PROJECT MANUAL ENGINEERING BUILDING POWER FACTOR CORRECTION PROJECT NUMBER 16-019 FEBRUARY 3, 2016 TABLE OF CONTENTS Pages Table of Contents CONTRACT DOCUMENTS Section Invitation for Bids SBP 6.13 Bid SC 6.21 Contractor’s Design/Bid/Build (D/B/B) Agreement SBP 6.13 Contractor’s Bid SC 6.221 Labor and Material Bond Contractor’s Insurance Certificate(s) UI 1 Certification and Affidavit Regarding Unauthorized Immigrants Building Code Compliance Policy University Insurance Requirements A SC 6.23 The General Conditions of the Contractor’s Design/Bid/Build (D/B/B) Agreement DIVISION 01 – GENERAL CONDITIONS Section 01 00 00 General Conditions 01 02 00 Administration and Supervision 01 04 00 Project Coordination 01 09 00 Reference Standards 01 15 00 Administration, Procedures, Codes 01 30 00 Submittals 01 45 00 Cutting and Patching 01 54 00 Safety and Health 01 60 00 Materials and Equipment 01 70 00 Project Closeout 01 71 00 Cleaning 01 74 00 Warranties and Bonds 01 78 00 Definitions and Explanations 7 3 4 2 7 6 4 3 4 4 1 3 4 END OF TABLE OF CONTENTS IT Emergency Generator Project Number: 16007 January 25, 2016 TABLE OF CONTENTS TOC - 1 100% CD INVITATION FOR BIDS State of Colorado University of Colorado Colorado Springs Project No.: 16-019 Project Title: Engineering Building – Power Factor Correction Estimated Construction Cost: $ 40,000.00 Project Description This project is intended to correct the low power factor of the engineering building as seen by electrical utility company. Provide (2) automatic capacitor banks for the existing (2) main distribution centers “MDC1” and “MDC2”. Provide a 275 kVAR, 480V, 3 phase capacitor bank with integral main circuit breaker and NEMA 3R enclosure for “MDC1”. This unit will be located outside the building and adjacent to the electrical room wall. Provide a 75 kVAR, 480V, 3 phase capacitor bank with a NEMA 1 enclosure for “MDC2”. This unit will be located in the main electrical room. Provide all conduit, conductors, switches and fuses as required. Provide required sealing for all penetrations through exterior walls. The right is reserved to waive informalities or irregularities and to reject any and all bids. Bidder may procure bidding documents from the University website: http://www.uccs.edu/facsrvs/planning-design-and-construction/projects-out-for-bid.html A Deposit will not be required for each complete set of Contract Documents as documents are only available on the above noted web site. Bidders are to download PDF copies of the documents from the web site for their use, and reproduced as needed at their own expense. Each Bid shall be submitted on the required Bid Form and must be accompanied by a Bid Bond on State Building Programs Bid Bond Form SC 6.14 in an amount not less than 5% of the total Bid (included in the bid documents). The Bid Bond may also be (1) a cashier’s check or (2) a certified check made payable to the Treasurer of the State of Colorado in an amount not less than 5% of the total Bid. The Bid Bond is submitted as a guaranty that the Bid will be maintained in full force and effect for a period of thirty (30) days after the opening of the Bids for the project. Contractor’s Registration is not required. Electronic Bids shall be received by email at: Address: University of Colorado Colorado Springs Sherry Reed – Project Manager sreed@uccs.edu Submission Deadline: Wednesday, February 17th, 2016 @ 2:00 PM Point of Contact: Agency: Phone: Email: Sherry Reed University of Colorado Colorado Springs 719-255-3758 sreed@uccs.edu Media of Publication: http://www.uccs.edu/facsrvs/planning-design-and-construction/projects-out-for-bid.html Publication Date: February 1st, 2016 STATE OF COLORADO OFFICE OF THE STATE ARCHITECT STATE BUILDINGS PROGRAMS BID REGENTS OF THE UNIVERSITY OF COLORADO, a body corporate, acting by and through the Institution/Agency: UNIVERSITY OF COLORADO COLORADO SPRINGS Project No./Name: 16-019 / Engineering Building Power Factor Correction Bidder Acknowledges Receipt of Addenda Numbers: Bidder Anticipates Services outside the United States or Colorado: Bidder will comply with 80% Colorado Labor on project above $500,000: Bidder is a Service-Disabled Veteran Owned Small Business: Base Bid No Yes No Yes No Yes If Yes see 3A below If No see 3B below If Yes see 3C below $ (Refer to Bid Alternate Form SC-6.13.1 Attached, If Applicable) Bidder’s Time of Completion a. Time Period from Notice to Proceed to Substantial Completion: b. Time Period from Substantial Completion to Final Acceptance: c. Total Time of Completion of Entire Project (a + b): 1. BID: Pursuant to the advertisement by the State of Colorado dated February 3, 2016 the undersigned bidder hereby proposes to furnish all the labor and materials and to perform all the work required for the complete and prompt execution of everything described or shown in or reasonably implied from the Bidding Documents, including the Drawings and Specifications, for the work and for the base bid indicated above. Bidders should include all taxes that are applicable. 2. EXAMINATION OF DOCUMENTS AND SITE: The bidder has carefully examined the Bidding Documents, including the Drawings and Specifications, and has examined the site of the Work, so as to make certain of the conditions at the site and to gain a clear understanding of the work to be done. 3. PARTIES INTERESTED IN BID: The bidder hereby certifies that the only persons or parties interested in this Bid are those named herein, and that no other bidder or prospective bidder has given any information concerning this Bid. A. If the bidder anticipates services under the contract or any subcontracts will be performed outside the United States or Colorado, the bidder shall provide in a written statement which must include, but need not be limited to the type of services that will be performed at a location outside the United States or Colorado and the reason why it is necessary or advantageous to go outside the United States or Colorado to perform such services. (Does not apply to any project that receives federal moneys) B. For State Public Works projects per C.R.S. 8-17-101, Colorado labor shall be employed to perform at least 80% of the work. Colorado Labor means any person who is a resident of the state of Colorado at the time of the Public Works project. Bidders indicating that their bid proposal will not comply with the 80% Colorado Labor requirement are required to submit written justification along with the bid submission. (Does not apply to any project that receives federal moneys– C. A Service-Disabled Veteran Owned Small Business (SDVOSB) per C.R.S. 24-103-211, means a business that is incorporated or organized in Colorado or maintains a place of business or has an office in Colorado and is officially registered and verified by the Center for Veteran Enterprise within the U.S. Department of Veteran Affairs. Attach proof of certification along with the bid submission. 4. BID GUARANTEE: This Bid is accompanied by the required Bid Guarantee. You are authorized to hold said Bid Guarantee for a period of not more than thirty (30) days after the opening of the Bids for the work above indicated, unless the undersigned bidder is awarded the Contract, within said period, in which event the Director, State Buildings Programs, may retain said Bid Guarantee, until the undersigned bidder has executed the required Agreement and furnished the required Performance Bond, Labor and Material Payment Bond, Insurance Policy and Certificates of Insurance and Affidavit Regarding Unauthorized Immigrants. 5. TIME OF COMPLETION: The bidder agrees to achieve Substantial Completion of the Project from the date of the Notice to Proceed within the number of calendar days entered above, and in addition, further agrees that the period between Substantial Completion and Final Acceptance of the Project will not exceed the number of State Form SBP-6.13 Rev.7/2015 6. 7. 8. 9. calendar days noted above. If awarded the Work, the bidder agrees to begin performance within ten (10) days from the date of the Notice to Proceed subject to Article 46, Time of Completion and Liquidated Damages of The General Conditions of the Contract, and agrees to prosecute the Work with due diligence to completion. The bidder represents that Article 7D of the Contractor’s Agreement (SC-6.21) has been reviewed to determine the type and amount of any liquidated damages that may be specified for this contract. EXECUTION OF DOCUMENTS: The bidder understands that if this Bid is accepted, bidder must execute the required Agreement and furnish the required Performance Bond, Labor and Material Payment Bond, Insurance Policy and Certificates of Insurance and Affidavit Regarding Unauthorized Immigrants within ten (10) days from the date of the Notice of Award, and that the bidder will be required to sign to acknowledge and accept the Contract Documents, including the Drawings and Specifications. ALTERNATES: Refer to the Information for Bidders (SC-6.12) for Method of Award for Alternates and use State Form SBP-6.13.1 Bid Alternates form to be submitted with this bid form if alternates are requested by the institution/agency in the solicitation documents. Submit wage rates (direct labor costs) for prime contractor and subcontractor as requested by the institution/agency in the solicitation documents. The right is reserved to waive informalities and to reject any and all Bids. SIGNATURES: If the Bid is being submitted by a Corporation, the Bid shall be signed by an officer, i.e., President or Vice-President. If a sole proprietorship or a partnership is submitting the Bid, the Bid shall so indicate and be properly signed. Dated this Day of , 20 THE BIDDER: Company Name Address (including city, state and zip) Phone number: Name (Print) and Title State Form SBP-6.13 Rev.7/2015 Signature STATE OF COLORADO OFFICE OF THE STATE ARCHITECT STATE BUILDINGS PROGRAM CONTRACTOR'S DESIGN/BID/BUILD (D/B/B) AGREEMENT (STATE FORM SC-6.21) DEPARTMENT ID: N/A CONTRACT ID #: N/A PROJECT #: 16-019 PROJECT NAME: Rev. 7/2015 SC-6.21 Engineering Building Power Factor Correction STATE OF COLORADO OFFICE OF THE STATE ARCHITECT STATE BUILDINGS PROGRAM CONTRACTOR'S DESIGN/BID/BUILD AGREEMENT (STATE FORM SC-6.21) TABLE OF CONTENTS……………………………………………………………………………………Page RECITALS……………………………………………………………………………………………………… 1 ARTICLE 1. ARTICLE 2. ARTICLE 3. ARTICLE 4. ARTICLE 5. ARTICLE 6. ARTICLE 7. 1. 2. 3. 4. 5. PERFORMANCE OF THE WORK………………………………………………………….. PROVISIONS OF THE CONTRACT DOCUMENTS……………………………………... TIME OF COMPLETION…………………………………………………………………….. ESSENTIAL CONDITIONS…………………………………………………………………. CONTRACT SUM…………………………………………………………………………….. CONTRACT DOCUMENTS…………………………………………………………………. OPTIONAL PROVISIONS AND ELECTIONS…………………………………………….. MODIFICATION OF ARTICLE 45. GUARANTEE INSPECTIONS AFTER COMPLETION………………………………………………………………………………… MODIFICATION OF ARTICLE 27. LABOR AND WAGES…………………………….… MODIFICATION OF ARTICLE 39. NON-BINDING DISPUTE RESOLUTION – FACILITATED NEGOTIATIONS……………………………………………………………. MODIFICATION OF ARTICLE 46. TIME OF COMPLETION AND LIQUIDATED DAMAGES…………………………………………………………………………………….. NOTICE IDENTIFICATION………………………………………………………………….. 1 1 1 2 2 2 2 2 2 2 2 3 SIGNATURE APPROVALS………………………………………………………………………………….. 4 EXHIBITS: A. Contractor's Bid (Form SC-6.13) B. Performance Bond (Form SC-6.22) C. Labor and Material Payment Bond (Form SC-6.221) D. Insurance Certificates E. Certification and Affidavit Regarding Unauthorized Immigrants (required at contract signing prior to commencing work) F. Building Code Compliance Policy: Coordination of Approved Building Codes, Plan Reviews and Building Inspections. G. University Insurance Requirements A SC-6.21 Rev. 7/2015 i STATE OF COLORADO OFFICE OF THE STATE ARCHITECT STATE BUILDINGS PROGRAM CONTRACTOR'S DESIGN/BID/BUILD (D/B/B) AGREEMENT (STATE FORM SC-6.21) Department ID: N/A Contract ID #: N/A Project #: 16-019 1. PARTIES. THIS AGREEMENT is entered into by and between the STATE OF COLORADO, acting by and through the REGENTS OF THE UNIVERSITY OF COLORADO, a body corporate, acting by and through the UNIVERSITY OF COLORADO COLORADO SPRINGS, hereinafter referred to as the Principal Representative, and ______ having its offices at ______ hereinafter referred to as the Contractor. 2. EFFECTIVE DATE AND NOTICE OF NONLIABILITY. This Agreement shall not be effective or enforceable until it is approved and signed by the State Controller or its designee (hereinafter called the “Effective Date”), but shall be effective and enforceable thereafter in accordance with its provisions. The State shall not be liable to pay or reimburse Contractor for any performance hereunder or be bound by any provision hereof prior to the Effective Date. RECITALS: WHEREAS, the Principal Representative intends to _correct the low power factor of the engineering building as seen by electrical utility company by providing (2) automatic capacitor banks for the existing (2) main distribution centers “MDC1” and “MDC2”. Providing a 275 kVAR, 480V, 3 phase capacitor bank with integral main circuit breaker and NEMA 3R enclosure for “MDC1”. This unit will be located outside the building and adjacent to the electrical room wall. Providing a 75 kVAR, 480V, 3 phase capacitor bank with a NEMA 1 enclosure for “MDC2”. This unit will be located in the main electrical room and providing all conduit, conductors, switches and fuses as required. Contractor will also provide required sealing for all penetrations through exterior walls._ hereinafter called the Project; and WHEREAS, authority exists in the Law and Funds have been budgeted, appropriated, and otherwise made available, and a sufficient unencumbered balance thereof remains available for payment In Fund Number __N/A____, Account Number _ _; and WHEREAS, this is a phase one waived contract, waiver number 156 Contractors Agreement for Capital Construction Form SC6.21. WITNESSETH, that the State of Colorado and the Contractor agree as follows: ARTICLE 1. PERFORMANCE OF THE WORK The Contractor shall perform all of the Work required for the complete and prompt execution of everything described or shown in, or reasonably implied from the Contract Documents for the above referenced Project. ARTICLE 2. PROVISIONS OF THE CONTRACT DOCUMENTS The Contractor agrees to perform the Work to the highest industry standards and to the satisfaction of the State of Colorado and its Architect/Engineer in strict accordance with the provisions of the Contract Documents. SC-6.21 Rev. 7/2015 Page 1 of 4 ARTICLE 3. TIME OF COMPLETION The Contractor agrees to Substantially Complete the Project within __ calendar days from the date of the Notice to Proceed, in addition, the Contractor agrees to finally complete the Project from Substantial Completion to Final Acceptance within __ calendar days for a total time of completion of the entire Project of __ calendar days. The Contractor shall perform the Work with due diligence to completion. ARTICLE 4. ESSENTIAL CONDITION Timely completion of the Project is an essential condition of this Agreement. The Contractor shall be subject to any liquidated damages described in Article 7D for failure to satisfactorily complete the Work within the time periods in Article 3 above. ARTICLE 5. CONTRACT SUM The Contractor shall be paid for the performance of this Agreement, subject to any additions and deductions as provided for in Articles 32, 34 and 35 of The General Conditions of the Construction Contract SC-6.23, the sum of ________ DOLLARS AND NO/100* ($________*). ARTICLE 6. CONTRACT DOCUMENTS The Contract Documents, as enumerated in Article 1 of The General Conditions of the Contractor’s Design/Bid/Build (D/B/B) Agreement SC-6.23, are all essential parts of this Agreement and are fully incorporated herein. ARTICLE 7. OPTIONAL PROVISIONS AND ELECTIONS The provisions of this Article 7 alter the Articles (The General Conditions of the Contractor’s Design/Bid/Build Agreement SC-6.23) or enlarge upon them as indicated: The Principal Representative and or the State Buildings Program shall mark boxes and initial where applicable. 1. MODIFICATION OF ARTICLE 45. GUARANTEE INSPECTIONS AFTER COMPLETION If the box below is marked the six month guarantee inspection is not required. ______ Principal Representative initial 2. MODIFICATION OF ARTICLE 27. LABOR AND WAGES If the box is marked the Federal Davis-Bacon Act shall be applicable to the Project. The minimum wage rates to be paid on the Project shall be furnished by the Principal Representative and included in the Contract Documents. ______ Principal Representative initial 3. MODIFICATION OF ARTICLE 39. NON-BINDING DISPUTE RESOLUTION – FACILITATED NEGOTIATIONS If the box is marked, and initialed by the State as noted, the requirement to participate in facilitated negotiations shall be deleted from this Contract. Article 39, Non-Binding Dispute Resolution – Facilitated Negotiations, shall be deleted in its entirety and all references to the right to the same where ever they appear in the contract shall be similarly deleted. The box may be marked only for projects with an estimated value of less than $500,000. ______ Principal Representative initial SC-6.21 Rev. 7/2015 Page 2 of 4 4. MODIFICATION OF ARTICLE 46. TIME OF COMPLETION AND LIQUIDATED DAMAGES If an amount is indicated immediately below, liquidated damages shall be applicable to this Project as, and to, the extent shown below. Where an amount is indicated below, liquidated damages shall be assessed in accordance with and pursuant to the terms of The General Conditions of the Design/Bid/Build Agreement Article 46, Time of Completion And Liquidated Damages, in the amounts and as here indicated. The election of liquidated damages shall limit and control the parties right to damages only to the extent noted. 1. For the inability to use the Project, for each day after the number of calendar days specified in the Contractor’s bid for the Project and the Agreement for achievement of Substantial Completion, until the day that the Project has achieved Substantial Completion and the Notice of Substantial Completion is issued, the Contractor agrees that an amount equal to _____________________________ ($ ) shall be assessed against Contractor from amounts due and payable to the Contractor under the Contract, or the Contractor and the Contractor’s Surety shall pay to the Principal Representative such sum for any deficiency, if amounts on account thereof are deducted from remaining amounts due, but amounts remaining are insufficient to cover the entire assessment. 2. For damages related to or arising from additional administrative, technical, supervisory and professional expenses related to and arising from the extended closeout period, for each day in excess of the number of calendar days specified in the Contractor’s bid for the Project and the Agreement to finally complete the Project as defined by the issuance of the Notice of Final Acceptance) after the issuance of the final Notice of Substantial Completion, the Contractor agrees that an amount equal to ____________________________________ ($ ) shall be assessed against Contractor from amounts due and payable to the Contractor under the Contract, or the Contractor and the Contractor’s Surety shall pay to the Principal Representative such sum for any deficiency, if amounts on account thereof are deducted from remaining amounts due but amounts remaining are insufficient to cover the entire assessment. 5. NOTICE IDENTIFICATION All Notices pertaining to General Conditions or otherwise required to be given shall be transmitted in writing, to the individuals at the addresses listed below, and shall be deemed duly given when received by the parties at their addresses below or any subsequent persons or addresses provided to the other party in writing. Notice to Principal Representative: Gary Reynolds, PE With copies to (State Buildings Program (or Delegate) State of Colorado): Carolyn Fox, RA Notice to Contractor: With copies to: Sherry Reed, UCCS Project Manager SC-6.21 Rev. 7/2015 Page 3 of 4 SIGNATURE APPROVALS: THE PARTIES HERETO HAVE EXECUTED THIS CONTRACT *Persons signing for Contractor hereby swear and affirm that they are authorized to act on Contractor’s behalf and acknowledge that the State is relying on their representations to that effect. Principal is not a recognized title and will not be accepted THE CONTRACTOR STATE OF COLORADO, acting by and through: (Insert Name & Title of Agency or IHE) By: Legal Name of Contracting Entity Gary Reynolds, P.E., Principal Representative Date: *Signature By Name (print) Dat e: Title APPROVED DEPARTMENT OF PERSONNEL & ADMINISTRATION STATE BUILDINGS PROGRAM State Architect (or authorized Delegate) By: Carolyn Fox, RA, Delegee Date: ALL CONTRACTS MUST BE APPROVED BY THE STATE CONTROLLER: CRS §24-30-202 requires the State Controller to approve all State Contracts. This Contract is not valid until signed and dated below by the State Controller or delegate. Contractor is not authorized to begin performance until such time. If Contractor begins performing prior thereto, the State of Colorado is not obligated to pay Contactor for such performance or for any goods and/or services provided hereunder. APPROVED: STATE OF COLORADO STATE CONTROLLER'S OFFICE State Controller (or authorized Delegate) By: Julie Brewster, CPA, Delegee Date: SC-6.21 Rev. 7/2015 Page 4 of 4 STATE OF COLORADO OFFICE OF THE STATE ARCHITECT STATE BUILDINGS PROGRAM CONTRACTOR'S DESIGN/BID/BUILD AGREEMENT (STATE FORM SC-6.21) EXHIBIT A CONTRACTOR’S BID (Form SBP-6.13) STATE OF COLORADO OFFICE OF THE STATE ARCHITECT STATE BUILDINGS PROGRAM CONTRACTOR'S DESIGN/BID/BUILD AGREEMENT (STATE FORM SC-6.21) EXHIBIT B PERFORMANCE BOND (Form SC-6.22) Not Required STATE OF COLORADO OFFICE OF THE STATE ARCHITECT STATE BUILDINGS PROGRAM CONTRACTOR'S DESIGN/BID/BUILD AGREEMENT (STATE FORM SC-6.21) EXHIBIT C LABOR AND MATERIAL PAYMENT BOND (Form SC-6.221) STATE OF COLORADO OFFICE OF THE STATE ARCHITECT STATE BUILDINGS PROGRAMS LABOR AND MATERIAL BOND Regents of the University of Colorado, a body corporate, acting by and through the Institution/Agency: University of Colorado Colorado Springs Project No./Name: 16-019 / Engineering Building Power Factor Correction BONDING COMPANY: DO NOT MAKE ANY CHANGES TO THE LANGUAGE IN THIS BOND. KNOW ALL PERSONS BY THESE PRESENTS: That the Contractor: and University of Colorado Colorado Springs 1420 Austin Bluffs Parkway Colorado Springs, CO 80918 as Principal and hereinafter called "Principal," and as Surety and hereinafter called "Surety," a corporation organized and existing under the laws of are held and firmly bound unto the STATE OF COLORADO acting by and through (agency or institution) hereinafter called "Principal Representative," and to all subcontractors and any others who have supplied or furnished or shall supply or furnish materials, rental machinery, tools, or equipment actually used in the performance of the hereinafter identified Contract, or who have performed or shall perform labor in the performance of or in connection with said Contract, hereinafter called "Obligees" in the sum of . Dollars and No/100 Dollars ($ ) together with interest at the rate of eight per cent (8%) per annum on all payments becoming due in accordance with said Contract, from the time such payments shall become due until such payment shall be made, for the payment of which, well and truly made to the Obligees, the Principal and the Surety bind themselves, their heirs, executors, administrators, successors and assigns, jointly and severally, firmly, by these presents. WHEREAS, the Principal and the State of Colorado acting by and through the Principal Representative have entered into a certain Contract, hereinafter called "Contract," dated _______________, 20 for the construction of a PROJECT described as 16-019 / Engineering Power Factor Correction which Contract is hereby by reference made a part hereof; State Form SC-6.221 (Rev. 9/2008) Page 1 of 2 NOW, THEREFORE, THE CONDITION OF THIS OBLIGATION is such that if the Principal and the Surety shall fully indemnify and save harmless the State of Colorado and the Principal Representative from and against any and all costs and damages, including patent infringements, which either may suffer by reason of any failure or failures of the Principal promptly and faithfully to perform all terms and conditions of said Contract and shall fully reimburse and repay the State of Colorado and the Principal Representative all outlay and expense which the State of Colorado and the Principal Representative may incur in making good any such failure or failures, and further, if the Principal and his subcontractors shall duly and promptly pay for any and all labor, materials, team hire, sustenance, provisions, provender, rental machinery, tools, or equipment and other supplies which have been or shall be used or consumed by said Principal or his subcontractors in the performance of the work of said Contract , and it said Principal shall duly and promptly pay all his subcontractors the sums due them for any and all materials, rental machinery, tools, or equipment and labor that have been or shall be furnished, supplied, performed or used in connection with performance of said Contract, and shall also fully indemnify and save harmless the State of Colorado and the Principal Representative to the extent of any and all expenditures which either or both of them may be required to make by reason of any failures or defaults by the Principal or any subcontractor in connection with such payments; then this obligation shall be null and void, otherwise it shall remain in full force and effect. It is expressly understood and agreed that any alterations which may be made in the terms of said Contract or in the work to be done under said Contract, or any extension(s) of time for the performance of the Contract, or any forebearance on the part of either the State of Colorado or the Principal to any of the others, shall not in any way release the Principal and the Surety, or either of them, their heirs, executors, administrators, successors or assigns from their liability hereunder, notice to the Surety of any such alteration, extension or forbearance being hereby waived. IN WITNESS WHEREOF, the Principal and the Surety have executed this Bond, this , A.D., 2016. (Corporate Seal) day of THE PRINCIPAL ATTEST: By: Title: Secretary (Corporate Seal) SURETY By: Attorney-in-fact THIS BOND MUST BE ACCOMPANIED BY POWER OF ATTORNEY, EFFECTIVELY DATED Note: State Form SC-6.221 (Rev. 9/2008) This bond is issued simultaneously with another bond conditioned for the full and faithful performance of the contract. Page 2 of 2 STATE OF COLORADO OFFICE OF THE STATE ARCHITECT STATE BUILDINGS PROGRAM CONTRACTOR'S DESIGN/BID/BUILD AGREEMENT (STATE FORM SC-6.21) EXHIBIT D INSURANCE CERTIFICATE(S) (attached) STATE OF COLORADO OFFICE OF THE STATE ARCHITECT STATE BUILDINGS PROGRAM CONTRACTOR'S DESIGN/BID/BUILD AGREEMENT (STATE FORM SC-6.21) EXHIBIT E Certification and Affidavit Regarding Unauthorized Immigrants (required at contract signing prior to commencing work) (UI-1, attached) STATE OF COLORADO OFFICE OF THE STATE ARCHITECT STATE BUILDINGS PROGRAMS CERTIFICATION AND AFFIDAVIT REGARDING UNAUTHORIZED IMMIGRANTS Institution/Agency: Project No./Name: Regents of the University of Colorado, a body corporate, acting by and through the University of Colorado Colorado Springs 16-019 / Engineering Building Power Factor Correction A. CERTIFICATION STATEMENT CRS 8-17.5-101 & 102 (HB 06-1343, SB 08-193) The Vendor, whose name and signature appear below, certifies and agrees as follows: 1. The Vendor shall comply with the provisions of CRS 8-17.5-101 et seq. The Vendor shall not knowingly employ or contract with an unauthorized immigrant to perform work for the State or enter into a contract with a subcontractor that knowingly employs or contracts with an unauthorized immigrant. 2. The Vendor certifies that it does not now knowing employ or contract with and unauthorized immigrant who will perform work under this contract, and that it will participate in either (i) the “E-Verify Program”, jointly administered by the United States Department of Homeland Security and the Social Security Administration, or (ii) the “Department Program” administered by the Colorado Department of Labor and Employment in order to confirm the employment eligibility of all employees who are newly hired to perform work under this contract. 3. The Vendor shall comply with all reasonable requests made in the course of an investigation under CRS 8-17.5-102 by the Colorado Department of Labor and Employment. If the Vendor fails to comply with any requirement of this provision or CRS 8-17.5-101 et seq., the State may terminate work for breach and the Vendor shall be liable for damages to the State. B. AFFIDAVIT CRS 24-76.5-101 (HB 06S-1023) 1. If the Vendor is a sole proprietor, the undersigned hereby swears or affirms under penalty of perjury under the laws of the State of Colorado that (check one): I am a United States citizen, or I am a Permanent Resident of the United States, or I am lawfully present in the United States pursuant to Federal law. I understand that this sworn statement is required by law because I am a sole proprietor entering into a contract to perform work for the State of Colorado. I understand that state law requires me to provide proof that I am lawfully present in the United States prior to starting work for the State. I further acknowledge that I will comply with the requirements of CRS 24-76.5-101 et seq. and will produce the required form of identification prior to starting work. I acknowledge that making a false, fictitious, or fraudulent statement or representation in this sworn affidavit is punishable under the criminal laws of Colorado as perjury in the second degree under CRS 18-8-503 and it shall constitute a separate criminal offense each time a public benefit is fraudulently received. CERTIFIED and AGREED to this _ ____ day of ___ ___, _20 VENDOR: Vendor Full Legal Name BY: Signature of Authorized Representative State Form UI-1 Issued 7/2008 Page 1 of 1 Title __. STATE OF COLORADO OFFICE OF THE STATE ARCHITECT STATE BUILDINGS PROGRAM CONTRACTOR'S DESIGN/BID/BUILD AGREEMENT (STATE FORM SC-6.21) EXHIBIT F Building Code Compliance Policy: Coordination of Approved Building Codes, Plan Reviews and Building Inspections OFFICE OF THE STATE ARCHITECT STATE BUILDINGS PROGRAMS POLICIES AND PROCEDURES BUILDING CODE COMPLIANCE POLICY: COORDINATION OF APPROVED BUILDING CODES, PLAN REVIEWS AND BUILDING INSPECTIONS Updates from 2010 Updates from 2011 Updates from 2012 Updates from 2013 Rev. 7/2013 OFFICE OF THE STATE ARCHITECT/STATE BUILDINGS PROGRAMS POLICIES AND PROCEDURES BUILDING CODE COMPLIANCE COORDINATION OF APPROVED BUILDING CODES, PLAN REVIEWS AND BUILDING INSPECTIONS TABLE OF CONTENTS INTRODUCTION A. Intent B. Statutory Responsibilities/Executive Order SECTION I. BUILDING CODES A. Approved Building Codes See Exhibit A – Approved Building Codes B. Requests To Change The Application Of Certain Provisions Of The Code 1. Alternative Methods 2. Modifications 3. Appeals 4. Amendments 5. Code Deficiencies in Existing Buildings SECTION II. CODE COMPLIANCE PLAN REVIEWS A. Code Compliance Plan Reviews See Exhibit B – Plan Review Procedures B. Notice to Proceed (Construction Permit) SECTION III. BUILDING INSPECTIONS A. B. C. D. Building Inspection Record Building Inspection Authorization Inspection Report Building Occupancy/Documentation SECTION IV. COORDINATION WITH OTHER STATE AGENCIES A. B. C. D. E. F. G. Department of Regulatory Agencies/State Plumbing and Electrical Boards Department of Labor and Employment/State Boiler Inspector Department of Labor and Employment/Conveyance Administrator Local Fire Jurisdictions and Department of Public Safety/Division of Fire Safety Department of Public Health and Environment/Division of Consumer Protection Department of Local Affairs/Division of Housing Department of Public Health and Environment/Division of Air Pollution Control SECTION V. COMPLIANCE A. Agency Action Plan for Building Code Compliance B. Building Code Compliance Documentation Submittal Rev. 7/2013 1 OFFICE OF THE STATE ARCHITECT/STATE BUILDINGS PROGRAMS POLICIES AND PROCEDURES BUILDING CODE COMPLIANCE COORDINATION OF APPROVED BUILDING CODES, PLAN REVIEWS AND BUILDING INSPECTIONS Exhibits A – Approved Building Codes B – Plan Review Procedures C – Plan Review Authorization (SBP-017) D – Building Inspection Record (SBP-BIR) E– Building Inspection Authorization (SBP-018) F – Inspection Report (SBP-019) G – Notice to Proceed (SBP-6.26) or (SBP-7.26) H – Notice of Substantial Completion (SBP-07) I – Notice of Approval of Occupancy/Use (SBP-01) J – Notice of Final Acceptance (SC-6.27) K – Agency Action Plan for Code Compliance L – Code Compliance Documentation Submittal M – Request for Modification References 1. Colorado Revised State Statutes: 9-4-101-118, Article 4 9-5-101-106, Article 5 12-23-100.2-120, Article 23 25-4-1601, Part 16 Boiler Inspection, Department of Labor and Employment Department of Personnel Electricians, Department of Regulatory Agencies Food Service Establishments, Department of Public Health and Environment 12-58-101-117, Article 58 Plumbers, Department of Regulatory Agencies 24-30-1301-1307, Part 13 State Buildings, Department of Personnel 24-30-1401-1408, Part 14 Negotiations of Consultant’s Contracts, Department of Personnel 24-32-3301-3327, Part 33 Division of Housing, Department of Local Affairs 24-33.5-1201-1210, Part 12 Division of Fire Safety, Department of Public Safety 9-1-101-106, Article 1 Construction Requirements 9-1.3-101-105, Article 1.5 Low Flow Plumbing Fixtures 9-5.5-101-120, Article 5.5 Elevator and Escalator Certification, Department of Labor and Employment 24-82-901-902, Part 9 Outdoor Lighting Fixtures 25-7-501-512, Part 5 Division of Air Pollution Control, Department of Public Health and Environment 2. Executive Order #D0011 95 This policy supersedes Coordination of Approved Building Codes, Drawing Reviews and Building Inspections (Issued 5/1998) and Code Compliance Reviews (Issued 5/1998). Rev. 7/2013 2 OFFICE OF THE STATE ARCHITECT/STATE BUILDINGS PROGRAMS POLICIES AND PROCEDURES BUILDING CODE COMPLIANCE COORDINATION OF APPROVED BUILDING CODES, PLAN REVIEWS AND BUILDING INSPECTIONS INTRODUCTION A. Intent It is the intent of this policy to coordinate the efforts of state personnel responsible for managing construction projects, in order to ensure compliance with approved building codes and standards, by establishing standardized methods to review construction documents and inspect buildings under construction. This policy covers renovation as well as new construction. Routine maintenance is not covered under this policy. In addition, this policy intends to coordinate and track through documentation, e.g. the Compliance Notice, the Notice to Proceed, the Building Inspection Record (SBP-BIR), and the Notice of Approval of Occupancy/Use, the efforts of the various state entities responsible for specific portions of code compliance. Because code compliance is a multi-disciplined effort involving many individuals and departments, each state agency has a shared responsibility for ensuring that its construction projects comply with applicable codes. To a large extent, code compliance is quality control involving: structural stability, life safety, minimum standards and environmental health. Building code compliance plan review is required for all projects (capital construction, controlled maintenance, emergency, cash or in-house funded projects) unless an exception is provided per the building code. Building code compliance reporting is required only on appropriated projects - capital construction and controlled maintenance. This building code compliance policy and procedures are intended to assist the various state entities involved in the construction of state buildings in understanding the processes and requirements developed to assure that state buildings are constructed in accordance with the adopted codes. While the state has determined that it is in its interest to employ third part code review agents in an attempt to verify compliance with the code, this in no way relieves the architect/engineer or the contractor from their obligations to design and construct the project in conformance with the adopted codes nor is it intended to transfer any duties, obligations, or liabilities of the design and construction teams to the code review agents. The code review agents are agents of the Department of Personnel and Administration/Office of the State Architect (DPA/OSA) and conduct their work at the direction of the Office of the State Architect that is considered as the Building Official for state projects. The code review agents have powers only as delegated by OSA. While the code review agents are expected to conduct their work with due diligence, it is recognized that their work is limited to general review and inspection of the work and is not considered to constitute an in-depth or comprehensive analysis of the design or construction nor are they in any way authorized to direct the design or construction. Failure of the code review agent to identify a non-compliant condition, either in design or construction, does not waive the obligation of the design and construction teams to comply with the code. Plan reviews or inspections presuming to give authority to violate or cancel the provisions of the code or other ordinances shall not be valid. The policy is divided into five sections: Section I – Approved Building Codes; Section II – Code Compliance Plan Reviews; Section III – Building Inspections; Section IV – Coordination with Other State Agencies; and Section V - Compliance. Since all sections are interdependent, this policy attempts to define and establish an integrated process from the initial design drawing review phase through owner occupancy. The initial effective date of this policy was July 1, 1998. Rev. 7/2013 3 OFFICE OF THE STATE ARCHITECT/STATE BUILDINGS PROGRAMS POLICIES AND PROCEDURES BUILDING CODE COMPLIANCE COORDINATION OF APPROVED BUILDING CODES, PLAN REVIEWS AND BUILDING INSPECTIONS B. Statutory Responsibilities / Executive Order 1. STATUTORY RESPONSIBILITIES BY DEPARTMENT (Emphases in the following excerpts have been added). DRAWING REVIEW, BUILDING AND HVAC INSPECTION DEPARTMENT OF PERSONNEL & ADMINISTRATION/STATE BUILDINGS AND REAL ESTATE PROGRAMS (CRS 24-30-13) 24-30-1303(1)(j) Develop, or cause to be developed, standards of inspection, with the approval of the governor, which shall be the basis of all inspections and be responsible for assuring the uniform inspection of construction projects by the state agencies, utilizing such resources as may be locally available, in conjunction with the architect, engineer, or consultant; 24-30-1303(1)(n)(II) Develop, or cause to be developed, methods of control on a standardized basis for all state agencies to ensure conformity of physical planning with approved building codes and of construction with approved physical planning. 24-30-1303(z) Establish minimum building codes, with the approval of the governor and the general assembly after the recommendations and review of the capital development committee, for all construction by state agencies on state-owned or state lease-purchase properties or facilities. At the discretion of the department, said codes may apply to state leased facilities where local building codes may not exist. 24-30-1303(3)(a) All buildings and facilities, except public roads and highways and projects under the supervision of the division of wildlife and the division of parks and outdoor recreation erected for state purposes shall be constructed in conformity with a construction procedures manual for state facilities and state-assisted facilities prepared by the department and approved by the governor. Such construction shall be made only upon plans, design and construction documents which comply with approved state standards and rules and regulations promulgated pursuant to this section. ELECTRICAL INSPECTION DEPARTMENT OF REGULATORY AGENCIES / STATE ELECTRICAL BOARD (CRS 12-23) 12-23-116 (2) Any electrical installation in any new construction or remodeling or repair, other than manufactured units certified by the division of housing pursuant to section 24-32-3311, C.R.S., except in any incorporated town, or city, any county, or any city and county having its own electrical code and inspection equal to the minimum standards as are provided in this article, shall be inspected by a state electrical inspector. A state electrical inspector shall inspect any new construction, remodeling, or repair subject to the provisions of this subsection (2) within three working days after the receipt of the application for inspection. If the inspection is not performed within five working days, work may resume on any such Rev. 7/2013 4 OFFICE OF THE STATE ARCHITECT/STATE BUILDINGS PROGRAMS POLICIES AND PROCEDURES BUILDING CODE COMPLIANCE COORDINATION OF APPROVED BUILDING CODES, PLAN REVIEWS AND BUILDING INSPECTIONS construction, repair, or remodeling. Prior to the commencement of any such electrical installation, the person making such installation shall make application for inspection and pay the required fee therefor. PLUMBING INSPECTION DEPARTMENT OF REGULATORY AGENCIES / STATE EXAMINING BOARD OF PLUMBERS (CRS 12-58) 12-58-114.5 (1) Any plumbing or gas piping installation in any new construction or remodeling or repair, other than manufactured units inspected in accordance with the provisions of part 7 of article 32 of title 24, C.R.S., except in any incorporated town or city, any county, or any city and county having its own plumbing code equal to the minimum standards provided in this article, shall be inspected by a state plumbing inspector in those areas where a local jurisdiction has requested such inspections. A state plumbing inspector shall inspect any new construction, remodeling, or repair subject to the provisions of this subsection (1) within three working days after the receipt of the application for inspection. If the inspection is not performed within five working days, work may resume on any such construction, repair, or remodeling. Prior to the commencement of any such plumbing or gas piping installation, the person making such installation shall make application for inspection and pay the required fee therefor. BOILER INSPECTION DEPARTMENT OF LABOR AND EMPLOYMENT / BOILER INSPECTION SECTION (CRS 9-4) 9-4-106 Owner report boilers, wrongful use of boilers, inspection of new installations. (1) It is the duty of the owner or user of boilers, except those boilers exempt from the provisions of this Article under section 9-4-104, used or which are to be used in this state, to report to the section the location of newly installed or relocated boilers. (2) Before the installers of any boiler have boilers placed in service, they shall notify the section, which, within ten days or as soon thereafter as possible from the date of receiving such notification, shall send an inspector to examine said boilers to determine that the construction, material, bracing, fuel and fluid supply systems, control apparatus, combustion air and ventilating air, electric wiring, piping, and all other parts of such boilers are such as to assure the safety of the boilers. (3) Upon completion of installation, all boilers shall be inspected by a state boiler inspector. At the time of inspection, each boiler shall be assigned a serial number by the inspector, which serial number shall be stamped on or affixed to the boiler. ELEVATOR INSPECTION DEPARTMENT OF LABOR AND EMPLOYMENT / CONVEYANCE SECTION (CRS 9-5.5) 9-5.5-104 Applies to the design, construction, operation, inspection, testing, maintenance, alteration and repair of the following equipment: (a) Hoisting and lowering mechanisms equipped with a car or platform that moves between two or more landings. Such equipment includes, but is not limited to, elevators and platform lifts, personnel hoists, stairway chair lifts, and dumbwaiters. (b) Power-driven stairways and walkways for carrying persons between landings. Such equipment Rev. 7/2013 5 OFFICE OF THE STATE ARCHITECT/STATE BUILDINGS PROGRAMS POLICIES AND PROCEDURES BUILDING CODE COMPLIANCE COORDINATION OF APPROVED BUILDING CODES, PLAN REVIEWS AND BUILDING INSPECTIONS includes, but is not limited to, escalators and moving walks. (c) Automated people movers as defined in ASCE 21. Furthermore, the statute requires all conveyances in Colorado to be registered with the Conveyance Section / Division of Oil and Public Safety (OPS); requires all conveyance contractors, mechanics, and inspectors to be licensed by OPS; requires all conveyances to be installed, altered, repaired, serviced and maintained according to adopted standards, and allows local authorities having jurisdiction to regulate conveyances if approved by OPS. FIRE SUPPRESSION INSTALLATION AND INSPECTION DEPARTMENT OF PUBLIC SAFETY / DIVISION OF FIRE SAFETY (CRS 24-33.5-12) 24-33.5-1206.4 System approval, inspection, and inspectors. (1) No installation, modification, alteration, or repair of a fire suppression system shall be completed and cleared for use, and no structure or partial structure in which such fire suppression system is installed, modified, altered, or repaired shall be cleared for occupancy, until such fire suppression system has been approved by a certified fire suppression systems inspector. Approval shall include review of approved working plans and hydraulic calculations, installation inspections, and final tests. FOOD SERVICE LICENSE/PLAN REVIEW/INSPECTION DEPARTMENT OF PUBLIC HEALTH AND ENVIRONMENT/DIVISION OF CONSUMER PROTECTION (CRS 25-4-16) 25-4-1605 Submission of plans for approval – required. (1) An owner or operator shall submit plans and specifications to the department or local board of health in the jurisdiction in which a retail food establishment is to be constructed or extensively remodeled before such construction or extensive remodeling is begun or any existing structure is converted for use as a retail food establishment. Such plans and specifications shall be submitted for review and approval, in such form as the department requires, to ensure that the retail food establishment layout, equipment, and food handling procedures are conducive to providing to providing a safe food product…. Such plans and specifications shall indicate the proposed layout, arrangement, mechanical plants, construction materials of work areas, and the location, type, and model of proposed fixed equipment and facilities. (2) The construction, extensive remodeling, or conversion of any retail food establishment shall be in accordance with the plans and specifications submitted to and approved by the department or local board of health. The department or local board of health shall conduct preopening inspections of retail food establishments to assure compliance with the approved plans, as circumstances require. FACTORY-BUILT NONRESIDENTIAL STRUCTURES DEPARTMENT OF LOCAL AFFAIRS/DIVISION OF HOUSING (CRS 24-32-33) 24-32-3311 Certification of factory-built residential and nonresidential structures. (1) Factory-built structures manufactured, substantially altered or repaired, sold, or offered for sale within this state after the effective date of the rules promulgated pursuant to this part 33 shall bear the insignia of approval issued by the division and affixed by the division or an authorized quality assurance representative. Rev. 7/2013 6 OFFICE OF THE STATE ARCHITECT/STATE BUILDINGS PROGRAMS POLICIES AND PROCEDURES BUILDING CODE COMPLIANCE COORDINATION OF APPROVED BUILDING CODES, PLAN REVIEWS AND BUILDING INSPECTIONS (4) All factory-built structures bearing an insignia of approval issued by the division and affixed by the division or an authorized quality assurance representative pursuant to this part 33 shall be deemed to comply with the requirements of all ordinances or rules, including those for electrical and plumbing, enacted by the state government and any local government that are applicable to the manufacture of structures…. (5) No factory-built structures bearing an insignia of approval issued by the division and affixed by the division or an authorized quality assurance representative pursuant to this part 33 shall be in any way modified contrary to the rules promulgated pursuant to section 24-32-3305 prior to or during installation unless approval is first obtained from the division. ASBESTOS ABATEMENT/RENOVATION/DEMOLITION DEPARTMENT OF PUBLIC HEALTH AND ENVIRONMENT/AIR POLLUTION CONTROL DIVISION (CRS 25-7-503) 25-7-503 Notification is required for all demolitions of all facilities and for all asbestos abatement projects that exceed the trigger levels. The notification requirements apply to both friable and non-friable asbestos materials. Permits are required for the abatement of friable asbestos projects where the quantity of asbestos-containing material to be abated exceeds the trigger levels and the work is in an area of public access. 2. GOVERNOR’S EXECUTIVE ORDER # D0011 95 Improving the Alignment of State Plans with Regional Visions “Whereas, the Interregional Council of the Smart Growth and Development Initiative recommends that cooperation among all levels of government is integral in establishing responsible growth practices in the state of Colorado.” SECTION I. BUILDING CODES A. Approved Building Codes See Exhibit A – Approved Building Codes B. Requests To Change Application Of Certain Provisions Of The Code (Note: This section only applies to the International Building Code (IBC), the International Mechanical Code (IMC) and the International Energy Conservation Code (IECC). Contact the other state agencies listed in Section IV for other codes.) All approved changes must be filed with State Buildings Programs by the code review agent or approved agency building official as they are determined. In addition, agencies are required to submit documentation of the approved changes with the project code compliance final submittal. 1. Alternative Methods. The IBC has provided provisions to allow alternative methods and materials to the prescriptive requirements of the code. Alternative methods maintain the level of life safety created by the code’s prescriptive requirements but uses other methods than may be required by the prescriptive section of the code. Procedure for requesting approval of an alternative method is as follows: Rev. 7/2013 7 OFFICE OF THE STATE ARCHITECT/STATE BUILDINGS PROGRAMS POLICIES AND PROCEDURES BUILDING CODE COMPLIANCE COORDINATION OF APPROVED BUILDING CODES, PLAN REVIEWS AND BUILDING INSPECTIONS a) The Architect/Engineer shall submit a request for consideration of alternative method to the state code review agent or the approved agency building code official. This request shall identify the prescriptive requirements of the code that are to be addressed by the alternative method and provide documentation as to how equivalency with the prescriptive requirements will be achieved. b) The state code review agent or the approved agency building code official will review the request and may accept or reject the request. In consideration of the request, the code review agent may request additional documentation as required. c) The details of any action approving the use of any alternative method shall be recorded and entered in the files at State Buildings Programs. d) Consulting fees associated with alternatives will be paid by the Agency. 2. Modifications. When there are practical difficulties involved in carrying out the provisions of the code, State Buildings Programs or the approved agency building code official may grant modifications for individual cases. State Buildings Programs shall first find that a special individual reason makes the strict letter of the code impractical and that the modification is in conformance with the intent and purpose of the code and that such modification does not lessen any health, accessibility, life and fire safety or structural requirements. Procedures for requesting approval of a modification are as follows: a) The Agency is to provide in writing a request for modification to State Buildings Programs or approved agency building code official. Be as specific as possible, indicating the code section to be modified. Provide reasons for the modification and other substantiating documentation as required. b) State Buildings Programs or approved agency building code official will review the request. At its option State Buildings Programs may solicit the comments from its code review agents and other qualified entities. Submit information as specified on Exhibit M Request for Modification. c) State Buildings Programs or approved agency building code official shall first find that a special individual reason makes the strict letter of the code impractical and that the modification is in conformance with the intent and purpose of the code and that such modification does not lessen any health, accessibility, life and fire safety or structural requirements. d) The details of any action granting modifications shall be recorded and entered in the files of State Buildings Programs. e) Modifications may only be provided by State Buildings Programs or the approved agency building code official. f) Consulting fees associated with modifications will be paid by the Agency. 3. Appeals When the Agency has a disagreement as to the interpretation of code requirements, it may appeal the decision of the state code review agent or the approved agency building code official. It is noted that an appeal is not permitted to reduce or waive the requirements of the code. The procedure for appeals is as follows: a) Provide a request in writing for appeals to State Buildings Programs or the approved agency building code official. Be as specific as possible, indicating the code section in contention. Provide reasons for the appeal and other substantiating documentation as required. b) State Buildings Programs will review the request. At its option State Buildings Programs may solicit the comments from its code review agents. Fees associated with such solicited comments will be paid by State Buildings Programs. c) Accepted Appeals will be distributed to the agency and the state’s code review agents. Rev. 7/2013 8 OFFICE OF THE STATE ARCHITECT/STATE BUILDINGS PROGRAMS POLICIES AND PROCEDURES BUILDING CODE COMPLIANCE COORDINATION OF APPROVED BUILDING CODES, PLAN REVIEWS AND BUILDING INSPECTIONS d) Rejected Appeals will be distributed to the agency and the state’s code review agents. e) Establishment of Board of Appeals. State Buildings Programs will endeavor to establish a Board of Appeals. Once this board is established it will be responsible to review and act upon the request on behalf of State Buildings Programs. f) Appeals may only be provided by State Buildings and Programs or approved agency building code officials. 4. Amendments. Amendments are intended to modify, delete, or supplement specific provisions of the codes. Amendments are to be applicable to all projects and must be approved by State Buildings Programs. The procedure for requesting approval of an amendment is as follows: a) The agency is to provide in writing a request for amendment to State Buildings Programs. Be as specific as possible, indicating the code section to be modified, deleted, or supplemented. Provide reasons for the amendment and other substantiating documentation as required. b) State Buildings Programs will review the request. At its option State Buildings Programs may solicit the comments from its code review agents. Fees associated with such solicited comments will be paid by State Buildings Programs. c) Rejected amendments will be returned to the Agency. d) Amendments may only be established by State Buildings Programs. 5. Code Deficiencies in Existing Buildings a) Each project where repairs, alterations, renovations, upgrades or additions are proposed in an existing state owned building should include a code compliance plan commensurate with the scope of the project. The code review agent’s review will be as is needed to assess compliance within the project scope. All work is to comply with IBC 3401 and 3403 as a minimum requirement. Additionally, it is the policy of State Buildings Programs to bring existing structures into conformance with current codes as much as practical within the intended scope of the project. To this end the code review agent is directed to comment on conditions as discovered that are noted not in compliance with current code requirements. Such deficiencies that are noted should either be corrected in the drawings or acknowledged by the agency in a letter to the code review agent indicating why the items cannot be incorporated into the work. This is limited to work that is not required by the code under provisions of IBC 3403. b) Existing Non-Conforming Buildings A building that cannot be shown to comply with the building code edition adopted and current at the time of first construction (Uniform Building Code or International Building Code) or had a subsequent change in occupancy or use is considered to be an existing non-conforming building. It is incumbent upon the agency and/or Architect/Engineer to include code compliance in its due diligence study for the project scope definition and funding request and design in order to address existing non-conforming conditions as early in the process as possible to avoid future problems. Existing non-conforming conditions should be addressed in the code compliance plan. Rev. 7/2013 9 OFFICE OF THE STATE ARCHITECT/STATE BUILDINGS PROGRAMS POLICIES AND PROCEDURES BUILDING CODE COMPLIANCE COORDINATION OF APPROVED BUILDING CODES, PLAN REVIEWS AND BUILDING INSPECTIONS The code review agent is directed to comment on the existing non-conforming conditions as discovered whether or not the conditions are within the scope of the project. Discovery may occur either during plan review or inspections. At its option the code review agent may choose not to comment on conditions that it considers not to substantially affect the overall life safety of the facility. Conditions that are existing and non-conforming are to be corrected as part of any project involving the subject building. Conditions that cannot be corrected must be individually acknowledged in a letter to State Buildings Programs and the Office of Risk Management and signed by the agency Principal Representative indicating why the condition cannot be corrected or otherwise mitigated. State Buildings Programs will request an opinion from the code review agent regarding the nature of the nonconforming condition and will then consult with the Office of Risk Management concerning appropriate action. c) Renovations Where substantial work or renovation is proposed within a building or portion of a building, that building or portion is to be brought into full compliance with the current code to the maximum degree possible. All due diligence studies and project funding requests should take this into account. The code review agent is directed to comment on conditions that are noted not to comply with current code requirements as discovered, whether or not the conditions are within the scope of the project. Such deficiencies that are noted should be corrected in the work. If the deficiency cannot be corrected or otherwise mitigated, it must be acknowledged by the agency in a letter to the code review agent indicating why the items cannot be incorporated into the work. If the code review agent does not agree with the agency findings, it may request the matter be addressed to State Buildings Programs prior to issuance of a Compliance Notice. This is limited to work that is not required by the code under provisions of IBC 3403 or 3406. The code review agent may issue a Compliance Notice with a contingent reference to the agency Principal Representative with letters as discussed herein. d) Change of Use or Occupancy Existing buildings that are to undergo a Change of Use are required to comply with current code requirements per IBC 3406. Existing conditions that cannot be modified to meet current code requirements may be addressed to State Buildings Programs with a request for modification per SBP policy. Note: The term code review agent refers to either the approved SBP code consultants or the approved agency building code official. SECTION II. CODE COMPLIANCE PLAN REVIEWS A. Agency project managers for all construction projects requiring code review for state agencies on state-owned or state leased-purchased properties or facilities are to submit design documents for code compliance reviews to the state’s code review agents or State Buildings Programs approved agency building code official. The purpose of these reviews is to ensure conformity of physical planning with approved state building codes. Rev. 7/2013 10 OFFICE OF THE STATE ARCHITECT/STATE BUILDINGS PROGRAMS POLICIES AND PROCEDURES BUILDING CODE COMPLIANCE COORDINATION OF APPROVED BUILDING CODES, PLAN REVIEWS AND BUILDING INSPECTIONS All documents submitted for code compliance drawing reviews are to be prepared by licensed professional architects pursuant to Title 12, Article 4, C.R.S., or, if applicable, licensed professional engineers pursuant to Title 25, Article 4, C.R.S. 1. State Buildings Programs has selected and contracted with several consultants to provide code compliance reviews statewide. Each agency, however, directly procures the services of the code review agent through a Plan Review Authorization (SBP-017) form for each project. An estimated cost for the code review is to be initially included on the Construction Project Application (SC-4.1) by the agency. Note: The Department of Public Health and the Environment, Division of Consumer Protection will review drawings for food service related projects. Agencies are responsible for contacting local fire districts to seek their input at the beginning of the design process. 2. Instructions for working with the state’s approved code review agents are included in SBP’s document Plan Review Procedures (Exhibit B). 3. The Plan Review Procedures document is referenced in the Architect/Engineer Agreement (SC-5.1) and the Architect/Engineer Agreement Terms and Conditions (SC5.1T) and is thereby incorporated into the contracts for professional services as a guideline for minimum required information for code review submittals per drawing phase. B. All reviewed projects are to be provided with a Compliance Notice with a listing of required inspections by the state’s code review agent or the approved agency building code official prior to State Buildings Programs/Delegee issuance of the Notice to Proceed (SBP-6.26) or (SBP-7.26). If the Compliance Notice is contingent on the inclusion of the Construction Document code review submittal comments, the agency project manager must certify to State Buildings Programs on the Compliance Notice that is sent to SBP with the Notice to Proceed (SBP6.26 or SBP-7.26) that the code review agent’s comments were incorporated into the drawings and specifications. If there were exceptions to the code review agent’s comments that were resolved through an appeals process, that resolution must also be certified by the agency project manager. SECTION III. BUILDING INSPECTIONS All reviewed construction projects shall be inspected for building code compliance. This section describes the responsibilities for building inspections of State Buildings Programs. Section IV describes inspection responsibilities of other state departments. A. Building Inspection Record (SBP-BIR). At the completion of the code compliance plan review phase, the state’s code review agent or the approved agency building code official will issue along with the Compliance Notice a list of the required inspections. Prior to the start of construction, the agency project manager will conduct a coordination meeting with the code review agent who will serve as inspector of record for the project and others who may have building inspection responsibilities (if applicable) to identify the responsible parties for each required inspection and assign the responsibility for the final inspection sign off. The Architect/Engineer and the Contractor will also attend this meeting. If applicable, a representative from the local fire district will be invited to attend. Rev. 7/2013 11 OFFICE OF THE STATE ARCHITECT/STATE BUILDINGS PROGRAMS POLICIES AND PROCEDURES BUILDING CODE COMPLIANCE COORDINATION OF APPROVED BUILDING CODES, PLAN REVIEWS AND BUILDING INSPECTIONS 1. The agency’s project manager will transfer the required inspections onto the Building Inspection Record (SBP-BIR) yellow card that is to be provided to the Contractor at contract signing. 2. The Building Inspection Record (SBP-BIR) will indicate by checked box, the minimum required inspections and the appropriate inspectors for each project submitted for review. 3. The Building Inspection Record (SBP-BIR) is to be posted in an obvious, protected location, along with all related inspection reports and documents. 4. It is intended that all inspectors sign the Building Inspection Record (SBP-BIR) and enter their ICC Certification number (if applicable) after conducting each inspection. See Section III.B below for the required inspector qualifications. 5. At the completion of the project when the agency project manager and the code review agent as inspector of record for the project have determined that all required inspections have taken place, they both will sign the Building Inspection Record (SBP-BIR). The fully signed Building Inspection Record (SBP-BIR) along with all supporting documents will become part of the project close-out documentation and a copy of the Building Inspection Record (SBP-BIR) will be sent to State Buildings Programs. B. Building Inspection Authorization (SBP-018). State Buildings Programs has selected and contracted with several consultants to provide building inspections statewide. However, each agency must directly procure the services of the consultant through a Building Inspection Authorization (SBP-018) form for each project. An estimated cost for the building inspection is to be initially included on the Construction Project Application (SC-4.1). Note that agency staff may perform inspections only if they have appropriate ICC certifications. Qualifications include ICC Certified Commercial Building, Electrical, Mechanical, or Plumbing Inspector. A licensed architect or engineer in the state of Colorado with appropriate ICC certification and who is not the architect or engineer of record for the project may also perform the inspections. C. Inspection Report (SBP-019). 