project 375 Beach 92nd Street Queens, NY 11693 NEW YORK CITY BUILDING DEPARTMENT NOTES 1. A TEST WILL BE CONDUCTED UNDER DIRECTION OF A LICENSED PROFESSIONAL ENGINEER OR ARCHITECT OR OTHER PERSON HAVING NOT LESS THAN FIVE (5) YEARS EXPERIENCE SUPERVISING THE INSTALLATION OF THE MECHANICAL SYSTEM. THE TEST WILL SHOW COMPLIANCE WITH 2008 BUILDING CODE REQUIREMENTS AS OUTLINED IN SECTION [BC 1704]. 2. THE LICENSED PROFESSIONAL ENGINEER OR ARCHITECT OR OTHER PERSON HAVING NOT LESS THAN FIVE (5) YEARS EXPERIENCE SUPERVISING THE INSTALLATION OF MECHANICAL SYSTEMS AND CONDUCTING SUCH TESTS WILL FILE DOCUMENTATION AND REPORT OF TEST THAT THE SYSTEM COMPLIES WITH THE CONSTRUCTION DOCUMENTS AND APPLICABLE LAWS. 3. SPECIAL INSPECTIONS: a. SMOKE CONTROL SYSTEMS INSPECTIONS SHALL BE PERFORMED IN ACCORDANCE WITH SECTION [BC 1704.14] OF THE 2008 NYC BUILDING CODE. NEW PIPING, DUCTWORK OR EQUIPMENT SHEET# EXISTING PIPING, DUCTWORK OR EQUIPMENT TO REMAIN EXISTING RETURN GRILLE/ REGISTER TO REMAIN EXISTING SUPPLY DIFFUSER TO REMAIN EXISTING RETURN GRILLE/ REGISTER TO BE DEMOLISHED TRADE DESCRIPTION DWG. TITLE 1 M-101.00 GROUND LEVEL: MECHANICAL - SYMBOL & NOTES 2 M-102.00 GROUND LEVEL: NYCECC COMCHECK COMPLIANCE CERTIFICATE 3 M-201.00 GROUND LEVEL: MECHANICAL - SPECIFICATIONS I 4 M-202.00 GROUND LEVEL: MECHANICAL - SPECIFICATIONS II 5 M-203.00 GROUND LEVEL: MECHANICAL - SPECIFICATIONS III 6 M-301.00 GROUND LEVEL: MECHANICAL - DUCTWORK PLAN & NOTES 7 M-401.00 GROUND LEVEL: MECHANICAL - DETAILS I 8 M-601.00 GROUND LEVEL: MECHANICAL - EQUIPMENT SCHEDULES architect IN 4. SMOKE DETECTION SYSTEMS SHALL BE INSTALLED AND SEQUENCED TO FOLLOW CONTROLS OPERATIONS IN ACCORDANCE WITH THE REQUIREMENTS OF SECTION [MC 606] OF THE 2008 NYC MECHANICAL CODE. 5. FIRE DAMPERS, SMOKE DAMPERS, COMBINATION FIRE/SMOKE DAMPERS AND CEILING DAMPERS LOCATED WITHIN AIR DISTRIBUTION AND SMOKE CONTROL SYSTEMS SHALL BE INSTALLED IN ACCORDANCE WITH THE REQUIREMENTS OF SECTION [MC 607] OF THE 2008 NYC MECHANICAL CODE. 6. ALL FIRE DAMPERS SHALL BE ACCEPTED FOR USE BY THE NEW YORK CITY DEPARTMENT OF BUILDINGS AND SHALL BE MANUFACTURED AND INSTALLED IN ACCORDANCE WITH THE REQUIREMENTS OF UL 555. 7. SMOKE DAMPERS SHALL BE ACCEPTED FOR USE BY THE NEW YORK CITY DEPARTMENT OF BUILDINGS AND SHALL BE MANUFACTURED AND INSTALLED IN ACCORDANCE WITH THE REQUIREMENTS OF UL 555S. 8. COMBINATION FIRE/SMOKE DAMPERS SHALL BE ACCEPTED FOR USE BY THE NEW YORK CITY DEPARTMENT OF BUILDINGS AND SHALL BE MANUFACTURED AND INSTALLED IN ACCORDANCE WITH THE REQUIREMENTS OF BOTH UL 555 AND UL 555S. 9. CEILING RADITATION DAMPERS SHALL BE ACCEPTED FOR USE BY THE NEW YORK CITY DEPARTMENT OF BUILDINGS AND SHALL BE MANUFACTURED AND INSTALLED IN ACCORDANCE WITH THE REQUIREMENTS OF UL 555C. 10. THESE PLANS ARE APPROVED