TENDER ENQUIRY
[ WEB TENDER ]
Tender No
: 1300000997
Purchasing Executive : Pravin Nikhare
To
Telephone No:
Fax No:
Email ID:
Department:
Purchasing Executive:
Telephone No:+91
Fax No:+91
Email ID:
EY COMMERCIAL
Pravin Nikhare
23763585
23741386
pknikhare@mazagondock.gov.in
Tender Number:
Tender Date:
Tender Closing Date
Tender Closing Time
RFQ Number:
1300000997
19.01.2016
03.02.2016
15:00:00
2050000944
Tender Fee:
Rs
0.00
EMD Amount:
Rs
0.00
Pre Bid Meeting Date
Pre Bid Meeting Time
Tender Opening Date:
03.02.2016
Tender Opening Time:
Offer should be valid up to: 02.05.2016
Security Deposit:
0.00 % of PO value Perf. Bank Guarantee:
00:00:00
15:10:00
10.00 % of PO value
( Kindly read and refer relevant terms & conditions for further details. Do ensure to Quote Department Name, Purchase Executive's Name,
Tender Number, Closing date & time and RFQ Number in your Quotation & related correspondence )
Dear Sir / Madam ,
SUB:- SUPPLY,INSTALLATION.TESTING AND COMMISSIONING OF INTELLIGENT ADDRESABLE FIRE
DETECTION SYSTEM AT SUBMARINE (SM2)
Mazagon Dock Shipbuilders Limited (MDL) invites Competitive - Bid from reputed suppliers for the following in TWO
BID system (Part I Techno-Commercial Bid & Part II - Price Bid).
Sl.No.
00010
0000000010
Material/Service Details
Supply of Fire alarm Panel with Acess.
Service Description :
The Line item 00010 covers the following services
Service Number:Short Description:- SITC Fire alarm Panel with
Acessories
Page: 1 of 3
Quantity/Unit
1 Activity unit
1 Number
Delivery Date
29.05.2016
Tender Number:- 1300000997
Sl. No.
Tender Date:- 19.01.2016
Material/Service Details
Service Details:1) Supply of Fire Alarm Control Panel --1 Nos
RFQ Number:- 2050000944
Quantity/Unit
Delivery Date
Supply of networkable 2 Loops Micro processor based 2 wire fault tolerant loop with optional
redunadant network module ,each loop shall have the capability of connecting 126 devices.The fire
alarm control panel shall have built in degarde mode function.The panel should have inbuilt TCP/IP
communication for Panel Program and Remote Monitoring option through LAN or WAN
communication.The panel shall be able to give location of all fire and More Fire /fault and Isolation
conditions of addressable units via the address codes.The panel shall have the capacity of storing upto
2000 events.Further, the panel must be able to automatically switch ON /OFF respective control
module when ever any alarm is triggered. The panel should have inbuilt common Alarm, Fault and
monitored sounder output. The panel shall have a 8x40 characters LCD display with resolution of 256
X 112 pixels, and analog output, external/inbuilt printer to log all fire or fault events complete in all
respects.The Panel Should have protection caregory of IP30. Also the panel should have the option to
operate in manned and unmanned mode.The panel shall have a built in power supply and battery
charger along with maintenance free 24 AH, 2 x 12 volt SMF Lead acid batteries capable of running
for a minimum of 24 hours with battery charger complete as required.and as per specifications and
Duly Approved by EN54/LPCB/VDS/FM and as per NFPA Standards
2) Batteries for above panel:24 AH, 2 x 12 volt
The panel shall have a built in power supply and battery charger along with maintenance free 24 AH,
2 x 12 volt SMF Lead acid batteries capable of running for a minimum of 24 hours with battery
charger complete as required.and as per specifications and Duly Approved by EN54/LPCB/VDS/FM
3)Supply of Adressable Smoke detectors:20 Nos
Supply instalation and testing of Intelligent Analog Addressable Photoelectric Type Smoke Detector
with inbuilt turbo Isolator and integral response indicator with 360 degree viewing angle. Detector
shall communicate 3 danger levels for differentiated alarm activation and high tolerance to dust,dirt,
temperature fluctuations and air currents. Detector should have unquie address for communication
and assigned through panel with Mounting Base as required with the protection category of IP40 and
Duly Approved by EN54/LPCB/VDS/FM and as per NFPA Standards
4) Supply of Inteliigent addressable MCP:2 No's
Supply of Inteliigent addressable manual call point with inbuilt turbo Isolator . Also should have
protection category of IP66 and extra acceesories as required, duly approved by EN54/LPCB/VDS
and as per NFPA Standards
5) Supply of Adressable ATEx Smoke detectors:-4 No's
Explosion proof Adressable Detectors & Accessories and as per NFPA Standards.
6) Supply of 2c 2.5 sqmm armored FRLS cable with pvc conduit as PER Requirement :- 300 Meters.
7)Supply of Inteliigent adress. soundr cum beco:-2 Nos
Supply of Inteliigent addressable loop powered sounder cum beacon with base, inbuilt turbo Isolator,
able to provide an o/p of 99dBA at 1m, peak light o/p of at least 3.2cd and shall have 11
programmable tones, 3 volume settings selectable from the panel and fully synchronized with other
Page: 2 of 3
Tender Number:- 1300000997
Sl. No.
00020
0000000010
Tender Date:- 19.01.2016
RFQ Number:- 2050000944
Material/Service Details
Quantity/Unit
Delivery Date
sounders and shall have the ability to switch between one tone for alert and one tone for evacuation.
Shall have protection category of IP42 and duly approved by EN54/LPCB/VDS/FM and as per NFPA
Standards
Instalaltion,Testing and Comessioning FA
Service Description :.
1 Activity unit
29.05.2016
The Line item 00020 covers the following services
Service Number:1 Number
Short Description:- Commissioning of Fire
Detection system
Service Details:- Installation testing and Commissioning of Fire Detection system
Pre qualification Criteria.
Firm should have Experience in Similar works Installation testing of fire Detector systems.
1) Firm has to install test FDS System as per user's requirement Inside Submarine
2) Firm has to address with Tag plates on the sensor as per programming carried out on the panel.
3) Firm has to arrange required tools and accessories for installation Testing and Commissioning of
the system.
General
1)All relevant drawings, Manuals Operation,programing,Maintenance and Trouble Shooting of all
equipments installed with latest version to be provided. Soft copy and Hard Copy- 4 sets.
2) GA drawing, electrical diagrams for control panel, with as built and latest version. List of
accessories.