1. The Inspection Report (SBP-019) is to be used by the inspection consultant or ICC certified agency staff providing inspection services to thoroughly document what has been rejected and what has been approved in addition to the consultant or staff member inspector signing the Building Inspection Record (SBP-BIR) card. The inspections may include as per the Building Inspection Record (SBP-BIR): Building Inspections Special Inspections Elevator Inspections* Electrical Inspections* Plumbing Inspections* Fire Department Inspections Boiler Inspections* Health Department Inspections* Other Inspections * Note: The Plumbing and Electrical Boards, the Health Department, the Boiler Inspector, and Conveyance Administrator provide other means for the contractor to request their inspections. Refer to section IV. Rev. 7/2013 12 OFFICE OF THE STATE ARCHITECT/STATE BUILDINGS PROGRAMS POLICIES AND PROCEDURES BUILDING CODE COMPLIANCE COORDINATION OF APPROVED BUILDING CODES, PLAN REVIEWS AND BUILDING INSPECTIONS 2. It is the responsibility of the agency’s project manager to receive all Inspection Reports after the inspector has completed each required inspection and direct the Contractor to comply with all corrections noted. Additionally, the agency’s project manager is also required to coordinate efforts with the other state authorities conducting required inspections (refer to section IV) and sign the Building Inspection Record (SBP-BIR) to indicate that the inspection was conducted and completed, if the inspecting entity has not already done so. 3. Building Inspections are in addition to the observations performed by the Architect/Engineer as required by the A/E Agreement. These building inspections shall include: a) Inspections of footings / foundations, concrete slab and under-floor, lowest floor elevation, framing, lath and gypsum board, fire-resistant penetrations, mechanical and energy efficiency, roofing, and final inspections. b) Special inspections as required by applicable provisions of the code including steel, concrete, masonry, wood, soils/foundations, spray-applied fireproofing and smoke control systems. The Architect/Engineer shall identify the special inspections required. c) Plumbing and electrical inspections per the State Plumbing and Electrical Boards (refer to section IV). d) Fire protection system per the Division of Fire Safety and fire alarm by the local fire district (refer to section IV). e) Boiler inspections for new and modified installations (refer to section IV). f) Elevator/escalator inspections for new or altered installations (refer to section IV). g) Health Department inspections for all food service installations by the local health authority (refer to section IV). D. Building Occupancy / Documentation. Once the contractor has determined that the project is complete, the agency’s project manager verifies that all items on the close-out documents have been completed, and that the forms are fully signed-off prior to issuing the Notice of Final Acceptance (SC-6.27). The steps in the close-out process include: 1. Notice of Substantial Completion (SBP-07). Following the Contractor’s submittal of the Notice of Completion accompanied by the Contactor’s punch list, the Architect/Engineer, the Principal Representative and the Contractor will conduct a final inspection and the Architect/Engineer will issue a final punch list. The Notice of Substantial Completion will establish the date of substantial completion of the project (and the beginning of the warranty period) and will be issued when: all required building code inspections have been completed and all deficiencies noted on the Building Inspection Record (SBP-BIR) have been corrected; the building has been fully cleaned and can be used by the Principal Representative and the public; and the Contractor has provided a schedule for the completion of all items on the punch list. 2. Notice of Approval of Occupancy/Use (SBP-01). If the Principal Representative wishes to occupy the entire project or a portion of the project before completion following the issuance of the Notice of Substantial Completion, then a review of the conditions and progress are noted. This review is conducted by the Architect/Engineer, State Buildings Programs, and the Contractor and evaluates security, safety systems, exiting, power, lighting and HVAC systems. Rev. 7/2013 13 OFFICE OF THE STATE ARCHITECT/STATE BUILDINGS PROGRAMS POLICIES AND PROCEDURES BUILDING CODE COMPLIANCE COORDINATION OF APPROVED BUILDING CODES, PLAN REVIEWS AND BUILDING INSPECTIONS 3. Notice of Final Acceptance (SC-6.27). The Notice of Final Acceptance (SC-6.27) establishes the completion date of the project. It shall not be authorized until the Contractor performs the work to allow completion and approval of the Pre-Acceptance Checklist (SBP-05). Where Notices of Partial Substantial Completion (SBP-071) have been issued, Notices of Partial Final Acceptance (SBP-6.271) may be similarly issued when appropriate. SECTION IV. COORDINATION WITH OTHER STATE DEPARTMENTS G. Coordination with State Plumbing and Electrical Boards The Colorado General Assembly has created the Colorado State Electrical Board and the Colorado Examining Board of Plumbers of the Department of Regulatory Agencies with the power to adopt and enforce plumbing and electrical codes. State Buildings Programs supports the boards’ efforts in ensuring compliance with the adopted codes. 1. Codes. The State Boards regularly adopt plumbing and electrical codes as per Appendix A, Approved Building Codes. Compliance with these codes is mandatory on all construction projects. 2. Amendments. The State Boards have issued amendments as part if their adoption of these codes. Compliance with these amendments is required on all construction projects. 3. Variances. State Buildings Programs will not consider alternative methods, modifications, appeals, or amendments to the codes approved by the state boards. Requests for such should be addressed to the State Boards at (303) 894-2300 and copied in writing to State Buildings Programs. 4. Code Compliance Plan Reviews. The state boards do not conduct plan reviews. However, the state’s code review agents will conduct plan reviews for electrical and plumbing work for conformance with the state boards’ adopted codes. Please note that the boards enforce the editions of their codes that are in effect at the time of permitting not at the time of design or plan review. 5. Inspections. Plumbing and electrical inspections on state projects are to be provided by the state boards. Such inspections should be noted on the Building Inspection Record (SBP-BIR) card. It is the responsibility of the contractor to call for these inspections at (303) 894-2300. 6. The State Electrical Board and the Colorado Examining Board of Plumbers both issue inspection permits and charge a fee. At the completion of the final inspections, a certificate of approval will be issued. G. Coordination with Local Fire Jurisdictions and the Division of Fire Safety Most state facilities are included within the boundaries of an established fire district. It is the responsibility of those fire authorities to provide service to the state facilities. This policy is in compliance with Executive Order D0011 95 which requires that state facilities be planned and built in a manner consistent with local regulations. 1. Codes. Agencies are responsible that project design and construction is in compliance with the codes approved by the fire district where the project is to be built. In the event that there is no local district, or the district has not approved a recognized code, the current edition of the International Fire Code shall be utilized. Rev. 7/2013 14 OFFICE OF THE STATE ARCHITECT/STATE BUILDINGS PROGRAMS POLICIES AND PROCEDURES BUILDING CODE COMPLIANCE COORDINATION OF APPROVED BUILDING CODES, PLAN REVIEWS AND BUILDING INSPECTIONS 2. Review. It is mandatory that agencies consult local fire districts prior to the start of design. Plans and specifications for all construction projects with fire code related issues shall be submitted to the fire district for review. Fire protection systems must be reviewed by Department of Public Safety/Division of Fire Safety certified personnel. A fee is charged for plan registration, plan review, and inspection. Fire alarm systems shall be reviewed by the fire district or by the state’s code review agent. Unless otherwise approved by State Buildings Programs, the fire district review will be incorporated into the documents. In the event of a conflict, State Buildings Programs should be contacted. 3. Inspections. All construction projects must be made available to the fire district for inspections. Fire protection systems shall be inspected by Division of Fire Safety certified personnel. Fire alarm systems shall be inspected by the fire district or an approved inspector. Unless otherwise approved by State Buildings Programs any requirements resulting from these inspections shall be incorporated into the project. It is the responsibility of the agency’s project manager to coordinate this inspection with the local fire district. 4. Sovereignty. This policy is an effort to facilitate cooperation between the state and local authorities. This policy does not limit the sovereign authority of the state. C. Coordination with State Boiler Inspector The Colorado General Assembly has created the Boiler Inspection Section of the Division of Oil and Public Safety of the Department of Labor and Employment with the power to adopt and enforce the Colorado Boiler and Pressure Vessel Code. State Buildings Programs supports the Boiler Inspector’s efforts in ensuring compliance with the adopted codes. 1. Codes. The Boiler Inspection Section regularly adopts Boiler and Pressure Vessel Codes. Compliance with these codes is mandatory on all construction projects. 2. Amendments. The Boiler Inspection Section may issue amendments as part of its adoption of the code. Compliance with these amendments is mandatory on construction projects. 3. Variances. State Buildings Programs will not consider alternate methods, modifications, appeals, or amendments to the codes approved by the Boiler Inspection Section. Requests for such should be addressed to the Boiler Inspection Section at (303) 3188481 and copied in writing to State Buildings Programs. 4. Code Compliance Plan Reviews. The Boiler Inspection Section does not conduct plan reviews. However, the state’s code review agents will conduct plan reviews for boiler and pressure vessel work (both new and repair) in conformance with the Boiler Inspection Section’s adopted codes. 5. Inspections. Boiler and pressure vessel installation and/or repair inspections are to be provided by the Boiler Inspection Section. Such inspections should be noted on the Building Inspection Record (SBP-BIR) card. It is the responsibility of the Contractor to call for these inspections at (303) 318-8481. 6. The Boiler Inspection Section issues an inspection certificate when a boiler installation or repair has been found to comply with the Colorado Boiler and Pressure Vessel Code and a fee will be charged. D. Coordination with Administrator for Conveyances The Colorado General Assembly has created the Conveyance Section of the Division of Oil and Public Safety of the Department of Labor and Employment with the power to adopt and enforce a safety code for elevators, escalators, and automated people movers. State Buildings Programs supports the Division’s efforts in ensuring compliance with the adopted standards. Rev. 7/2013 15 OFFICE OF THE STATE ARCHITECT/STATE BUILDINGS PROGRAMS POLICIES AND PROCEDURES BUILDING CODE COMPLIANCE COORDINATION OF APPROVED BUILDING CODES, PLAN REVIEWS AND BUILDING INSPECTIONS 1. Codes. The Conveyance Section adopts standards for conveyances. Compliance with these standards is mandatory on all construction projects. 2. Amendments. The Conveyance Section may issue amendments to the adopted standards. Compliance with these amendments is mandatory on all construction projects. 3. Variances. State Buildings Programs will not consider alternative methods, modifications, appeals, or amendments to the standards approved by the Conveyance Section. Request for such should be addressed to the Conveyance Section at (303) 3188536 and copied in writing to State Buildings Programs. 4. Code Compliance Plan Reviews. The Conveyance Section does not conduct plan reviews. However, the state’s code review agents will conduct plan reviews for elevators and escalators (both new and altered) in conformance with the Conveyance Section’s adopted standards. All conveyances in Colorado shall be registered with the Conveyance Section/Division of Oil and Public Safety. 5. Inspections. Inspections are to be provided by inspectors licensed by the Conveyance Section/Division of Oil and Public Safety. Qualified local authorities having jurisdiction may enter into a memorandum of agreement with the Conveyance Section/Division of Oil and Public Safety to regulate conveyances that are located within their jurisdiction. 6. The Conveyance Section or authority having jurisdiction will issue a Certificate of Operation indicating that the conveyance has been inspected by a third party licensed conveyance inspector and complies with the rules of the Conveyance Section or approved authority having jurisdiction. E. Coordination with the Division of Consumer Protection of the Colorado Department of Public Health and Environment The Colorado General Assembly has created the Division of Consumer Protection within the Department of Public Health and Environment to adopt and enforce a uniform code of sanitary rules and regulations for food service establishment construction or renovation. State Buildings Programs supports the Division’s efforts in ensuring compliance with the adopted code. 1. Codes. The Division regularly adopts sanitary rules and regulations. Compliance with these rules and regulations is mandatory on all construction projects. 2. Amendments. The Division may issue amendments as part of the uniform code of sanitary rules and regulations. Compliance with these amendments is mandatory on all construction projects. 3. Variances. State Buildings Programs will not consider alternate methods, modifications, appeals or amendments to the code approved by the Division. Requests for such should be addressed to the Division of Consumer Protection at (303) 692-3620. 4. Code Compliance Plan Reviews. The Division does provide for mandatory drawing reviews. At the time a plan is submitted for review, an application fee of $75 dollars shall be paid to the department or local board of health. 5. Inspections. The Division conducts a pre-opening inspection of a new or extensively remodeled food service establishment. The fee for plan review and peopening inspection shall be the actual cost of such review, which shall not exceed $280. It is the responsibility of the agency’s project manager to coordinate this inspection with the local health department. 6. A license to operate will be granted by the Division following compliance. F. Coordination with the Division of Housing of the Colorado Department of Local Affairs Rev. 7/2013 16 OFFICE OF THE STATE ARCHITECT/STATE BUILDINGS PROGRAMS POLICIES AND PROCEDURES BUILDING CODE COMPLIANCE COORDINATION OF APPROVED BUILDING CODES, PLAN REVIEWS AND BUILDING INSPECTIONS The Colorado General Assembly has created the Division of Housing within the Department of Local Affairs to establish rules and regulations concerning factory-built nonresidential structures. State Buildings Programs supports the Division’s efforts in ensuring compliance with the adopted code. 1. Codes. The Division of Housing has adopted the 2012 edition of the International Building Code. Contact the Division for applicable appendices and other required codes and standards. Refer to Resolution #35. 2. Amendments. The Division of Housing may issue amendments as part of its adoption of the code. Compliance with the adopted code and amendments is required. 3. Variances. State Buildings Programs will not consider alternate methods, modifications, appeals, or amendments on factory-built nonresidential structures. Requests for such should be addressed to the Division of Housing at (303) 866-2033 and copied in writing to State Buildings Programs. 4. Code Compliance Plan Reviews. The Division of Housing provides for plan reviews of factory-built nonresidential structures for special occupancies, e.g. structures to be used as day care centers rather than structures to be used as portable offices. The state’s code review agents will provide plan reviews for code compliance for site adaptation and installation issues. 5. Inspections. Inspections at the factory for factory-built nonresidential structures will be conducted by the Division of Housing certified personnel. Factory-built nonresidential structures approved by the Division of Housing will bear an official insignia. The state’s code review agent will indicate the site related inspections that are required. G. Coordination with the Air Pollution Control Division of the Colorado Department of Public Health and Environment The Colorado General Assembly has created the Air Pollution Control Division within the Department of Public Health and Environment to adopt and enforce regulations for asbestos abatement. State Buildings Programs supports the Division’s efforts in ensuring compliance with the adopted regulations. 1. Codes. The Air Pollution Control Division enforces Regulation No. 8 Part B Asbestos adopted by the Air Quality Control Commission. Contact the Air Pollution Control Division for all state and federal regulations requiring inspections for asbestos. 2. Amendments. The Division may issue amendments to Regulation No 8. Compliance with current regulations is mandatory. 3. Variances. State Buildings Programs is not involved in approving variances. Requests for approval of alternative procedures should be addressed to the Permit Coordinator at the Air Pollution Control Division at (303) 692-3100. 4. All Renovation Projects. The structures/components to be disturbed must be inspected for asbestos by a state certified asbestos inspector. If the amount of asbestos-containing material to be disturbed exceeds the following trigger levels then an abatement contractor must remove the material. In single family residences, the trigger levels are 50 linear feet on pipes, 32 square feet on other surfaces, or the volume equivalent of a 55 gallon drum. In other than single family residences, the trigger levels are 260 linear feet on pipes, 160 square feet on other surfaces, or the volume equivalent of a 55 gallon drum. A certified removal contractor must remove asbestos containing materials that are regulated or may become regulated before they are disturbed by renovation or demolition Rev. 7/2013 17 OFFICE OF THE STATE ARCHITECT/STATE BUILDINGS PROGRAMS POLICIES AND PROCEDURES BUILDING CODE COMPLIANCE COORDINATION OF APPROVED BUILDING CODES, PLAN REVIEWS AND BUILDING INSPECTIONS activities. A written notification to DPHE, payment of a notification fee and a ten (10) working day waiting period is required before the removal of regulated asbestos containing materials. 5. Demolitions, Destructive Salvage, House Moving. The building must be inspected for asbestos by a state certified asbestos inspector. Asbestos removal (if necessary) must be performed by a certified removal contractor. A Notification of Demolition form must be submitted to DPHE even if no asbestos was found during inspection; payment of a notification fee and a ten (10) working day waiting period are required before the demolition can proceed. SECTION V. COMPLIANCE A. Agency Action Plan for Building Code Compliance Each agency and institution of the state is required to complete the enclosed form annually to describe their action plan for code compliance in accordance with this policy. The completed Agency Action Plan for Building Code Compliance (see Appendix K) is to be returned to SBP by January 1 of each year for review and approval. A memorandum of understanding with the local fire district is to be provided every five years. B. Building Code Compliance Documentation Submittal Agencies are required to submit the following documents to State Buildings Programs when a project is complete and closed out. Non-delegated and delegated agencies should send (1) the Notice to Proceed (SBP-6.26) or (SBP-7.26) and (2) copies of the Compliance Notice (including building inspection recommendations) issued by the code review agent with certification, if required, and documentation concerning alternative methods, modifications, and appeals, if applicable, or a memo from the agency with email from code review agent stating why code review was not required;(3) Building Inspection Record (SBP-BIR); (4) Notice of Approval of Occupancy/Use (SBP-01). The documents should be submitted along with the Code Compliance Documentation Submittal memo (Exhibit L). Rev. 7/2013 18 Exhibit A APPROVED STATE BUILDING CODES The following approved building codes and standards have been adopted by State Buildings Programs (SBP) and other state agencies as identified below as the minimum requirements to be applied to all state-owned buildings and physical facilities including capital construction and controlled maintenance construction projects. The 2012 edition of the International Building Code (IBC) (as adopted by the Colorado State Buildings Program as follows: Chapter 1 as amended, Chapters 2-35 and Appendices C and I) The 2012 edition of the International Mechanical Code (IMC) (as adopted by the Colorado State Buildings Program as follows: Chapters 2-15 and Appendix A) The 2012 edition of the International Energy Conservation Code (IECC) (as adopted by the Colorado State Buildings Program) The 2011 edition of the National Electrical Code (NEC) (National Fire Protection Association Standard 70) (as adopted by the Colorado State Electrical Board) The 2009 edition of the International Plumbing Code (IPC) (as adopted by the Colorado Examining Board of Plumbers as follows: Chapter 1 Section 101.2,102, 105, 107, Chapters 2-13 and Appendices B, D, E, F and G) The 2009 edition of the International Fuel Gas Code (IFGC) (as adopted by the Colorado Examining Board of Plumbers as follows: Chapter 1 Section 101,102, 105, 107, Chapters 2-8 and Appendices A, B, and C) The National Fire Protection Association Standards (NFPA) (as adopted by the Department of Public Safety/Division of Fire Safety as follows with editions shown in parentheses: NFPA-1 (2006), 11 (2005), 12 (2005), 12A (2004), 13 (2002), 13D (2002), 13R (2002), 14 (2003), 15 (2001), 16 (2003), 17 (2002), 17A (2002), 20 (2003), 22 (2003), 24 (2002), 25 (2002), 72 (2002), 409 (2004), 423 (2004), 750 (2003) and 2001 (2004)) The 2010 edition of the ASME Boiler and Pressure Vessel Code (as adopted by the Department of Labor and Employment/Boiler Inspection Section as follows: sections I, IV, V, VIII-Divisions 1 and 2 and 3, 1X, X including the 2011 addenda and B31.1, 2010 edition.) The 2011 edition of the National Boiler Inspection Code (NBIC) (as adopted by the Department of Labor and Employment/Boiler Inspection Section) The 2012 edition of the Controls and Safety Devices for Automatically Fired Boilers CSD-1 (as adopted by the Department of Labor and Employment/Boiler Inspection Section) The 2011 edition of the Boiler and Combustion Systems Hazards Code, NFPA 85 (as adopted by the Department of Labor and Employment/Boiler Inspection Section) The 2007 edition of ASME A17.1 Safety Code for Elevators and Escalators (as adopted by the Department of Labor and Employment/Conveyance Section and as amended by ASME International) The 2005 edition of ASME A17.3 Safety Code for Existing Elevators and Escalators (as adopted by the Department of Labor and Employment/Conveyance Section and as amended by ASME International) Rev. 7/2013 1 Exhibit A The 2005 edition of ASME A18.1 Safety Standard for Platform Lifts and Stairway Chairlifts (as adopted by the Department of Labor and Employment/Conveyance Section and as amended by ASME International) The current edition of the Rules and Regulations Governing the Sanitation of Food Service Establishments (as adopted by the Department of Public Health and Environment/Colorado State Board of Health) The 2003 edition of ICC/ANSI A117.1, Accessible and Usable Buildings and Facilities (as adopted by the Colorado General Assembly as follows: CRS 9-5-101, as amended, for accessible housing) Note: Additional codes, standards and appendices may be adopted by the state agencies and institutions in addition to the minimum codes and standards herein adopted by State Buildings Programs. 1. The 2012 edition of the IBC became effective on July 1 of 2013. Consult the state electrical and plumbing boards and the state boiler inspector and conveyance administrator and the Division of Fire Safety for adoption of current editions and amendments to their codes. 2. Projects should be designed and plans and specifications should be reviewed based upon the approved codes at the time of A/E contract execution. If an agency prefers to design to a different code such as a newer edition of a code that State Buildings Programs has not yet adopted, the agency must contact SBP for approval and then amend the A/E contract with a revised Exhibit C, Approved State Building Codes. Please note that the state plumbing and electrical boards enforce the editions of their codes that are in effect at the time of permitting not design. 3. The state’s code review agents, or the State Buildings Programs approved agency building official, shall review all documents for compliance with the codes stipulated herein. Note: The Department of Public Health and Environment, Division of Consumer Protection will review drawings for food service related projects. 4. This policy does not prohibit the application of various life safety codes as established by each agency for specific building types and funding requirements. NFPA 101 and other standards notwithstanding, approved codes will supersede where their minimum requirements are the most restrictive in specific situations. If a conflict arises, contact State Buildings Programs for resolution. 5. It is anticipated that compliance with the federal Americans with Disabilities Act Accessibility Guidelines for Buildings and Facilities (ADAAG) and Colorado Revised Statutes Section 9-5-101 will be met by compliance with the 2012 International Building Code and ICC/ANSI A117.1. However, each project may have unique aspects that may require individual attention to these legislated mandates. 6. The 2012 edition of the International Building Code (IBC) is to be applied to factory-built nonresidential structures as established by the Division of Housing within the Department of Local Affairs. A. Appendices Appendices are provided to supplement the basic provisions of the codes. Approved IBC Appendices are as follows: 1. Mandatory IBC Appendix Chapter C - Agricultural Buildings IBC Appendix Chapter I - Patio Covers Rev. 7/2013 2 Exhibit A 2. Optional Any non-mandatory appendix published in the International Building Code may be utilized at the discretion of the agency. Use of an appendix shall be indicated in the project code approach. B. Amendments 1. International Building Code, Chapter 1 as amended CHAPTER 1 SCOPE AND ADMINISTRATION PART 1—SCOPE AND APPLICATION SECTION 101 GENERAL 101.1 Title. These regulations shall be known as the Building Code of the Department of Personnel & Administration/Office of the State Architect (DPA/OSA), hereinafter referred to as “this code”. 101.2 Scope. The provisions of this code shall apply to the construction, alteration, movement, enlargement, replacement, repair, equipment, use and occupancy, location, maintenance, removal and demolition of every building or structure or any appurtenances connected or attached to such buildings or structures. Exception: Detached one- and two-family dwellings and multiple single-family dwellings (townhouses) not more than three stories above grade plane in height with a separate means of egress and their accessory structures shall comply with the International Residential Code. 101.2.1 Appendices. Provisions in the appendices shall not apply unless specifically adopted. 101.3 Intent. The purpose of this code is to establish the minimum requirements to safeguard the public health, safety and general welfare through structural strength, means of egress facilities, stability, sanitation, adequate light and ventilation, energy conservation, and safety to life and property from fire and other hazards attributed to the built environment and to provide safety to fire fighters and emergency responders during emergency operations. 101.4 Referenced codes. The other codes listed in Sections 101.4.1 through 101.4.6 and referenced elsewhere in this code shall be considered part of the requirements of this code to the prescribed extent of each such reference. Rev. 7/2013 3 101.4.1 Gas. The provisions of the International Fuel Gas Code shall apply to the installation of gas piping from the point of delivery, gas appliances and related accessories as covered in this code. These requirements apply to gas piping systems extending from the point of delivery to the inlet connections of appliances and the installation and operation of residential and commercial gas appliances and related accessories. 101.4.2 Mechanical. The provisions of the International Mechanical Code shall apply to the installation, alterations, repairs and replacement of mechanical systems, including equipment, appliances, fixtures, fittings and/or appurtenances, including ventilating, heating, cooling, airconditioning and refrigeration systems, incinerators and other energy-related systems. 101.4.3 Plumbing. The provisions of the International Plumbing Code shall apply to the installation, alteration, repair and replacement of plumbing systems, including equipment, appliances, fixtures, fittings and appurtenances, and where connected to a water or sewage system and all aspects of a medical gas system. 101.4.6 Energy. The provisions of the International Energy Conservation Code shall apply to all matters governing the design and construction of buildings for energy efficiency. SECTION 102 APPLICABILITY 102.1 General. Where there is a conflict between a general requirement and a specific requirement, the specific requirement shall be applicable. Where, in any specific case, different sections of this code specify different materials, methods of construction or other requirements, the most restrictive shall govern. 102.2 Other laws. The provisions of this code shall not be deemed to nullify any provisions of local, state or federal law. 102.3 Application of references. References to chapter or section numbers, or to provisions not specifically identified by number, shall be construed to refer to such chapter, section or provision of this code. 102.4 Referenced codes and standards. The codes and standards referenced in this code shall be considered part of the requirements of this code to the prescribed extent of each such reference and as further regulated in Sections 102.4.1 and 102.4.2. 102.4.1 Conflicts. Where conflicts occur between provisions of this code and referenced codes and standards, the provisions of this code shall apply. 102.4.2. Provisions in referenced codes and standards. Where the extent of the reference to the referenced code or standard includes subject matter that is within the scope of this code or the International Codes listed in Section 101.4, the provisions of this code or the International Codes listed in Section 101.4, as applicable, shall take precedence over the provisions in the referenced code or standard. 102.5 Partial invalidity. In the event that any part or provision of this code is held to be illegal or void, this shall not have the effect of making void or illegal any of the other parts or provisions. 102.6 Existing structures. The legal occupancy of any structure existing on the date of adoption of this code shall be permitted to continue without change, except as is specifically covered in this code or as is deemed necessary by DPA/OSA through its code review agent for the general safety and welfare of the occupants and the public. PART 2—ADMINISTRATION AND ENFORCEMENT SECTION 104 DUTIES AND POWERS OF BUILDING OFFICIAL 104.1 General. DPA/OSA as the building official is hereby authorized and directed to enforce the provisions of this code. DPA/OSA shall have the authority to render interpretations of this code and to adopt policies and procedures in order to clarify the application of its provisions. Such interpretations, policies and procedures shall be in compliance with the intent and purpose of this code. Such policies and procedures shall not have the Rev. 7/2013 4 effect of waiving requirements specifically provided for in this code. 104.2 Plan reviews. DPA/OSA through its code review agent shall review construction documents and issue compliance notices for the erection, and alteration, demolition and moving of buildings and structures and inspect the premises for which such compliance notices have been issued. 104.4 Inspections. DPA/OSA through its code review agent shall make all of the required inspections, or DPA/OSA shall have the authority to accept reports of inspection by approved agencies or individuals. Reports of such inspections shall be in writing and be certified by a responsible officer of such approved agency or by the responsible individual. DPA/OSA is authorized to engage such expert opinion as deemed necessary to report upon unusual technical issues that arise. 104.9 Approved materials and equipment. Materials, equipment and devices approved by DPA/OSA through its code review agent shall be constructed and installed in accordance with such approval. 104.9.1 Used materials and equipment. The use of used materials which meet the requirements of this code for new materials is permitted. Used equipment and devices shall not be reused unless approved by DPA/OSA through its code review agent. 104.10 Modifications. Wherever there are practical difficulties involved in carrying out the provisions of this code, DPA/OSA shall have the authority to grant modifications for individual cases, upon application of the owner or owner’s representative, provided DPA/OSA shall first find that special individual reason makes the strict letter of this code impractical and the modification is in compliance with the intent and purpose of this code and that such modification does not lessen health, accessibility, life and fire safety, or structural requirements. The details of action granting modifications shall be recorded and entered in the files of DPA/OSA. 104.10.1 Flood hazard areas. DPA/OSA shall not grant modifications to any provision required in flood hazard areas as established by Section 1612.3 unless a determination has been made that: 1. A showing of good and sufficient cause that the unique characteristics of the size, configuration or topography of the site render the elevation standards of Section 1612 inappropriate. 2. A determination that failure to grant the variance would result in exceptional hardship by rendering the lot undevelopable. 3. A determination that the granting of a variance will not result in increased flood heights, additional threats to public safety, extraordinary public expense, cause fraud on or victimization of the public, or conflict with existing laws or ordinances. 4. A determination that the variance is the minimum necessary to afford relief, considering the flood hazard. 5. Submission to the applicant of written notice specifying the difference between the design flood elevation and the elevation to which the building is to be built, stating that the cost of flood insurance will be commensurate with the increased risk resulting from the reduced floor elevation, and stating that construction below the design flood elevation increases risks to life and property. 104.11 Alternative materials, design and methods of construction and equipment. The provisions of this code are not intended to prevent the installation of any material or to prohibit any design or method of construction not specifically prescribed by this code, provided that any such alternative has been approved. An alternative material, design or method of construction shall be approved where DPA/OSA through its code review agent finds that the proposed design is satisfactory and complies with the intent of the provisions of this code, and that the material, method or work offered is, for the purpose intended, at least the equivalent of that prescribed in this code in quality, strength, effectiveness, fire resistance, durability and safety. 104.11.1 Research reports. Supporting data, where necessary to assist in the approval of materials or assemblies not specifically provided for in this code, shall consist of valid research reports from approved sources. 104.11.2 Tests. Whenever there is insufficient evidence of compliance with the provisions of this code, or evidence that a material or method does not conform to the requirements of this code, or in order to substantiate claims for alternative materials or methods, DPA/OSA through its code review agent shall have the authority to require tests as evidence of compliance to be made at no expense to the jurisdiction. Test methods shall be as specified in this code or by other recognized test standards. In the absence of recognized and accepted test methods, DPA/OSA through its code review agent shall approve the testing procedures. Tests shall be performed by an approved agency. Rev. 7/2013 5 SECTION 105 PLAN REVIEWS 105.1 Required. Any owner or authorized agent who intends to construct, enlarge, alter, repair, move, demolish, or change the occupancy of a building or structure, or to erect, install, enlarge, alter, repair, remove, convert or replace any electrical, gas, mechanical or plumbing system, the installation of which is regulated by this code, or to cause any such work to be done, shall first contact a DPA/OSA code review agent. 105.2 Work exempt from plan review. Exemptions from plan review requirements of this code shall not be deemed to grant authorization for any work to be done in any manner in violation of the provisions of this code or any other laws or ordinances of this jurisdiction. Plan review shall not be required for the following: Building: 1. One-story detached accessory structures used as tool and storage sheds, playhouses and similar uses, provided the floor area does not exceed 120 square feet (11 m2). 2. Fences not over 6 feet (1829 mm) high. 3. Oil derricks. 4. Retaining walls that are not over 4 feet (1219 mm) in height measured from the bottom of the footing to the top of the wall, unless supporting a surcharge or impounding Class I, II or IIIA liquids. 5. Water tanks supported directly on grade if the capacity does not exceed 5,000 gallons (18 925 L) and the ratio of height to diameter or width does not exceed 2:1. 6. Sidewalks and driveways not more than 30 inches (762 mm) above adjacent grade, and not over any basement or story below and are not part of an accessible route. 7. Painting, papering, tiling, carpeting, cabinets, counter tops and similar finish work. 8. Temporary motion picture, television and theater stage sets and scenery. 9. Prefabricated swimming pools accessory to a Group R-3 occupancy that are less than 24 inches (610 mm) deep, do not exceed 5,000 gallons (18 925 L) and are installed entirely above ground. 10. Shade cloth structures constructed for nursery or agricultural purposes, not including service systems. 11. Swings and other playground equipment accessory to detached one- and two-family dwellings. 12. Window awnings supported by an exterior wall that do not project more than 54 inches (1372 mm) from the exterior wall and do not require additional support of Groups R-3 and U occupancies. 13. Nonfixed and movable fixtures, cases, racks, counters and partitions not over 5 feet 9 inches (1753 mm) in height. Electrical: Repairs and maintenance: Minor repair work, including the replacement of lamps or the connection of approved portable electrical equipment to approved permanently installed receptacles. Radio and television transmitting stations: The provisions of this code shall not apply to electrical equipment used for radio and television transmissions, but do apply to equipment and wiring for a power supply and the installations of towers and antennas. Temporary testing systems: A plan review shall not be required for the installation of any temporary system required for the testing or servicing of electrical equipment or apparatus. Gas: 1. Portable heating appliance. 2. Replacement of any minor part that does not alter approval of equipment or make such equipment unsafe. Mechanical: 1. 2. 3. 4. Portable heating appliance. Portable ventilation equipment. Portable cooling unit. Steam, hot or chilled water piping within any heating or cooling equipment regulated by this code. 5. Replacement of any part that does not alter its approval or make it unsafe. 6. Portable evaporative cooler. 7. Self-contained refrigeration system containing 10 pounds (5 kg) or less of refrigerant and actuated by motors of 1 horsepower (746 W) or less. Plumbing: Rev. 7/2013 6 1. The stopping of leaks in drains, water, soil, waste or vent pipe, provided, however, that if any concealed trap, drain pipe, water, soil, waste or vent pipe becomes defective and it becomes necessary to remove and replace the same with new material, such work shall be considered as new work and a plan review shall be obtained and inspection made as provided in this code. 2. The clearing of stoppages or the repairing of leaks in pipes, valves or fixtures and the removal and reinstallation of water closets, provided such repairs do not involve or require the replacement or rearrangement of valves, pipes or fixtures. 105.2.1 Emergency repairs. Where equipment replacements and repairs must be performed in an emergency situation, plan review information shall be submitted promptly to DPA/OSA through its code review agent. 105.2.2 Repairs. Application or notice to DPA/OSA through its code review agent is not required for ordinary repairs to structures, replacement of lamps or the connection of approved portable electrical equipment to approved permanently installed receptacles. Such repairs shall not include the cutting away of any wall, partition or portion thereof, the removal or cutting of any structural beam or load-bearing support, or the removal or change of any required means of egress, or rearrangement of parts of a structure affecting the egress requirements; nor shall ordinary repairs include addition to, alteration of, replacement or relocation of any standpipe, water supply, sewer, drainage, drain leader, gas, soil, waste, vent or similar piping, electric wiring or mechanical or other work affecting public health or general safety. 105.2.3 Public service agencies. A plan review shall not be required for the installation, alteration or repair of generation, transmission, distribution or metering or other related equipment that is under the ownership and control of public service agencies by established right. 105.4 Validity of compliance notice. The issuance or granting of a compliance notice shall not be construed to be an approval of any violation of any of the provisions of this code or of any other ordinance of the jurisdiction. The issuance of a compliance notice based on construction documents and other data shall not prevent DPA/OSA through its code review agent from requiring the correction of errors in the construction documents and other data. 105.7 Placement of building inspection record. The building inspection record based on the compliance notice inspection recommendations shall be kept on the site of the work until the completion of the project. SECTION 106 FLOOR AND ROOF DESIGN LOADS 106.1 Live loads posted. Where the live loads for which each floor or portion thereof of a commercial or industrial building is or has been designed to exceed 50 psf (2.40 kN/m2), such design live loads shall be conspicuously posted by the owner in that part of each story in which they apply, using durable signs. It shall be unlawful to remove or deface such notices 106.2 Issuance of notice of approval of occupancy/use. A notice of approval of occupancy/use required by Section 111 shall not be issued until the floor load signs, required by Section 106.1, have been installed. 106.3 Restrictions on loading. It shall be unlawful to place, or cause or permit to be placed, on any floor or roof of a building, structure or portion thereof, a load greater than is permitted by this code. SECTION 107 SUBMITTAL DOCUMENTS 107.1 General. Submittal documents consisting of construction documents, statement of special inspections, geotechnical report and other data shall be submitted. The construction documents shall be prepared by a registered design professional where required by the statutes of the state of Colorado. Where special conditions exist, DPA/OSA through its code review agent is authorized to require additional construction documents to be prepared by a registered design professional. Exception: DPA/OSA is authorized to waive the submission of construction documents and other data not required to be prepared by a registered design professional if it is found that the nature of the work applied for is such that review of construction documents is not necessary to obtain compliance with this code. 107.2 Construction documents. Construction documents shall be in accordance with Sections 107.2.1 through 107.2.5. Rev. 7/2013 7 107.2.1 Information on construction documents. Construction documents shall be dimensioned and drawn upon suitable material. Construction documents shall be of sufficient clarity to indicate the location, nature and extent of the work proposed and show in detail that it will conform to the provisions of this code and relevant laws, ordinances, rules and regulations. 107.2.2 Fire protection system shop drawings. Shop drawings for the fire protection system(s) shall be submitted to indicate conformance to this code and the construction documents and shall be approved prior to the start of system installation. Shop drawings shall contain all information as required by the referenced installation standards in Chapter 9. 107.2.3 Means of egress. The construction documents shall show in sufficient detail the location, construction, size and character of all portions of the means of egress including the path of the exit discharge to the public way in compliance with the provisions of this code. In other than occupancies in Groups R-2, R-3, and I-1, the construction documents shall designate the number of occupants to be accommodated on every floor, and in all rooms and spaces. 107.2.4 Exterior wall envelope. Construction documents for all buildings shall describe the exterior wall envelope in sufficient detail to determine compliance with this code. The construction documents shall provide details of the exterior wall envelope as required, including flashing, intersections with dissimilar materials, corners, end details, control joints, intersections at roof, eaves or parapets, means of drainage, waterresistive membrane and details around openings. The construction documents shall include manufacturer’s installation instructions that provide supporting documentation that the proposed penetration and opening details described in the construction documents maintain the weather resistance of the exterior wall envelope. The supporting documentation shall fully describe the exterior wall system which was tested, where applicable, as well as the test procedure used. 107.2.5 Site plan. The construction documents submitted with the application for permit shall be accompanied by a site plan showing to scale the size and location of new construction and existing structures on the site, distances from lot lines, the established street grades and the proposed finished grades and, as applicable, flood hazard areas, floodways, and design flood elevations; and it shall be drawn in accordance with an accurate boundary line survey. In the case of demolition, the site plan shall show construction to be demolished and the location and size of existing structures and construction that are to remain on the site or plot. DPA/OSA through its code review agent is authorized to waive or modify the requirement for a site plan when the application for plan review is for alteration or repair or when other wise warranted. 107.2.5.1 Design flood elevations. Where design flood elevations are not specified, they shall be established in accordance with Section 1612.3.1. 107.3 Examination of documents. DPA/OSA through its code review agent shall examine or cause to be examined the accompanying submittal documents and shall ascertain by such examinations whether the construction indicated and described is in accordance with the requirements of this code and other pertinent laws or ordinances. 107.3.3 Phased approval. DPA/OSA through its code review agent is authorized to issue a compliance notice for the construction of foundations or any other part of a building or structure before the construction documents for the whole building or structure have been submitted, provided that adequate information and detailed statements have been filed complying with pertinent requirements of this code. The holder of such compliance notice for the foundation or other parts of a building or structure shall proceed at the holder’s own risk with the building operation and without assurance that a compliance notice for the entire structure will be granted. 107.3.4 Design charge. professional in responsible 107.3.4.1 General. The registered design professional in responsible charge shall be responsible for reviewing and coordinating submittal documents prepared by others, including phased and deferred submittal items, for compatibility with the design of the building. 107.3.4.2 Deferred submittals. For the purposes of this section, deferred submittals are defined as those portions of the design that are not submitted at the time of the plan review and Rev. 7/2013 8 that are to be submitted to DPA/OSA through its code review agent within a specified period. Deferral of any submittal items shall have the prior approval of DPA/OSA through its code review agent. The registered design professional in responsible charge shall list the deferred submittals on the construction documents for review by DPA/OSA through its code review agent. Documents for deferred submittal items shall be submitted to the registered design professional in responsible charge who shall review them and forward them to DPA/OSA through its code review agent with a notation indicating that the deferred submittal documents have been reviewed and found to be in general conformance to the design of the building. The deferred submittal items shall not be installed until the deferred submittal documents have been approved by DPA/OSA through its code review agent. 107.4 Amended construction documents. Work shall be installed in accordance with the approved construction documents, and any changes made during construction that are not in compliance with the approved construction documents shall be resubmitted for approval as an amended set of construction documents. SECTION 108 TEMPORARY STRUCTURES AND USES 108.1 General. DPA/OSA through its code review agent is authorized to issue a compliance notice for temporary structures and temporary uses. Such compliance notice shall be limited as to time of service, but shall not be permitted for more than 180 days. DPA/OSA through its code review agent is authorized to grant extensions for demonstrated cause. 108.2 Conformance. Temporary structures and uses shall conform to the structural strength, fire safety, means of egress, accessibility, light, ventilation and sanitary requirements of this code as necessary to ensure public health, safety and general welfare. 108.3 Temporary power. DPA/OSA through its code review agent is authorized to give permission to temporarily supply and use power in part of an electric installation before such installation has been fully completed and the final certificate of completion has been issued. The part covered by the temporary certificate shall comply with the requirements specified for temporary lighting, heat or power in NFPA 70. SECTION 109 FEES 109.1 Payment of fees. Refer to DPA/OSA Building Code Compliance Policy. SECTION 110 INSPECTIONS 110.1 General. Construction or work for which a plan review is required shall be subject to inspection by DPA/OSA through its code review agent and such construction or work shall remain accessible and exposed for inspection purposes until approved. Approval as a result of an inspection shall not be construed to be an approval of a violation of the provisions of this code or of other ordinances of the jurisdiction. Inspections presuming to give authority to violate or cancel the provisions of this code or of other ordinances of the jurisdiction shall not be valid. It shall be the duty of the holder of the notice to proceed to cause the work to remain accessible and exposed for inspection purposes. Neither DPA/OSA, its code review agent nor state agency shall be liable for expense entailed in the removal or replacement of any material required to allow inspection. 110.2 Preliminary inspection. Before issuing a compliance notice, DPA/OSA through its code review agent is authorized to examine or cause to be examined buildings, structures and sites for which an application has been filed. 110.3 Required inspections. DPA/OSA through its code review agent, upon notification, shall make the inspections set forth in Sections 110.3.1 through 110.3.10. 110.3.1 Footing and foundation inspection. Footing and foundation inspections shall be made after excavations for footings are complete and any required reinforcing steel is in place. For concrete foundations, any required forms shall be in place prior to inspection. Materials for the foundation shall be on the job, except where concrete is ready mixed in accordance with ASTM C 94, the concrete need not be on the job. 110.3.2 Concrete slab and under-floor inspection. Concrete slab and under-floor inspections shall be made after in-slab or under-floor reinforcing steel and building service equipment, conduit, piping accessories and other ancillary Rev. 7/2013 9 equipment items are in place, but before any concrete is placed or floor sheathing installed, including the subfloor. 110.3.3 Lowest floor elevation. In flood hazard areas, upon placement of the lowest floor, including the basement, and prior to further vertical construction, the elevation certification required in Section 1612.5 shall be submitted to DPA/OSA through its code review agent. 110.3.4 Frame inspection. Framing inspections shall be made after the roof deck or sheathing, all framing, fireblocking and bracing are in place and pipes, chimneys and vents to be concealed are complete and the rough electrical, plumbing, heating wires, pipes and ducts are approved. 110.3.5 Lath and gypsum board inspection. Lath and gypsum board inspections shall be made after lathing and gypsum board, interior and exterior, is in place, but before any plastering is applied or gypsum board joints and fasteners are taped and finished. Exception: Gypsum board that is not part of a fire-resistance-rated assembly or a shear assembly. 110.3.6 Fire- and smoke-resistant penetrations. Protection of joints and penetrations in fireresistance-rated assemblies, smoke barriers and smoke partitions shall not be concealed from view until inspected and approved. 110.3.7 Energy efficiency inspections. Inspections shall be made to determine compliance with Chapter 13 and shall include, but not be limited to, inspections for: envelope insulation R- and U-values, fenestration U-value, duct system R-value, and HVAC and water-heating equipment efficiency. 110.3.8 Other inspections. In addition to the inspections specified above, DPA/OSA through its code review agent is authorized to make or require other inspections of any construction work to ascertain compliance with the provisions of this code and other laws that are enforced by DPA/OSA. 110.3.9 Special inspections. inspections, see Section 1704. For special 110.3.10 Final inspection. The final inspection shall be made after all work required is completed. 110.3.10.1 Flood hazard documentation. If located in a flood hazard area, documentation of the elevation of the lowest floor as required in Section 1612.5 shall be submitted to DPA/OSA prior to the final inspection. 110.4 Inspection agencies. DPA/OSA through its code review agent is authorized to accept reports of approved inspection agencies, provided such agencies satisfy the requirements as to qualifications and reliability. 110.5 Inspection requests. It shall be the duty of the holder of the notice to proceed or their duly authorized agent to notify DPA/OSA through its code review agent when work is ready for inspection. It shall be the duty of the notice to proceed holder to provide access to and means for inspections of such work that are required by this code. 110.6 Approval required. Work shall not be done beyond the point indicated in each successive inspection without first obtaining the approval of DPA/OSA through its code review agent. The code review agent, upon notification, shall make the requested inspections and shall either indicate the portion of the construction that is satisfactory as completed, or notify the holder of the notice to proceed or his or her agent wherein the same fails to comply with this code. Any portions that do not comply shall be corrected and such portion shall not be covered or concealed until authorized by the code review agent. SECTION 111 CERTIFICATE OF OCCUPANCY 111.1 Use and occupancy. No building or structure shall be used or occupied, and no change in the existing occupancy classification of a building or structure or portion thereof shall be made, until DPA/OSA has issued a notice of approval of occupancy/use therefor as provided herein. Issuance shall not be construed as an approval of a violation of the provisions of this code or of other ordinances of the jurisdiction. Exception: Notices of approval of occupancy/use are not required for work exempt from plan review under Section 105.2. 111.3 Temporary occupancy. DPA/OSA is authorized to issue a temporary notice of approval of occupancy/use for discrete portions of work before the completion of the entire work provided that such portion or portions shall be occupied safely. C. Referenced Codes 1. While not adopted in entirety, portions of the following codes are referenced in the International Building Code (IBC), the International Mechanical Code (IMC), the International Energy Conservation Code (IECC) the International Plumbing Code (IPC), and the International Fuel Gas Code (IFGC). These following codes would be applied as reference standards. 2012 International Fire Code (IFC) 2012 International Existing Building Code (IEBC) D. Referenced Standards The IBC, IMC, IECC, IPC and IFGC standards shall be utilized to provide specific, or prescriptive, requirements on how to achieve the requirements established in the code. These standards may be unique to the code or may be derived from other established industry standards. Recognized standards may also be used to show compliance with the standard of duty established by the code. Rev. 7/2013 10 EXHIBIT B CODE COMPLIANCE PLAN REVIEW PROCEDURES 1. All construction for state agencies on state-owned or state leased-purchased properties or facilities are to submit design documents for code compliance plan reviews to the state’s code review agents or State Buildings Programs (SBP) approved agency building official. If a code review agent determines that code review is not required, provide an email documenting that fact to be submitted with Exhibit L. If a state agency leases space in an area where local building codes may not apply, the agency may also follow this process. For a listing of projects that do not require code review, refer to International Building Code section 105.2 and 105.2.2. 2. Upon selection of an Architect/Engineer, a Plan Review Authorization (SBP-017) should be prepared and delivered to the selected code review agent. This authorization indicates the project valuation and the review fee authorized. With this authorization, please provide an intended submittal schedule. Reviews for projects submitted to the code review agent without a Plan Review Authorization (SBP-017) will not commence until the agent receives the prepared authorization form. 3. Prepare the project Schematic Design (SD), Design Development (DD), and Construction Document (CD) submittals in accordance with the attached checklists and submit to the code review agent for review. On projects of limited scope where a combined SD/DD or SD/DD/CD submittal is considered appropriate, please consult with the code review agent prior to submittal. 4. The code review agent will provide a written list of comments addressing issues noted in the review. A response shall be prepared and submitted to the code review agent addressing the deficiencies and questions noted in the review. Specifically, state the agent’s comment followed by the Architect/Engineer’s response chronologically. At the Construction Document review, a response shall be prepared and submitted to the code review agent within 30 days or a mutually agreed upon timeframe addressing the deficiences and questions noted in the review. 5. Once all code issues have been satisfactorily addressed, the code review agent will issue a Compliance Notice to the submitting agency along with a listing of required inspections and will send a copy to State Buildings Programs indicating that the documents appear to be in compliance with code requirements and are appropriate for bidding for lump sum bid projects. On CM/GC projects, a similar process is to be followed through schematic design; however, design development code compliance reviews must be completed on DD documents prior to establishing and accepting a GMP and the Compliance Notice must be issued on CD documents prior to bidding each bid package. If the Compliance Notice is contingent on required modifications to the documents for either lump sum or CM/GC projects, the agency must certify to SBP that the modifications have been incorporated into the documents at the issuance of the Notice to Proceed (SBP-6.26 or SBP7.26). 6. Review of responses and subsequent preparation of a Compliance Notice received more than 30 days or more than the mutually agreed upon date may result in additional services as determined by State Buildings Programs. (Note: Withholding all payment for plan review services until a Compliance Notice is issued is not permitted unless the code review agent is negligent in providing a timely review of responses submitted within the 30 day or mutually agreed upon timeframe. All disputes concerning delays and payments should be brought to SBP’s attention.) 7. Meetings between the agency and/or Architect/Engineer and the code review agent may be requested at any time. Such meetings may be considered additional services beyond the authorized fee per the discretion of the code review agent, at the contracted rates, with a pre-approved top set number encumbered through an approved amendment to the authorization. 8. Communication Policy Rev. 7/2013 1 Exhibit B 9. a. All communication to the code review agent, verbal and written, shall be directed through the assigned reviewer for the code review agent. The reviewer will be assigned at the time of initial submittal and all participants will be notified who this individual is. b. All communications from the Architect/Engineer shall be directed through an assigned individual in the Architect/Engineer’s office. The Architect/Engineer should indicate who the assigned individual will be with the initial submittal. c. The code review agent may discuss code issues in meetings and/or on the phone. However, it should be understood that these are discussions only and should not be construed to establish the final opinion of the code review agent. The codes are complex documents and matters of interpretation and application often require extensive study to establish the code review agent’s opinions. Only written comments provided by the code review agent shall be considered to be official opinions. d. Written review comments will be provided based upon the code review agent’s reviews of submittals. The code review agent will provide detailed reviews of the documents based upon the code review agent’s understanding of the material presented. It should be noted that an item of code compliance that is not noted with a review and is later discovered would be incorporated with future submittal reviews. Progress submittal reviews should not be considered approved sign-offs of the reviewed documents. The code review agent’s reviews will not alleviate the Architect/Engineer’s responsibility to provide Construction Documents in full compliance with all applicable codes. The code review agent will provide reviews in a timely manner. Projects of unusual character or complexity may require more extensive study of various issues and, therefore, more time. The code review agent will not compromise the accuracy of reviews to meet a schedule. If schedules dictate, the code review agent will provide partial reviews in order to facilitate the design process and supplemental reviews may be provided as appropriate. Submittals from the Architect/Engineer should include detailed delineation in regards to the intended code approach in order to expedite the review process. All submittals shall include the information outlined in the State Buildings Programs attached checklists for the appropriate phase of submittal and scope of the project. 10. Request to Change Application of Certain Provisions of the Code (See Section 1.B of SBP Building Code Compliance policy for detailed information on requests for alternative methods, modifications, appeals, and amendments.) a. Any variations from basic code compliance shall be clearly documented. Alternative or equivalent methods or materials shall be submitted to the code review agent or approved agency building code official for review. The code review agent will issue a written opinion of compliance and has the authority to accept, reject or forward the equivalency to State Buildings Programs for action. Written opinions for equivalency may be considered additional services and may be billed on an hourly basis at the contracted rates with a pre-approved top set number encumbered through an approved amendment to the authorization. b. Modifications from code requirements may be requested from State Buildings Programs or approved agency building code official. SBP may request the Agency to get an opinion on the modification request from the code review agent who will issue a written opinion. Written opinions for modification requests may be considered additional services and may be billed on an hourly basis at the contracted rates with a pre-approved top set number encumbered through an approved amendment to the authorization. Rev. 7/2013 2 Exhibit B Code Review Checklist For Schematic Design Submittal The following information shall be included in Schematic Design submittal documents for code review purposes. Plans shall include minimum overall dimensions and shall be of sufficient clarity to indicate schematically the location, nature and extent of the proposed work. A title sheet and additional sheets as necessary shall be included and contain the following information: 1. 