditional Contract 64 6.6 Potential Barrier in adopting Relational Contract 66 6.7 Element to be added in Relational Contract 68 CHAPTER I INTRODUCTION 1.0 Background of the study Construction projects are undertaken by many parties, all with their own goals and motivations which may not always be aligned. The alignment is normally pursued through a contract between parties which aim at achieving are commonly agreed goals. A contract is a voluntary agreement between two or more parties, and the purpose of a contract is to set out the rights, responsibilities, and liabilities of the parties. The contract allocates risk among the parties. Contracts may be formal and written, with fairly explicit described behaviors and understanding. Years of legal analysis and substantial experience have gone into drafting and fine-tuning the standard forms of contract that are commercially available. Nonetheless, they are not perfect for every project or every party. Different groups of contracting parties, and also people within the same group, interpret contract clauses in different ways. For that reason, many contracts are custom made to suit individuals and projects. The contractual interrelationship between parties to a construction project will often determine what remedies are available as well as allocation of responsibility and liability. Furthermore, they are governed by contracts, which do not necessarily produce win-win outcomes. In Malaysia there are two type of contract that is commonly used which are traditional contract and design and build contract. In traditional contract method, contractor agrees to build the design that provided by the client. The contractor only has responsibility for construction and 2 not for design. Design and Build comes in various forms but is typified by the contractor taking both design and construction responsibility. In integrated D&B contracting the contractor develops the design and constructs the building based on a set of requirements provided by the employer. However recently there is a new approach in contracting in Malaysia construction industry which is relationship contracting. Implementation of traditional contracting systems in construction industries frequently lead to confrontations and unresolved issues associated with different commercial alignment of individual parties. Hence, the modern type of contracting systems emerges, hoping to replace and sealed up the adversarial traditional style of management. According to a publication by Alan McLennan Strategic Services, an alliance network company in Australia, relationship contracting is a term applied to contracting arrangement where management of relationship is given precedence over the dictate of a standard form of contract. It is a strategic alliance between organisations to achieve mutual benefits. Relationship contracting is based on trust, appropriate risk allocation, teamwork, sharing of profit or loss and most importantly the alignment of goals. Basically, relationship contracting falls into two broad categories. They are either project based or long term strategic alliance. Project based contracts are commonly known as project-specific partnering and the arrangement will last until the end of the project. The arrangement is between the principal and a few contractors. The other form would be a long-term partnering or more likely to be termed as alliancing because it usually last for years between the principle and the main contractor. 3 1.1 Problem Statement In traditional contracts, contractual and flexibilities that are required in ever changing construction scenarios are not supported in order to face uncertainty and complexity. These include split responsibility between construction and design. This can and unfortunately often does lead to disputes about whether defects are really design defects (for which the employer is responsible) or defects in materials and workmanship (for which the contractor is responsible). The other major disadvantage of this route is that the final design is often not fully developed before construction starts and this can create problems and price uncertainty. This can make general contracting unsuitable for public bodies with budgetary constraints. The traditional form of contracts emphasizes the separation of roles in the parties involved and a rather unbalance allocation of risks. The standard form of contract encourages self-interest and protection of individual positions (McLennan). It handles the contracts in a mechanical ways, indicating the time span, obligations and other notices in writing. It ignores some of the crucial aspects dealing with behaviors and commitments such as trust, honesty, fair dealing, good faith and open communication. According to Scott (2001), the limitations of traditional contracting are: · Misalignment between the owner and the individual contractors · Misalignment between the individual contractors · Lack of access to the contractors’ skills and expertise at a time when they can best and most influence the eventual outcome Traditional contracting tends to escalate the project time and targeted cost due to unforeseen circumstances such as dispute between client and contractors. Moreover, the contractors have no interest or intention to reduce the overall project cost and construction schedule. There is no incentive or benefit for them to gain. 4 On the other hand, relationship contracting offers an approach to encourage cost savings and reduction in construction time through systematic contracting procedures. At worst, it contains schedule overruns and cost. The relationship based contracts is designed to overcome the limitation of traditional contracting. It opens up the doorway to continuous improvement in performance, communication, trust, risk management and future collaboration. Relationship contracting is founded on the principle that there is a mutual benefit to he client and the contractor to deliver the project at the lowest cost – when cost increases both the contractor and the client are worse off (Sai On Cheung etc.). The core values of the relationship rely upon commitment, trust, respect, innovation, fairness and enthusiasm. What is actually meant by relational contract and how its application could help to ease current dilemma in construction contract. Do the contracting parties have substantial knowledge on relational contract and to what extend its application in Malaysia? A study should be carried out to investigate these statements. 1.2 Aims and Objective The aim of the study is to investigate problem in pursuing traditional contracts with the view of introducing relational contract in construction practice. The aim is supported by the following objectives: (i) To study the current practice of construction contract. (ii) To analyze problems associated with the application of traditional contract in Malaysia (iii) To appraise the knowledge and the application of Relational Contract in Malaysia. (iv) To recommend an improvisation of traditional contract through relational contract’s elements 5 1.3 Research Methodology Research methodology starts with problem formulation which consists of identifying area of study and selection of topics. Relational Contract in Malaysia has been chosen as the area of this study. After identify the area of this study, aim and objectives of this study were set. Then, literature review work been carried out involving a through searching and investigating relational contract related issues through different primary and secondary sources such as textbooks, articles, journals, papers and international conference paper. In additional, there also effort on searching and browsing through internet web pages, internet websites, online library, electronic database and online articles and journals to seek for supplementary information. The purpose of the literature review was to gather important information related to the topic and deepen the understanding of relational contract, the advantages and potential barrier in adopting it in the construction industry. Based on the literature review work, a questionnaire was developed. There were five sections in the questionnaire contains of questions related on problems in traditional contract and relational issue. Each section in the questionnaire required respondent to answered questions that gives information required for the study. Then, the questionnaire has been distributed to Class A contractors in Johor Bahru area. Out of 44 questionnaires distributed, only 22 questionnaires returned. Returned questionnaire has been analysed by using software namely Statistical Package for Social Sciences Software (SPSS). In the analysis, two method has been used which is Frequency Analysis and Average Index Analysis. Based on the analysis, findings were obtained and a conclusion was derived based on the results. Findings and conclusion must be referred and answered the aim and objective that has been set before. Figure 1.1 shows the methodology flow chart of this study. 6 Problem Formulation Identify area of study Selection of topic Aim & Objectives Literature Review • Magazine • Journal • Internet • Article • Book Questionnaire Analysis Statistical Package for Social Sciences Software (SPSS) Finding 1 Finding 2 Finding 3 Conclusion Figure 1.1: Methodology Flow Chart Finding 4 7 1.4 Scope of Study (i) This research study on the current contract practice in Malaysia. It also will cover the problem occurs in traditional contracting practice. (ii) Further, it will cover on how the relational contract could overcome the weakness of current contract. (iii) The study is mainly to investigate the acceptability and knowledge of relational contract in Malaysia (iv) The questionnaire will be conducted in Johor Bahru. (v) Respondent of this study is from Class A Contractor. (vi) Analysis that is going to be used for this study is Statistical Package for Social Sciences Software (SPSS). 1.5 Importance of this study The importance of this study is to know the current contract procurement that is regularly used in the industry. This information is important in order to see the pattern in contracting whether there is any development or new criteria stated by the client in choosing type of procurement. Furthermore, problem in current contract used is identified through this study and improvisation can be made by introducing the new philosophy in contracting. Relational Contract is introduced to the industry and their acceptance is studied. 8 1.6 Conclusion This chapter has illustrated in details on fundamental of the study. In this chapter, background of the study was discussed in detailed. The natures of construction industry were illustrated. The following sub-section is on problem statement where problems in the traditional contract have been illustrated. Aim and objective were defined in this chapter. There four objective that has been outlined. Research methodology of this studies also being discussed. There also limitation in the study. Those limitations have been outlined in scope of study. Lastly is on the importance of the study. CHAPTER II CONSTRUCTION CONTRACTS 2.1 Introduction In the previous chapter, the discussion was on the aim and objective of the study, problem statement, method used in this study, scope of this study and the importance of the study. Thus chapter will deal with construction contract. This chapter is divided into three sub-sections which will discuss current practice in Malaysia, types of contract procurement used in Malaysia and traditional contract detail. The following sub-section will examine current practice in Malaysia. 2.2 Current practise in Malaysia In Malaysia there are generally three category of procurement system being adopted which are separated and co-operative procurement system, where the responsibility for the design and construction aspects of the project are the responsibility of separates organization. This kind of procurement is known as Traditional Contract. Another procurement method are integrated procurement system, where design and construction become the responsibility of the organization, usually a contractor and the owner only has one organization to deal with. This procurement are known as design and built contract. 10 Last category of procurement is management oriented procurement. This contract emphasize on overall management of the design and construction of the project, with the latter element usually carried out by works or package contractors and the management contractor having the status and the responsibility of a consultant. However this management contract are no longer been used in Malaysia as it is cause a lots of problem and the government of Malaysia has decided not to used it for further project undertaking. Out of these three categories, there are numerous variant formed by different arrangements between the owner and the contractor. As it is commonly found in Malaysia, the procurement system is very much related to the contractual arrangement between owner and the contractor. This arrangement is dictated by the standard form of contract used. The typical forms are JKR 203, PAM, ICE, FIDIC and some bigger corporation such as TELEKOM, TENAGA NASIONAL, PERBADANAN PUTRAJAYA and PETRONAS are using their own forms. These forms might have been used as result of default, as compared with other procurement systems. There are several types of construction procurement in Malaysia. These are discussed in the following section. 2.3 Types of Contract Procurement used in Malaysia Common types of construction procurement used in Malaysia were traditional contract, design and build contract, management contract, construction management, hybrids contract and miscellaneous contract. Each of the contracts will be illustrated in detail in the following sub-section. 