FIRM NAME: _____________________ RFQ NO. 2015-R0025 REQUEST FOR QUALIFICATIONS DESIGN AND CONTRACT ADMINISTRATION OF THE CAMPUS-WIDE EXTERIOR SECURITY CAMERA PLAN FOR FACILITIES DEPARTMENT COLLEGE of DuPAGE COMMUNITY COLLEGE DISTRICT NO. 502 Statement of Qualification Due: APRIL 22, 2015 at 2:00PM CST In the event of office closure due to inclement weather, bid deadline will be extended to the next business day at the same time. DELIVER TO: COLLEGE of DuPAGE PURCHASING DEPARTMENT BID/PROPOSAL BOX BIC ROOM 1540 425 FAWELL BLVD. GLEN ELLYN, ILLINOIS 60137 ISSUED BY THE PURCHASING DEPARTMENT Page | 1 RFQ No. 2015-R0025 Purchasing Department 425 Fawell Boulevard Glen Ellyn, Illinois 60137-6599 http://www.cod.edu PHONE (630) 942-2217 FAX (630) 942-3750 April 6, 2015 Request for Qualifications Statements of Qualification for DESIGN AND CONTRACT ADMINISTRATION OF THE CAMPUS WIDE EXTERIOR SECURITY CAMERA PLAN for the Facilities Department will be received by the College of DuPage, District 502, at the office of the Purchasing Manager, Berg Instructional Center (BIC) Building, Room 1540, 425 Fawell Blvd., Glen Ellyn, IL 60137, until 2:00 PM, Wednesday, April 22, 2015, at which time they will be reviewed for consideration. In the event of office closure due to inclement weather, the deadline will be extended to the next business day at the same time. Any Qualifications received after the date and time stated above will be returned unopened. College of DuPage shall not be responsible for responses that are not received at the specific office location indicated above by the stated deadline. It is solely, the Respondent’s responsibility, to ensure that adequate time is allowed for timely and accurate delivery. No cost proposals are to be submitted with the qualifications. Cost proposals will be requested only after a consultant selection is made REQUESTS FOR INFORMATION/CLARIFICATION If any Respondent submitting a statement of qualifications for this project is in doubt as to the true meaning of the specifications or other documents or any part thereof, Respondent shall request clarification from the Buyer, Kelly Froehlich. Questions must be submitted in writing and be directed via email to the Buyer at: Purchasing@cod.edu no later than Thursday, March 8, 2015 at 5:00pm. Questions for which answers are provided will be communicated to interested vendors via addendum. EQUAL EMPLOYMENT OPPORTUNITY In the hiring of employees for the performance of work under the Contract and any subcontract thereunder, no Contractor or Subcontractor shall, by reason of race, color, sex, religion, national origin, ancestry, age, marital status, disability, unfavorable military discharge or sexual orientation discriminate against any citizen of the United States, in the employment of Labor or workers, who are qualified and available to perform work to which the employment is related. Neither shall any Contractor or Subcontractor, or any person on behalf of either, discriminate against or intimidate any employee hired for the performance of work under this Contract on account of race, color, sex, religion, national origin, ancestry, age, marital status, disability, unfavorable military discharge or sexual orientation. SUBMISSION OF PROPOSALS Respondents shall submit: TWO (2) copies of this entire RFQ, including the Statement of Qualifications, and Certifications pages are to be submitted, in an envelope, to Bid Proposal Box located at: College of DuPage, Room BIC 1540, 425 Fawell Blvd., Glen Ellyn, Illinois 60137, attention Purchasing Manager, no later than the date and hour for the shown in these documents. The envelope submitted by the firm shall carry the Page | 2 following information on the face of the envelope: Firm's name, address, RFQ number and name, advertised date of RFQ Closing and the hour designated for RFQ Closing as shown in the legal advertisement. When hand delivering proposals, Vendors will need to allow sufficient time to locate available parking and report to the stated location. The college will not be responsible nor make allowances for any delays in delivery of proposals In lieu of the above, you may also submit an electronic proposal by emailing the Buyer, Kelly Froehlich at purchasing@cod.edu no later than 2:00p.m. April 22, 2015. Please include the RFQ number and title in the subject line of the electronic submission. INSURANCE GC-15 INSURANCE REQUIREMENTS 1) 2) 3) Prior to the commencement of work the Successful Offeror will provide, at its sole cost and expense, Certificates of Insurance which shall remain in force throughout the term of the agreement, or any extension thereof. The Contractor shall require all policies of insurance that are in any way related to the work and are secured and maintained by Contractor and all tiers of subcontractors to include clauses providing that each underwriter shall waive all of