ONLY FOR THE WORK INDICATED ON THE APPLICATION SPECIFICATION SHEET. ALL OTHER MATTERS SHOWN ARE NOT TO BE RELIED UPON OR TO BE CONSIDERED AS EITHER BEING APPROVED OR IN ACCORDANCE WITH APPLICABLE CODES. A. ALL EXISTING WORK REQUIRED TO REMAIN BUT INTERFERING WITH PROPOSED NEW MECHANICAL (AS WELL AS ELECTRICAL AND GENERAL CONSTRUCTION WORK) SHALL BE RELOCATED AND RECONNECTED USING MATERIALS CONFORMING TO STANDARDS OF THIS CONTRACT. B. REMOVE ALL EXISTING AIR HANDLERS, CEILING AND FLOOR MOUNTED AIR CONDITIONING UNITS WITH ALL ASSOCIATED DUCTWORK, TERMINAL BOXES, DIFFUSERS, GRILLES, HANGERS C. AND ACCESSORIES. EXISTING SUPPLY DIFFUSER TO BE DEMOLISHED RELOCATED RETURN GRILLE/ REGISTER A Division of The Wall Consulting Group, Inc. All Rights Reserved. 2007- 2010 231 West 29th Street - Suite 606, New York, NY 10001 Tel: 212 . 967 . TWIG / Fax: 212 . 967 . 8945 D. REMOVE ALL EXHAUST, RETURN AND TRANSFER FANS AND ASSOCIATED DUCTWORK. RELOCATED SUPPLY DIFFUSER info@twigcon.com REMOVE ALL PIPING, VALVING AND HANGERS ASSOCIATED WITH PIPING TO BE REMOVED E. BACK TO MAINS. IDENTIFY ALL PIPING BY SERVICE TYPE AND CAP AT MAINS. www.twigcon.com NEW RETURN GRILLE/ REGISTER REMOVE BASE BUILDING DUCTWORK AS INDICATED BELOW: 1. REMOVE ALL EXISTING BASE BUILDING SUPPLY AIR, RETURN AIR AND EXHAUST AIR DUCTWORK WITH ALL ASSOCIATED DIFFUSERS, TERMINAL BOXES, CONTROLS, COLLARS, DAMPERS, RETURN/EXHAUST GRILLES AND CONTROLS AND ALL ASSOCIATED DEVICES BACK TO THE EXISTING SUPPLY, RETURN AND EXHAUST AIR SHAFTS, OR AS NOTED ON DRAWINGS. 2. CONTRACTOR TO CONTACT BUILDING MANAGEMENT AND TENANT REGARDING REMOVAL SCOPE OF WORK TO MAINTAIN CONTINUITY OF ALL SERVICES TO ALL TENANTS WHO ARE TO REMAIN OPERATIONAL AND NOT BE AFFECTED BY DEMOLITION 3. WORK. NEW SUPPLY DIFFUSER MECHANICAL SYMBOLS THERMOSTAT OR TEMPERATURE SENSOR TO BE WALL OR DUCT MOUNTED. REFER TO PLANS FOR LOCATION. ALL EXISTING BUILDING FIRE DAMPERS, FIRE/SMOKE DAMPERS, DUCT MOUNTED SMOKE DETECTORS AT SUPPLY AND RETURN AIR SHAFTS TO REMAIN. HUMIDISTAT OR HUMIDITY SENSOR TO BE WALL OR DUCT MOUNTED. REFER TO PLANS FOR LOCATION. F. PROVIDE ADDITIONAL SUPPORT FOR ALL EXISTING DUCTS AND PIPING TO REMAIN WHICH ARE AFFECTED BY DEMOLITION OF EXISTING CEILING AND PARTITIONS. SITE PLAN: 375 BEACH 92ND STREET, QUEENS , NY BLOCK #: 16109 LOT #: 43 NORTH NYC d. HIGH PRESSURE-STEAM PIPING AND ASSOCIATED EQUIPMENT INSPECTIONS SHALL BE PERFORMED ACCORDANCE WITH SECTION [BC 1704.17] OF THE 2008 NYC BUILDING CODE. A. PRIOR TO PROPOSAL SUBMISSION. THIS CONTRACTOR SHALL VISIT THE SITE TO REVIEW THE EXISTING CONDITIONS ASSOCIATED WITH THE SCOPE OF WORK AND ADJACENT AREAS TO ASCERTAIN THE DIFFICULTIES WHICH WILL AFFECT THE EXECUTION OF THE WORK OF THIS CONTRACT. B. SUBMISSION OF A PROPOSAL WILL BE CONSTRUED AS