2. Rev. 7/2013 GENERAL: An outline of submittal requirements as required by the state contract for A/E design services on the project. A schematic table of contents listing drawings anticipated to be included in the construction document submittal package. Provide an outline of anticipated hazardous materials to be used, stored and probable locations for use and storage. Schematic code compliance plan. (See attached example) A key plan for additions and renovations indicating the relationship of the project area to the existing building(s). BUILDING CLASSIFICATION: A. Occupancy Classification: Compute the floor area and occupant load of the building or portion(s) thereof. See section 1002 and Table 1004.1.2. Indicate the occupancy group(s) which the use of the building or portion(s) thereof most nearly resembles. See sections 301, 303.1, 304.1, 305.1, 306.1, 307.1, 308.1, 309.1, 310.1, 311.1, and 312.1. See section 302 for buildings with mixed occupants and establish if it is to be a separated use or non-separated use. Demonstrate by drawing and/or narrative how the building will conform to the occupancy requirements in Section 303 through 312. B. Type of Construction: Indicate the type of construction proposed for the building. Indicate the building materials proposed and the fire resistance of the parts of the building. See Chapter 6. Demonstrate by drawing and/or narrative how the building will conform to the type of construction requirements in Chapter 6. Indicate if the building is to be fully, partially or non fire sprinklered. C. Location on Property: Indicate the location of the building on the site and clearances to property lines and/or building on a plot plan. See Tables 601, 602, and 704.8 for fire resistance of exterior walls and opening protection. See Section 503. D. Allowable Floor Area: Indicate the proposed floor area and calculate the allowable floor area for each occupancy in the building. See Table 503 for basic allowable floor area for each occupancy group and type of construction. See Section 506 and 507 for allowable increases based in location on property and installation of an approved automatic fire sprinkler system. See Section 504.2 for allowable floor area of multi-story buildings. Demonstrate by drawing and/or narrative the total allowable and actual proposed floor area. E. Height and Number of Stories: Indicate the height of the building and the number of stories, Section 502.1. See Table 503 for the maximum height and number of stories permitted based on occupancy group and type of construction. See Section 504.2 for 3 Exhibit B allowable story increased based on the installation of an approved automatic fire-sprinkler system. Include the allowable and proposed height and number of stories in the narrative. 1. Provide a schematic exiting design indicating how exiting from all portions of the building will conform to the requirements of IBC Chapter 10. Indicate proposed occupant load and calculate required exit widths. Indicate proposed rated corridors, stair enclosures, exit passageways, horizontal exits, etc. 2. Demonstrate how the building will conform with other applicable detailed code regulations in Chapters 4, 7 through 11, 14, 15, 24 through 26, and 30 through 33 by drawing and/or narrative. 3. In most cases, renovation/addition projects require all the previously requested information, in addition to the following: a. Square footage and locations of areas to be renovated. b. Square footage and occupancy classifications and uses of existing spaces not to be renovated. c. Details of investigations necessary to determine the Type of Construction of the existing building and types and locations of fire resistive construction such as: Area Separation Walls Vertical and Horizontal Occupancy Separations Horizontal Exits Tenant Separations Rated Corridor Construction d. Overall floor plants indicating how exiting from renovated areas interface with all other adjacent areas. * Rev. 7/2013 Note: Verification of required opening protection in fire resistive construction should also be noted. F. Structural Analysis: systems. Provide sketches and descriptions of proposed structural G. Building Systems: Provide sketches and descriptions of plumbing, mechanical and electrical systems. H. Building Materials: Provide an outline of proposed construction materials. 4 Exhibit B Code Review Checklist For Design Development Submittal The following information should be included in Design Development submittal documents for code review purposes. Plans should include overall dimensions, drawn to scale, and should be of sufficient clarity to indicate fully the development of the project’s location, nature and extent of the work proposed. 1. Provide the code review SD submittal building classification information and code compliance plan with changes highlighted. 2. Provide Design Development drawings indicating, at a minimum, the following: Rev. 7/2013 A. Site Plan Show property lines, streets, roads, sidewalks, curbs, curb cuts, building location, future additions, existing buildings, driveways, parking lot layout, walks, steps, ramps, fences, gates and walls. Show north arrow. Provide dimensions where yard area increases are proposed and where exterior wall/opening protection may be required. B. Floor Plans Dimensions: Overall and additional dimensions, as applicable. Show north arrow. Rooms: Room names and numbers, and cross references to enlarged plans (as applicable) Floors: Floor elevations, ramps, stairs. Walls: Indicate existing and new walls. Show fire rated corridors, occupancy separations, area separation, shaft enclosures, etc. Doors: Door swings. Windows: Indicate fire and human impact labeled assemblies. Toilet Rooms: Plumbing fixtures, stalls, and cross references to enlarged plans (as applicable) Stairs: Dimension of stairwell, number of risers and treads. Miscellaneous Items: Drinking fountains, folding partitions, and elevators. C. Roof Plan Show roof slopes, crickets and skylights. Show drainage to roof drains, overflow drains, scuppers, etc. D. Exterior Elevations Show floor elevations, finish grades and vertical dimensions. Show roof slope, door and window locations, indicate all materials. E. Building Sections Show vertical dimensions relating to floor, ceiling, and roof height. Note and indicate all materials and proposed listed assemblies for fire rated construction. F. Reflected Ceiling Plan Indicate ceiling materials. Show proposed ceiling layout. G. Enlarged Floor Plan(s) (as appropriate) Toilet Room Plans: Show plumbing fixtures, stall layout and handicap accessibility. Verify plumbing fixture count with code requirements. Kitchens: Show kitchen equipment layout. H. Schedules Develop outlines for doors, windows and associated frames. 5 Exhibit B I. Structural Notes Outline to include: Live Loads: Floor, stairs, corridors, roof, snow, earthquake and wind. Dead Loads: Material weight, mechanical and electrical weight, wet-pipe or drypipe fire sprinkler system, and soil bearing pressure. Material Strength: Concrete, masonry, steel and wood. Foundation design based on Soils Report. J. Structural Schematics Provide foundation plan and structural plan that include floor, roof, and wall construction. K. Mechanical Schematics Show HVAC system layout. Show fuel-fired boiler equipment location. Show gas service location. Show kitchen exhaust hood location. Show smoke control system operation narrative/schematic, as applicable. L. Plumbing Schematics Show water and gas service connections. Plumbing Fixtures: Show water closets, urinals, lavatories and drinking fountains. Roof Drainage: Show roof drain leader sizes, and overflow drains, etc., as appropriate. M. Electrical Schematics Show electrical service and electrical panel location(s). Show light fixtures layout. N. Specification Outline Describe structural, mechanical and electrical systems including fire protection. Establish specification sections for principle materials and finishes. 3. Remodel/addition projects should additionally indicate interface with existing conditions, and limits of work within the existing building. Rev. 7/2013 6 Exhibit B Code Review Checklist For Construction Document Submittal The following information should be included in Construction Document submittal for code review purposes. Plans should be fully dimensioned and drawn to scale and should be of sufficient clarity to indicate the precise location, nature and extent of the work proposed. 1. Provide the code review DD submittal building classification information and code compliance plan with changes highlighted. 2. Provide four (4) sets of Construction Documents indicating, at a minimum, the following: Rev. 7/2013 A. Title Sheet Table of Contents Names of Architect, Engineers and Consultants Building Code Analysis (see Schematic Design submittal requirements) Note Type of Work: 1) New Building 2) Building Addition 3) Alteration/Renovation/Tenant Finish Code Compliance Plan (example: Attachment A) Data Point Connection Chart, if applicable (example: Attachment B) Vicinity Map Identify types and provide amounts and locations of all hazardous materials intended to be stored or used and the type of use as indicated by Table 307.7(1) and 307.7(2). Quantities of all hazardous materials are required to be identified at all locations. List actual quantities and compare to exempt amounts as provided for in Tables 307.7(1) and 307.7(2). Note: Projects with extensive quantities of hazardous materials will be required to submit a Hazardous Materials Management Plan. B. Site Plan Property lines, street names, scale, north arrow Building location, set backs, finish floor elevation, dimensions Contours: Existing and new grades Existing and new paving, parking lot plan Sidewalks, steps, curbs, curb cuts and drives Fences, gates, walls and retaining walls Existing structures, trees and shrubs to remain or to be removed New Landscaping: Trees, shrubs, ground cover Utilities: New and existing Site Details: Handicap curb ramps, signage, etc. Handicap Accessible Routes C. Floor Plan(s) Dimensions: Overall, building break, grid lines, room and opening dimensions, north arrow Rooms: Room names and numbers, and cross reference to enlarged plans Floors: Floor elevations, change in materials, ramps, stairs Walls: Indicate existing and new walls, wall types, material and fire rated assemblies Doors: Door swing and number Windows: Indicate mullions Toilet Rooms: Plumbing fixtures, stalls, floor drains, and cross reference to enlarged plans 7 Exhibit B Stairs: Dimension of stairwell, show traffic pattern, number of risers and treads, cross reference to stair details Miscellaneous Items: Fire extinguisher cabinets, access doors, drinking fountains, folding partitions, ladders, lockers, shelving, railings, guardrails, and elevators Alterations: Existing opening to be infilled and new openings to be cut Rev. 7/2013 D. Roof Plan Materials: Type of roofing Drainage: Roof drains, overflow drains, scuppers, gutters, leaders Roof pitch to drains showing high point and low point Crickets, skylights, vents, fans, mechanical equipment, roof access Miscellaneous: Roof pavers, ladders, splash blocks, ventilation of roof spaces, and expansion joints E. Exterior Elevations Materials: Type of exterior finish Windows and Doors: Provide window and door openings, dimension height of opening, indicate window and door type Dimensions: Grid lines, vertical dimensions, floor levels, grade elevations Miscellaneous: Ladders, louvers, railings, gutters and downspouts F. Building Sections Dimensions: Vertical dimensions relating to floor, ceiling, roof, top of steel Provide grid lines and cross reference to floor plans Materials: Note and indicate material as well as listed fire rated assemblies G. Reflected Ceiling Plan Provide ceiling construction. Show ceiling breaks, or change in height Show ceiling pattern, diffusers, light fixtures, exit signage and access panels H. Enlarged Floor Plan(s) Toilet Room Plans: Plumbing fixtures, stall layout, and handicap accessibility Verify plumbing fixture count with code requirements. Kitchens: Kitchen equipment layout I. Interior Elevations Toilet Room Elevations: Plumbing fixture heights and handicap accessibility Indicate wall finish materials J. Schedules Room Finish Schedule: Show interior finishes Door Schedule: Door types, sizes and fire rating, door hardware Window Schedule: Window types, frames, labels, glazing and sizes K. Architectural Details Stairs: Riser and tread dimensions, headroom clearance, and handrail details and attachment details Guardrails: Height and distance between intermediate rails and attachment details Ramps: Slope and length and handrails Wall Types: Fire rated construction, corridor walls, shaft walls, area separation walls, occupancy separation walls. Indicate listed assemblies for fire rated construction. Specify fire penetration sealants at rated walls. L. Structural Notes Live Loads: Floors, stairs, corridors, roof, snow, earthquake and wind Dead Loads: Material weight, mechanical and electrical weight, wet-pipe or dry-pipe fire sprinkler system, and soil bearing pressure 8 Exhibit B Material Strength: Concrete, masonry, steel and wood Foundation design based on Soils Report. Provide one (1) copy of the Soils/Geotechnical Report. 3. Rev. 7/2013 M. Structural Plans Provide Foundation Plan and Structural Framing Plans that include floor, roof, and wall construction N. Structural Details (as required) O. Structural Calculations (one set) P. Mechanical Plans Show HVAC system layout Show fire damper and fire/smoke damper locations, location of fuel-fired equipment, including type and size of flues, BTUH input, gas pipe sizes Provide kitchen exhaust hood size/fire protection, smoke control systems, as applicable Q. Plumbing Plans Storm sewer, sanitary sewer, water, gas, fire hydrant, catch basin locations Water and gas connections Plumbing Fixtures: Water closets, urinals, lavatories, and drinking fountains Roof Drainage: Roof drain, overflow drain, scuppers, and leader sizes and locations Fire sprinkler system and standpipe location and main connections List kitchen equipment Sand traps, grease traps, etc. Plumbing isometrics R. Electrical Plans Service and distribution equipment location: Electrical service, transformer, electrical meter and panel location Exit sign locations, light fixtures layout and emergency lighting Electrical outlets and circuits Fire alarm/detection system Light fixture schedule Panelboard circuit schedule/calculations One-line diagram S. Specifications Describe structural, mechanical and electrical systems Complete specification sections for principal materials and finishes Provide statement of special inspections required Remodel/addition projects should additionally indicate interface with existing conditions and limits of work within the existing building. 9 Exhibit B (ATTACHMENT A) Rev. 7/2013 10 Exhibit C STATE OF COLORADO OFFICE OF THE STATE ARCHITECT STATE BUILDINGS PROGRAMS PLAN REVIEW AUTHORIZATION State’s Code Review Consultant Institution or Agency: Project No./Name: Date (Institution/Agency) as Principal Representative intends to supplement the Base Consultant Agreement for Plan Review/On-Site Inspection dated and routing number and form a contract for code compliance reviews in accordance with the conditions stipulated in the Base Consultant Agreement. Plan Review Fee: Fees will be determined using the Plan Review Fee Table, Section I.3.A. of Exhibit A of the Base Consultant Agreement and is based upon a project valuation of $ . + (Base Amount) = (Incremental Fee) (Total Fee) Phases of development to be reviewed are as follows (check applicable boxes): Schematic Design Phase (SD) Design Development Phase (DD) Construction Document Phase (CD) Schematic Design/Design Development Phases Combined (SD/DD) Additional services may be requested or assigned in writing by the Principal Representative. Projects will not be approved for bidding until the state’s code review agent has approved the construction documents for code compliance by issuing a Compliance Notice. Code Review Agent Date State Buildings Programs (or Authorized Delegate) Date State Form SBP-017 Rev. 7/2012 Principal Representative (Institution or Agency) Date Exhibit D STATE OF COLORADO OFFICE OF THE STATE ARCHITECT STATE BUILDINGS PROGRAMS BUILDING INSPECTION RECORD Institution or Agency: Project No./Name: Building Official/Code Review Agent: Architect/Engineer: Contractors: General: Electrical: Mechanical: Plumbing: Notice to Proceed Date: Provide If Checked Type of Construction: Occupancy Classifications: Project Manager: Project Manager Signature At Completion: Inspector of Record Signature at Completion: BIR Completion Date: * No work shall be concealed or covered until the appropriate inspector has inspected and approved. Building (Consultant) Footings/Foundations Concrete Slab / Under-Floor Framing (after rough elec/mech/plumb) Lath and Gypsum Board Fire-Resistant Penetrations Mechanical/Energy Efficiency Roofing Other Final Steel Concrete Masonry Wood Soils/Foundations Spray-Applied Fireproofing Smoke Control Systems Other Final Underground Rough Walls Rough Ceilings Final Underground Gas Inside Water Final Fire Sprinkler System Fire Alarm System Other Final Final Special (Consultant) Elevator Inspection (State) Electrical (Co. St. Electrical Bd.) Plumbing (Co. Ex. Bd. of Plumbers) Fire Department Inspection (Local) Health Dept. Inspection (Local) Boiler Inspection (State) Date Inspector/ICC# Comments or Corrections Date Inspector Comments or Corrections Date Inspector Comments or Corrections Date Inspector Comments or Corrections Date Inspector Comments or Corrections Date Inspector Comments or Corrections Date Inspector Comments or Corrections Date Inspector Comments or Corrections New Installation Repair or Alteration Final Place this card in an obvious, protected location, along with all related inspection reports and documents. SBP-BIR Rev. 5/2012 Exhibit D 615-92-53-7997 SBP-BIR Rev. 5/2012 Exhibit E STATE OF COLORADO OFFICE OF THE STATE ARCHITECT STATE BUILDINGS PROGRAMS BUILDING INSPECTION AUTHORIZATION State’s Code Review Consultant Institution or Agency: Project No./Name: Date (Department/Agency) as Principal Representative intends to supplement the Base Consultant Agreement for Plan Review/On-Site Inspection dated and routing number and form a contract for code compliance building inspections in accordance with the conditions stipulated in the Base Consultant Agreement. Building Inspection Fee: Fees will be determined based on the code consultant’s hourly rates and mileage reimbursement as per Exhibit D of the Base Consultant Agreement. Determination of the hours required are to be based on the scope and complexity of the project and the requested inspections as per the Building Inspection Record (SBP-BIR). The consultant proposal dated is incorporated herein by reference. Building inspection fee calculation. (Attach code consultant’s proposal justification to this form): ( (Hourly Rate) X )+ ( (Anticipated Hrs.) (Mileage) X )= (Mileage Reimb.) (Total Fee) The following building inspections are requested: (Check applicable boxes): Footings/Foundations Concrete Slab / Under-Floor Framing (after rough elec/mech/plg) Lath and Gypsum Board Fire-Resistant Penetration Mechanical / Energy Efficiency Roofing Other Final Additional services may be requested or assigned in writing by the Principal Representative. Projects will not be approved for occupancy until state’s code review agent completes and approves the requested inspections by signing-off on the final inspection on the Building Inspection Record (SBP-BIR). Code Review Agent Date State Buildings Programs (or Authorized Delegate) Date SBP-018 Rev. 7/2008 Principal Representative (Institution or Agency) Date Exhibit F STATE OF COLORADO OFFICE OF THE STATE ARCHITECT STATE BUILDINGS PROGRAMS INSPECTION REPORT Inspection Entity/Code Review Agent: Inspection Date and Time: Contractor: Institution or Agency: Project No./Name: (Check One) Building Footings/Foundation_________ _________________________ Concrete Slab / Under-Floor__ _________________________ Framing ___________ _________________________ Lath and Gypsum Board_____ _________________________ Fire-Resistant Penetrations__ ________________________ Mechanical / Energy Efficiency _________________________ Roofing___________________ _________________________ Other _________________ _________________________ Final _________________ Special Steel_____________________ _________________________ Concrete _________________ _________________________ Masonry __________________ _________________________ Wood ____________________ _________________________ Soils / Foundations__________ _________________________ Spray-Applied Fireproofing___ _________________________ Smoke Control Systems______ _________________________ Other ___________________ _________________________ Project Location COMMENTS Time/Date made: _________________________ Inspector: _______________________________ Partial Elevator Final ____________________ Other _________________________ _________________________ State Form SBP-019 Rev. 7/2008 Reject Approved Exhibit G STATE OF COLORADO OFFICE OF THE STATE ARCHITECT STATE BUILDINGS PROGRAMS NOTICE TO PROCEED (DESIGN/BID/BUILD CONTRACT) Date of Notice: Date to be inserted by the Principal Representative Date/Description of Contract Documents: Institution/Agency: Project No./Name: Attach Notice of Code Compliance from Code Review Agent/Building Official for Documents Listed Above To: This is to advise you that your Performance Bond, Labor and Material Payment Bond, the requisite Builder’s Risk Insurance Policy or Certificate for same, and Certificates of Insurance have been received. Our issuance of this Notice does not relieve you of responsibility to assure that the bond and insurance requirements of the Contract Documents are covering the above described work has been fully met for the duration of the Agreement. The Agreement dated executed. You are hereby authorized and directed to proceed within ten (10) days from date of this Notice as required in the Agreement. Any liquidated damages for failure to achieve substantial completion by the date agreed that may be applicable to this contract will be calculated using the date of this Notice for the date of the commencement of the Work. By ________________________________________ State Buildings Programs Date (or Authorized Delegate) By ________________________________________ Principal Representative Date (Institution or Agency) When completely executed, this form is to be sent by certified mail to the Contractor by the Principal Representative. State Form SBP-6.26 Rev. 7/2010 Page 1 of 1 Exhibit H STATE OF COLORADO OFFICE OF THE STATE ARCHITECT STATE BUILDINGS PROGRAMS NOTICE OF SUBSTANTIAL COMPLETION Date of Substantial Completion: Date to be inserted by the Principal Representative Institution/Agency: Project No./Name: TO: Principal Representative and Contractor This is to advise you that the Work has been reviewed, inspected and determined, to the best knowledge, information and belief of the Architect/Engineer, to be substantially complete as of the date noted above in accordance with the criteria outlined in Article 41 of The General Conditions of the Contract and the Specifications, including without limitation a) suitable for occupancy, b) inspected for code compliance with Building Inspection Records signed by code officials for the State, c) determined to be fully and comfortably usable, and d) fully cleaned and appropriate for presentation to the public. A punch list of work to be completed, work not in compliance with the Drawings or Specifications, and unsatisfactory work is attached hereto, along with the Contractor’s schedule for the completion of each and every item identified on the punch list specifying the Subcontractor or trade responsible for the work, and the dates the completion or correction will be commenced and finished within any period indicated in the Agreement for punch list completion prior to Final Acceptance. Except as stated on the reverse side of this Notice of Substantial Completion, all manufacturers’ warranties, other special warranties and the Contractor’s one-year obligation to perform remedial work, shall commence on the Date of Substantial Completion noted above. This Notice of Substantial Completion shall be effective and establish the Date of Substantial Completion only when fully executed by the Contractor and the Principal Representative. The Principal Representative accepts the Work as substantially complete as of the Date of Substantial Completion herein noted. The Contractor agrees to complete or correct the Work identified on the attached punch list and to do so in accordance with attached punch list completion schedule Architect/Engineer Date Principal Representative (Institution or Agency) Date State Buildings Programs (or Authorized Delegate) Date Contractor (If Applicable) Date State Form SBP-07 Rev. 7/2012 Page 1 of 2 Exhibit H The responsibilities of the Principal Representative and the Contractor for security, maintenance, heat, utilities, and insurance shall be as specified in the Contract Documents or as otherwise hereafter noted: Exceptions, if any, to the commencement of warranties shall be: pages, and the attached Contractor’s schedule showing the dates of The attached final punch list consists of commencement and completion of each punch list item consists of pages. When completely executed, this form shall be sent to the Contractor and the Principal Representative with a copy to State Buildings Programs. State Form SBP-07 Rev. 7/2012 Page 2 of 2 Exhibit I STATE OF COLORADO OFFICE OF THE STATE ARCHITECT STATE BUILDINGS PROGRAMS NOTICE OF APPROVAL OF OCCUPANCY/USE Date of Occupancy: Date to be inserted by the Architect/Engineer after consulation with Principal Representative Institution/Agency: Project No./Name: Portion(s) of project for which Beneficial Occupancy is approved: Type of Beneficial Occupancy: Total or Partial The items identified below if applicable must be complied with before Occupancy is approved. Date Completed A/E Signoff 1. The Notice of Substantial Completion has been issued and the Building Inspection Record is completely signed-off and attached. 2a. Notification has been made to the local Fire Department concerning which portion(s) of the building will be occupied and the date(s). 2b. Fire alarms, smoke detection systems and building fire sprinkler systems have been fully checked and are operable. 2c. The building’s siamese fire connection must be installed and operable, if applicable. 3. Coordination for final utility and service connections and meters (water, gas, sewer, electricity and telecommunication) has been made and systems are in full operating order. 4. Sterilization of plumbing systems has been performed. 5. Operational test of systems and equipment has been performed as required. 6. Systems adjustments such as balancing, equipment operations, etc., have been performed. Reports have been submitted to the Architect/Engineer for approval. 7. Principal Representative furnished equipment and furnishings are coordinated and placed. 8. All elements left unfinished must be in such condition that there would be no hazard to the health or safety of the occupants. 9. All restroom facilities must be fully functional and operable. 10. All light fixtures must be installed and operable. 11. All exit lights and emergency lighting systems have been checked and are operable. State Form SBP-01 Rev. 7/2008 Page 1 of 2 Exhibit I 12. All windows have been glazed and hardware is available for ventilation purposes. 13. All routes of egress must be clear of construction materials and debris at all times. 14. There must be a means of pedestrian access to each building. Contractor must have sidewalks installed before occupancy and pedestrian barricades and other means of public protection as required. Occupancy does not constitute acceptance of the project as being complete. It simply provides the Principal Representative the opportunity to occupy/use the project or the applicable portion thereof prior to final completion and acceptance. Occupants can expect to be impacted by the Contractor’s efforts to complete the project. The Contractor under the contract would not repair any damage by normal use or willfulness caused by the occupants. Architect/Engineer Date Principal Representative (Institution or Agency) Date State Buildings Programs (or Authorized Delegate) Date Contractor Date State Form SBP-01 Rev. 7/2008 Page 2 of 2 Exhibit J STATE OF COLORADO OFFICE OF THE STATE ARCHITECT STATE BUILDINGS PROGRAMS NOTICE OF FINAL ACCEPTANCE Date of Notice of Acceptance: Date to be inserted by Architect/Engineer after consultation with the Principal Representative Institution/Agency: Project No./Name: TO: Notice is hereby given that the State of Colorado, acting by and through the accepts as complete* the above numbered project. State Buildings Programs (or Authorized Delegate) Date Principal Representative (Institution or Agency) , Date *When completely executed, this form is to be sent by certified mail to the Contractor by the Principal Representative. State Form SBP-6.27 Rev. 9/2006 Exhibit K STATE OF COLORADO OFFICE OF THE STATE ARCHITECT STATE BUILDINGS PROGRAMS AGENCY ACTION PLAN FOR CODE COMPLIANCE DATE: AGENCY/INSTITUTION: PREPARED BY: TITLE: The Department of Personnel & Administration (DPA)/State Buildings Programs (SBP) is responsible per CRS 24-301303 for establishing minimum building codes, developing methods to ensure conformity of physical planning with approved building codes, and developing standards of inspection. In order to implement this statutory responsibility, SBP developed the policy Building Code Compliance: Coordination of Approved Building Codes, Plan Reviews and Building Inspections. A major tenet of the SBP Building Code Compliance policy is the annual reporting that is required of all state agencies/institutions. Each agency/institution must detail how it complies with SBP requirements for plan review, building inspection, and compliance reporting. This report, Agency Action Plan for Code Compliance, is required to be prepared and submitted to SBP for review and approval in January of each year. There are three agencies/institutions that currently have a grandfathered-in agency building official code process. In addition to submitting the Agency Action Plan for Code Compliance, those agencies/institutions must also submit to SBP annually a written report which describes the code compliance process at the agency, identifies all individuals that are involved, and includes their International Code Council (ICC) certifications. Plan Reviews 1. How does your agency/institution comply with the Building Code Compliance policy requirements concerning plan review? Include the following issues: A. Does your agency/institution utilize the services of one or more of the state’s code review agents (all with ICC certification) to provide code compliance plan reviews on your capital construction, controlled maintenance, emergency and cash or in-house funded projects? Note that code compliance reporting as discussed below is required only on appropriated projects – capital construction and controlled maintenance. However, building code compliance plan review is required on all projects – unless an exception is provided per IBC Section 105.2. If there is a question as to whether code review is required or not, the agency project manager should consult with one of the state’s code review agents. B. If your agency has been pre-approved by SBP to conduct your own plan reviews, identify the individual(s) responsible by name, job title, and experience and attach their resumes and ICC certifications. Building Inspections 1. How does your agency/institution comply with the Building Code Compliance policy requirements concerning building inspection? Include the following issues: A. It is the responsibility of the agency project manager to coordinate the building inspections that have been called for at the conclusion of the plan review process. What is your agency/institution’s standard process for conducting building, special, and elevator inspections? For building inspections, do you utilize the services of one or more of the state’s code review agents, or a third party architect/engineer with ICC certification, or an inspection consultant, or your agency technical staff (ICC certification required)? If agency technical staff is used, identify the individual(s) by name, job title, and experience, indicate the type(s) of inspections, and attach a resume detailing his/her qualifications including ICC certification number. Do you utilize the services of an inspection consultant for special inspections? Rev. 7/2013 Exhibit K B. The Colorado State Electrical Board (Department of Regulatory Agencies) is required by statute to perform electrical inspections on all projects on state owned land. How does your agency comply? The Colorado Examining Board of Plumbers (Department of Regulatory Agencies) is required by statute to perform plumbing inspections on all projects on state owned land. How does your agency comply? For those small in-house projects where the State Boards elect not to inspect, does your agency utilize the services of the design architect/engineer, and inspection consultant, or agency technical staff? If agency technical staff is used, identify the individual by name, job title, and experience, indicate type(s) of inspections, and attach a resume detailing his/her qualifications. Individuals performing electrical and plumbing inspections must have qualifications and experience to equal the minimum standards as per statutes CRS 12-23-106 and CRS 12-58-101-107, respectively. Other Plan Review and Building Inspection Responsibilities 1. What is your agency/institution’s standard process for working with the local fire department during design and/or plan review? How do you work with the local fire department and/or the Division of Fire Safety (Department of Public Safety) conducting fire sprinkler and other fire code compliance inspections? 2. What is your agency/institution’s standard process for working with the local health department (delegated by the Department of Public Health and Environment) for plan review and inspection of food service facilities? 3. What is your agency/institution’s standard process for working with the state boiler inspector (Department of Labor and Employment) or approved insurance company inspectors conducting inspections of new, repaired, or relocated boilers? 4. What is your agency/institution’s standard process for working with the conveyance administrator (Department of Labor and Employment) re certified inspectors for new elevator and escalators? Code Compliance Documentation 1. Describe you agency/institution’s methodology for maintaining files. Do you maintain a centralized code compliance file or is the documentation maintained within specific project files? Are interim reviews, correspondence, and reports kept permanently or just final documents? 2. Identify the individual/job title responsible for coordinating the code compliance documentation submittal and project closeout final SC4.1 reconciliation submittal. As per the requirement in the SBP Building Code Compliance policy, the following documents must be submitted with the appropriate transmittal that is included in the policy: Notice of Code Compliance including inspection recommendations or memo from agency with email from code review agent stating code review was not required. If the Compliance Notice was contingent on the inclusion of the Construction Documents code review comments (as most are), the agency project manager must certify that the comments were incorporated into the drawings and specifications or provide an explanation for why they weren’t. If alternative methods, modifications, or appeals were approved for this project, detailed documentation must be submitted. Notice to Proceed (SBP-6.26) or (SBP-7.26) Building Inspection Record Notice of Approval of Occupancy/Use (SBP-01) Codes and Standards 1. Provide a list of life safety codes and other codes and standards that have been adopted by your agency/institution, if any, due to specific building types, accreditation requirements, or funding requirements. These codes are in addition to the minimum approved codes and standards adopted by SBP. Rev. 7/2013 EXHIBIT L-1 PROJECT CLOSE OUT CODE COMPLIANCE DOCUMENTATION SUBMITTAL (ALL AGENCIES) To: State Buildings Programs From: (Name) (Agency) Date: Project Name and #: The following four code compliance documents are required for all agencies and are attached and indicated on this memo of transmittal (copies, no originals). Notice of Code Compliance including building inspection recommendations issued by code review agent or memo from agency stating why code review was not required for the project. If the Compliance Notice was contingent on the inclusion of the Construction Document code review comments, the agency project manager must certify that the code review agent’s comments were incorporated into the drawings and specifications. If alternative methods, modifications, or appeals were approved, submit detailed documentation. Notice to Proceed (SBP-6.26) or (SBP-7.26) Building Inspection Record (SBP-BIR) Notice of Approval of Occupancy/Use (SBP-01) Rev. 7/2013 EXHIBIT M REQUEST FOR MODIFICATION Project Name and Number: Date: The Office of the State Architect/State Buildings Programs (OSA/SBP) building code plan review consultants may approve alternative means and methods as per International Building Code (IBC) Section 104.11. Requests for modification for the IBC (IBC Section 104.10) must be directed to the building code administrator at OSA/SBP. Amended for OSA/SBP use, IBC Section 104.10 states: “Whenever there are practical difficulties involved in carrying out the provisions of this code, OSA/SBP shall have the authority to grant modifications for individual cases, upon application of the owner …, provided OSA/SBP shall first find that special individual reason makes the strict letter of this code impractical and the modification is in compliance with the intent and purpose of this code and that such modification does not lessen health, accessibility, life and fire safety, or structural requirements. The details of action granting modifications shall be recorded and entered into the files of OSA/SBP.” OSA/SBP must have adequate documentation concerning the request to fully explain and demonstrate due diligence in making the determination. Sufficient drawings that document the project and the issue requested must be provided. Note that while the building code plan review consultants are familiar because of their review of the documents, no graphic information has been submitted to OSA/SBP. The request for modification must be initiated by the OSA/SBP delegate or agency contact person not the architect/engineer or other consultant. Please provide the following information: State Agency/Institution of Higher Education Individual Making Request (with email and phone contact information) Building Code Plan Review Consultant for the project IBC Section(s) for which Modification is Requested Drawings Attached o Yes o No Code Analysis if not included on Drawings Description of Issue and Identify any Supporting Documentation Rev. 7/2013 STATE OF COLORADO OFFICE OF THE STATE ARCHITECT STATE BUILDINGS PROGRAM CONTRACTOR'S DESIGN/BID/BUILD AGREEMENT (STATE FORM SC-6.21) EXHIBIT G University Insurance Requirements A INSURANCE REQUIREMENTS (A) This insert applies to the following State Contracts: General Conditions of the Construction Contract Design/Bid/Build (SC-6.23), or Contractors Agreement Design/Bid/Build (SC-6.21), or Standing Order Contractor, or Construction Manager/General Contractor CM/GC (SC-6.4), or Design/Build Entity (SC-8.0). Design/Build Guaranteed Max SC 9.0 For purposes of this supplement “Contractor” as used herein shall mean, as appropriate to the State Contract form being used, Contractor, Standing Order Contractor, Construction Manager/General Contractor, or Design/Build Entity. The Contractor shall obtain and maintain, at its own expense and for the duration of the contract including any warranty periods under the Contract are satisfied, the insurance coverages set forth below. By requiring such insurance, the Principal Representative shall not be deemed or construed to have assessed the risk that may be applicable to the Contractor its agents, representatives, employees or subcontractors under this contract. The insurance requirements herein for this Contract in no way limit the indemnity covenants contained in the Contract. The Principal Representative in no way warrants that the limits contained herein are sufficient to protect the Contractor from liabilities that might arise out of the performance of the work under this Contract by the Contractor, its agents, representatives, employees, or subcontractors. The Contractor shall assess its own risks and if it deems appropriate and/or prudent, maintain higher limits and/or broader coverages. The Contractor is not relieved of any liability or other obligations assumed or pursuant to the Contract by reason of its failure to obtain or maintain insurance in sufficient amounts, duration, or types. COVERAGES AND LIMITS OF INSURANCE - - Contractor shall provide coverage with limits of liability not less than those stated below. 1. Commercial General Liability – ISO CG 0001 or equivalent. Coverage to include: • Premises and Operations • Explosions, Collapse and Underground Hazards • Personal / Advertising Injury • Products / Completed Operations • Liability assumed under an Insured Contract (including defense costs assumed under contract) • Independent Contractors • Designated Construction Projects(s) General Aggregate Limit, ISO CG 2503 (1997 Edition) • Additional Insured—Owners, Lessees or Contractors Endorsement, ISO Form 2010 (2004 Edition or equivalent) Page 1 of 7 • • • • Liability Limits Primary General Liability Umbrella or Excess Liability* Additional Insured—Owners, Lessees or Contractors Endorsement (Completed Operations), ISO CG 2037 (7/2004 Edition or equivalent) The policy shall be endorsed to include the following additional insured language on the Additional Insured Endorsements specified above: “The Regents of the University of Colorado, a Body Corporate, named as an additional insured with respect to liability and defense of suits arising out of the activities performed by, or on behalf of the Contractor, including completed operations”. Commercial General Liability Completed Operations policies must be kept in effect for up to three (3) years after completion of the project. For buildings with a construction cost greater than $99 million, the Commercial General Liability Completed Operations policies must be kept in effect for up to eight (8) years after the completion of the project. An umbrella and/or excess liability policy may be used to meet the minimum liability requirements provided that the coverage is written on a “following form” basis. General Aggregate Each Occurrence $2,000,000 Products/Completed Operation Aggregate $2,000,000 $1,000,0000 Personal/Advertising Injury $1,000,000 $5,000,000 $5,000,000 $5,000,000 $5,000,000 *Umbrella or Excess Liability does not apply to projects totaling $500, 000 or under. The following exclusionary endorsements are prohibited in the CGL policy: 1. Damage to work performed by subcontract/vendor (CG 22-94 or similar); 2. Contractual liability coverage exclusion modifying or deleting the definition of an “insured contract”; 3. If applicable to the work to be performed: Residential or multi-family; 4. If applicable to the work to be performed: Exterior insulation finish systems; 5. If applicable to the work to be performed: Subsidence or earth movement. 2. Automobile Liability Bodily Injury and Property Damage for any owned, hired, and non-owned vehicles used in the performance of this contract Minimum Limits: Bodily Injury/Property Damage (Each Accident) 3. $ 1,000,000 Workers Compensation • Statutory Benefits (Coverage A) Page 2 of 7 • Employers Liability (Coverage B) a. b. Policy shall contain a waiver of subrogation in favor of the Principal Representative. This requirement shall not apply when a contractor or subcontractor is exempt under Colorado Workers’ Compensation Act., AND when such contractor or subcontractor executes the appropriate sole proprietor waiver form. Minimum Limits: Coverage A (Workers’ Compensation) Coverage B (Employers Liability) Each accident Disease each employee Disease policy limit 4. $ $ $ 100,000 100,000 500,000 Contractors Pollution Liability • If Contractor is providing directly or indirectly working with pollution/environmental hazards, Contractor must provide or cause those conducting the work to provide Pollution Liability Insurance coverage. Pollution Liability policy must include contractual liability coverage. • Coverage shall apply to sudden and gradual pollution conditions resulting from the escape of release of smoke, vapors, fumes, acids, alkalis, toxic chemicals, liquids, or gases, natural gas, waste materials, or other irritants, contaminants, or pollutants (including asbestos). Policy shall cover the Contractor’s completed operations. • If the coverage is written on a claims-made basis, the Contractor warrants that any retroactive date applicable to coverage under the policy precedes the effective date of this Contract; and that continuous coverage will be maintained or an extended discovery period will be exercised for a period of three (3) years beginning from the time that work under this contract is completed. • The policy shall be endorsed to include the following as Additional Insureds: The Regents of the University of Colorado, a Body Corporate, named as an additional insured with respect to liability and defense of suits arising out of the activities performed by, or on behalf of the Construction Manager, including completed operations. • Endorsements CA9948 and MCS-90 are required on the Automobile Liability Coverage if the Contractor is transporting any type of hazardous materials. • Contractors Pollution Liability policies must be kept in effect for up to three (3) years after completion of the project. Minimum Limits: Per Loss Aggregate 5. Statutory $ $ 1,000,000 1,000,000 Professional Liability (Errors and Omissions) (This Professional Liability requirement applies only to Design/Build Entity, SC-8.0.) Page 3 of 7 The Contractor shall maintain Errors and Omissions Liability covering negligent acts, errors and/or omissions, including design errors of the Contractor for damage sustained by reason of or in the course of operations under this Contract. The policy/coverages shall be amended to include the following: Amendment of any Contractual Liability Exclusion to state: “This exclusion does not apply to any liability of others which you assume under a written contract provided such liability is caused by your negligent acts.” In the event that any professional liability insurance required by this Contract is written on a claims-made basis, Contractor warrants that any retroactive date under the policy shall precede the effective date of this Contract; and that either continuous coverage will be maintained or an extended discovery period will be exercised for a period of three (3) years beginning at the time work under this Contract is completed. Policy shall contain a waiver of subrogation against The Regents of the University of Colorado, a Body Corporate. Wrongful Act General Aggregate 6. $2,000,000 $2,000,000 Builder’s Risk/ Installation Floater Unless otherwise provided or instructed by the Principal Representative, the Contractor shall purchase and maintain, in a company or companies lawfully authorized to do business in the jurisdiction in which the project is located, Builder’s Risk Insurance in the amount of the initial contract amount as well as subsequent modifications for the entire project at the site on a replacement cost basis without optional deductibles. This coverage is required for new buildings or additions to existing buildings and for materials and equipment to be installed in existing structures. • Covered Cause of Loss: Special Form • Include Theft and Vandalism • Labor costs to repair damaged work • Shall be written for 100% of the completed value (replacement cost basis) • Deductible maximum is $50,000.00 • Waiver of Subrogation is to apply • The Regents of the University of Colorado, a body corporate, shall be added as Additional Named Insured on Builders Risk. 1. 2. Policy must provide coverage from the time any covered property becomes the responsibility of the Contractor, and continue without interruption during construction, renovation, or installation, including any time during which the covered property is being transported to the construction installation site, or awaiting installation, whether on or off site. The Policy shall be maintained, unless otherwise provided in the contract documents or Page 4 of 7 3. 4. 5. 6. otherwise agreed in writing by all persons and entities who are beneficiaries of such insurance, until final payment has been made or until no person or entity other than the Principal Representative has insurable interest in the property to be covered, whichever is later. The Builder’s Risk insurance shall include interests of the Principal Representative, and if applicable, affiliated or associated entities, the General Contractor, subcontractors and subtier contractors in the project. Builders’ Risk Coverage shall be on a Special Covered Cause of Loss Form and shall include theft, vandalism, malicious mischief, collapse, false-work, temporary buildings and debris removal including demolition, increased cost of construction, architect’s fees and expenses, flood (including water damage), earthquake, and if applicable, all below and above ground structures, piping, foundations including underground water and sewer mains, piling including the ground on which the structure rests and excavation, backfilling, filling, and grading. Equipment Breakdown Coverage (a.k.a. Boiler & Machinery) shall be included as required by the Contract Documents or by law, which shall specifically cover insured equipment during installation and testing (including hot testing, where applicable). Other coverages may be required if provided in contract documents. The Builders’ Risk shall be written for 100% of the completed value (replacement cost basis) of the work being performed. The Builders’ Risk shall include the following provisions: a. Replacement Cost Basis - including modification of the valuation clause to cover all costs needed to repair the structure or work (including overhead and profits) and will pay based on the values figured at the time of rebuilding or repairing, not at the time of loss b. Modify or delete exclusion pertaining to damage to interior of building caused by an perils insured against are covered; also provide coverage for water damage Note, if the addition, or renovation is to an existing building, The Principal Representative requires that the Contractor provide as an option to include the existing building into the Builders’ Risk Policy. The Principal Representative shall provide the replacement cost value of the existing building At the option of the Principal Representative, the Principal Representative may include Soft Costs (including Loss of Use)/Delay in Opening Endorsement under the builder’s risk policy. The Principal Representative agrees to provide the necessary exposure base information for quotation by the Builder’s Risk carrier. The Principal Representative agrees to pay the premium associated with the Soft Costs coverage, the Principal Representative decides to purchase this coverage. 7. The Builders’ Risk Policy shall specifically permit occupancy of the building during construction. Partial occupancy or use of the work shall not commence until the insurance company or companies providing insurance have consented to such partial occupancy or use. The Principal Representative and Contractor shall take reasonable steps to obtain consent of the insurance company or companies and delete any provisions with regard to restrictions within any Occupancy Clauses within the Builders’ Risk Policy. The Builders’ Risk Policy shall remain in force until acceptance of the project by the Principal Representative. 8. The deductible shall not exceed $50,000 and shall be the responsibility of the Contractor except for losses such as flood (not water damage), earthquake, windstorm, tsunami, volcano, etc. Losses in excess of $50,000 insured shall be adjusted in conjunction with the Page 5 of 7 Principal Representative. Any insurance payments/proceeds shall be made payable to the Principal Representative subject to requirements of any applicable mortgagee clause. The Contractor shall pay subcontractors their just shares of insurance proceeds received by the Contractor, and by appropriate agreements, written where legally required for validity, shall require subcontractors to make payments to their sub-subcontractors in similar manner. The Principal Representative shall have the authority to adjust and settle any losses in excess of $50,000 with insurers unless one of the parties in interest shall object in writing within five days after occurrence of loss to the Principal Representative exercise of this power. It is expressly agreed that nothing in this section shall be subject to arbitration and any references to arbitration are expressly deleted. 9. The Contractor is responsible for providing 45 days’ notice of cancellation to the Principal Representative. . The policy shall contain all generally applicable conditions, definitions, exclusions and endorsements related to the Project. If the Contractor does not intend to purchase such Builder’s Risk Insurance required by the Contract and with all of the coverages in the amount described above, the Contractor shall so inform the Principal Representative as stated in writing prior to commencement of the work. The Principal Representative may then affect insurance that will protect the interests of the Principal Representative, the General Contractor, Subcontractors and sub-tier contractors in the project. Coverages applying shall be the same as stated above including other coverages that may be required by the Principal Representative. The cost shall be charged to the Contractor. Coverage shall be written for 100% of the completed value of the work being performed, with a deductible not to exceed $50,000 per occurrence for most projects. All deductibles will be assumed by the Contractor. Waiver of Subrogation is to apply against all parties named as insureds, but only to the extent the loss is covered, and Beneficial Occupancy Endorsements are to apply. If the Principal Representative is damaged by the failure or neglect of the Contractor to purchase or maintain insurance as described above, without so notifying the Principal Representative , then the Contractor shall bear all reasonable costs properly attributable thereto. ADDITIONAL INSURANCE REQUIREMENTS 1. All insurers must be licensed or approved to do business within the State of Colorado, and unless otherwise specified, all policies must be written on a per occurrence basis. 2. Contractor’s insurance carrier should possess a minimum A.M. Best’s Insurance Guide rating of A- VI. 3. On insurance policies where the Principal Representative are named as additional insureds, the Principal Representative shall be additional insureds to the full limits of liability purchased by the Contractor even if those limits of liability are in excess of those required by this Contract. 4. Contractor shall furnish the Principal Representative with certificates of insurance (ACORD form or equivalent approved by the Principal Representative) as required by this Contract. The certificates for each insurance policy are to be signed by a person authorized by that insurer to bind coverage on its behalf. Page 6 of 7 5. 6. 7. 8. 9. All certificates and any required endorsements are to be received and approved by the Principal Representative before work commences. Each insurance policy required by this Contract must be in effect at or prior to commencement of work under this Contract and remain in effect for the duration of the project. Failure to maintain the insurance policies as required by this Contract or to provide evidence of renewal is a material breach of contract. Upon request by the Principal Representative, Contractor must provide a copy of the actual insurance policy effecting coverage(s) required by the contract. The Contractor’s insurance coverage shall be primary insurance and non-contributory with respect to all other available resources. The Contractor shall advise the Principal Representative in the event any general aggregate or other aggregate limits are reduced below the required per occurrence limit. At their own expense, the Contractor will reinstate the aggregate limits to comply with the minimum requirements and shall furnish to the Principal Representative a new certificate of insurance showing such coverage is in force. Provide a minimum of thirty (30) days advance written notice to the Principal Representative for cancellation, non-renewal, or material changes to policies required under the Contract (45 days for builders’ risk coverage.. Certificate Holder: The Regents of the University of Colorado, University Risk Management, 1800 Grant Street, Suite 700, Denver, CO 80203. Failure of the Contractor to fully comply with these requirements during the term of the Contract may be considered a material breach of contract and may be cause for immediate termination of the Contract at the option of the Principal Representative. The Principal Representative reserves the right to negotiate additional specific insurance requirements at the time of the contract award. Subcontractors Contractor’s certificate(s) shall include all subcontractors as additional insureds under its policies or subcontractors shall maintain separate insurance as determined by the Contractor, however, subcontractor's limits of liability shall not be less than $1,000,000 per occurrence / $2,000,000 aggregate. Non-Waiver The parties hereto understand and agree that The Principal Representative is relying on, and does not waive or intend to waive by any provision of this Contract, the monetary limitations or any other rights, immunities, and protections provided by the Colorado Governmental Immunity Act, et seq., as from time to time amended, or otherwise available to the Principal Representative or its officers, employees, agents, and volunteers. Mutual Cooperation The Principal Representative and Contractor shall cooperate with each other in the collection of any insurance proceeds which may be payable in the event of any loss, including the execution and delivery of any proof of loss or other actions required to effect recovery. Revised 8-30-11 Page 7 of 7 STATE OF COLORADO OFFICE OF THE STATE ARCHITECT STATE BUILDINGS PROGRAM THE GENERAL CONDITIONS OF THE CONTRACTOR’S DESIGN/BID/BUILD (D/B/B) AGREEMENT (STATE FORM SC-6.23) SC-6.23 Rev. 7/2015 STATE OF COLORADO OFFICE OF THE STATE ARCHITECT STATE BUILDINGS PROGRAM THE GENERAL CONDITIONS OF THE CONTRACTOR’S DESIGN/BID/BUILD AGREEMENT (STATE FORM SC-6.23) TABLE OF CONTENTS……………………………………………………………………………………………………..Page THE CONTRACT ARTICLE 1. DEFINITIONS……………………………….……………………..…………..……………...…….…………. 1 A. CONTRACT DOCUMENTS……….…………….……………………………………………….….……...... 1 B. DEFINITIONS OF WORDS AND TERMS USED…………………….………………………….…….……1 ARTICLE 2. EXECUTION, CORRELATIONS, INTENT OF DOCUMENTS, COMMUNICATIONS AND COOPERATION….…………………………………………………………….……..……………..……...... 4 A. EXECUTION………………………………………………………………….….………………..………...…. 4 B. CORRELATION……………………………………………………………………………….……..……...….4 C. INTENT OF DOCUMENTS…………….……………………………………………….……………….….… 4 D. PARTNERING, COMMUNICATIONS AND COOPERATION…………………………………….….…… 5 ARTICLE 3. COPIES FURNISHED……………………………………………………….……..…………………….….... 6 ARTICLE 4. OWNERSHIP OF DRAWINGS…………………………………………….…..……………………............. 6 THE ARCHITECT ARTICLE 5. ARCHITECT/ENGINEER’S STATUS……………….……………………..……………….…….………….6 ARTICLE 6. ARCHITECT/ENGINEER DECISIONS AND JUDGMENTS……….………..………………………….... 6 A. DECISIONS………………………….…………………………………………………………….……..…….. 6 B. JUDGMENTS…………………………………..………………………………………………….…………....6 C. ACCESS TO WORK…………………….………………………………………………………….…………. 7 D. INSPECTION………………………………………..………………………………………………….….…... 7 THE CONTRACTOR ARTICLE 7. CONTRACTOR’S SUPERINTENDENCE AND SUPERVISION….……….…..………………..…......... 7 ARTICLE 8. MATERIALS AND EMPLOYEES….………………………………………….…………………….….…….8 ARTICLE 9. SURVEYS, PERMITS, LAWS, TAXES AND REGULATIONS……………...…………………..….……. 8 A. SURVEYS………………………………………………………..………………………………………….…..8 B. PERMITS AND LICENSES……………..………………………………………………………………....…. 8 C. TAXES……………………………………………….…………………………………………………….….… 9 D. LAWS AND REGULATIONS………….…………………….…………………………………………….….. 9 ARTICLE 10. PROTECTION OF WORK AND PROPERTY……………..……………………………………………….. 9 A. GENERAL PROVISIONS………………………….……………………………………………………..…… 9 B. SAFETY PRECAUTIONS…………………….…………….………………………………………………… 10 C. EMERGENCIES…………………..…………………………………………………………………………… 10 ARTICLE 11. DRAWINGS AND SPECIFICATIONS ON THE WORK……………..….….……………………..............10 ARTICLE 12. REQUESTS FOR INFORMATION AND SCHEDULES…………..………….…………………………… 11 A. REQUESTS FOR INFORMATION……………..…………………………….…………………………….... 11 B. SCHEDULES…………………………………………….…………………..…………………………..….…. 11 ARTICLE 13. SHOP DRAWINGS, PRODUCT DATA AND SAMPLES……..………………..….…….……...………... 13 A. SUBMITTAL PROCESS………………………………………………..……….………………………..…... 13 B. FABRICATION AND ORDERING……………..………………………………….……………………..…... 13 C. DEVIATIONS FROM DRAWINGS OR SPECIFICATIONS……………..……….……………………...... 14 D. CONTRACTOR REPRESENTATIONS……………………………….…………..…….…………………... 14 ARTICLE 14. SAMPLES AND TESTING…………………………………………………..…….…………………............ 14 A. SAMPLES………………………………………………………………………………………..…………..…. 14 B. TESTING – GENERAL…….…………..…………………………………………………………………....... 14 C. TESTING – CONCRETE AND SOILS………….…………………………………………………………… 14 i SC-6.23 Rev. 7/2015 D. ARTICLE 15. A. B. C. D. ARTICLE 16. ARTICLE 17. ARTICLE 18. ARTICLE 19. ARTICLE 20. ARTICLE 21. A. B. C. ARTICLE 22. ARTICLE 23. A. B. C. D. E. F. G. ARTICLE 24. ARTICLE 25. A. B. C. D. E. F. G. H. ARTICLE 26. ARTICLE 27. ARTICLE 28. ARTICLE 29. ARTICLE 30. TESTING – OTHER………….………………………………..………………………………………….…… 15 SUBCONTRACTS………….…………………………………………………..…..………….…….………... 15 CONTRACT PERFORMANCE OUTSIDE THE UNITED STATES OR COLORADO…….….………… 15 SUBCONTRACTOR LIST…………..………………………………………………………………..…..…... 15 SUBCONTRACTOR SUBSTITUTIONS…..…………………….……………………………………….…. 15 CONTRACTOR RESPONSIBILITIES………………………………………………………………………. 15 RELATIONS OF CONTRACTOR AND SUBCONTRACTOR………………..…………………….......... 16 MUTUAL RESPONSIBILITY OF CONTRACTORS….………………………..……………………..........16 SEPARATE CONTRACTS………………..……………………………………..……………………...........16 USE OF PREMISES……………………………………..……………………………………………............ 16 CUTTING, FITTING OR PATCHING…………………..………………………………………..…….......... 17 UTILITIES………………………………….…………..…………………………….………………..……...... 17 TEMPORARY UTILITIES…………………………………………..……………………………….………… 17 PROTECTION OF EXISTING UTILITIES…………..…………………………………………………..…... 17 CROSSING OF UTILITIES……………………………………….……………………………………….….. 17 UNSUITABLE CONDITIONS……………………..………………………………………………………….. 17 TEMPORARY FACILITIES………………………..……………………………………………………......... 17 OFFICE FACILITIES………………………………………………………..……………………………..….. 17 TEMPORARY HEAT………………………………..…………………………………….………………..…. 17 WEATHER PROTECTION………………………………………………………………………………….… 18 DUST PARTITIONS……………………………………..……………………………….……………………. 18 BENCH MARKS…………………………………………………..……………………….…………………... 18 SIGN…………………………………………………………………………..………….……………………... 18 SANITARY PROVISION…….…………………..…………………………………….……………………… 18 CLEANING UP………..……………………………….…………………………..…………………….......... 18 INSURANCE…………..……………..………………………………………………….……………….......... 18 GENERAL………….………….………………......................................................................................... 18 COMMERCIAL GENERAL LIABILITY INSURANCE (CGL)…….………………………….…………….. 19 AUTOMOBILE INSURANCE……………………………………………………………………………….. 19 WORKERS COMPENSATIONS INSURANCE………………..……………………..…….…………..…... 19 UMBRELLA LIABILITY INSURANCE………………………………………………………………….…..... 20 BUILDER’S RISK INSURANCE……………………………………………………………………………… 20 POLLUTION LIABILITY INSURANCE………………………………………………………………………. 21 ADDITIONAL MISCELLANEOUS INSURANCE PROVISIONS………………………………….……..... 21 CONTRACTOR’S PERFORMANCE AND PAYMENT BONDS………..………….……….………........ 21 LABOR AND WAGES………………………………………………..…………….………..……………….. 22 ROYALTIES AND PATENTS…………………………………………..…………………..………….…….. 22 ASSIGNMENT…………………………………………………………..……………………………….…….. 22 CORRECTION OF WORK BEFORE ACCEPTANCE………………..……………………...…….……… 22 PAYMENT AND COMPENSATION ARTICLE 31. APPLICATIONS FOR PAYMENTS……………….…………..……………………………...……………...23 A. CONTRACTOR’S SUBMITTALS…………………………..……………..……………………..…………... 23 B. ARCHITECT/ENGINEER CERTIFICATION………………………….……………..………..…………….. 24 C. RETAINAGE WITHHELD………………………………………………..……..……………….……………. 24 D. RELEASE OF RETAINAGE……………………………………………..……………….……….………….. 24 ARTICLE 32. CERTIFICATES FOR PAYMENTS………………..…………………..……….……..…….….………..….. 25 ARTICLE 33. PAYMENTS WITHHELD…………………………………………………………………...……………….... 25 ARTICLE 34. DEDUCTIONS FOR UNCORRECTED WORK……………..…………………….…….……….………….26 ARTICLE 35. CHANGES IN THE WORK……………………………………………………….……………….………….. 26 A. THE VALUE OF CHANGED WORK…………………………….………………………………………..…. 26 B. DETAILED BREAKDOWN…………………………………………...…..…………………………………... 27 C HAZARDOUS MATERIALS…………………………………………..…………………………….………… 28 D EMERGENCY FIELD CHANGE ORDERED WORK……………………………….………….…………...29 E. APPROPRIATION LIMITATIONS – § 24-91-103.6, C.R.S., as amended………………………..……... 29 ARTICLE 36. CLAIMS………………………..…………..…………………………………………………….…….……..… 30 ii SC-6.23 Rev. 7/2015 ARTICLE 37. A. B. ARTICLE 38. ARTICLE 39. DIFFERING SITE CONDITIONS…………..…………………………….………………………….…….…. 32 NOTICE IN WRITING…………………..……………………………………………………………………... 32 LIMITATIONS……………………………………….….…………………………………………………….… 32 DELAYS AND EXTENSIONS OF TIME………………………….……….……………….………..…….... 32 NON-BINDING DISPUTE RESOLUTION – FACILITATED NEGOTIATIONS…….…..….………..….. 33 COMPLETION ARTICLE 40. RIGHT OF OCCUPANCY….………………..……………..……………………………….………………… 35 ARTICLE 41. COMPLETION, FINAL INSPECTION, ACCEPTANCE AND SETTLEMENT………..…...……………. 35 A. NOTICE OF COMPLETION…………………………………………………………………………….…..…35 B. FINAL INSPECTION…………………………………………………………….………………………..…… 35 C. NOTICE OF SUBSTANTIAL COMPLETION…………………………………………..………………….... 36 D. NOTICE OF ACCEPTANCE…………………….……………………………………………………………. 37 E. SETTLEMENT………………………………………………..…………………………………………….….. 37 ARTICLE 42. GENERAL WARRANTY AND CORRECTION OF WORK AFTER ACCEPTANCE….….………….... 38 ARTICLE 43. LIENS……………………………………………………………………………………………...……………. 38 ARTICLE 44. ONE-YEAR GUARANTEE AND SPECIAL GUARANTEES AND WARRANTIES………..…………... 39 A. ONE-YEAR GUARANTEE OF THE WORK…………………………..…………………………………..… 39 B. SPECIAL GUARANTEES AND WARRANTIES…………………………………..…………………..……. 39 ARTICLE 45. GUARANTEE INSPECTIONS AFTER COMPLETION……..……………………………….………….… 39 ARTICLE 46. TIME OF COMPLETION AND LIQUIDATED DAMAGES………..………………………….…………… 40 ARTICLE 47. DAMAGES…………………………………………………………..…………………………….…………… 41 ARTICLE 48. STATE’S RIGHT TO DO THE WORK; TEMPORARY SUSPENSION OF WORK; DELAY DAMAGES..………………………………………………………...