3) Documents with Details specifications of the installed systems.
4) Duration of work completion shall be 4 weeks from the date of the order issued.
5) Pre-dispatch inspection will be carried out for panel and system after approval of GA Drawings.
6) Any other activities which are not mentioned in this specification but required for the successful
installation, testing and commissioning of the Fire warning system shall be in contractorfs scope.
Terms & Conditions as indicated in Part A of this tender and other enclosures / annexures form an integral part of this
tender document. We look forward to receive your most competitive and reasonable offer against this Tender.
For Mazagon Dock Shipbuilders Ltd
Page: 3 of 3
TENDER NO EY/CD/PSN/PROJECT/1300000997 FOR FIRE DETECTION SYSTEM FOR SM2
PART - A
WEB TENDER
TENDER ENQUIRY (TWO - BID SYSTEM)
DIVISION: SUBMARINE
DEPARTMENT- COMMERCIAL (EAST YARD)
TENDER NO: EY/CD/PSN/PROJECT/1300000997
CLOSING DATE:03.02.2016
TENDER DATE: -19.01.2016
CLOSING TIME: - 15.00 hrs
MAZAGON DOCK SHIPBUILDERS LIMITED (MDL), (Formerly known as Mazagon Dock Limited) INVITES
COMPETITIVE BIDS from reputed Indian Bidders / Suppliers only in TWO – BID SYSTEM (Part-I Techno Commercial
Bid and Part-II Price Bid) for the following Work / Supplies:
1. Description of Work / Supplies:
Sr. No
Description & Specification of Item
SUPPLY,INSTALLATION,TESTING AND COMMISSIONING OF INTELLIGENT ADDRESSABLE FIRE
DETECTION SYSTEM FOR SUBMARINE(SM2)
1
The detailed scope of work is uploaded as Enclosure-1
2.
Duplicate Supply Clause: In case of supply of duplicate supply/spurious/substandard items by the firm, MDL will
resort to prosecution of the firm by taking legal action with all the stringent measures against the firm for supplying
such items which has lead to delay of the project of national importance and has endangered the national security.
The firm will also be blacklisted in MDL & will be debarred from quoting in future MDL tenders and the same will be
intimated to all other public sector undertakings and other Government Organizations.
3.
Pre-Qualification documents & criteria:
Bidders should submit the following documents along with their offer:3.1
Bidders not registered with Mazagon Dock Shipbuilders Limited should submit Valid Bidders Company Profile
and Shop & Establishment registration certificate / Registration Certificate from local body for conducting
business, duly self attested, stamped with their company seal.
3.3
Bidder must have Similar works experience in supply, Installation and testing of fire Detector
systems The bidders experience and past experience on supplies for last 3 years (Order Copies & work
completion certificate to be appended)
Note: Bidders need to submit supporting documentary evidence in support of the Pre-Qualification Criteria
viz. Purchase Order, Work Order, Work Completion Certificate issued by the party for whom the work is
done. MDL has a right to verify / cause verification of authenticity of the said documents whenever felt
necessary. MDL reserves the right to ask for hard copies of above documents.
4
Bidders registered with Mazagon Dock Shipbuilders Limited should furnish copy of valid Registration Certificate.
5
Earnest Money Deposit (EMD) / BID BOND: Not Applicable
6
Validity Period: Bids / Offers shall have a validity period of 90 Days from the tender closing date. A bid valid for a
shorter period will be liable for rejection.
7.1
Submission of offer in Two Bid System: Offer must be submitted in two parts, each offer securely closed (sealed) separately, in Two
Envelopes Part - I & Part – II as stated below;
A) Part-I: This Envelope super scribing the Tender No, Due date & Time should contain the following;
(Note: Following documents should be page numbered from first page to last page like 1/x to x/x)
Technical Bid in Original + Two copies, consisting of
7.1.1
7.1.2
7.1.3
7.1.4
7.1.5
7.1.6
7.1.7
Technical Bid in Original duly signed.
Acceptance on clauses of Tender Enquiry, GT&C in the Prescribed Formats duly stamped, signed &
filled ‘Accepted OR Not Accepted’ as applicable for each of the clause.
STACS Acceptance in the Prescribed Format duly stamped, signed & filled ‘Accepted OR Not
Accepted’ as applicable for each of the clause.
Price schedule BLANKING the PRICES but clearly indicating ‘QUOTED / UNQUOTED’ as applicable
against each of the listed item in the prescribed format duly Stamped & Signed.
Deviation Sheet in the prescribed format in case of any deviations from Terms, Conditions & Technical
requirements specified in the STACS, Tender Enquiry & GT&C.
Bidders / Suppliers should submit the additional documents as applicable and described at para 3
above.
Copies of valid Registration or Approval certificates in case of Bidder’s firms registered with MDL.
P a g e |1
TENDER NO EY/CD/PSN/PROJECT/1300000997 FOR FIRE DETECTION SYSTEM FOR SM2
7.1.8
7.2
8.
Bank details for payment by RTGS / NEFT in the format enclosed.
B) Part-II Bid: This securely closed (sealed) Envelope super scribing Tender Enquiry No., Due date & Time should
contain only the PRICES for each of the listed items strictly in the prescribed format provided with the tender. If the
space provided is not sufficient, bidder may attach additional sheets. Offer in any other format shall not be considered.
Both these securely closed Envelopes i.e. Part-I & Part-II should be put in a Third Bigger Envelope securely closed
(Sealed), super scribing Tender Enquiry No., Due date & Time and addressed To, EXECUTIVE DIRECTOR
th
(Commercial-East Yard), 7 Floor, Reclamation Building, East Yard, Mazagon Dock Shipbuilders Limited,
Dockyard Road, Mumbai 400 010, INDIA.
7.2.1
The offers shall be deposited ONLY in Tender Box for East Yard Commercial, situated at MDL
Reception Centre, Mazagon Dock Shipbuilders Limited, Dockyard Road, Mumbai 400 010, India
on / or before The Closing Date & Closing Time and addressed To Executive Director (CommercialEast Yard) (offers deposited in any other tender box in MDL other than the one indicated above
shall be rejected). In case of Bulky Offers / Bids, which cannot be accommodated in the designated
Tender Box, such bids / offers shall be sent by post / courier so as should reach the undersigned well
before the due date and time.
7.2.2
The bids may also be sent by Speed Post / Courier Service well in advance so as should reach the
Undersigned / Department (address as mentioned above) well before the due date and time. Timely
submission of the Bids is the responsibility of the bidders and no reasons / excuses in this regard will
be entertained by MDL.