EVIDENCE THAT THE ABOVE SITE EXAMINATION HAS BEEN MADE AND LATER CLAIMS WILL NOT BE RECOGNIZED FOR EXTRA LABOR, EQUIPMENT OR MATERIALS REQUIRED BECAUSE OF DIFFICULTIES ENCOUNTERED WHICH COULD HAVE BEEN FORESEEN HAD SUCH AN EXAMINATION BEEN MADE. C. DEMOLITION WORK SHALL INCLUDE ALL MATERIALS, LABOR, EXTENSIONS, CONNECTIONS, CUTTING REPAIRING, ADAPTING AND OTHER MECHANICAL WORK REQUIRED TO MAINTAIN SERVICE PENDING THE COMPLETION OF THE PERMANENT WORK. COORDINATE THE EXTENT OF DEMOLITION WORK WITH THE ARCHITECT AND BUILDING MANAGEMENT. MECHANICAL DRAWING LIST 2. SCOPE OF WORK. b. ALL MECHANICAL SYSTEMS, EQUIPMENT AND MATERIALS INSPECTIONS SHALL BE PERFORMED IN ACCORDANCE WITH SECTION [BC 1704.15] OF THE 2008 NYC BUILDING CODE. FUEL OIL STORAGE EQUIPMENT AND ASSOCIATED FUEL-PIPING SYSTEMS AND EQUIPMENT INSPECTIONS SHALL BE PERFORMED IN ACCORDANCE WITH SECTION [BC 1704.16] OF THE 2008 BUILDING CODE. MECHANICAL LINE REPRESENTATION 1. GENERAL ALL WORK SHALL COMPLY WITH APPLICABLE SECTIONS OF THE BULDING CODE, CITY OF NEW YORK, EFFECTIVE JULY 1, 2008 AND ALL AMENDMENTS AND RULES AND REGULATIONS OF THE DEPARTMENT OF BUILDINGS TO DATE. c. MECHANICAL DEMOLITION NOTES ELECTRIC ON/OFF THERMALLY PROTECTED SWITCH WITH PILOT LIGHT G. ALL MATERIALS AND EQUIPMENT SHALL BE DISPOSED OF IN ACCORDANCE WITH APPLICABLE LAWS AND ENVIRONMENTAL REGULATIONS. SMOKE DETECTOR H. COORDINATE WITH OWNER TO DETERMINE WHETHER EQUIPMENT IS TO BE TURNED OVER FOR FUTURE USE AND STORED IN THEIR ASSOCIATED STORAGE LOCATIONS. SPOT TYPE LIQUID DETECTOR STARTER / DISCONNECT SWITCH SPACE SENSOR MECHANICAL SCOPE OF WORK MECHANICAL GENERAL NOTES MECHANICAL DRAWING NOTATIONS AY A. GENERAL B ICA A. GENERAL 1. PRIOR TO START OF CONSTRUCTION, CONTRACTOR SHALL PERFORM EXISTING CONDITIONS SURVEY OF THE BASE BUILDING MAIN DUCTS (SUPPLY & RETURN) AND TAKE TRAVERSE READINGS AT EACH BASE BUILDING SUPPLY MAIN. THIS REPORT SHALL BE SUBMITTED TO THE ENGINEER FOR REVIEW & COORDINATION. B. NEW ROOF MOUNTED MAKE-UP AIR UNIT (H+V UNIT) 1. FURNISH AND INSTALL ONE (1) GAS FIRED HEATING AND VENTILATING UNIT, AS INDICATED AND SCHEDULED ON THE DRAWINGS. THE UNIT SHALL BE PROVIDED WITH THE ASSOCIATED ACCESSORIES FOR PROPER OPERATION, TO INCLUDE BUT NOT LIMITED TO GAS PIPING, VALVES, GAUGES, HANGERS, DUCTWORK CONNECTIONS, CONTROLS (WIRING T-STAT, SWITCHES), VIBRATION ISOLATORS, ETC. ["MAU-1"] C. NEW ROOF MOUNTED KITCHEN EXHAUST FAN A - SECTION DESIGNATION B - DRAWING NO. 3. ALL AIR & WATER TESTING & BALANCING SHALL BE PERFORMED IN THE PRESENCE OF THE ENGINEER. REFER TO DRAWING SPECIFICATIONS FOR REQUIREMENTS. POINT OF NEW CONNECTION TO EXISTING WORK 4. ALL CONTROL WORK MUST BE PERFORMED BY TECHNICIANS AND ORGANIZATIONS WITH AT LEAST 5 YEARS OF EXPERIENCE AND WITH FULL FACTORY AUTHORIZATION AND CURRENT CERTIFICATION FOR ALL THE COMPONENTS OF THE SYSTEM. REMOVE AND PATCH EXISTING WORK 5. DUCT DIMENSIONS SHOWN ON THE CONTRACT DRAWINGS ARE FOR AIR FLOW AREA. WHERE DUCTS ARE INDICATED AS ACOUSTICALLY LINED, THE DUCT DIMENSIONS SHALL BE INCREASED AS OUTLINED IN THE HVAC SPECIFICATIONS. 