11 2.3.1 Traditional Contract Traditional contract is known to be the most popular procurement used in construction industry in Malaysia. This sub-section explores traditional method. Most of the government tender used traditional contract in their projects. According to Stephen Wearne (1997), the same scenario happened in North America, the UK and other industrialized and developing countries where one main contractor is employed to construct a project. In traditional contract, the owner has separate contract with the both the designer and the general contractor. There is no contractual relationship between the designer and the general contractor. In this delivering method, the design is typically completed before the contractor is hired. It is the contractor’s project manager responsibility to obtain the project plans and specifications, developing a cost estimate and project schedule for construction, established a project management system in order to manage the construction activities and managing the construction. The traditional delivery method is illustrated in Figure 2.1 and a stage in traditional method in delivering project is shown in Figure 2.2. The method is widely used as it has been in the practice for a long time. As the technique is subject to some weaknesses, the Design and build has been introduced. It is discussed in the following sub-section. 12 OWNER GENERAL CONTRACTOR DESIGNER CONSULTANT SUBCONTRACTOR Figure 2.1: Traditional Delivery Method Brief Feasibility study Scheme Design Production Design Tender Construction Occupation Financial commitment Low Low Moderate Moderate High Figure 2.2: Stages in Traditional method in delivering project 13 2.3.2 Design and Build Contract A design and build contract also known as a ‘package deal’ or ‘turnkey contract’ is one under which contractor undertakes both designing and constructing the contract works, which are to be completed in such a way to meet the requirement of the employer. According to Janssens (1991), design and build building procurement whereby the contractor who constructs the works, also undertake all of, or a portion of the design of the work. Unlike many other contractual arrangements, Design and Build requires the contractor to undertake design for the project. This contract requires the contractor to be responsible for both design and construct part. However, contractors have three major methods to discharge their design responsibilities; by employing in-house designers, engaging external consultants or a mixture of both. Based on the studies done by Y.Y Ling (1998), whether they employed in-house designers or external consultant does not make a huge difference to the project delivering. The most important is the attitude of the Design and Build contractor who is the project leader. Therefore, leadership of the contractor is more important than the procurement route adopted. Besides leadership, an experience in Design and Build project is another important factor in determining the performances of designers. There is also development in construction contract due to growth in construction project. There is an emergence need to have a management contract as it seem to be difficult for the contractor to manage the construction part and management part. This contract will be discussed in the following topics. 14 2.3.3 Management Contracting A comparatively recent development on large and complex projects has been the emergence of the ‘management contractor’ whose only role is to manage, coordinate and supervise the work of numerous specialist by whom the whole of the construction work is carried out. Under a modern management contract, these specialists are employed as subcontractor to the main or management contractor but the latter is relieved of any responsibility to the employer for subcontractor defaults. The underlying philosophy of this type of procurement is that the management of the construction process constitutes a particular expertise which can be distinctly identified and accordingly addressed through the employment of the management contractor. Compared to traditional general contracting and design and build types of contracts, management contracting is unfortunately deficient in the availability of standard forms of conditions of contract. In Malaysia, no particular authority, institution or body has published any such form. 2.3.4 Construction Management Construction management contracts are sub-set of the general corpus of management type of contracts and as such share common characteristics with management contracts. These have metamorphosed recently into an alternatively to the latter type of contract and are being employed mainly on large and complex projects having multiplicity of trades, user and designers. In essence, a construction management contract is an arrangement under which the employer enters into a direct contractual relationship with each of the specialist contractors, while at the same time employing a ‘construction manager’ to provide managerial and supervisory services for the project. The obligations undertaken by the construction manager in such a case depend upon the terms of the contract by which he is employed. In addition to traditional, design and build, 15 management contract and construction management, there is hybrid approach to procurement system. 2.3.5 Hybrids In addition to the main types of contract strategy as described before, there have also hybrids such as: (i) ‘Develop and construct’ contract: This is similar to a design and build contract, but a concept design is prepared by independent professionals engaged by the employer before the design and build contractor is selected. (ii) Design and Manage Contract: This is similar to a management contract, but the contractor is also responsible for detailed design or for managing the design process. (iii) ‘Design and Construction Management’ Contract: This is similar to construction management but the construction manager is also responsible for detailed design or for managing the design process. There are no published standard form contracts governing any of the above hybrids and the practice is to employ ‘ad hoc’ or ‘bespoke’ forms customize for the particular project or application. In construction industry, there also contract that are being utilized by the industry. Those contracts are stated under miscellaneous contract that will be illustrated in the following sub-section. 16 2.3.6 Miscellaneous Contracts Over and above the common methods of contract procurement describe above, there exist other types of contracts that are being utilized by the local construction industry. These are essentially variations of the conventional methods and have been developed to address specific uses. Such contract include as bellows: (i) ‘Build, Operate and Transfer Contract’: This is a type of privately financed contract whereby the contractor finances the project, designs it, undertakes the construction owns and operates it over the concession period and on its expiry transfers the beneficial ownership of the project back to the employer. (ii) ‘Serial Contract’: This is a contract resulting from a procedure called ‘serial tendering’. Fundamentally, a serial tender is a standing offer to carry out work for more than one project in accordance with the tender submitted for the initial project or based on hypothetical bills of quantities representing the average project of a series. (iii) Continuation Contract: This is an ad hoc arrangement to extend the scope of the initial or original contract beyond its original contract domain. For example, if there is no standing offer to do more work than that originally envisaged. The original and continuation contract are dealt with separately. If and when the latter arises, the original contract may be used as a basis for realizing the continuation contract. 17 (iv) Periodic Contract: This is similar to a term contract, but the execution of work or supply of goods is required at intervals, regularly or on demand rather than being continuous for a stated time. (v) Partnering Contract: This contract is in essence an extension to the normal serial contract whereby over a predetermined period of time, the contractor automatically receives all new contracts from the employer with payment to be made by reference to an initially agreed formula. (vi) Independent Contract This is essentially a contract for services whereby the party undertaking a stipulated task for an agreed consideration is free to select his own mode of doing it. He is either under the control or direction of the other. There are no published local standard forms of conditions of contract governing the above miscellaneous contracts and use is made of ‘ad hoc’ or ‘bespoke’ form. There another type of contract called as term contract. Term contract is a contract used for minor work during a specific time. This type of contract is discussed in the last sub-section under types of procurement used in Malaysia in the following sub-section. 2.3.7 Term Contract A ‘term contract’ is one by which an employer seeks to make a provision for the carrying out of certain categories of work (usually minor work of alteration or repair and/or maintenance) during specified period of time. Depending upon the 18 term on which tenders are invited and accepted, the resulting legal relationship may be a contract which binds the contractor to carry out whatever work of the specified description the employer chooses to order during period stated. Alternatively, the acceptance of a tender may result in a ‘standing offer’ by the contractor, which ripens into a contract on each occasion that an order is placed but which may be revoked at any time. At the moment, there is no local standard form of conditions of contract for a term contract though there is a tendency to either modify the JCT Standard form of measured term contract (1998 Edition) or to generate ‘bespoke’ forms. As been discussed in the topics before, there is many type of construction contract used in Malaysia. Contractor may choose any of the contracts above in their project. However, there is a selection criteria outlined in previous study. Those outline and the reason why the contractors choose to use certain contract is discussed in next sub-section. 2.3.8 Selection preferences type of contract The uncertainties in the construction industry are generated by some of the construction projects exceeding their time and cost budgets. At the time when the cost of building and of borrowing money regarded as high, clients are less willing to tolerate such uncertainties. Although cost, time and quality are the three most important considerations, the business of building procurement invariability calls for some compromise or conscious balancing of these priorities. A study has been conducted by Maizon Hashim (1998), on the client criteria on the choice of procurement system in Malaysia. The result of these studies shows that clients who want to control the design and variations to a large extent in their project will follow the traditional procurement path. 19 Client who wants a relatively fast method for their project will take the design and build procurement path as the construction time is reduced because the design and build will proceed in parallel and there is also a guaranteed cost and completion date. Clients who want to modify or develop the design requirements during construction will take the management contracting procurement path because they can adjust the programmed and costs for their projects. It can be concluded that whatever method of procurement is used, the client ought to make clear to the tendering contractor what the objectives of the project are and how they relate to one another. As the traditional contract is said to be the most used contract procurement in Malaysia, the next sub-section is going to give a clear view on traditional contract in order to deepen the knowledge in this type of contract. 2.4 Traditional Contract There has been many reasons to why the preferences to adopt different type of contract in construction. The following section illustrates why traditional contract is still being used by the industry although there is many other contract in the industry. The criticism on traditional contract is also being illustrated deeply in this sub-section. Furthermore, advantages, disadvantages and its limitation also being discussed. 2.4.1 Why used Traditional Contract? The traditional procurement system is predominant in the Malaysian construction industry and, until 1992 at least, able to satisfy its requirements (Masterman, 1992). As is well known, it is characterized by the contractor not being responsible for the design or the documentation work (e.g. Goldfayl, 1999, Rwelamila and Meyer 1999) and with a clear division between the design and construction process responsibilities (Rowlinson, 1999, Martin, 2000). Also, each phase in the traditional system is separate (Tenah, 2001, Walker and Hampson, 20 2003), with the design and construction processes being quite different (Wearne 1997). Each phase also contains different stages. The design development phase, for example, comprises project briefing, feasibility studies, outline proposals, scheme design and detail design (Smith, 1998). The reasons for the system’s continuance are obvious to many observers: (i) It exploits the economic potential of the free market by enabling contractors to be selected either by open or select competition among an unlimited number of pre-qualified competitors (Rowlinson, 1999). (ii) The separation of design and construction appointment and service provision C effectively restricts the amount of opportunistic business behavior of those involved until the design is completed. (iii) Considerable flexibility is allowed for unforeseen events occurring during the construction phase, e.g., ground conditions, changes in scope and design, and errors in documentation (e.g., Turner, 1990; Goldfayl, 1999; Walker and Hampson, 2003). (iv) It is a ‘value for money’ delivery system which employs participants with different talents and combines these talents into a business relationship to produce the desired results with greater certainty (Rowlinson, 1999). As been illustrated before, it is undoubtedly that traditional contract is the best contract used. However, behind these reasons, there’s also criticism made on traditional contract. Criticism on traditional contract will be illustrated in the next sub-section. 