ANNUAL REGIONAL BULK PERFORMANCE EVALUATION REPORT OF XONXA DAM TRANSFER SCHEME AND BULK WATER SUPPLY - CHRIS HANI DISTRICT MUNICIPALITY CHIEF DIRECTORATE: BULK INFRASTRUCTURE PROGRAMME PERIOD: 01 APRIL 2013 TO 31 MARCH 2014 2 Programme Management: Regional Bulk Infrastructure TABLE OF CONTENTS 1. Introduction 2. Background 2.1 2.2 2.3 2.4 2.5 3. Progress to date 3.1 3.2 3.4 3.5 4. Outcomes and outputs Beneficiaries and project results Jobs Created Conclusions / Lessons Learned 5.1 5.2 5.3 5.4 6. Implementation of approved business plan Schedules of work and phasing of the activities 3.3 Risks taken and management thereof Capacities dedicated to the programme Key challenges within the project Project result and beneficiaries 4.1 4.2 4.3 5. Description of project Project History Project concept, design and plan Start date – duration of the programme Fund previously allocated to project Main successes and failures of the project to date Ownership and sustainability of infrastructure works Outcomes, outputs, successes and failures versus the cost Lessons Learned Recommendations ANNEXURE A: Project Implementation Photos ANNEXURE B: Project schedule – Included in file folder ANNEXURE C: Cash flow Projections ANNEXURE D: Labour Schedule (Actual) - Included in file folder APRIL 2014 3 Programme Management: Regional Bulk Infrastructure 1. APRIL 2014 INTRODUCTION In terms of Section 10(7) (b) of the Division of Revenue Act (DoRA), Act No 2 of 2013 as promulgated in Government Gazette No 36555 dated 10 June 2013; the transferring national officer must submit an annual performance report for Schedule 6 within four months in respect of a province and six months in respect of a municipality after the end of the financial year to the National Treasury. The Regional Bulk Infrastructure Grant (RBIG) is a Schedule 6 indirect conditional grant for the benefit in kind of municipalities. This performance evaluation report, covering quarter 4 and annual report of the 2013/14 fiscal year, for the Xonxa Dam Transfer Scheme and Bulk Water Supply project, one of the Regional Bulk Infrastructure Grant projects, currently being implemented by the Chris Hani District Municipality (CHDM) in the Eastern Cape Province, with Department of Water Affairs (DWA) as the funder and CHDM (being the Water Services Authority) as co-funder. 2. BACKGROUND 2.1 Description of Project The Xonxa Dam Bulk Transfer Scheme and Bulk Water Supply project comprises the augmentation of the Queenstown bulk water supply through the inter-regional transfer of raw water from the Xonxa Dam to the Queenstown Water Treatment Works. The main purpose for this project is to augment the current water supply shortfall within the municipality and to open up the urgently needed supply of bulk potable water to indigent areas within and surrounding Queenstown. Without this project and its components, the service delivery as a whole within the Lukhanji Local Municipality (LM) cannot be extended to eradicate current service delivery backlogs. The water supply shortfall has a major impact on the social and economic development within this region and currently impacts greatly on the future social and economic growth and sustainability within the municipality. The total project cost is currently estimated at R470 000 000 (including VAT). This estimate includes contingencies and contract price adjustments (CPA). The contract is being implemented through six (6) contracts due to staggered annual funding allocations: Contract 1: Construction of Pumping Station (Civil Works) Contract 2: Manufacturing and Supply of Coated and Lined Steel Pipes Contract 3: Installation of Pumping Main Contract 4: Installation of Gravity Main Contract 5: Mechanical & Electrical (M&E) Installation Contract 6: Machibini Potable Bulk Water Supply All institutional and legal criteria are in place to successfully implement this project. With regards to the existing cost recovery system(s), all by-laws, indigent policy and credit control policies are in place. Lukhanji LM has an existing billing system to recover costs from beneficiaries within the available demographic area. 4 Programme Management: Regional Bulk Infrastructure 2.2 APRIL 2014 Project history As far back as 1920 the Xonxa Dam Bulk Transfer Scheme was identified as the preferred option for the bulk augmentation of the Lukhanji Municipality water supply. Studies by the National Department of Water Affairs (DWA) supported this solution: “Augmentation of Queenstown Water Supplies”, October 2003 “Lukhanji Regional Water Supply Feasibility Study”, January 2006 The DWA reports clearly identified the shortfall in water supply currently being experienced in the Lukhanji Municipality. 