6. BALANCE ALL DIFFUSERS/REGISTERS IN THE AREA OF WORK TO THE REQUIRED CFM'S AS INDICATED ON THE HVAC DRAWINGS. 7. CONTRACTOR TO CONTACT BUILDING MANAGEMENT AND TENANT REGARDING DEMOLITION/REMOVAL SCOPE OF WORK TO ENSURE THAT OTHER TENANTS THAT ARE TO STAY OPERATIONAL ARE NOT AFFECTED BY REMOVALS OF THE BASE BUILDING WORK. 8. COORDINATE WITH BUILDING MANAGEMENT FOR ANY SERVICE INTERRUPTION OF EXISTING SYSTEMS AND GIVE NOTICE AS REQUIRED BY BUILDING RULES AND REGULATIONS. REVISION SYMBOL MECHANICAL ABBREVIATIONS AD AL (550)A ACCESS DOOR ACOUSTIC LINING 5 37 L NE ET 2. CONTRACTOR TO VERIFY THE LOCATION(S) AND INTEGRITY OF THE EXISTING EXHAUST TAP IN EXISTING SHAFT. PATCH AND REPAIR DAMGED DUCTWORK (AS REQUIRED) AND REBALANCE THE TOILET EXHAUST DUCT TO REQUIRED CFM'S. SECTION DESIGNATION ON DRAWING WHERE SECTION IS CUT RE 1. FURNISH AND INSTALL TWO (2) TOILET EXHAUST FANS TO BE INTERCONNECTED TO THE EXISTING BASE BUILDING SYSTEM. THE UNITS SHALL BE PROVIDED WITH THE ASSOCIATED ACCESSORIES FOR PROPER OPERATION, TO INCLUDE BUT NOT LIMITED TO PIPING, VALVES, GAUGES, HANGERS, CONTROLS, (WIRING T-STAT, SWITCHES), VIBRATION ISOLATORS, ETC. ["EF-B-1"] 2. AIR LEAKAGE TESTING CONFORMING TO SMACNA STANDARDS OF ALL DUCTWORK IS REQUIRED AND MUST BE OBSERVED BY THE ENGINEER. REFER TO DRAWING SPECIFICATIONS FOR SCHEDULING AND TESTING REQUIREMENTS. MA JA DR AN H HC ST D. NEW TOILET EXHAUST FAN SYSTEM DRAWING NOTE TAG SN 92 1. FURNISH AND INSTALL ONE (1) KITCHEN EXHAUST FAN, AS INDICATED AND SCHEDULED ON THE DRAWINGS. THE UNIT SHALL BE PROVIDED WITH THE ASSOCIATED ACCESSORIES FOR PROPER OPERATION, TO INCLUDE BUT NOT LIMITED TO INSULATED DUCTWORK CONNECTIONS, HANGERS, DUCT RISER SUPPORTS, CONTROLS (WIRING T-STAT, SWITCHES), VIBRATION ISOLATORS, ETC. ["KX-1"] 1. THERE IS A DRAWING SPECIFICATION AS PART OF THIS CONTRACT. AC BE SUBMISSIONS DATE rev no issue 02.14.11 1 FILING & PRICING CUBIC FEET PER MINUTE AND DIFFUSER TYPE (REFER TO SCHEDULE) BMS BUILDING MANAGEMENT SYSTEM CFM CUBIC FEET PER MINUTE CD CONDENSATE DRAIN F.A. FREE AREA SD SMOKE DAMPER TD TRANSFER DUCT WMS WIRE MESH SCREEN project 375 Beach 92nd Street Queens, NY 11693 dwg title GROUND FLOOR MECHANICAL SYMBOLS & NOTES seal & signature issue date 02/11/2011 project no. t10-12-0230 drawn by cadd checked by twig scale AS NOTED dwg. no. NYCECC NOTES: TO THE BEST OF MY KNOWLEDGE, BELIEF AND PROFESSIONAL JUDGMENT, THESE PLANS AND SPECIFICATIONS ARE IN COMPLIANCE WITH THE NEW YORK CITY ENERGY CONSERVATION CODE. THESE