Bid Rejection Criteria:
Following bids shall be categorically rejected;
A.
i.
ii.
The Bids received after tender closing date and time.
Firm not having similar work experience of Installation testing of fire Detector systems
Following bid rejection criteria may render the bids liable for Rejection:
B.
i.
ii.
iii.
iv.
v.
vi.
vii.
Bidder’s failure to submit sufficient or complete details for evaluation of the bids within the given period
which may range in between two to three weeks depending on the deficiencies noticed in the drawings /
technical data which shall not however conflict with validity period.
Incomplete / misleading / ambiguous bids in the considered opinion of TNC.
Bids with technical requirements and or terms not acceptable to MDL / Customers / External agency
nominated as applicable.
Bids received without pre – qualification documents where required as per tender.
Bids not meeting the pre-qualification parameters stipulated in the tender enquiry.
Unreasonably longer delivery period quoted by the firm.
Validity period indicated by bidders is shorter than that specified in the tender enquiry.
9.
Pricing: Bidder’s shall quote the prices of all the items listed in the tender enquiry for delivery of the items in
Mazagon Dock Shipbuilders Limited Stores. The prices quoted shall remain firm and fixed during the currency of the
order / contract unless agreed otherwise by MDL.
10.
Terms of Payment: - No Advance in any manner will be paid to the Supplier / Bidder / Vendor / Contractor.
Payment for the value of supplies , as reduced by any deductibles and/or the amount leviable towards
liquidated damages, if any and after including taxes, duties, Octroi , service tax etc. as may be payable through
RTGS /NEFT/ECS between 25 to 30 days after receipt of complete set of the items / Equipment, spares, work
completion certificate etc as per the ordered terms and against submission of documents in Triplicate
including Delivery challan(s), Release note from the nominated Inspection Agency, Test reports /
Certificates, Packing Lists, Invoice, Performance Guarantee, Storage / Preservation / Installation / Commissioning
/ Maintenance Procedures & other Technical documentation in requisite sets as relevant. Bidders shall furnish all
the necessary details like name of the bank / branch, branch code No, bank account no in their technical bid as
per the RTGS/NEFT format provided with the tender enquiry. Part Supply Part Payment will not be acceptable.
11.
Guarantee/ Warranty: One Year Guarantee/Warranty from date of acceptance of material by MDL user.
12.
Delivery Period / Completion Schedule: Time is the essence of the contract. Material shall be delivered
within 4 weeks from the date of placement of order. Bidders are requested to confirm the delivery schedule in
their offer.
13.
Performance Bank Guarantee: - 10% OF THE PO VALUE, valid for 1 Year +1 month extra after acceptance of the
item
14.
The contract will be governed by STACS and General Terms and conditions while executing work. In case of
discrepancy, clauses mentioned in Tender, Technical Scope and Rate sheet will override the clauses
mentioned in other annexure including STACS & GT&C.
15.
Taxes & Duties:
Bidders must indicate the nature of taxes & duties applicable for the work and quote the amounts of Taxes and
duties as applicable separately as shown in Part – II price bid format at Enclosure – 2. The items/services – wise
P a g e |2
TENDER NO EY/CD/PSN/PROJECT/1300000997 FOR FIRE DETECTION SYSTEM FOR SM2
rates quoted in the Rate Sheet should exclude Taxes & Duties. Bidder should indicate Taxes and Duties as
applicable separately under each of the head in same Rate Sheet, which will be paid extra.
Supplier will not be entitled to any increase in rate of taxes occurring during the period of extended delivery
completion schedule if there is delay in supplies / completion attributed to him. However, if there is a decrease in
taxes, the same must be passed on to MDL.
In absence of any such stipulation in the bid, it will be considered that the prices quoted by the bidder are
inclusive of Taxes & Duties and no separate liability for payment of Taxes & Duties will devolve upon MDL.
16.
17.
Loading Criteria: Deviations sought by the bidder in respect of following terms shall be loaded on the bidder/s
quoted prices during price evaluation by MDL. Among the equal bids, bidders with ISO 9000 series accreditation
over Non-ISO bidders, Firstly Manufacturers then their authorized dealers will be given preference. The loading
criteria that will be adopted as detailed below:
16.1
Payment Terms: - It is desirable that the bidder accepts the Payment Terms indicated by the company
in the Tender document. Varied payment terms quoted by indigenous bidders as compared to the
terms stated in the Tender document shall be normalized by adopting the Prime Lending Rate of State
Bank of India plus 2% thereon on the amount (s) at variation and / or for the period (in no. of days)
at variation.
16.2
Delivery of the goods at MDL premises should be responsibility of the supplier.
16.3
For the additional delivery period sought by the bidder over the stipulated date of delivery as per
Tender, 0.50% per completed week will be loaded to the quoted price.
16.4
Deviations sought in respect of rate per week and / or maximum ceiling in respect of liquidated
damages shall be loaded to the quoted price. For example, the maximum ceiling towards liquidated
damages stipulated in the Tender is 5% and the bidder seeks to limit it to, say 3.50% then the price
quoted will be loaded by 1.5%. If the rate of LD per week is 0.50% per week or part thereof as per
tender and the bidder seeks it as, say, 0.40% per week or part thereof, the maximum ceiling on LD as
per tender will first be equated to weeks (10 weeks in this case) and the rate proposed by the bidder
i.e. 0.40% will be multiplied by the so equated maximum period (which works out to 4%) and the
quoted price will be loaded accordingly by 1%. Delivery being the essence of the contract, it is
desirable if the bidder(s) adhere to the stipulated clause.
Ranking of Bids & Determination of L-1 Bidders:
17.1
Ranking of price bids shall be done on the basis of Overall items inclusive of taxes, duties and
levies. If any variations in statutory levies, the break up in respect of taxes, duties and levies is clearly
and separately furnished in the bid and MDL is satisfied that the rates of taxes, duties & levies
indicated therein are in line with the tax law: so that escalation due to variation in the taxes, duties &
levies can be justifiably considered to the extent legitimately allowable on the base amount(s) indicated
in the bid. Therefore, bidder is requested to show the break up regarding taxes, duties & levies as
applicable in the bid.
18.
Consignee: The Successful bidder/s shall arrange dispatch of goods by appropriate transport mode as per the
order to ‘Mazagon Dock Shipbuilders Limited Stores’ at East Yard Stores on working days (Monday to Friday)
between 8.00 hrs to 15.00 hrs (Lunch Time 11.30 to 12.00 hrs) . In case truck/tempo reaches our yard beyond
above time the same may be retained over night at your risk & cost.