5 Figure 1: Locality Plan and Project Extent 2.3 Project concept, design and plan Studies by the National Department of Water Affairs (DWA) clearly identified and confirmed the shortfall in water supply being experienced in the Lukhanji Municipality. The following table presents the water balance as per the DWA reports: Table 2.1: Lukhanji LM Water Balance Area Queenstown Complex Demand 2005 (Ml/day) -21.51 2020 (Ml/day) -24.11 2045 (Ml/day) -28.22 Ilinge & Machibini villages Demand -6.6 -6.6 -6.6 Waterdown Dam (Assured Yield) 12.6 12.6 12.6 Bongola Dam (Assured Yield) 3.7 3.7 3.7 Total shortfall to be augmented from Xonxa with Waterdown and Bongola Dam operated at safe yield -11.81 -14.41 -18.52 Ref. Lukhanji Regional Water Supply Feasibility Study, January 2006 Since 2003, Chris Hani District Municipality has pursued various options to secure the required funding for the development and implementation of this project and has only recently (in 2010) been able to avail limited funds through RBIG funding to successfully initiate the planning and design phase of the project. In order to address the water supply and infrastructure development problems the solution is the augmentation of the Queenstown water supply through the bulk raw water conveyance from the Xonxa Dam to the Queenstown Water Treatment Works. From the water treatment works bulk potable water will be conveyed to the specific indigent areas within and surrounding Lukhanji Municipality. Over and above the augmentation to Queenstown the project will also open up the alternative water supply (surface) opportunity to villages in the Xonxa dam area. As per design the new bulk infrastructure to be constructed under this project comprise: New pump station (2 512 kW) at Xonxa Dam comprising three (two duty and one standby) high lift pumps, with two pumps to pump 330 ℓ/s at a total head of 479 m, complete with fittings, pipe work and civil and electrical services; A DN600 welded steel pipe connection from the existing Xonxa Dam off-take, across the White Kei River to the pump station site. This will open up surface water supply to the surrounding Xonxa area; Eskom electrical supply to the pump station (2.5 MVA); Bulk DN600 welded steel pipeline (rising main), 23 km in length, complete with valves, chambers, meters, cathodic protection and telemetry system; Concrete Break Pressure Reservoir (5 Mℓ); Bulk DN500 steel gravity main, 11.65 km in length complete with valves, chambers, meters and cathodic protection; Full mechanical, electrical and electronic installation for the transfer scheme pipeline; 7 Programme Management: Regional Bulk Infrastructure APRIL 2014 Discharge and energy dissipation infrastructure at the WTW reservoir with the possible energy recovery of 280 kW/hr to effectively re-use the residual head; Machibini bulk water supply pump station (133 kW) at the eZibeleni high level reservoirs, consisting of two (one duty and one standby) intermediate pumps, pumping 47 ℓ/s at a total head of 220 m; Machibini bulk DN250 steel pipeline (rising main) 1.1 km in length, complete with valves, chambers, meters and cathodic protection; Break pressure reservoir; Distribution Reservoir (2 Mℓ); Machibini and Ilinge bulk gravity distribution pipeline(s) (27 km). The infrastructure is designed and sized in accordance with the demands for a 35year planning horizon up to 2045. This supply capacity will allow for the refurbishment of the aged Waterdown pipeline in the near future. The Xonxa design is based on the demands as per Table 2.1 with a design Peak Factor (PF) of 1.5. The PF is based on the peak week factor plus allowance for 18 hrs pumping (to avoid punitive power tariffs) as well as published data, allowance for balancing storage and past experience