21 2.4.2 Criticism on Traditional Contract The traditional system has, however, been declining noticeably in popularity in Malaysia in recent years (Tan, 2001). The same has also been noted in many countries (Mo and Ng 1997) - a particular criticism being that it is unable to cope with the complexity and dynamic nature of the current construction industry (Rwelamila and Meyer 1999). The paper, reports an exploratory survey conducted in Malaysia to ascertain the reasons for this decline. In particular, the concern are with four major criticisms of the traditional system identified in the literature: a) Time consuming aspects of the development processes b) The effect of cost uncertainty c) The effect on buildability d) Fragmentation of organisational interfaces a) Time consuming aspects of the development processes A 1997 survey showed only 54% of the clients in Malaysia to be satisfied with the completion time for traditionally procured projects (Hashim, 1997). This may be partly attributed to the complexity in designing modern buildings (Newcombe, 1996). The traditional system, however, has also been continuously identified as the slowest method of procuring construction projects available to a client (Masterman, 1992, Chang and Ive, 2002). It is said to be the most convoluted and inefficient in Malaysia (Tan cited in Hashim, 1997) and elsewhere (Rowlinson, 1999). One reason given for this is that the traditional system is a sequential process (Masterman, 1992). The construction phase, for example, should not begin until the design is completed. However, the preparation and approval of drawings, and the mistakes 22 and discrepancies found in the design documents are frequent causes of delay in the design phase (Chan and Kumaraswamy, 1997). As a result, whole development process is lengthened (Turner 1990). Similarly, when the design team permits the client to postpone the briefing decisions until the later stages, this results in key time delays – again causing the whole project to be delayed (Barnes cited in Chan and Kumaraswamy, 1996). Of course, the effects of delays are well documented: severe criticism arises when projects run far longer than planned and legal disputes always arise over how much responsibility each party is willing to take for delays (Chan and Kumaraswamy, 1996; Tenah, 2001); the developer may be forced to sell or lease the building to cover the interest incurred (Hashim, 1997); although extensions of time may help the contractor, the initial completion date of the project is still affected with concomitant affects on the client (The Aqua Group, 1996); impacts on inflation, where the final cost of large projects is much more than the first estimation (Taylor et al 1999); etc. In an attempt to overcome these problems, the time made available for the design phase is often reduced to below what is regarded by many practitioners as a reasonable minimum (e.g., Emmitt, 1997). As a result, the design documents are said to be “inevitably incomplete” (Yates, 2002; Walker and Hampson, 2003). Errors also regularly occur in the form of differences in dimensions between plans and sections, incorrect dimensioning of walls and openings between the drawings and on-site (Ogunlana et al 1996). In many cases, project designs and bills of quantities are not prepared before the contractor is selected due to the lack of design information available (Masterman, 1992; Rwelamila and Meyer, 1999). Far from saving time overall, therefore, this inevitably results in delays in the construction phase due to unclear drawings and specifications, which prevents contractors planning for the resources required for the work (Chan and Kumaraswamy, 1997). Another implication of a reduced design period is an increase in variations later. Variations are not only a source of annoyance in terms of time and cost (Bromilow cited in Chan and Kumaraswamy, 1997) but are “a timeconsuming and expensive undertaking” (Hovet, 1994). They also always lead to poor 23 on-time performance (Chan and Kumaraswamy, 1996). Based on the reasons listed above it is showed that development process in traditional do takes longer time. b) The effect of cost uncertainty An associated issue concerns cost uncertainty. Although the description of ‘lump sum price’ under the traditional system seems to imply that the cost of the project will be the amount of the accepted tender, this is rarely the case in practice (Cooke, 2001). As Rowlinson (1999) and Turner (1990) point out, there is cost certainty only at the beginning stage of the construction process - no one actually knows the final construction project price until the project has been completed (Hovet, 1994). In short, although a traditional lump sum tender may give the lowest tender price, it may not result in the lowest overall construction cost. Because of the long period of time taken to design, document and tender, there are inevitably significant changes in the market forces, tender prices, interest and inflation rates (Lavender, 1990; Turner, 1990). Price fluctuations in construction materials have also been found to be particularly significant in economically unstable countries (Akinci and Fischer, 1998; The Aqua Group, 1999; Kayode cited in Akpan and Igwe, 2001). For most projects, however, variations that occur during the construction phase have the most significant and inevitable effect on final cost (Kumaraswamy and Walker, 1999; Rowlinson, 1999; Rwelamila and Meyer, 1999; Akpan and Igwe, 2001). The variations result in many extra claims (Morledge, 2002) and are often “very expensive” (Lavender, 1990). “Scope growth” during the construction phase has been identified as a particular problem, with the majority of cost increase being derived from this source (Akinci and Fischer, 1998) From the clients’ point of view, contractors are seeking opportunities to create profit and additional revenue (Yates, 2002) and variations provide such an opportunity. Also, variations cause confrontational disputes over 24 what might be a fair price for a project (Walker and Hampson, 2003). In fact, it is this very issue of increased claims by low bidders that is said to be one of the reasons for the increased usage of the design and construct system (Molenaar et al 1999). c) The effect on buildability What looks good on paper or the computer screen can be difficult to build and designs are sometimes impractical (Tenah, 2001). As mentioned earlier, this can result in variations initiated by either clients or contractors. Buildability, as “the extent to which the design of a building facilitates ease of construction, subject to the overall requirements for the completed building” is considered to be underprovided for most construction projects (CIRIA cited in Low 2001). It is said that clients are dissatisfied with building designs which do not provide value for money, in terms of constructability (Low and Abeyegoonasekera, 2001); their new facilities can be difficult to operate and expensive to maintain (Markus, 1997); productivity levels become difficult to raise and there is “incapacity to handle current realities” (Kumaraswamy and Dulaimi, 200); and that the neglect of buildability is just not sustainable in the long term (Barker, 1998). This also points to the conclusion that the lowest initial cost is not necessarily the most cost effective option or provides the greatest return. It is incumbent on designers, therefore, to incorporate buildability into their designs. To do this, it is obvious that contractors need to be involved in the design phase in order to maximise buildability, as they know the significant variables affecting their ability to complete projects within a given budget and schedule and to an acceptable level of quality (Walker and Hampson, 2003; Ling, et al 2004). With the traditional system, however, the contractor’s input into the design process is “minimal” and “often nil” (Rowlinson, 1999). With this separation of contractors from the design development stage, therefore, the opportunity to incorporate buildability into the design is largely lost (Masterman, 1992; Walker and Hampson, 2003) and clients cannot receive the best possible design solution (Love et al 1997). Additionally, architects, who are seen to be traditionally the leader of the construction process, seem unwilling to give contractors the leadership of this process (Dulaimi et al 2004). 25 In reality, however, each project participant in the traditional system is a separate entity and there is no overall management and coordination in this system (Tenah, 2001). It is also said that it is difficult for the architect to exercise objectivity in his/her decisions (Turner, 1990). Moreover, the abilities of architects to manage projects have been questioned over the past two decades (Masterman, 1992) and a better solution may be to involve the contractor more in the process. Furthermore, one of the major problems in the traditional system is thought to be that it pushes the budget setting responsibility onto the clients and the design consultants (Masterman, 1992; Hovet, 1994). Again, this points to the possible benefits from involving the contractor more closely in the process. d) Fragmentation of organizational interfaces It has been observed that the traditional system does not create a unified team in which experience, feedback, and new ideas are shared (Tenah, 2001), with team members often not putting the clients’ requirements as their first priority (Smith, 1998) - resulting in completed projects that are not fully responsive to the client’s needs (Markus, 1997). The separation of design and construction is an obvious cause of this. In an organisational context, this separation extends into the various sub processes involved also. For a large construction project, these sub processes can be extensive with a concomitant effect on relationships (Harmon, 2003). This situation, termed the fragmentation of organisation interfaces, has been held to be a major weakness in the traditional system (Love et al, 1997). As has been observed by many commentators, a particular problem associated with the fragmentation of organisation interfaces within the traditional system is the tendency towards adversarial relationships (e.g., McDermott, 1999). This is said to arise predominantly because of the separation of the design and construction teams (e.g., Turner, 1990) - a situation viewed as one of “fragmentation, friction and mistrust” (Newcombe, 1997), with the gap between design and construction contributing to “major behavioural, cultural and organisational differences between project 26 individuals and groups” (Love et al, 1997). It is argued, for example, that the architect and other key members of the design team fail to provide essential management to coordinate the overall process of planning, design and construction (Turner, 1990). Similarly, the rush to complete the design often creates problems in coordination between the project team members (Ogunlana et al, 1996). As a result it has been suggested that communication problems can be reduced through the design and construct procurement system, for example, because of the reduced number of communication links with this approach (Kashiwagi, 1999). Also, as Kadefors (2002) points out, the client fears that the contractor will scrutinise the contractual documents for errors and ambiguities that may lead to claims, exploit their monopolist position by excessive pricing of extra work, or save money by lowering quality. This client dissatisfaction has also led some researchers to conclude that the traditional system fails to provide an appropriate relationship between the client and the contractor (Ngowi, 1997). The problems caused by fragmentation of organisational interfaces, however, go beyond the separation of design and construction. There are “conflicts, inconsistencies and mismatches” between all the project team members (Hegazy et al, 2001), possibly due to simple misunderstandings or prior assumptions or beliefs (Gardiner and Simmons, 1998). These have often been attributed to communication difficulties caused by either language differences (Ngowi, 1997; Loosemore and Lee, 2002) or differences in the communicating cultures involved (Loosemore and Lee, 2002). Chan and Kumaraswamy (1997), for example, report that inadequate communication among all project team members’ results in problems in project coordination and schedules. Likewise, Murray et al. (2002) found many communication problems at the contractor-subcontractor-architect design interfaces, while poorly communicated design changes have also been noted as leading to costly variations (Zaneldin et al, 2001). In addition, culture has been identified as affecting the degree of uncertainty and anxiety of project participants – these being lower on projects where members of different organisations share the same culture (Ngowi, 1997). 27 An alternative explanation of the source of conflict relates to the hierarchical power structure implicit in the traditional system (Newcombe, 1996; Liu and Fellows, 1999) leading to conflict between the project team members and clients (Newcombe, 1996; Girmscheid and Hartmann, 2002). A further view is that adversarial relationships arise in the traditional system because of the liabilities and penalties on a party who has either done something wrong, or instructed another party to do something wrong (Kumaraswamy and Dulaimi, 2001). The above discussion had shown the weakness of traditional approach. Despite these weaknesses, the traditional contract possesses some advantages which explain in the following sub-section. 