LAWYERS TO THE CONSTRUCTION & ENGINEERING INDUSTRIES www.klgates.com Summer 2007 In Site Own goals: when is time at large? The circumstances in which time will be 'at large' in a contract as a result of the prevention principle were considered in the recent Wembley Stadium case, Multiplex Construction (UK) Limited v. Honeywell Systems Limited (No.2) (TCC, 6 March 2007). The prevention principle means that an employer cannot hold a contractor to a specified completion date if the employer has prevented the contractor from completing by that date. Instead, time becomes at large. The obligation to complete by a specified date is replaced with an implied obligation to complete within a reasonable time. Acts of prevention by the employer are commonly included in the list of relevant events entitling a contractor to an extension of time, such as in the JCT suite of contracts, to avoid this situation arising. The Wembley project was already suffering from significant delays when Honeywell entered into a communications systems sub-contract with Mutliplex in May 2004 and delays continued to be experienced after Honeywell started work (with Honeywell blaming Multiplex and vice versa). During 2005 Multiplex issued Welcome to the Summer edition of In Site. three revised programmes to Honeywell, each showing a progressively extended completion date. Multiplex issued these programmes in the form of directions under clause 4.2 of the Sub-Contract Conditions, which allowed it to issue 'any reasonable direction in writing to [Honeywell] in regard to the Sub-Contract Works (including the ordering of any Variation therein)'. Clause 11.10 listed the Relevant Events entitling Honeywell to an extension of time and included 'delay caused by any act of prevention or default by [Multiplex] in performing its obligations under the Sub-Contract' (clause 11.10.7). The list of Relevant Events did not include directions issued under clause 4.2. Honeywell's works were not completed by the extended completion date. Disputes arose and, in the first instance, the adjudicator decided that the extension of time clause did not contain a mechanism for extending time in respect of delays caused by a direction under clause 4.2, and hence time was at large. Multiplex rejected this decision and issued proceedings for declarations that time was not at large continued on page 2 Welcome to the Summer edition of In Site. In this edition we consider the application of the 'prevention principle' to extensions of time on the Wembley Stadium project; report on the new contracts being published by the NEC and JCT; provide our usual adjudication update; and report on other recent statutory and procedural developments of interest. Contents Time at large 1 New contract forms 2 Adjudication update 3 Other recent developments 4 Who to Contact 4 In Site continued from page 1 and that there was an effective procedure to allow an extension of time. Mr Justice Jackson agreed with Multiplex and granted the declarations sought. Mutliplex's primary argument was that there was an applicable mechanism for extending the period for completion i.e. directions issued under clause 4.2 did not need to be specifically referred to in the list of Relevant Events as the issue of the programmes was an 'act of prevention' by Multiplex and hence covered by clause 11.10.7. Jackson J derived the following three propositions from a review of the authorities on the 'prevention principle': n legitimate actions by an employer may still be characterised as prevention, if those actions cause delay beyond the completion date; n acts of prevention by an employer do not set time at large if the contract provides for extensions of time in respect of those events; and n insofar as the extension of time provisions are ambiguous, they should be construed in favour of the contractor. Honeywell argued that directions and instructions lawfully given could not be acts of prevention. The judge did not agree and, applying the above principles, considered that the correct analysis was that directions under clause 4.2 did not automatically qualify for consideration under the extension of time clause as many directions have no effect on the duration of the works. Nevertheless, if Multiplex issued a direction which constituted a Variation and which did lead to completion on a later date, then such variation 'prevents' Honeywell from completing by the due date and is therefore an act of prevention within the meaning of clause 11.10.7 - even though it is permitted by the contract. Multiplex could, therefore, award an extension of time rather than time being at large. This case is a useful reminder that the contract machinery is often there for the benefit of both parties. It is important for an employer to be able to grant an extension of time when there is an act of prevention as it may otherwise be faced with the uncertain situation of having works which only need to be finished within a 'reasonable time'. New NEC3 and JCT Forms NEC Term Service Short Contract and Supply Contract Building on the growing popularity of the third edition of the Engineering and Construction Contract ('NEC3') suite of contracts, the NEC will introduce two new forms of contract later this year. The Term Service Short Contract and Supply Contract are due to be published this Autumn and reflect the desire of the NEC to cater for the full procurement spectrum. The Term Service Short Contract is intended for use across a broad range of services, but will represent a simplified and shorter document than the existing Term Service Contract ('TSC'). The Term Service Short Contract is intended for use at a sub-contract level, below the TSC, but also as a standalone product. The NEC