from similar bulk conveyance schemes. Each supply/demand area however is unique. The choice of PF for this design as well as demand was benchmarked against current actual available water demand data for Queenstown. This data references comprised: 1. Water abstraction data from Bongola and Waterdown Dams, April 2009 to May 2013; 2. Records of daily water supply (demand) from the water treatment works, June 2012 to July 2013 3. Billing records for water use in Queenstown, Mlungisi and EZibeleni. These records were not in a convenient / useful format. Based on data reference one (1), the projected demand of 28.11 Mℓ/d to 30.01 Mℓ/d for the period 2005 to 2015 compares favourably to the actual 2013 demand of 26.56 Mℓ/d with a factor of safety allowance included. Based on data reference 2, the data presented a slightly lower average monthly demand but still verifies the original water demands indicated; however the main purpose of evaluating the daily flows is to determine / benchmark the PF for design purposes. As per design the Peak Factor (PF) is defined as PF (flow) + PF (pumping hrs). The average PF (flow) as per the reference 2 data set is 1.15 with the max. PF = 1.26. Using data from the paper by Jacobs & Strijdom, the recommend PF (peak week) is shown as 1.28. Using the design diagrams based on equations developed by Smook that take into account balancing storage it gives a PF of 1.16. The PF for pumping hrs is calculated as 1.235 making the PF = 1.16 x 1.235 = 1.43 (Smook equations) and 1.28 x 1.235 = 8 Programme Management: Regional Bulk Infrastructure APRIL 2014 1.58 (Jacob & Strijdom). The PF based on the average actual PF = 1.15 x 1.235 = 1.42 and the max PF = 1.26 x 1.235 = 1.56. The actual design PF of 1.5 is therefore considered accurate based on actual data reference. The current design is the most feasible solution taking economic, social, environmental and institutional and engineering challenges into consideration. The preferred solution will mitigate the current water supply shortfall in a holistic and practical manner. It will ultimately augment and provide a sufficient and reliable (low risk) bulk water source. This augmentation will also open up basic service delivery opportunities urgently needed in the Lukhanji Municipally and hinterland. It will also allow the opportunity for the refurbishment and upgrade of the Waterdown pipeline currently in urgent need of such works. Due to current funding allocations, timeframes and magnitude of the project, the Works must be implemented through six (6) separate contracts: 2.4. Contract 1: Pump Station and Dam Connection Contract 2: Materials Supply Contract for the DN600 & DN500 pipes Contract 3: Installation of the Pumping Main (DN600) Contract 4: Installation of the Gravity main (DN500) and Reservoir Contract 5: Installation of the full Mechanical, Electrical and Electronic equipment Contract 6: Machibini and Ilinge Bulk Water Supply (Civil, M&E). Start date – duration of the programme The project planning and design was initiated in 2010 with appointments for specialist studies, water use and environmental applications initiated concurrently. The design development, documentation and procurement as well as implementation /construction stage is currently in various stages on each of the proposed contracts. The current implementation strategy is mainly guided by project funding allocations. The following dates have been set in line with the current anticipated implementation strategy. Contract 1: Pump Station and Dam Connection Current Project Status: Contract Number: Contractor: Contract Amount: Contract Award Date: Contract Start date: Completion Date: Close-out Stage 35/2011/MD (AM) SC Contractors cc R24 814 921.35 (incl. VAT) 22 February 2012 5 March 2012 (Site Handover) December 2013 Contract 2: Supply and Delivery of Coated and Lined Steel Pipes Current Project Status: Contract Number: Contractor: Contract Amount: Contract Award date: Contract Start Date: Completion Date: Implementation/Construction Stage 55/2011/MD (AM) Capital Star Steel (Pty) Ltd R66, 276,665 (incl. VAT) 22 February 2012 5 March 2012 (procurement of materials) 30 June 2014 (pending gravity main contract) 9 Programme Management: Regional Bulk Infrastructure APRIL 2014 Contract 3: Installation of Pumping Main Current Project Status: Implementation/Construction Stage Contract Number: 19/2012/MD (AM) Contractor: Esorfranki Pipelines (Pty) Ltd Contract Amount: R92 626 742.43 (incl. VAT) Contract Award date: 26 October 2012 Contract Start Date: 12 November 2012 Completion Date: 7 June 2014 (based on approved extension of time claims) Contract 4: Installation of Gravity main and Reservoir Current Project Status: Tender Adjudication submitted contract to be awarded by CHDM Contract Award Date: Mid-May 2014 Contract Start date: June 2014 Completion date: December 2015 17/02/2014. Awaiting Contract 5: Mechanical and Electrical Installations Current Project Status: Documentation and Procurement. Contract document to be finalized upon confirmation of funding availability. Tender Date: tbc (funding dependent) Contract Start date: tbc (funding dependent) Completion date: tbc (funding dependent) anticipated 2015 Contract 6: Machibini and Ilinge Bulk Water Supply (Civil, M&E) Current Project Status: Design development & documentation and procurement stages. Environmental approvals in progress. Tender Date: tbc (funding dependent) Contract Start date: tbc (funding dependent) Completion date: tbc (funding dependent) anticipated 2016 The current estimated completion date, based on current and anticipated MTEF allocations is March 2016. 2.5. Funds previously allocated to project Table 1 below indicates the DWA funding that was made available to the project up to date. Table 1: Funding/Expenditure for the past financial years 2007/08 to 2010//11 2011/12 2012/13 ECR002 3. R17,953,808 R11,746,955 R69,761,901 2013/14 R77,912,326 PROGRESS TO DATE The performance evaluation was conducted on 07 April 2014 by a team listed below: T Dlulane SV Pongoma G.B. Tshonti C Arendse DWA – Regional Office EC DWA – Regional Office EC CHDM – ISD Co-ordinator RHDHV – Resident Engineer 10 Programme Management: Regional Bulk Infrastructure 3.1 G Henning I Foord B Marasha APRIL 2014 RHDHV – Assist. Resident Engineer Esorfranki – Site Agent CCD Consulting – ISD Consultant Implementation of the approved business plan The current status of each of the projects is as follows: 1. Contract 1: Construction of Pump Station and Dam Connection (Civil Works) Current Project Status: Stage 1 – 4 Complete Stage 5: Construction Administration and Inspection (99.5%) Pump Station building works at practical completion. Snag list items on-going. 2. Contract 2: Manufacturing, Supply and Delivery of Coated and Lined Steel Pipes Current Project Status: Completion date: Stage 1 – 4 Complete Stage 5: Construction Administration and Inspection (77%) 1647 lengths of 610mm pipes delivered to site for pumping main installation contract. Balance of pipes delivered in April / May 2014. 975 lengths of 508 mm pipes are currently being manufactured. May/June 2014 (with commencement of gravity main) 3. Contract 3: Installation of Pumping Main (DN600) Current Project Status: Completion date: Stage 1 – 4 Complete Stage 5: Construction Administration and Inspection (75%). Work is currently under construction. 07 June 2014 (extension of time claims approved due to community unrest) 4. Contract 4: Installation of Gravity main (DN500) and 5 Mℓ Reservoir Current Project Status: Completion Date: Stage 1 – 4 Complete Stage 5: Awaiting Contract award by CHDM. Dec 2015 (current estimate) 5. Contract 5: Mechanical and Electrical Installations Current Project Status: Completion Date: Stage 1 – 3 Complete Stage 4: Design Development & Documentation and Procurement Stages (85%) Tender documents and drawings are in final draft. Implementation time frame is currently dependent on implementation/ completion of gravity main contract. Dec 2015 (current estimate) 11 Programme Management: Regional Bulk Infrastructure 6. APRIL 2014 Contract 6: Machibini and Ilinge Bulk Water Supply (Civil, Mechanical and Electrical) Current Project Status: Stage 1 – 2 Complete Stage 3: Design Development (50%) Completion Date: March 2016 (current estimate) The progress to date on sub-consultant studies and approvals is as follows: Dept of Water Affairs Applications The water use license for this scheme’s water