2.4.3 Advantages and disadvantages of traditional contract Traditional contract is still the most popular procurement in Malaysia and other developing countries as it is a well known contract. The credibility of this contract is well known. The advantages are listed below: Tenders are on a like-for-like basis Scheme fully pre-designed and specified Early commitment to maximum price Reduced estimating risk (and therefore cost to Employer) Provides contractually agreed prices for valuation of variations, cost control and analysis 28 Standards are easier to control Two-stage tendering allows Contractor to have input in to design and buildability and helps team-building, thereby helping avoid future adversarial attitudes Several ready made contracts available for use depending on size and complexity of the scheme and the pre-construction design timescale available - cost plus, activity schedule, bills of quantities (full or approximate). However, Tan (1985) viewed the traditional method of project implementation in Malaysia as being too lengthy; it needs a radical overhaul and restructing to make the process faster and more efficient. This method today, is taking severe battering from all quarters and the most severe complaints are coming from their clients themselves. Nonetheless as the projects become larger and more complex and also the requirement of the client change, this method has come under increasing attack due to cost and time overruns. Allan McLennan and Graham Scott (2002) viewed many of the current procurement method and delivering systems of building and other construction projects are not sustainable. On the contrary, those methods are demonstrably inequitable, adversarial, ineffective and inefficient and consequently fail to achieve the outcomes sought by the major parties involved. Due to those factors the construction industry is significantly under performing and its contribution to the economy in general and to the creation of wealth in particular is seriously compromise. This situation is in urgent need for a solution. Through Allan McLennan and Graham Scott (2002) observation, particularly over the last decade show that: 29 Unpredictable and excessive cost over runs regularly occurs and this makes financial management of infrastructure programs very difficult (40% in some cases; Construction Queensland Report). Poor and unacceptable quality outcomes occur and this includes the unreliable management of quality assurances systems and processes. Poor and inadequate designs are causing contract management difficulties. A low trust, blame culture causes ongoing poor relations and There is a growing waste of emotional and physical energy in adversarial disputes The inevitable conclusion is that there remains a powerful need for reform in the industry. It is noticeable that the traditional way of dealing with the human involvement in contract documentation is characterized by master-servant concepts, hierarchy of decision making authority, bureaucratic rules driven outlook, responsibilities detailed in mechanical way, e.g. compliance with time limits and other like clauses and lastly self interest and self serving provisions. According to those factors it is time to investigate a quantum shift in the way humans interact in the contractual setting. Concept like “good faith”, “fair dealing”, “trust” and “trustworthiness” need to take on specific meaning within contractual agreements. An alternative way of delivering projects is needed in order to overcome the weakness of traditional contract and Relationship contracting seems to be the option to overcome those weaknesses. The disadvantages of traditional approach create the limitation of traditional contract as discussed in the following topic. 30 2.4.4 Limitation of traditional contract Current practice of traditional contracting has some limitations that impact the performance of the project. There are three principle areas identified by Scott (2001) as shown below: Misalignment between the owner and the individual contractors The owner is primarily concerned with the delivery of the project as a whole where as contractors only focus on the completion of the work they are paid for. They have no further interest in the project once their service has been completed. The contractors hardly have any incentive to design and build the project in an economical as well as optimal way. This shows a misalignment between the owner and the contractors as they have separate commercial objectives. Misalignment between contractors Traditional contracting structures often lead to misalignment between individual contractors because each contractor has the financial interest in its own performance only. They do not see any benefits in working proactively to improve the efficiency of the project as a whole. Moreover, the inefficiency of others might allow one to institute claims, blaming the failure to perform of others has caused their inability to fulfill their contractual obligations. 31 Lack of access to contractor expertise The strength and expertise of contractors are rarely effectively utilised by the owner in traditional contracting. The failure to engage key contractors in the early stage imposed potential penalties for the owner such as a more uncertain cost estimates, greater uncertainty in the project execution schedules and less comprehensive knowledge on the total risk profile of the entire project. As all disadvantages and limitations have been recognized, many studies have proposed the alternative as to adopt Relational Contract. Chapter III is discussing further on Relational Contract. 2.5 Conclusion This chapter has been illustrated in detailed on traditional contract. The discussion is on the current practice in Malaysia which has been discussing on how contracting work is done in Malaysia. The next topic is on types of procurement used in Malaysia. In this subsection, seven types of contract have been illustrated. Those contracts were traditional contract, design and build contract, management contracting, construction management, hybrid contract, miscellaneous contracts and the term contract. Selection preferences type of contract preferred by the contractor also has been outlined. The next sub-section is on the traditional contract. The discussion is on the used of traditional contract, the criticism on traditional contract, the advantages and the disadvantages of traditional contract and its limitation. The next chapter will be on Relational Contract. CHAPTER III RELATIONAL CONTRACT 3.1 Introduction Traditional contract has been discussed in detailed in the previous chapter. As been mentioned in that chapter, traditional contract has several disadvantages that lead to some limitation. These limitations can be overcome by applying the relational contract approach. Therefore relational contract will be discussed in detailed in this chapter. This chapter is divided into five sub-section that are relational contract in general, benefits in relational contract, potential barrier in adopting relational contract, paradigm shift from traditional to relational contract and the last one is the use of relational contract in Malaysia. 3.2 Relational Contract Relational contracting (RC) is based on recognition of mutual benefits and win-win scenarios through more cooperative relationships between the parties. RC principles underpin various approaches, such as partnering, alliancing, long-term contracting, joint venturing and other collaborative working arrangements and better risk-sharing mechanisms (Alsagoff and McDermott, 1994; Jones, 2000). According to these RC principles, parties do not strictly adhere to the legal mechanisms 33 provided in specific contracts, but instead operate from a dynamic standpoint within a collective framework of contractual, economic, and behavioral forces (Macaulay, 1963). Relationships between the parties are therefore important, particularly in complex, lengthy, and evolving transactions, as seen in construction projects, where the underlying contractual scenario may change considerably over time. Relational Contract is based on a dynamic relations scenario, all segments (i.e., past, present, and future) of which are interrelated (Macneil, 1974), rather than partitioned as discrete transactions. Proactive measures are suggested for unfolding future transactions as and when they eventualize. Relational Contract provides the means to sustain ongoing does, the need for the contract may be of less importance (Macneil, 1978). Relational Contract considers contracts as promises of doing something in the future, but not all events can be foreseen (discerned or realized), and as all the information needed cannot be perceived completely (collected or measured or quantified) at the time of contracting, mutual future planning is required. This may well give rise to “opportunism” (Lyons and Mehta, 1997) that benefits one party at the expense of other(s) and needs trust and trustworthy behavior (to counteract opportunism) among the parties. A party is trustworthy if it successfully resists opportunism, and trusting if it believes the other party is trustworthy. Mutual trust is a social relation characterized by both parties being both trusting and trustworthy. Two types of trust work as safeguards against opportunism: self-interested trust (SIT) and socially oriented trust (SOT). SIT is forward looking in expecting direct rewards from cooperation in the form of continuing business. On the other hand, SOT is backward looking and based on a history of working relationships and social relations that create shared values, moral positions, and friendships that discourage opportunism, even if the probability of future trade is low (Lyons and Mehta, 1997). This trust is generated through individual motivation and attitudes and also through individual and interorganizational relationships (Fukuyama relations in long and complex contracts 34 by adjustment processes of a more thoroughly transaction-specific, ongoing, administrative kind. This may or may not include an original agreement, and if it 1995), which considerably influences the project outcomes and is critical to the relationships of the contracting parties (Drexler and Larson, 2000). Such trust can sustain cooperative behavior and the envisaged JRM in the face of unforeseen events and emerging problems. Results from recent studies (as discussed in later sections) show that this motivation and attitude are now detectable in the industry. However, while non-legal enforcement mechanisms clearly play a major role in RC, legal mechanisms may also play a part in such exchange arrangements. Equally, more formal (i.e., legal) contractual arrangements are accompanied by supportive non legal mechanisms. This is seen in present construction industry approaches to RC through partnering and alliancing. Project partners work as a team on the basis of a charter that is not legally binding, so that the original contract will take precedence in case any problem is not resolved as partners. RC approaches appear useful in achieving the overall objective, which is to reduce the sum of production and transaction costs (Walker and Chau 1999). RC offers a cost-effective means of encouraging collectively beneficial behavior when transactions are exposed to opportunism, but a fully contingent (or complete) contract is too costly (if not impossible) to specify. In fact, all possible contingencies and their likely outcomes cannot be prepared for, given the many potential permutations. RC is characterized by the subordination of legal requirements and related formal documents to informal agreements in commercial transactions, such as verbal promises, or partnering charters. This mode of governance calls upon all parties to (1) recognize the positive gains from maintaining the business relationship, (2) transcend the hostility, and (3) overcome the uncertainties associated with unforeseen events in order to improve overall efficiency through motivation and improved attitudes. Disagreements are then negotiated toward solutions that do not jeopardize the relationship between the parties. Such objectives and approaches also provide an ideal framework for the joint management of risks (i.e., JRM) that cannot be foreseen or clearly allocated to one 35 party at the outset. Relational contract seem to be the best alternative way in contracting and benefit of this contract that will be illustrated below, strengthen this statement. 3.3 Benefits of Relationship Based Contracts The most important question to be answer with regard to relationship contracting is why. Why there is a need for the client to adopt relationship contracting as compared to traditional contracts? The question could be easily answered by looking at the benefits of using relationship contracting. Benefits offered by relationship contracting as described by ACA (1999): Cost - Optimum project life cycle cost - Reduce capital expenditure costs - Acceptable financial results for both clients and contractors commensurate with their inputs and the risks undertaken by each party - Improve operating performance - “cost of change” curve will be significantly flatter Time - Certainty of project time - Reduced project delivery time Risks - Better management of inherent risks - Clearly defined risk allocation / sharing at outset 36 Relationships - Enhance business relationships - Establishment and achievement of common / aligned goals - Improvement behaviour of the parties to the contract, especially where the contract experiences practical and / or financial difficulties - A greater personal satisfaction for all projects parties - Avenue for repeat business with resulting benefits to clients and contractors Technology / Innovation - Greater incentive and encouragement to innovate in design, technology, systems, processes and techniques - Greater incentive and encouragement to apply the latest technology Optimum standard - Optimum standards of quality, safety, industrial relations, community relations and environmental performance during the project execution and in operation - Development of the industry’s professionals and workforce - Increase industry research and development as a result of improved Financial certainty - World best standards of project delivery - Increase flexibility to match changing project requirements Relational contract approach recognized to be the alternative approach in contracting as it promotes a lot of benefit to the industry. However, there is potential barrier in adopting this approach. That potential barrier is illustrated in the next section. 