…………………………………..……… 42 A. STATE’S RIGHT TO DO THE WORK…………………………..…………………………………………... 42 B. TEMPORARY SUSPENSION OF WORK…………………………………………………………………... 42 C. DELAY DAMAGES………………………………………………………………………..…………………... 43 ARTICLE 49. STATE’S RIGHT TO TERMINATE CONTRACT……….….………………………………………….…... 43 A. GENERAL………………………………………………………………………………………………………. 43 B. CONDITIONS AND PROCEDURES………………………………..……………………………………..… 43 C. ADDITIONAL CONDITIONS……………………………………………………..…………………………… 44 ARTICLE 50. TERMINATION FOR CONVENIENCE OF STATE………………………………………………………... 44 A. NOTICE OF TERMINATION…………………………………..……………………………………………... 44 B. PROCEDURES……………………………………………………………..………………………………..… 44 ARTICLE 51. CONTRACTOR’S RIGHT TO STOP WORK AND/OR TERMINATE CONTRACT…….….…….......... 45 ARTICLE 52. SPECIAL PROVISIONS…………………………………………………………………….…….………….. 46 A. CONTROLLER’S APPROVAL……………………..……………………………………………………..….. 46 B. FUND AVAILABILITY…………………………………………..……………………………………………… 46 C. GOVERNMENTAL IMMUNITY………………………………………………………………………………..46 D. INDEPENDENT CONTRACTOR……………………………………………………..……………………… 46 E. COMPLIANCE WITH LAW……………………….………………………………………………….……….. 46 F. CHOICE OF LAW………………………………………….………………………………………………...… 46 G. BINDING ARBITRATION PROHIBITED…………………………………………………………………….. 47 H. SOFTWARE PIRACY PROHIBITION………………………..…………………………….…………….….. 47 I. EMPLOYEE FINANCIAL INTEREST/CONFLICT OF INTEREST……………………………………….. 47 J. VENDOR OFFSET………………….…………………………………………………………………………. 47 K. PUBLIC CONTRACTS FOR SERVICES..……………………………………………………………….…. 47 L. PUBLIC CONTRACTS WITH NATURAL PERSONS……………………………………………………... 48 ARTICLE 53. MISCELLANEOUS PROVISIONS………………….………………….…………………………...……….. 48 A. CONSTRUCTION OF LANGUAGE………………………………………..………………………………… 48 B. SEVERABILITY…………………………………..………………………………………………….....……… 48 C. SECTION HEADINGS………………………………………….…………………………………….……….. 48 D. AUTHORITY……………………………………………………………….…………………………………... 48 E. INTEGRATION OF UNDERSTANDING………………….…………………………………………………. 48 F. VENUE………………………………………………………………….………………………………………. 48 G. NO THIRD PARTY BENEFICIARIES…………………………………………..…………………………… 48 iii SC-6.23 Rev. 7/2015 H. I. J. K. WAIVER……………………………………………………………..………………………………………..… 48 INDEMNIFICATION……………………………………………………………………………………….……49 STATEWIDE CONTRACT MANAGEMENT SYSTEM………………………………………………….…. 49 CORA DISCLOSURE……………………………………………………………………………...……….…. 49 iv SC-6.23 Rev. 7/2015 STATE OF COLORADO OFFICE OF THE STATE ARCHITECT STATE BUILDINGS PROGRAM THE GENERAL CONDITIONS OF THE CONTRACTOR’S DESIGN/BID/BUILD AGREEMENT (STATE FORM SC-6.23) ARTICLE 1. DEFINITIONS A. CONTRACT DOCUMENTS The Contract Documents consist of the following some of which are procedural documents used in the administration and performance of the Agreement: 1. 2. 3. 4. 5. 6. 7. 8. 9. 10. 11. 12. 13. 14. 15. 16. 17. 18. 19. 20. 21. 22. 23. B. Contractor’s Design/Bid/Build Agreement; (SC-6.21); Performance Bond (SC-6.22) and Labor and Material Payment Bond (SC-6.221); General Conditions of the Contractor’s Design/Bid/Build Agreement (SC- 6.23) and if applicable, Supplementary General Conditions; Detailed Specification Requirements, including all addenda issued prior to the opening of the bids; and, Drawings, including all addenda issued prior to the opening of the bids. Change Orders (SC-6.31) and Amendments (SC-6.0), if any, when properly executed. Authorization to Bid (SBP-6.10) Information for Bidders (SBP-6.12); Bid (SBP-6.13); Bid Bond (SBP-6.14); Notice of Award (SBP-6.15); Builder’s risk insurance certificates of insurance (ACORD 25-S); Liability and Workers’ compensation certificates of insurance; Notice to Proceed (Design/Bid/Build) (SBP-6.26); Notice of Approval of Occupancy/Use (SBP-01); Notice of Partial Substantial Completion (SBP-071); Notice of Substantial Completion (SBP-07); Notice of Partial Final Acceptance (SC-6.27); Notice of Final Acceptance (SBP-6.271); Notice of Partial Contractor's Settlement (SC-7.3); Notice of Contractor’s Settlement (SBP-7.31); Application and Certificate for Contractor’s Payment (SBP-7.2); Other procedural and reporting documents or forms referred to in the General Conditions, the Supplementary General Conditions, the Specifications or required by the State Buildings Program or the Principal Representative, including but not necessarily limited to PreAcceptance Check List (SBP-05) and the Building Inspection Record (SBP-BIR). A list of the current standard State Buildings Program forms applicable to this Contract may be obtained from the Principal Representative on request. DEFINITIONS OF WORDS AND TERMS USED 1. AGREEMENT. The term “Agreement” shall mean the written agreement entered into by the State of Colorado acting by and through the Principal Representative and the Contractor for the performance of the Work and payment therefore, on State Form SC-6.21. The term Agreement when used without reference to State Form SC-6.21 may also refer to the entirety of the parties’ agreement to perform the Work described in the Contract Documents or reasonably inferable there from. The term “Contract” shall be interchangeable with this latter meaning of the term Agreement 2. ARCHITECT/ENGINEER. The term “Architect/Engineer” shall mean either the architect of record or the engineer of record under contract to the State of Colorado for the Project identified in the Contract Documents. Page 1 of 49 SC-6.23 Rev. 7/2015 3. 4. 5. 6. 7. 8. 9. 10. 11. 12. CHANGE ORDER. The term “Change Order” means a written order directing the Contractor to make changes in the Work, in accordance with Article 35A, The Value of Changed Work. COLORADO LABOR. The term “Colorado labor”, as provided in C.R.S. § 8-17-101(2)(a), as amended, means any person who is a resident of the state of Colorado, at the time of the public Works project, without discrimination as to race, color, creed, sex, sexual orientation, marital status, national origin, ancestry, age, or religion except when sex or age is a bona fide occupational qualification. A resident of the state of Colorado is a person who can provide a valid Colorado driver’s license, a valid Colorado state-issued photo identification, or documentation that he or she has resided in Colorado for the last thirty days. CONTRACTOR. The word “Contractor” shall mean the person, company, firm, corporation or other legal entity entering into a contract with the State of Colorado acting by and through the Principal Representative DAYS. The term “days” whether singular or plural shall mean calendar days unless expressly stated otherwise. Where the term “business days” is used it shall mean business days of the State of Colorado. DRAWINGS. The term “Drawings” shall mean all drawings approved by appropriate State officials which have been prepared by the Architect/Engineer showing the Work to be done, except that where a list of drawings is specifically enumerated in the Supplementary General Conditions or division 1 of the Specifications, the term shall mean the drawings so enumerated, including all addenda drawings. EMERGENCY FIELD CHANGE ORDER. The term “Emergency Field Change Order” shall mean a written change order for extra Work or a change in the Work necessitated by an emergency as defined in Article 35C executed on State form SC 6.31 and identified as an Emergency Field Change Order. The use of such orders is limited to emergencies and to the amounts shown in Article 35C. FINAL ACCEPTANCE. The terms “final acceptance” or “finally complete” mean the stage in the progress of the Work, after substantial completion, when all remaining items of Work have been completed, all requirements of the Contract Documents are satisfied and the Notice of Acceptance can be issued. Discrete physical portions of the Project may be separately and partially deemed finally complete at the discretion of the Principal Representative when that portion of the Project reaches such stage of completion and a partial Notice of Acceptance can be issued. FIXED LIMIT OF CONSTRUCTION COST. The term “Fixed Limit of Construction Cost” shall set forth a dollar amount available for the total Construction Cost of all elements of the Work as specified by the Principal Representative. NOTICE. The term “Notice” shall mean any communication in writing from either contracting party to the other by such means of delivery that receipt cannot properly be denied. Notice shall be provided to the person identified to receive it in Article 7.5 (Contractor’s Design/Bid/Build Agreement SC-6.21), Notice Identification, or to such other person as either party identifies in writing to receive Notice. Notice by facsimile transmission where proper transmission is evidence shall be adequate where facsimile numbers are included in Article 7.5 (Contractor’s Design/Bid/Build Agreement SC-6.21). Notwithstanding an email delivery or return receipt, email Notice shall not be adequate. Acknowledgment of receipt of a voice message shall not be deemed to waive the requirement that Notice, where required, shall be in writing. OCCUPANCY. The term “Occupancy” means occupancy taken by the State as Owner after the Date of Substantial Completion at a time when a building or other discrete physical portion of the Project is used for the purpose intended. The Date of Occupancy shall be the date of such first use, but shall not be prior to the date of execution of the Notice of Approval of Occupancy/Use. Prior to the date of execution of a Notice of Approval of Occupancy/Use, the state shall have no right to occupy and the project may not be considered safe for occupancy for the intended use. Page 2 of 49 SC-6.23 Rev. 7/2015 13. 14. 15. 16. 17. 18. 19. 20. 21. 22. 23. 24. 25. OWNER. The term “Owner” shall mean the Principal Representative. PRINCIPAL REPRESENTATIVE. The term “Principal Representative ” shall be defined, as provided in § 24-30-1301(11), C.R.S., as the governing board of a state department, institution, or agency; or if there is no governing board, then the executive head of a state department, institution, or agency, as designated by the governor or the general assembly and as specifically identified in the Contract Documents, or shall have such other meaning as the term may otherwise be given in § 24-30-1301(11), C.R.S., as amended. The Principal Representative may delegate authority. The Contractor shall have the right to inquire regarding the delegated authority of any of the Principal Representative’s representatives on the project and shall be provided with a response in writing when requested. PRODUCT DATA. The term “Product Data ” shall mean all submittals in the form of printed manufacturer’s literature, manufacturer’s specifications, and catalog cuts. PROJECT. The "Project" is the total construction of which the Work performed under the Contract Documents is a part, and may include construction by the Principal Representative or by separate contractors. REASONABLY INFERABLE. The phrase “reasonably inferable” means that if an item or system is either shown or specified, all material and equipment normally furnished with such items or systems and needed to make a complete installation shall be provided whether mentioned or not, omitting only such parts as are specifically excepted, and shall include only components which the Contractor could reasonably anticipate based on his or her skill and knowledge using an objective, industry standard, not a subjective standard. This term takes into consideration the normal understanding that not every detail is to be given on the Drawings and Specifications If there is a difference of opinion, the Principal Representative shall make the determination as to the standards of what reasonably inferable. SAMPLES. The term “Samples” shall mean examples of materials or Work provided to establish the standard by which the Work will be judged. SBP. The term "SBP" means "State Buildings", which is used in connection with labeling applicable State form documents (e.g., "SBP-01" is the form number for Notice of Approval of Occupancy/Use). SC. The term "SC" means "State Contract" which is used in connection with labeling applicable State form documents (e.g. "SC 6.23" is the State form number for these General Conditions of the Contractor’s Design/Bid/Build Agreement). SCHEDULE OF VALUES. The term “Schedule of Values” is defined as the itemized listing of description of the Work by Division and Section of the Specifications. The format shall be the same as Form SC-7.2. Included shall be the material costs, and the labor and other costs plus the sum of both. SHOP DRAWINGS. The term “Shop Drawings” shall mean any and all detailed drawings prepared and submitted by Contractor, Subcontractor at any tier, vendors or manufacturers providing the products and equipment specified on the Drawings or called for in the Specifications. SPECIFICATIONS. The term “Specifications” shall mean the requirements of the CSI divisions of the project manual prepared by the Architect/Engineer describing the Work to be accomplished. STATE BUILDINGS PROGRAM. Shall refer to the Office of the State Architect within the Department of Personnel & Administration of Colorado State government responsible for project administration, review, approval and coordination of plans, construction procurement policy, contractual procedures, and code compliance and inspection of all buildings, public Works and improvements erected for state purposes; except public roads and highways and projects under the supervision of the division of wildlife and the division of parks and outdoor recreation as provided in § 24-30-1301, et seq, C.R.S. The term State Buildings Program shall also mean that individual within a State Department agency or institution, including institutions of higher education, who has signed an agreement accepting delegation to perform all or part of the responsibilities and functions of State Buildings Program. SUBCONTRACTOR. The term “Subcontractor” shall mean a person, firm or corporation supplying labor, materials, equipment and/or Services for Work at the site of the Project for, and under separate contract or agreement with the Contractor. Page 3 of 49 SC-6.23 Rev. 7/2015 26. 27. 28. 29. 30. 31. SUBMITTALS. The term “submittals” means drawings, lists, tables, documents and samples prepared by the Contractor to facilitate the progress of the Work as required by these General Conditions or the Drawings and Specifications. They consist of Shop Drawings, Product Data, Samples, and various administrative support documents including but not limited to lists of subcontractors, construction progress schedules, schedules of values, applications for payment, inspection and test results, requests for information, various document logs, and as-built drawings. Submittals are required by the Contract Documents, but except to the extent expressly specified otherwise are not themselves a part of the Contract Documents. SUBSTANTIAL COMPLETION. The terms “substantial completion” or “substantially complete” mean the stage in the progress of the Work when the construction is sufficiently complete, in accordance with the Contract Documents as modified by any Change Orders, so that the Work, or at the discretion of the Principal Representative, any designated portion thereof, is available for its intended use by the Principal Representative and a Notice of Substantial Completion can be issued. Portions of the Project may, at the discretion of the Principal Representative, be designated as substantially complete. SUPPLIER. The term "Supplier" shall mean any manufacturer, fabricator, distributor, material man or vendor. SURETY. The term “Surety” shall mean the company providing the labor and material payment and performance bonds for the Contractor as obligor. VALUE ENGINEERING. “Value Engineering” or “VE” is defined as an analysis and comparison of cost versus value of building materials, equipment, and systems. VE considers the initial cost of construction, coupled with the estimated cost of maintenance, energy use, life expectancy and replacement cost. VE related to this Project shall include the analysis and comparison of building elements in an effort to reduce overall Project costs, while maintaining or enhancing the quality of the design intent, whenever possible. WORK. The term “Work” shall mean all or part of the labor, materials, equipment, and other services required by the Contract Documents or otherwise required to be provided by the Contractor to meet the Contractor’s obligations under the Contract. ARTICLE 2. A. EXECUTION, CORRELATION, INTENT OF DOCUMENTS, COMMUNICATION AND COOPERATION EXECUTION The Contractor, within ten (10) days from the date of Notice of Award, will be required to: 1. Execute the Agreement, State Form SC-6.21; 2. Furnish fully executed Performance and Labor and Material Payment Bonds on State Form s SC-6.22 and SC-6.221; and 3. Furnish certificates of insurance evidencing all required insurance on standard Acord forms designed for such purpose. 4. Furnish certified copies of any insurance policies requested by the Principal Representative. B. CORRELATION By execution of the Agreement the Contractor represents that the Contractor has visited the site, has become familiar with local conditions and local requirements under which the Work is to be performed, including the building code programs of the State Buildings Program as implemented by the Principal Representative, and has correlated personal observations with the requirements of the Contract Documents. C. INTENT OF DOCUMENTS The Contract Documents are complementary, and what is called for by any one document shall be as binding as if called for by all. The intention of the documents is to include all labor, materials, equipment and transportation necessary for the proper execution of the Work. Words describing materials or Work which have a well-known technical or trade meaning shall be held to refer to such recognized standards. In any event, if any error exists, or appears to exist, in the requirements of the Drawings or Specifications, or if any disagreement exists as to such requirements, the Contractor shall have the Page 4 of 49 SC-6.23 Rev. 7/2015 same explained or adjusted by the Architect/Engineer before proceeding with the Work in question. In the event of the Contractor’s failure to give prior written Notice of any such errors or disagreements of which the Contractor or the Subcontractors at any tier are aware, the Contractor shall, at no additional cost to the Principal Representative, make good any damage to, or defect in, Work which is caused by such omission. Where a conflict occurs between or within standards, Specifications or Drawings, which is not resolved by reference to the precedence between the Contract Documents, the more stringent or higher quality requirements shall apply so long as such more stringent or higher quality requirements are reasonably inferable. The Architect/Engineer shall decide which requirements will provide the best installation. With the exception noted in the following paragraph, the precedence of the Contract Documents is in the following sequence: 1. 2. 3. 4. The Agreement (SC-6.21); The Supplementary General Conditions, if any; The General Conditions (SC-6.23); and Drawings and Specifications, all as modified by any addenda. Change Orders and Amendments, if any, to the Contract Documents take precedence over the original Contract Documents. Notwithstanding the foregoing order of precedence, the Special Provisions of Article 52 of the General Conditions, Special Provisions, shall take precedence, rule and control over all other provisions of the Contract Documents. Unless the context otherwise requires, form numbers in this document are for convenience only. In the event of any conflict between the form required by name or context and the form required by number, the form required by name or context shall control. The Contractor may obtain State forms from the Principal Representative upon request. D. PARTNERING, COMMUNICATIONS AND COOPERATION In recognition of the fact that conflicts, disagreements and disputes often arise during the performance of construction contracts, the Contractor and the Principal Representative aspire to encourage a relationship of open communication and cooperation between the employees and personnel of both, in which the objectives of the Contract may be better achieved and issues resolved in a more fully informed atmosphere. The Contractor and the Principal Representative each agree to assign an individual who shall be fully authorized to negotiate and implement a voluntary partnering plan for the purpose of facilitating open communications between them. Within thirty days (30) of the Notice to Proceed, the assigned individuals shall meet to discuss development of an informal agreement to accomplish these goals. The assigned individuals shall endeavor to reach an informal agreement, but shall have no such obligation. Any plans these parties voluntarily agree to implement shall result in no change to the contract amount, and no costs associated with such plan or its development shall be recoverable under any contract clause. In addition, no plan developed to facilitate open communication and cooperation shall alter, amend or waive any of the rights or duties of either party under the Contract unless and except by written Amendment to the Contract, nor shall anything in this clause or any subsequently developed partnering plan be deemed to create fiduciary duties between the parties unless expressly agreed in a written Amendment to the Contract. It is also recognized that projects with relatively low contract values may not justify the expense or special efforts required. In the case of small projects with an initial Contract value under $500,000, the requirements of the preceding paragraph shall not apply. Page 5 of 49 SC-6.23 Rev. 7/2015 ARTICLE 3. COPIES FURNISHED The Contractor will be furnished, free of charge, the number of copies of Drawings and Specifications as specified in the Contract Documents, or if no number is specified, all copies reasonably necessary for the execution of the Work. ARTICLE 4. OWNERSHIP OF DRAWINGS Drawings or Specifications, or copies of either, furnished by the Architect/Engineer, are not to be used on any other Work. At the completion of the Work, at the written request of the Architect/Engineer, the Contractor shall endeavor to return all Drawings and Specifications. The Contractor may retain the Contractor’s Contract Document set, copies of Drawings and Specifications used to contract with others for any portion of the Work and a marked up set of as-built drawings. ARTICLE 5. ARCHITECT/ENGINEER’S STATUS The Architect/Engineer is the representative of the Principal Representative for purposes of administration of the Contract, as provided in the Contract Documents and the Agreement. In case of termination of employment or the death of the Architect/Engineer, the Principal Representative will appoint a capable Architect/Engineer against whom the Contractor makes no reasonable objection, whose status under the Contract shall be the same as that of the former Architect/Engineer. ARTICLE 6. ARCHITECT/ENGINEER DECISIONS AND JUDGMENTS, ACCESS TO WORK AND INSPECTION A. DECISIONS The Architect/Engineer shall, within a reasonable time, make decisions on all matters relating to the execution and progress of the Work or the interpretation of the Contract Documents, and in the exercise of due diligence shall be reasonably available to the Contractor to timely interpret and make decisions with respect to questions relating to the design or concerning the Contract Documents. B. JUDGMENTS The Architect/Engineer is, in the first instance, the judge of the performance required by the Contract Documents as it relates to compliance with the Drawings and Specifications and quality of Workmanship and materials. The Architect/Engineer shall make judgments regarding whether directed Work is extra or outside the scope of Work required by the Contract Documents at the time such direction is first given. If, in the Contractor’s judgment, any performance directed by the Architect/Engineer is not required by the Contract Documents or if the Architect/Engineer does not make the judgment required, it shall be a condition precedent to the filing of any claim for additional cost related to such directed Work that the Contractor, before performing such Work, shall first obtain in writing, the Architect/Engineer’s written decision that such directed Work is included in the performance required by the Contract Documents. If the Architect/Engineer’s direction to perform the Work does not state that the Work is within the performance required by the Contract Documents, the Contractor shall, in writing, request the Architect/Engineer to advise in writing whether the directed Work will be considered extra Work or Work included in the performance required by the Contract Documents. The Architect/Engineer shall respond to any such written request for such a decision within three (3) business days and if no response is provided, or if the Architect/Engineer’s written decision is to the effect that the Work is included in the performance required by the Contract Documents, the Contractor may file with the Principal Representative and the Architect/Engineer a Notice of claim in accordance with Article 36, Claims. Whether or not a Notice of claim is filed, the Contractor shall proceed with the ordered Work. Disagreement with the decision of the Architect/Engineer shall not be grounds for the Contractor to refuse to perform the Work directed or to suspend or terminate performance. Page 6 of 49 SC-6.23 Rev. 7/2015 C. ACCESS TO WORK The Architect/Engineer, the Principal Representative and representatives of State Buildings Program shall at all times have access to the Work. The Contractor shall provide proper facilities for such access and for their observations or inspection of the Work. D. INSPECTION The Architect/Engineer has agreed to make, or that structural, mechanical, electrical engineers or other consultants will make, periodic visits to the site to generally observe the progress and quality of the Work to determine in general if the Work is proceeding in accordance with the Contract Documents. Observation may extend to all or any part of the Work and to the preparation, fabrication or manufacture of materials. Without in any way meaning to be exclusive or to limit the responsibilities of the Architect/Engineer or the Contractor, the Architect/Engineer has agreed to observe, among other aspects of the Work, the following for compliance with the Contract Documents: 1. 2. 2. 3. 4. 5. 6. 7. 8. 9. Compaction testing reports based upon the findings and recommendations of the Principal Representative’s testing consultant; Bearing surfaces of excavations before concrete is placed based upon the findings and recommendations of the Principal Representative’s soils engineering consultant; Reinforcing steel after installation and before concrete is poured; Structural concrete; Laboratory reports on all concrete testing based upon the findings and recommendations of the Principal Representative’s testing consultant; Structural steel during and after erection and prior to its being covered or enclosed; Steel welding; Principal Representative will furnish steel welding inspection consultant/agency if required or necessary for the project; Mechanical and plumbing Work following its installation and prior to its being covered or enclosed; Electrical Work following its installation and prior to its being covered or enclosed; and Any special or quality control testing required in the Contract Documents provided by the Principal Representative’s testing consultant. If the Specifications, the Architect/Engineer’s instructions, laws, ordinances of any public authority require any Work to be specifically tested or approved, the Contractor shall give the Principal Representative, Architect/Engineer and appropriate testing agency (if necessary) timely notice of its readiness for observation by the Architect/Engineer or inspection by another authority, and if the inspection is by another authority, of the date fixed for such inspection, required certificates of inspection being secured by the Contractor. The Contractor shall give all required Notices to the Principal Representative or his or her designee for inspections required for the building inspection program. It shall be the responsibility of the Contractor to determine the Notice required by the State pursuant to Building Inspection Record for the Project, according to State form SBP-B.I.R., or the equivalent form required by the Principal Representative as approved by the State Buildings Program. If any such Work is covered up without approval or consent of the Architect/Engineer or prior to any building code inspection, it must, if required by the Architect/Engineer, the Principal Representative or the State Buildings Program, be uncovered for examination, at the Contractor’s expense. If such Work is found to be not in accordance with the Contract Documents, the Contractor shall pay such costs, unless he or she shall show that the defect in the Work was caused by another contractor engaged by the Principal Representative. In addition, examination of questioned Work may be ordered, and if so ordered, the Work must be uncovered by the Contractor. If such Work be found in accordance with the Contract Documents, the Contractor shall be reimbursed the cost of examination and replacement. ARTICLE 7. CONTRACTOR’S SUPERINTENDENCE AND SUPERVISION The Contractor shall employ, and keep present (as applicable) on the Project during its progress, a competent project manager as satisfactory to the Principal Representative. The project manager shall not be changed except with the consent of the Principal Representative, unless the project manager proves to Page 7 of 49 SC-6.23 Rev. 7/2015 be unsatisfactory to the Contractor and ceases to be in his or her employ. The project manager shall represent the Contractor for the Project, and in the absence of the Contractor, all directions given to the project manager shall be as binding as if given to the Contractor. Directions received by the project manager shall be documented by the project manager and communicated in writing with the Contractor. The Contractor shall employ, and keep present on the Project during its progress, a competent superintendent and any necessary assistants, all satisfactory to the Architect/Engineer and the Principal Representative. The superintendent shall not be changed except with the consent of the Architect/Engineer and the Principal Representative, unless the superintendent proves to be unsatisfactory to the Project Manager/Contractor and ceases to be in his or her employ. The superintendent shall represent the Project Manager/Contractor in his or her absence and all directions given to the superintendent shall be as binding as if given to the Project Manager/Contractor. Directions received by the superintendent shall be documented by the superintendent and confirmed in writing with the Project Manager/Contractor. The Contractor shall give efficient supervision to the Work, using his or her best skill and attention. He or she shall carefully study and compare all Drawings, Specifications and other written instructions and shall without delay report any error, inconsistency or omission which he or she may discover in writing to the Architect/Engineer. The Contractor shall not be liable to the Principal Representative for damage to the extent it results from errors or deficiencies in the Contract Documents or other instructions by the Architect/Engineer, unless the Contractor knew or had reason to know, that damage would result by proceeding and the Contractor fails to so advise the Architect/Engineer. The superintendent shall see that the Work is carried out in accordance with the Contract Documents and in a uniform, thorough and first-class manner in every respect. The Contractor’s superintendent shall establish all lines, levels, and marks necessary to facilitate the operations of all concerned in the Contractor’s Work. The Contractor shall lay out all Work in a manner satisfactory to the Architect/Engineer, making permanent records of all lines and levels required for excavation, grading, foundations, and for all other parts of the Work. ARTICLE 8. MATERIALS AND EMPLOYEES Unless otherwise stipulated, the Contractor shall provide and pay for all materials, labor, water, tools, equipment, light, power, transportation and other facilities necessary for the execution and completion of the Work. Unless otherwise specified, all materials shall be new and both workmanship and materials shall be first class and of uniform quality. The Contractor shall, if required, furnish satisfactory evidence as to the kind and quality of materials. The Contractor is fully responsible for all acts and omissions of the Contractor’s employees and shall at all times enforce strict discipline and good order among employees on the site. The Contractor shall not employ on the Work any person reasonably deemed unfit by the Principal Representative or anyone not skilled in the Work assigned to him. ARTICLE 9. SURVEYS, PERMITS, LAWS, TAXES AND REGULATIONS A. SURVEYS The Principal Representative shall furnish all surveys, property lines and bench marks deemed necessary by the Architect/Engineer, unless otherwise specified. B. PERMITS AND LICENSES Permits and licenses necessary for the prosecution of the Work shall be secured and paid for by the Contractor. Unless otherwise specified in the Specifications, no local municipal or county building permit shall be required. However, State Buildings Program requires each Principal Representative to administer a building code inspection program, the implementation of which may vary at each agency or institution of the State. The Contractors’ employees shall become personally familiar with these local conditions and requirements and shall fully comply with such requirements. State electrical and Page 8 of 49 SC-6.23 Rev. 7/2015 plumbing permits are required, unless the requirement to obtain such permits is altered by State Building’s Programs. The Contractor shall obtain and pay for such permits. Easements for permanent structures or permanent changes in existing facilities shall be secured and paid for by the Principal Representative, unless otherwise specified. C. TAXES 1. Refund of Sales and Use Taxes The Contractor shall pay all local taxes required to be paid, including but not necessarily limited to all sales and use taxes. If requested by the Principal Representative prior to issuance of the Notice to Proceed or directed in the Supplementary General Conditions or the Specifications, the Contractor shall maintain records of such payments in respect to the Work, which shall be separate and distinct from all other records maintained by the Contractor, and the Contractor shall furnish such data as may be necessary to enable the State of Colorado, acting by and through the Principal Representative, to obtain any refunds of such taxes which may be available under the laws, ordinances, rules or regulations applicable to such taxes. When so requested or directed, the Contractor shall require Subcontractors at all tiers to pay all local sales and use taxes required to be paid and to maintain records and furnish the Contractor with such data as may be necessary to obtain refunds of the taxes paid by such Subcontractors. No State sales and use taxes are to be paid on material to be used in this Project. On application by the purchaser or seller, the Department of Revenue shall issue to a Contractor or to a Subcontractor at any tier, a certificate or certificates of exemption per § 39-26-114(1)(d), C.R.S., and § 39-26-203, C.R.S. 2. D. Federal Taxes The Contractor shall exclude the amount of any applicable federal excise or manufacturers’ taxes from the proposal. The Principal Representative will furnish the Contractor, on request exemption certificates. LAWS AND REGULATIONS The Contractor shall give all notices and comply with all laws, ordinances, rules and regulations bearing on the conduct of the Work as drawn or specified. If the Contractor observes that the Drawings or Specifications require Work which is at variance therewith, the Contractor shall without delay notify the Architect/Engineer in writing and any necessary changes shall be adjusted as provided in Article 35, Changes In The Work. The Contractor shall bear all costs arising from the performance of Work required by the Drawings or Specifications that the Contractor knows to be contrary to such laws, ordinances, rules or regulations, if such Work is performed without giving Notice to the Architect/Engineer. ARTICLE 10. PROTECTION OF WORK AND PROPERTY A. GENERAL PROVISIONS The Contractor shall continuously maintain adequate protection of all Work and materials, protect the property from injury or loss arising in connection with this Contract and adequately protect adjacent property as provided by law and the Contract Documents. The Contractor shall make good any damage, injury or loss, except to the extent: 1. 2. 3. B. Directly due to errors in the Contract Documents; Caused by agents or employees of the Principal Representative; and, Due to causes beyond the Contractor’s control and not to fault or negligence; provided such damage, injury or loss would not be covered by the insurance required to be carried by the Contractor; SAFETY PRECAUTIONS The Contractor shall take all necessary precautions for the safety of employees on the Project, and shall comply with all applicable provisions of federal, State and municipal safety laws and building Page 9 of 49 SC-6.23 Rev. 7/2015 codes to prevent accidents or injury to persons on, about or adjacent to the premises where the Work is being performed. He or she shall erect and properly maintain at all times, as required by the conditions and progress of the Work, all necessary safeguards for the protection of Workers and the public and shall post danger signs warning against the hazards created by such features of construction as protruding nails, hoists, well holes, elevator hatchways, scaffolding, window openings, stairways and falling materials; and he or she shall designate a responsible member of his or her organization on the Project, whose duty shall be the prevention of accidents. The name and position of any person so designated shall be reported to the Architect/Engineer by the Contractor. The Contractor shall provide all necessary bracing, shoring and tying of all structures, decks and framing to prevent any structural failure of any material which could result in damage to property or the injury or death of persons; take all precautions to insure that no part of any structure of any description is loaded beyond its carrying capacity with anything that will endanger its safety at any time during the execution of this Contract; and provide for the adequacy and safety of all scaffolding and hoisting equipment. The Contractor shall not permit open fires within the building enclosure. The Contractor shall construct and maintain all necessary temporary drainage and do all pumping necessary to keep excavations and floors, pits and trenches free of water. The Contractor shall be solely responsible for all construction means, methods, techniques, sequences and procedures, and for coordinating all portions of the Work, except as otherwise noted. The Contractor shall take due precautions when obstructing sidewalks, streets or other public ways in any manner, and shall provide, erect and maintain barricades, temporary walkways, roadways, trench covers, colored lights or danger signals and any other devices necessary or required to assure the safe passage of pedestrians and automobiles. C. EMERGENCIES In an emergency affecting the safety of life or of the Work or of adjoining property, the Contractor without special instruction or authorization from the Architect/Engineer or Principal Representative, is hereby permitted to act, at his or her discretion, to prevent such threatened loss or injury; and he or she shall so act, without appeal, if so authorized or instructed. Provided the Contractor has no responsibilities for the emergency, if the Contractor incurs additional cost not otherwise recoverable from insurance or others on account of any such emergency Work, the Contract sum shall be equitably adjusted in accordance with Article 35, Changes In The Work. ARTICLE 11. DRAWINGS AND SPECIFICATIONS ON THE WORK The Contractor shall keep on the job site one copy of the Contract Documents in good order, including current copies of all Drawings and Specifications for the Work, and any approved Shop Drawings, Product Data or Samples, and as-built drawings. As-built drawings shall be updated weekly by the Contractor and Subcontractors to reflect actual constructed conditions including dimensioned locations of underground Work and the Contractor's failure to maintain such updates may be grounds to withhold portions of payments otherwise due in accordance with Article 33, Payments Withheld. All such documents shall be available to the Architect/Engineer and representatives of the State. In addition, the Contractor shall keep on the job site one copy of all approved addenda, Change Orders and requests for information issued for the Work. The Contractor shall develop procedures to insure the currency and accuracy of as-built drawings and shall maintain on a current basis a log of requests for information and responses thereto, a Shop Drawing and Product Data submittal log, and a Sample submittal log to record the status of all necessary and required submittals. ARTICLE 12. REQUESTS FOR INFORMATION AND SCHEDULES A. REQUESTS FOR INFORMATION The Architect/Engineer shall furnish additional instructions with reasonable promptness, by means of drawings or otherwise, necessary for the proper execution of the Work. All such drawings and instructions shall be consistent with the Contract Documents and reasonably inferable there from. The Page 10 of 49 SC-6.23 Rev. 7/2015 Architect/Engineer shall determine what additional instructions or drawings are necessary for the proper execution of the Work. The Work shall be executed in conformity with such instructions and the Contractor shall do no Work without proper drawings, specifications or instructions. If the Contractor believes additional instructions, specifications or drawings are needed for the performance of any portion of the Work, the Contractor shall give Notice of such need in writing through a request for information furnished to the Architect/Engineer sufficiently in advance of the need for such additional instructions, specifications or drawings to avoid delay and to allow the Architect/Engineer a reasonable time to respond. The Contractor shall maintain a log of the requests for information and the responses provided. B. SCHEDULES 1. Submittal Schedules Prior to filing the Contractor ’s first application for payment, a schedule shall be prepared which may be preliminary to the extent required, fixing the dates for the submission and initial review of required Shop Drawings, Product Data and Samples for the beginning of manufacture and installation of materials, and for the completion of the various parts of the Work. It shall be prepared so as to cause no delay in the Work or in the Work of any other contractor. The schedule shall be subject to change from time to time in accordance with the progress of the Work, and it shall be subject to the review and approval by the Architect/Engineer. It shall fix the dates at which the various Shop Drawings Product Data and Samples will be required from the Architect/Engineer. The Architect/Engineer, after review and agreement as to the time provided for initial review, shall review and comment on the Shop Drawings, Product Data and Samples in accordance with that schedule. The schedule shall be finalized, prepared and submitted with respect to each of the elements of the Work in time to avoid delay, considering reasonable periods for review, manufacture or installation. At the time the schedule is prepared, the Contractor, the Architect/Engineer and Principal Representative shall jointly identify the Shop Drawing, Product Data and Samples, if any, which the Principal Representative shall receive simultaneously with the Architect/Engineer for the purposes of owner coordination with existing facility standards and systems. The Contractor shall furnish a copy for the Principal Representative when so requested. Transmittal of Shop Drawings and Product Data copies to the Principal Representative shall be solely for the convenience of the Principal Representative and shall neither create nor imply responsibility or duty of review by the Principal Representative. The Contractor may also, or at the direction of the Principal Representative at any time shall, prepare and maintain a schedule, which may also be preliminary and subject to change to the extent required, fixing the dates for the initial responses to requests for information or for detail drawings which will be required from the Architect/Engineer to allow the beginning of manufacture, installation of materials and for the completion of the various parts of the Work. The schedule shall be subject to review and approval by the Architect/Engineer. The Architect/Engineer shall, after review and agreement, furnish responses and detail drawings in accordance with that schedule. Any such schedule shall be prepared and approved in time to avoid delay, considering reasonable periods for review, manufacture or installation, but so long as the request for information schedule is being maintained, it shall not be deemed to transfer responsibility to the Contractor for errors or omissions in the Contract Documents where circumstances make timely review and performance impossible. The Architect/Engineer shall not unreasonably withhold approval of the Contractor’s schedules and shall inform the Contractor and the Principal Representative of the basis of any refusal to agree to the Contractor’s schedules. The Principal Representative shall attempt to resolve any disagreements. Page 11 of 49 SC-6.23 Rev. 7/2015 2. Schedule of Values Within twenty-one (21) calendar days after the date of the Notice to Proceed, the Contractor shall submit to the Architect/Engineer and Principal Representative, for approval, and to the State Buildings Program when specifically requested, a complete itemized schedule of the values of the various parts of the Work, as estimated by the Contractor, aggregating the total price. The schedule of values shall be in such detail as the Architect/Engineer or the Principal Representative shall require, prepared on forms acceptable to the Principal Representative. It shall, at a minimum, identify on a separate line each division of the Specifications including the general conditions costs to be charged to the Project. The Contractor shall revise and resubmit the schedule of values for approval when, in the opinion of the Architect/Engineer or the Principal Representative, such resubmittal is required due to changes or modifications to the Contract Documents or the Contract sum. The total cost of each line item so separately identified shall, when requested by the Architect/Engineer or the Principal Representative, be broken down into reasonable estimates of the value of: a. Material, which shall include the cost of material actually built into the Project plus any local sales or use tax paid thereon; and, b. Labor and other costs. The cost of subcontracts shall be incorporated in the Contractor’s schedule of values, and when requested by the Architect/Engineer or the Principal Representative, shall be separately shown as line items. The Architect/Engineer shall review the proposed schedules and approve it after consultation with the Principal Representative, or advise the Contractor of any required revisions within ten (10) days of its receipt. In the event no action is taken on the submittal within ten days, the Contractor may utilize the schedule of values as its submittal for payment until it is approved or until revisions are requested. When the Architect/Engineer deems it appropriate to facilitate certification of the amounts due to the Contractor, further breakdown of subcontracts, including breakdown by labor and materials, may be directed. This schedule of values, when approved, will be used in preparing Contractor’s applications for payment on State Form SC-7.2, Application for Payment. 3. Construction Schedules Within twenty-one (21) calendar days after the date of the Notice to Proceed, the Contractor shall submit to the Architect/Engineer and the Principal Representative, and to the State Buildings Program when specifically requested, on a form acceptable to them, an overall timetable of the construction schedule for the Project. Unless the Supplementary General Conditions or the Specifications allow scheduling with bar charts or other less sophisticated scheduling tools, the Contractor’s schedule shall be a critical-path method (CPM) construction schedule. The CPM schedule shall start with the date of the Notice to Proceed and include submittals activities, the various construction activities, change order Work (when applicable), close-out, testing, demonstration of equipment operation when called for in the Specifications, and acceptance. The CPM schedule shall at a minimum correlate to the schedule of values line items and shall be cost loaded if requested by the Architect/Engineer or Principal Representative. The completion time shall be the time specified in the Agreement and all Project scheduling shall allocate float utilizing the full period available for construction as specified in the Agreement on State Form SC 6.13, without indication of early completion, unless such earlier completion is approved in writing by the Principal Representative and State Building Programs. Page 12 of 49 SC-6.23 Rev. 7/2015 The time shown between the starting and completion dates of the various elements within the construction schedule shall represent one hundred per cent (100%) completion of each element. All other elements of the CPM schedule shall be as required by the Specifications. In addition, the Contractor shall submit monthly updates or more frequently, if required by the Principal Representative, updates of the construction schedule. These updates shall reflect the Contractor’s “Work in place” progress. When requested by the Architect/Engineer, the Principal Representative or the State Buildings Program, the Contractor shall revise the construction schedule to reflect changes in the schedule of values. When the testing of materials is required by the Specifications, the Contractor shall also prepare and submit to the Architect/Engineer and the Principal Representative a schedule for testing in accordance with Article 14, Samples and Testing. ARTICLE 13. SHOP DRAWINGS, PRODUCT DATA AND SAMPLES A. SUBMITTAL PROCESS The Contractor shall check and field verify all dimensions. The Contractor shall check, approve and submit to the Architect/Engineer in accordance with the schedule described in Article 12, Requests for Information and Schedules, all Shop Drawings, Product Data and Samples required by the specifications or required by the Contractor for the Work of the various trades. All Drawings and Product Data shall contain identifying nomenclature and each submittal shall be accompanied by a letter of transmittal identifying in detail all enclosures. The number of copies of Shop Drawings and Product Data to be submitted shall be as specified in the Specifications and if no number is specified then three copies shall be submitted. The Architect/Engineer shall review and comment on the Shop Drawings and Product Data within the time provided in the agreed upon schedule for conformance with information given and the design concept expressed in, or reasonably inferred from, the Contract Documents. The nature of all corrections to be made to the Shop Drawings and Product Data, if any, shall be clearly noted, and the submittals shall be returned to the Contractor for such corrections. If a change in the scope of the Work is intended by revisions requested to any Shop Drawings and Product Data, the Contractor shall be requested to prepare a change proposal in accordance with Article 35, Changes In The Work. On resubmitted Shop Drawings, Product Data or Samples, the Contractor shall direct specific attention in writing on the transmittal cover to revisions other than those corrections requested by the Architect/Engineer on any previously checked submittal. The Architect/Engineer shall promptly review and comment on, and return, the resubmitted items. The Contractor shall thereafter furnish such other copies in the form approved by the Architect/Engineer as may be needed for the prosecution of the Work. B. FABRICATION AND ORDERING Fabrication shall be started by the Contractor only after receiving approved Shop Drawings from the Architect/Engineer. Materials shall be ordered in accordance with approved Product Data. Work which is improperly fabricated, whether through incorrect Shop Drawings, faulty workmanship or materials, will not be acceptable. Page 13 of 49 SC-6.23 Rev. 7/2015 C. DEVIATIONS FROM DRAWINGS OR SPECIFICATIONS The review and comments of the Architect/Engineer of Shop Drawings, Product Data or Samples shall not relieve the Contractor from responsibility for deviations from the Drawings or Specifications, unless he or she has in writing called the attention of the Architect/Engineer to such deviations at the time of submission, nor shall it relieve the Contractor from responsibility for errors of any sort in Shop Drawings or Product Data. Review and comments on Shop Drawings or Product Data containing identified deviations from the Contract Documents shall not be the basis for a Change Order or a claim based on a change in the scope of the Work unless Notice is given to the Architect/Engineer and Principal Representative of all additional costs, time and other impacts of the identified deviation by bring it to their attention in writing at the time the submittals are made, and any subsequent change in the Contract sum or the Contract time shall be limited to cost, time and impacts so identified. D. CONTRACTOR REPRESENTATIONS By preparing, approving, and/or submitting Shop Drawings, Product Data and Samples, the Contractor represents that the Contractor has determined and verified all materials, field measurements, and field construction criteria related thereto, and has checked and co-ordinated the information contained within each submittal with the requirements of the Work, the Project and the Contract Documents and prior reviews and approvals. ARTICLE 14. SAMPLES AND TESTING A. SAMPLES The Contractor shall furnish for approval, with such promptness as to cause no delay in his or her Work or in that of any other Contractor, all Samples as directed by the Architect/Engineer. The Architect/Engineer shall check and approve such Samples, with reasonable promptness, but only for conformance with the design intent of the Contract Documents and the Project, and for compliance with any submission requirements given in the Contract Documents. B. TESTING - GENERAL The Contractor shall provide such equipment and facilities as the Architect/Engineer may require for conducting field tests and for collecting and forwarding samples to be tested. Samples themselves shall not be incorporated into the Work after approval without the permission of the Architect/Engineer. All materials or equipment proposed to be used may be tested at any time during their preparation or use. The Contractor shall furnish the required samples without charge and shall give sufficient Notice of the placing of orders to permit the testing thereof. Products may be sampled either prior to shipment or after being received at the site of the Work. Tests shall be made by an accredited testing laboratory. Except as otherwise provided in the Specifications, sampling and testing of all materials, and the laboratory methods and testing equipment, shall be in accordance with the latest standards and tentative methods of the American Society of Testing Materials (ASTM). The cost of testing which is in addition to the requirements of the Specifications shall be paid by the Contractor if so directed by the Architect/Engineer, and the Contract sum shall be adjusted accordingly by Change Order ; provided however, that whenever testing shows portions of the Work to be deficient, all costs of testing including that required to verify the adequacy of repair or replacement Work shall be the responsibility of the Contractor. C. TESTING - CONCRETE AND SOILS Unless otherwise specified or provided elsewhere in the Contract Documents, the Principal Representative will contract for and pay for the testing of concrete and for soils compaction testing through an independent laboratory or laboratories selected and approved by the Principal Representative. The Contractor shall assume the responsibility of arranging, scheduling and coordinating the concrete sample collection efforts and soils compaction efforts in an efficient and cost effective manner. Testing shall be performed in accordance with the requirements of the Specifications, and if no requirements are specified, the Contractor shall request instructions and testing shall be as directed by the Architect/Engineer or the soils engineer, as applicable, and in accordance with standard industry practices. Page 14 of 49 SC-6.23 Rev. 7/2015 The Principal Representative and the Architect/Engineer shall be given reasonable advance notice of each concrete pour and reserve the right to either increase or decrease the number of cylinders or the frequency of tests. Soil compaction testing shall be at random locations selected by the soils engineer. In general, soils compaction testing shall be as directed by the soils engineer and shall include all substrate prior to backfill or construction. D. TESTING - OTHER Additional testing required by the Specifications will be accomplished and paid for by the Principal Representative in a manner similar to that for concrete and soils unless noted otherwise in the Specifications. In any case, the Contractor will be responsible for arranging, scheduling and coordinating additional tests. Where the additional testing will be contracted and paid for by the Principal Representative the Contractor shall give the Principal Representative not less than one month advance written Notice of the date the first such test will be required. ARTICLE 15. SUBCONTRACTS A. CONTRACT PERFORMANCE OUTSIDE OF THE UNITED STATES OR COLORADO After the contract is awarded, Contractor is required to provide written notice to the Principal Representative no later than twenty (20) days after deciding to perform services under this contract outside the United States or Colorado or to subcontract services under this contract to a subcontractor that will perform such services outside the United States or Colorado. The written notification must include, but need not be limited to, a statement of the type of services that will be performed at a location outside the United States or Colorado and the reason why it is necessary or advantageous to go outside the United States or Colorado to perform the services. All notices received by the State pursuant to outsourced services shall be posted on the Colorado Department of Personnel & Administration’s website. If Contractor knowingly fails to notify the Principal Representative of any outsourced services as specified herein, the Principal Representative, at its discretion, may terminate this contract as provided in C.R.S. § 24-102-206 (4). (Does not apply to any project that receives federal moneys) B. SUBCONTRACTOR LIST Prior to the Notice to Proceed to commence construction, the Contractor shall submit to the Architect/Engineer, the Principal Representative and State Buildings Program a preliminary list of Subcontractors. It shall be as complete as possible at the time, showing all known Subcontractors planned for the Work. The list shall be supplemented as other Subcontractors are determined by the Contractor and any such supplemental list shall be submitted to the Architect/Engineer, the Principal Representative and State Buildings Program not less than ten (10) days before the Subcontractor commences Work. C. SUBCONTRACTOR SUBSTITUTIONS The Contractor’s list shall include those Subcontractors, if any, which the Contractor indicated in its bid, would be employed for specific portions of the Work if such indication was requested in the bid documents issued by the State. The substitution of any Subcontractor listed in the Contractor’s bid shall be justified in writing not less than ten (10) days after the date of the Notice to Proceed to commence construction, and shall be subject to the approval of the Principal Representative. For reasons such as the Subcontractor’s refusal to perform as agreed, subsequent unavailability or later discovered bid errors, or other similar reasons, but not including the availability of a lower Subcontract price, such substitution may be approved. The Contractor shall bear any additional cost incurred by such substitutions. D. CONTRACTOR RESPONSIBLE FOR SUBCONTRACTORS The Contractor shall not employ any Subcontractor that the Architect/Engineer, within ten (10) days after the date of receipt of the Contractor’s list of Subcontractors or any supplemental list, objects to in writing as being unacceptable to either the Architect/Engineer, the Principal Representative or State Buildings Program. If a Subcontractor is deemed unacceptable, the Contractor shall propose a Page 15 of 49 SC-6.23 Rev. 7/2015 substitute Subcontractor and the Contract sum shall be adjusted by any demonstrated difference between the Subcontractor’s bids, except where the Subcontractor has been debarred by the State or fails to meet qualifications of the Contract Documents to perform the Work proposed. The Contractor shall be fully responsible to the Principal Representative for the acts and omissions of Subcontractors and of persons either directly or indirectly employed by them. All instructions or orders in respect to Work to be done by Subcontractors shall be given to the Contractor. ARTICLE 16. RELATIONS OF CONTRACTOR AND SUBCONTRACTOR The Contractor agrees to bind each Subcontractor to the terms of these General Conditions and to the requirements of the Drawings and Specifications, and any Addenda thereto, and also all the other Contract Documents, so far as applicable to the Work of such Subcontractor. The Contractor further agrees to bind each Subcontractor to those terms of the General Conditions which expressly require that Subcontractors also be bound, including without limitation, requirements that Subcontractors waive all rights of subrogation, provide adequate general commercial liability and property insurance, automobile insurance and workers’ compensation insurance as provided in Article 25, Insurance. Nothing contained in the Contract Documents shall be deemed to create any contractual relationship whatsoever between any Subcontractor and the State of Colorado acting by and through its Principal Representative. ARTICLE 17. MUTUAL RESPONSIBILITY OF CONTRACTORS Should the Contractor cause damage to any separate contractor on the Work, the Contractor agrees, upon due Notice, to settle with such contractor by agreement, if he or she will so settle. If such separate contractor sues the Principal Representative on account of any damage alleged to have been so sustained, the Principal Representative shall notify the Contractor, who shall defend such proceedings if requested to do so by Principal Representative. If any judgment against the Principal Representative arises there from, the Contractor shall pay or satisfy it and pay all costs and reasonable attorney fees incurred by the Principal Representative, in accordance with Article 52C, Indemnification, provided the Contractor was given due Notice of an opportunity to settle. ARTICLE 18. SEPARATE CONTRACTS The Principal Representative reserves the right to enter into other contracts in connection with the Project or the Contract. The Contractor shall afford other contractors reasonable opportunity for the introduction and storage of their materials and the execution of their Work, and shall properly connect and coordinate his or her Work with theirs. If any part of the Contractor’s Work depends, for proper execution or results, upon the Work of any other contractor, the Contractor shall inspect and promptly report to the Architect/Engineer any defects in such Work that render it unsuitable for such proper execution and results. Failure of the Contractor to so inspect and report shall constitute an acceptance of the other contractor's Work as fit and proper for the reception of Work, except as to defects which may develop in the other Contractor’s Work after the execution of the Contractor's Work. To insure the proper execution of subsequent Work, the Contractor shall measure Work already in place and shall at once report to the Architect/Engineer any discrepancy between the executed Work and the Drawings. ARTICLE 19. USE OF PREMISES The Contractor shall confine apparatus, the storage of materials and the operations of workmen to limits indicated by law, ordinances, permits and any limits lines shown on the Drawings. The Contractor shall not unreasonably encumber the premises with materials. The Contractor shall enforce all of the Architect/Engineer’s instructions and prohibitions regarding, without limitation, such matters as signs, advertisements, fires and smoking. Page 16 of 49 SC-6.23 Rev. 7/2015 ARTICLE 20. CUTTING, FITTING OR PATCHING The Contractor shall do all cutting, fitting or patching of Work that may be required to make its several parts come together properly and fit it to receive or be received by Work of other Contractors shown upon, or reasonably inferred from, the Drawings and Specifications for the complete structure, and shall provide for such finishes to patched or fitted Work as the Architect/Engineer may direct. The Contractor shall not endanger any Work by cutting, excavating or otherwise altering the Work and shall not cut or alter the Work of any other Contractor save with the consent of the Architect/Engineer. ARTICLE 21. UTILITIES A. TEMPORARY UTILITIES Unless otherwise specifically stated in the Specifications or on the Drawings, the Principal Representative shall be responsible for the locations of all utilities as shown on the Drawings or indicated elsewhere in the Specifications, subject to the Contractor's compliance with all statutory or regulatory requirements to call for utility locates. When actual conditions deviate from those shown the Contractor shall comply with the requirements of Article 37, Differing Site Conditions. The Contractor shall provide and pay for the installation of all temporary utilities required to supply all the power, light and water needed by him and other Contractors for their Work and shall install and maintain all such utilities in such manner as to protect the public and Workmen and conform with any applicable laws and regulations. Upon completion of the Work, he or she shall remove all such temporary utilities from the site. The Contractor shall pay for all consumption of power, light and water used by him or her and the other Contractors, without regard to whether such items are metered by temporary or permanent meters. The Superintendent shall have full authority over all trades and Subcontractors at any tier to prevent waste. The cut-off date on permanent meters shall be either the agreed date of the date of the Notice of Substantial Completion or the Notice of Approval of Occupancy/Use of the Project. B. PROTECTION OF EXISTING UTILITIES Where existing utilities, such as water mains, sanitary sewers, storm sewers and electrical conduits, are shown on the Drawings, the Contractor shall be responsible for the protection thereof, without regard to whether any such utilities are to be relocated or removed as a part of the Work. If any utilities are to be moved, the moving must be conducted in such manner as not to cause undue interruption or delay in the operation of the same. C. CROSSING OF UTILITIES When new construction crosses highways, railroads, streets, or utilities under the jurisdiction of State, city or other public agency, public utility or private entity, the Contractor shall secure proper written permission before executing such new construction. The Contractor will be required to furnish a proper release before final acceptance of the Work. ARTICLE 22. UNSUITABLE CONDITIONS The Contractor shall not Work at any time, or permit any Work to be done, under any conditions contrary to those recommended by manufacturers or industry standards which are otherwise proper, unsuited for proper execution, safety and performance. Any cost caused by ill-timed Work shall be borne by the Contractor unless the timing of such Work shall have been directed by the Architect/Engineer or the Principal Representative, after the award of the Contract, and the Contractor provided Notice of any additional cost. ARTICLE 23. TEMPORARY FACILITIES A. OFFICE FACILITIES The Contractor shall provide and maintain without additional expense for the duration of the Project temporary office facilities, as required and as specified, for its own use and the use of the Architect/Engineer, representatives of the Principal Representative and State Buildings Program. B. TEMPORARY HEAT The Contractor shall furnish and pay for all the labor, facilities, equipment, fuel and power necessary to supply temporary heating, ventilating and air conditioning, except to the extent otherwise specified, Page 17 of 49 SC-6.23 Rev. 7/2015 and shall be responsible for the installation, operation, maintenance and removal of such facilities and equipment. Unless otherwise specified, the permanent HVAC system shall not be used for temporary heat in whole or in part. If the Contractor desires to put the permanent system into use, in whole or in part, the Contractor shall set it into operation and furnish the necessary fuel and manpower to safely operate, protect and maintain that HVAC system. Any operation of all or any part of the permanent HVAC system including operation for testing purposes shall not constitute acceptance of the system, nor shall it relieve the Contractor of his or her one-year guarantee of the system from the date of the Notice of Substantial Completion of the entire Project, and if necessary due to prior operation, the Contractor shall provide manufacturers’ extended warranties from the date of the Contractor’s use prior to the date of the Notice of Substantial Completion. C. WEATHER PROTECTION The Contractor shall, at all times, provide protection against weather, so as to maintain all Work, materials, apparatus and fixtures free from injury or damages. D. DUST PARTITIONS If the Work involves Work in an occupied existing building, the Contractor shall erect and maintain during the progress of the Work, suitable dust-proof temporary partitions, or more permanent partitions as specified, to protect such building and the occupants thereof. E. BENCH MARKS The Contractor shall maintain any site bench marks provided by the Principal Representative and shall establish any additional benchmarks specified by the Architect/Engineer as necessary for the Contractor to layout the Work and ascertain all grades and levels as needed. F. SIGN The Contractor shall erect and permit one 4’ x 8’ sign only at the site to identify the Project as specified or directed by the Architect/Engineer which shall be maintained in good condition during the life of the Project. G. SANITARY PROVISION The Contractor shall provide and maintain suitable, clean, temporary sanitary toilet facilities for any and all workmen engaged on the Work, for the entire construction period, in strict compliance with the requirement of all applicable codes, regulations, laws and ordinances, and no other facilities, new or existing, may be used by any person on the Project. When the Project is complete the Contractor shall promptly remove them from the site, disinfect, and clean or treat the areas as required. If any new construction surfaces in the Project other than the toilet facilities provided for herein are soiled at any time, the entire areas so soiled shall be completely removed from the Project and rebuilt. In no event may present toilet facilities of any existing building at the site of the Work be used by employees of any contractor. ARTICLE 24. CLEANING UP The Contractor shall keep the building and premises free from all surplus material, waste material, dirt and rubbish caused by employees or Work, and at the completion of the Work shall remove all such surplus material, waste material, dirt, and rubbish, as well as all tools, equipment and scaffolding, and shall wash and clean all window glass and plumbing fixtures, perform cleanup and cleaning required by the Specifications and leave all of the Work clean unless more exact requirements are specified. ARTICLE 25. INSURANCE A. GENERAL The Contractor shall procure and maintain all insurance requirements and limits as set forth below, at his or her own expense, for the length of time set forth in Contract requirements. The Contractor shall continue to provide evidence of such coverage to State of Colorado on an annual basis during the aforementioned period including all of the terms of the insurance and indemnification requirements of this agreement. All below insurance policies shall include a provision preventing cancellation without thirty (30) days’ prior notice by certified mail. A completed Certificate of Insurance shall be filed with Page 18 of 49 SC-6.23 Rev. 7/2015 the Principal Representative and State Buildings Program within ten (10) days after the date of the Notice of Award, said Certificate to specifically state the inclusion of the coverages and provisions set forth herein and shall state whether the coverage is “claims made” or “per occurrence”. B. COMMERCIAL GENERAL LIABILITY INSURANCE (CGL) This insurance must protect the Contractor from all claims for bodily injury, including death and all claims for destruction of or damage to property (other than the Work itself), arising out of or in connection with any operations under this Contract, whether such operations be by the Contractor or by any Subcontractor under him or anyone directly or indirectly employed by the Contractor or by a Subcontractor. All such insurance shall be written with limits and coverages as specified below and shall be written on an occurrence form. General Aggregate Products – Completed Operations Aggregate Each Occurrence Personal Injury $2,000,000 $2,000,000 $1,000,000 $1,000,000 The following coverages shall be included in the CGL: 1. Per project general aggregate (CG 25 03 or similar) 2. Additional Insured status in favor of the State of Colorado and any other parties as outlined in The Contract and must include both ONGOING Operations AND COMPLETED Operations per CG2010 10/01 and CG 2037 10/01 or equivalent as permitted by law. 3. The policy shall be endorsed to be primary and non-contributory with any insurance maintained by Additional Insureds. 