abstraction from the Xonxa Dam was approved by Department of Water Affairs on 24 June 2010 to the abstraction value of 6,668,550 m³ per annum (Ref 9/03/09/279 SW). The DWA General Authorization for all Stream Crossings on the project was approved on 30 January 2012 (Ref 27/2/2/S932/1). The DWA RBIG IRS Report was approved on 16 February 2012. DWA approval to connect to the Xonxa Dam off-take has been received with the final QCPs being approved for the valve. Environmental Application: The Basic Assessment Report (BA) was approved with the ROD issued in September 2011 (NREC 134-009-2011). Macibini Environmental applications and approvals in progress. Authority Approvals: Way Leave Applications The large extent of the proposed pipeline servitude falls within either State or Municipal land with only one private property affected by the implementation of this project. There are also some quitrent properties within villages that are impacted by the pipeline route and installation Work to be done. This is currently being resolved with a specialist dealing with all land legal matters, to be followed by a servitude registration. The Eskom Way Leave application (co-use approval) was submitted in November 2010 with final approval received from Eskom on 30 November 2010. Final approval from Eastern Cape Roads and Public Works for the implementation of this scheme was received on 14 April 2011. Eskom Electrical Supply The 2.5MVA electrical supply to the pump station is done by Eskom. This will be an Eskom internal design, external constructed project and is currently in the implementation phase. All Eskom connection fees have been paid in full. Expected date for supply line to be commissioned is 2nd quarter of 2014, however Eskom has also indicated that they have run into community unrests and this date is expected to shift to the 3rd quarter of 2014. Cathodic Protection (CP) Survey and Design The CP resistivity survey and design has been completed. Cathodic protection installation monitoring is ongoing for the various pipeline construction contracts. 12 Programme Management: Regional Bulk Infrastructure APRIL 2014 Geotechnical Investigations All geotechnical investigations along the main pipeline route from Xonxa dam to Queenstown have been completed with a detailed geotechnical report submitted in July 2010. The geotechnical investigation is still to be done on the Machibini & Ilinge pipeline routes. Engineering Surveys and Servitudes Registration: The detailed engineering survey has been completed along the main pipeline route from Xonxa Dam to Queenstown. Final survey is still to be done on the Machibini & Ilinge pipeline routes pending environmental inputs. Servitude registration will be done through external conveyors following final land legal resolve process. Final registration will be in place at commissioning of pipeline. With regards to the existing cost recovery system(s), all bylaws, indigent policy and credit control policies are in place. Lukhanji LM has an existing billing system to recover costs form beneficiaries within the available demographic area as well as a current operations and maintenance contract for the water treatment works and bulk pipeline infrastructure. Table 2.2: Milestones Product Feasibility Study Planned date for Name of Organization completion compiling/ developing FS/IRS/Design/EIA Royal Haskoning DHV Completed (formerly Stewart Scott) Date FS/IRS/Design/EIA approved August 2004 Implementation Readiness Study Royal Haskoning DHV (formerly SSI Engineers) Completed February 2012 Preliminary Design Royal Haskoning DHV (formerly SSI Engineers) Completed March 2009 EIA Pollution Control Technologies Completed September 2011 WUL Pollution Control Technologies Completed June 2010 Operation and Royal Haskoning DHV / Maintenance Plan CHDM 2015/16 pending Financial Funding Royal Haskoning DHV / Plan CHDM 2013/14 pending Completed pending Design Royal Haskoning DHV (formerly SSI Engineers) 3.2 Schedules of work and phasing of the activities Refer to Section 2.4 and Section 3.1 above. A Gantt chart / programme for Contract 3 is attached as Annexure B. 3.3 Risks taken and management thereof As the Scheme comprises of infrastructure, no major risks other than those normally encountered on a project of this size and nature had to been taken. 