37 3.4 Potential Barriers to adopting Relational Contract There are several barriers to overcome before the relationship contracting can be successfully implemented. Most clients and contractors are settled in the mindset of the traditional contracting environment that is of course adversarial. Though it might not be the best solution for them but it is within their comfort zone and they are familiar with the terms and obligations within the traditional context. When a relationship contract is to be adopted, they must be committed to adapt to the new changes and embrace the challenges ahead in order to achieve mutual benefits. Table 3.1 shows the summarized form of attitudes and behaviors that the contracting parties should be prepared to face. 38 Table 3.1: Attitudes and Behaviors (Alan McLennan Strategic Services) Before changing into new approach of contracting, there must be an understanding on how the paradigms shift from traditional contract to relational contract. The paradigm shift is illustrated in the next section. 39 3.5 Paradigm Shift from Traditional Contract to Relational Contract Figure 3.1: Partnering / Alliance Curve from Lendrum (2003) Figure 3.1 shows the partnering / alliance curve which represent the phases of shift from a traditional based contracting system to a relationship contracting system. The curve outlines the progression of partnership and their possible impact over time on some crucial performance criteria such as quality of relationship, rate of investment, adding value and competitive advantage. There are basically three phases during the transition process. At the initial stage of a partnering or alliance, all the contract partners have to learn how to trust one other. All their ‘attitudes and behaviors’ as mentioned earlier would need to shift towards a new paradigm, a paradigm that promote credibility and trust. If this fails, the failure of the relationship would be imminent. 40 The building of relationship begins to consolidate if the partnering or alliance sustain through the first phase. After the second phase, the consolidation process would have been completed. The contract partners would be able to see significant improvements in performance and relationships. Not forgetting, partnerships and alliances are dynamic living things whose rate of progress and direction can be changed by myriad internal and external factor (Lendrum, 2003). For this reason, different partnerships and alliances develop at a different rate and the continuous improvement is not linear over time. Understanding the paradigm shift is important as its shows that changes is not easy and need a lots of energy in changing the attitude of contracting parties. However, this approach had shown its successful achievement by employing this new approach. 3.6 The use of Relational Contract in Malaysia The primary purpose of the research project is to develop a system or a method to evaluate the suitability of adopting relationship based contracting system in civil engineering contracts in Malaysia. Relationship contracting is still a new paradigm for many construction firms in Malaysia regardless of their scale. Nevertheless, the successfulness of applying relationship contracting in the construction of the Kuala Lumpur International Airport (KLIA) has proved to be a good start and an excellent example for further consideration of applying such contracting system in future development. Rashid (2002) mentioned that the application of project-based partnering during the construction of KLIA is said to be among the key factors that enable the mega airport project to be completed in record time. More achievement can be achieved by starting adopting relational contract approach. However, the most important thing is that, the industry must ready to accept the changes and willing to sacrifice in term of money and time in learning this new approach. 41 3.7 Conclusion This chapter has been illustrated in detailed on Relational Contract. The discussion is on the relational contract itself, the benefits of the contract, and potential barriers in adopting it, paradigm shift from traditional contract to relational contract and the use of relational contract in Malaysia. The first sub-section which is on relational contract were discussing in detail about relational contract and the element of the contract. Next is on the benefit of relational contract. Benefit on relational has been divided into six items which is cost, time, risk, relationships, technology/innovation and optimum standard. Potential barriers have been illustrated in detail in Table 3.1. Next sub-section is on the paradigm shift from traditional contract to relational contract. Figure 3.1 illustrated the changes in graphic. The used of relational contract also has been discussed. From the discussion, it is found that a few mega projects in Malaysia such as the construction of KLIA (Kuala Lumpur International Airport) is using Relational contract during contracting. The following chapter is on Methodology. CHAPTER IV METHODOLOGY 4.1 Introduction Literature work on Traditional contract and Relational contract has been discussed in detailed in the previous chapter. Method in conducting the whole study is illustrated in this chapter. This chapter is divided into four sub-sections that are literature review, developing questionnaire, data collection and data analysis. All sub-section is discussed in detailed below. 4.2 Literature review The literature review involved a through searching and investigating relational contract related issues through different primary and secondary sources such as textbooks, articles, journals, papers and international conference paper. In additional, there also effort on searching and browsing through internet web pages, internet websites, online library, electronic database and online articles and journals to seek for supplementary information. The purpose of the literature review was to gather important information related to the topic and deepen the understanding of relational contract, the advantages and potential barrier in adopting it in the 43 construction industry. The second state involves data collection via questionnaire. The development of questionnaire is discussed below. 4.3 Develop Questionnaire A sounding methodology is required in order to meet the aim and objectives of this study. The first part of the main objectives of master project is to study the current practice of construction contract and the problems associated with the application of traditional contract in Malaysia. Surveys on local companies are carried out. The respondents mainly are Class A contractor. Based on previous work done by Lim Chuan Jye (2005), questionnaire approach is the most effective method in carrying out the survey. The questionnaire consists of five distinct parts – the company profile, respondent profile, traditional contract, problem in traditional contract and Relational contract. Most of the question needs the respondent to rank answer, ranging from strongly agree to strongly disagree. The structured questionnaire controls the response as well as easier to understand the questionnaire. The first and second section of the questionnaire was on company and respondent profile. Both sections were design to provide information on the background of the company and the respondent. That information is important to the researcher to access the genuinity of the respondent. In both section, which is section A and B, respondents are required to tick the answer provided. Respondent will tick the most suitable answers. Question in Section A requires the respondent to provide the company name, company telephone number, nature of company, age of the company and classification of company whereas in Section B were sex, age of respondent, respondent position in the company and his experience. Sections C and D were on Traditional Contract. Both sections required respondent to circle the most appropriate to each statement. Question is rated in ranking mode from ‘the most frequently used’ to ‘never used’ and from ‘Strongly 44 agree’ to ‘strongly disagree’. Questions covered in this section have been classed into five criteria. The criteria were as follow: Type of contract document used Type of contract used The reason why used traditional contract Respondent opinion on Traditional contract Problem in Traditional Contract The last section was Section E which is on Relational Contract. Respondent were asked on whether they have been used or heard about Relational Contract. Then, they were asked on factors that they would like to add into current contract and the potential barrier in adopting Relational Contract. The purpose of those questions is to get the clear view on respondent’s readiness in accepting the Relational Contract. An example of questionnaire is attached in Appendix A. 4.4 Survey In spite of the literature review, interview with practical company personal or his management team has been done in order to gain practical information, hands-on issue and experiences related to traditional contract. The survey commenced in early August 2007. List of Class A contractor in Johor Bahru were obtained through PKK (Pusat Khidmat Kontraktor) website. Personal interview been carried out as well as drop-by the survey to the respondent. A set of questionnaire was presented to each respondent for better communication purposes during the interviews. This method is ensuring the questionnaire returned promptly. 45 The survey was tedious and many difficulties throughout been the process such as difficult to get response, delay in replying the survey and reluctant to answer the questionnaire. Forty four companies have been approach but only twenty two companies but only twenty two have response to the survey. The most probably reason for this is many felt insecure due to sensitive issues in contracts and they don’t have time to respond to the survey due to their work load. Most of the respondent used Traditional Contract. This suits previous literature, stating that traditional contract is the most popular contract used in Malaysia. 4.5 Data Analysis SPSS have been used in analyzing the questionnaire. Frequencies analysis is employed. The outcome of the analysis presented in the form of frequencies of respondent, percentage and mean index. In this studies, mean index range from 4.00 to 5.00 is considered as strongly agree. From the analysis, the results are presented in the form of charts and tables. Finally results were compared with the findings in literature review in order to discover whether the objectives of the study been achieved or not. 4.5.1 Frequency Analysis Frequency analysis used a tabular form to represent the result of data analysis of frequency of response that respondents gave to the different variables in the questionnaire. The result was tabulated in the form of frequency number and percentages according to total respondents. For graphic result presentation, bar chart and pie chart are used as summaries. 46 4.5.2 Average Index Analysis In average index analysis, the result will be further summarized to obtain the overall level of importance and evaluation in the Malaysia Construction Industry. The respondents were requested to determine the most regularly contract used, problems face with traditional contract, knowledge on relational contract and the potential barrier in adopting it in construction industry. The average index analysis for each variable was calculated by using the similar classification of the rating scales follows: Average Index = ∑ ai.xi ∑ xi Table 4.1: The level of agree for Average Index Analysis Average Index Rating Scale 0.00 ≤ Average Index (I) ≥ 1.00 Strongly Disagree 1.00 ≤ Average Index (I) ≥ 2.00 Disagree 2.00 ≤ Average Index (I) ≥ 3.00 No Strong Feeling 3.00 ≤ Average Index (I) ≥ 4.00 Agree 4.00 ≤ Average Index (I) ≥ 5.00 Strongly Agree *Source by researcher 47 4.6 Conclusion In this chapter it has been illustrated on the method in the study. The discussion is on the literature work. Method in doing the literature work has been outlined in this sub-section. Mainly, literature work involved a through searching and investigating relational contract related issue through different sources such as textbooks, articles, journals, paper and conferences paper. Next is developing the questionnaire. Each section of the questionnaire was discussed. The questionnaire consist of five distinct parts which is the company profile, respondent profile, traditional contract, problem in traditional contract and the last part is on relational contract. The following topic is on survey process. List of Class A contractor were obtained from the PKK (Pusat Khidmat Kontraktor) website. Personnel interview as well as drop by questionnaire was used in distributing the questionnaire. The last sub-section is on data analysis. SPSS have been used in analyzing the questionnaire. Frequencies analysis is employed. The outcome of the analysis presented in the form of frequencies of respondent, percentage and mean index. Then result was presented in the form of charts and tables. The following chapter is on Preliminaries analysis. CHAPTER V PRELIMINARIES ANALYSIS 5.1 Introduction In the previous chapter, it has been discussed deeply on the methods used in conducting this study. Method of analysing the data also discussed in that chapter. Data collection and preliminaries analysis will be discussing deeper in this chapter. This chapter is divided into two sub-sections that are data collection and respondent background. Both sections are based on section A and B in the questionnaire. Each of the sub-section will be discussed in detailed in the following sub-section. 