4. A waiver of Subrogation in favor of all Additional Insured parties. 5. Personal Injury Liability 6. Contractual Liability coverage to support indemnification obligation per Article 53.I 7. Explosion, collapse and underground (xcu) The following exclusionary endorsements are prohibited in the CGL policy: 1. Damage to Work performed by Subcontract/Vendor (CG 22-94 or similar) 2. Contractual Liability Coverage Exclusion modifying or deleting the definition of an “insured contract” from the unaltered SO CG 0001 1001 policy from (CG 24 26 or similar) 3. If applicable to the Work to be performed: Residential or multi-family 4. If applicable to the Work to be performed :Exterior insulation finish systems 5. If applicable to the Work to be performed: Subsidence or Earth Movement The Contractor shall maintain general liability coverage including Products and Completed Operations insurance, and the Additional Insured with primary and non-contributory coverage as specified in this Contract for three (3) years after completion of the project. C. AUTOMOBILE LIABILITY INSURANCE and business auto liability covering liability arising out of any auto (including owned, hired and non-owned autos). Combined Bodily Injury and Property Damage Liability (Combined Single Limit): Coverages: Specific waiver of subrogation Page 19 of 49 SC-6.23 Rev. 7/2015 $1,000,000 each accident D. WORKERS' COMPENSATION INSURANCE The Contractor shall procure and maintain Workers' Compensation Insurance at his or her own expense during the life of this Contract, including occupational disease provisions for all employees per statutory requirements. Policy shall contain a waiver of subrogation in favor of the State of Colorado. The Contractor shall also require each Subcontractor to furnish Workers' Compensation Insurance, including occupational disease provisions for all of the latter’s employees, and to the extent not furnished, the Contractor accepts full liability and responsibility for Subcontractor’s employees. In cases where any class of employees engaged in hazardous Work under this Contract at the site of the Project is not protected under the Workers’ Compensation statute, the Contractor shall provide, and shall cause each Subcontractor to provide, adequate and suitable insurance for the protection of employees not otherwise protected. E. UMBRELLA LIABILITY INSURANCE (for construction projects exceeding $10,000,000, provide the following coverage): The Contractor shall maintain umbrella/excess liability insurance on an occurrence basis in excess of the underlying insurance described in Section B-D above. Coverage shall follow the terms of the underlying insurance, included the additional insured and waiver of subrogation provisions. The amounts of insurance required in Sections above may be satisfied by the Contractor purchasing coverage for the limits specified or by any combination of underlying and umbrella limits, so long as the total amount of insurance is not less than the limits specified in each section previously mentioned. Each occurrence Aggregate F. $5,000,000 $5,000,000 BUILDER’S RISK INSURANCE Unless otherwise expressly stated in the Supplementary General Conditions (e.g. where the State elects to provide for projects with a completed value of less than $1,000,000), the Contractor shall purchase and maintain, in a company or companies lawfully authorized to do business in the jurisdiction in which the Project is located, property insurance written on a builder’s risk “all-risk” or equivalent policy form in the amount of the initial Contract Sum, plus value of subsequent Contract Modifications and cost of materials supplied or installed by others, comprising total value for the entire Project at the site on a replacement cost basis without optional deductibles. Such property insurance shall be maintained, unless otherwise provided in the Contract Documents or otherwise agreed in writing by all persons and entities who are beneficiaries of such insurance, until final payment has been made or until no person or entity other than the Owner has an insurable interest in the property, or the Date of Notice specified on the Notice of Acceptance, State Form SBP-6.27 or whichever is later. This insurance shall include interests of the Owner, the Contractor, Subcontractors and Subsubcontractors in the Project as named insureds. All associated deductibles shall be the responsibility of the Contractor. Such policy may have a deductible clause but not to exceed ten thousand dollars ($10,000.00). Property insurance shall be on an “all risk” or equivalent policy form and shall include, without limitation, insurance against the perils of fire (with extended coverage) and physical loss or damage including, without duplication of coverage, theft, vandalism, malicious mischief, collapse, earthquake, flood, windstorm, false Work, testing and startup, temporary buildings and debris removal including demolition occasioned by enforcement of any applicable legal requirements, and shall cover reasonable compensation for Architect’s and Contractor’s services and expenses required as a result of such insured loss. Contractor shall maintain Builders Risk coverage including partial use by Owner. Page 20 of 49 SC-6.23 Rev. 7/2015 The Contractor shall waive all rights of subrogation as regards the State of Colorado and the Principal Representative, its officials, its officers, its agents and its employees, all while acting within the scope and course of their employment For damages caused by fire or thoer causes of loss to the extent covered by property insurance obtained pursuant to this Section or other property insurance applicable to the Work. The Contractor shall require all Subcontractors at any tier to similarly waive all such rights of subrogation and shall expressly include such a waiver in all subcontracts. Upon request, the amount of such insurance shall be increased to include the cost of any additional Work to be done on the Project, or materials or equipment to be incorporated in the Project, under other independent contracts let or to be let. In such event, the Contractor shall be reimbursed for this cost as his or her share of the insurance in the same ratio as the ratio of the insurance represented by such independent contracts let or to be let to the total insurance carried. The Principal Representative, with approval of the State Controller, shall have the power to adjust and settle any loss. Unless it is agreed otherwise, all monies received shall be applied first on rebuilding or repairing the destroyed or injured Work. G. POLLUTION LIABILITY INSURANCE If Contractor is providing directly or indirectly Work with pollution/environmental hazards, the Contractor must provide or cause those conducting the Work to provide Pollution Liability Insurance coverage. Pollution Liability policy must include contractual liability coverage. State of Colorado must be included as additional insureds on the policy. The policy limits shall be in the amount of $1,000,000 with maximum deductible of $25,000 to be paid by the Subcontractor/Vendor. H. ADDITIONAL MISCELLANEOUS INSURANCE PROVISIONS Certificates of Insurance and/or insurance policies required under this Contract shall be subject to the following stipulations and additional requirements: 1. 2. 3. 4. Any and all deductibles or self-insured retentions contained in any Insurance policy shall be assumed by and at the sole risk of the Contractor; If any of the said policies shall fail at any time to meet the requirements of the Contract Documents as to form or substance, or if a company issuing any such policy shall be or at any time cease to be approved by the Division of Insurance of the State of Colorado, or be or cease to be in compliance with any stricter requirements of the Contract Documents, the Contractor shall promptly obtain a new policy, submit the same to the Principal Representative and State Building Programs for approval if requested, and submit a Certificate of Insurance as hereinbefore provided. Upon failure of the Contractor to furnish, deliver and maintain such insurance as provided herein, this Contract, in the sole discretion of the State of Colorado, may be immediately declared suspended, discontinued, or terminated. Failure of the Contractor in obtaining and/or maintaining any required insurance shall not relieve the Contractor from any liability under the Contract, nor shall the insurance requirements be construed to conflict with the obligations of the Contractor concerning indemnification; All requisite insurance shall be obtained from financially responsible insurance companies, authorized to do business in the State of Colorado and acceptable to the Principal Representative; Receipt, review or acceptance by the Principal Representative of any insurance policies or certificates of insurance required by this Contract shall not be construed as a waiver or relieve the Contractor from its obligation to meet the insurance requirements contained in these General Conditions. ARTICLE 26. CONTRACTOR’S PERFORMANCE AND PAYMENT BONDS The Contractor shall furnish a Performance Bond and a Labor and Material Payment Bond on State Forms SC-6.22, Performance Bond, and SC-6.221, Labor and Material Payment Bond, or such other forms as State Buildings Program may approve for the Project, executed by a corporate Surety authorized to do business in the State of Colorado and in the full amount of the Contract sum. The expense of these bonds shall be borne by the Contractor and the bonds shall be filed with State Buildings Program. Page 21 of 49 SC-6.23 Rev. 7/2015 If, at any time, a Surety on such a bond is found to be, or ceases to be in strict compliance with any qualification requirements of the Contract Documents or the bid documents, or loses its right to do business in the State of Colorado, another Surety will be required, which the Contractor shall furnish to State Buildings Program within ten (10) days after receipt of Notice from the State or after the Contractor otherwise becomes aware of such conditions. ARTICLE 27. LABOR AND WAGES In accordance with laws of Colorado, C.R.S. § 8-17-101(1), as amended, Colorado labor shall be employed to perform at least eighty percent of the Work. If the Federal Davis-Bacon Act shall be applicable to the Project, as indicated in Article 6B (Design/Bid/Build Agreement SC-6.21), Modification of Article 27, the minimum wage rates to be paid on the Project will be specified in the Contract Documents. ARTICLE 28. ROYALTIES AND PATENTS The Contractor shall be responsible for assuring that all rights to use of products and systems have been properly arranged and shall take such action as may be necessary to avoid delay, at no additional charge to the Principal Representative, where such right is challenged during the course of the Work. The Contractor shall pay all royalties and license fees required to be paid and shall defend all suits or claims for infringement of any patent rights and shall save the State of Colorado harmless from loss on account thereof, in accordance with Article 52C, Indemnification; provided, however, the Contractor shall not be responsible for such loss or defense for any copyright violations contained in the Contract Documents prepared by the Architect/Engineer or the Principal Representative of which the Contractor is unaware, or for any patent violations based on specified processes that the Contractor is unaware are patented or that the Contractor should not have had reason to believe were patented. ARTICLE 29. ASSIGNMENT Except as otherwise provided hereafter the Contractor shall not assign the whole or any part of this Contract without the written consent of the Principal Representative. This provision shall not be construed to prohibit assignments of the right to payment to the extent permitted by C.R.S. § 4-9-406, et. seq., as amended, provided that written Notice of assignment adequate to identify the rights assigned is received by the Principal Representative and the controller for the agency, department, or institution executing this Contract (as distinguished from the State Controller). Such assignment of the right to payment shall not be deemed valid until receipt by the Principal Representative and such controller and the Contractor assumes the risk that such written Notice of assignment is received by the Principal Representative and the controller for the agency, department, or institution involved. In case the Contractor assigns all or part of any moneys due or to become due under this Contract, the instrument of assignment shall contain a clause substantially to the effect that it is agreed that the right of the assignee in and to any moneys due or to become due to the Contractor shall be subject to all claims of all persons, firms, and corporations for services rendered or materials supplied for the performance of the Work called for in this Contract, whether said service or materials were supplied prior to or after the assignment. Nothing in this Article shall be deemed a waiver of any other defenses available to the State against the Contractor or the assignee. ARTICLE 30. CORRECTION OF WORK BEFORE ACCEPTANCE The Contractor shall promptly remove from the premises all Work or materials condemned or declared irreparably defective as failing to conform to the Contract Documents on receipt of written Notice from the Architect/Engineer or the Principal Representative, whether incorporated in the Work or not. If such materials shall have been incorporated in the Work, or if any unsatisfactory Work is discovered, the Contractor shall promptly replace and re-execute his or her Work in accordance with the requirements of the Contract Documents without expense to the Principal Representative, and shall also bear the expense of making good all Work of other contractors destroyed or damaged by the removal or replacement of such defective material or Work. Should any defective Work or material be discovered during the process of construction, or should reasonable doubt arise as to whether certain material or Work is in accordance with the Contract Documents, the value of such defective or questionable material or Work shall not be included in any Page 22 of 49 SC-6.23 Rev. 7/2015 application for payment, or if previously included, shall be deducted by the Architect/Engineer from the next application submitted by the Contractor. If the Contractor does not perform repair, correction and replacement of defective Work, in lieu of proceeding by issuance of a Notice of intent to remove condemned Work as outlined above, the Principal Representative may, not less than seven (7) days after giving the original written Notice of the need to repair, correct, or replace defective Work, deduct all costs and expenses of replacement or correction as instructed by the Architect/Engineer from the Contractor’s next application for payment in addition to the value of the defective Work or material. The Principal Representative may also make an equitable deduction from the Contract sum by unilateral Change Order, in accordance with Article 33, Payments Withheld and Article 35, Changes In The Work. If the Contractor does not remove such condemned or irreparably defective Work or material within a reasonable time, the Principal Representative may, after giving a second seven (7) day advance Notice to the Contractor and the Surety, remove them and may store the material at the Contractor’s expense. The Principal Representative may accomplish the removal and replacement with its own forces or with another Contractor. If the Contractor does not pay the expense of such removal and pay all storage charges within ten (10) days thereafter, the Principal Representative may, upon ten (10) days’ written Notice, sell such material at auction or at private sale and account for the net proceeds thereof, after deducting all costs and expenses which should have been borne by the Contractor. If the Contractor shall commence and diligently pursue such removal and replacement before the expiration of the seven day period, or if the Contractor shall show good cause in conjunction with submittal of a revised CPM schedule showing when the Work will be performed and why such removal of condemned Work should be scheduled for a later date, the Principal Representative shall not proceed to remove or replace the condemned Work. If the Contractor disagrees with the Notice to remove Work or materials condemned or declared irreparably defective, the Contractor may request facilitated negotiation of the issue and the Principal Representative’s right to proceed with removal and to deduct costs and expenses of repair shall be suspended and tolled until such time as the parties meet and negotiate the issue During construction, whenever the Architect/Engineer has advised the Contractor in writing, in the Specifications, by reference to Article 6, Architect/Engineer Decisions And Judgments, of these General Conditions or elsewhere in the Contract Documents of a need to observe materials in place prior to their being permanently covered up, it shall be the Contractor’s responsibility to notify the Architect/Engineer at least forty-eight (48) hours in advance of such covering operation. If the Contractor fails to provide such notification, Contractor shall, at his or her expense, uncover such portions of the Work as required by the Architect/Engineer for observation, and reinstall such covering after observation. When a covering operation is continued from day to day, notification of the commencement of a single continuing covering operation shall suffice for the activity specified so long as it proceeds regularly and without interruption from day to day, in which event the Contractor shall coordinate with the Architect/Engineer regarding the continuing covering operation. ARTICLE 31. APPLICATIONS FOR PAYMENTS A. CONTRACTOR’S SUBMITTALS On or before the first day of each month and no more than five days prior thereto, the Contractor may submit applications for payment for the Work performed during such month covering the portion of the Work completed as of the date indicated, and payments on account of this Contract shall be due per § 24-30-202(24) (correct notice of amount due), within forty-five (45) days of receipt by the Principal Representative of application for payments that have been certified by the Architect/Engineer. The Contractor shall submit the application for payment to the Architect/Engineer on State forms SBP-7.2, Certificate for Contractor's Payment, or such other format as the State Buildings Program shall approve, in an itemized format in accordance with the schedule of values or a cost loaded CPM schedule when required, supported to the extent reasonably required by the Architect/Engineer or the Principal Representative by receipts or other vouchers, showing payments for materials and labor, prior payments and payments to be made to Subcontractors and such other evidence of the Contractor’s right to payments as the Architect/Engineer or Principal Representative may direct. Page 23 of 49 SC-6.23 Rev. 7/2015 If payments are made on account of materials not incorporated in the Work but delivered and suitably stored at the site, or at some other location agreed upon in writing, such payments shall be conditioned upon submission by the Contractor of bills of sale or such other procedure as will establish the Principal Representative’s title to such material or otherwise adequately protect the Principal Representative’s interests, and shall provide proof of insurance whenever requested by the Principal Representative or the Architect/Engineer, and shall be subject to the right to inspect the materials at the request of either the Architect/Engineer or the Principal Representative. All applications for payment, except the final application, and the payments there under, shall be subject to correction in the next application rendered following the discovery of any error. B. ARCHITECT/ENGINEER CERTIFICATION In accordance with the Architect/Engineer’s agreement with the Principal Representative, the Architect/Engineer after appropriate observation of the progress of the Work shall certify to the Principal Representative the amount that the Contractor is entitled to, and forward the application to the Principal Representative. If the Architect/Engineer certifies an amount different from the amount requested or otherwise alters the Contractor’s application for payment, a copy shall be forwarded to the Contractor. If the Architect/Engineer is unable to certify all or portions of the amount requested due to the absence or lack of required supporting evidence, the Architect/Engineer shall advise the Contractor of the deficiency. If the deficiency is not corrected at the end of ten (10) days, the Architect/Engineer may either certify the remaining amounts properly supported to which the Contractor is entitled, or return the application for payment to the Contractor for revision with a written explanation as to why it could not be certified. C. RETAINAGE WITHHELD Unless otherwise provided in the Supplementary General Conditions, an amount equivalent to five percent (5%) of the amount shown to be due the Contractor on each application for payment shall be withheld until the Work required by the Contract has been performed. The withheld percentage of the contract price of any such Work, improvement, or construction shall be administered according to § 24-91-101, et seq., C.R.S., as amended, and except as provided in § 24-91-103, C.R.S., as amended, and Article 31D, shall be retained until the Work or discrete portions of the Work, have been completed satisfactorily, finally or partially accepted, and advertised for final settlement as further provided in Article 41. D. RELEASE OF RETAINAGE The Contractor may, for satisfactory and substantial reasons shown to the Principal Representative’s satisfaction, make a written request to the Principal Representative and the Architect/Engineer for release of part or all of the withheld percentage applicable to the Work of a Subcontractor which has completed the subcontracted Work in a manner finally acceptable to the Architect/Engineer, the Contractor, and the Principal Representative. Any such request shall be supported by a written approval from the Surety furnishing the Contractor’s bonds and any surety that has provided a bond for the Subcontractor. The release of any such withheld percentage shall be further supported by such other evidence as the Architect/Engineer or the Principal Representative may require, including but not limited to, evidence of prior payments made to the Subcontractor, copies of the Subcontractor’s contract with the Contractor, any applicable warranties, as-built information, maintenance manuals and other customary close-out documentation. Neither the Principal Representative nor the Architect Engineer shall be obligated to review such documentation nor shall they be deemed to assume any obligations to third parties by any review undertaken. The Contractor’s obligation under these General Conditions to guarantee Work for one year from the date of the Notice of Substantial Completion or the date of any Notice of Partial Substantial Completion of the applicable portion or phase of the Project, shall be unaffected by such partial Page 24 of 49 SC-6.23 Rev. 7/2015 release; unless a Notice of Partial Substantial Completion is issued for the Work subject to the release of retainage. Any rights of the Principal Representative which might be terminated by or from the date of any final acceptance of the Work, whether at common law or by the terms of this Contract, shall not be affected by such partial release of retainage prior to any final acceptance of the entire Project. The Contractor remains fully responsible for the Subcontractor’s Work and assumes any risk that might arise by virtue of the partial release to the Subcontractor of the withheld percentage, including the risk that the Subcontractor may not have fully paid for all materials, labor and equipment furnished to the Project. If the Principal Representative considers the Contractor’s request for such release satisfactory and supported by substantial reasons, the Architect/Engineer shall make a “final inspection” of the applicable portion of the Project to determine whether the Subcontractor ’s Work has been completed in accordance with the Contract Documents. A final punch list shall be made for the Subcontractor’s Work and the procedures of Article 41, Completion, Final Inspection, Acceptance and Settlement, shall be followed for that portion of the Work, except that advertisement of the intent to make final payment to the Subcontractor shall be required only if the Principal Representative has reason to believe that a supplier or Subcontractor to the Subcontractor for which the request is made, may not have been fully paid for all labor and materials furnished to the Project. ARTICLE 32. CERTIFICATES FOR PAYMENTS State Form SBP-7.2, Certificate For Contractor's Payment, and its continuation detail sheets, when submitted, shall constitute the Certificate of Contractor ’s Application for Payment, and shall be a representation by the Contractor to the Principal Representative that the Work has progressed to the point indicated, the quality of the Work is in accordance with the Contract Documents, and materials for which payment is requested have been incorporated into the Project except as noted in the application. If requested by the Principal Representative the Certificate of Contractor’s Application for Payment shall be sworn under oath and notarized. ARTICLE 33. PAYMENTS WITHHELD The Architect/Engineer, the Principal Representative or State Buildings Program may withhold, or on account of subsequently discovered evidence nullify, the whole or any part of any application on account of, but not limited to any of the following: 1. 2. 3. 4. 5. 6. 7. 8. 9. 10. 11. 12. Defective Work not remedied; Claims filed or reasonable evidence indicating probable filing of claims; Failure of the Contractor to make payments to Subcontractors for material or labor; A reasonable doubt that the Contract can be completed for the balance of the contract price then unpaid; Damage or injury to another contractor or any other person, persons or property except to the extent of coverage by a policy of insurance; Failure to obtain necessary permits or licenses or to comply with applicable laws, ordinances, codes, rules or regulations or the directions of the Architect/Engineer; Failure to submit a monthly construction schedule; Failure of the Contractor to keep Work progressing in accordance with the time schedule; Failure to keep a superintendent on the Work; Failure to maintain as built drawings of the Work in progress; Unauthorized deviations by the Contractor from the Contract Documents; or On account of liquidated damages. In addition, the Architect Engineer, Principal Representative or State Buildings Program may withhold or nullify the whole or any part of any application for any reason noted elsewhere in these General Conditions of the Contractor’s Design/Bid/Build Agreement. Nullification shall mean reduction of amounts shown as previously paid on the application. The amount withheld or nullified may be in such amount as the Page 25 of 49 SC-6.23 Rev. 7/2015 Architect/Engineer or the Principal Representative estimates to be required to allow the State to accomplish the Work, cure the failure and cover any damages or injuries, including an allowance for attorneys fees and costs where appropriate. When the grounds for such withholding or nullifying are removed, payment shall be made for the amounts thus withheld or nullified on such grounds. ARTICLE 34. DEDUCTIONS FOR UNCORRECTED WORK If the Architect/Engineer and the Principal Representative deem it inexpedient to correct Work damaged or not performed in accordance with the Contract Documents, the Principal Representative may, after consultation with the Architect/Engineer and ten (10) days’ Notice to the Contractor of intent to do so, make reasonable reductions from the amounts otherwise due the Contractor on the next application for payment. Notice shall specify the amount or terms of any contemplated reduction. The Contractor may during this period correct or perform the Work. If the Contractor does not correct or perform the Work, an equitable deduction from the Contract sum shall be made by Change Order, in accordance with Article 35, Changes In The Work, unilaterally if necessary. If either party elects facilitation of this issue after Notice is given, the ten-day (10) notice period shall be extended and tolled until facilitation has occurred. ARTICLE 35. CHANGES IN THE WORK The Principal Representative may designate, without invalidating the Agreement, and with the approval of State Buildings Program and the State Controller, may order extra Work or make changes with or without the consent of the Contractor as hereafter provided, by altering, adding to or deducting from the Work, the Contract sum being adjusted accordingly. All such changes in the Work shall be within the general scope of and be executed under the conditions of the Contract, except that any claim for extension of time made necessary due to the change or any claim of other delay or other impacts caused by or resulting from the change in the Work shall be presented by the Contractor and adjusted by Change Order to the extent known at the time such change is ordered and before proceeding with the extra or changed Work. Any claims for extension of time or of delay or other impacts, and any costs associated with extension of time, delay or other impacts, which are not presented before proceeding with the change in the Work, and which are not adjusted by Change Order to the extent known, shall be waived. The Architect/Engineer shall have authority to make minor changes in the Work, not involving extra cost, and not inconsistent with the intent of the Contract Documents, but otherwise, except in an emergency endangering life or property, no extra Work or change in the Contract Documents shall be made unless by 1) a written Change Order, approved by the Principal Representative, State Buildings Program, and the State Controller prior to proceeding with the changed Work; or 2) by an Emergency Field Change Order approved by the Principal Representative and State Buildings Program as hereafter provided in Article 35C, Emergency Field Ordered Changed Work; or 3) by an allocation in writing of any allowance already provided in the encumbered contract amount, the Contract sum being later adjusted to decrease the Contract sum by any unallocated or unexpended amounts remaining in such allowance. No change to the Contract sum shall be valid unless so ordered. A. THE VALUE OF CHANGED WORK 1. The value of any extra Work or changes in the Work shall be determined by agreement in one or more of the following ways: a. By estimate and acceptance of a lump-sum amount; 2. b. By unit prices specified in the Agreement, or subsequently agreed upon, that are extended by specific quantities; c. By actual cost plus a fixed fee in a lump sum amount for profit, overhead and all indirect and off-site home office costs, the latter amount agreed upon in writing prior to starting the extra or changed Work. Where the Contractor and the Principal Representative cannot agree on the value of extra Work, the Principal Representative may order the Contractor to perform the changes in the Work and a Change Order may be unilaterally issued based on an estimate of the change in the Work prepared by the Architect/Engineer. The value of the change in the Work shall be the Principal Representative’s determination of the amount of equitable adjustment attributable to Page 26 of 49 SC-6.23 Rev. 7/2015 the extra Work or change. The Principal Representative’s determination shall be subject to appeal by the Contractor pursuant to the claims process in Article 36, Claims. 3. Except as otherwise provided in Article 35B, Detailed Breakdown, below, the Cost Principles of the Colorado Procurement Rules in effect on the date of this Contract, pursuant to § 24-107-101, C.R.S., as amended, shall govern all Contract changes. B. DETAILED BREAKDOWN In all cases where the value of the extra or changed Work is not known based on unit prices in the Contractor’s bid or the Agreement, a detailed change proposal shall be submitted by the Contractor on a Change Order Proposal (SC-6.312), or in such other format as the State Buildings Program approves, with which the Principal Representative may require an itemized list of materials, equipment and labor, indicating quantities, time and cost for completion of the changed Work. Such detailed change proposals shall be stated in lump sum amounts and shall be supported by a separate breakdown, which shall include estimates of all or part of the following when requested by the Architect/Engineer or the Principal Representative: 1. 2. 3. 4. 5. 6. 7. 8. 9. 10. 11. Materials, indicating quantities and unit prices including taxes and delivery costs if any (separated where appropriate into general, mechanical and electrical and/or other Subcontractors’ Work; and the Principal Representative may require in its discretion any significant subcontract costs to be similarly and separately broken down). Labor costs, indicating hourly rates and time and labor burden to include Social Security and other payroll taxes such as unemployment, benefits and other customary burdens. Costs of project management time and superintendence time of personnel stationed at the site, and other field supervision time, but only where a time extension, other than a weather delay, is approved as part of the Change Order, and only where such project management time and superintendence time is directly attributable to and required by the change; provided however that additional cost of on-site superintendence shall be allowable whenever in the opinion of the Architect/Engineer the impact of multiple change requests to be concurrently performed will result in inadequate levels of supervision to assure a proper result unless additional superintendence is provided. Construction equipment (including small tools). Expenses for equipment and fuel shall be based on customary commercially reasonable rental rates and schedules. Equipment and hand tool costs shall not include the cost of items customarily owned by workers. Workers’ compensation costs, if not included in labor burden. The cost of commercial general liability and property damage insurance premiums but only to the extent charged the Contractor as a result of the changed Work. Overhead and profit, as hereafter specified. Builder’s risk insurance premium costs. Bond premium costs. Testing costs not otherwise excluded by these General Conditions. Subcontract costs. Unless modified in the Supplementary General Conditions, overhead and profit shall not exceed the percentages set forth in the table below. OVERHEAD PROFIT COMMISSION 10% 5% 0% 5% 0% 5% To the Contractor or to Subcontractors for the portion of Work performed with their own forces: To the Contractor or to Subcontractors for Work performed by others at a tier immediately below either of them: Page 27 of 49 SC-6.23 Rev. 7/2015 Overhead shall include: a) insurance premium for policies not purchased for the Project and itemized above, b) home office costs for office management, administrative and supervisory personnel and assistants, c) estimating and change order preparation costs, d) incidental job burdens, e) legal costs, f) data processing costs, g) interest costs on capital, h) general office expenses except those attributable to increased rental expenses for temporary facilities, and all other indirect costs, but shall not include the Social Security tax and other direct labor burdens. The term “Work” as used in the proceeding table shall include labor, materials and equipment and the "Commission" shall include all costs and profit for carrying the subcontracted Work at the tiers below except direct costs as listed in items 1 through 11 above if any. On proposals for Work involving both additions and credits in the amount of the Contract sum, the overhead and profit will be allowed on the net increase only. On proposals resulting in a net deduct to the amount of the Contract sum, profit on the deducted amount shall be returned to the Principal Representative at fifty percent (50%) of the rate specified. The inadequacy of the profit specified shall not be a basis for refusal to submit a proposal. Except in the case of Change Orders or Emergency Field Change Orders agreed to on the basis of a lump sum amount or unit prices as described in paragraphs 35A1 and 35A2 above, The Value of Changed Work, the Contractor shall keep and present a correct and fully auditable account of the several items of cost, together with vouchers, receipts, time cards and other proof of costs incurred, summarized on a Change Order form (SC-6.31) using such format for supporting documentation as the Principal Representative and State Buildings Program approve. This requirement applies equally to Work done by Subcontractors. Only auditable costs shall be reimbursable on Change Orders where the value is determined on the basis of actual cost plus a fixed fee pursuant to paragraph 35A3 above, or where unilaterally determined by the Principal Representative on the basis of an equitable adjustment in accordance with the Procurement Rules, as described above in Article 35A, The Value Of Changed Work. Except for proposals for Work involving both additions and credits, changed Work shall be adjusted and considered separately for Work either added or omitted. The amount of adjustment for Work omitted shall be estimated at the time it is directed to be omitted, and when reasonable to do so, the agreed adjustment shall be reflected on the schedule of values used for the next Contractor’s application for payment. The Principal Representative reserves the right to contract with any person or firm other than the Contractor for any or all extra Work; however, unless specifically required in the Contract Documents, the Contractor shall have no responsibility without additional compensation to supervise or coordinate the Work of persons or firms separately contracted by the Principal Representative. C. HAZARDOUS MATERIALS 1. The Principal Representative represents that it has undertaken an examination of the site of the Work and has determined that there are no hazardous substances, as defined below, which the Contractor could reasonably encounter in its performance of the Work. In the event the Principal Representative so discovers hazardous substances, the Principal Representative shall render harmless such hazards before the Contractor commences the Work. 2. In the event the Contractor encounters any materials reasonably believed to be hazardous substances which have not been rendered harmless, the Contractor shall immediately stop Work in the area affected and report the condition to the Principal Representative, in writing. For purposes of this Agreement, "hazardous substances" shall include asbestos, lead, polychlorinated biphenyl (PCB) and any or all of those substances defined as "hazardous substance", "hazardous waste", or "dangerous or extremely hazardous wastes" as those terms are used in the Comprehensive Environmental Response, Compensation and Liability Act (CERCLA) and the Resource Conservation and Recovery Act (RCRA), and shall also include materials regulated by the Toxic Substances Control Act (TSCA), the Clean Air Act, the Air Page 28 of 49 SC-6.23 Rev. 7/2015 Quality Act, the Clean Water Act, and the Occupational Safety and Health Act. The Work in the affected area shall not therefore be resumed except by written agreement of the Principal Representative and the Contractor, if in fact materials that are hazardous substances have not been rendered harmless. The Work in the affected area shall be resumed only in the absence of the hazardous substances or when it has been rendered harmless or by written agreement of the Principal Representative and the Contractor. 3. D. The contractor shall not be required to perform Work without consent in any areas where it reasonably believes hazardous substances that have not been rendered harmless are present. EMERGENCY FIELD CHANGE ORDERED WORK The Principal Representative, without invalidating the Agreement, and with the approval of State Buildings Program and without the approval of the State Controller, may order extra Work or make changes in the case of an emergency that is a threat to life or property or where the likelihood of delays in processing a normal Change Order will result in substantial delays and or significant cost increases for the Project. Emergency Field Orders are not to be used solely to expedite normal Change Order processing absent a clear showing of a high potential for significant and substantial cost or delay. Such changes in the Work may be directed through issuance of an Emergency Field Change Order signed by the Contractor, the Principal Representative (or by a designee specifically appointed to do so in writing), and approved by the Director of State Buildings Program or his or her delegate. The change shall be directed using an Emergency Field Change Order form (SC-6.31E). If the amount of the adjustment of the Contract price and time for completion can be determined at the time of issuance of the Emergency Field Change Order, those adjustments shall be reflected on the face of the Emergency Field Change Order. Otherwise, the Emergency Field Change Order shall reflect a not to exceed (NTE) amount for any schedule adjustment (increasing or decreasing the time for completion) and an NTE amount for any adjustment to Contract sum, which NTE amount shall represent the maximum amount of adjustment to which the Contractor will be entitled, including direct and indirect costs of changed Work, as well as any direct or indirect costs attributable to delays, inefficiencies or other impacts arising out of the change. Emergency Field Change Orders directed in accordance with this provision need not bear the approval signatures of the State Controller. On Emergency Field Change Orders where the price and schedule have not been finally determined, the Contractor shall submit final costs for adjustment as soon as practicable. No later than seven (7) days after issuance, except as otherwise permitted, and every seven days thereafter, the Contractor shall report all costs to the Principal Representative and the Architect/Engineer. The final adjustment of the Emergency Field Change Order amount and the adjustment to the Project time for completion shall be prepared on a normal Change Order from (SC-6.31) in accordance with the procedures described in Article 35A, The Value of Changed Work, and B, Detailed Breakdown, above. Unless otherwise provided in writing signed by the Director of State Buildings Program to the Principal Representative and the Contractor, describing the extent and limits of any greater authority, individual Emergency Field Change Orders shall not be issued for more than $25,000, nor shall the cumulative value of Emergency Field Change Orders exceed an amount of $100,000. E. APPROPRIATION LIMITATIONS - § 24-91-103.6, C.R.S., as amended The amount of money appropriated, as shown on the Contractor’s Design/Bid/Build Agreement (SC 6.21), is equal to or in excess of the Contract amount. No Change Order, Emergency Field Change Order, or other type of order or directive shall be issued by the Principal Representative, or any agent acting on his or her behalf, which directs additional compensable Work to be performed, which Work causes the aggregate amount payable under the Contract to exceed the amount appropriated for the original Contract, as shown on the Agreement (SC-6.21), unless one of the following occurs: (1) the Contractor is provided written assurance from the Principal Representative that sufficient additional lawful appropriations exist to cover the cost of the additional Work; or (2) the Work is covered by a contractor remedy provision under the Contract, such as a claim for extra cost. By way of example only, no assurance is required for any order, directive or instruction by the Architect/Engineer or the Page 29 of 49 SC-6.23 Rev. 7/2015 Principal Representative to perform Work which is determined to be within the performance required by the Contract Documents; the Contractor’s remedy shall be as described elsewhere in these General Conditions. Written assurance shall be in the form of an Amendment to the Contract reciting the source and amount of such appropriation available for the Project. No remedy granting provision of this Contract shall obligate the Principal Representative to seek appropriations to cover costs in excess of the amounts recited as available to pay for the Work to be performed. ARTICLE 36. CLAIMS It is the intent of these General Conditions to provide procedures for speedy and timely resolution of disagreements and disputes at the lowest level possible. In the spirit of on the job resolution of job site issues, the parties are encouraged to use the partnering processes of Article 2D, Partnering, Communications and Cooperation, before turning to the more formal claims processes described in this Article 36, Claims. The use of non-binding dispute resolution, whether through the formal processes described in Article 39, Non-Binding Dispute Resolution – Facilitated Negotiations, or through less formal alternative processes developed as part of a partnering plan, are also encouraged. Where such process cannot resolve the issues in dispute, the claims process that follows is intended to cause the issues to be presented, decided and where necessary, documented in close proximity to the events from which the issues arise. To that end, and in summary of the remedy granting process that follows commencing with the next paragraph of this Article 36, Claims, the Contractor shall 1) first, seek a decision by the Architect/Engineer, and 2) shall second, informally present the claim to Principal Representative as described hereafter, and 3) failing resolution in the field, give Notice of intent to exercise statutory rights of review of a formal contract controversy, and 4) seek resolution outside the Contract as provided by the Procurement Code. If the Contractor claims that any instructions, by detailed drawings, or otherwise, or any other act or omission of the Architect/Engineer or Principal Representative affecting the scope of the Contractor’s Work, involve extra cost, extra time or changes in the scope of the Work under this Contract, the Contractor shall have the right to assert a claim for such costs or time, provided that before either proceeding to execute such Work (except in an emergency endangering life or property), or filing a Notice of claim, the Contractor shall have obtained or requested a written decision of the Architect/Engineer following the procedures as provided in Article 6A and B, Architect/Engineer Decisions and Judgments, respectively; provided, however, that in the case of a directed change in the Work pursuant to Article 36A4, no written judgment or decision of the Architect/Engineer is required. If the Contractor is delayed by the lack of a response to a request for a decision by the Architect/Engineer, the Contractor shall give Notice in accordance with Article 38, Delays and Extensions of Time. Unless it is the Architect/Engineer’s judgment and determination that the Work is not included in the performance required by the Contract Documents, the Contractor shall proceed with the Work as originally directed. Where the Contractor’s claim involves a dispute concerning the value of Work unilaterally directed pursuant to Article 35A3 the Contractor shall also proceed with the Work as originally directed while his or her claim is being considered. The Contractor shall give the Principal Representative and the Architect/Engineer Notice of any claim promptly after the receipt of the Architect/Engineer’s decision, but in no case later than three (3) business days after receipt of the Architect/Engineer’s decision (or no later than ten (10) days from the date of the Contractor's request for a decision when the Architect/Engineer fails to decide as provided in Article 6). The Notice of claim shall state the grounds for the claim and the amount of the claim to the extent known in accordance with the procedures of Article 35, Changes In The Work. The period in which Notice must be given may be extended by the Principal Representative if requested in writing by the Contractor with good cause shown, but any such extension to be effective shall be in writing. The Principal Representative shall respond in writing, with a copy to the Architect/Engineer, within a reasonable time, and except where a request for facilitation of negotiation has been made as hereafter provided, in no case later than seven (7) business days (or at such other time as the Contractor and Page 30 of 49 SC-6.23 Rev. 7/2015 Principal Representative agree) after receipt of the Contractor’s Notice of claim regarding such instructions or alleged act or omission. If no response to the Contractor’s claim is received within seven (7) business days of Contractor's Notice (or at such other time as the Contractor and Principal Representative agree) and the instructions have not been retracted, it shall be deemed that the Principal Representative has denied the claim. The Principal Representative may grant or deny the claim in whole or in part, and a Change Order shall be issued if the claim is granted. To the extent any portion of claim is granted where costs are not clearly shown, the Principal Representative may direct that the value of that portion of the Work be determined by any method allowed in Article 35A, The Value of Changed Work. Except in the case of a deemed denial, the Principal Representative shall provide a written explanation regarding any portion of the Contractor's claim that is denied. If the Contractor disagrees with the Principal Representative’s judgment and determination on the claim and seeks an equitable adjustment of the Contract sum or time for performance, he or she shall give Notice of intent to exercise his or her statutory right to seek a decision on the contract controversy within ten (10) days of receipt of the Principal Representative’s decision denying the claim. A “contract controversy," as such term is used in the Colorado Procurement Code, § 24-109-106, C.R.S., shall not arise until the initial claim process described above in this Article 36 has been properly exhausted by the Contractor. The Contractor's failure to proceed with Work directed by the Architect/Engineer or to exhaust the claim process provided above in this Article 36, shall constitute an abandonment of the claim by the Contractor and a waiver of the right to contest the decision in any forum. At the time of filing the Notice of intent to exercise his or her statutory right to seek a decision on the contract controversy, the Contractor may request that the Principal Representative defer a decision on the contract controversy until a later date or until the end of the Project. If the Principal Representative agrees, he or she shall so advise the Contractor in writing. If no such request is made, or if the Principal Representative does not agree to such a request, the Principal Representative shall render a written decision within twenty (20) business days and advise the Contractor of the reasons for any denial. Unless the claim has been decided by the Principal Representative (as opposed to delegates of the Principal Representative), the person who renders the decision on this statutory contract controversy shall not be the same person who decided the claim. To the extent any portion of the contract controversy is granted where costs are not clearly shown, the Principal Representative may direct that the value of that portion of the Work be determined by any method allowed in Article 35A, The Value of Changed Work. In the event of a denial the Principal Representative shall give Notice to the Contractor of his or her right to administrative and judicial reviews as provided in the Colorado Procurement Code, § 24-109-201 et seq, C.R.S., as amended. If no decision regarding the contract controversy is issued within twenty (20) business days of the Contractor's giving Notice (or such other date as the Contractor and Principal Representative have agreed), and the instructions have not been retracted or the alleged act or omission have not been corrected, it shall be deemed that the Principal Representative has ruled by denial on the contract controversy. Except in the case of a deemed denial, the Principal Representative shall provide an explanation regarding any portion of the contract controversy that involves denial of the Contractor’s claim. Either the Contractor or the Principal Representative may request facilitation of negotiations concerning the claim or the contract controversy, and if requested, the parties shall consult and negotiate before the Principal Representative decides the issue. Any request for facilitation by the Contractor shall be made at the time of the giving of Notice of the claim or Notice of the contract controversy. Facilitation shall extend the time for the Principal Representative to respond by commencing the applicable period at the completion of the facilitated negotiation, which shall be the last day of the parties’ meeting, unless otherwise agreed in writing. Disagreement with the decision of the Architect Engineer, or the decision of the Principal Representative to deny any claim or denying the contract controversy, shall not be grounds for the Contractor to refuse to perform the Work directed or to suspend or terminate performance. During the period that any claim or contract controversy decision is pending under this Article 36, Claims, the Contractor shall proceed diligently with the Work directed. Page 31 of 49 SC-6.23 Rev. 7/2015 In all cases where the Contractor proceeds with the Work and seeks equitable adjustment by filing a claim and or statutory appeal, the Contractor shall keep a correct account of the extra cost, in accordance with Article 35B, Detailed Breakdown supported by receipts. The Principal Representative shall be entitled to reject any claim or contract controversy whenever the foregoing procedures are not followed and such accounts and receipts are not presented. The payments to the Contractor in respect of such extra costs shall be limited to reimbursement for the current additional expenditure by the Contractor made necessary by the change in the Work, plus a reasonable amount for overhead and profit, determined in accordance with Article 35B, Detailed Breakdown, determined solely with reference to the additional Work, if any, required by the change. ARTICLE 37. DIFFERING SITE CONDITIONS A. NOTICE IN WRITING The Contractor shall promptly, and where possible before conditions are disturbed, give the Architect/Engineer and the Principal Representative Notice in writing of: 1. 