13 Programme Management: Regional Bulk Infrastructure APRIL 2014 Acceptable risks identified on the project and which are managed responsibly and in accordance with the applicable laws and legislation is as follows: Financial Legal Occupational Health and Safety Environmental Quality Sustainability of investment / infrastructure Eskom has indicated that they also experienced community unrest and that the original commissioning date of the 1st quarter in 2014 has now possibly moved to the 2nd or 3rd quarter of 2014. It is not expected that this will impact on the M&E contract as funding for this contract is not yet allocated. Another risk being faced on a frequent basis on site in the Xonxa and Machibini villages is community unrest. Chris Hani District Municipality, with the assistance of Umhlaba Consulting Services, appointed through Royal Haskoning DHV, have dealt with this, however we are still experiencing community unrest on a regular basis. Currently all matters have been resolved. This will be closely monitored throughout the duration of the remaining contracts. 3.4 Capacities dedicated to the programme The capacities dedicated to the programme are as follows: 3.5 Water Services Authority: Chris Hani District Municipality Water Services Provider: Lukhanji Municipality Funding: Department of Water Affairs – Regional Bulk Infrastructure Grant (RBIG) and Chris Hani District Municipality (co-funding) Regulator – Department of Water Affairs Overall Programme and Project Management: Royal Haskoning DHV / CHDM PMU Specialized professional services, financial management and administrative support: Royal Haskoning DHV / Sub-consultants Design, contract administration and construction monitoring: Royal Haskoning DHV Construction work: o Contract 1: SC Contractors cc o Contract 2: Capital Star Steel (Pty) Ltd o Contract 3: Esorfranki Pipelines (Pty) Ltd o Contract 4 - 6: TBA Key challenges within the project The following key challenges to date are highlighted: Staggered funding allocations on the project have required that the design be adjusted to adopt a phased implementation strategy/approach. The original implementation strategy was adjusted from three to six contracts. Delay in pumping main construction project due to community unrest demanding upgrading of existing local water supply infrastructure has since been resolved. 14 Programme Management: Regional Bulk Infrastructure APRIL 2014 On-going difficulties in obtaining community cooperation in gaining access along the pipeline route through the Xonxa village as the community anticipates compensation for accommodating the pipeline going past the village within state owned land. Delay in pumping main construction project due to land use compensation demands in the Machibini area. Delay in pumping main construction project due to labour demands in the Machibini area. Inclement weather (consequential delays) impacted on progress of the dam connection installation through the White Kei River. 4. PROJECT RESULTS AND BENEFICIARIES 4.1 Outcomes and outputs The current expected outcomes and outputs are on track and in line with the programme. 4.2 Beneficiaries and project results The Xonxa Dam Transfer Scheme and Bulk Water Supply project will impact directly on the Lukhanji Municipality area as well as the Xonxa area situated in the Emalahleni Municipality. The total extent of the Lukhanji Municipality is 4 388 square kilometre (km²) making up 12% of the entire district. Based on the Lukhanji Integrated Development Plan 2010/2011 and research done by various agencies including Global Insight (2006) and the Bureau of Market Research (2006) it is agreed that the population of Lukhanji has grown by an average of one percent per annum between 2001 and 2006. Given this modest growth the population of Lukhanji is estimated at 208 081. The majority (91%) of the population is black. Lukhanji has 52 020 households. This translates to an average household size of 4 persons per household and almost 25.68% of the entire district population. The Lukhanji LM is a comparatively poor area with the number of indigent people (earning less than the indigent