5.2 Data Collection In this chapter, a detail analysis of data and result will be shown and elaborated by using Frequency Analysis. Registered company with Pusat Khidmat Kontraktor (PKK) were randomly selected as a targeted respondents to determine contract that are regularly used, their opinion on traditional contract and problem faced with the contract and their acceptances to Relational Contract through questionnaire survey. Only Class A contractor were chosen in this survey. Coverage of this organization was hoped to represent the local construction industry. Among 49 44 set of questionnaire form distributed, there were 22 set of replied with completed questionnaire form that cover 50% of the total 44 set questionnaire form in the study. In order to determine the contract that are regularly used, their opinion on traditional contract and problem faced with the contract and their acceptances to Relational Contract, frequency analysis and mean index analysis have been used in this study. The classification of the rating scales are as follows: reply not reply 50% reply 50% not reply Figure 5.1: Response Percentage As mentioned earlier 44 questionnaire have been distributed, but only 22 are returned. The scenario is presented in Figure 5.1 50 5.3 Respondent Background 5.3.1 Gender Distribution The gender distribution is vital to show the involvement of men and women personal in the study. The gender distribution is shown as follows: Female 23% Male Female Male 77% Figure 5.2: The percentage of gender distribution As shown in Figure 5.2, the gender distribution among the respondent shows that most of the respondent are male which represent 77%, while 23% of the respondent is female. 51 5.3.2 Age Distribution The age distribution analysis is vital to show the respondent age in this study. The age distribution is shown as follows: 50-59 years 5% 40-49 years 9% 20-29 years 30-39 years 30-39 years 32% 20-29 years 54% 40-49 years 50-59 years Figure 5.3: The percentage of age distribution Age distribution among the respondent is shown in Figure 5.3. The figure shows that the large portion goes to age ranging from 20-29 years old which is 54%. Age ranging from 30-39years old is 32%, 40-49 years old is 9% and the smallest portion is age ranging from 50-59 years old which is only 5%. 52 5.3.3 Position Distribution Position in the company of the respondent also is important factor that need to be considered in this study. The respondent’s position in the company is shown as follow: Site Supervision 9% Construction Manager 9% Construction Manager Quantity Surveyor 27% Engineer Project Manager Engineer 32% Quantity Surveyor Site Supervision Project Manager 23% Figure 5.4: The percentage of respondent’s position in the company The percentage of Respondent’s position who answered the survey is shown in Figure 5.4. It is shown that 32% of the respondent is an engineer, 23% is a project manager and 27% is quantity surveyor while both site supervisor and construction manager each is 9%. 53 5.3.4 Experience Distribution An experience of the respondent is another importance aspect that needs to be considering in the study. The categories of number of experiences years that involved in the construction industry are as follow: 1-2years 32% 1-2years 3-4years 4-5years 7 years and above 49% 7 years and above 4-5years 5% 3-4years 14% Figure 5.5: The percentage of respondent’s experience in the company Most of the respondents have experience in construction industry more than 7 years. This shows in Figure 5.5, where 49% of the respondents have more than 7 years experience. 32% of respondent with 1-2 years experience, 14% with 3-4 years experience and 5% with 5-6 year experience. From the figure, it can be concluded that most of the respondent is experience staff and knowledgeable in construction industry. 54 5.4 Conclusion This chapter has been discussing on the preliminaries analysis. All data and results were presented in table and pie chart. Analysis is using frequencies analysis. The analysis is on the response percentage where from 44 questionnaire distributed, only 22 are returned. Next sub-section is on the respondent background where the gender distribution, age distribution, position distribution and experience distribution has been analyzed and presented in this chapter. Next chapter will be discussing on analysis and discussion of the results. CHAPTER VI ANALYSIS AND DISCUSSION 6.1 Introduction Data collection and preliminary analysis had been discussed in the previous chapter. In this chapter, findings of the study will be illustrated in detail. This chapter is divided into two sub-sections mainly traditional contract and relational contract. Each of the sub-section will be analyzed and discussed in detail in the following sub-sections. 6.2 Traditional Contract 6.2.1 Contracts that are regularly used The type of contract procurement regularly used by the industry is one of the most important factors in the study. Figure 6.1 shows types of contract procurement used by the industry. 56 Contract used in Malaysia 5% 5% 5% 13% traditional contract design & build Management Project Alliancing Partnering contract 72% Figure 6.1: The practice of contract procurement in the construction industry In this survey, twenty two respondents were taken in to consideration. Respondents Class A contractors. From the survey, 72% of respondents used traditional contract, 13% used design and build, the remaining used other contracts such as management contract, project alliancing and partnering contract. The literature work shows that traditional lump sump system, design and build or turnkey system and management contracting are used in practices. The traditional lump sump system was favoured in Malaysia before the introduction of the turnkey system in 1983. However this Turnkey or Design and Build system is subject to one major weakness that is the increase of construction cost. This survey also reveals that the traditional contract is one of the frequently selected procurement systems in Malaysia. The scenario is illustrated in Figure 6.1 57 6.2.2 Problems with Traditional Contract Knowing the frequency of Problems that respondents face with in Traditional Contract is important for this study in order to prove that there were weaknesses in that contract. Figure 6.2 shows the distribution of respondent facing problems with traditional contract. yes No 50% Yes 50% no Figure 6.2: Problem with traditional contract From the above figure it is clearly shows that 50% admit to facing problems with traditional contract and another 50% encounters no problems at all. Potential problems that have been identified in literature work are listed in Table 6.1 and each of the problems has been analyzed and the analysis is shown in Table 6.1. 58 Table 6.1: Analysis on the problem with Traditional Contract Frequency No 1 2 3 4 5 6 Average Reason The process stages i.e. design development stage, documentation stage, tendering stage and construction phase have a longer duration than other nontraditional procurement methods. Construction cannot commence if the design is incomplete. Severe criticisms and legal disputes result in slow growth in the economy when projects are delayed. The decision processes of the traditional procurement system are slow and convoluted. The selection processes for architects and contractors are time consuming. The time consuming aspects of the development processes contribute to the need for extension of time (E.O.T). 1 2 3 4 5 Total Index 0 0 3 4 4 11 4.091 Categories Strongly agree 0 1 0 4 6 11 4.364 Strongly agree 0 0 2 7 2 11 4.000 Strongly agree 0 0 2 8 1 11 3.909 Agree 0 1 3 6 1 11 3.636 Agree 0 0 2 7 2 11 4.000 Strongly agree 59 Frequency No 7 8 9 10 11 12 13 14 15 Average Reason Variations often lead to unnecessary increases in the final cost of construction. Cost increase derives from scope growth during the construction period. The tender price accepted is not the overall construction cost of the project. There is cost certainty at the commencement stage of the construction processes. Very few projects are completed within the tendered price. Variations occur as a result of the incomplete designs that are never finalized for tendering. Full drawings and a complete bill are often not ready when a project goes to tender. There is no buildability input by contractor during the design period. The lowest bid does not ensure quality. 1 2 3 4 5 Total Index 0 0 1 8 2 11 4.091 Categories Strongly agree 0 0 2 7 2 11 4.000 Strongly agree 0 1 3 6 1 11 3.636 Agree Agree 0 0 4 6 1 11 3.727 Agree 0 0 5 3 3 11 3.818 Agree 0 0 4 5 2 11 3.818 Agree 0 0 6 3 2 11 3.636 Agree 0 1 6 3 1 11 3.364 0 1 1 4 5 11 4.182 Strongly agree 60 Frequency No 16 17 18 Average Reason There is no integration between the design and Construction processes. The designers are not knowledgeable about the relevant design construction inputs. It is difficult for an architect to exercise decision objectivity in playing the roles of both designer and project manager. 1 2 3 4 5 Total Index 0 0 6 4 1 11 3.545 0 2 3 5 1 11 3.455 0 1 5 4 1 11 3.455 Categories Agree Agree Agree From the study, it shows that 50% of the respondents admitted that they are encounter problem with Traditional contract. Table 6.1 shows problems related with traditional contract. The blue box represents average mean index ranging from 4-5 which can be considered as critical problems while the yellow box represent average mean index below than 4-5 and will be considered as less critical. Potential problems that have been listed are Process stages in traditional contract which takes longer time than other contracts (P1), construction that cannot commence if the design is not complete (P2), severe criticism and legal disputes which result in slow growth in economy when the project is delayed (P3), the decision processes of the traditional procurement system which are slow and convoluted (P4), the selection processes for architects and contractors which are time consuming (P5), time consuming aspect of development that will lead to the need for the extension of time (P6), variation which often leads to unnecessary increase in the final cost of construction (P7), cost increase which derives from scope growth during the construction period (P8), the tender price accepted which is not the overall construction cost of the project (P9), there exists cost certainty at the 61 commencement stage of the construction processes (P10), very few projects are completed within the tendered price (P11), variations occur as a result of the incomplete designs that were never finalized for tendering (P12), full drawings and a complete bill were often not ready when a project goes to tender (P13), there is no buildability input by contractor during the design period (P14), the lowest bid does not ensure quality (P15), there is no integration between the design and construction processes (P16), the designers are not knowledgeable about the relevant design construction inputs (P17) and it is difficult for an architect to exercise decision objectivity in playing the roles of both designer and project manager (P18). It has been analyzed that seven problems are categorized as critical problems and the other eleven problems are categorized as less critical from the listed problems. Figure 6.3 illustrate surveyed among the respondent while Figure 6.4 visualizes on less critical problems. 4.36 4.40 Av era g e In d e x 4.30 4.18 P1 4.20 4.09 P2 4.09 4.10 P3 4.00 4.00 LL 4.00 P6 4.00 P7 P8 3.90 P15 3.80 P1 P2 P3 P6 P7 P8 P15 Problem with traditional contract Figure 6.3: Critical problems with traditional contract 62 In Figure 6.3, it is shown that there are seven critical problems identified through mean index analysis. The problems were process stages in traditional contract which takes longer time than other contracts (P1), construction that cannot commence if the design is not complete (P2), severe criticism and legal disputes result in slow growth in the economy when project are delayed (P3), time consuming aspect of the development will lead to the need for extension of time (P6), variation often lead to unnecessary increases in the final cost of construction (P7), cost increase derives from scope growth during the construction period (P8) and the lowest bid does not ensure quality (P15). “Construction works cannot proceed if there are changes in design” (P2) with mean index 4.36, seems to be the most critical problem in traditional contract as visualized in Figure 6.3. It has been agreed that in traditional contract when there are changes in design or specification of material, construction work on that part cannot proceed. It is because of the nature in the traditional contract itself where it promotes fragmentation in contracting. Any changes in construction work has to be approved by parties involved in the construction and these processes consume took a lot of time and may stop the construction work. This situation will delay the project delivery date and increase the construction cost. The effect is critical and that may be the reason that has been agreed to be the most critical problems compared to others. The second critical problem with 4.18 mean index is “the lowest bid does not ensure quality’ (P3). This is true based on the interviews with respondents that the lowest bid does not ensure quality as there may be error during the estimating process. Error in the estimating process will affect the quality of work as contractors will use low quality material that will lead to the inequality work. The next critical problems which have the same mean index which is 4.09 is “stages in traditional contract take longer time” (P1) and “variation which often leads to unnecessary increase in the final cost” (P7). Fragmentation in traditional contract does take a longer time as any decision made has to be proved or agreed by parties involved in the construction. This process takes a longer time as it is difficult to obtain cooperation from them. Last three critical problems derived from this survey were 63 P3, P6 and P8 where each of them has 4.00 for their mean index. These problems result in the increase of project time and lead to higher cost of the project. These findings confirm to Tan (1985). Tan viewed the Traditional method of project implementation in Malaysia as being too lengthy hence needs a radical overhaul and restricting to make the process faster and more efficient. Variation and scope growth during construction also considered as problems as both will increase the overall cost of the project. Cost and time have linear relationship where cost will increase as time increases. It is important to control the problem to avoid an increase in the construction cost. 4.00 3.91 P4 3.90 3.82 3.82 3.80 P5 3.73 3.70 3.64 3.64 3.60 Average 3.50 Index 3.40 P9 3.64 P10 3.55 3.46 3.46 3.36 P11 P12 3.30 P13 3.20 P14 3.10 P16 P17 3.00 P4 P5 P9 P10 P11 P12 P13 P14 P16 P17 P18 P18 Problem with Traditional Contract Figure 6.4: Problems with traditional contract: Less Critical Figure 6.4 shows less critical problem associated with traditional contract. It shows that the highest mean index with 3.91 in less critical problem is “the decision process of the traditional procurement system which is slow” (P4). This problem can be considered or categorized as the most critical problem as the value is near to 4.00. Once again, this is a problem relating to fragmentation in traditional contract. 