its rights of recovery, under subrogation or otherwise, against College of DuPage, Board of Trustees and employees of the College. The Contractor shall waive all rights of recovery against College of DuPage, Board of Trustees, employees of the College and other Contractors and Subcontractors which Contractor may have or acquired because of deductible clauses in or inadequacy of limits of any policies of insurance that are in any way related to the work and that are secured and maintained by Contractor. The Contractor shall require all tiers of Subcontractors to waive the rights of recovery against College of DuPage and all tiers of Subcontractors. Insurance Requirements of the Contractor Prior to the effective date of this Contract, the Contractor, at its cost, shall secure and maintain at all times, unless specified otherwise, until completion of the term of this Contract the insurance specified below. Nothing contained in these insurance requirements is to be construed as limiting the extent of the Contractor's responsibility for payment of damages resulting from its operations under this Contract. The insurance purchased and maintained by the Contractor shall be primary and not excess or pro rata to any other insurance issued to the College. The Contractor's insurance shall apply separately to each insured against whom claim is made or suit is brought, except with respect to the limits of the insurer's liability. The limits of liability shall be as stated below, unless, prior to the effective date of this Contract, written approval is granted by the College of DuPage Department of Risk Management for variance from those limits. 1. Coverages (a) Workers Compensation Insurance Workers' Compensation shall be in accordance with the laws of the State of Illinois or any other applicable jurisdiction. The Workers Compensation policy shall also include the following provisions: Page | 3 (1) Employers' Liability coverage with a limit of $500,000 each Accident $500,000 each Employee $500,000 Policy Limit for Disease (2) Broad form all states coverage (b) Commercial General Liability Insurance (1) The Commercial General Liability shall be on an occurrence form basis to cover bodily injury and property damage including loss of use. General Liability limits shall not be less than $1,000,000 per occurrence and $2,000,000 aggregate combined single limit for bodily injury and property damage. The General Liability policy shall include, without limitation the following coverages: (e) (c) (a) All premises and operations; (b) Broad Form Blanket Contractual Liability; (c) Products/Completed Operations; (d) Broad Form Property Damage Liability; Cross Liability. Comprehensive Automobile Liability Insurance Comprehensive Automobile Liability to cover all owned, non-owned and hired automobiles, trucks and trailers. The Comprehensive Automobile Liability limits shall not be less than the following: 1) 2) (d) Liability - All Autos: Bodily Injury & Property Damage - $1,000,000 per Occurrence Uninsured/Motorists: Per Illinois Requirements Umbrella/Excess Liability Insurance In addition to the coverages and limits specified above, Contractor and Sub-Contractors of any tier shall secure and maintain a limit of liability no less than: 1) 2) 2. $2,000,000 each occurrence for all liability $2,000,000 in the aggregate per policy year separately with respect to products and completed operations Additional requirements (a) Additional Insured College of DuPage, its officials, employees and agents shall be named as additional insured under the Commercial General Liability policy. (b) Qualification of Insurers All insurance companies providing coverage shall be licensed or approved by the Department of Insurance, State of Illinois, and general rating of "A", and shall be a Class V or higher in the financial size category as listed in A.M. Best's Key Rating Guide, current edition or interim report. Companies with ratings lower than “A”, V will be acceptable only upon written consent of the College of DuPage Department of Risk Management. (c) Insurance Notices All policies of insurance which may be required under terms of this Contract shall be endorsed to provide that the insurance company shall notify the Purchasing Manager, College of DuPage Room BIC 1540, 425 Fawell Blvd., Glen Ellyn, Illinois 60137 at least 30 days prior to the effective date of any cancellation or modification of such policies. When required in the Special Conditions, the successful Bidder shall furnish prior to the date on which Contractor commences performance of the contract, Certificates of Insurance maintained by Contractor. In no event shall any failure of the College to receive Certificates of Insurance required hereof or to demand receipt of such Certificates of Insurance be construed as a waiver of Contractor's obligations to obtain insurance pursuant to these