19.
No Price Preference shall be given to any Bidder Irrespective of their status.
20.
Modifications to the Bids: - Bidders desirous of submitting modified bids prior to the closing date & time may
do so by submitting revised bid online not later than the deadline for submission of bids.
21.
Public Grievance Cell: A Public Grievance Cell headed by General Manager (F - CA), Shri. S.D.Kajawe has been
set up in the Company. Members of public having complaints or grievances are advised to contact him on
rd
Wednesday between 10.00 hours and 12.30 hours in his office on 3 floor, West block Building or send their
complaints / grievances to him in writing for redressal. His Telephone No. is 022 2378 1561 Ext’n 2121.
22.
Liquidated Damages: Time is an essence of the contract therefore the job, as ordered, should be completed on the
dates mutually agreed upon in accordance with the delivery schedule. In cases of delay not attributable to
Purchaser beyond the agreed schedule, the Successful bidder shall pay liquidated damages, a sum representing
0.5% (Half per cent) per week or part thereof, subject to maximum of 5% of the final order value.
23.
Option Clause:
MDL retains the right to place orders for additional quantities up to a maximum of 50% of the originally
contracted quantity at the same rate and terms of the contract. Such an option shall be available during
the original period of contract. Option quantity during extended Delivery period is limited to 50% of balance
quantity after original delivery period.
24.
Hindrance Register
All hindrances with date of occurrences and removal shall be noted in the Hindrance Register. The
Hindrance Register shall be signed by the reps of both MDL as well as Contractor
P a g e |3
TENDER NO EY/CD/PSN/PROJECT/1300000997 FOR FIRE DETECTION SYSTEM FOR SM2
25.
MDL reserves the right to consider placement of Order / Contract in part or in full against the tendered quantity.
26.
Inspection:
Receipt Inspection.
a) Receipt Inspection shall be carried out by User dept with (MTC-EY). MDL shall carry out necessary
inspection of the items on receipt in the MDL on the basis of appropriate MDL Inspection
system requirements & the Inspection documents submitted by suppliers. Any objection raised
by MDL inspection team against quality of material or workmanship shall be satisfactorily corrected by
the supplier at his expenses including replacement as may be required within shortest possible time
within 30 days. Items damaged during transit shall also be rectified or replaced by the supplier within
shortest possible time.
b) Rejection of the material: Any portion of the equipment found defective/rejected, the supplier shall
collect the same at his cost from the MDL Yard, all incidental charges being born by supplier,
(inclusive of custom duty, if payable), within 30 days from the date of intimation to the supplier of
such rejection. The MDL reserves the rights to dispose off the rejected item at the end of a total
period of 90 days in any manner, to the best advantage to the MDL& recover storage charges & any
consequential damages, from sale proceeds of such disposal.
27.
MDL shall not be bound by any printed conditions or provisions in the sellers bid forms or acknowledgement of
contract, invoices, packing list and any other documents which purport to impose any conditions at variance with the
tender terms / final negotiated & accepted terms.
28.
Issue of Tender Enquiry Document: - The Tender Enquiry can be downloaded from our website
www.mazagondock.gov.in
29.
Bidders intending to witness the Tender opening shall have to submit the letter of authority to the Tender Opening
Officers and will sign on the sheet of paper in token of his presence at the time of tender opening.
30.
In case of any clarifications, bidders are requested to contact the undersigned, before the closing date of the tender.
We look forward to receive your most competitive and reasonable offer against this tender.
Yours faithfully,
For MAZAGON DOCK SHIPBUILDERS LIMITED
Pravin Nikhare, M (C – EY)
(Purchase Executive)
Enclosures:
Enclosure1: Scope of Supply / Work.
Enclosure2: Rate Sheet Format.
Enclosure3: Tender Enquiry Terms and Acceptance Format.
Enclosure4: General Terms & Conditions with Acceptance Format.
Enclosure5: Standard Terms & Conditions (STACS) with Acceptance Format
Enclosure6: Loading Factors
Enclosure7: Deviation Sheet
Enclosure8: RTGS/NEFT Format.
Enclosure9: Check List for Bidder’s
Bidders to refer following documents of this Tender from MDL website “www.mazagondock.gov.in” under Heads –
Tenders / EY Submarine and reading “Standard Annexures for EY-Tenders”.
Performance Bank Guarantee format.
NEFT Format.
General Terms & Conditions (GT&C). Encl. 4 below.
Standard Terms & Conditions (STACS) FOR PURCHASE OF ITEMS. Encl. 5 below
Statutory Requirements, Official Secret Act 1923 & Safety clause.
P a g e |4
TENDER NO EY/CD/PSN/PROJECT/1300000997 FOR FIRE DETECTION SYSTEM FOR SM2
Enclosure-1
Scope of Supply
TENDER ENQUIRY NO. EY/CD/PSN/PROJECT/1300000997
Sr.
No
Description & Specification of Item
Quantity
Delivery Period
Requirement of Temporary fire warning system at SM2
SITC(Supply, Installation ,Testing and commissioning ) of SITC INTELLIGENT ADDRESSABLE FIRE
DETECTION SYSTEM at submarine (SM2)
100
The Line item 100 covers the following Supply
Description :
10
1) Supply of Fire Alarm Control Panel-1
Nos
Supply of networkable 2 Loops Micro
processor based 2 wire fault tolerant
loop with optional redundant network
module, each loop shall have the
capability of connecting 126 devices. The
fire alarm control panel shall have built
in degrade mode function. The panel
should have inbuilt TCP/IP communication
for Panel Program and Remote Monitoring
option through LAN or WAN communication.
The panel shall be able to give location
of all fire and More Fire /fault and
solution conditions of addressable units
via the address codes. The panel shall
have the capacity of storing up to 2000
events. Further, the panel must be able
to automatically switch ON /OFF
respective control module when ever any
alarm is triggered. The panel should have
inbuilt
common Alarm, Fault and monitored sounder
Output. The panel shall have a 8x40
characters LCD display with resolution of
256 X 112 pixels, and analog output,
External/ inbuilt printer to log all fire
or fault events complete in all respects.