expects that 2 SUMMER 2007 it will be suitable for a wide range of services from grass cutting to bus and taxi services, so it should be attractive across a broad range of industry groups. Although publication is pending, it is understood that it will be based on a fixed service period with prices based on a lump sum or rates and quantities. The NEC says the second of its new forms, the Supply Contract, is being released in response to popular demand. Like the Term Service Short Contract, the NEC expects the Supply Contract to be put to a variety of uses. It suggests that the contract will be suitable for the supply of items such as rolling stock, process plant and bulk fuel/materials. The NEC emphasises that the contract is suitable for use even in sophisticated markets, but will also be flexible enough to provide for supply on a 'free issue' or call-off basis. If it is indeed as versatile as the NEC is promising then it will represent a useful tool for many types of project. The NEC suite of contracts is gaining popularity all the time and there is no doubt that these forms of contract will enhance its appeal to potential users. The NEC is trying to increase the use of the NEC3 suite beyond its traditional use in construction and engineering projects and these new contracts represent a step towards that goal. JCT Constructing Excellence Contract The new JCT Constructing Excellence Contract was launched on 1 March 2007. Speaking at the House of Commons launch, Sir Michael Latham welcomed its 'highly readable' style and focus on 'trust and fairness'. It is continued on page 3 www.klgates.com continued from page 2 intended for use throughout the supply chain, including the provision of professional services. Collaborative working is at the core of the Constructing Excellence Contract, which is based on the Be Collaborative Contract published in 2003. The overriding principle of the contract is that the parties have the intention to work with each other and all other project participants in a 'co-operative and collaborative manner in good faith and in the spirit of mutual trust and respect' (clause 2.1). This principle is given 'teeth' as the adjudicator or the Court in any subsequent dispute will take into account whether or not the parties have adhered to that overriding principle (clause 2.9). Other partnering principles, such as supply chain management, benchmarking and effective management of risk are also emphasised. The latter is done through the introduction of a 'Risk Register' and a 'Risk Allocation Schedule' for considering fair and/or practical risk allocations and time and cost consequences. There is also an optional multi-party Project Team Agreement which, if signed up to, introduces a pain/gain mechanism encouraging participants to commit to the success of the whole project, not just their part of it. This contract has come about as a result of requests from the Local Government Association for a collaborative style of JCT contract suitable for use by the public sector and conducive to building long-term relationships, but it is promoted as being equally suitable for the private sector. It forms a welcome addition to the range of partnering and collaborative working contracts (such as NEC and PPC 2000) now available to the construction and engineering industries. Enforcement of non-compliant adjudication procedures It is well established that, if the adjudication provisions in a construction contract do not comply with section 108 of the Housing, Grants, Construction and Regeneration Act 1996 (the 'Act'), then the Scheme for Construction Contracts will apply and any decision under the non-compliant adjudication procedure is unenforceable. This ground is often relied on by parties seeking to resist enforcement of an adjudicator's award. Two recent decisions in the TCC have, however, raised questions about the ability of parties to resist enforcement of adjudicators' decisions on this ground. There are a number of similarities between the cases of Epping Electrical Company Limited v. Briggs and Forrester (Plumbing Services) Limited (TCC, 19 January 2007) ('Epping') and Aveat Heating Limited v. Jerram Falkus Construction Limited (TCC, 1 February 2007 ('Aveat'): n they came before the same judge within a fortnight of each other; n they concerned an adjudicator's decision that was made under an adjudication procedure which failed to comply with the Act; n the problem with the procedure was the same i.e. the procedure said that the adjudicator's decision would be valid even if delivered late; and n the judge found that this attempt to render late decisions valid meant that the adjudication procedure was not compliant with the Act and the Scheme applied. Despite these similarities, the judge refused to enforce the decision in Epping, whilst allowing enforcement in Aveat. How can these different decisions be reconciled? The crucial difference between the cases is that in Epping the decision was delivered late, whereas the adjudicator in Aveat delivered his decision on time, despite the fact that the procedure he was following provided for late decisions still to be valid. The judge followed the generally accepted reasoning that the Scheme replaces non-compliant procedures, but he appears to have gone one step further and asked whether the way in which the adjudication was actually carried out offended the Scheme. In Epping it did because the decision was delivered late, which the Scheme does not permit. In Aveat it did not, because the decision was delivered on time, in accordance with the Scheme. What these two cases indicate is that a contractual adjudication procedure which does not comply with the Act will not necessarily be enough to prevent