insurance requirements. Page | 4 OBJECTIVE The College of DuPage is accepting statements of qualifications from firms to provide services to evaluate and design a exterior security camera system utilizing existing networks and infrastructure. This RFQ is a solicitation for qualifications and is not a contract or an offer for a contract. Any agreement resulting from this RFQ will be at the discretion of the College of DuPage. The ultimate goal of a selected respondent is to furnish a design package for solicitation of an exterior security camera system on the Glen Ellyn campus. EVALUATION OF RESPONSES This Request for Qualifications shall be used in the selection of a designer for an exterior security camera system. The evaluation of Responses will be based on the total qualifications submittal of the respondent’s design firm. All properly submitted qualification packages will be reviewed, evaluated, and ranked by a committee of College of DuPage representatives. College of DuPage may, at its option, request additional information or an interview with one (1) or more of the top respondents prior to final selection. Qualifications shall not include any information related to the Respondent’s fees, pricing, or compensation. College of DuPage reserves the right to reject any and all responses and re-solicit for new Qualifications. College of DuPage makes no representations, written or oral, that it will enter into any form of an agreement with any Respondent of this RFQ. By submitting its Qualifications in response to this RFQ, Respondent accepts the evaluation process and acknowledges and accepts that determination of the “most qualified” respondent will require subjective judgments by College of DuPage. PROPOSED PROJECT SCHDULE RFQ Due: April 22, 2015 Contact Short List Firms: April 29, 2015 Interview Short List Firms: May 4, 2015 Board Award Design Firm: June 25, 2015 Design development start: July 1, 2015 GENERAL INSTRUCTIONS 1. Submittals shall be prepared simply and economically, providing a straightforward description of the Respondent’s Qualifications as related to the questions and ability to meet the requirements of this RFQ. 2. Emphasis shall be based on quality, completeness, clarity of content, responsiveness to the questions and requirements, and an understanding of project needs for College of DuPage. 3. Respondents are requested to submit (4) copies of qualifications to be received by College of DuPage Purchasing Department on specified date and time. 4. Qualification and any other information submitted by respondents in response to this RFQ shall become property of the Owner. 5. Failure to comply with all requirements contained in this Request for Qualifications may result in rejection of Qualifications submittal Page | 5 STATEMENT OF QUALIFICATIONS Statements of Qualifications must be typewritten, single-spaced separate, single, single-and-a-half, or doublespaced, using both sides of the paper. Please include the following categories, in order. A. Company Profile 1. Company Name: 2. Company Address: 3. Contact Name: 4. Phone Number: 5. Email Address: 6. Number of Years in Business: 7. Number of Employees B. Relevant Experiences and Capabilities 1. List Colleges and Universities where firm has provided design services. 2. List and describe past and present exterior security camera system projects. 3. List security camera and network manufacturers and/or firms that your firm has worked with on past projects. 4. Provide 3 (three) references, including pertinent contact information of all references. C. Organization of Design Team 1. List organization of team members, Electrical Engineers, Civil Engineers, Plan Design Engineers, CAS Designers, etc. which will be assigned to potential project for the College of DuPage. For each Team Member, List: a. Job title b. Years’ experience c. Educational and professional qualifications of each team member (Degree/Certification) d. Experience and any applicable past project list of each team member D. Respondent Approach 1. State briefly what you to be the most pertinent considerations and challenges of this specific project 2. Identify what is unique about your approach to design the services that your company will bring to the College of DuPage. 