threshold of R2160/month) living in the area at 75.4% (39 223 households or 156 892 people). The Xonxa Dam Transfer Scheme and Bulk Water Supply project will also open up the water supply to (number of villages) villages surrounding the Xonxa Dam. The affected Xonxa Villages accounts for an additional 1,868 poor households (13,055 people). The beneficiaries of this project are all highly dependent on Government Grant Funding. The Xonxa Dam Transfer Scheme and Bulk Water Supply will impact directly on the entire population through the delivery of basic services (water, sanitation and housing) and promote economic development within the Lukhanji LM, creating further employment opportunities. Over and above the overall project impact the immediate local investment and benefits include the use of local labour and local SMME contractors in accordance with the Contracts in place. The optimum use of local labour is encouraged with a contractual obligation to implement 20% of the works on the Pump Station contract 15 Programme Management: Regional Bulk Infrastructure APRIL 2014 and 30% of the works on the Pumping Main installation contract using local SMME contractors. There is also further immediate local investment in the Xonxa community with the upgrading, maintenance and rental use of the community accommodation facilities as site camp on Contract 19/2012/MD (AM) Pumping Main installation. 4.3 Jobs Created Based on the current implementation approach, it is estimated that approximately 300 temporary jobs will be created during the implementation of this project, split between 108 females (36%) and 192 males (64%) and will include: Adults (>35 years of age): 180 (60%) Youth (< 35 years of age): 120 (40%) Disabled Persons: 33 (11%) The total projected man hours is estimated at 1,080,000 and can be allocated to: Adults (>35 years of age): 648 000 Youth (< 35 years of age): 432 000 Disabled Persons: 118 800 To date, 98% of the labour used on Contract 35/2011/MD (AM) Pump Station and Dam Connection has been local labour. The total number of labour (person) days for quarters 1, 2, 3 and 4 is 22 831 days with a local investment of R4 008 619. The combined labour schedule (SC Contractors and Esorfranki) for all four quarters of 2013/ 2014 has been included as Annexure D. 5. CONCLUSION / LESSONS LEARNED 5.1 Main successes and failures of the project to date The first 3 contracts are currently in implementation with the first contract, Pump Station and Dam Connection, at completion stage. All environmental and institutional approvals are in place. Most of the major community issues have been resolved and are managed on an on-going basis. Quality of construction work and materials are up to standard and being monitored accordingly. OHS and environmental controls are in place and being managed successfully. 5.2 Ownership and sustainability of infrastructure works The ownership of the bulk infrastructure will fall under CHDM with the operation and maintenance to be done through the WSP and the current O&M contracts in place. 5.3 Outcomes, outputs, successes and failures versus the costs The delay in funding allocations and staggered implementation approach has impacted on construction as well as monitoring costs as well as through inflation cost on materials, labour, fuel etc. Through proper management of the contracts, early procurement of high value materials and fittings i.e. steel coil/pipes, valves etc. the impact of inflation could be managed and ring fenced much better and this is definitely one of the successes on this project; however this is only one component and the type of equipment procured 16 Programme Management: Regional Bulk Infrastructure APRIL 2014 allowed accommodating early procurement without any financial, legal or operating risk to the client. 5.4 Lessons Learned Ongoing community perceptions are very difficult to manage throughout the entire project lifecycle. What is agreed and set in the pre-planning / feasibility stages and what is anticipated or demanded during the implementation stages are not always the same; the difference being that delays or disputes at the implementation stage come at a great cost to the project. Bulk infrastructure project, in light of the current funding and procurement constraints should be designed on a phased implementation approach. This eliminates re-design and adjustments before, and during, implementation. 