64 Fragmentation affects the quality of traditional contract. It is difficult to obtain agreement on something from parties involved in the construction contract. The figure shows that the less critical problem or minor problem faced by the construction industry is P14 which is “there is no buildability input by contractor during the design period” with the mean value 3.36. Buildability in construction is not really a problem as the pattern or method of work in construction is almost the same as long as it doesn’t involve a difficult structure. Everybody in the industry knows the basic in commencement the work, so input from the contractor on buildability is not a critical problem. 6.3 Relational Contract As far as relational contract is construct the survey addressed several issues such as knowledge on relational contract, potential barriers in adopting relational contract and elements to be added in traditional contract. 6.3.1 Knowledge on Relational Contract Knowing the frequency of respondent’s knowledge in Relational contract is important in this study in order to investigate a level of understanding among respondents on this matter. Distribution of knowledge on Relational Contract is as follow: 65 Yes 23% Yes No No 77% Figure 6.5: Distribution of respondent facing problems with traditional contract It may appear that many of the practitioners in the construction industry in Malaysia have no knowledge or are aware of the Relational contract. Figure 6.4 shows that 77% of the respondents never used or heard about Relational Contract. Only 23% knew or have heard about the contract. However, 23% who answered YES, have actually never used Relational Contract. The knowledge come through reading or just knowing in an informal way such as from other practitioner in the industry. It can be concluded that none of the respondents have used the relational contract. However, surprisingly the entire respondents indicate that they mightl not encounter problems in adopting Relational contract. 6.3.2 Potential Barriers in adopting Relational Contract Factors that have been considered in this study are Potential barrier in adopting Relational contract element in traditional contract. Distribution of potential barrier in adopting Relational Contract is as follow: 66 Table 6.2: Analysis on potential barrier in adopting Relational Contract No 1 2 3 4 5 Frequency 1 2 3 4 5 Total Average Index 2 0 3 8 9 22 4.000 Strongly agree 1 4 3 10 4 22 3.545 Agree 1 3 3 9 6 22 3.727 Agree 1 2 2 11 6 22 3.864 Agree 1 0 7 9 5 22 3.773 Agree Reason Lack of client knowledge (about project processes and Relational Contract) Lack of trust between contracting parties Failure to share information between contracting parties Persistence of “Master” (e.g Client/prime consultant) and “Slave” concept Unfair risk-reward plan Categories Table 6.2 shows the analysis on potential barriers in adopting relational contract. In the table, the blue box represents average mean index ranging from 4-5 which can be considered as the most potential barrier, while the yellow box represents the average mean index below than 4-5 and will be considered as not really a barrier in adopting relational contract. List of potential reasons were listed in the table are lack of client knowledge (R1), lack of trust between contracting parties (R2), failure to share information between contracting parties (R3), persistence of “Master” (e.g Client/prime consultant) and “Slave” concept (R4) and unfair riskreward plan (R5). 67 4.00 4.00 3.86 3.90 3.77 3.73 3.80 R1 Average 3.70 Index 3.60 R2 3.55 R3 R4 3.50 R5 3.40 3.30 R1 R2 R3 R4 R5 Potential Barrier in adopting Relational Contract Figure 6.6: Potential Barrier in adopting Relational Contract Analysis in Table 6.2 is then illustrated into a bar chart as shown in Figure 6.6. From the bar chart, it shows that the highest mean index is 4.00 which is lack of client knowledge (R1). R1 has the highest rated as respondents agree that knowledge of the relational contract is important before applying it. Both client and contractor must understand well how the contract works, such as the content of the contract and the project process in order to ensure the effectiveness of this contract. Other factors which have mean index below 4.00 and can be considered as not becoming a potential barrier in adopting relational contract. Those factors were R4 with 3.86, followed by R5 with 3.77, R3 with 3.73 and the last reason is R2 with 3.55. R4 which is persistence of “Master” (e.g Client/prime consultant) and “Slave” concept. This concept does not really occur in Malaysia’s construction industry as contracting parties in the industry usually have a good relationship between them. So, the “Master” and “Slave” concept rarely occurs a barrier because the situation in this country. 68 Unfair risk reward plan (R5) is also not a potential barrier in the construction industry, everybody knows their role or their scope of work also the portion of risk and reward that they should receive in the project. Based on informal discussions with respondents, most of them state that they know the risk and agreed with the risk. So, this will not be not an issue as far as the barrier to the application of relational contract is concerned. Failure to share information between contracting parties (R3) is also considered as not being a barrier in adopting relational contract as in traditional contract sharing information is not a problem. Contracting parties do not hesitate to share information as they realize that they need to cooperate in order to achieve the project goal. Lastly, is (R2) which is lack of trust between contracting parties. Since they are willing to share information in traditional contract, they would not face much difficulty in accepting the ‘open book’ concept in relationship contract. Again, they have established a certain level of trust between them. Trust is another important issue if a relationship contracting was to be successfully implemented. From the study, it can be concluded that the only potential barrier in adopting Relational Contract is the lack of client knowledge. This is because Relational contract may not be adopted if the client himself doesn’t understand the fundamental of relational contract. 6.3.3 Elements to be added in traditional contract Element in relational contract are then studied and are then applied to determined whether it is suitable to be added in traditional contract. Analysis on element to be added is shown in Table 6.3 as follow: 69 Table 6.3: Analysis on added factors for Traditional Contract No Frequency 1 2 3 4 5 Total Average Index Reason 1 Alignment of goals 0 0 4 10 8 22 4.182 2 Risk allocation 0 0 7 9 6 22 3.955 0 0 0 10 12 22 4.545 0 0 7 9 6 22 3.955 0 0 5 6 11 22 4.273 0 1 10 8 3 22 3.591 0 0 4 10 8 22 4.182 3 4 5 6 Clearly defined scope Form of contract Integrated project team Gain share / Pain share Categories Strongly Agree Agree Strongly Agree Agree Strongly Agree Agree Open honest 7 communication / behavior / Change Strongly Agree of attitude 5.00 4.50 4.55 4.18 3.96 4.27 3.96 4.18 3.59 4.00 3.50 E1 3.00 Average 2.50 Index 2.00 E2 1.50 E5 1.00 E6 0.50 E7 E3 E4 0.00 E1 E2 E3 E4 E5 E6 E7 Element to be added in Traditional Contract Figure 6.7: Elements to be added in Traditional Contract 70 Table 6.3 shows the elements to be added in traditional contract. In the table, the blue box represents average mean index ranging from 4-5 which can be considered as elements to be added, while the yellow box represent average mean index below than 4-5 and will be considered as not being an element to be added in traditional contract. The list of potential elements to be added were listed in the table are the alignment of goals (E1), Risk allocation (E2), clearly defined scope (E3), form of contract (E4), Integrated project team (E5), Gain share / Pain share (E6) and Open honest communication / behavior / Change of attitude (E7). Analysis in Table 6.3 then had been illustrated into bar chart as shown in Figure 6.7. From the bar chart, it shows that the entire respondents agreed that out of seven elements in relational contract, four are highly recommended to be adopted in current contract practices in order to improve the outcome of the project and achieve a win-win situation. Clearly defined scope followed by Integrated Project Team, alignment of goals and open honest communication is the most wanted element to be added in traditional contract. In Figure 6.6 also shows the highest average index, which is 4.55, is clearly defined scope. The importance of defining scope is because everybody in the construction project directly or indirectly influences the overall outcome of the project. By a clearly defined scope, every level in the organization will have a better understanding between each other and work together in order to achieve the goal. From the study, it can be concluded that this element is the critical element that the industry needs to add in traditional contract in order to improve its quality and that the industry should to understand that having individual goals for each party is not helping the industry in upgrading its quality or to ensure the successfulness of the project. The second element to be added is the integrated project team (E5) with the mean index 4.27. This element is about cooperation between contracting parties. Nowadays, the Malaysian construction industry is aware that each party must be integrated project team. Just being a team is not enough in producing a good product. It must be an integrated in order to upgrade the nature of work in current contract. 71 The third and forth element to be added is alignment of goal (E1) and open and honest communication (E7) with the mean index 4.18. Alignment of goal is important as every parties involved should have the same goal and avoid individual goals. Individual goals lead to one party achievement and not everybody achievement. One or two party success in their part or work won’t ensure the successfulness of the project. That why it is important to have the same alignment of goals. Another element is open honest communication. Honesty is important as it leads to trust between each other. Trust must be built from the start of the project till it ends, as it can avoid bad feeling between each other. There also elements that have mean index below than 4-5 which were Risk allocations (E2), form of contract (E4) and Gain share/Pain share (E6). From the figure, it shows that E2 and E4 have the same mean index which is 3.96 while E6 with 3.59. Risk allocation is not an element to be added as it has been practiced in traditional contract. In traditional contract, every party knows their risk in contract project undertaking. Type of contract is also not an issue as it as contracting parties know the term and condition for each contract and agreed on the regulations upon entering the contract. The last element is gain share and pain share. This element is also not an element to be added as each parties once again said that the portion of risk and reward has been stated in the contract and there is no way for the contracting parties to share other parties pain. Most of the respondents are comfortable with the current nature and prefer it to be maintained. From the analysis, it can be concluded that it is important to define project goals and project scopes in a complete and unambiguous manner. It is importance to have an Integrated Project Team in achieving the project goals. It must operate on mutual trust that puts the best interest of the project ahead of purely self-centered gains, achieving a single and unified team (ACA, 1999). Alignment of goal is vital in facilitating effective teamwork and communication. In order to encourages everyone to confront issues and differences from the perspective of developing solutions rather than allowing them to escalate into disputes, open honest communication is one that should be recommended to be added into current contract. 72 6.4 Conclusion This chapter has illustrated in detail analysis that has been done. In the analysis, it is found that contracts are regularly used is traditional contract as the contract is familiar to work with, the most critical problem in traditional contract is that construction cannot commence if the design is incomplete as fragmentation made decision is difficult to obtain and this leads to the extension of the project duration, the only potential barrier in adopting relational contract are lack of client knowledge as the understanding in the contract is important before applying it and element to be added in traditional contract is a clearly defined scope followed by integrated project team, alignment of goals and open honest communication. CHAPTER VII CONCLUSION AND RECOMMENDATION 7.1 Introduction Findings and discussion of this study have been discussed in previous chapter. All those findings have been concluded and are presented in this chapter according to the outlined objective that been listed in chapter 1. Based on the analysis, the summary of results in identifying the most regularly contract used in construction industry, problems in traditional contract, potential barrier in adopting Relational Contract and the element of relational contract that want to be added in traditional contract are as below: 7.2 Findings The following are the conclusions derived from the literature study and questionnaire survey conducted. 