3. Detail why your firm is currently the best available to provide the requested services to the College of DuPage. Page | 6 E. Milestones Using May 1, 2015 as a start date for design, identify a time schedule with detailed processes and milestones that you would submit to the College of DuPage for completion of a design package, in the below format: Description of Project Phase Estimated Date of Completion DISQUALIFICATION Under no circumstances are respondents to contact or discuss this RFQ with any College of DuPage employee, other than using the methods outlined in this RFQ, any of the information contained herein or about this project in general. Respondents are strictly forbidden from visiting the College’s locations or approaching any College employee, vendor, contractor or subcontractor for any information related to this RFQ or this project without the direct knowledge and authorization in writing in advance from the Purchasing Manager or Buyer. Violation of these provisions may subject the respondent to immediate disqualification. USE OF THE COLLEGE OF DUPAGE NAME Vendors will not use the College of DuPage name or logo in any form or any manner whatsoever without prior written permission from College of DuPage. Page | 7 CERTIFICATIONS THE UNDERSIGNED IS CAUTIONED TO CAREFULLY READ THESE CERTIFICATIONS PRIOR TO SIGNING THE SIGNATURE PAGE. SIGNING THE SIGNATURE PAGE SHALL CONSTITUTE A WARRANTY BY THE UNDERSIGNED THAT ALL THE STATEMENTS, CERTIFICATIONS AND INFORMATION SET FORTH WITHIN THESE CERTIFICATIONS ARE TRUE, COMPLETE AND CORRECT AS OF THE DATE THE SIGNATURE PAGE IS SIGNED. THE UNDERSIGNED IS NOTIFIED THAT IF THE COLLEGE LEARNS THAT ANY OF THE FOLLOWING CERTIFICATIONS WERE FALSELY MADE, THAT ANY CONTRACT ENTERED INTO WITH THE UNDERSIGNED SHALL BE SUBJECT TO TERMINATION. A. Prevailing Wage Act. To the extent required by law, Contractor shall not pay less than the prevailing wage as established pursuant to an Act Regulating the Wages of Laborers, Mechanics, and Other Workman employed under Contract for Public Workers 820 ILCS 130/1 et seq. Our company certifies that it is eligible for proposalding on public contracts and has complied with section 11a of the Prevailing Wage Act, 820 ILCS 130.01-12. Yes_____ No_____ B. Human Rights Act. To the extent required by law, Contractor shall aproposale by the Illinois Human Rights Act, 775 ILCS 10/0.01 et seq. C. Drug Free Workplace. To the extent required by law, Contractor shall aproposale requirements of the Drug Free Workplace Act 30 ILCS 580.1 et seq. with the D. Sexual Harassment Policy. Contractor represents by the signing of this agreement that it has a written sexual harassment policy that is in accordance with 775 ILCS 5/2-105 (A) (4). E. Non-debarment. By executing this agreement Contractor certifies that it has not been debarred from public contracts in the State of Illinois for violating either 33E-3 or 33E-4 of the Public Contracts Act, 720 ILCS 5/33E-1 et seq. F. Fair Employment Practice: Companyr is in compliance with all State and Federal laws regarding Fair Employment Practice as well as all rules and regulations. Yes______ No________ G. Our company has an Equal Employment Opportunity and Affirmative Action Program which complies with Executive Order 11246, the Vietnam Era Veterans’ Readjustment Assistance Act of 1974, and the Rehabilitation Act of 1973. Yes _______ No _______ H Our company certifies that it is eligible for proposalding on public contracts and is not in violation of either paragraph 33E-3 or 33-E-4 of Public Act 86-150, 720ICLS 5 with regards to proposal rigging/proposal rotating.. Yes_______ No_______ I When required by law, the proposal and all proposal’s subcontractors must participate in applicable apprenticeship and training programs approved by and registered with the United States Department of Labor’s Bureau of Apprenticeship and Training as required by Illinois Public Act 093-0642. ADVICE MINORITY/WOMAN-OWNED, DISADVANTAGED BUSINESS? YES_____ NO_____. If yes, please attach copy of certification and advise certification number and expiration date below: STATE NEGOTIATED PROPOSAL/ COOPERATIVE AGREEMENT: YES _____ NO _______ Contract No. ___________ Name of Certifying Entity: _________________________________________________________ Certification #: ________________ _____________ CE-1 Page | 8 Expiration Date: _____ SIGNATURE PAGE Check One: SOLE PROPRIETOR PARTNERSHIP (and/or JOINT VENTURE) LIMITED LIABILITY COMPANY CORPORATION The undersigned acknowledges receipt of a full set of Contract Documents and Addenda Numbers __________________ (None unless indicated here). The undersigned makes the foregoing Proposal subject to all of the terms and conditions of the Contract Documents. The undersigned certifies that all of the foregoing statements of the Vendor Certifications are true and correct. The undersigned warrants that all of the facts and information submitted by the undersigned in connection with this Proposal are true and correct. Upon award and execution of this Contract by the College of DuPage Board of Trustees, the undersigned agrees that execution of this Proposal shall stand as the undersigned's execution of this Contract. BUSINESS NAME:__________________________________________________________________________ BUSINESS ADDRESS: ____________________________________________________________________________________________ BUSINESS TELEPHONE: FAX NUMBER: EMAIL ADDRESS: CELLULAR TELEPHONE NUMBER: FEIN/SSN: AUTHORIZED