2. subsurface or latent physical conditions at the site differing materially from those indicated in or reasonably assumed from the information provided in the Contract Documents; and, unknown physical conditions at the site, of an unusual nature, differing materially from those ordinarily encountered and generally recognized as inherent in Work of the character provided for in the Contract Documents. The Architect/Engineer shall promptly investigate the conditions, and if it is found that such conditions do materially so differ and cause an increase or decrease in the Contractor ’s costs of performance of any part of the Work required by the Contract Documents, whether or not such Work is changed as a result of such conditions, an equitable adjustment shall be made and the Contract sum shall be modified in accordance with Article 35, Changes In The Work. If the time required for completion of the Work affected by such materially differing conditions will extend the Work on the critical path as indicated on the CPM schedule, the time for completion shall also be equitably adjusted. B. LIMITATIONS No claim of the Contractor under this clause shall be allowed unless the Contractor has given the Notice required in Article 37A, Notice In Writing, above. The time prescribed for presentation and adjustment in Articles 36, Claims and 38, Delays And Extensions Of Time, shall be reasonably extended by the State to the extent required by the nature of the differing conditions; provided, however, that even when so extended no claim by the Contractor for an equitable adjustment hereunder shall be allowed if not quantified and presented prior to the date the Contractor requests a final inspection pursuant to Article 41A, Notice Of Completion. ARTICLE 38. DELAYS AND EXTENSIONS OF TIME If the Contractor is delayed at any time in the progress of the Work by any act or neglect of the State of Colorado or the Architect/Engineer, or of any employee or agent of either, or by any separately employed Contractor or by strikes, lockouts, fire, unusual delay in transportation, unavoidable casualties or any other causes beyond the Contractor’s control, including weather delays as defined below, the time of Completion of the Work shall be extended for a period equal to such portion of the period of delays directly affecting the completion of the Work as the Contractor shall be able to show he or she could not have avoided by the exercise of due diligence. The Contractor shall provide Notice in writing to the Architect/Engineer, the Principal Representative and State Buildings Program within three (3) business days from the beginning of such delay and shall file a written claim for an extension of time within seven (7) business days after the period of such delay has ceased, otherwise, any claim for an extension of time is waived. Page 32 of 49 SC-6.23 Rev. 7/2015 Provided that the Contractor has submitted reasonable schedules for approval when required by Article 12, Requests for Information and Schedules, if no schedule is agreed to fixing the dates on which the responses to requests for information or detail drawings will be needed, or Shop Drawings, Product Data or Samples are to be reviewed as required or allowed by Article 12B, Schedules, no extension of time will be allowed for the Architect/ Engineer’s failure to furnish such detail drawings as needed, or for the failure to initially review Shop Drawings, Product Data or Samples, except in respect of that part of any delay in furnishing detail drawings or instructions extending beyond a reasonable period after written demand for such detailed drawings or instructions is received by the Architect/Engineer. In any event, any claim for an extension of time for such cause will be recognized only to the extent of delay directly caused by failure to furnish detail drawings or instructions or to review Shop Drawings, Product Data or Samples pursuant to schedule, after such demand. All claims for extension of time due to a delay claimed to arise or result from ordered changes in the scope of the Work, or due to instructions claimed to increase the scope of the Work, shall be presented to the Architect/Engineer, the Principal Representative and State Buildings Program as part of a claim for extra cost, if any, in accordance with Article 36, Claims, and in accordance with the Change Order procedures required by Article 35, Changes In The Work. Except as otherwise provided in this paragraph, no extension of time shall be granted when the Contractor has failed to utilize a CPM schedule or otherwise identify the Project’s critical path as specified in Article 12, Requests for Information and Schedules, or has elected not to do so when allowed by the Supplementary General Conditions or the Specifications to use less sophisticated scheduling tools, or has failed to maintain such a schedule. Delay directly affecting the completion of the Work shall result in an extension of time only to the extent that completion of the Work was affected by impacts to the critical path shown on Contractor’s CPM schedule. Where the circumstances make it indisputable in the opinion of the Architect/Engineer that the delay affected the completion of the Work so directly that the additional notice of the schedule impact by reference to a CPM schedule was unnecessary, a reasonable extension of time may be granted. Extension of the time for completion of the Work will be granted for delays due to weather conditions only when the Contractor demonstrates that such conditions were more severe and extended than those reflected by the ten-year average for the month, as evidenced by the Climatological Data, U. S. Department of Commerce, for the Project area. Extensions of the time for completion of the Work due to weather will be granted on the basis of one and three tenths (1.3) calendar days for every day that the Contractor would have Worked but was unable to Work, with each separate extension figured to the nearest whole calendar day. For weather delays and delays caused by events, acts or omissions not within the control of the Principal Representative or any person acting on the Principal Representative’s behalf, the Contractor shall be entitled to an extension of time only and shall not be entitled to recovery of additional cost due to or resulting from such delays. This Article does not, however, preclude the recovery of damages for delay by either party under other provisions in the Contract Documents. ARTICLE 39. NON-BINDING DISPUTE RESOLUTION – FACILITATED NEGOTIATIONS The Contractor and Principal Representative agree to designate one or more mutually acceptable persons willing and able to facilitate negotiations and communications for the resolution of conflicts, disagreements or disputes between them at the specific request of either party with regard to any Project decision of either of them or any decision of the Architect/Engineer. The designation of such person(s) shall not carry any obligation to use their services except that each party agrees that if the other party requests the intervention of such person(s) with respect to any such conflict, dispute or disagreement, the non-requesting party shall participate in good faith attempts to negotiate a resolution of the issue in dispute. If the parties cannot agree on a mutually acceptable person to serve in this capacity one shall be so appointed; provided, however, that either party may request the director of State Buildings Program to appoint such a person, who, if appointed, shall be accepted for this purpose by both the Contractor and the Principal Representative. Page 33 of 49 SC-6.23 Rev. 7/2015 The cost, if any, of the facilitative services of the person(s) so designated shall be shared if the parties so agree in any partnering plan; or in the absence of agreement the cost shall be borne by the party requesting the facilitation of negotiation. Any dispute, claim, question or disagreement arising from or relating to the Contract or an alleged breach of the Contract may be subject to a request by either party for facilitated negotiation subject to the limitations hereafter listed, and the parties shall participate by consultation and negotiation with each other, as guided by the facilitator and with recognition of their mutual interests, in an attempt to reach an equitable solution satisfactory to both parties. The obligation to participate in facilitated negotiations shall be as described above and elsewhere in these General Conditions, as by way of example in Article 36, Claims, or Article 34, Deductions for Uncorrected Work and to the extent not more particularly described or limited elsewhere, each party’s obligations shall be as follows: 1. 2. 3. 4. 5. 6. 7. 8. 9. 10. a party shall not initiate communication with the facilitator regarding the issues in dispute; except that any request for facilitation shall be made in writing with copies sent, faxed or delivered to the other party; a party shall prepare a brief written description of its position if so requested by the facilitator (who may elect to first discuss the parties’ positions with each party separately in the interest of time and expense); a party shall respond to any reasonable request for copies of documents requested by the facilitator, but such requests, if voluminous, may consist of an offer to allow the facilitator access to the parties’ documents; a party shall review any meeting agenda proposed by a facilitator and endeavor to be informed on the subjects to be discussed; a party shall meet with the other party and the facilitator at a mutually acceptable place and time, or, if none can be agreed to, at the time and place designated by the facilitator for a period not to exceed four hours unless the parties agree to a longer period; a party shall endeavor to assure that any facilitation meeting shall be attended by any other persons in their employ that the facilitator requests be present, if reasonably available, including the Architect/Engineer; each party shall participate in such facilitated face-to-face negotiations of the issues in dispute through persons fully authorized to resolve the issue in dispute; each party shall be obligated to participate in negotiations requested by the other party and to perform the specific obligations described in paragraphs (1) through (10) this Article 39, Facilitated Negotiation, no more than three times during the course of the Project; neither party shall be under any obligation to resolve any issue by facilitated negotiation, but each agrees to participate in good faith and the Principal Representative shall direct the Architect/Engineer to appropriately document any resolution or agreement reached and to execute any Amendment or Change Order to the Contract necessary to implement their agreement; and, any discussions and documents prepared exclusively for use in the negotiations shall be deemed to be matters pertaining to settlement negotiations and shall not be subsequently available in further proceedings except to the extent of any documented agreement. In accordance with State Fiscal Rules and Article 52F, Choice of Law; No Arbitration, nothing in this Article 39 shall be deemed to call for arbitration or otherwise obligate the State to participate in any form of binding alternative dispute resolution. A partnering plan developed as described in Article 2D, Communications and Cooperation, may modify or expand the requirements of this Article but may not reduce the obligation to participate in facilitated negotiations when applicable. In the case of small projects estimated to be valued under $500,000, the requirements of this Article may be deleted from this Contract, by modification in Article 7 (Contractor’s Agreement SC-6.21), Optional Provisions And Elections. When so modified, the references to the parties’ right to elect facilitated negotiation elsewhere in these General Conditions shall be deleted. Page 34 of 49 SC-6.23 Rev. 7/2015 ARTICLE 40. RIGHT OF OCCUPANCY The Principal Representative shall have the right to take possession of and to use any completed or partially completed portions of the Work, even if the time for completing the entire Work or portions of the Work has not expired and even if the Work has not been finally accepted, and the Contractor shall fully cooperate with the Principal Representative to allow such possession and use. Such possession and use shall not constitute an acceptance of such portions of the Work. Prior to any occupancy of the Project, an inspection shall be made by the Principal Representative, State Buildings Program and the Contractor. Such inspection shall be made for the purpose of ensuring that the building is secure, protected by operation safety systems as designed, operable exits, power, lighting and HVAC systems, and otherwise ready for the occupancy intended and the Notice of Substantial Completion has been issued for the occupancy intended. The inspection shall also document existing finish conditions to allow assessment of any damage by occupants. The Contractor shall assist the Principal Representative in completing and executing State Form SBP-01, Approval of Occupancy/Use, prior to the Principal Representative’s possession and use. Any and all areas so occupied will be subject to a final inspection when the Contractor complies with Article 41, Completion, Final Inspection, Acceptance and Settlement. ARTICLE 41. COMPLETION, FINAL INSPECTION, ACCEPTANCE AND SETTLEMENT A. NOTICE OF COMPLETION When the Work, or a discrete physical portion of the Work (as hereafter described) which the Principal Representative has agreed to accept separately, is substantially complete and ready for final inspection, the Contractor shall file a written Notice with the Architect/Engineer that the Work, or such discrete physical portion, in the opinion of the Contractor, is substantially complete under the terms of the Contract. The Contractor shall prepare and submit with such Notice a comprehensive list of items to be completed or corrected prior to final payment, which shall be subject to review and additions as the Architect/Engineer or the Principal Representative shall determine after inspection. If the Architect/Engineer or the Principal Representative believe that any of the items on the list of items submitted, or any other item of Work to be corrected or completed, or the cumulative number of items of Work to be corrected or completed, will prevent a determination that the Work is substantially complete, those items shall be completed by the Contractor and the Notice shall then be resubmitted. B. FINAL INSPECTION Within ten (10) days after the Contractor files written Notice that the Work is substantially complete, the Architect/Engineer, the Principal Representative, and the Contractor shall make a “final inspection” of the Project to determine whether the Work is substantially complete and has been completed in accordance with the Contract Documents. State Buildings Program shall be notified of the inspection not less than three (3) business days in advance of the inspection. The Contractor shall provide the Principal Representative and the Architect/Engineer an updated punch list in sufficient detail to fully outline the following: 1. 2. Work to be completed, if any; and Work not in compliance with the Drawings or Specifications, if any. A final punch list shall be made by the Architect/Engineer in sufficient detail to fully outline to the Contractor: 1. 2. 3. Work to be completed, if any; Work not in compliance with the Drawings or Specifications, if any; and unsatisfactory Work for any reason, if any. The required number of copies of the final punch list will be countersigned by the authorized representative of the Principal Representative and will then be transmitted by the Architect/Engineer to the Contractor, the Principal Representative, and State Buildings Program. The Architect/Engineer's final punch list shall control over the Contractor's preliminary punch list. Page 35 of 49 SC-6.23 Rev. 7/2015 C. NOTICE OF SUBSTANTIAL COMPLETION Notice of Substantial Completion shall establish the date of substantial completion of the Project. The Contractor acknowledges and agrees that because the departments, agencies and institutions of the State of Colorado are generally involved with the business of the public at large, greater care must be taken in establishing the date of substantial completion than might otherwise be the case to ensure that a project or building or discrete physical portion of the Work is fully usable and safe for public use, and that such care necessarily raises the standard by which the concept of substantial completion is applied for a public building. The Notice of Substantial Completion shall not be issued until the following have been fully established: 1. 2. 3. 4. 5. All required building code inspections have been called for and the appropriate code officials have affixed their signatures to the Building Inspection Record indicating successful completion of all required code inspections; All required corrections noted on the Building Inspection Record shall have been completed unless the Architect/Engineer, the Principal Representative and State Buildings Program, in their complete and absolute discretion, all concur that the condition requiring the remaining correction is not in any way life threatening, does not otherwise endanger persons or property, and does not result in any undue inconvenience or hardship to the Principal Representative or the public; The building, structure or Project can be fully and comfortably used by the Principal Representative and the public without undue interference by the Contractor’s employees and Workers during the completion of the final punch list taking into consideration the nature of the public uses intended and taking into consideration any stage or level of completion of HVAC system commissioning or other system testing required by the Specifications to be completed prior to issuance of the Notice of Substantial Completion; The Project has been fully cleaned as required by these General Conditions, and as required by any stricter requirements of the Specifications, and the overall state of completion is appropriate for presentation to the public; and The Contractor has provided a schedule for the completion of each and every item identified on the punch list which specifies the Subcontractor or trade responsible for the Work, and the dates the completion or correction of the item will be commenced and finished; such schedule will show completion of all remaining final punch list items within the period indicated in the Contract for final punch list completion prior to Final Acceptance, with the exception of only those items which are beyond the control of the Contractor despite due diligence. The schedule shall provide for a reasonable punch list inspection process. Unless liquidated damages have been specified in Article 7.4 of the Contractor’s Design/Bid/Build Agreement SC-6.21), the cost to the Principal Representative, if any, for re-inspections due to failure to adhere to the Contractor’s proposed punch-list completion schedule shall be the responsibility of the Contractor and may be deducted by the Principal Representative from final amounts due to the Contractor. Substantial completion of the entire Project shall not be conclusively established by a decision by the Principal Representative to take possession and use of a portion, or all of the Project, where portions of the Project cannot meet all the criteria noted above. Notice of Substantial Completion for the entire Project shall, however, only be withheld for substantial reasons when the Principal Representative has taken possession and uses all of the Project in accordance with the terms of Article 40, Right Of Occupancy. Failure to furnish the required completion schedule shall constitute a substantial reason for withholding the issuance of any Notice of Substantial Completion. The Contractor shall have the right to request a final inspection of any discrete physical portion of the Project when in the opinion of the Principal Representative, The Architect/Engineer and State Buildings Program a final punch list can be reasonably prepared, without confusion as to which portions of the Project are referred to in any subsequent Notice of Partial Final Settlement which might be issued after such portion is finally accepted. Discrete physical portions of the Project may be, but Page 36 of 49 SC-6.23 Rev. 7/2015 shall not necessarily be limited to, such portions of the Project as separate buildings where a Project consists of multiple buildings. Similarly, an addition to an existing building where the Project also calls for renovation or remodeling of the existing building may constitute a discrete physical portion of the Project. In such circumstances, when in the opinion of the Principal Representative, the Architect/Engineer and State Buildings Program, the requirements for issuance of a Notice of Substantial Completion can be satisfied with respect to the discrete portion of the Project, a partial Notice of Substantial Completion may be issued for such discrete physical portion of the Project. D. NOTICE OF ACCEPTANCE The Notice of Acceptance shall establish the completion date of the Project. It shall not be authorized until the Contractor shall have performed all of the Work to allow completion and approval of the PreAcceptance Checklist (SBP-05). Where partial Notices of Substantial Completion have been issued, partial Notices of Final Acceptance may be similarly issued when appropriate for that portion of the Work. Partial Notice of Final Acceptance may also be issued to exclude the Work described in Change Orders executed during late stages of the Project where a later completion date for the Change Ordered Work is expressly provided for in the Contract as amended by the Change Order, provided the Work can be adequately described to allow partial advertisement of any Notice of Partial Final Settlement to be issued without confusion as to the Work included for which final payment will be made. E. SETTLEMENT Final payment and settlement shall be made on the date fixed and published for such payment except as hereafter provided. The Principal Representative shall not authorize final payment until all items on the Pre-Acceptance check list (SBP-05) have been completed, the Notice of Acceptance issued, and the Notice of Contractors Settlement published. If the Work shall be substantially completed, but Final Acceptance and completion thereof shall be prevented through delay in correction of minor defects, or unavailability of materials or other causes beyond the control of the Contractor, the Principal Representative in his or her discretion may release all amounts due to the Contractor except such amounts as may be in excess of three times the cost of completing the unfinished Work or the cost of correcting the defective Work, as estimated by the Architect/Engineer and approved by State Buildings Program. Before the Principal Representative may issue the Notice of Contractor’s Settlement and advertise the Project for final payment, the Contractor shall have corrected all items on the punch list except those items for which delayed performance is expressly permitted, subject to withholding for the cost thereof, and shall have: 1. Delivered to the Principal Representative: a. b. c. d. All guarantees and warranties; All statements to support local sales tax refunds, if any; Three (3) complete bound sets of required operating maintenance instructions; and, One (1) set of hard copy as-built Contract Documents, and one (1) electronic copy showing all job changes. 2. Demonstrated to the operating personnel of the Principal Representative the proper operation and maintenance of all equipment. 3. Delivered to the State of Colorado Department of Personnel & Administration in accordance with C.R.S. § 24-103-210: a. A written disclosure of the five most costly goods incorporated into the project, including iron, steel, or related manufactured goods and the total cost and country of origin of those five goods and whether the project was subject to any existing domestic content preferences. Page 37 of 49 SC-6.23 Rev. 7/2015 Upon completion of the foregoing the Project shall be advertised in accordance with the Notice of Contractor’s Settlement by two publications of Notice, the last publication appearing at least ten (10) days prior to the time of final settlement. Publication and final settlement should not be postponed or delayed solely by virtue of unresolved claims against the Project or the Contractor from Subcontractors, suppliers or materialmen based on good faith disputes; the resolution of the question of payment in such cases being directed by statute. Except as hereafter provided, on the date of final settlement thus advertised, provided the Contractor has submitted a written Notice to the Architect/Engineer that no claims have been filed, and further provided the Principal Representative shall have received no claims, final payments and settlement shall be made in full. If any unpaid claim for labor, materials, rental machinery, tools, supplies or equipment is filed before payment in full of all sums due the Contractor, the Principal Representative and the State Controller shall withhold from the Contractor on the date established for final settlement, sufficient funds to insure the payment of such claim, until the same shall have been paid or withdrawn, such payment or withdrawal to be evidenced by filing a receipt in full or an order for withdrawal signed by the claimant or his or her duly authorized agent or assignee. The amount so withheld may be in the amount of 125% of the claims or such other amount as the Principal Representative reasonably deems necessary to cover expected legal expenses. Such withheld amounts shall be in addition to any amount withheld based on the cost to compete unfinished Work or the cost to repair defective Work. However, as provided by statute, such funds shall not be withheld longer than ninety (90) days following the date fixed for final settlement with the Contractor, as set forth in the published Notice of Contractor’s Settlement, unless an action at law shall be commenced within that time to enforce such unpaid claim and a Notice of such action at law shall have been filed with the Principal Representative and the State Controller. At the expiration of the ninety (90) day period, the Principal Representative shall authorize the State Controller to release to the Contractor all other money not the subject of such action at law or withheld based on the cost to compete unfinished Work or the cost to repair defective Work. Notices of Partial Final Settlement may be similarly advertised, provided all conditions precedent have been satisfied as though that portion of the Work affected stood alone, a Notice of Partial Acceptance has been issued, and the consent of surety to the partial final settlement has been obtained in writing. Thereafter, partial final payments may be made to the Contractor subject to the same conditions regarding unpaid claims. ARTICLE 42. GENERAL WARRANTY AND CORRECTION OF WORK AFTER ACCEPTANCE The Contractor warrants that the materials used and the equipment furnished shall be new and of good quality unless specified to the contrary. The Contractor further warrants that the Work shall, in all respects, be free from material defects not permitted by the Specifications and shall be in accordance with the requirements of the Contract Documents. Neither the final certificate for payment nor any provision in the Contract Documents shall relieve the Contractor of responsibility for defects or faulty materials or Workmanship. The Contractor shall be responsible to the Principal Representative for such warranties for the longest period permitted by any applicable statute of limitations. In addition to these general warranties, and without limitation of these general warranties, for a period of one year after the date of any Notice of Substantial Completion, or any Notice of Partial Substantial Completion if applicable, the Contractor shall remedy defects, and faulty Workmanship or materials, and Work not in accordance with the Contract Documents which was not accepted at the time of the Notice of Final Acceptance, all in accordance with the provisions of Article 44, One-Year Guarantee And Special Guarantees And Warranties. ARTICLE 43. LIENS Colorado statutes do not provide for any right of lien against public buildings. In lieu thereof, § 38-26-107, C.R.S., provides adequate relief for any claimant having furnished labor, materials, rental machinery, tools, equipment, or services toward construction of the particular public Work in that final payment may not be made to a Contractor until all such creditors have been put on Notice by publication in the public press of Page 38 of 49 SC-6.23 Rev. 7/2015 such pending payment and given opportunity for a period of up to ninety (90) days to stop payment to the Contractor in the amount of such claims. ARTICLE 44. ONE-YEAR GUARANTEE AND SPECIAL GUARANTEES AND WARRANTIES C. A. ONE-YEAR GUARANTEE OF THE WORK The Contractor shall guarantee to remedy defects and repair or replace the Work for a period of one year from the date of the Notice of Substantial Completion or from the dates of any partial Notices of Substantial Completion issued for discrete physical portions of the Work. The Contractor shall remedy any defects due to faulty materials or Workmanship and shall pay for, repair and replace any damage to other Work resulting there from, which shall appear within a period of one year from the date of such Notice(s) of Substantial Completion. The Contractor shall also remedy any deviation from the requirements of the Contract Documents which shall later be discovered within a period of one year from the date of the Notice of Substantial Completion; provided, however, that the Contractor shall not be required to remedy deviations from the requirements of the Contract Documents where such deviations were obvious, apparent and accepted by the Architect/Engineer or the Principal Representative at the time of the Notice of Final Acceptance. The Principal Representative shall give Notice of observed defects or other Work requiring correction with reasonable promptness. Such Notice shall be in writing to the Architect/Engineer and the Contractor. The one year guarantee of the Contractor’s Work may run separately for discrete physical portions of the Work for which partial Notices of Substantial Completion have been issued, however, it shall run from the last Notice of Substantial Completion with respect to all or any systems common to the Work to which more than one Notice of Substantial Completion may apply. This one-year guarantee shall not be construed to limit the Contractor’s general warranty described in Article 42, General Warranty and Correction of Work After Acceptance, that all materials and equipment are new and of good quality, unless specified to the contrary, and that the Work shall in all respects be free from material defects not permitted by the Specifications and in accordance with the requirements of the Contract Documents. B. SPECIAL GUARANTEES AND WARRANTIES In case of Work performed for which product, manufacturers or other special warranties are required by the Specifications, the Contractor shall secure the required warranties and deliver copies thereof to the Principal Representative through the Architect/Engineer upon completion of the Work. These product, manufacturers or other special warranties, as such, do not in any way lessen the Contractor’s responsibilities under the Contract. Whenever guarantees or warranties are required by the Specifications for a longer period than one year, such longer period shall govern. ARTICLE 45. GUARANTEE INSPECTIONS AFTER COMPLETION The Architect/Engineer, the Principal Representative and the Contractor together shall make at least two (2) complete inspections of the Work after the Work has been determined to be substantially complete and accepted. One such inspection, the “Six-Month Guarantee Inspection,” shall be made approximately six (6) months after date of the Notice of Substantial Completion, unless in the case of smaller projects valued under $500,000 this inspection is declined in Article 7A (Contractor’s Agreement SC-6.21), Modification of Article 45, in which case the inspection to occur at six months shall not be required. Another such inspection, the “Eleven-Month Guaranty Inspection” shall be made approximately eleven (11) months after the date of the Notice of Substantial Completion. The Contractor shall schedule and so notify all parties concerned, and the Principal Representative shall so notify State Buildings Program, of these inspections. If more than one Notice of Substantial Completion has been issued at the reasonable discretion of the Principal Representative separate eleven month inspections may be required where the one year guarantees do not run reasonably concurrent. Written punch lists and reports of these inspections shall be made by the Architect/Engineer and forwarded to the Contractor, the Principal Representative, State Buildings Program, and all other participants within ten (10) days after the completion of the inspections. The punch list shall itemize all guarantee items, prior Page 39 of 49 SC-6.23 Rev. 7/2015 punch list items still to be corrected or completed and any other requirements of the Contract Documents to be completed which were not waived by final acceptance because they were not obvious or could not reasonably have been previously observed. The Contractor shall immediately initiate such remedial Work as may be necessary to correct any deficiencies or defective Work shown by this report, and shall promptly complete all such remedial Work in a manner satisfactory to the Architect/Engineer, the Principal Representative and State Buildings Program. If the Contractor fails to promptly correct all deficiencies and defects shown by this report, the Principal Representative may do so, after giving the Contractor ten (10) days written Notice of intention to do so. The State of Colorado, acting by and through the Principal Representative, shall be entitled to collect from the Contractor all costs and expenses incurred by it in correcting such deficiencies and defects, as well as all damages resulting from such deficiencies and defects. ARTICLE 46. TIME OF COMPLETION AND LIQUIDATED DAMAGES It is hereby understood and mutually agreed, by and between the parties hereto, that the date of beginning, rate of progress, and the time for completion of the Work to be done hereunder are ESSENTIAL CONDITIONS of this Agreement, and it is understood and agreed that the Work embraced in this Contract shall be commenced at the time specified in the Notice to Proceed (SC-6.26). It is further agreed that time is of the essence of each and every portion of this Contract, and of any portion of the Work described on the Drawings or Specifications, wherein a definite and certain length of time is fixed for the performance of any act whatsoever. The parties further agree that where under the Contract additional time is allowed for the completion of the Work or any identified portion of the Work, the new time limit or limits fixed by such extension of the time for completion shall be of the essence of this Agreement. The Contractor acknowledges that subject to any limitations in the Advertisement for Bids, issued for the Project, the Contractor’s bid is consistent with and considers the number of days to substantially complete the Project and the number of days to finally complete the Project to which the parties may have stipulated in the Agreement, which stipulation was based on the Contractor’s bid. The Contractor agrees that Work shall be prosecuted regularly, diligently and uninterruptedly at such rate of progress as will ensure the Project will be substantially complete, and fully and finally complete, as recognized by the issuance of all required Notices of Substantial Completion and Notices of Final Acceptance, within any times stipulated and specified in the Agreement, as the same may be amended by Change Order or other written modification, and that the Principal Representative will be damaged if the times of completion are delayed. It is expressly understood and agreed, by and between the parties hereto, that the times for the Substantial Completion of the Work or for the final acceptance of the Work as may be stipulated in the Agreement, and as applied here and in Article 7.4 of the Contractor’s Design/Bid/Build Agreement SC-6.21), Modifications of Article 46, are reasonable times for these stages of completion of the Work, taking into such consideration all factors, including the average climatic range and usual industrial conditions prevailing in the locality of the building operations. If the Contractor shall neglect, fail or refuse to complete the Work within the times specified in the Agreement, such failure shall constitute a breach of the terms of the Contract and the State of Colorado, acting by and through the Principal Representative, shall be entitled to liquidated damages for such neglect, failure or refusal, as specified in Article 7.4 of the Contractor’s Design/Bid/Build Agreement SC-6.21, Modification of Article 46. The Contractor and the Contractor’s Surety shall be jointly liable for and shall pay the Principal Representative, or the Principal Representative may withhold, the sums hereinafter stipulated as liquidated damages for each calendar day of delay until the entire Project is 1) substantially completed, and the Notice (or all Notices) of Substantial Completion are issued, 2) finally complete and accepted and the Notice (or all Notices) of Acceptance are issued, or 3) both. Delay in substantial completion shall be measured from the Date of the Notice to Proceed and delay in final completion and acceptance shall be measured from the Date of the Notice of Substantial Completion. Page 40 of 49 SC-6.23 Rev. 7/2015 In the first instance, specified in Article 7.4.1 of the Contractor’s Design/Bid/Build Agreement SC-6.21, Modification of Article 46, liquidated damages, if any, shall be the amount specified therein, for each calendar day of delay beginning after the stipulated number of days for Substantial Completion from the date of the Notice to Proceed, until the date of the Notice of Substantial Completion. Unless otherwise specified in any Supplementary General Conditions, in the event of any partial Notice of Substantial Completion, liquidated damages shall accrue until all required Notices of Substantial Completion are issued. In the second instance, specified in Article 7.4.2 of the Contractor’s Design/Bid/Build Agreement SC-6.21, Modification of Article 46, liquidated damages, if any, shall be the amount specified in Article 7.4.2 of the Contractor’s Design/Bid/Build Agreement SC-6.21, Modification of Article 46, for each calendar day in excess of the number of calendar days specified in the Contractor’s bid for the Project and stipulated in the Agreement to finally complete the Project (as defined by the issuance of the Notice of Acceptance) after the final Notice of Substantial Completion has been issued. In the third instance, when so specified in both Articles 7.4.1 and 7.4.2 of the Contractor’s Agreement SC6.21, both types of liquidated damages shall be separately assessed where those delays have occurred. The parties expressly agree that said amounts are a reasonable estimate of the presumed actual damages that would result from any of the breaches listed, and that any liquidated damages that are assessed have been agreed to in light of the difficulty of ascertaining the actual damages that would be caused by any of these breaches at the time this Contract was formed; the liquidated damages in the first instance representing an estimate of damages due to the inability to use the Project; the liquidated damages in the second instance representing an estimate of damages due to the additional administrative, technical, supervisory and professional expenses related to and arising from the extended closeout period including delivery of any or all guarantees and warranties, the submittals of sales and use tax payment forms, the calling for the final inspection and the completion of the final punch list. The parties also agree and understand that the liquidated damages to be assessed in each instance are separate and distinct, although potentially cumulative, damages for the separate and distinct breaches of delayed substantial completion or final acceptance. Such liquidated damages shall not be avoided by virtue of the fact of concurrent delay caused by the Principal Representative, or anyone acting on behalf of the Principal Representative, but in such event the period of delay for which liquidated damages are assessed shall be equitably adjusted in accordance with Article 38, Delays And Extensions Of Time. ARTICLE 47. DAMAGES If either party to this Contract shall suffer damage under this Contract in any manner because of any wrongful act or neglect of the other party or of anyone employed by either of them, then the party suffering damage shall be reimbursed by the other party for such damage. Except to the extent of damages liquidated for the Contractor’s failure to achieve timely completion as set forth in Article 46, Time of Completion and Liquidated Damages, the Principal Representative shall be responsible for, and at his or her option may insure against, loss of use of any existing property not included in the Work, due to fire or otherwise, however caused. Notwithstanding the foregoing, or any other provision of this Contract, to the contrary, no term or condition of this contract shall be construed or interpreted as a waiver, express or implied, of any of the immunities, rights, benefits, protection, or other provisions of the Colorado Governmental Immunity Act, Section 24-10-101, et seq., CRS, as now or hereafter amended. The parties understand and agree that liability for claims for injuries to persons arising out of negligence of the State of Colorado, its departments, institutions, agencies, boards, officials and employees is controlled and limited by the provisions of Section 24-101-101, et seq., CRS, as now or hereafter amended and the risk management statutes, Section 24-30-1501, et seq., CRS, as now or hereafter amended. Notice of intent to file a claim under this clause shall be made in writing to the party liable within a reasonable time of the first observance of such damage and not later than the time of final payment, except that in the case of claims by the Principal Representative involving warranties against faulty Work or materials Notice shall be required only to the extent stipulated elsewhere in these General Conditions. Claims made to the Principal Representative involving extra cost or extra time arising by virtue of instructions to the Contractor to which Article 36, Claims, applies shall be made in accordance with Article Page 41 of 49 SC-6.23 Rev. 7/2015 36. Other claims arising under the Contract involving extra cost or extra time which are made to the Principal Representative under this clause shall also be made in accordance with the procedures of Article 36, whether or not arising by virtue of instructions to the Contractor; provided however that it shall not be necessary to first obtain or request a written judgment of the Architect/Engineer. Provided written Notice of intent to file a claim is provided as required in the preceding paragraph, nothing in this Article shall limit or restrict the rights of either party to bring an action at law or to seek other relief to which either party may be entitled, including consequential damages, if any, and shall not be construed to limit the time during which any action might be brought. Nothing in these General Conditions shall be deemed to limit the period of time during which any action may be brought as a matter of contract, tort, warranty or otherwise, it being the intent of the parties to allow any and all actions at law or in equity for such periods as the law permits. All such rights shall, however be subject to the obligation to assert claims and to appeal denials pursuant to Article 36, Claims, where applicable. STATE’S RIGHT TO DO THE WORK; TEMPORARY SUSPENSION OF WORK; DELAY DAMAGES STATE’S RIGHT TO DO THE WORK If after receipt of Notice to do so, the Contractor should neglect to prosecute the Work properly or fail to perform any provision of the Contract, the Principal Representative, after a second seven (7) days’ advance written Notice to the Contractor and the Surety may, without prejudice to any other remedy the Principal Representative may have, take control of all or a portion of the Work, as the Principal Representative deems necessary and make good such deficiencies deducting the cost thereof from the payment then or thereafter due the Contractor, as provided in Article 30, Correction Of Work Before Acceptance and Article 33, Payments Withheld, provided, however, that the Architect/Engineer shall approve the amount charged to the Contractor by approval of the Change Order. ARTICLE 48. A. B. TEMPORARY SUSPENSION OF WORK The State, acting for itself or by and through the Architect/Engineer, shall have the authority to suspend the Work, either wholly or in part, for such period or periods as may be deemed necessary due to: 1. 2. 3. 4. 5: 6. Unsuitable weather; Faulty Workmanship; Improper superintendence or project management; Contractor’s failure to carry out orders or to perform any provision of the Contract Documents; Loss of, or restrictions to, appropriations; Conditions, which may be considered unfavorable for the prosecution of the Work. If it should become necessary to stop Work for an indefinite period, the Contractor shall store materials in such manner that they will not become an obstruction or become damaged in any way; and he or she shall take every precaution to prevent damage to or deterioration of the Work, provide suitable drainage and erect temporary structures where necessary. Notice of suspension of Work shall be provided to the Contractor in writing stating the reasons therefore. The Contractor shall again proceed with the Work when so notified in writing. The Contractor understands and agrees that the State of Colorado cannot predict with certainty future revenues and could ultimately lack the revenue to fund the appropriations applicable to this Contract. The Contractor further acknowledges and agrees that in such event that State may, upon Notice to the Contractor, suspend the Work in anticipation of a termination of the Contract for the convenience of the State, pursuant to Article 50, Termination For Convenience of State. If the Contract is not so terminated the Contract sum and the Contract time shall be equitably adjusted at the time the Principal Representative directs the Work to be recommenced and gives Notice that the revenue to fund the appropriation is available. Page 42 of 49 SC-6.23 Rev. 7/2015 C. DELAY DAMAGES The Principal Representative and the State of Colorado shall be liable to the Contractor for the payment of any claim for extra costs, extra compensation or damages occasioned by hindrances or delays encountered in the Work only when and to the limited extent that such hindrance or delay is caused by an act or omission within the control of the Principal Representative, the Architect/Engineer or other persons or entities acting on behalf of the Principal Representative. Further, the Principal Representative and the State of Colorado shall be liable to the Contractor for the payment of such a claim only if the Contractor has provided required Notice of the delay or impact, or has presented its claim for an extension of time or claim of other delay or other impact due to changes ordered in the Work before proceeding with the changed Work. Except as otherwise provided, claims for extension of time shall be Noticed and filed in accordance with Article 38, Delays and Extensions of Time, within three (3) business days of the beginning of the delay with any claim filed within seven (7) days after the delay has ceased, or such claim is waived. Claims for extension of time or for other delay or other impact resulting from changes ordered in the Work shall be presented and adjusted as provided in Article 35, Changes in the Work. ARTICLE 49. STATE’S RIGHTS TO TERMINATE CONTRACT A. GENERAL If the Contractor should be adjudged bankrupt, or if he or she should make a general assignment for the benefit of his or her creditors, or if a receiver should be appointed to take over his affairs, or if he or she should fail to prosecute his or her Work with due diligence and carry the Work forward in accordance with the construction schedule and the time limits set forth in the Contract Documents, or if he or she should fail to subsequently perform one or more of the provisions of the Contract Documents to be performed by him, the Principal Representative may serve written Notice on the Contractor and the Surety on performance and payment bonds, stating his or her intention to exercise one of the remedies hereinafter set forth and the grounds upon which the Principal Representative bases his or her right to exercise such remedy. In such event, unless the matter complained of is satisfactorily cleared within ten (10) days after delivery of such Notice, the Principal Representative may, without prejudice to any other right or remedy, exercise one of such remedies at once, having first obtained the concurrence of the Architect/Engineer in writing that sufficient cause exists to justify such action. B. CONDITIONS AND PROCEDURES 1. The Principal Representative may terminate the services of the Contractor, which termination shall take effect immediately upon service of Notice thereof on the Contractor and his or her Surety, whereupon the Surety shall have the right to take over and perform the Contract. If the Surety does not provide Notice to the Principal Representative of its intent to commence performance of the Contract within ten (10) days after delivery of the Notice of termination, the Principal Representative may take over the Work, take possession of and use all materials, tools, equipment and appliances on the premises and prosecute the Work to completion by such means as he or she shall deem best. In the event of such termination of his or her service, the Contractor shall not be entitled to any further payment under the Contract until the Work is completed and accepted. If the Principal Representative takes over the Work and if the unpaid balance of the contract price exceeds the cost of completing the Work, including compensation for any damages or expenses incurred by the Principal Representative through the default of the Contractor, such excess shall be paid to the Contractor. If, however, the cost, expenses and damages as certified by the Architect/Engineer exceed such unpaid balance of the contract price, the Contractor and his or her Surety shall pay the difference to the Principal Representative. 2. The Principal Representative may require the Surety on the Contractor ’s bond to take control of the Work and see to it that all the deficiencies of the Contractor are made good, with due diligence within ten (10) days of delivery of Notice to the Surety to do so. As between the Principal Representative and the Surety, the cost of making good such deficiencies shall all be borne by the Surety. If the Surety takes over the Work, either by election upon termination of the services of the Contractor pursuant to Section B(1) of this Article 49, State's Right To Page 43 of 49 SC-6.23 Rev. 7/2015 3. C. Terminate Contract, or upon instructions from the Principal Representative to do so, the provisions of the Contract Documents shall govern the Work to be done by the Surety, the Surety being substituted for the Contractor as to such provisions, including provisions as to payment for the Work, the times of completion and provisions of this Article as to the right of the Principal Representative to do the Work or to take control of all or a portion of the Work. The Principal Representative may take control of all or a portion of the Work and make good the deficiencies of the Contractor, or the Surety if the Surety has been substituted for the Contractor, with or without terminating the Contract, employing such additional help as the Principal Representative deems advisable in accordance with the provisions of Article 48A, State's Right To Do The Work; Temporary Suspension Of Work; Delay Damages. In such event, the Principal Representative shall be entitled to collect from the Contractor and his or her Surety, or to deduct from any payment then or thereafter due the Contractor, the costs incurred in having such deficiencies made good and any damages or expenses incurred through the default of Contractor, provided the Architect/Engineer approves the amount thus charged to the Contractor. If the Contract is not terminated, a Change Order to the Contract shall be executed, unilaterally if necessary, in accordance with the procedures of Article 35, Changes In The Work. ADDITIONAL CONDITIONS If any termination by the Principal Representative for cause is later determined to have been improper, the termination shall be automatically converted to and deemed to be a termination by the Principal Representative for convenience and the Contractor shall be limited in recovery to the compensation provided for in Article 50, Termination For Convenience Of State. Termination by the Contractor shall not be subject to such conversion. ARTICLE 50. TERMINATION FOR CONVENIENCE OF STATE A. NOTICE OF TERMINATION The performance of Work under this Contract may be terminated, in whole or from time to time in part, by the State whenever for any reason the Principal Representative shall determine that such termination is in the best interest of State. Termination of Work hereunder shall be effected by delivery to the Contractor of a Notice of such termination specifying the extent to which the performance of Work under the Contract is terminated and the date upon which such termination becomes effective. B. PROCEDURES After receipt of the Notice of termination, the Contractor shall, to the extent appropriate to the termination, cancel outstanding commitments hereunder covering the procurement of materials, supplies, equipment and miscellaneous items. In addition, the Contractor shall exercise all reasonable diligence to accomplish the cancellation or diversion of all applicable outstanding commitments covering personal performance of any Work terminated by the Notice. With respect to such canceled commitments, the Contractor agrees to: 1. 2. settle all outstanding liabilities and all claims arising out of such cancellation of commitments, with approval or ratification of the Principal Representative, to the extent he or she may require, which approval or ratification shall be final for all purposes of this clause; and, assign to the State, in the manner, at the time, and to the extent directed by the Principal Representative, all of the right, title, and interest of the Contractor under the orders and subcontracts so terminated, in which case the State shall have the right, in its discretion, to settle or pay any or all claims arising out of the termination of such orders and subcontracts. The Contractor shall submit his or her termination claim to the Principal Representative promptly after receipt of a Notice of termination, but in no event later than three (3) months from the effective date thereof, unless one or more extensions in writing are granted by the Principal Representative upon written request of the Contractor within such three month period or authorized extension thereof. Upon failure of the Contractor to submit his or her termination claim within the time allowed, the Principal Representative may determine, on the basis of information available to him, the amount, if Page 44 of 49 SC-6.23 Rev. 7/2015 any, due to the Contractor by reason of the termination and shall thereupon pay to the Contractor the amount so determined. Costs claimed, agreed to, or determined pursuant to the preceding and following paragraph shall be in accordance with the provisions of § 24-107-101, C.R.S., as amended and associated Cost Principles of the Colorado Procurement Rules as in effect on the date of this Contract. Subject to the preceding provisions, the Contractor and the Principal Representative may agree upon the whole or any part of the amount or amounts to be paid to the Contractor by reason of the termination under this clause, which amount or amounts may include any reasonable cancellation charges thereby incurred by the Contractor and any reasonable loss upon outstanding commitments for personal services which he or she is unable to cancel; provided, however, that in connection with any outstanding commitments for personal services which the Contractor is unable to cancel, the Contractor shall have exercised reasonable diligence to divert such commitments to other activities and operations. Any such agreement shall be embodied in an Amendment to this Contract and the Contractor shall be paid the agreed amount. The State may from time to time, under such terms and conditions as it may prescribe, make partial payments against costs incurred by the Contractor in connection with the termination portion of this Contract, whenever, in the opinion of the Principal Representative, the aggregate of such payments is within the amount to which the Contractor will be entitled hereunder. The Contractor agrees to transfer title and deliver to the State, in the manner, at the time, and to the extent, if any, directed by the Principal Representative, such information and items which, if the Contract had been completed, would have been required to be furnished to the State, including: a. b. completed or partially completed plans, Drawings and information; and, materials or equipment produced or in process or acquired in connection with the performance of the Work terminated by the Notice. Other than the above, any termination inventory resulting from the termination of the Contract may, with written approval of the Principal Representative, be sold or acquired by the Contractor under the conditions prescribed by and at a price or prices approved by the Principal Representative. The proceeds of any such disposition shall be applied in reduction of any payments to be made by the State to the Contractor under this Contract or shall otherwise be credited to the price or cost of Work covered by this Contract or paid in such other manners as the Principal Representative may direct. Pending final disposition of property arising from the termination, the Contractor agrees to take such action as may be necessary, or as the Principal Representative may direct, for the protection and preservation of the property related to this Contract which is in the possession of the Contractor and in which the State has or may acquire an interest. Any disputes as to questions of fact, which may arise hereunder, shall be subject to the Remedies provisions of the Colorado Procurement Code, §§ 24-109-101, et seq., C.R.S., as amended. ARTICLE 51. CONTRACTOR’S RIGHT TO STOP WORK AND/OR TERMINATE CONTRACT If the Work shall be stopped under an order of any court or other public authority for a period of three (3) months through no act or fault of the Contractor or of any one employed by him, then the Contractor may on seven (7) days’ written Notice to the Principal Representative and the Architect/Engineer stop Work or terminate this Contract and recover from the Principal Representative payment for all Work executed, any losses sustained on any plant or material, and a reasonable profit only for the Work completed. If the Architect/Engineer shall fail to issue or otherwise act in writing upon any certificate for payment within ten (10) days after it is presented and received by the Architect/Engineer, as provided in Article 31, Applications For Payments, or if the Principal Representative shall fail to pay the Contractor any sum certified that is not disputed in whole or in part by the Principal Representative in writing to the Contractor and the Architect/Engineer within thirty (30) days after the Architect/Engineer’s certification, then the Contractor may Page 45 of 49 SC-6.23 Rev. 7/2015 on ten (10) days’ written Notice to the Principal Representative and the Architect/Engineer stop Work and/or give written Notice of intention to terminate this Contract. If the Principal Representative shall thereafter fail to pay the Contractor any amount certified by the Architect/Engineer and not disputed in writing by the Principal Representative within ten (10) days after receipt of such Notice, then the Contractor may terminate this Contract and recover from the Principal Representative payment for all Work executed, any losses sustained upon any plant or materials, and a reasonable profit only for the Work completed. The Principal Representative’s right to dispute an amount certified by the Architect/Engineer shall not relieve the Principal Representative of the obligation to pay amounts not in dispute as certified by the Architect/Engineer. ARTICLE 52. SPECIAL PROVISIONS A. CONTROLLER’S APPROVAL CRS 24-30-202(1) This Contract shall not be deemed valid until it has been approved by the Colorado State Controller or designee. B. FUND AVAILABILITY CRS 24-30-202(5.5) Financial obligations of the State payable after the current fiscal year are contingent upon funds for that purpose being appropriated, budgeted, and otherwise made available C. GOVERNMENTAL IMMUNITY No term or condition of this contract shall be construed or interpreted as a waiver, express or implied, of any of the immunities, rights, benefits, protections, or other provisions, of the Colorado Governmental Immunity Act, CRS §24-10-101 et seq., or the Federal Tort Claims Act, 28 U.S.C. §§1346(b) and 2671 et seq., as applicable now or hereafter amended. D. INDEPENDENT CONTRACTOR 4 CCR 801-2 Contractor shall perform its duties hereunder as an independent contractor and not as an employee. Neither Contractor nor any agent or employee of Contractor shall be deemed to be an agent or employee of the State. Contractor and its employees and agents are not entitled to unemployment insurance or orkers compensation benefits through the State and the State shall not pay for or otherwise provide such coverage for Contractor or any of its agents or employees. Unemployment insurance benefits will be available to Contractor and its employees and agents only if such coverage is made available by Contractor or a third party. Contractor shall pay when due all applicable employment taxes and income taxes and local head taxes incurred pursuant to this contract. Contractor shall not have authorization, express or implied, to bind the State to any agreement, liability or understanding, except as expressly set forth herein. Contractor shall (a) provide and keep in force workers' compensation and unemployment compensation insurance in the amounts required by law, (b) provide proof thereof when requested by the State, and (c) be solely responsible for its acts and those of its employees and agents. E. COMPLIANCE WITH LAW Contractor shall strictly comply with all applicable federal and State laws, rules, and regulations in effect or hereafter established, including, without limitation, laws applicable to discrimination and unfair employment practices. F. CHOICE OF LAW Colorado law, and rules and regulations issued pursuant thereto, shall be applied in the interpretation, execution, and enforcement of this contract. Any provision included or incorporated herein by reference which conflicts with said laws, rules, and regulations shall be null and void. Any provision incorporated herein by reference which purports to negate this or any other Special Provision in whole or in part shall not be valid or enforceable or available in any action at law, whether by way of complaint, defense, or otherwise. Any provision rendered null and void by the operation of this provision shall not invalidate the remainder of this contract, to the extent capable of execution. Page 46 of 49 SC-6.23 Rev. 7/2015 G. BINDING ARBITRATION PROHIBITED The State of Colorado does not agree to binding arbitration by any extra-judicial body or person. Any provision to the contrary in this contract or incorporated herein by reference shall be null and void. H. SOFTWARE PIRACY PROHIBITION. Governor’s Executive Order D 002 00 State or other public funds payable under this contract shall not be used for the acquisition, operation, or maintenance of computer software in violation of federal copyright laws or applicable licensing restrictions. Contractor hereby certifies and warrants that, during the term of this contract and any extensions, Contractor has and shall maintain in place appropriate systems and controls to prevent such improper use of public funds. If the State determines that Contractor is in violation of this provision, the State may exercise any remedy available at law or in equity or under this contract, including, without limitation, immediate termination of this contract and any remedy consistent with federal copyright laws or applicable licensing restrictions. I. EMPLOYEE FINANCIAL INTEREST/CONFLICT OF INTEREST CRS 24-18-201 & CRS 24-50-507 The signatories aver that to their knowledge, no employee of the State has any personal or beneficial interest whatsoever in the service or property described in this contract. Contractor has no interest and shall not acquire any interest, direct or indirect, that would conflict in any manner or degree with the performance of Contractor’s services and Contractor shall not employ any person having such known interests. J. VENDOR OFFSET CRS 24-30-202(1) & CRS 24-30-202.4 Subject to CRS §24-30-202.4 (3.5), the State Controller may withhold payment under the State’s vendor offset intercept system for debts owed to State agencies for: (a) unpaid child support debts or child support arrearages; (b) unpaid balances of tax, accrued interest, or other charges specified in CRS §39-21-101, et seq.; (c) unpaid loans due to the Student Loan Division of the Department of Higher Education; (d) amounts required to be paid to the Unemployment Compensation Fund; and (e) other unpaid debts owing to the State as a result of final agency determination or judicial action. K. PUBLIC CONTRACTS FOR SERVICES. CRS §8-17.5-101. [Not Applicable to agreements relating to the offer, issuance, or sale of securities, investment advisory services or fund management services, sponsored projects, intergovernmental agreements, or information technology services or products and services] Contractor certifies, warrants, and agrees that it does not knowingly employ or contract with an illegal alien who will perform Work under this contract and will confirm the employment eligibility of all employees who are newly hired for employment in the United States to perform Work under this contract, through participation in the E-Verify Program or the Department program established pursuant to CRS §817.5-102(5)(c), Contractor shall not knowingly employ or contract with an illegal alien to perform Work under this contract or enter into a contract with a subcontractor that fails to certify to Contractor that the subcontractor shall not knowingly employ or contract with an illegal alien to perform Work under this contract. Contractor (a) shall not use E-Verify Program or Department program procedures to undertake pre-employment screening of job applicants while this contract is being performed, (b) shall notify the subcontractor and the contracting State agency within three days if Contractor has actual knowledge that a subcontractor is employing or contracting with an illegal alien for Work under this contract, (c) shall terminate the subcontract if a subcontractor does not stop employing or contracting with the illegal alien within three days of receiving the notice, and (d) shall comply with reasonable requests made in the course of an investigation, undertaken pursuant to CRS §8-17.5-102(5), by the Colorado Department of Labor and Employment. If Contractor participates in the Department program, Contractor shall deliver to the contracting State agency, Institution of Higher Education or political subdivision a written, notarized affirmation, affirming that Contractor has examined the legal Work status of such employee, and shall comply with all of the other requirements of the Department program. If Contractor fails to comply with any requirement of this provision or CRS §8-17.5-101 et seq., the contracting State agency, institution of higher education or political subdivision may terminate this contract for breach and, if so terminated, Contractor shall be liable for damages. Page 47 of 49 SC-6.23 Rev. 7/2015 L. PUBLIC CONTRACTS WITH NATURAL PERSONS. CRS §24-76.5-101. Contractor, if a natural person eighteen (18) years of age or older, hereby swears and affirms under penalty of perjury that he or she (a) is a citizen or otherwise lawfully present in the United States pursuant to federal law, (b) shall comply with the provisions of CRS §24-76.5-101 et seq., and (c) has produced one form of identification required by CRS §24-76.5-103 prior to the effective date of this contract. ARTICLE 53. MISCELLANEOUS PROVISIONS A. CONSTRUCTION OF LANGUAGE The language used in these General Conditions shall be construed as a whole according to its plain meaning, and not strictly for or against any party. Such construction shall, however, construe language to interpret the intent of the parties giving due consideration to the order of precedence noted in Article 2C, Intent of Documents. B. SEVERABILITY Provided this Agreement can be executed and performance of the obligations of the Parties accomplished within its intent, the provisions hereof are severable and any provision that is declared invalid or becomes inoperable for any reason shall not affect the validity of any other provision hereof, provided that the Parties can continue to perform their obligations under this Agreement in accordance with its intent. C. SECTION HEADINGS The captions and headings in this Agreement are for convenience of reference only, and shall not be used to interpret, define, or limit its provisions. D. AUTHORITY Each person executing the Agreement and its Exhibits in a representative capacity expressly represents and warrants that he or she has been duly authorized by one of the parties to execute the Agreement and has authority to bind said party to the terms and conditions hereof. E. INTEGRATION OF UNDERSTANDING This Contract is intended as the complete integration of all understandings between the parties and supersedes all prior negotiations, representations, or agreements, whether written or oral. No prior or contemporaneous addition, deletion, or other amendment hereto shall have any force or affect whatsoever, unless embodied herein in writing. No subsequent novation, renewal, addition, deletion, or other amendment hereto shall have any force or effect unless embodied in a written Change Order or Amendment to this Contract. F. VENUE All suits or actions related to this Agreement shall be filed and proceedings held in the State of Colorado and exclusive venue shall be in the City and County of Denver. G. NO THIRD PARTY BENEFICIARIES Enforcement of this Agreement and all rights and obligations hereunder are reserved solely to the Parties. Any services or benefits which third parties receive as a result of this Contract are incidental to the Contract, and do not create any rights for such third parties. H. WAIVER Waiver of any breach under a term, provision, or requirement of this Agreement, or any right or remedy hereunder, whether explicitly or by lack of enforcement, shall not be construed or deemed as a waiver of any subsequent breach of such term, provision or requirement, or of any other term, provision, or requirement. Page 48 of 49 SC-6.23 Rev. 7/2015 I. INDEMNIFICATION Contractor shall indemnify, save, and hold harmless the State, its employees and agents, against any and all claims, damages, liability and court awards including costs, expenses, and attorney fees , to the extent such claims are caused by any negligent act or omission of the Contractor, its employees, agents, subcontractors or assignees pursuant to the terms of this Contract, but not to the extent such claims are caused by any negligent act or omission of, or breach of contract by, the State, its employees, agents, other contractors or assignees, or other parties not under control of or responsible to the Contractor. J. STATEWIDE CONTRACT MANAGEMENT SYSTEM If the maximum amount payable to Contractor under this Contract is $100,000 or greater, either on the Effective Date or at anytime thereafter, this section shall apply. Contractor agrees to be governed, and to abide, by the provisions of CRS 24-102-205, 24-102-206, 24-103-601, 24-103.5-101, 24-105-101, and 24-105-102 concerning the monitoring of vendor performance on state contracts and inclusion of contract performance information in a statewide contract management system. Contractor’s performance shall be subject to Evaluation and Review in accordance with the terms and conditions of this Contract, State law, including C.R.S 24-103.5-101, and State Fiscal Rules, Policies and Guidance. Evaluation and Review of Contractor’s performance shall be part of the normal contract administration process and Contractor’s performance will be systematically recorded in the statewide Contract Management System. Areas of Evaluation and Review shall include, but shall not be limited to quality, cost and timeliness. Collection of information relevant to the performance of Contractor’s obligations under this Contract shall be determined by the specific requirements of such obligations and shall include factors tailored to match the requirements of Contractor’s obligations. Such performance information shall be entered into the statewide Contract Management System at intervals established herein and a final Evaluation, Review and Rating shall be rendered within 30 days of the end of the Contract term. Contractor shall be notified following each performance Evaluation and Review, and shall address or correct any identified problem in a timely manner and maintain Work progress. Should the final performance Evaluation and Review determine that Contractor demonstrated a gross failure to meet the performance measures established hereunder, the Executive Director of the Colorado Department of Personnel and Administration (Executive Director), upon request by the Principal Representative, and showing of good cause, may debar Contractor and prohibit Contractor from bidding on future contracts. Contractor may contest the final Evaluation, Review and Rating by: (a) filing rebuttal statements, which may result in either removal or correction of the evaluation (CRS 24-105-102(6)), or (b) under CRS 24-105-102(6), exercising the debarment protest and appeal rights provided in CRS 24-109-106, 107, 201 or 202, which may result in the reversal of the debarment and reinstatement of Contractor, by the Executive Director, upon a showing of good cause. K. CORA DISCLOSURE To the extent not prohibited by federal law, this Agreement and the performance measures and standards under CRS §24-103.5-101, if any, are subject to public release through the Colorado Open Records Act, CRS §24-72-101, et seq. Page 49 of 49 SC-6.23 Rev. 7/2015 SECTION 01 00 00 – GENERAL CONDITIONS PART 1 - GENERAL 1.1 GENERAL REQUIREMENTS A. Division 01 - General Requirements relates to and expands upon the Conditions of the Contract, including the General Conditions and the Supplementary Conditions, but does not supersede requirements specified in those documents or in the Owner/Contractor Agreement. B. Division 01 - General Requirements governs work under all other divisions of the Specifications, including Project Specifications issued under separate cover, and the Drawings. 