The Panel Should have protection category
of IP30. Also the panel should have the
option to operate in manned and unmanned
mode. The panel shall have a built in
power supply and battery charger along
with maintenance free 24 AH, 2 x 12 volt
SMF Lead acid batteries capable of
running for a minimum of 24 hours with
battery charger complete as required and
as per specifications and Duly Approved
by
EN54/LPCB/VDS/FM and as per NFPA
Standards
1 nos
2) Batteries for above panel:24 AH, 2 x
12
volt
The panel shall have a built in power
P a g e |5
TENDER NO EY/CD/PSN/PROJECT/1300000997 FOR FIRE DETECTION SYSTEM FOR SM2
supply and battery charger along with
maintenance free 24 AH, 2 x 12 volt SMF
Lead acid batteries capable of running
for a minimum of 24 hours with battery
charger complete as Required. and as per
specifications and Duly Approved by
EN54/LPCB/VDS/FM
3)Supply of Addressable Smoke
detectors:20 Nos
Supply installation and testing of
Intelligent Analog Addressable
Photoelectric Type Smoke Detector with
inbuilt turbo Isolator and integral
response indicator with 360 degree
viewing angle. Detector shall communicate
3 danger levels for differentiated alarm
activation and high tolerance to dust,
dirt, temperature Fluctuations and air
currents. Detector should have unquie
address for communication and assigned
through panel with Mounting Base as
required with the protection category of
IP40 and Duly Approved by
EN54/LPCB/VDS/FM and as per NFPA
Standards.
4) Supply of Intelligent addressable
MCP:2 Nos
Supply of Intelligent addressable manual
call point with inbuilt turbo Isolator.
Also should have protection category of
IP66 and extra accessories as required,
duly approved by EN54/LPCB/VDS and as per
NFPA Standards
5) Supply of Addressable ATEx Smoke
detectors:-4 No's
Explosion proof Addressable Detectors &
Accessories and as per NFPA Standards
6) Supply of 2c 2.5 sqmm armored FRLS
cable with pvc conduit as PER Requirement
:- 300 Meters
7) Supply of Intelligent address. soundr
cum beco:-2 Nos
Supply of Intelligent addressable loop
powered sounder cum beacon with base,
inbuilt turbo Isolator, able to provide
an o/p of 99dBA at 1m, peak light o/p of
at least 3.2cd and shall have 11
programmable tones, 3 volume settings
selectable from the panel and fully
synchronized with other sounders and
shall have the ability to switch between
one tone for alert and one tone for
evacuation. Shall have protection
category of IP42 and duly approved by
EN54/LPCB/VDS/FM and as per
P a g e |6
TENDER NO EY/CD/PSN/PROJECT/1300000997 FOR FIRE DETECTION SYSTEM FOR SM2
NFPA Standards
The Line item 200 covers the following services(Installation, testing
and Commissioning of Fire Detection system of Sr. no 100)
200
Service Number
Description :
Installation, testing and Commissioning
of Fire Detection system
1) Firm has to install test FDS System as
per user's requirement Inside Submarine
2) Firm has to address with Tag plates on
the sensor as per programming carried out
on the panel.
3) Firm has to arrange required tools and
accessories for installation Testing and
Commissioning of the system.
General
1) All relevant drawings, Manuals
Operation, programing, Maintenance and
Trouble Shooting of all equipments
installed with latest version to be
provided. Soft copy and Hard Copy- 4
sets.
2) GA drawing, electrical diagrams for
control panel, with as built and latest
Version. List of accessories.
3) Documents with Details specifications
of the installed systems.
4) Duration of work completion shall be 4
Weeks from the date of the order issued.
5) Pre-dispatch inspection will be
carried
Out for panel and system after approval
of GA Drawings.
6) Any other activities which are not
mentioned in this specification but
required for the successful installation,
testing and commissioning of the Fire
warning system shall be in contractor fs
scope
20
1 No
Important Note:
• Bidders are requested to submit their offer clearly mentioning all the details required and enclose all the desired
documents as mentioned in the tender, to avoid clarification/delay at the later stage in processing of the tender.
•
Bidder to attach all the enclosures as required in tender duly stamped & signed.
•
Ranking of price bids shall be done on the basis of Overall items inclusive of all taxes, duties and levies
•
Bidder must have similar work experience of Supply, Installation, testing of fire Detector systems and also
submit relevant purchase order/work completion documents otherwise offer will be rejected.
•
Sr. No 100 for Supply of Items and Sr. no 200 for (services) Installation, commissioning and testing of Sr. no
100
•
Bidder has to quote Lump sum rate for Sr. No 100 and Sr. 200
P a g e |7
TENDER NO EY/CD/PSN/PROJECT/1300000997 FOR FIRE DETECTION SYSTEM FOR SM2
Enclosure-2
RATE SHEET FORMAT
TENDER ENQUIRY NO: EY/CD/PSN/PROJECT/1300000997
Sr.
No
Description & Specification of Item
Quantity
(A)
Rate
(Rs)
Lump sum
(B)
Total
C=AxB
Requirement of Temporary fire warning system at SM2
SITC(Supply Installation Testing and commissioning ) of SITC INTELLIGENT ADDRESSABLE FIRE DETECTION
SYSTEM at submarine (SM2)
100
The Line item 100 covers the following Supply of Items
Description :
1) Supply of Fire Alarm Control
Panel-1 No
Supply of networkable 2 Loops Micro
processor based 2 wire fault tolerant
loop with optional redundant network
module, each loop shall have the
capability of connecting 126 devices.
The fire alarm control panel shall
have built in degrade mode function.
The panel should have inbuilt TCP/IP
communication for Panel Program and
Remote Monitoring option through LAN
or WAN communication. The panel shall
be able to give location of all fire
and More Fire /fault and solution
conditions of addressable units via
the address codes. The panel shall
have the capacity of storing up to
2000 events. Further, the panel must
be able to automatically switch ON
/OFF respective control module when
ever any alarm is triggered. The
panel should have inbuilt
common Alarm, Fault and monitored
sounder
Output. The panel shall have a 8x40
characters LCD display with
resolution of 256 X 112 pixels, and
analog output,
External/ inbuilt printer to log all
fire or fault events complete in all
respects. The Panel Should have
protection category of IP30. Also the
panel should have the option to
operate in manned and unmanned mode.