PLANS ARE APPROVED ONLY FOR THE WORK ON THE APPLICATION SPECIFICATION SHEET. ALL OTHER MATTERS SHOWN ARE NOT TO BE RELIED UPON OR TO BE CONSIDERED AS EITHER BEING APPROVED OR IN ACCORDANCE WITH APPLICABLE CODES. cad file sheet 1 of 8 375 Beach 92nd Street M-101.00.dwg NYC dob# project NYCECC COMPLIANCE SHEETS 375 Beach 92nd Street Queens, NY 11693 architect A Division of The Wall Consulting Group, Inc. All Rights Reserved. 2007- 2010 08.31.10 231 West 29th Street - Suite 606, New York, NY 10001 Tel: 212 . 967 . TWIG / Fax: 212 . 967 . 8945 info@twigcon.com 1. www.twigcon.com NYCECC COMPLIANCE: MECHANICAL James Moorhead - SSK J. Moorhead 02.17.11 SUBMISSIONS James Moorhead - SSK J. Moorhead DATE rev no issue 02.14.11 1 FILING & PRICING 02.17.11 project 375 Beach 92nd Street Queens, NY 11693 dwg title GROUND FLOOR MECHANICAL NYCECC CERTIFICATES seal & signature 2. NYCECC COMPLIANCE: INTERIOR LIGHTING & POWER issue date 02/11/2011 project no. t10-12-0230 drawn by cadd checked by twig scale AS NOTED dwg. no. NYCECC NOTES: TO THE BEST OF MY KNOWLEDGE, BELIEF AND PROFESSIONAL JUDGMENT, THESE PLANS AND SPECIFICATIONS ARE IN COMPLIANCE WITH THE NEW YORK CITY ENERGY CONSERVATION CODE. THESE PLANS ARE APPROVED ONLY FOR THE WORK ON THE APPLICATION SPECIFICATION SHEET. ALL OTHER MATTERS SHOWN ARE NOT TO BE RELIED UPON OR TO BE CONSIDERED AS EITHER BEING APPROVED OR IN ACCORDANCE WITH APPLICABLE CODES. cad file sheet 2 of 8 375 Beach 92nd Street M-102.00.dwg NYC dob# project 375 Beach 92nd Street Queens, NY 11693 MECHANICAL SPECIFICATIONS - I 5. EQUIPMENT (PUMPS, AIR CONDITIONING UNITS, FANS, VFD'S, ETC.) 1.09 ACCESS DOORS IN GENERAL CONSTRUCTION PART 1 - GENERAL 1.01 GENERAL REQUIREMENTS: A. WORK INCLUDES ALL HVAC WORK FOR THAI ROCK RESTAURANT, AT 375 BEACH 92ND STREET, QUEENS, NY 11693 B. INSTALL ALL NEW WORK IN A NEAT WORKMANLIKE MANNER READILY ACCESSIBLE FOR OPERATION, MAINTENANCE AND REPAIR. C. CODES, PERMITS AND INSPECTIONS: 1. ALL WORK SHALL COMPLY WITH REQUIREMENTS OF NYC BUILDING CODE, NYC BUILDING DEPARTMENT, BUILDING MANAGEMENT, AND ALL AUTHORITIES HAVING JURISDICTION AND APPLICABLE NATIONAL, STATE AND LOCAL CODES, LAWS AND REGULATIONS GOVERNING OR RELATING TO ANY PORTION OF THIS WORK SHALL BE INCORPORATED INTO AND MADE A PART OF THESE SPECIFICATIONS. CONTRACTOR IS TO INFORM ENGINEER OF ANY EXISTING WORK OR MATERIALS WHICH VIOLATE ANY OF THE ABOVE LAWS AND REGULATIONS. ANY WORK DONE BY THE CONTRACTOR CAUSING SUCH VIOLATION SHALL BE CORRECTED AT CONTRACTOR'S EXPENSE BY THIS CONTRACTOR AND AT NO EXPENSE TO THE OWNER. 