74 7.2.1 Objective1: To study the current practice of construction contract The first objective has been achieved through questionnaire survey. The questionnaire consists of five type of contract procurement that is used in Malaysia which is traditional contract, design and builds contract, management contract, project alliancing contract and partnering contract. From the analysis, it is shown that traditional contract is the most regularly contract used in Malaysia. 7.2.2 Objective 2: To analyze problems associated with the application of traditional contract in Malaysia Second objective has also been achieved through questionnaire survey. 18 potential problems have been listed in the questionnaire. From 18 problems listed, it is found that out of 18, 7 problems are recognized to be the most critical problem faced by the industry. These problem is the process stages i.e. design development stage, documentation stage; tendering stage and construction phase have a longer duration than other nontraditional procurement methods, Construction cannot commence if the design is incomplete, severe criticisms and legal disputes result in slow growth in the economy when projects are delayed, The time consuming aspects of the development processes contribute to the need for extension of time (E.O.T), Variations often lead to unnecessary increases in the final cost of construction, Cost increase derives from scope growth during the construction period and the lowest bid does not ensure quality. From those problem listed above, it is found that construction cannot commence if the design is incomplete is the most critical problem faced by the industry. 75 7.2.3 Objective 3:To appraise the knowledge and the application of Relational Contract in Malaysia Third objective was achieved through questionnaire survey. Respondent knowledge in relational contract was studied. Through the study, it is found that only 23% of the respondent knew about this approach. Surprisingly, it can be concluded that most of the respondent don’t know about the contract. Potential barrier in adopting relational contract had been identified. It is found that lack of knowledge in relational contract especially in the project process is the critical potential barrier in adopting Relational contract. 7.2.4 Objective 4: To recommend an improvisation of traditional contract through Relational contract’s elements The fourth objective was Improvisation of traditional contract is achieved through questionnaire survey. found in the study. Element in relational contract that can be used or adopt in the traditional contract is listed in the questionnaire. Based on the survey, it is found that alignment of goals, clearly defined scope, integrated project team and open and honest communication is the elements that need to be added in traditional contract in order to improve the quality of the contract. However, it is agreed that clearly defined scope is the most important element to be added in the traditional contract compared to others element. Improvisation is important in upgrading the traditional contract in order overcome it weakness. 76 7.3 Conclusion From those findings, Traditional contract is undoubtedly will be continue to be used in Malaysia. Traditional contract remain its popularity because of it is familiar to work with and there is no hidden agenda between contracting parties. Contractors feel save using traditional contract. Moreover traditional contract has been used for along time and lots of amendment made to improve the contract. Traditional is considered as a stable contract compared to other contracts. However, practitioners admitted that there also weaknesses in traditional contract. It is recommended that those weaknesses can be overcome by adopting some of Relational element such as clearly defined scope between contracting parties, adopting integrated project team in contracting, alignment of goals among contracting parties and an honest communication. Generally, this study has achieved its aims and objectives of studying the problem in traditional contract, knowledge of the practitioners on relational contract and the application of Relational Contract in Malaysia 7.4 Recommendations for further study This project has provided substantial information on the concept of relationship contracting and the potential of its application in Malaysia. It is hoping that the research would open up the door to further introduction and promotion of relationship contracting in Malaysia. Further work that could be carried out in future research is listed below: 1) Obtain the latest development in relationship contracting through various resources. 2) Conduct a survey with large sample size and a variety of construction projects in different sectors. 76 REFERENCES AND BIBLIOGRAPHY Australian Constructors Association, 1999, Relationship contracting – Optimising project outcome, ACA, North Sydney. Ashworth,A 1996, Contractual procedures in the construction industry, 3rd edn., Addison Wesley Longman Limited, England. Australian Constructors Association, 1999, Relationship contracting – Optimising project outcome, ACA, North Sydney. Tan, E.K, 1985, Radical Changes Urged for Industry, Building and Construction News Yearbook, Malaysia. Maizon Hashim, 1997, Clients’ Criteria on the Choice of Procurement Systems- A Malaysian Experience Rashid K, 2002, Construction procurement in Malaysia – Process and systems, constrains and strategies, International Islamic University Malaysia, Kuala Lumpur. Scott B, 2001, Partnering in Europe – Incentive base alliance for projects, Thomas Telford Publishing, London. Lendrum,T 2003, The strategic partnering handbook – The practitioner’s guide to partnerships & alliances, 4th edn., McGraw Hill, Sydney. Thorpe D. & Dugdale G., 2003, Procurement and risk sharing, Client driving innovation international conference, Australia. 62 77 U.S. Department of State Foreign Affairs Handbook Volume 6 Handbook 2— Contracting Officer’s Representative Turner,J (ed.) 2003, Contracting for project management, Gower Publishing Limited, Oxon. Y.Y. Ling, Procurement Design Services for Design-Build Projects, School of Building & Estimate Management, National University of Singapore Gan Eng Toh, Procurement Strategy Selection for Construction: An Artificial Neutral Network Approach, Faculty of Build Environment, Universiti Teknologi Malaysia. George Baker, Robert Gibbons, Kevin J. Murphy, 2001, Relational Contract and the Theory of the Firm, Journal of Economic. UNIVERSITI TEKNOLOGI MALAYSIA Questionnaire Form Dear Sir / Ma’am, The purpose of this questionnaire is to study the RELATIONAL CONTRACT IN MALAYSIA. All information given by the respondent will be kept confidential. Thus, your sincerity and honesty in answering this questionnaire is much appreciated. Please submit the complete form using the envelope given. Thank you for your cooperation. Prepared By Nurul Alifah Binti Jatarona Student of Master of Science (Construction Management) Faculty of Civil Engineering UTM, Skudai Johor (Contact No. : 012-4563960) Under Supervision Of Assoc. Prof. Dr. Aminah binti Md. Yusof Lecturer Faculty of Civil Engineering UTM, Skudai Johor (Contact No. : 012-7102340) 1 Introduction Relationship contracting has been available as a style of infrastructure delivery since early 1980s. It is a term applied to contracting arrangement where management of relationship is given precedence over the dictate of a standard form of contract. It is a strategic alliance between organisations to achieve mutual benefits based on trust, appropriate risk allocation, teamwork, sharing of profit or loss and most importantly the alignment of goals. Traditional contracting systems in construction industries frequently lead to confrontations and unresolved issues associated with different commercial alignment of individual parties which tends to escalate the project time and targeted cost. On the contrary, relationship contracts offer an approach to encourage cost savings and reduction in construction time through systematic contracting procedures thus overcoming the limitations of traditional contracts. Section A: Company Profile 1. Company : ______________________________________________ 2. Telephone Number : _________________________________ 3. Nature of company : Client Contractor Consultant Other: _____________________________ 2 4. Age of the company 1-2 years 3-4 years 5-6 years 7 years and above 5. Classification of company: CIDB PKK Others: __________________________________________ Section B: Respondent Profile 1. Sex: 2. Age: Male Female 20-29 years 30-39 year 40-49 year 50-59 year 3 4. Position in the company Engineer Project Manager Quantity Surveyor Construction Manager Site Supervisor 5. Experience in construction industry : 1-2 years 3-4 years 5-6 years 7 years and above Section C: Traditional Contract Please Circle the response that you think is most appropriate to each statement. 1. What kind of contract document you used? Question Most Frequently used 5 Frequently used Neutral Seldom used Never used 4 3 2 1 a. JKR 203 b. PAM 5 4 3 2 1 c. CIDB 5 4 3 2 1 d. IEM 5 4 3 2 1 4 2. Which of the following contract that you are usually used? Question Most Frequently used 5 Frequently used Neutral Seldom used Never used 4 3 2 1 a. Traditional Contract b. Design & Built Contract 5 4 3 2 1 c. Management Contract 5 4 3 2 1 d. Project Alliancing Contract 5 4 3 2 1 e. Partnering Contract 5 4 3 2 1 3. Why you choose this contract? Question a. b. c. d. e. f. Familiar to work with as it is a well known contract Easy and straight forward Standards are easier to control Suitable to use whether for experience or inexperience contractor Faster track Cost certainty No Strongly Strong Disagree Disagree Feelings Strongly Agree Agree 5 4 3 2 1 5 4 3 2 1 5 4 3 2 1 5 4 3 2 1 5 5 4 4 3 3 2 2 1 1 Strongly Agree Agree No Strong Feelings Disagree Strongly Disagree 5 4 3 2 1 5 5 4 4 3 3 2 2 1 1 5 4 3 2 1 5 4 3 2 1 4. What do you think about Traditional Contact? Question a. b. c. d. e. Suitable to use whether for experience or inexperience contractor Cost certainty Time predictability Easy and straight forward contract Tenders are on a like-forlike basis 5 f. g. Scheme fully pre-designed and specified Early commitment to maximum price 5 4 3 2 1 5 4 3 2 1 5. Did you face any problem due to traditional contract? Yes (proceed to Section D) No (proceed to Section E) Section D: Problem in Traditional Contract Please Circle the response that you think is most appropriate to each statement. Question 1. 2. 3. 4. 5. The process stages i.e. design development stage, documentation stage, tendering stage and construction phase have a longer duration than other nontraditional procurement methods. Construction cannot commence if the design is incomplete. Severe criticisms and legal disputes result in slow growth in the economy when projects are delayed. The decision processes of the traditional procurement system are slow and convoluted. The selection processes for architects and contractors are time consuming. Strongly Agree Agree No Strong Feelings Disagree Strongly Disagree 5 4 3 2 1 5 4 3 2 1 5 4 3 2 1 5 4 3 2 1 5 4 3 2 1 6 Question 6. 7. 8. 9. 10. 11. 12. 13. 14. 15. 16. 17. 18. The time consuming aspects of the development Processes contribute to the need for extension of time (E.O.T). Variations often lead to unnecessary increases in the final cost of construction. Cost increase derives from scope growth during the construction period. The tender price accepted is not the overall construction cost of the project. There is cost certainty at the commencement stage of the construction processes. Very few projects are completed within the tendered price. Variations occur as a result of the incomplete designs that are never finalized for tendering. Full drawings and a complete bill are often not ready when a project goes to tender. There is no buildability input by contractor during the design period. The lowest bid does not ensure quality. There is no integration between the design and Construction processes. The designers are not knowledgeable about the relevant design construction inputs. It is difficult for an architect to exercise decision objectivity in playing the roles of both designer and project manager. Strongly Agree Agree No Strong Feelings Disagree Strongly Disagree 5 4 3 2 1 5 4 3 2 1 5 4 3 2 1 5 4 3 2 1 5 4 3 2 1 5 4 3 2 1 5 4 3 2 1 5 4 3 2 1 5 4 3 2 1 5 4 3 2 1 5 4 3 2 1 5 4 3 2 1 5 4 3 2 1 7 Section E: Relational Contract 1. Have you used or heard of relationship contracts? Yes No 2. Factors that you like to added into your current contract in order to improve the outcome of the project and achieve a win-win situation if possible? Question a. b. c. d. e. f. g. Alignment of goals Risk allocation Clearly defined scope Form of contract Integrated project team Gain share / Pain share Open honest communication / behavior / Change of attitude Strongly Agree Agree No Strong Feelings Disagree Strongly Disagree 5 4 3 2 1 5 4 3 2 1 5 4 3 2 1 5 4 3 2 1 5 4 3 2 1 5 4 3 2 1 5 4 3 2 1 8 3. Potential barrier in adopting Relational Contract Question a. b. c. d. e. Lack of client knowledge (about project processes and Relational Contract) Lack of trust between contracting parties Failure to share information between contracting parties Persistence of “Master” (e.g Client/prime consultant) and “Slave” concept Unfair risk-reward plan Strongly Agree Agree No Strong Feelings Disagree Strongly Disagree 5 4 3 2 1 5 4 3 2 1 5 4 3 2 1 5 4 3 2 1 5 4 3 2 1 Your cooperation in this matter is appreciated. Thank you. 9