The panel shall have a built in power
supply and battery charger along with
maintenance free 24 AH, 2 x 12 volt
SMF Lead acid batteries capable of
running for a minimum of 24 hours
with battery charger complete as
required and as per specifications
and Duly Approved by
EN54/LPCB/VDS/FM and as per NFPA
1
P a g e |8
TENDER NO EY/CD/PSN/PROJECT/1300000997 FOR FIRE DETECTION SYSTEM FOR SM2
Standards
2) Batteries for above panel:24 AH, 2
x 12 volt
The panel shall have a built in power
supply and battery charger along with
maintenance free 24 AH, 2 x 12 volt
SMF Lead acid batteries capable of
running for a minimum of 24 hours
with battery charger complete as
Required. and as per specifications
and Duly Approved by EN54/LPCB/VDS/FM
3)Supply of Addressable Smoke
detectors:20 Nos
Supply installation and testing of
Intelligent Analog Addressable
Photoelectric Type Smoke Detector
with inbuilt turbo Isolator and
integral response indicator with 360
degree viewing angle. Detector shall
communicate 3 danger levels for
differentiated alarm activation and
high tolerance to dust, dirt,
temperature Fluctuations and air
currents. Detector should have unquie
address for communication and
assigned through panel with Mounting
Base as required with the protection
category of IP40 and Duly Approved by
EN54/LPCB/VDS/FM and as per NFPA
Standards.
4) Supply of Intelligent addressable
MCP:2 Nos
Supply of Intelligent addressable
manual call point with inbuilt turbo
Isolator. Also should have protection
category of IP66 and extra
accessories as required, duly
approved by EN54/LPCB/VDS and as per
NFPA Standards
5) Supply of Addressable ATEx Smoke
detectors:-4 No's
Explosion proof Addressable Detectors
& Accessories and as per NFPA
Standards
6) Supply of 2c 2.5 sqmm armored FRLS
cable with pvc conduit as PER
Requirement :- 300 Meters
7) Supply of Intelligent address.
soundr cum beco:-2 Nos
Supply of Intelligent addressable
loop powered sounder cum beacon with
base, inbuilt turbo Isolator, able to
provide an o/p of 99dBA at 1m, peak
P a g e |9
TENDER NO EY/CD/PSN/PROJECT/1300000997 FOR FIRE DETECTION SYSTEM FOR SM2
light o/p of at least 3.2cd and shall
have 11 programmable tones, 3 volume
settings selectable from the panel
and fully synchronized with other
sounders and shall have the ability
to switch between one tone for alert
and one tone for evacuation. Shall
have protection category of IP42 and
duly approved by EN54/LPCB/VDS/FM and
as per NFPA Standards
The Line item 200 covers the following services(Installation testing
200
and commissioning of Fire Detection system for Sr. no 100)
Installation testing and
commissioning of Fire Detection
system
1) Firm has to install test FDS
System as per user's requirement
Inside Submarine
2) Firm has to address with Tag
plates on the sensor as per
programming carried out on the panel.
3) Firm has to arrange required tools
and accessories for installation
Testing and Commissioning of the
system.
General
1) All relevant drawings, Manuals
Operation, programming, Maintenance
and Trouble Shooting of all
equipments installed with latest
version to be provided. Soft copy and
Hard Copy- 4 sets.
2) GA drawing, electrical diagrams
for
control panel, with as built and
latest
Version. List of accessories.
3) Documents with Details
specifications of the installed
systems.
4) Duration of work completion shall
be 4
Weeks from the date of the order
issued.
5) Pre-dispatch inspection will be
carried Out for panel and system
after approval of GA Drawings.
6) Any other activities which are not
mentioned in this specification but
required for the successful
installation, testing and
commissioning of the Fire warning
system shall be in contractor scope
1
•
Bidders are requested to submit their offer; clearly mentioning all the details required and enclose all the
desired documents as mentioned in the tender, to avoid clarification/delay at the later stage in processing
of the tender.
•
Sr. No 100 for Supply of Items and Sr. no 200 for (services) Installation, commissioning and testing of Sr. no
100
•
Bidder has to quote Lump sum rate for Sr. No 100 and Sr. 200
P a g e | 10
TENDER NO EY/CD/PSN/PROJECT/1300000997 FOR FIRE DETECTION SYSTEM FOR SM2
IMPORTANT NOTES TO THE BIDDERS:
i)
TAXES & DUTIES:
The rates / price quoted by Indigenous Bidder are to be exclusive of duties and taxes. However, nature / type
and rate of duties & taxes are to be clearly indicated in the offer by the bidder separately.
ii)
Supplier should clearly indicate “QUOTED” or “NOT QUOTED” as applicable against each of the
above listed items.
Sr. No
Taxes, Duties & other charges
Applicable
Amount
(Please specify with applicable rates)
Rate
1
Excise Duty
2
VAT
3
CST
4
Octroi
5
iii)
Please Specify any other Taxes & Duties
All pages of the tender document including scope of supply, terms & conditions must be signed, stamped with
Co. seal and submitted along with the Part-I of the offer as a token of acceptance of the terms and conditions.
In case your offer deviates from our requirement and terms and conditions in any manner, these deviations
must be clearly indicated in your PART-I in a separate sheet, failing which our requirement and terms and
conditions will be binding on bidder.
Company’s Seal
(Signature, Name & Designation)
Date:
P a g e | 11
TENDER NO EY/CD/PSN/PROJECT/1300000997 FOR FIRE DETECTION SYSTEM FOR SM2
Enclosure-3
TEF ACCEPTANCE FORMAT
(Bidders requested to fill complete details as ACC/DEV)
To,
MAZAGON DOCK SHIPBUILDERS LIMITED
COMMERCIAL DEPARTMENT (E.Y)
TENDER ENQUIRY NO EY/CD/PSN/PROJECT/1300000997
TEF
CLAUSE No.
BIDDER’S
REMARK
TEF
CLAUSE No.
BIDDER’S
REMARK
ACC/DEV
1. Description
of Work /
Supplies
TEF
CLAUSE No.
ACC/DEV
ACC/DEV
3. PreQualification
documents &
criteria
2. Duplicate Supply
Clause
4.
5. Earnest Money
Deposit
7. Submission
of offer
8. Bid rejection
Criteria
10. Terms of
Payment
11. Guarantee/
Warranty
13. PBG
14.
15. Taxes & Duties
16. Loading
Criteria
17. Ranking of Bids
18. Consignee
19.
20. Modifications to
the Bids
21. Public
Grievance Cell
22 Liquidated
Damages
25.
28
BIDDER’S
REMARK
Not Applicable
9. Pricing
12. Delivery
Period
24 .Hindrance
register
23.Optiona
clause
26. Inspection
29.
6. Validity Period
27.
30.
COMPANY’S NAME & ADDRESS _:
_____________________________
_____________________________
____________________________
SIGNATURE:
DATE:
NAME:
DESIGNATION:
BIDDER’S COMPANY SEAL:
NOTES:
1.