1.2 PROJECT IDENTIFICATION AND PRINCIPAL ENTITIES A. University of Colorado Colorado Springs: Ms. Sherry Reed Planning, Design, and Construction 1420 Austin Bluffs Parkway Colorado Springs, CO 80918 (719) 255-3758 sreed@uccs.edu 1.3 PROJECT CONSULTANTS A. Electrical Engineer: ME Engineers Mr. David Hoag, P.E. 3425 Austin Bluffs Parkway, Suite 201 Colorado Springs, CO 80918 (719) 536-0036 david.hoag@me-engineers.com B. Owner: Wherever the word “Owner” is used in this Project Manual, it shall mean: Ms. Sherry Reed Planning, Design, and Construction 1420 Austin Bluffs Parkway Colorado Springs, CO 80918 (719) 255-3758 sreed@uccs.edu C. Owner's Representative: Wherever the word “Owner's Representative” is used in this Project Manual, it shall mean: ME Engineers 3425 Austin Bluffs Parkway, Suite 201 Colorado Springs, Colorado 80918 Engineeering Building Power Factor Correction Project Number: 16-019 February 1, 2016 GENERAL CONDITIONS 01 00 00 - 1 100% CD D. 1.4 General Contractor: Wherever the words “Contractor” or “General Contractor” are used in this Project Manual, they shall mean the contractor who is party to the Owner/Contractor Agreement. WORK COVERED BY CONTRACT DOCUMENTS A. Single Contract: Unless otherwise indicated or specified, all Work indicated on the Drawings and described in the Specifications is to be executed under one prime contract between Owner and General Contractor. B. Summary of Work: This project is intended to correct the low power factor of the engineering building as seen by electrical utility company. Provide (2) automatic capacitor banks for the existing (2) main distribution centers “MDC1” and “MDC2”. Provide a 275 kVAR, 480V, 3 phase capacitor bank with integral main circuit breaker and NEMA 3R enclosure for “MDC1”. This unit will be located outside the building and adjacent to the electrical room wall. Provide a 75 kVAR, 480V, 3 phase capacitor bank with a NEMA 1 enclosure for “MDC2”. This unit will be located in the main electrical room. Provide all conduit, conductors, switches and fuses as required. Provide required sealing for all penetrations through exterior walls. The Work includes installing a reinforced concrete generator foundation and screen wall/fence, 100KVA UPS, 1020KW Generator and 400A ATS, GW1 panel and boring of generator conduit for the installation. C. The locations of all existing utilities, as indicated on the Drawings, are approximate. General Contractor shall be responsible for verifying location of all underground and above ground utilities prior to construction. Any damage to these utilities shall be the Contractor’s responsibility and they shall be repaired at no cost to the Owner. D. Failure to Visit Site: Will not relieve Contractor from necessity of furnishing materials or performing work that may be required to complete the Work in accordance with Drawings and Specifications without additional cost to Owner. 1.5 WORK BY OWNER OR UNDER SEPARATE CONTRACT A. Coordination and Cooperation: 1. Cooperate fully with separate contractors so work on those contracts may be carried out smoothly, without interfering with or delaying work under this Contract. Coordinate the Work of this Contract with work performed under separate contracts. Cooperate in the scheduling of work and in the use of space. Coordinate with Owner's Representative. 1.6 ACCESS TO SITE 1. Contractor's Access to Site: Limited to access routes as directed by the Owner. 1.7 COORDINATION WITH OCCUPANTS A. Owner Occupancy: Owner will occupy the premises during entire construction period, with the exception of areas under construction. Cooperate with Owner during construction operations to minimize conflicts and facilitate Owner usage. Perform the Work so as not to interfere with Owner's operations. Maintain existing exits, unless otherwise indicated. 1. Maintain access to existing walkways, corridors, and other adjacent occupied or used facilities. Do not close or obstruct walkways, corridors, or other occupied or used facilities without written permission from Owner and authorities having jurisdiction. a. Emergency Exits: Maintain all required fire exits from existing building at all times Engineeering Building Power Factor Correction GENERAL CONDITIONS Project Number: 16-019 01 00 00 - 2 February 1, 2016 100% CD 2. existing building is occupied during construction process. b. Exit Doors, Stairways and Discharge Areas: Acceptable to local code authority. Related Requirements: See Section 01 35 16 Alteration Project Procedures. B. Disruptive Operations: Noisy and disruptive operations (such use of jack hammers and other noisy equipment): 1. Schedule and coordinate such operations with Owner. 2. Upon notification from Owner, cease operations that are, in opinion of Owner, disruptive. Schedule such operations as described above. C. Existing Utility Interruptions: Do not interrupt utilities serving facilities occupied by Owner or others unless permitted under the following conditions and then only after arranging to provide temporary utility services according to requirements indicated: 1. Notify Owner not less than two d a y s in advance of proposed utility i nterruptions. 2. Do not proceed with utility interruptions without Owner's written permission. 3. In general outages shall be scheduled at times coordinated with the Owner. D. Provide not less than 72 hours' notice to Owner of activities that will affect Owner's operations. E. Construction Parking: Parking for construction labor on site shall be paid by the Contractor. F. Owner Occupancy of Completed Areas of Construction: Owner reserves the right to occupy and to place and install equipment in completed areas of building, before Substantial Completion, provided such occupancy does not interfere with completion of the Work. Such placement of equipment and partial occupancy shall not constitute acceptance of the total Work. 1. Before partial Owner occupancy, mechanical and electrical systems shall be fully operational, and required tests and inspections shall be successfully completed. On occupancy, Owner will operate and maintain mechanical and electrical systems serving occupied portions of building. 2. On occupancy, Owner will assume responsibility for maintenance and custodial service for occupied portions of building. 1.8 USE OF SITE A. General: Contractor shall have limited use of premises for construction operations as indicated on Drawings by the Contract limits and as defined at the Pre-construction Conference. B. Limit use of premises to areas within the Contract limits indicated. Do not disturb portions of Project site beyond areas in which the Work is indicated. 1. Owner Occupancy: Restrict access to extent required to allow for on-going occupancy of portions of the building outside the area of work. 2. Driveways and Entrances: Keep driveways and entrances serving premises clear and available to Owner, Owner's employees, and emergency vehicles at all times. Do not use these areas for parking or storage of materials. a. Schedule deliveries to minimize use of driveways and entrances. b. Schedule deliveries to minimize space and time requirements for storage of materials and equipment on-site. C. Use of Existing Building: Maintain existing building in a weathertight condition throughout construction period. Repair damage caused by construction operations. Protect building and its occupants during construction period. 1. 1. Related Requirements: a. Section 01 35 16 Alteration Project Procedures. b. Section 01 50 00 Temporary Facilities and Controls. D. On-Site Work Hours: Work shall be generally performed inside the existing building during normal Engineeering Building Power Factor Correction Project Number: 16-019 February 1, 2016 GENERAL CONDITIONS 01 00 00 - 3 100% CD business working hours, Monday through Friday, unless specifically authorized by the Owner’s Representative. E. Special Campus Restrictions: 1. Areas in the vicinity of the building will be designated by Owner's Project Manager for the purposes of Contractor's staging, stockpiling, and vehicle access. 2. No portion of the site may be used by Contractor without prior approval by Owner's Project Manager. 3. Contractor personnel are prohibited from existing building interiors except as required to execute specific work indicated on Drawings. 4. Contractor is prohibited from utilizing the building’s computers, phones and internet access. 5. Contractor and associated personnel and subcontractors are not permitted to use existing and toilet facilities and service sinks in the building for personal use, for cleaning tools, or for disposing of construction waste materials. 6. Building keys will not be made available to Contractor. Access into and throughout the building will be arranged through Owner's Project Manager. 7. Protect existing property from unauthorized access to building interiors, roofs, etc. Temporary work or storage of materials is not permitted to compromise building security. 8. Temporary work must not compromise structural integrity. 9. No construction waste materials may be disposed of in Owner's dumpsters or other Owner containers. 10. Construction areas shall be limited to the portions of the site indicated on Drawings. 11. Control smoke, dust, dirt, odors and other objectionable effects, and limit to the immediate area of construction. Contractor is responsible for cleaning other areas affected by noncompliance with this requirement, including contents of affected areas. 12. Clean work areas of debris, and " broom clean" no less frequently than at the end of each work day. Remove all debris from exterior site areas which could be wind blown. See Section 01 7000 for additional requirements. F. Special Restriction: 1. All Contractor's personnel, including but not limited to subcontractors, suppliers, inspectors, laborers, and any personnel under contract to or in the direct employ of the Contractor are not permitted to interact with students of the existing college facility in any manner. 2. Contractor's Superintendent: Must be subject to a full background check by UCCS authorities and may not have any prior convictions related to drug abuse, child abuse, or similar violations of applicable law. 1.9 WORK SEQUENCE AND CONSTRUCTION PHASING A. 1.10 A. Sequencing of Construction Plan: Before start of construction on site, submit three copies of construction plan regarding access to work; use of site; and scheduling and phasing of new, demolition and renovation work for acceptance by Owner and Architect. After acceptance of plan, construction sequencing shall comply with accepted plan unless deviations are accepted in writing. 1. No work may commence until Notice to Proceed is provided by the Owner. HAZARDOUS COMMUNICATION REQUIREMENTS: All Contractors are responsible for compliance with mandatory federal rules and regulations concerning Hazard Communication, including, but not limited to those regulations contained in 29 CFR 191 0.1200 Hazard Communication, 1910.146 Confined Space, 1910.147 Lock-out Tag-out, 1910.1101 Asbestos, and Engineeering Building Power Factor Correction Project Number: 16-019 February 1, 2016 GENERAL CONDITIONS 01 00 00 - 4 100% CD 1926.62 Lead. Contractor and all subcontractors working at sites under the control of the Owner shall make available to the Architect, upon request, copies of the Hazard Communication Program used by their firm. In addition to this requirement, all regulations related to Multi-employer workplaces shall be adhered to. These regulations are found in 29 CFR 1910.1200, (e) (2) (I) through (e) (4) specifically: B. 1.11 (e) (2) Multi-employer workplaces. Employers who produce, use, or store hazardous chemicals at workplace in such a way that employees of other employer(s) may be exposed (for example, employees of a construction contractor working on site) shall additionally ensure that the hazard communication programs developed and implemented under paragraph (e) include the following: 1. (e) (2) (i) The methods the employer will use to provide the other employer(s) with a copy of the safety data sheet, or to make it available at a central location in the workplace, for each hazardous chemical the other employer(s)’ employees may be exposed to while working; 2. (e) (2) (ii) The methods the employer will use to inform the other employer(s) of any precautionary measures that need to be taken to protect employees during the workplace’s normal operating conditions and in foreseeable emergencies; and, (e) (2) (iii) The methods the employer will use to inform the other employer(s) of the labeling system used in the workplace. 3. (e) (3) The employer may rely on an existing hazard communication program to comply with these requirements, provided that it meets the criteria established in this paragraph (e). 4. (e) (4) The employer shall make the written hazard communication program available, upon request, to employees, their designated representatives, the Assistant Secretary and the Director, in accordance with requirements of 29 CFR 1910.20 (e). 5. The referenced regulations were excerpted from 29 CFR 1910.1200. This excerpt shall not be relied upon for compliance with mandatory federal, state and local regulations. The Contractor shall comply with all such regulations and shall be solely liable for insuring that all requirements under applicable regulations are met. PROJECT MANUAL FORMATS AND CONVENTIONS A. MasterFormat: This Project Manual is organized on the basis of the 2004 Edition of the Construction Specifications Institute (CSI) MasterFormat. 1. In general, Section numbers are assigned six digits. The first two digits identify the Division (Level 1). The next two pairs of numbers, Levels 2 and 3, identify the subject matter of the section in order of increasing hierarchical specificity. In some cases, a Level 4 number is supplied following a decimal point, when clarity requires a higher degree of specificity. Level 5 numbers or letters are not assigned and are reserved for user-defined categories. 2. The system of groups, subgroups and Divisions are listed in the Table of Contents of this Project Manual. It consists of 50 Divisions, Division 00 though Division 49, some of which are not used or are reserved for future expansion of the MasterFormat. B. Specification Language: These Specifications are of abbreviated, simplified or streamlined type and include incomplete sentences. 1. Omissions of words or phrases such as "the contractor shall", "in conformity therewith", "shall be", "as noted on the Drawings", "a", "the", are intentional. 2. Supply omitted words or phrases by inference. 3. Supply words "shall be" or "shall" by inference when colon is used within sentences or phrases. 4. Supply words "on the Drawings" by inference when "as indicated" is used with sentences or phrases. 1.12 EXAMINATION OF SITE Engineeering Building Power Factor Correction Project Number: 16-019 February 1, 2016 GENERAL CONDITIONS 01 00 00 - 5 100% CD A. Failure to visit the site will in no way relieve any Contractor from the necessity of furnishing materials or performing work that may be required to complete work in accordance with the Contract Documents without additional cost to the OWNER. Bids will be accepted from only those bidders who attend the mandatory pre-bid conference at the job site. PART 2 - PRODUCTS - Not Used PART 3 - EXECUTION - Not Used END OF SECTION 01 00 00 Engineeering Building Power Factor Correction Project Number: 16-019 February 1, 2016 GENERAL CONDITIONS 01 00 00 - 6 100% CD SECTION 01 03 00 - ADMINISTRATION AND SUPERVISION PART 1 - GENERAL 1.1 RELATED DOCUMENTS A. 1.2 Drawings and general provisions of the contract, including General and Supplementary Conditions and other Specification sections, apply to work of this section. SURVEYS, LAYOUTS, AND LEVELS A. 1.3 General: Working from lines and levels established by the existing building, and as shown in relation to the work, establish and maintain bench marks and other dependable markers to set the lines and levels for the work of construction as needed to properly locate every element of the work of the entire project. Calculate and measure required dimensions as shown (within recognized tolerances if not otherwise indicated); do not scale the drawings to determine dimensions. Continuously advise tradesmen performing the work of the marked lines and levels provided for use in the layout of work. SUBMITTALS A. 1.4 Within 10 days of the Notice to Proceed, the Contractor shall submit a Schedule of Values to be used in determining general progress of the project, and for determining percentage of work accomplished for progress payments. As a minimum, the Schedule of Values shall indicate the value of materials and labor for each major category of work. The value of materials and labor shall be shown separately. PROGRESS SCHEDULE A. 1.5 Furnish Project Schedule, as required by the General Conditions, not less than four copies in the form of: Bar chart, showing start and completion of each activity or unit of work and overall percentage of completion against time. Provide such details as required by the Consultant. The Contractor shall provide a detailed construction schedule within two weeks of the award and identify all materials with a lead time greater than 30 days. The Contractor shall provide weekly updates to the construction schedule throughout the duration of the project. PROJECT RECORD DOCUMENTS A. Maintain at job site, one copy of: 1. Contract Drawings 2. Specifications 3. Addenda 4. Reviewed Shop Drawings 5. Change Orders 6. Other Modifications to Contract 7. Field Test Records 8. As-Built Drawings B. Maintain documents in clean, dry, legible condition and do not use record documents for construction purposes. Make documents available at all times for inspection by the Owner’s Representative. Engineering Building Power Factor Correction Project Number: 16-019 February 1, 2016 ADMINISTRATOIN AND SUPERVISION 01 02 00 - 1 100% CD C. Label each document "Project Record" in 1" or larger printed letters. D. Record drawing information in colored pencil with different colors for the various systems and defined by color legend. E. Record drawings and specifications shall include the following: 1. Location of internal utilities and appurtenances concealed in construction referenced to visible and accessible features of structure. Location of concealed valves, dampers, controls, balancing devices, junction boxes, cleanouts, and other items requiring access or maintenance. 2. Field changes of dimension and detail, changes made by Change Order or Field Order and details not on original contract drawings. F. Submit all record drawings to the Consultant at the completion of the project. 1.6 CLEANING A. Cleaning and Protection Work: At the time each unit of work or element of the construction is completed in each area of the Project, clean the unit or element to a condition suitable for occupancy and use (as intended), and restore minor or superficial damage. Replace units and elements which are damaged beyond successful restoration. Clean and restore adjoining surfaces and other work which was soiled or damaged (superficially) during the installation; replace other work damaged beyond successful restoration. Where the performance of subsequent work could possibly result in damage to the complete unit or element, provide protective covering or other provisions to minimize possible damage. Repeat cleaning and protection operations during remainder of construction period, wherever work might otherwise be damaged by sustained soiling or exposure. B. During Construction: Oversee cleaning and ensure that building, grounds, and public properties are maintained free from accumulation of waste materials and rubbish. At reasonable intervals during progress of work, clean up site and access and dispose of waste materials, rubbish, and debris. Grounds around the access areas shall be broom clean by the end of each day. C. Final Cleaning: Remove all discarded materials and equipment. Restore sidewalks, lawns, landscaping, driveways, etc. to the condition prior to commencement of work. 1.7 PROJECT SIGN A. 1.8 A project sign is not required. Do not erect any project sign or jobsite sign of any kind, except warning signs, without written authorization of the Owner. COORDINATION A. The Contractor shall coordinate the work so as not to interfere with the building custodian's normal cleanup activities. B. The Contractor shall be responsible for coordinating all the work of the project. The Contractor shall coordinate the efforts of all subcontractor(s) and the deliveries of suppliers so that the work progresses in an orderly fashion without delay towards timely completion of a complete project in accordance with the drawings and specifications. Engineering Building Power Factor Correction Project Number: 16-019 February 1, 2016 ADMINISTRATOIN AND SUPERVISION 01 02 00 - 2 100% CD C. 1.9 The Contractor shall note that concurrent with his work, other contractors, suppliers, and the Owner's's facilities and maintenance personnel may be working in relatively close proximity. The Contractor will be solely responsible for coordinating his work with that of other contractors and will make no claims for failure to do so. METHODS OF CONSTRUCTION A. The procedure and method of construction is the prerogative and the responsibility of the Contractor. If professional assistance is required to safely implement method of construction, the Contractor shall, on his own, employ professional help. PART 2 - NOT USED PART 3 - NOT USED END OF SECTION 01 03 00 Engineering Building Power Factor Correction Project Number: 16-019 February 1, 2016 ADMINISTRATOIN AND SUPERVISION 01 02 00 - 3 100% CD SECTION 01 04 00 - PROJECT COORDINATION PART 1 - GENERAL 1.1 RELATED DOCUMENTS: A. 1.2 Drawings and general provisions of the Contract, including General and Supplementary Conditions and Division 1-Specification sections, apply to work of this section. SUMMARY: A. Section Includes: Requirements for coordination, supervision and administration for Project, including but not necessarily limited to: 1. Coordination. 2. Administrative and supervisory personnel. 3. General installation provisions. 4. Cleaning and protection. B. Related Sections: For descriptions of the work of the entire Project within and outside of the work of this Contract: Section 01 01 00. 1.3 SUBMITTALS: A. Coordination Drawings: For locations where several elements of equipment, mechanical or combined mechanical and electrical work must be sequenced and positioned with precision in order to fit into the available space, prepare coordination shop drawings showing the actual physical dimensions at accurate scale required for the installation. Prepare and submit coordination drawings prior to purchase/fabrication/installation of any of the elements involved in the coordination. B. Staff Names: Within 10 days of Notice to Proceed, submit a list of the Contractor's principal staff assignments, including the Superintendent in attendance at the site. Submit addresses and telephone numbers, including after-hours telephone numbers for emergency response. 1.4 GENERAL COORDINATION: A. General: Each entity involved in the performance of work for the entire Project shall cooperate in the overall coordination of the work; promptly, when requested, furnish information concerning its portion of the work; and respond promptly and reasonably to the decisions and requests of persons designated with coordination, supervisory, administrative, or similar authority. Where necessary, prepare memoranda for distribution to each party involved outlining special procedures required for coordination. B. Administrative Procedures: Coordinate scheduling and timing of required administrative procedures with other construction work. Such administrative activities include, but are not limited to, the following: 1. Preparation of schedules. 2. Installation and removal of temporary facilities. 3. Delivery and processing of submittals. 4. Progress meetings. 5. Project closeout activities. Engineering Building Power Factor Correction Project Number: 16-019 February 1, 2016 PROJECT COORDINATOIN 01 04 00 - 1 100% CD C. Conservation: Coordinate construction activities to ensure that operations are carried out with consideration given to conservation of energy, water and materials. Salvage materials and equipment involved in performance of, but not actually incorporated in, the Work. Refer to other sections for disposition of salvaged materials that are designated as the Owner's's property. D. Site Utilization: In addition to the site utilization limitations and requirements indicated in Section 01010 and indicated by the Contract Documents, administer the allocation of available space equitably among entities needing access and space, so as to produce the best overall efficiency in the performance of the total work of the project. Schedule deliveries so as to minimize the space and time requirements for storage of materials and equipment on the site; but do not unduly risk delays in the work. 1. The Contractor shall note that concurrent with his work, other contractors, suppliers, and the Owner's facilities and maintenance personnel may be working in relatively close proximity. The Contractor will be solely responsible for coordinating his work with that of other contractors and will make no claims for failure to do so. E. Coordination Meetings: Where necessary, schedule coordination meetings for this purpose on an asneeded basis. F. Layout: It is recognized that the Contract Documents are diagrammatic in showing certain physical relationships of the various elements and systems and their interfacing with other elements and systems. Establishment and coordination of these relationships is the exclusive responsibility of the Contractor. Do not scale the drawings. Field measure all conditions prior to fabrication and construction. Lay out and arrange all elements to contribute to safety, efficiency and to carry the harmony of design throughout the Work. In case of conflict or undimensioned locations, verify required positioning with the Owner’s Representative. G. Substrate Examination: The Installer of each element of the work must examine the conditions of the substrate to receive the work, dimensions and spaces adjacent, tolerances, interfacing with other elements and services, and the conditions under which the work will be performed, and must notify the Contractor in writing of conditions detrimental to the proper or timely completion of the work. Do not proceed with the work until unsatisfactory conditions have been corrected in a manner acceptable to the Installer. H. Large and Heavy Equipment and Materials: Coordinate the movement of heavy items with shoring and bracing, so that the building structure will not be overloaded during the movement and installation. Where equipment or products to be installed on the roof are too heavy to be hand-carried, do not transport across roof deck; position by crane or other device so as to avoid overloading the roof deck. 1.5 COMPLETE SYSTEMS: A. It is the intent of the Contract Documents that all systems, including mechanical and electrical, be complete and functional to provide the intended or specified performance. The Contractor shall provide all incidental items and parts necessary to achieve this requirement. B. Provide correctly sized power, utilities, piping, drains, services and their connections to equipment and systems requiring them, whether or not specific items are listed in the schedule at the end of this section. 1.6 MECHANICAL/ELECTRICAL/EQUIPMENT A. COORDINATION: Sequence, coordinate and integrate the various elements of equipment, mechanical work and electrical work so that various systems and mechanical plant will perform as indicated and be in harmony with other work of the building. The Owner’s Representative, including the Project Architect or Engineer, will supervise the coordination, which is the exclusive responsibility of the Contractor. Engineering Building Power Factor Correction Project Number: 16-019 February 1, 2016 PROJECT COORDINATOIN 01 04 00 - 2 100% CD B. Install piping, ductwork and similar services straight and true, aligned with other work, close to walls and overhead structure, allowing for insulation, concealed (except where indicated as exposed) in occupied spaces, and out-of-the-way with maximum passageway and headroom remaining in each space. C. Install electrical work in a neat, organized manner with conduit and similar services in or parallel with building lines, and concealed unless indicated as exposed. D. Arrange all work to facilitate maintenance and repair or replacement of equipment. Locate services requiring maintenance on valves and similar units in front of services requiring less maintenance. Connect equipment for ease of disconnecting, with minimum of interference with other work. PART 2 - PRODUCTS (Not Applicable) PART 3 - EXECUTION 3.1 GENERAL INSTALLATION PROCEDURES: A. Inspection of Conditions: Require the Installer of each major component to inspect both the substrate and conditions under which work is to be performed. Do not proceed until unsatisfactory conditions have been corrected in an acceptable manner. B. Inspect materials or equipment immediately upon delivery and again prior to installation. Reject damaged and defective items. C. Recheck measurements and dimensions, before starting fabrication or installation. D. Manufacturer's Instructions: Comply with manufacturer's installation instructions and recommendations, to the extent that those instructions and recommendations are more explicit or stringent than requirements contained in Contract Documents. E. Installation: Provide attachment and connection devices and methods necessary for securing work. Secure work true to line and level. Allow for expansion and building movement. Install each component during weather conditions and project status that will ensure the best possible results. Isolate each part of the completed construction from incompatible material as necessary to prevent deterioration. Coordinate temporary enclosures with required inspections and tests, to minimize the necessity of uncovering completed construction for that purpose. F. Visual Effects: Provide uniform joint widths in exposed work. Arrange joints in exposed work to obtain the best visual effect. Refer questionable choices to the Owner’s Representative for final decision. G. Mounting Heights: Where mounting heights are not indicated, install individual components at standard mounting heights recognized within the industry for the particular application indicated. Refer questionable mounting height decisions to the Owner’s Representative for final decision. 3.2 CLEANING AND PROTECTION: A. During handling and installation, clean and protect construction in progress and adjoining materials in place. Apply protective covering where required to ensure protection from damage or deterioration at substantial completion. Engineering Building Power Factor Correction Project Number: 16-019 February 1, 2016 PROJECT COORDINATOIN 01 04 00 - 3 100% CD B. Clean and maintain completed construction as frequently as necessary through the remainder of the construction period. Adjust and lubricate operable components to ensure operability without damaging effects. C. Limiting Exposures: Supervise construction activities to ensure that no part of the construction, completed or in progress, is subject to harmful, dangerous, damaging, or otherwise deleterious exposure during the construction period. Where applicable, such exposures include, but are not limited to, the following: 1. Excessive static or dynamic loading. 2. Water or ice. 3. Solvents. 4. Chemicals. 5. Puncture. 6. Abrasion. 7. Heavy traffic. 8. Soiling, staining and corrosion. 9. Unusual wear or other misuse. 10. Contact between incompatible materials. 11. Misalignment. 12. Excessive weathering. 13. Unprotected storage. 14. Improper shipping or handling. 15. Theft. 16. Vandalism. END OF SECTION 01 04 00 Engineering Building Power Factor Correction Project Number: 16-019 February 1, 2016 PROJECT COORDINATOIN 01 04 00 - 4 100% CD SECTION 01 09 00 - REFERENCE STANDARDS PART 1 - GENERAL 1.1 RELATED DOCUMENTS: A. Drawings and general provisions of the Contract, including General and Supplementary Conditions and other Specification sections, apply to work of this section. B. Administration, Procedures, Codes. 1.2 SUMMARY: A. 1.3 Section Includes: General information and listing of reference standards. REFERENCE STANDARDS: A. Applicability of Standards: Except where Contract Documents include more explicit or stringent requirements, applicable construction industry standards have the same force and effect as if bound or copied directly into Contract Documents. Such standards are made a part of the Contract Documents by reference. Individual Sections indicate which codes and standards the Contractor must keep available at the project site for reference. Referenced standards take precedence over standards that are not referenced but generally recognized in the construction industry as applicable. B. Conflicting Requirements: Where compliance with two or more standards is specified, and they establish different or conflicting requirements for minimum quantities or quality levels, the most stringent requirement will be enforced, unless the Contract Documents indicate otherwise. Refer requirements that are different, but apparently equal, and uncertainties as to which quality level is more stringent to the Owner’s Representative for a decision before proceeding. C. Unreferenced Standards: Unreferenced standards are not directly applicable to the Work, except as a general requirement of whether the Work complies with recognized construction industry standards. D. Publication Dates: Where compliance with an industry standard is required, comply with standard in effect as of date of Contract Documents. E. Updated Standards: At the request of the Owner, Contractor or authority having jurisdiction, submit a Change Order proposal where an applicable code or standard has been revised and reissued after the date of the Contract Documents and before performance of Work affected. The Owner will decide whether to issue a Change Order to proceed with the updated standard. F. Copies of Standards: Each entity engaged in construction on the Project is required to be familiar with industry standards applicable to that entity's construction activities. Copies of applicable standards are not bound with the Contract Documents. G. Where copies of standards are needed for proper performance of a recognized construction activity, the Contractor shall obtain copies directly from the publication source. Engineering Building Power Factor Correction Project Number: 16-019 February 1, 2016 REFERENCE STANDARDS 01 09 00 - 1 100% CD H. Although copies of standards needed for enforcement of requirements may be part of required submittals, the Owner reserves the right to require the Contractor to submit additional copies as necessary for enforcement of requirements. PART 2 - PRODUCTS (Not applicable) PART 3 - EXECUTION (Not applicable) END OF SECTION 01 09 00 Engineering Building Power Factor Correction Project Number: 16-019 February 1, 2016 REFERENCE STANDARDS 01 09 00 - 2 100% CD SECTION 01 15 00 - ADMINISTRATION, PROCEDURES, CODES PART 1 - GENERAL 1.1 RELATED DOCUMENTS: A. Drawings and general provisions of the Contract, including General and Supplementary Conditions and other Division 1-Specification sections, apply to work of this section. B. Reference Standards. 1.2 SUMMARY: A. 1.3 Section Includes: General administrative requirements and procedures and related applicable codes. CODES: A. Obtain all permits, inspections, approvals, and certificates required by law. Conform to all laws, ordinances, rules and regulations applicable to the location of the Project. B. Governing Regulations: In addition to the above, conform to the following standards and regulations: 1. International Building Code, 2012 edition. 2. International Mechanical Code, 2012 edition. 3. International Plumbing Code, 2012 edition. 4. International Fire Code, 2012 edition. 5. National Electric Code, 2012 edition (NFPA No. 70). 6. All State regulations. C. Publication Dates: Comply with codes and standards in effect at the date of the Contract Documents, except where a standard of a specific date or edition is indicated. 1.4 ATTACHMENTS TO CONCRETE: A. No drilled inserts or powder-actuated fasteners are permitted by any trade in pre-stressed concrete except as specifically authorized by the General Contractor and carried out under the direct supervision of his Superintendent. B. Only those devices with a maximum controlled penetration of 0.75" or less will be permitted, unless specifically indicated on the structural details in the Project Drawings. Make holes through slabs by means of sleeves placed no closer than 2" from tensioning cables. Core drilling will not be permitted unless unavoidable and as specified in Section 01045. Engineering Building Power Factor Correction Project Number: 16-019 February 1, 2016 ADMINISTRATOIN, PROCEDURES AND CODES 01 15 00 - 1 100% CD 1.5 CONTRACTOR'S CONSTRUCTION SCHEDULE: A. Furnish Construction Schedule, as required by General Conditions, not less than 4 copies. Prepare the schedule on a sheet, or series of sheets, of stable transparency, or other reproducible media, of sufficient width to show data for the entire construction period. B. Secure time commitments for performing critical elements of the Work from parties involved. Coordinate each element on the schedule with other construction activities; include minor elements involved in the sequence of the Work. Show each activity in proper sequence. Indicate graphically sequences necessary for completion of related portions of the Work. C. Coordinate the Contractor's construction schedule with the schedule of values, list of subcontracts, submittal schedule, progress reports, payment requests and other schedules. D. Bar Chart Schedule: 1. Prepare a fully developed, horizontal bar chart type Contractor's construction schedule. Submit within 30 days of the date established for "Commencement of the Work". 2. Provide a separate time bar for each significant construction activity. Provide a continuous vertical line to identify the first working day of each week. Use the same breakdown of units of the Work as indicated in the "Schedule of Values". 3. Within each time bar, indicate estimated completion percentage in 10% increments. As Work progresses, place a contrasting mark in each bar to indicate Actual Completion. 4. Include listing of Subcontractors, suppliers and materials men with name of contact person, address and phone number E. Updating: 1. The schedules shall be updated and reissued weekly and shall reflect actual job progress, delays or gains of time and any rescheduling. The original schedule and each updating shall be furnished in 4 copies to the Owner’s Representative. All costs for this scheduling shall be borne by the Contractor. Submit Owner’s Representative copies as a part of each pay request which will not be processed without such updates. 2. When schedule revisions affect the submittals schedule, revise that schedule and submit to Owner’s Representative with revised Construction Schedule. 1.6 DELIVERY, STORAGE AND HANDLING: A. 1.7 Properly carton, crate, cover and protect materials, products and equipment for shipping, handling and storing. Use appropriate means for hoisting and loading which will prevent damage or overstress to items being handled or shipped. Store them under roof in controlled environment whenever feasible otherwise store off the ground under suitable coverings properly secured against wind and weather. Protect all items from rain, snow, moisture, wind, cold, heat, frost, sun, staining, discoloration, deterioration and physical damage from any cause. Refer to individual sections for specific requirements. ENVIRONMENTAL HEALTH AND SAFETY: A. Physical, Life, and Fire Safety: There will be joint contractor and Owner's responsibilities to control physical hazards (i.e., compressed gases, welding, electrical, safety netting, cranes, scaffolding, supplies on the roof and electrical) which may endanger the health of contractor or Owner's employees, students, patients, and visitors as may cause property damage. Engineering Building Power Factor Correction Project Number: 16-019 February 1, 2016 ADMINISTRATOIN, PROCEDURES AND CODES 01 15 00 - 2 100% CD B. During the construction phase, the Owner's Physical Plant staff will monitor all construction projects for compliance with acceptable safety practices. The following minimum items are included: 1. Exit corridors and exit doors will not be blocked without making prior arrangements for alternate exit routes. 2. Contractor will provide physical barriers with appropriate warning signage to protect public areas from construction work. 3. Contractor will conduct daily inspections to eliminate fire hazards and any other safety hazards which may adversely affect Owner's employees, students, visitors, and patients. 4. Contractor will provide signs used for proper identification of construction areas. 5. Contractor will provide an adequate number of fire extinguishers to be available on-site for emergency use in the construction area. 6. Contractor and Owner will provide emergency notification phone numbers to be posted in all construction areas. C. OSHA Hazard Communication Standard: 1. Every Contractor or subcontractor performing work shall have to comply with this standard. Compliance includes joint Owner and Contractor responsibilities for the purpose of providing timely communications and information sharing with regard to hazardous materials and chemicals and chemical sources which may be present on-site or brought in by the Contractor. Owner's Physical Plant representatives will discuss right-to-know issues with the Contractor or his representative during the pre-construction conference(s). 2. Owner will provide Contractor with the following: a. Information regarding hazardous chemicals and agents to which they may be exposed while on the job site. Medical Safety Data Sheets (MSDSs) will be provided by the Owner. b. Precautions that employees shall take to lessen the possibility for exposure by employment of appropriate protective measures. c. Precautionary methods to take in a foreseeable emergency. 3. The Contractor is responsible for all safety training and environmental surveillance of their workers. 4. The Contractor shall inform and provide designated Owner’s Representative with the following information: a. Material safety data sheets for all chemicals they introduce into the workplace(s). b. The information regarding potential sources of pollutants which may be entrained in Owner's's air intakes (i.e., roofing tar fumes, nuisance dusts, exhaust from internal combustion engines, welding or cutting fumes, and asbestos - if damaged or encountered during the course of their work. D. Asbestos Control: There may be asbestos containing materials within the existing building where work will be performed under this contract. 1. The presence of asbestos-containing materials on the job site does not mean a problem exists. Areas where asbestos is friable and not contained are of concern. 2. There are several Owner and Contractor responsibilities regarding asbestos. These are: a. The Owner Shall: 1) Notify the Contractor of the condition and location(s) where asbestos is known to be present or may be reasonably be encountered (i.e., insulations, ceiling tiles, floor tiles, fire doors, wall and ceiling plasters, concrete, grouting, etc.). 2) Request that undamaged asbestos-containing materials are not damaged. 3) Require Contractors to report suspected asbestos problems to the Owner. 4) Require that the Contractor train and monitor their own employees where applicable. 5) Coordinate with the Contractor when response action is required by either the Owner's Asbestos Abatement Team or by a Subcontractor. 6) Monitor areas where friable asbestos is present during construction/renovation projects for its own records and purpose. Monitoring results can be shared with Contractors but are in no way to be used for Contractor employee monitoring. Engineering Building Power Factor Correction Project Number: 16-019 February 1, 2016 ADMINISTRATOIN, PROCEDURES AND CODES 01 15 00 - 3 100% CD b. E. 1.8 7) Have the final word on all asbestos-related concerns and contractual arrangements. The Contractor Shall: 1) Notify the Owner of any suspected or existing problem involving asbestos and cease work in that area until the Owner has assessed the situation. 2) Be responsible for all environmental/industrial hygiene surveillance of their work staff and subcontractors. 3) Not create problems which can result in asbestos exposure to building occupants. Carcinogenics: Contractor or any subcontractor shall not knowingly install or cause to be installed any material or product containing carcinogenics. OCCUPATIONAL SAFETY AND HEALTH ADMINISTRATION (OSHA) A. The Contractor shall have sole responsibility for compliance on the job site to all applicable portions of the Occupational Safety and Health Act. The Contractor is responsible for other regulatory requirements as they relate to occupational Health and Safety requirements. For example, NIOSH, ANSI, and MSA. B. Protection of life, health and public welfare as it relates to the execution of the construction contract is the responsibility of the Contractor. The Owner’s Representative may, at their discretion, observe, inspect, or comment on plans, procedures, or actions employed at the project as they relate to safety of life, health or public welfare. If conditions are imposed by the Owner which interfere with, or imply actions detrimental to safety, written notice shall be returned to the Owner for action prior to affecting any unsafe conditions. C. Contractors shall use OSHA Lock Out / Tag Out procedures when working with energized equipment. D. All contractors entering confined spaces owned by CU or while conducting work under contract with CU shall develop a written program and utilize procedures that, at a minimum, comply with all federal, state and local confined space standards and all applicable regulatory requirements. Contractors shall, independent of the University, monitor the space to obtain their own data to ensure a safe entry and exit. Any data generated by a contractor’s confined space entry, should be provided to the Facilities Management confined Space Program Manager. E. When contractors perform work that may involve Facilities Management controlled permit required confined spaces, Facilities Management will: 1. Inform contractors of permit required confined spaces and that entry is allowed only after compliance with the confined space entry standard; 2. Require contractors planning to enter a confined space to provide the Facilities Management Confined Space Program Manager in charge of that space, 48-hour advance notice of such planned entry. The contractors entry will be in accordance with the current Occupational Safety and Health Administration confined space entry standard and a signed document stating such, shall be provided to the FM Confined Space Program Manager prior to entry. F. The FM Confined Space Program Manager, following receipt of notice of contractor planned entry, will: 1. Apprise contractor of the hazards identified in the confined space and of any prior experience that is documented on the space; 2. Appraise the contractor of any precautions or procedures that CU has implemented for the protection of workers in or near the confined space. Engineering Building Power Factor Correction Project Number: 16-019 February 1, 2016 ADMINISTRATOIN, PROCEDURES AND CODES 01 15 00 - 4 100% CD 1.9 HOT WORK PERMITS A. UCCS is using FM Global Hot Work Permit Program as an essential tool in preventing fires in our buildings. The permit is just a tool and does not disclose all precautions for every hot work application. All hot work on campus shall be strictly supervised while the work is being performed. B. UCCS Hot Work Permit 1. Permits are required for all work involving open flames or producing heat and/or sparks (ie brazing, cutting, grinding, soldering torch applied roofing and welding) 2. Permits are required for all hot work in existing buildings. Permits are not required for ground up construction. 3. Contact the Department of Public Safety to obtain a Hot Work Permit 24 hours (business hours) prior to your scheduled work. Ron Honn (255-3201 (rhonn@uccs.edu <mailto:rhonn@uccs.edu> or Cindy Norton (255-3212) cnorton@uccs.edu <mailto:cnorton@uccs.edu>. 4. Permits are to be picked up from the Department of Public Safety front desk, or may be dropped off at your construction site. 5. Review your permit precautions checklist before proceeding with your work and display the permit in the work area. 6. Once work is completed, complete the hot work permit process by signing off on who did the work and that the fire watch requirement was completed. 7. Return the completed Hot Work Permit to the Department of Public Safety for their recordkeeping. C. Individuals or firms who obtain a permit shall fully read, understand and implement the requirements of the permit. D. Any person or firm who conducts hot work without the full implementation of the permit requirements shall be fined five hundred dollars ($500) the first time and one thousand dollars ($1,000) for subsequent occurrences. When the requirements of the hot work permit are not being implemented, the improper activities shall be stopped immediately until a hot work permit is obtained. Contractor shall be responsible for any damages caused as a result of improper hot work activities or the work stoppage. Any contractor who is found to be in non-compliance a third time, will not be allowed to work on campus until further notice by Facilities Services. E. UCCS project managers shall have the authority to stop improper or non-permitted hot work activities. 1.10 A. 1.11 PERMITS The contractor must post permit(s) in a prominent location at the jobsite including all inspection reports. The contractor shall have an updated set of contract documents available at the jobsite for all inspections. INSPECTIONS A. The Contractor must schedule all required inspections 48 hours in advance by calling UCCS Project Manager or directly contacting their designated inspectors. Inspectors will complete these inspections within 48 hours with the exception of weekends and state holidays. B. The contractor is required to arrange for the all inspections as required by the Building Inspection Record and CRS 24-30-1303 including but limited to Footings/Foundations, Concrete, Framing, Lath and Gypsum Board, Fire Resistant Penetrations, Mechanical/Energy Efficiency and Roofing. Engineering Building Power Factor Correction Project Number: 16-019 February 1, 2016 ADMINISTRATOIN, PROCEDURES AND CODES 01 15 00 - 5 100% CD C. Re-inspections: A re-inspection fee may be assessed for each inspection or reinspection when such portion of work for which inspection is called is not complete or when corrections called for are not made. D. The Contractor will be responsible for all cost related to re-inspections and will be billed at the testing agency bill-out rate for re-inspections. 1.12 A. 1.13 UNIVERSITY OF COLORADO SEXUAL HARASSMENT POLICY Contractors should be aware of and review the University of Colorado at Colorado Springs policies that prohibit discrimination and harassment on the basis of race, color, national origin, sex, age, disability, creed, religion, sexual orientation or veteran status. These policies are located on the web at: http://www.uccs.edu/hr. Contractor personnel must adhere to these policies and conduct themselves in a manner that does not discriminate or harass as a result of interacting with an around the University of Colorado faculty, staff and students and visitors. FIRE ALARM INTERRUPTION A. Contractor shall contact UCCS Public Safety at 719-255-3201 or e-mail rhonn@uccs.edu <mailto:rhonn@uccs.edu> prior to all interruptions or shutdowns of fire alarm systems. Interruptions or shutdowns shall be scheduled three (3) working days in advance with UCCS Department of Public Safety and UCCS Project Manager. Contractor shall provide a fire watch as directed by UCCS Public Safety during interruption or shutdown. B. The Contractor shall be responsible for preventing nuisance alarm due to activities at their work site. Common sources of nuisance alarms are: 1. Smoke (soldering, welding, cooking, etc.) 2. Grinding 3. Dust (drilling, sweeping, canister vacuums, sand blasting, etc.) 4. Water leaking (plumbing leaks, overflows) 5. Water sprayed on or near detectors (pressure washing or cleaning with water) 6. Popcorn or other food burning in microwaves 7. Static electricity (covering or uncovering detectors) 8. Changing filters on air handling units (dust) 9. Steam (leaks, pressure pop-offs) 10. Broken or frozen sprinkler heads 11. Sprinkler drain valves turned by mistake 1 2 . Va n dal i s m C. Precautions to prevent nuisance alarms are: 1. 1During construction projects, treat all buildings, except totally new construction, as though they were occupied buildings with live systems. 2. Do not assume that all detectors are in plain sight. Contact University personnel for verification. 3. Maintain dust control measures per UCCS Standards: a. Maintaining barriers b. Covering air returns 4. Asking UCCS personnel to cap or disable smoke detectors (Note any capping or disabling of fire safety devices is to be done ONLY by UCCS personnel, not contractors.) 5. Avoiding recirculation of dust or smoke through the building air handling system. 6. Follow campus hot work procedures. 7. Do not expose fire alarm devices to water or extreme temperatures. 8. Contact Alarm Systems Supervisor for any actions that affect fire detection, alarm, and suppression systems. Engineering Building Power Factor Correction Project Number: 16-019 February 1, 2016 ADMINISTRATOIN, PROCEDURES AND CODES 01 15 00 - 6 100% CD PART 2 - PRODUCTS (Not applicable) PART 3 - EXECUTION (Not applicable) END OF SECTION 01 15 00 Engineering Building Power Factor Correction Project Number: 16-019 February 1, 2016 ADMINISTRATOIN, PROCEDURES AND CODES 01 15 00 - 7 100% CD SECTION 01 30 00 - SUBMITTALS PART 1 - GENERAL 1.1 RELATED DOCUMENTS: A. 1.2 Drawings and general provisions of the Contract, including General and Supplementary Conditions and other Specification sections, apply to work of this section. SUMMARY: A. 1.3 Section Includes: Administrative and procedural requirements for submittal and review of product data, shop drawings, samples and similar items required by the specifications. ADMINISTRATIVE SUBMITTALS: A. Refer to other Division-1 Sections and other Contract Documents for requirements for administrative submittals. Such submittals include, but are not limited to: 1. Schedules. 2. Permits. 3. Applications for payment. 4. Performance and payment bonds. 5. Insurance certificates. 6. List of Subcontractors. 7. Schedule of Values. 8. Inspection and test results. 9. Closeout documents. 10. Coordination drawings. B. Administrative submittals are for information and record and do not require action on the part of the Owner’s Representative except where not in conformity with the Contract Documents. If such nonconformity is observed, the Owner’s Representative will notify the Contractor within two weeks of the Owner’s Representative's actual receipt of the non-comforming document. Failure to observe or notify by the Owner’s Representative on any issue does not relieve Contractor of compliance with Contract Documents. 1.4 SUBMITTAL LOG A. A submittal Log is included at the end of this section. The Contractor is required to submit information pertaining to each of the listed items. the Contractor may also The Contractor shall update the Submittal Log on a timely basis, and shall bring the log to scheduled progress meetings for coordination and review. Engineering Building Power Factor Correction Project Number: 16-019 February 1, 2016 SUBMITTALS 01 30 00 - 1 100% CD 1.5 SUBMITTAL PROCEDURES: A. General: the Contractor shall make submittals to the Owner’s Representative only after the Contractor has reviewed and fully coordinated all aspects of construction regarding each submittal. the Contractor shall indicate his action except for samples and selection submittals. B. Submittals which lack the Contractor's review, coordination, and action will be returned to the Contractor without action. C. Coordination: Coordinate the preparation and processing of submittals with the performance of construction activities. The Contractor shall transmit each submittal sufficiently in advance of performance of related construction activities to avoid delay. the contractor is wholly responsible for the submittal process, its timing, and any related delay. 1. Coordinate each submittal with fabrication, purchasing, testing, delivery, other submittals and related activities that require sequential activity. 2. Coordinate transmittal of different types of submittals for related elements of the Work so processing will not be delayed by the need to review submittals concurrently for coordination. 3. Distribute submittals to related subcontractors for comment to assure the timely coordination of the work. 4. The Owner’s Representative reserves the right to withhold action on a submittal requiring coordination with other submittals until related submittals are received. 5. If, during the Contractor's submittal review, any inconsistency, conflict, or deviation from or with the Contract Documents becomes apparent, it is the Contractor's responsibility to inform the Owner’s Representative immediately of all concerns in writing. D. Processing: To avoid the need to delay installation as a result of the time required to process submittals, allow sufficient time for submittal review, including time for resubmittals. 1. Allow 2 weeks from receipt of the submittal by the Owner’s Representative for initial review. Allow additional time if processing must be delayed to permit coordination with subsequent submittals. The Owner’s Representative will advise the Contractor when a submittal being processed must be delayed for coordination. 2. If an intermediate submittal is necessary, process the same as the initial submittal. 3. Allow 2 weeks from receipt of the submittal by the Owner’s Representative for reprocessing each submittal. 4. No extension of Contract Time will be authorized because of failure to transmit submittals to the Owner’s Representative sufficiently in advance of the Work to permit processing, including resubmittals of incomplete or rejected submittal items. E. Submittal Preparation: Place a permanent label or title block on each submittal for identification. Indicate the name of the entity that prepared each submittal on the label or title block. 1. Provide a space approximately 4" x 5" on the label or beside the title block on Shop Drawings to record the Contractor's review and approval markings and the action taken. 2. Include the following information on the label for processing and recording action taken. a. Project name. b. Date. c. Name and address of Contractor. d. Name and address of Subcontractor. e. Name of manufacturer. f. Number and title of appropriate Specification Section. F. Submittal Transmittal: Package each submittal appropriately for transmittal and handling. Transmit each submittal from Contractor to Owner’s Representative using a transmittal form. Submittals received from sources other than the Contractor will not be returned. Engineering Building Power Factor Correction Project Number: 16-019 February 1, 2016 SUBMITTALS 01 30 00 - 2 100% CD 1. G. 1.6 On the transmittal, record relevant information and requests for data. On the form, or separate sheet, record deviations from Contract Document requirements, including minor variations and limitations. Include Contractor's certification that information complies with Contract Document requirements. Submittal Reviews: 1. The Owner’s Representative will provide two submittal reviews, one initial review and one follow up review. After the second review, if the submittals do not meet the requirements of the Contract Documents, the Contractor shall provide compensation to the Owner’s Representative for additional submittal reviews. CONTRACTOR'S CONSTRUCTION SCHEDULE A. Bar-Chart Schedule: Prepare a fully developed, horizontal bar-chart-type, contractor's construction schedule. Submit within 14 days after the date established for "Commencement of the Work" or "Notice to Proceed." 1. Provide a separate time bar for each significant construction activity. Provide a continuous vertical line to identify the first working day of each week. Use the same breakdown of units of the Work as indicated in the "Schedule of Values." 2. Within each time bar, indicate estimated completion percentage in 10 percent increments. As Work progresses, place a contrasting mark in each bar to indicate Actual Completion. 3. Prepare the schedule on a sheet, or series of sheets, of stable transparency, or other reproducible media, of sufficient width to show data for the entire construction period. 4. Secure time commitments for performing critical elements of the Work from parties involved. Coordinate each element on the schedule with other construction activities; include minor elements involved in the sequence of the Work. Show each activity in proper sequence. Indicate graphically the sequences necessary for completion of related portions of the Work. 5. Coordinate the Contractor's Construction Schedule with the Schedule of Values, list of subcontracts, Submittal Schedule, progress reports, payment requests, and other schedules. 6. Indicate completion in advance of the date established for Substantial Completion. Indicate Substantial Completion on the schedule to allow time for the Owner’s Representative's procedures necessary for certification of Substantial Completion. B. Schedule Updating: Revise the schedule after each meeting, event, or activity where revisions have been recognized or made. Issue the updated schedule concurrently with the report of each meeting. Schedule updating is required prior to the processing of all Contractor's application for payment. 1.7 SHOP DRAWINGS: A. Submit newly prepared information, drawn to accurate scale. Highlight, encircle, or otherwise indicate deviations from the Contract Documents. Do not reproduce Contract Documents or copy standard information as the basis of Shop Drawings. Standard information prepared without specific reference to the Project is not considered Shop Drawings. Do not use Shop Drawings without an appropriate final stamp indicating action taken. B. Shop Drawings include fabrication and installation drawings, setting diagrams, schedules, patterns, templates and similar drawings. Include the following information: 1. Dimensions. 