2. THIS CONTRACTOR SHALL PROCURE THE SERVICES OF A THIRD PARTY INSPECTION COMPANY TO PERFORM ALL SPECIAL INSPECTIONS IN ACCORDANCE WITH THE NEW YORK CITY BUILDING CODE. SECURE ALL REQUIRED PERMITS AND APPROVALS AND TRANSMIT SAME TO THE OWNER. CONTRACTOR SHALL BE RESPONSIBLE FOR ALL FEES 3. ALL APPLICABLE EQUIPMENT SHALL HAVE AN "M.E.A. OR B.S.A. NUMBER." D. SITE VERIFICATION: 1. PRIOR TO SUBMISSION OF THE BID, THIS CONTRACTOR SHALL VISIT THE JOB SITE TO ASCERTAIN THE ACTUAL FIELD CONDITIONS AS THEY RELATE TO THE WORK INDICATED ON THE DRAWINGS AND DESCRIBED HEREIN. DISCREPANCIES, IF ANY, SHALL BE BROUGHT TO THE ENGINEER'S ATTENTION PRIOR TO SUBMISSION OF THE BID, AND IF NOT RESOLVED TO SATISFACTION, SHALL BE SUBMITTED AS A WRITTEN QUALIFICATION OF THE BID. SUBMISSION OF A BID SHALL BE EVIDENCE OF SITE VERIFICATION HAS BEEN PERFORMED AS DESCRIBED ABOVE. E. CONTRACT DOCUMENTS: 2. 3. PRIOR TO SUBMISSION OF A FORMAL BID, THIS CONTRACTOR SHALL REVIEW ALL DRAWINGS OF THE ENTIRE PROJECT INCLUDING GENERAL CONSTRUCTION, DEMOLITION, ARCHITECTURAL, MECHANICAL, ELECTRICAL, PLUMBING AND SPRINKLER AND SHALL INCLUDE ANY WORK REQUIRED IN THE BID WHICH IS INDICATED OR IMPLIED TO BE PERFORMED BY THIS TRADE IN OTHER SECTIONS OF THE WORK. DRAWINGS ARE DIAGRAMMATIC AND INDICATE GENERAL ARRANGEMENT OF WORK AND APPROXIMATE LOCATION OF EQUIPMENT. REFER TO ARCHITECTURAL DRAWINGS FOR ALL DIMENSIONS AND COORDINATE FINAL LOCATIONS OF DIFFUSERS, GRILLES, REGISTERS, THERMOSTATS, SENSORS, SWITCHES AND ANY WALL MOUNTED DEVICES. ALL WORK SHALL BE COORDINATED WITH OTHER TRADES TO AVOID CONFLICT. 4. IF A CONFLICT OCCURS IN THE SPECIFICATIONS AND/OR ON THE DRAWINGS, THE MORE STRINGENT SITUATION SHALL APPLY. 5. ANY EQUIPMENT, PARTS, MATERIALS, ACCESSORIES, OR LABOR THAT IS NECESSARY FOR PROPER PERFORMANCE OF THE MECHANICAL WORK ALTHOUGH NOT SPECIFICALLY MENTIONED HEREIN OR SHOWN ON THE DRAWINGS, SHALL BE FURNISHED AND INSTALLED WITHOUT ADDITIONAL COSTS. F. GUARANTEE: 6. ALL MATERIALS AND WORKMANSHIP SHALL BE GUARANTEED FOR A PERIOD OF ONE YEAR FROM DATE OF FINAL ACCEPTANCE OF THIS WORK. FINAL ACCEPTANCE SHALL BE DEFINED AS THE TIME AT WHICH THE MECHANICAL WORK IS TAKEN OVER AND ACCEPTED BY THE OWNER, AND IS UNDER CARE, CUSTODY, AND CONTROL OF THE OWNER. ENGAGE THE SERVICES OF VARIOUS MANUFACTURERS SUPPLYING THE EQUIPMENT FOR THE PROPER STARTUP AND OPERATION OF ALL SYSTEMS INSTALLED. INSTRUCT THE OWNERS PERSONNEL IN THE PROPER OPERATION AND SERVICING OF THE SYSTEM. 7. THE CONTRACTOR SHALL GUARANTEE TO REPLACE OR REPAIR PROMPTLY AND ASSUME RESPONSIBILITY FOR ALL EXPENSES INCURRED FOR ANY W0RKMANSHIP AND EQUIPMENT IN WHICH DEFECTS DEVELOP WITHIN THE GUARANTEE PERIOD. THIS WORK SHALL BE DONE AS DIRECTED BY THE OWNER. THIS GUARANTEE SHALL INCLUDE RESPONSIBILITY FOR ALL EXPENSES INCURRED IN REPAIRING AND REPLACING WORK OF OTHER TRADES AFFECTED BY DEFECTS, REPAIRS OR REPLACEMENTS IN EQUIPMENT SUPPLIED BY THIS CONTRACTOR. 