2.
3.
4.
5.
Bidders should carefully read the Terms & Conditions of the Tender Enquiry Form (TEF) prior to filling up this
acceptance format.
This format should be properly filled, signed and returned by the bidder(s) along with their technical offer for
considering their Bid.
Bidder(s) should indicate “ACC” for Accepted, “DEV” for Deviation Taken for each clause number in the above table.
Bidder(s) to attach Separate Sheet indicating all relevant details such as Number & description of the Clause,
Reasons for Deviation and Alternative suggested for any deviations taken by them.
Clause numbers shown in the above format also includes the sub-clauses under these clauses. For example Clause
no. ‘3’ means – Clause nos. 3.1, 3.1.1, 3.1.2-------
P a g e | 12
TENDER NO EY/CD/PSN/PROJECT/1300000997 FOR FIRE DETECTION SYSTEM FOR SM2
Enclosure-4
ACCEPTANCE FORM FOR GENERAL TERMS AND CONDITIONS
(Bidders requested to fill complete details as ACC/DEV)
To,
MAZAGON DOCK SHIPBUILDERS LIMITED
COMMERCIAL DEPARTMENT (E.Y)
TENDER ENQUIRY NO. EY/CD/PSN/PROJECT/1300000997
GT&C
CLAUSE No.
BIDDER’S
REMARK
GT&C
CLAUSE No.
ACC/DEV
BIDDER’S
REMARK
GT&C
CLAUSE No.
BIDDER’S
REMARK
ACC/DEV
Not Applicable
ACC/DEV
A20 (Security
Deposit)
Not Applicable
A30 (Forfeiture of
EMD/BID BOND)
A50
(Forfeiture of
Performance
guarantee)
Not Applicable
A60 (Supplies)
A70 (Progress
report and
monitoring)
A80
(Cancellation
of order)
A90 (Preservation
and Maintenance)
A100 (Freight
and Insurance)
A110 (Taxes
and duties)
A120 (Demurrage)
A130
(Inspection,
Testing)
A140 (Receipt
Inspection by
MDL)
A150 (Rejection of
Material)
A160
(Technological
developments
and
modification)
A170
(Purchaser
Right)
A180 (Bank
Guarantee/Insurance
Cover)
Not Applicable
A40 (Forfeiture
of SD)
Not Applicable
A190 (Bidders
response in
case of no
participation
A200 (Facility
Provision)
COMPANY’S NAME & ADDRESS__:
_____________________________
_____________________________
____________________________
SIGNATURE:
DATE:
NAME:
DESIGNATION:
BIDDER’S COMPANY SEAL:
NOTES:
1.
2.
3.
4.
5.
Bidders should carefully read the General Terms & Conditions (GT&C) of the Tender Enquiry prior to filling up this
acceptance format.
This format should be properly filled, signed and returned by the bidder(s) along with their technical offer for
considering their Bid.
Bidder(s) should indicate “ACC” for Accepted, “DEV” for Deviation Taken for each clause number in the above table.
Bidder(s) to attach Separate Sheet indicating all relevant details such as Number & description of the Clause,
Reasons for Deviation and Alternative suggested for any deviations taken by them.
Clause numbers shown in the above format also includes the sub-clauses under these clauses. For example Clause
no. ‘8’ means – Clause nos.-8.1, 8.2, 8.3.
P a g e | 13
TENDER NO EY/CD/PSN/PROJECT/1300000997 FOR FIRE DETECTION SYSTEM FOR SM2
Enclosure-5
STACS ACCEPTANCE FORMAT
(Bidders requested to fill complete details as ACC/DEV)
To,
MAZAGON DOCK SHIPBUILDERS LIMITED
COMMERCIAL DEPARTMENT (E.Y)
STACS
CLAUSE No.
TENDER ENQUIRY NO. EY/CD/PSN/PROJECT/1300000997
BIDDER’S
STACS
BIDDER’S
STACS
REMARK
CLAUSE No.
REMARK
CLAUSE No.
BIDDER’S
REMARK
ACC/DEV
ACC/DEV
ACC/DEV
120 (General)
200
(Communication
and Language)
210 (Purchasers
Property)
220 (Risk
Purchase)
230 (Recovery
Adjustment
Provision)
240 (Additional
Bank
Guarantee)
250
(Indemnification)
260 (Transfer of
Supplies/Contract)
270 (Sub
contractor and
Right of
Purchase)
280 (Patent
Rights)
290
(Agents/Agency
Commission)
300 (Use of
undue
influence/corrupt
practice)
310 (Immunity of
Government of
India Clause)
320 (Export
License)
330 (Banned or
de-Listed
contractors)
340 (Duty of
personnel of
supplier/supplier)
350 (Arbitration)
360 (Jurisdiction
of Court)
COMPANY’S NAME & ADDRESS__:
_____________________________
_____________________________
____________________________
SIGNATURE
:
DATE
:
NAME
:
DESIGNATION :
BIDDER’S COMPANY SEAL:
NOTES:
1.
Bidder(s) should carefully read the Standard Terms & Conditions (STACS) included in the tender prior to
filling up this acceptance format.
1
This format should be properly filled, signed and returned by the bidder(s) along with their technical offer
for considering their Bid.
2
Bidder(s) should indicate “ACC” for Accepted, “DEV” for Deviation Taken for each clause number in the
above table.
3
Bidder(s) to attach Separate Sheet indicating all relevant details such as Number & description of the
Clause, Reasons for Deviation and Alternative suggested for any deviations taken by them.
5.
STACS clause numbers shown in the above format also includes the sub-clauses under these clauses. For
example ‘6’ means – clause nos. 6.1, 6.2.
P a g e | 14
TENDER NO EY/CD/PSN/PROJECT/1300000997 FOR FIRE DETECTION SYSTEM FOR SM2
Enclosure-6
LOADING FACTORS FOR RANKING OF BIDS
A.
B.
C.
Sr.
No.
Description
1
Basic price Quoted
a) Ex Works
b) Delivered to MDL Stores
2
Add: insurance charges
In case of 1(a)
3
4
Add: Inland Road Transport
Cost excluding taxes & duties without loading
towards any deviations
In case of 1(a)
Sr.Nos.(1+2+3)
Loading due to variations in financial Term
5
Variation in payment Terms
6
Cost excluding Taxes & duties after loading for
variations in financial terms.
Loading on Account of deviations in following commercial terms.