enforcement. A party resisting enforcement will now also have to show that the way in which the adjudication was actually carried out offended the Scheme. SUMMER 2007 3 In Site Other recent developments Pre-Action Protocol The Pre-Action Protocol for Construction and Engineering Disputes has recently undergone some changes to streamline the protocol process, prevent delays and reduce costs. Civil Procedure Rules Part 36. The main changes include the following: n a defendant no longer has to make a payment into court in support of an offer to settle i.e. it no longer has to prove it is 'good for the money'; From 6 April 2007, respondents have three months, rather than four, in which to respond to the letter of claim and the pre-action meeting should now normally be held within 28 days of the letter of response. Further key amendments include a provision that the costs of the protocol procedure will have to be proportionate to the complexity of the case and the amount at stake and a recognition that not all supporting documents and evidence must be provided pre-action (the guiding principle will be one of proportionality). n the court's permission is now required for either party to withdraw or alter a Part 36 offer during the relevant period (usually 21 days) for acceptance (offers could previously be withdrawn at any time). No permission is required to withdraw or alter after the relevant period; n if an offer is not withdrawn, it can be accepted at any time without the court's permission (previously, offers could only be accepted after 21 days with the leave of the court); The amended Protocol applies to disputes that come into being from 6 April 2007. Disputes operating under the Protocol before that date will not be affected by the amendments. n if a defendant rejects a claimant's offer, the claimant only has to equal his offer to trigger the costs consequences of Part 36 (rather than better it); Changes to CPR Part 36 New rules came into force on 6 April 2007 concerning offers to settle and payments into court made pursuant to n in a money claim, a defendant's offer must be for a single sum of money. If payment is not made within 14 days of acceptance (or Who to Contact For further information contact the following Christopher Causer christopher.causer@klgates.com Kevin Greene kevin.greene@klgates.com James Hudson james.hudson@klgates.com Linda Kent linda.kent@klgates.com Trevor Nicholls trevor.nicholls@klgate.com David Race david.race@klgates.com T: +44 (0)20 7360 8147 T: +44 (0)20 7360 8188 T: +44 (0)20 7360 8150 T: +44 (0)20 7360 8151 T: +44 (0)20 7360 8177 T: +44 (0)20 7360 8106 such other period as agreed), judgment can be entered. That offers may now remain open for acceptance at any time (unless withdrawn) is likely to have significant tactical implications. It may give rise to a situation where an offeree discovers an unhelpful document and hence realises his case is weaker than he thought. He is then able to accept the offer before the unhelpful document is disclosed (which would presumably otherwise have resulted in the offer being withdrawn). One possibility may be to state in the offer that it automatically lapses after 21 days. However, given the specific notice provisions in CPR 36.3(6)&(7), such a condition may have the effect of turning a Part 36 offer into a Calderbank offer and thus may not necessarily afford the same degree of costs protection as a Part 36 offer. A new Practice Direction 36B has been issued to explain how the new rules operate in relation to offers and payments made before 6 April. Basically, any offers or payments made before that date remain valid, but their consequences will be governed by the new rules. K&L Gates 110 Cannon Street London EC4N 6AR www.klgates.com T: +44 (0)20 7648 9000 F: +44 (0)20 7648 9001 K&L Gates comprises approximately 1,400 lawyers in 22 offices located in North America, Europe and Asia, and represents capital markets participants, entrepreneurs, growth and middle market companies, leading FORTUNE 100 and FTSE 100 global corporations and public sector entities. For more information, please visit www.klgates.com. K&L Gates comprises multiple affiliated partnerships: a limited liability partnership with the full name Kirkpatrick & Lockhart Preston Gates Ellis LLP qualified in Delaware and maintaining offices throughout the U.S., in Berlin, and in Beijing (Kirkpatrick & Lockhart Preston Gates Ellis LLP Beijing Representative Office); a limited liability partnership (also named Kirkpatrick & Lockhart Preston Gates Ellis LLP) incorporated in England and maintaining our London office; a Taiwan general partnership (Kirkpatrick & Lockhart Preston Gates Ellis) which practices from our Taipei office; and a Hong Kong general partnership (Kirkpatrick & Lockhart Preston Gates Ellis, Solicitors) which practices from our Hong Kong office. K&L Gates maintains appropriate registrations in the jurisdictions in which its offices are located. A list of the partners in each entity is available for inspection at any K&L Gates office. This publication/newsletter is for informational purposes and does not contain or convey legal advice. The information herein should not be used or relied upon in regard to any particular facts or circumstances without first consulting a lawyer. Data Protection Act 1998 - We may contact you from time to time with information on Kirkpatrick & Lockhart Preston Gates Ellis LLP seminars and with our regular newsletters, which may be of interest to you. We will not provide your details to any third parties. Please e-mail london@klgates.com if you would prefer not to receive this information. 4 SUMMER 2007 ©1996-2007 Kirkpatrick & Lockhart Preston Gates Ellis LLP. All Rights Reserved.