SIGNATURE: _______ PRINT NAME: TITLE: _____________________________________________________________________________________ DATE: Subscribed to and sworn before me this day of , 2015. My commission expires: X Notary Public Signature Notary Seal * Attach hereto a partnership resolution or other document authorizing the individual signing this Signature Page to so sign on behalf of the Partnership. ** If the LLC is not registered in the State of Illinois, a copy of a current Certificate of Good Standing from the state of incorporation must be submitted with this Signature Page. *** Attach either a certified copy of the by-laws, articles, resolution or other authorization demonstrating such persons to sign the Signature Page on behalf of the LLC. *** If the corporation is not registered in the State of Illinois, a copy of the Certificate of Good Standing from the state of incorporation must be submitted with this Signature Page. ***** In the event that this Signature Page is signed by any persons other than the President and Secretary, attach either a certified copy of the corporate by-laws, a resolution or other authorization by the corporation, authorizing such persons to sign the Signature Page on behalf of the corporation. Page | 9 Purchasing Department 425 Fawell Boulevard Glen Ellyn, Illinois 60137-6599 http://www.cod.edu PHONE (630) 942-2813 FAX (630) 942-3750 2015-R0025 Design and Contract Administration of Campus-Wide Exterior Security Camera Plan Qualifications due Wednesday 4/22/2015 at 2:00pm CST ADDENDUM 4/16/2015 This addendum is issued to address questions. 1. Do you know how many cameras are estimated to be installed? Approximately 30. 2. What video management software is used currently? Exaqu 3. How many copies of RFQ should be submitted? Please submit 2 (two) printed copies or one email Bid by the due date. 4. What is the actual due date for questions? Questions were due April 15, by 5:00pm. However due to a typo in the documents, questions will be accepted until 4/17/2015 at 3:00PM CST. 5. We would not typically hire the electrical engineer, civil engineer, etc. These other disciplines are sometime brought on by the Owner. Is that an option for this project or is it required that we list other designers / engineers as part of our team? The College is requiring that the winning Firm bring on their own Engineers. 6. Can the College of DuPage tell us which designers/engineering firms have performed work for the College in the past and which firms have performed satisfactorily? It is the responsibility of the bidding Firm to make these decisions. Firm should not limit themselves to only C.O.D. recommendations, and therefore will not be able to provide a list. If you have not yet submitted your qualifications, please sign this addendum and include with your submission. If you have already submitted your qualifications,, please sign and return to Kelly Froehlich at purchasing@cod.edu purchasing@cod.edu prior to the bid opening, even if you have not bid on this particular item. You also have the option of withdrawing your bid if necessary. Please contact Kelly Froehlich with further questions. I HAVE RECEIVED ADDENDUM #1 _________________________________ Authorized Signature FIRM NAME & ADDRESS: __________________________________ __________________________________ ___________________________________ Sincerely, Purchasing Department College of DuPage Purchasing Department 425 Fawell Boulevard Glen Ellyn, Illinois 60137-6599 http://www.cod.edu PHONE (630) 942-2813 FAX (630) 942-3750 2015-R0025 Design and Contract Administration of Campus-Wide Exterior Security Camera Plan Qualifications due Wednesday 4/22/2015 at 2:00pm CST ADDENDUM #2 4/17/2015 This addendum is issued to address questions. Under A. Milestones, Firms are asked to use “May 1, 2015 as a start date for design, identify a time schedule with detailed processes and milestones that you would submit to the College of DuPage for completion of a design package…” Explanation: This is a sample timeline of how you would plan milestones, and not intended to be a proposal. The contract date will begin July 1, 2015, at which time the actual milestones will be planned. If you have not yet submitted your qualifications, please sign this addendum and include with your submission. If you have already submitted your qualifications,, please sign and return to Kelly Froehlich at purchasing@cod.edu purchasing@cod.edu prior to the bid opening, even if you have not bid on this particular item. You also have the option of withdrawing your bid if necessary. Please contact Kelly Froehlich with further questions. I HAVE RECEIVED ADDENDUM #1 _________________________________ Authorized Signature FIRM NAME & ADDRESS: __________________________________ __________________________________ ___________________________________ Sincerely, Purchasing Department College of DuPage