2. Identification of products and materials included. 3. Compliance with specified standards. 4. Notation of coordination requirements. 5. Notation of dimensions established by field measurement. Engineering Building Power Factor Correction Project Number: 16-019 February 1, 2016 SUBMITTALS 01 30 00 - 3 100% CD C. Initial Submittal: Submit one correctable, translucent, reproducible print and one blue- or black-line print each for the Owner’s Representative's review. The Owner’s Representative will return the reproducible print. The Contractor will provide prints of marked up sepia as may be required for his use and that of his Subcontractors and suppliers. D. Final Submittal: Submit 6 copies for final action by the Owner’s Representative. The Owner’s Representative shall return one copy to the Contractor. The Contractor shall be responsible for procuring copies of the final submittal so that desired distribution can be made to the Contractor's field office, his home office, the Record Documents, the fabricator, and any others requiring in the submittal. E. Where shop drawings are indicated to be submitted for "information only", submit three sets of prints to Owner’s Representative and retain one set for Project Record Documents. 1.8 PRODUCT DATA: A. Collect ALL Product Data into a single submittal for each element of construction or system. Product Data includes printed information such as manufacturer's installation instructions, catalog cuts, standard or special color charts, rough-in diagrams and templates, standard wiring diagrams and performance curves. Where Product Data must be specially prepared because standard printed data is not suitable for use, submit as "Shop Drawings". Product Data Submittal shall be provided in a vinyl covered 8 ½”x11” 3-ring binder. Product Data shall be organized within the binder into sections corresponding to specification sections. Provide a labeled tabbed divider between each section. Provide an index and a Contractor and Owner contact page at the front of the binder page. B. Mark each copy to show applicable choices and options. Where printed Product Data includes information on several products, some of which are not required, mark copies to indicate the applicable information. Include the following information. 1. Manufacturer's printed recommendations. 2. Compliance with recognized trade association standards. 3. Compliance with recognized testing agency standards. 4. Application of testing agency labels and seals. 5. Notation of dimensions verified by field measurement. 6. Notation of coordination requirements. C. Do not submit Product Data until compliance with requirements of the Contract Documents has been confirmed by the Contractor. D. Initial Submittal: Submit 6 copies for action by the Owner’s Representative. The Owner’s Representative shall return one copy to the Contractor. The Contractor shall be responsible for procuring copies of the final submittal so that desired distribution can be made to the Contractor's field office, his home office, the Record Documents, the fabricator, and any others involved in the submittal. E. Submittal is for information and record, unless otherwise indicated; and therefore, initial submittal is final submittal unless returned by the Owner’s Representative marked with a revise and resubmit action which indicates an observed non-compliance. Engineering Building Power Factor Correction Project Number: 16-019 February 1, 2016 SUBMITTALS 01 30 00 - 4 100% CD 1.9 SELECTIONS SUBMITTAL: A. 1.10 Where selections of colors, patterns, textures are specified to be made by the Owner’s Representative, assemble complete samples of all specified or approved products for all specification sections and submit to Owner’s Representative. Review specifications and assemble all such samples for a combined single submittal. Indicate on the transmittal the latest date for selections to be made for each item to permit delivery of material in accordance with Progress Schedule. Allow a minimum of two weeks for Owner’s Representative's action. Owner’s Representative's action is limited solely to the specified selections or rejection of submittal items not in accordance with Specifications. QUALITY ASSURANCE SUBMITTALS A. Submit quality-control submittals, including design data, certifications, manufacturer's instructions, manufacturer's field reports, and other quality-control submittals as required under other Sections of the Specifications. B. Certifications: Where other Sections of the Specifications require certification that a product, material, or installation complies with specified requirements, submit a notarized certification from the manufacturer certifying compliance with specified requirements. 1. Signature: Certification shall be signed by an officer of the manufacturer or other individual authorized to sign documents on behalf of the company. C. Inspection and Test Reports: Where standard tests are specified for products, including equipment, which tests are not performed at the job site, follow procedures for Product Data. For field inspection and tests specified to be performed by independent agencies, such agencies shall transmit directly one copy each to the Owner’s Representative, his consulting engineer where applicable, and the Contractor with an extra copy for Record Documents. 1.11 OWNER’S REPRESENTATIVE'S ACTION A. Except for submittals for the record or information, where action and return is required, the Owner’s Representative will review each submittal, mark to indicate action taken, and return to the Contractor. 1. Compliance with specified characteristics is the Contractor's responsibility. B. Action Stamp: The Owner’s Representative will stamp each submittal with a uniform, action stamp. The Owner’s Representative will mark the stamp appropriately to indicate the action taken, as follows: 1. Final Unrestricted Release: When the Owner’s Representative marks a submittal "No Exception Taken," the Work covered by the submittal may proceed provided it complies with requirements of the Contract Documents. Final payment depends on that compliance. 2. Final-But-Restricted Release: When the Owner’s Representative marks a submittal "Make Corrections Noted," the Work covered by the submittal may proceed provided it complies with notations or corrections on the submittal and requirements of the Contract Documents. Final payment depends on that compliance. 3. Returned for Resubmittal: When the Owner’s Representative marks a submittal "Revise and Resubmit," do not proceed with Work covered by the submittal, including purchasing, fabrication, delivery, or other activity. Revise or prepare a new submittal according to the notations; resubmit without delay. Repeat if necessary to obtain different action mark. a. Do not use, or allow others to use, submittals marked "Revise and Resubmit" at the Project Site or elsewhere where Work is in progress. Engineering Building Power Factor Correction Project Number: 16-019 February 1, 2016 SUBMITTALS 01 30 00 - 5 100% CD 4. C. Other Action: Where a submittal is for information or record purposes or special processing or other activity, the Owner’s Representative will return the submittal marked "Action Not Required." Unsolicited Submittals: The Owner’s Representative will return unsolicited submittals to the sender without action. PART 2 - PRODUCTS (Not applicable) PART 3 - EXECUTION (Not applicable) END OF SECTION 01 30 00 Engineering Building Power Factor Correction Project Number: 16-019 February 1, 2016 SUBMITTALS 01 30 00 - 6 100% CD SECTION 01 45 00 - CUTTING AND PATCHING PART 1 - GENERAL 1.1 RELATED DOCUMENTS: A. 1.2 Drawings and general provisions of the Contract, including General and Supplementary Conditions and Specification sections, apply to work of this section. SUMMARY A. Work Included: This section establishes general requirements in addition to those indicated in the General Conditions of the Contract for Construction pertaining to cutting, fitting, and patching of the work required to: 1. Make the several parts fit properly. 2. Uncover work to provide for installation, inspection, or both, of ill-timed work. 3. Remove and replace work not conforming to requirements of Contract Documents. 4. Patch new construction into existing construction. B. Related Work: 1. In addition to requirements specified, upon the Consultant's request, uncover work to provide for inspection of covered work, and remove samples of installed materials for testing. 2. Do not cut or alter work performed under separate contract without the Consultant's written permission. 1.3 DEFINITION: A. "Cutting and patching" is hereby defined to include but is not necessarily limited to the cutting and patching of nominally completed and previously existing work, in order to accommodate the listed requirements. Cutting and patching is further defined to include integral cutting and patching during the manufacturing, fabricating, erecting and installing process for individual units of work. B. Demolition is recognized as an example of a related but separate category of work, which may also require cutting and patching as defined in this section; refer to Selective Demolition Section. 1.4 RESPONSIBILITIES: A. Contractor shall be responsible for all cutting, fitting and patching, including attendant excavation and backfill, required to complete the Work or to: 1. Make its several parts fit together properly. 2. Uncover portions of the Work to provide for installation of ill-timed work. 3. Remove and replace defective work or work not conforming to requirements of Contract Documents. 4. Remove samples of installed work as specified for testing. 5. Provide routine penetrations of structural and non-structural surfaces for installation of mechanical and electrical work. B. Refer to other sections of the specifications for specific cutting and patching requirements and limitations applicable to individual units of work. Engineering Building Power Factor Correction Project Number: 16-019 February 1, 2016 CUTTING AND PATCHING 01 45 00 - 1 100% CD 1.5 SUBMITTALS: A. Proposals for Cutting and Patching: Submit a written request to the Owner’s Representative well in advance of executing any cutting or alteration which affects: 1. Work of the Owner or any separate contractor. 2. Structural value or integrity of any element of the Project. 3. Integrity or effectiveness of weather exposed or moisture-resistant elements or systems. 4. Efficiency, operational life, maintenance or safety of operational elements. 5. Visual qualities of sight-exposed elements. 6. Cutting new openings in existing structural concrete walls, floors and suspended slabs. 7. Cutting new openings in existing roofs and roofing materials. 8. Cutting exterior walls. 9. Cutting into shafts. B. Include description of why cutting and patching cannot reasonably be avoided, how it will be performed, how structural elements will be reinforced, products to be used, firms and trades to perform the work, approximate dates of the work, and anticipated results in terms of variations from the work as originally completed (structural, operational, visual and other qualities of significance). C. List utilities that will be disturbed or otherwise affected by work, including those that will be relocated and those that will be out-of- service temporarily. Indicate how long utility service will be disrupted. D. Where cutting and patching involves addition of reinforcement to structural elements, submit details and engineering calculations, from a Licensed Professional Engineer, to show how reinforcement is integrated with the original structure. E. Approval by Owner’s Representative to proceed with proposed cutting-and-patching does not waive his right to later require complete removal and replacement of work found to be unsatisfactorily cut-andpatched. 1.6 QUALITY ASSURANCE: A. Requirements for Structural Work: Do not cut and patch structural work in a manner resulting in a reduction of load-carrying capacity or load/deflection ratio. B. Operational and Safety Limitations: Do not cut and patch operational elements and safety-related components in a manner resulting in a reduction of capacities to perform in the manner intended or resulting in decreased operational life, increased maintenance, or decreased safety. C. Visual Requirements: Do not cut and patch work which is exposed on the exterior or exposed in occupied spaces of the building, in a manner resulting in a reduction of visual qualities or resulting in substantial evidence of the cut-and-patch work, both as judged solely by the Owner’s Representative. Remove and replace work judged by the Owner’s Representative to be cut-and-patched unsatisfactorily, visually. 1.7 PROJECT CONDITIONS: A. Where cutting and patching of existing construction is required, prior to start of work, inform Owner of existing construction to be disturbed. Owner will determine if existing construction contains asbestos. Do not proceed with work until Owner has made an examination. Refer to Section 01105. Engineering Building Power Factor Correction Project Number: 16-019 February 1, 2016 CUTTING AND PATCHING 01 45 00 - 2 100% CD PART 2 - PRODUCTS 2.1 MATERIALS: A. Use materials that are identical to existing materials. If identical materials are not available or cannot be used where exposed surfaces are involved, use materials that match existing adjacent surfaces to the fullest extent possible with regard to visual effect. Use materials whose installed performance will equal or surpass that of existing materials. PART 3 - EXECUTION 3.1 EXAMINATION: A. Inspect existing conditions of Project, including elements subject to damage or to movement during cutting and patching. B. After uncovering work, inspect conditions affecting installation of products, or performance of work. C. Report unsatisfactory or questionable conditions to the Owner’s Representative in writing; do not proceed with work until Owner’s Representative has provided further instructions. 3.2 PREPARATION: A. Temporary Support: Provide adequate support for work to be cut, to prevent failure. Do not endanger other work. B. Protection: Provide adequate protection of other work during cutting-and-patching, to prevent damage; and provide protection of the work from adverse weather exposure. Avoid interference with use of adjoining areas or interruption of free passage to adjoining areas. Take all precautions necessary to avoid cutting existing pipe, conduit or ductwork serving the building, but scheduled to be removed or relocated until provisions have been made to bypass them. 3.3 CUTTING AND PATCHING: A. General: Employ skilled workers to perform cutting and patching. Proceed with cutting-and-patching at the earliest feasible time and complete without delay. 1. Cutting: Cut work by methods least likely to damage work to be retained and work adjoining. Review proposed procedure with original Installer where possible, and comply with his recommendations. Cut holes and slots neatly to size required and temporarily cover openings when not in use. 2. In general, cut work with sawing and grinding tools. Do not use hammering and chopping tools. Core drill openings through concrete work where possible. 3. To avoid marring existing finished surfaces, cut or drill from the exposed or finished side into concealed surfaces. 4. Cut through concrete and masonry using a cutting machine such as a Carborundum saw or diamond core drill. 5. Fit work airtight to pipes, sleeves, ducts, conduit and other penetrations through surfaces. Engineering Building Power Factor Correction Project Number: 16-019 February 1, 2016 CUTTING AND PATCHING 01 45 00 - 3 100% CD B. Patching: Patch with seams which are durable and as invisible as possible. Comply with specified tolerances for the work. Where feasible, inspect and test patched areas to demonstrate integrity of the installation. 1. Restore exposed finishes of patched areas; and, where necessary extend finish restoration onto retained work adjoining, in a manner which will eliminate evidence of patching. Where a patch occurs in a smooth painted surface, extend final paint coat over the entire unbroken surface containing the patch. 2. Where removal of walls or partitions extends one finished area into another, patch and repair floor and wall surfaces in the new space to provide an even surface of uniform color and appearance. Remove existing floor and wall coverings and replace with new materials, if necessary to achieve uniform color and appearance. 3. Patch, repair or re-hang existing ceilings as necessary to provide an even plane surface of uniform appearance. END OF SECTION 01 45 00 Engineering Building Power Factor Correction Project Number: 16-019 February 1, 2016 CUTTING AND PATCHING 01 45 00 - 4 100% CD SECTION 01 54 00 - SAFETY AND HEALTH PART 1 - GENERAL 1.1 RELATED DOCUMENTS A. 1.2 Drawings and general provisions of the contract, including General and Supplementary Conditions and other Specification sections, apply to work of this section. WORK COVERED BY THIS SECTION A. 1.3 This section is applicable to all work covered by this contract. APPLICABLE PUBLICATIONS A. The publications listed below form a part of this specification to the extent referenced. The publications are referred to in the text by basic designation only. B. OSHA General Industry and Health Standards (29 CFR 1910), Publications V2206; OSHA Construction Industry Standards (29 CFR 1926). One source of these regulations is OSHA Publication 2207, which includes a combination of both Parts 1910 and 1926 as they relate to construction safety and health. It is for sale by the Superintendent of Documents, U. S. Government Printing Office, Washington, DC 20402. C. National Emission Standards of Hazardous Air Pollutants (40 CFR, Part 61). D. Environmental Protection Agency (EPA) Final Rule (40 CFR Part 761) dated July 17, 1985. 1.4 DEFINITION OF HAZARDOUS MATERIALS A. 1.5 Refer to hazardous and toxic materials/substances included in Subparts H and Z of 29 CFR 1910; and to others as additionally defined in Fed. Std. 313. Those most commonly encountered include asbestos, polychlorinated biphenyls (PCB'S), explosives, and radioactive material, but may include others. The most likely products to contain asbestos are sprayed-on fireproofing, insulation, boiler lagging, pipe covering and likely products to contain PCB'S are transformers, capacitors, voltage regulators, and oil switches. QUALITY ASSURANCE: A. Safety Meeting: Representatives of the Contractor shall be prepared to discuss, in detail, the measures he/she intends to take in order to control any unsafe or unhealthy conditions associated with the work to be performed under the contract. If directed by the Owner, this meeting may be held in conjunction with other meetings which are scheduled to take place prior to start of work under this contract. The level of detail for the safety meeting is dependent upon the nature of the work and the potential inherent hazards. The Contractor's principal on-site representative(s), the general superintendent and his/her safety representative(s) shall attend this meeting. Engineering Building Power Factor Correction Project Number: 16-019 February 1, 2016 SAFETY AND HEALTH 01 54 00 - 1 100% CD B. Contractor Responsibility: The Contractor shall assume full responsibility and liability for compliance with all applicable regulations pertaining to the health and safety of personnel during the execution of work, and shall hold State of Colorado and its Consultants harmless for any action on his/her part or that of his/her employees or subcontractors, which results in illness, injury or death. C. Compliance With Regulations for Hazardous Materials: All work, including contact with and handling of hazardous materials, the disturbance or dismantling of structures containing hazardous materials and/or the disposal of hazardous materials shall comply with the applicable requirements of 29 CFR 1926/1910 or 40 CFR 761. Work involving the disturbance, dismantling of asbestos or asbestos containing materials; the demolition of structures containing asbestos; and/or the disposal and removal of asbestos, shall also comply with the requirements of 40 CFR, Part 61, Subparts A and M. All work shall comply with applicable state and municipal safety and health requirements. Where there is a conflict between applicable regulations, the most stringent shall apply. 1.6 SUBMITTALS A. Accident Reporting: A copy of each accident report, which the Contractor or subcontractors submit to their insurance carriers, shall be forwarded to the Owner's Representative as soon as possible, but in no event later than seven (7) calendar days after the day the accident occurred. B. Permits: When hazardous materials (if any) are disposed of off-site, submit copies of permits from applicable, Federal, state, or municipal authorities and necessary certificates that the material has been disposed of as per regulations. C. Other Submittals: Provide a plan of action for handling work protection from the fall exposure, and protection of the public at the ground level. Submittal shall contain the following as a minimum. 1. Number, type, and experience of employees to be used for the work. 2. Description of how applicable safety and health regulations and standards are to be met. 3. Type of protective equipment and work procedures to be used. 4. Identification of possible hazards, problems, and proposed control mechanisms. 5. Protection of public or others not related to the operation. 6. Interfacing and control of subcontractors, if any. 7. Copy of the Contractor’s safety manual PART 2 - PRODUCTS 2.1 MATERIALS AND EQUIPMENT: A. 2.2 Special facility, devices, equipment, clothing, and similar items used by the Contractor in the execution of work shall comply with the applicable regulations. HAZARDOUS MATERIALS A. The contractor shall bring to the attention of the Owner any material suspected of being hazardous which he/she encounters during execution of the work. A determination will be made by the Owner as to whether the Contractor shall perform tests to determine if the material is hazardous. If the Owner directs the Contractor to perform tests, and/or if the material is found hazardous and additional protective measures are needed, a contract change may be required, subject to applicable provisions of this contract. Engineering Building Power Factor Correction Project Number: 16-019 February 1, 2016 SAFETY AND HEALTH 01 54 00 - 2 100% CD PART 3 - EXECUTION 3.1 STOP WORK ORDERS A. 3.2 When the Contractor or his/her subcontractors are notified by the Owner's Representative(s) of any noncompliance with the provisions of the contract and the action(s) to be taken, the Contractor shall immediately, if directed, or within 48 hours after receipt of a notice of violation correct the unsafe or unhealthy condition. If the Contractor fails to comply promptly, all or any part of the work being performed may be stopped by the Owner or Owner’s Representative with a "Stop Work Order". When, in the opinion of the Owner or Owner’s Representative satisfactory corrective action has been taken to correct the unsafe and unhealthy condition, a start order will be given immediately. The Contractor shall not be allowed any extension of time or compensation for damages by reason of or in connection with such work stoppage. PROTECTION A. The Contractor shall take all necessary precautions to prevent injury to workers, the public, building occupants, or damage to property. For the purposes of this contract, the public or building occupants shall include all persons not employed by the Contractor or a subcontractor working under his/her direction. B. Storing, positioning or use of equipment, tools, materials, scraps, and trash in a manner likely to present a hazard to the public or building occupants by its accidental shifting, ignition, or other hazardous qualities is prohibited. C. Obstructions: No corridor, aisle, stairway, door of exit shall be obstructed or used in such a manner as to encroach upon routes of ingress or egress utilized by the public or building occupant, or to present unsafe or unhealthy conditions to the public or building occupant. D. Work shall not be performed in any area occupied by the public or employees unless specifically permitted by the Contract or the Owner's Representative, and unless adequate stops are taken for the protection of the public or employees. E. Alternate Precautions: When the nature of the work prevents isolation of the work area and the public or building occupants may be in or pass through, under or over the work area, alternate precautions such as the posting of signs, the use of signal personal, the erection of barricades or similar protection around particularly hazardous operations shall be used as appropriate. F. Public Thoroughfare: When work is to be performed over a public thoroughfare such as a sidewalk, lobby, or corridor, the thoroughfare shall be closed, if possible, or other precautions taken such as the installation of screens or barricades. When the exposure to heavy falling objects exists, as during demolition, special protection of the type detailed in 29 CFR 1910/1926 shall be provided. G. Fall Protection: The Contractor shall comply with OSHA regulation 1926.500 in its entirety for the entire duration of this project. Any violation of these regulations shall cause the project to be shut down until full compliance is achieved. Repeated violations may result in termination of the Contract. END OF SECTION 01 54 00 Engineering Building Power Factor Correction Project Number: 16-019 February 1, 2016 SAFETY AND HEALTH 01 54 00 - 3 100% CD SECTION 01 60 00 - MATERIALS AND EQUIPMENT PART 1 - GENERAL 1.1 RELATED DOCUMENTS A. 1.2 Drawings and general provisions of the Contract, including General and Supplementary Conditions and other Specification Sections, apply to this Section. SUMMARY A. 1.3 This Section includes administrative and procedural requirements governing the Contractor's selection of products for use in the Project. DEFINITIONS A. 1.4 Definitions used in this Article are not intended to change the meaning of other terms used in the Contract Documents, such as "specialties," "systems," "structure," "finishes," "accessories," and similar terms. Such terms are self-explanatory and have well-recognized meanings in the construction industry. 1. "Products" are items purchased for incorporation in the Work, whether purchased for the Project or taken from previously purchased stock. The term "product" includes the terms "material," "equipment," "system," and terms of similar intent. 2. "Named Products" are items identified by the manufacturer's product name, including make or model number or other designation, shown or listed in the manufacturer's published product literature that is current as of the date of the Contract Documents. 3. "Foreign Products," as distinguished from "domestic products," are items substantially manufactured (50 percent or more of value) outside the United States and its possessions. Products produced or supplied by entities substantially owned (more than 50 percent) by persons who are not citizens of, nor living within, the United States and its possessions are also considered to be foreign products. 4. "Materials" are products substantially shaped, cut, worked, mixed, finished, refined or otherwise fabricated, processed, or installed to form a part of the Work. 5. "Equipment" is a product with operational parts, whether motorized or manually operated, that requires service connections, such as wiring or piping. QUALITY ASSURANCE A. Source Limitations: To the fullest extent possible, provide products of the same kind from a single source. 1. When specified products are available only from sources that do not, or cannot, produce a quantity adequate to complete project requirements in a timely manner, consult with the Owner’s Representative to determine the most important product qualities before proceeding. 2. Qualities may include attributes, such as visual appearance, strength, durability, or compatibility. When a determination has been made, select products from sources producing products that possess these qualities, to the fullest extent possible. B. Compatibility of Options: When the Contractor is given the option of selecting between 2 or more products for use on the Project, the product selected shall be compatible with products previously selected, even if previously selected products were also options. Engineering Building Power Factor Correction Project Number: 16-019 February 1, 2016 MATERIALS AND EQUIPMENT 01 60 00 - 1 100% CD 1. 2. Each prime contractor is responsible for providing products and construction methods that are compatible with products and construction methods of other prime or separate contractors. If a dispute arises between prime contractors over concurrently selectable, but incompatible products, the Owner’s Representative will determine which products shall be retained and which are incompatible and must be replaced. C. Foreign Product Limitations: Except under one or more of the following conditions, provide domestic products, not foreign products, for inclusion in the Work: 1. No available domestic product complies with the Contract Documents. 2. Domestic products that comply with the Contract Documents are available only at prices or terms substantially higher than foreign products that comply with the Contract Documents. D. Nameplates: Except for required labels and operating data, do not attach or imprint manufacturers or producer's nameplates or trademarks on exposed surfaces of products that will be exposed to view in occupied spaces or on the exterior. 1. Labels: Locate required product labels and stamps on concealed surfaces or, where required for observation after installation, on accessible surfaces that are not conspicuous. 2. Equipment Nameplates: Provide a permanent nameplate on each item of service-connected or power-operated equipment. Locate on an easily accessible surface that is inconspicuous in occupied spaces. The nameplate shall contain the following information and other essential operating data: a. Name of product and manufacturer. b. Model and serial number. c. Capacity. d. Speed. e. Ratings. 1.5 PRODUCT DELIVERY, STORAGE, AND HANDLING A. Deliver, store, and handle products according to the manufacturer's recommendations, using means and methods that will prevent damage, deterioration, and loss, including theft. 1. Schedule delivery to minimize long-term storage at the site and to prevent overcrowding of construction spaces. 2. Coordinate delivery with installation time to assure minimum holding time for items that are flammable, hazardous, easily damaged, or sensitive to deterioration, theft, and other losses. 3. Deliver products to the site in an undamaged condition in the manufacturer's original sealed container or other packaging system, complete with labels and instructions for handling, storing, unpacking, protecting, and installing. 4. Inspect products upon delivery to ensure compliance with the Contract Documents and to ensure that products are undamaged and properly protected. 5. Store products at the site in a manner that will facilitate inspection and measurement of quantity or counting of units. 6. Store heavy materials away from the Project structure in a manner that will not endanger the supporting construction. 7. Store products subject to damage by the elements above ground, under cover in a weathertight enclosure, with ventilation adequate to prevent condensation. Maintain temperature and humidity within range required by manufacturer's instructions. Engineering Building Power Factor Correction Project Number: 16-019 February 1, 2016 MATERIALS AND EQUIPMENT 01 60 00 - 2 100% CD 1.6 SUBSTITUTIONS: A. Basis: After execution of the Contract, the Owner’s Representative will consider substitutions of products in place of those specified or approved only if the specified product or products, through no fault of the Contractor or his Subcontractors, cannot be delivered in time to meet the construction schedule or is no longer available. B. Procedure: Make written request for the substitution documenting fully the above reason. Include complete data on the proposed substitution substantiating compliance with the Contract Documents including product identification and description, performance and test data, references and samples where applicable, and an itemized comparison of the proposed substitution with the products specified or otherwise approved, with data relating to Contract time schedule, design and artistic effect where applicable, and its relationship to separate contracts. Accompany the request by accurate installed cost data on the proposed substitution in comparison with the product specified. C. Consideration: Making such requests for substitutions is a representation by the Contractor that: 1. The Contractor has personally investigated the proposed substitute product and determined that it is equal or superior in all respects to that specified and will carry the same warranty; 2. The cost data are complete and include all related costs under this Contract but excludes costs under separate contracts and excludes Design Consultant’s re-design costs, and the Contractor waives all claims for additional costs related to the substitution which subsequently become apparent; 3. The Contractor will coordinate the installation of the accepted substitute, making such changes as may be required for the Work to be complete in all respects. D. When approved by the Owner’s Representative, such substitution will be documented by Change Order modifying the Specifications. The Contract Sum will be changed only if the substitution results in a cost savings to the Owner. PART 2 - PRODUCTS 2.1 PRODUCT SELECTION A. General Product Requirements: Provide products that comply with the Contract Documents, that are undamaged and, unless otherwise indicated, new at the time of installation. 1. Provide products complete with accessories, trim, finish, safety guards, and other devices and details needed for a complete installation and the intended use and effect. 2. Standard Products: Where available, provide standard products of types that have been produced and used successfully in similar situations on other projects. B. Product Selection Procedures: The Contract Documents and governing regulations govern product selection. Procedures governing product selection include the following: 1. Proprietary Specification Requirements: Where Specifications name only a single product or manufacturer, provide the product indicated. No substitutions will be permitted. 2. Semiproprietary Specification Requirements: Where Specifications name 2 or more products or manufacturers, provide 1 of the products indicated. No substitutions will be permitted. a. Where Specifications specify products or manufacturers by name, accompanied by the term "or equal" or "or approved equal," comply with the Contract Document provisions concerning "substitutions" to obtain approval for use of an unnamed product. Engineering Building Power Factor Correction Project Number: 16-019 February 1, 2016 MATERIALS AND EQUIPMENT 01 60 00 - 3 100% CD 3. 4. 5. 6. 7. 8. 9. Nonproprietary Specifications: When Specifications list products or manufacturers that are available and may be incorporated in the Work, but do not restrict the Contractor to use of these products only, the Contractor may propose any available product that complies with Contract requirements. Comply with Contract Document provisions concerning "substitutions" to obtain approval for use of an unnamed product. Descriptive Specification Requirements: Where Specifications describe a product or assembly, listing exact characteristics required, with or without use of a brand or trade name, provide a product or assembly that provides the characteristics and otherwise complies with Contract requirements. Performance Specification Requirements: Where Specifications require compliance with performance requirements, provide products that comply with these requirements and are recommended by the manufacturer for the application indicated. a. Manufacturer's recommendations may be contained in published product literature or by the manufacturer's certification of performance. Compliance with Standards, Codes, and Regulations: Where Specifications only require compliance with an imposed code, standard, or regulation, select a product that complies with the standards, codes, or regulations specified. Visual Matching: Where Specifications require matching an established Sample, the Owner’s Representative's decision will be final on whether a proposed product matches satisfactorily. a. Where no product available within the specified category matches satisfactorily and complies with other specified requirements, comply with provisions of the Contract Documents concerning "substitutions" for selection of a matching product in another product category. Visual Selection: Where specified product requirements include the phrase "... as selected from manufacturer's standard colors, patterns, textures ..." or a similar phrase, select a product and manufacturer that complies with other specified requirements. The Owner’s Representative will select the color, pattern, and texture from the product line selected. Allowances: Refer to individual Specification Sections and "Allowance" provisions in Division 1 for allowances that control product selection and for procedures required for processing such selections. PART 3 - EXECUTION 3.1 INSTALLATION OF PRODUCTS A. Comply with manufacturer's instructions and recommendations for installation of products in the applications indicated. Anchor each product securely in place, accurately located and aligned with other Work. 1. Clean exposed surfaces and protect as necessary to ensure freedom from damage and deterioration at time of Substantial Completion. END OF SECTION 01 60 00 Engineering Building Power Factor Correction Project Number: 16-019 February 1, 2016 MATERIALS AND EQUIPMENT 01 60 00 - 4 100% CD SECTION 01 70 00 - PROJECT CLOSEOUT PART 1 - GENERAL 1.1 RELATED DOCUMENTS A. 1.2 Drawings and general provisions of Contract, including General and Supplementary Conditions and other Specification Sections, apply to this Section. SUMMARY A. 1.3 This Section specifies administrative and procedural requirements for project closeout, including but not limited to: 1. Inspection procedures. 2. Project record document submittal. 3. Operating and maintenance manual submittal. 4. Submittal of warranties. 5. Final cleaning. PROJECT COMPLETION AND FINAL INSPECTION A. The Contractor shall file a written notice with the Owner’s Representative that the work in the opinion of the Contractor, is complete under the terms of the contract. B. Within ten (10) days after the Contractor files written notice that the work is complete, the Owner’s Representative, the Owner and the Contractor shall make a "final inspection" of the project to determine whether the work has been completed in accordance with the contract documents. A final punch list shall be made by the Owner’s Representative in sufficient detail to fully outline to the Contractor. 1. Work to be completed, if any; 2. Work not in compliance with the drawings and specifications, if any; 3. Unsatisfactory work for any reason, if any. C. The required amount of copies of the punch list will be countersigned by the Owner’s Representative and the Owner and will be transmitted by the Owner’s Representative to the Contractor and the Owner. 1.4 ADVERTISEMENT AND FINAL PAYMENT A. Prior to final payment to the Contractor, the Owner shall advertise the project as set forth in Article 50 of the General Conditions of the Contract. B. Before the Principle Representative may advertise, the Contractor shall: 1. Deliver to the Owner’s Representative: a. Closing-out Checklist and Contractor Close-out forms with all items completed. b. Final pay request accounting for final additional changes to the Contract Sum, including deductions for uncorrected work and deductions for reinspection payments. The final pay request shall reflect a reduction of the retainage to zero. The final pay request amount shall show the total Contract Sum, as adjusted by change orders, previous payments, and the sum remaining due. c. All guaranties and warranties Engineering Building Power Factor Correction Project Number: 16-019 February 1, 2016 POJECT CLOSEOUTP 01 70 00 - 1 100% CD 2. 3. 4. 5. 6. 1.5 d. All statements to support local sales tax refunds. e. Three complete bound sets of required operating maintenance instructions and manuals. f. One set of drawings showing all job changes (as-built drawings) Complete start-up testing of systems, and demonstrate to the operating personnel of the Principal Representative proper operation and maintenance of all newly installed or refurbished equipment. Deliver tools, spare parts, extra stock, and similar items. Make final change-over of permanent locks and transmit keys to the Owner. Advise the Owner personnel of change-over in security provisions. Discontinue or change over and remove temporary facilities from the site, along with construction tools, mock-ups, and similar elements. Complete final clean up requirements, including touch-up painting. Touch-up and otherwise repair and restore marred exposed finishes. RECORD DOCUMENT SUBMITTALS A. General: Do not use record documents for construction purposes; protect from deterioration and loss in a secure, fire-resistive location; provide access to record documents for the Owner’s Representative’s reference during normal working hours. B. Record Drawings (as-built drawings): Maintain a clean, undamaged set of blue or black line white-prints of Contract Drawings and Shop Drawings. Mark the set to show the actual installation where the installation varies substantially from the Work as originally shown. Mark whichever drawing is most capable of showing conditions fully and accurately; where Shop Drawings are used, record a crossreference at the corresponding location on the Contract Drawings. Give particular attention to concealed elements that would be difficult to measure and record at a later date. 1. Mark record sets with erasable pencil; use other colors to distinguish between variations in separate categories of the Work. Define colors by color legend on front sheet. 2. Mark new information that is important to the Owner, but was not shown on Contract Drawings or Shop Drawings. 3. Note related Change Order numbers where applicable. 4. Organize record drawing sheets into manageable sets, bind with durable paper cover sheets, and print suitable titles, dates and other identification on the cover of each set. C. Record Specifications: Maintain one complete copy of the Project Manual, including addenda, and one copy of other written construction documents such as Change Orders and modifications issued in printed form during construction. Mark these documents to show substantial variations in actual Work performed in comparison with the text of the Specifications and modifications. Give particular attention to substitutions, selection of options and similar information on elements that are concealed or cannot otherwise be readily discerned later by direct observation. Note related record drawing information and Product Data. D. Maintenance Manuals: Organize operating and maintenance data into suitable sets of manageable size. Bind properly indexed data in individual heavy-duty 2-inch, 3-ring vinyl-covered binders, with pocket folders for folded sheet information. Mark appropriate identification on front and spine of each binder. Include the following types of information: 1. Emergency instructions. 2. Spare parts list. 3. Copies of warranties. 4. Wiring diagrams. 5. Recommended "turn around" cycles. 6. Inspection procedures. 7. Shop Drawings and Product Data. 8. Fixture lamping schedule. Engineering Building Power Factor Correction Project Number: 16-019 February 1, 2016 POJECT CLOSEOUTP 01 70 00 - 2 100% CD 1.6 MISCELLANEOUS KEYS, SWITCHES, ETC. A. 1.7 At the completion of the project, all loose keys for hose bibs; adjustment keys and wrenches for door closers and panic hardware, and keys for electric switches, electrical panels, etc., shall be accounted for and turned over to the Owner. WARRANTIES A. The Contractor and each sub-contractor shall remedy any defects to faulty materials or workmanship and pay for any damage to other work resulting therefrom, which shall appear in his work within a period of one year from the date of Notice of Acceptance and in accordance with the terms of any special warranties provided in the contract. The Owner shall give notice of observed defects with reasonable promptness. B. Upon completion of his work, the Contractor shall deliver to the Consultant in duplicate, a written warranty based on the provision of this Article properly signed and notarized. Warranty shall be addressed to the Owner. PART 2 - PRODUCTS (Not Applicable) PART 3 - EXECUTION 3.1 CLOSEOUT PROCEDURES A. Operating and Maintenance Instructions: Arrange for each installer of equipment that requires regular maintenance to meet with the Owner's personnel to provide instruction in proper operation and maintenance. If installers are not experienced in procedures, provide instruction by manufacturer's representatives. Include a detailed review of the following items: 1. Maintenance manuals. 2. Record documents. 3. Spare parts and materials. 4. Tools. 5. Lubricants. 6. Fuels. 7. Identification systems. 8. Control sequences. 9. Hazards. 10. Cleaning. 11. Warranties and bonds. 12. Maintenance agreements and similar continuing commitments. Engineering Building Power Factor Correction Project Number: 16-019 February 1, 2016 POJECT CLOSEOUTP 01 70 00 - 3 100% CD B. 3.2 As part of instruction for operating equipment, demonstrate the following procedures: 1. Start-up. 2. Shutdown. 3. Emergency operations. 4. Noise and vibration adjustments. 5. Safety procedures. 6. Economy and efficiency adjustments. 7. Effective energy utilization. FINAL CLEANING A. General: General cleaning during construction is required by the General Conditions and included in Section "Temporary Facilities". B. Cleaning: Employ experienced workers or professional cleaners for final cleaning. Clean each surface or unit to the condition expected in a normal, commercial building cleaning and maintenance program. Comply with manufacturer's instructions. 1. Complete the following cleaning operations before requesting final inspection: a. Remove labels that are not permanent labels. b. Clean transparent materials, including mirrors and glass in doors and windows. Remove glazing compound and other substances that are noticeable vision-obscuring materials. Replace chipped or broken glass and other damaged transparent materials. c. Clean exposed exterior and interior hard-surfaced finishes to a dust-free condition, free of stains, films and similar foreign substances. Restore reflective surfaces to their original reflective condition. Leave concrete floors broom clean. Vacuum carpeted surfaces. d. Wipe surfaces of mechanical and electrical equipment. Remove excess lubrication and other substances. Clean plumbing fixtures to a sanitary condition. Clean light fixtures and lamps. e. Clean the site, including landscape development areas, of rubbish, litter and other foreign substances. Sweep paved areas broom clean; remove stains, spills and other foreign deposits. Rake grounds that are neither paved nor planted, to a smooth even-textured surface. C. Removal of Protection: Remove temporary protection and facilities installed for protection of the Work during construction. D. Compliance: Comply with regulations of authorities having jurisdiction and safety standards for cleaning. Do not burn waste materials. Do not bury debris or excess materials on the Owner's property. Do not discharge volatile, harmful or dangerous materials into drainage systems. Remove waste materials from the site and dispose of in a lawful manner. Where extra materials of value remaining after completion of associated Work have become the Owner's property, arrange for disposition of these materials as directed. END OF SECTION 01 70 00 Engineering Building Power Factor Correction Project Number: 16-019 February 1, 2016 POJECT CLOSEOUTP 01 70 00 - 4 100% CD SECTION 01 71 00 - CLEANING PART 1 - GENERAL 1.1 CLEANING A. Clean-up During Construction: Each contractor shall keep the building and premises free from all surplus material, waste material, dirt and rubbish caused by his employees or work, and at the completion of his work he shall remove all such surplus material, waste material, dirt and rubbish, as well as his tools, equipment and scaffolding, and shall leave his work clean and spotless, unless more exact requirements are specified. In case of dispute, the owner may remove all such items and charge the cost of such removal to the contractor. 1. Each sub-contractor shall perform his clean-up daily and shall transport his rubbish to an on-site location designated by the Contractor who will arrange for its removal. 2. Use of College dumpsters by the Contractor or his subcontractors is prohibited. B. Cleaners: With the exception of clean-up of the site and cleaning specifically assigned to Contractors under various sections of the specifications, all final clean-up of exterior and interior of the building shall be done by professional cleaners. C. Final Clean-up: 1. Exterior: In addition to items specified below, any new surfaces on exterior, concrete, metal, etc. shall be carefully and thoroughly cleaned. 2. Glass: Both sides of all glass in work areas shall be carefully and thoroughly cleaned by professional window cleaners and left absolutely clean and free from paint, grease, dirt, etc. 3. Hardware: Clean and polish all hardware and leave clean and free from paint, grease, dirt, etc. 4. Plumbing: Clean and polish all plumbing fixtures, fittings, and exposed plated piping. Leave clean and free from paint, grease, dirt, etc. Remove all labels. 5. Electrical: Clean and polish all electric fixtures, including glassware, switchplates, etc., and leave clean and free from paint, grease, dirt, etc. 6. Equipment: Carefully and thoroughly clean all items of equipment, mechanical, electrical, cabinets, ductwork, etc. 7. Floors: Thoroughly clean all floors. Mop resilient floor coverings with warm water and mild detergent as recommended by manufacturer of the tile, then thoroughly machine buff. Vacuum and clean carpeting. Damp mop or scrub concrete floors as required to leave them thoroughly clean when site or building is turned over to the Owner. D. Completion: The entire work inside and out, and the entire premises shall be in first-class, clean condition upon completion before being accepted by the Owner and the Owner. END OF SECTION 01 71 00 Engineering Building Power Factor Correction Project Number: 16-019 February 1, 2016 CLEANING 01 71 00 - 1 100% CD SECTION 01 74 00 - WARRANTIES AND BONDS PART 1 - GENERAL 1.1 RELATED DOCUMENTS: A. 1.2 Drawings and general provisions of the Contract, including General and Supplementary Conditions and other Specification Sections, apply to this Section. SUMMARY: A. Section Includes: General administrative and procedural requirements for warranties and bonds required by the Contract Documents, including manufacturer's standard warranties on products and special warranties. B. Related Sections: 1. Refer to the General Conditions for terms of the Contractor's special warranty of workmanship and materials. 2. General closeout requirements: Section 01700 3. Specific requirements for warranties for Work, products and installations: Individual Sections of Divisions-2 through -16 4. Certifications and other commitments and agreements for continuing services to Owner: Applicable portions of Contract Documents. C. Disclaimers and Limitations: Manufacturer's disclaimers and limitations on product warranties do not relieve the Contractor of the warranty on the Work that incorporates the products, nor does it relieve suppliers, manufacturers, and Subcontractors required to countersign special warranties with the Contractor. 1.3 DEFINITIONS: A. Standard Product Warranties: Preprinted written warranties published by individual manufacturers for particular products and specifically endorsed by the manufacturer to the Owner. B. Special Warranties: Written warranties required by or incorporated in the Contract Documents, either to extend time limits provided by standard warranties or to provide greater rights for the Owner. 1.4 GENERAL WARRANTY REQUIREMENTS: A. Related Damages and Losses: When correcting warranted Work that has failed, remove and replace other Work that has been damaged as a result of such failure or that must be removed and replaced to provide access for correction of warranted Work. B. Reinstatement of Warranty: When Work covered by a warranty has failed and been corrected by replacement or rebuilding, reinstate the warranty by written endorsement. The reinstated warranty shall be equal to the original warranty with an equitable adjustment for depreciation. Engineering Building Power Factor Correction Project Number: 16-019 February 1, 2016 WARRANTIES AND BONDS 01 74 00 - 1 100% CD C. Replacement Cost: Upon determination that Work covered by a warranty has failed, replace or rebuild the Work to an acceptable condition complying with requirements of Contract Documents. The Contractor is responsible for the cost of replacing or rebuilding defective Work regardless of whether the Owner has benefited from use of the Work through a portion of its anticipated useful service life. D. Owner's Recourse: Written warranties made to the Owner are in addition to implied warranties, and shall not limit the duties, obligations, rights and remedies otherwise available under the law, nor shall warranty periods be interpreted as limitations on time in which the Owner can enforce such other duties, obligations, rights, or remedies. E. Rejection of Warranties: The Owner reserves the right to reject warranties and to limit selections to products with warranties not in conflict with requirements of the Contract Documents. F. The Owner reserves the right to refuse to accept Work for the Project where a special warranty, certification, or similar commitment is required on such Work or part of the Work, until evidence is presented that entities required to countersign such commitments are willing to do so. 1.5 SUBMITTALS: A. Submit written warranties to the Owner prior to advertisement of the Notice of Contractor's Settlement. If the Notice of Acceptance designates a commencement date for warranties other than the date of Notice of Acceptance for the Work, or a designated portion of the Work, submit written warranties upon request of the Owner. B. When a designated portion of the Work is completed and occupied or used by the Owner, by separate agreement with the Contractor during the construction period, submit properly executed warranties to the Owner within 15 days of completion of that designated portion of the Work. C. When a special warranty is required to be executed by the Contractor, or the Contractor and a Subcontractor, supplier or manufacturer, prepare a written document that contains appropriate terms and identification, ready for execution by the required parties. Submit a draft to the OWNER through the Owner’s Representative for approval prior to final execution. D. Refer to individual Sections of Divisions 2 through 16 for specific content requirements, and particular requirements for submittal of special warranties. Engineering Building Power Factor Correction Project Number: 16-019 February 1, 2016 WARRANTIES AND BONDS 01 74 00 - 2 100% CD E. Form of Submittal: 1. Prior to advertisement of Notice of Contractor's Settlement, compile 2 copies of each required warranty and bond properly executed by the Contractor, or by the Contractor, Subcontractor, supplier or manufacturer. Organize the warranty documents into an orderly sequence based on the table of contents of the Project Manual. 2. Bind warranties and bonds in heavy duty, commercial quality, durable 3-ring vinyl covered looseleaf binders, thickness as necessary to accommodate contents, and sized to receive 8.5" by 11" paper. 3. Provide heavy paper dividers with celluloid covered tabs for each separate warranty. Mark the tab to identify the product or installation. Provide a typed description of the product or installation, including the name of the product, and the name, address and telephone number of the Installer. 4. Identify each binder on the front and the spine with the typed or printed title "WARRANTIES AND BONDS", the Project title or name, and the name of the Contractor. 5. When operating and maintenance manuals are required for warranted construction, provide additional copies of each required warranty, as necessary, for inclusion in each required manual. PART 2 - PRODUCTS (Not applicable) PART 3 - EXECUTION (Not applicable) END OF SECTION 01 74 00 Engineering Building Power Factor Correction Project Number: 16-019 February 1, 2016 WARRANTIES AND BONDS 01 74 00 - 3 100% CD SECTION 01 78 00 - DEFINITIONS AND EXPLANATIONS PART 1 - GENERAL 1.1 RELATED DOCUMENTS: A. 1.2 Drawings and general provisions of the Contract, including General and Supplementary Conditions and other Specification sections, apply to work of this section. SUMMARY: A. Section Includes: Definitions of certain terms used in the specifications, and explanations of the language, abbreviations thereof, format and certain conventions used in the specifications and associated Contract Documents. B. Limitations of Scope: The definitions and explanations of this section are not necessarily either complete or exclusive, but are general for the work to the extent such definitions or explanations are not stated more explicitly in other provisions of the Contract Documents. 1.3 DEFINITIONS: A. The term “Owner” shall mean University of Colorado Colorado Springs. B. Project Manual: The term "Project Manual" refers to a bound, printed volume or volumes, which includes conditions of the Contract and the Specifications. It may also include bidding requirements, contract forms, details, schedules, surveys, reports or other relevant items which may or may not be Contract Documents. C. General Requirements: Provisions and requirements of other Division 1 Sections apply to the entire work of the Contract and, where so indicated, to other elements of work which are included in the Project. D. Indicated: The term "indicated" is a cross reference to graphic representations, notes or schedules on the drawings, to other paragraphs or schedules in the specifications, and to similar means of recording requirements in the Contract Documents. Where terms such as "shown", "noted", "scheduled" and "specified" are used in lieu of "indicated", it is for the purpose of helping the reader accomplish the cross reference, and no limitation is intended except as specifically noted. E. Directed, Requested, etc.: Terms such as "directed", "requested", "authorized", "selected", "approved", "required", "accepted", and "permitted" mean "directed by the Owner’s Representative", "requested by the Owner’s Representative", etc. However, no such implied meaning will be interpreted to extend the Owner’s Representative responsibility into the Contractor's area of construction supervision. F. Installer: The entity (person or firm) engaged by the Contractor or his Subcontractor or Sub-subcontractor for the performance of a particular element of construction at the project site, including installation, erection, application and similar required operations. It is a general requirement that Installers be expert in the operations they are engaged to perform. G. The term "experienced", when used with the term "Installer" means having completed a minimum of 5 successful previous projects similar in size and scope to this Project and means the Installer is familiar with the precautions required and has complied with requirements of the authorities having jurisdiction. Engineering Building Power Factor Correction Project Number: 16-019 February 1, 2016 DEFINITIONS AND EXPLANATIONS 01 78 00 - 1 100% CD H. Where the specifications require Installer experience or other qualifications, such requirements apply to the firm and not to its employees or individual members. Where firm ownership has changed after the required experience occurred, the Owner reserve the right to consider the ownership change as invalidating the experience requirements. I. Project Site: The space available to the Contractor for the performance of the Work, either exclusively or in conjunction with others performing other work as part of the project. The extent of the project site is shown on the drawings, and may or may not be identical with the description of the land upon which the project is to be built. J. Testing Laboratory or Agency: An independent entity engaged to perform specific inspections or tests of the work, either at the project site or elsewhere; and to report and (if required) interpret the results of those inspections or tests. K. Approve: Where used in conjunction with the Owner’s Representative action on the Contractor's submittals, applications and requests, is limited to the Owner’s Representative responsibilities and duties as specified in the General and Supplementary Conditions. Such approval shall not release the Contractor from responsibility to fulfill requirements of the Contract Documents, unless otherwise provided in the Contract Documents. L. Regulation: The term "Regulations" includes laws, statutes, ordinances and lawful orders issued by authorities having jurisdiction, as well as rules, conventions and agreements within the construction industry that control performance of the Work, whether they are lawfully imposed by authorities having jurisdiction or not. M. Contractor's Option: Where materials, products, systems or methods are specified to be at the Contractor's option, the choice of which material, method, product or system will be used is solely the Contractor's. There will be no change in Contract Sum or Time because of such choice. N. Furnish: The term "furnish" is used to mean, "supply and deliver to the project site, ready for unloading, unpacking, assembly, installation, and similar operations". O. Install: The term "install" is used to describe operations at the project site including the actual "unloading, unpacking, assembly, erection, placing, anchoring, applying, working to dimension, finishing, curing, protecting, cleaning and similar operations". P. Provide: The term "provide" means "to furnish and install, complete and ready for the intended use". Q. Guarantee: The narrow definition of the term "warranty" is hereby established as applying to both "warranty" and "guarantee" which terms are used interchangeably. 1.4 SPECIFICATION EXPLANATIONS: A. General: This article is provided to help the user of these specifications to more readily understand the format, language, implied requirements and similar conventions of content. None of these explanations will be interpreted to modify the substance of the requirements. B. Specification Format: These specifications are organized and based on the CSI 16-Division format, including subdivision of the Divisions into Sections generally conforming to CSI "Masterformat" for section titles and numbers. Engineering Building Power Factor Correction Project Number: 16-019 February 1, 2016 DEFINITIONS AND EXPLANATIONS 01 78 00 - 2 100% CD C. 1.5 Imperative Language: Imperative language is used generally in the specifications. Requirements expressed imperatively are to be performed by the Contractor. At certain locations in the text, for clarity, contrasting subjective language is used to describe the responsibilities which must be fulfilled either indirectly by the Contractor or, when so noted, by others. SPECIFICATION CONTENT CONVENTIONS: A. Overlapping Requirements: Where compliance with two or more industry standards or sets of requirements is specified, and overlapping of those requirements also establishes different or conflicting minimums or levels of quality, the more stringent requirement will be enforced unless the Contract Documents specifically indicate otherwise. B. Refer apparently equal but different requirements and uncertainties as to which level of quality is required to the Owner’s Representative for decision before proceeding. C. In certain circumstances language used in specifications and other Contract Documents is of the abbreviated type. Implied words and meanings will be appropriately interpreted. Singular words will be interpreted as plural and plural words will be interpreted as singular where applicable and where the full context of the Contract Documents so indicates. D. Specialists: In certain circumstances the specification requires or implies that specific elements of the Work be assigned to specialists or expert entities who must be engaged to perform that element of the work. Such assignments are special requirements over which the Contractor has no choice or option. They are intended to establish which party or entity involved in a specific element of the Work is considered as being sufficiently experienced in the indicated construction processes or operations to be recognized as "expert" in those processes or operations. Nevertheless, the ultimate responsibility for fulfilling all contract requirements remains with the Contractor. E. These requirements should not be interpreted to conflict with the enforcement of the building codes and similar regulations governing the Work. They are also not intended to interfere with local trade union jurisdictional settlements and similar conventions. F. Trades: The use of certain titles such as "carpentry" in the specification is not intended to imply that the work must be performed by accredited or unionized individuals of a corresponding generic name, such as "carpenter". It also is not intended to imply that the requirements specified apply exclusively to tradepersons of that corresponding generic name. Engineering Building Power Factor Correction Project Number: 16-019 February 1, 2016 DEFINITIONS AND EXPLANATIONS 01 78 00 - 3 100% CD 1.6 DRAWING SYMBOLS: A. Graphic symbols used on the Drawings are those recognized in the construction industry for purposes indicated. Where not otherwise noted, symbols are defined by "Architectural Graphic Standards", published by John Wiley & Sons, Inc., seventh edition. B. Mechanical/Electrical Drawings: Graphic symbols used on mechanical and electrical Drawings are generally aligned with symbols recommended by ASHRAE. Where appropriate, they are supplemented by more specific symbols recommended by technical associations including ASME, ASPE, IEEE and similar organizations. Refer instances of uncertainty to the Owner’s Representative for clarification before proceeding. PART 2 - PRODUCTS (Not Applicable) PART 3 - EXECUTION (Not Applicable) END OF SECTION 01 78 00 Engineering Building Power Factor Correction Project Number: 16-019 February 1, 2016 DEFINITIONS AND EXPLANATIONS 01 78 00 - 4 100% CD