8. THIS CONTRACTOR IS RESPONSIBLE FOR THE MAINTENANCE AND OPERATION OF ALL SYSTEMS UNTIL THE FINAL ACCEPTANCE OF THE WORK. 9. ALL AIR CONDITIONING UNIT COMPRESSORS AND REFRIGERATION COMPONENTS SHALL HAVE A 5-YEAR WARRANTY. G. THE "GENERAL CONDITIONS OF THE CONTRACT FOR CONSTRUCTION" AIA DOCUMENT A201, LATEST EDITION, OR AS REQUIRED BY THE ARCHITECT DOCUMENTS, AND/OR THE STRUCTURAL ENGINEER'S DOCUMENTS, AS APPLICABLE, ARE PART OF THIS CONTRACT. H. DEFINITIONS: 10. MECHANICAL CONTRACTOR, "THIS CONTRACTOR" - THE PARTY OR PARTIES HAVE BEEN DULY AWARDED THE CONTRACT FOR AND ARE THEREBY MADE RESPONSIBLE FOR THE MECHANICAL WORK AS DESCRIBED HEREIN. 11. "THIS CONTRACT", "THE CONTRACT" - THE AGREEMENT COVERING THE WORK TO BE PERFORMED BY "THIS CONTRACTOR". 12. "APPROVED", "EQUAL", "SATISFACTORY", "ACCEPTED", "ACCEPTABLE", "EQUIVALENT" - SUITABLE FOR USE ON THE PROJECT, AS DETERMINED BY THE ENGINEER BASED ON DOCUMENTS PRESENTED FOR SUCH DETERMINATION. 13. "THESE SPECIFICATIONS", "THIS SECTION, PART, DIVISION" (OF THE SPECIFICATION) - THE DOCUMENT SPECIFYING THE WORK TO BE PERFORMED BY "THIS CONTRACTOR". 14. "THE MECHANICAL WORK", "THIS WORK", - ALL LABOR MATERIALS, EQUIPMENT, APPARATUS, CONTROLS, ACCESSORIES, AND OTHER ITEMS REQUIRED FOR A PROPER AND COMPLETE INSTALLATION BY THE MECHANICAL CONTRACTOR. 15. "ARCHITECT", "ENGINEER", "OWNER'S REPRESENTATIVE" - THE PARTY OR PARTIES RESPONSIBLE FOR INTERPRETING, ACCEPTING AND OTHERWISE RULING ON THE PERFORMANCE UNDER THIS CONTRACT. 16. "FURNISH" - PURCHASE AND DELIVER TO THE PROJECT SITE COMPLETE WITH EVERY NECESSARY APPURTENANCE AND SUPPORT, ALL AS PART OF THE MECHANICAL WORK. 17. "INSTALL" - UNLOAD AT THE DELIVERY POINT AT THE SITE AND PERFORM EVERY OPERATION NECESSARY TO ESTABLISH SECURE MOUNTING INSTALLATION AND CORRECT OPERATION AT THE PROPER LOCATION IN THE PROJECT, ALL AS PART OF THE MECHANICAL WORK. 18. "PROVIDE" - "FURNISH" AND "INSTALL". 19. "NEW" - MANUFACTURED WITHIN THE PAST TWO YEARS AND NEVER BEFORE USED. 20. "RELOCATE" - MOVE EXISTING EQUIPMENT AND ALL ACCESSORIES AS REQUIRED. 21. "REMOVE" - DISMANTLE AND CART AWAY FROM SITE INCLUDING ALL RELATED ACCESSORIES. ALL ITEMS SHALL BE LEGALLY DISPOSED OF. ALL OTHER EQUIPMENT AND OPERATIONS IN ANY WAY EFFECTED BY THE REMOVAL IS TO REMAIN IN FULL OPERATION. PROVIDE ALL NECESSARY COMPONENTS TO MAINTAIN SUCH OPERATION. 1.02 SCOPE OF WORK A. PROVIDE ALL LABOR, MATERIALS, EQUIPMENT, AND CONTRACTOR'S SERVICES NECESSARY FOR COMPLETE, SAFE INSTALLATION OF ALL MECHANICAL WORK. THE SCOPE OF WORK SHALL INCLUDE BUT NOT BE LIMITED TO THE FOLLOWING: 1. DEMOLITION AND REMOVAL OF ITEMS AS REQUIRED. 2. DUCTWORK AND DUCTWORK ACCESSORIES. 3. AIR DISTRIBUTION SYSTEM (AIR OUTLETS, ETC.). 4. PIPING AND PIPING ACCESSORIES INCLUDING ALL VALVING. 6. INSULATION OF PIPING, EQUIPMENT AND DUCTWORK. 7. SOUND ATTENUATORS AND SOUND LINING. 