6. RECOMMENDATIONS Implementation of the entire project as soon as funding allocations allow, limiting increase in project costs and addresses urgently needed water augmentation and “high risk” water supply to Lukhanji LM. 17 Programme Management: Regional Bulk Infrastructure ANNEXURE A: PROJECT IMPLEMENTATION PHOTOS The following contracts are currently in implementation phase: Contract 35/2011/MD (AM): Pump Station and Dam Connection Photo 1: Pump Station Building. Photo 2: Main Pump Hall APRIL 2014 18 Programme Management: Regional Bulk Infrastructure Photo 3: Operators house constructed above pump station. Outstanding works include earth lock block paving and clear view fencing. Photo 4: View of the back of the house with the septic tank shown at the bottom right of the photograph. APRIL 2014 19 Programme Management: Regional Bulk Infrastructure Photo 5: View of the kitchen inside the pump station operator house which is in the completion phase. Photo 6: Photograph showing the locality of the pump station to the operator’s house. As can be seen, the 12 pipes which CHDM requested be supplied and stored for future repair purposes will be stored on a platform near the back-half of the operator’s house. APRIL 2014 20 Programme Management: Regional Bulk Infrastructure Photo 7: Enlarged view of the platform behind the operator’s house where the repaired pipes, 12 of, will be stored for future use if needed. Photo 8: Main DN600 Gate Valve installed at dam connection. APRIL 2014 21 Programme Management: Regional Bulk Infrastructure Contract 55/2011/MD (AM): Material Supply (Pipes) Photo 9: Trucks delivering 12,192m DN600 X 52 8 mm steel CML pipes on site in Machibini Village. Photo 10: Pipe trucks being offloaded at the informal pipe yard in Machibini Village close to the two churches near the river crossing. APRIL 2014 22 Programme Management: Regional Bulk Infrastructure Photo 11: View of the informal pipe yard in Machibini Village where pipes are only stored temporarily. Contract 19/2012/MD (AM): Construction of Pumping Main Photo 12: Pipe being laid and welded in trench heading towards the pump station. APRIL 2014 23 Programme Management: Regional Bulk Infrastructure Photo 13: The concrete batching plant has been relocated on site close to the forest near Xonxa Village. Photo 14: Formwork being erected for the next concrete pours required for the pigcatcher/ pig-launchers chambers. APRIL 2014 24 Programme Management: Regional Bulk Infrastructure Photo 15: Air valve tee installed in face-brick chamber in Xonxa Village. Awaiting valve installation and cover slab for chamber. Photo 16: Natural grassing taking place along the pipeline route next to the dam. The rainy season being the main contributor to the re-vegetation. APRIL 2014 25 Programme Management: Regional Bulk Infrastructure Photo 17: The old concrete batching plant site has been de-established and is currently in the process of being rehabilitated. Photo 18: Fireproof testing of the two different options of concrete wrapping (chicken-mesh or Hessian) on a piece of pipe in the site camp. APRIL 2014 26 Programme Management: Regional Bulk Infrastructure Photo 19: Correct safety precautions such as fire extinguishers and water, from JoJo water tanks, were on hand in case of emergency. Photo 20: Photographs of all the landowners in Machibini Village, affected by the pipeline traversing their land, receiving their cheques. APRIL 2014 27 Programme Management: Regional Bulk Infrastructure Photo 21: Selected bedding material being placed in the trench levelled and compacted before pipe is put in place and welded accordingly. APRIL 2014 ANNEXURE B: PROJECT SCHEDULE - CONTRACT 3 GANTT CHART / PROGRAMME AWARDED UNDER PHASE 1 INCLUDED AS ANNEXURE B IN FILE FOLDER Programme Management: Regional Bulk Infrastructure ANNEXURE C: CASH FLOW Q1-Q4 APRIL 2014 Programme Management: Regional Bulk Infrastructure ANNEXURE D: LABOUR SCHEDULES (ACTUAL) INCLUDED AS ANNEXURE D IN FILE FOLDER APRIL 2014 Programme Management: Regional Bulk Infrastructure APRIL 2014