Details Tender Name The Wayside Chapel - Community Hall Audio/Visual Tender Reference # RFT004 Open Date Monday, 28 May 2013 Close Date Saturday, 15 Jun 2013 Department Community Development Tender Type Lump Sum Tender Categories Fit-Out: Audio/Visual Returnable Schedules Additional Documents Appendix 1 & 2 Level 2 Building Plan Level 3 Building Plan Contact Guy Cooper - guy.cooper@thewaysidechapel.com Overview The Wayside Chapel is seeking a Principal Contractor to project manage, design and construct an Audio-Visual solution in its Community Hall. The project will ensure that the multi-purpose space will be able to host a range of events including theatre productions, concerts, art shows, films, training events, corporate functions, educational forums and sound recording. Requirements The Principal Contractor appointed will have the required skills to manage the project from conception through to completion. In consultation with The Wayside Chapel’s executive team, the successful respondent will be responsible for the design and installation of the solution. The Principle Contractor will direct all consultants, subcontractors and procure all materials required for the project. The successful respondent will be able to demonstrate: Previous experience in undertaking projects of a similar size and nature Ability to deliver on time and within budget Capacity to undertake this project at this time The final solution commissioning and operational training plan Ongoing maintenance schedules Objectives To have a fully equipped multipurpose Community Hall that will enable The Wayside Chapel to: Produce theatre productions Stage musical performances and concerts, orchestral, choral or other Host quality, large scale Corporate Functions Hold Community Forums and Education Sessions Operate as a gallery, hosting artistic, historic and informative exhibitions Record and mix sound and music to studio quality Tender Process Go to market with an invitation to submit a tender in the form of a draft design solution and lump sum price Liaise with respondents, providing additional information as requested (e.g, architectural plans, electrical drawings, elaboration and/or clarification of objectives and proposed usage) Review and evaluate the tender submissions and supporting documentation against the criteria set out in this RFT document; Making a recommendation to the Board of The Wayside Chapel for the Preferred Principal Contractor Appendix 1 Returnable Schedule 1: Lump Sum Tender Price To: The Wayside Chapel: We: __________________________________ (Name of Tenderer) ___________________ (ABN), tender to perform the work under the Contract in accordance with the Design & Specification included in Appendix 2 on the following basis: Lump Sum Tender Price (plus GST) $ Address of Tenderer: Address or Registered Office of Tenderer: Contact Name: Contact email: Contact Telephone Number: Signed by or on behalf of the Company: ………………………………………………………. Date ……/……………/.2013 Appendix 2 Solution Requirements: Design, Specification & Construction Program Design Provide at least 1 Plan of the Community Hall and 1 Elevation of each wall of the Community Hall, detailing the location and specification of hardware (more than one of each is acceptable if this better enables demonstration of specific types of hardware). Specifications Provide specification of all other hardware, with particular reference to the bio-box and other centralized controls. Construction Program The construction program must: Be in the form of a bar chart and network diagram, showing the following: The interrelationship of the activities and their sequence; The duration of the activities; The commencement and completion dates of the activities; The Date for Practical Completion