7
8
9
10
D
Sr.Nos.4 + 5
Additional delivery period sought over stipulated
period as per Tender
Liquidated damages per week rate / maximum
ceiling
Warranty / Guarantee
Cost excluding Taxes & duties after loading for
variations on account of financial & Commercial
Terms
Sr.Nos. 6+7+8+9
Landed Cost:
11
12
Taxes & Duties
Landed cost
Sr.Nos. 10+11
P a g e | 15
TENDER NO EY/CD/PSN/PROJECT/1300000997 FOR FIRE DETECTION SYSTEM FOR SM2
Enclosure-7
DEVIATION FORMAT
(Bidders to fill, sign, stamp and RETURN this form in PART- I bid)
To,
MAZAGON DOCK SHIPBUILDERS LIMITED
COMMERCIAL EASTYARD
TENDER ENQUIRY NO.: EY/CD/PSN/PROJECT/1300000997
Deviation
Sr. No.
Page Sr. No. or
Enclosure Reference
of the Tender Enquiry
Clause Number for
Which the
Deviation
is Sought
Brief Text
Description of
the Clause
Reasons for
Deviation
Suggested
Alternative
1.
2.
& so on…
COMPANY’S NAME & ADDRESS__:
_____________________________
_____________________________
____________________________
SIGNATURE
:
DATE
:
NAME
:
DESIGNATION :
BIDDER’S COMPANY SEAL:
P a g e | 16
TENDER NO EY/CD/PSN/PROJECT/1300000997 FOR FIRE DETECTION SYSTEM FOR SM2
Enclosure-8
RTGS/NEFT – MANDATE AUTHORISATION FORM
(ILLUSTRATIVE FORMAT)
1. Supplier’s / Vendor’s Name:
2. Supplier’s / Vendor’s Name as per Bank Records:
3A. Supplier’s Code
3B. Supplier’s PAN Number: #
# Quoting PAN No. in all the e-returns has become 100% mandatory w.e.f. 14-02-2008 hence, ensure to fillup this and
also send a photocopy of PAN duly self-attested. If there is any difference between the name given in the supplier’s name
and name given in the PAN card, then a note to explain the reason for the difference and the correlation between both.
4. Supplier’s / Vendor’s Complete Postal Address:
Door No.
Street:
Location:
District:
City:
State
5. Supplier’s / Vendor’s E-mail ID:
PIN
6. Supplier’s / Vendor’s Telephone Number & Mobile Phone Number:
M
7. Name of the Bank:
8. Bank (Branch) Postal Address:
9. RTGS*/NEFT** - Code of the Branch:
RTGS:
NEFT:
RTGS* - “Real Time Gross Settlement”, NEFT** - “National Electronic Fund Transfer”.
These “IFSC” Codes are unique numbers of each Branch – “Indian Financial Services Code”. For some Branches both the
codes are the same and some Banks, may maintain one Code No. for RTGS and another Code No. for NEFT. Hence,
please fill-up both the rows, even if it is the same.
10. Nature of the Account: (Tick whichever is applicable & put ‘x’ mark for the balance two accounts)
Saving Bank Account:
Cash Credit Account:
Current Account:
11. Bank Account Number of the Supplier: ©
st
© Fill up from the 1 column. For the balance left out blank columns, please mention ‘x’ mark.
We hereby declare that the particulars given above are correct and complete. If the transaction is delayed for reasons of
incomplete or incorrect information, we would not hold MDL responsible.
Date:
Supplier’s Seal:
Authorized Signature of the Supplier:
Certified that the particulars as per Serial Numbers 2, 7 to 11 are correct as per our records.
Date:
Bank’s Stamp
Authorized Signature of the Officer of the Bank.
P a g e | 17
TENDER NO EY/CD/PSN/PROJECT/1300000997 FOR FIRE DETECTION SYSTEM FOR SM2
Enclosure-9
Bidders are requested to check and fill up the followings before they submit their bids and submit along with the
offer:CHECK LIST FOR BIDDER’S/SUPPLIER’S
TENDER NO :-EY/CD/PSN/PROJECT/1300000997
Scope of Work: Temporary fire warning system at SM2
Supplier
Sr.
No.
Description
Tender Requirement
Strike off
whichever is not
applicable
1
Offer Ref. No.
Supplier has to mention their offer no.
2
Technical Acceptance
Supplier has to mention about total technical
acceptance of Tender. (as per Encl. 1)
3
Registered
Whether supplier is Temporarily or Permanently
registered with MDL or not registered at all.
4
Registration
&Document as per TEF
3.
Whether supplier submitted copy of Registration
duly attested (If he is Temp. or Permanent
Registered) along with Document required as per
Tender Enquiry Format (TEF-3)
5
Payment Terms
Supplier has to mention whether payment terms
are acceptable or not acceptable as per tender
enquiry clause no. 10. If any deviation is there,
same has to be mentioned.
6
Blank Price bid format
Whether supplier/contractor submitted Blank
Price-Bid Format (stating only quoted/not quoted)
in Part I – Bid (Technical bid).
7
Offer Validity
Supplier has to mention validity of their offer (in
terms of weeks) from the closing date of
TENDER.
8
Delivery Period /
Completion Schedule
Supplier has to mention delivery / completion
period for Scope of work (in terms of days or
week).
9
TEF Acceptance
Whether Supplier accepted/
not accepted /accepted but deviation seeks for
TEF Clause no. ----.
10
STAC Acceptance
Whether Supplier accepted/
not accepted STAC.
Accepted/Not
Accepted
11
GT&C Acceptance
Whether Supplier accepted/
not accepted GT & C.
Accepted/Not
Accepted
12
Deviation
Whether supplier submitted/Not submitted
Deviation form .If any deviation seeks, same has
to be mention in Remark.
13
Taxes & Duties
Supplier has to mention applicable taxes & duties
in terms of % in Part I – Bid (technical part). If not,
write nil.
14
Delivery terms
Supplier has to mention about free delivery of
material to MDL Stores or if any deviation is there,
same has to be mentioned.
15
Guarantee/ warranty
Whether Supplier accepted/
not accepted (12 Months)
16
PBG @ 10 % of
Purchase order value
Whether Supplier accepted/
not accepted
Remark (if any)
__________________________________
Accepted / not
accepted
Submitted /not
submitted
Submitted /not
submitted
Acceptable / Not
acceptable
/Deviation sought
for TEF Clause
no.---
Y/N
Accepted/Not
Accepted
Accepted/Not
Accepted
P a g e | 18