8. AUTOMATIC TEMPERATURE CONTROLS. 9. TESTING AND BALANCING. 10. CUTTING AND PATCHING. 11. SHOP DRAWINGS. 12. AS-BUILT DRAWINGS. 13. OPERATING AND MAINTENANCE MANUALS. A. THIS CONTRACTOR SHALL SUBMIT TO THE ARCHITECT FOR APPROVAL A PLAN INDICATING THE SIZE AND LOCATION OF ALL ACCESS DOORS REQUIRED FOR OPERATION AND MAINTENANCE OF ALL CONCEALED EQUIPMENT, DEVICES, VALVES, DAMPERS AND CONTROLS. CONTRACTOR SHALL ARRANGE FOR FURNISHING AND INSTALLATION OF ALL ACCESS DOORS IN FINISHED CONSTRUCTION AND INCLUDE COSTS IN THE BID. ACCESS DOORS SHALL BE OF ADEQUATE SIZE TO PROVIDE ACCESS TO CONCEALED ITEMS FOR OPERATIONS AND MAINTENANCE, WITH A MINIMUM SIZE OF 18"x18". PART 2 - PRODUCTS/APPLICATIONS 2.01 DUCTWORK AND ACCESSORIES A. ALL DUCTWORK SHALL BE FABRICATED AND INSTALLED IN ACCORDANCE WITH SMACNA HVAC DUCT CONSTRUCTION STANDARDS - METAL AND FLEXIBLE, 1995 OR LATEST EDITION, SMACNA HVAC AIR DUCT LEAKAGE TEST MANUAL, 1991 OR LATEST EDITION, NFPA 90A LATEST EDITION, AND NEW YORK CITY BUILDING CODE. THE MORE STRINGENT REQUIREMENT OF ANY CODES SHALL APPLY. architect 14. FULL COORDINATION WITH OTHER TRADES. B. PROVIDE ALL SUPPORTING AND HANGING DEVICES IN ACCORDANCE WITH NEW YORK CITY BUILDING CODE AND SMACNA. 15. WARRANTY AND GUARANTY. 16. PHASING AS REQUIRED BY OWNER, CONSTRUCTION MANAGER, GENERAL CONTRACTOR OR BUILDING MANAGEMENT. C. DUCTWORK LAYOUT AND ROUTING IS SCHEMATIC AND THE MECHANICAL CONTRACTOR IS RESPONSIBLE FOR ALL DUCT SIZE CHANGES AND RELOCATIONS TO ACCOMMODATE SPACE AND STRUCTURAL CONDITIONS. OFFSETS AND TRANSFORMATIONS SHALL PRESERVE THE FULL INSIDE CROSS-SECTIONAL AREA OF DUCTWORK SHOWN ON THE DRAWINGS. 17. PREMIUM TIME FOR WORK TO BE PERFORMED AFTER-HOURS AS REQUIRED BY BUILDING MANAGEMENT AND/OR OWNER. D. DUCTWORK SHALL HAVE PRESSURE CLASSIFICATION, SEALING REQUIREMENTS AND LEAKAGE TESTING IN ACCORDANCE WITH SMACNA AND AS LISTED BELOW UNLESS OTHERWISE SPECIFIED OR SHOWN ON THE DRAWINGS: 18. FILING, PERMITS, CONTROLLED INSPECTIONS. 1. 3" CLASS: ALL SUCTION AND DISCHARGE OF KITCHEN HOOD, AND SMOKE EXHAUST DUCTWORK. SEAL CLASS "B", LEAKAGE CLASS 12 (RECTANGULAR) OR CLASS 6 (ROUND). 19. FULL TESTING AND STARTUP OF ALL SYSTEMS. B. SECURE CERTIFICATES, PAY ALL FEES AND CHARGES FOR ALL WORK INSTALLED, CERTIFYING COMPLIANCE WITH ALL AUTHORITIES AND ARTICLES 27-132 (C26-106.3), 27-778 (C26-1301.1), 27-779 (C26-1301.2,) 27-780 (C261301.3),27-781 (C26-1301.4). CONTRACTOR TO PERFORM REQUIRED CONTROLLED INSPECTION AND OBTAIN ALL EQUIPMENT USE PERMITS. DELIVER CERTIFICATES TO OWNER FOR SIGNING BEFORE FILING. 1.03 COORDINATION WITH BUILDING MANAGEMENT A. THIS CONTRACTOR IS TO OBTAIN A COPY OF THE BUILDING RULES AND REGULATIONS PRIOR TO BID SUBMISSION TO DETERMINE REQUIREMENTS AND THE EXTENT OF PREMIUM TIME WORK REQUIRED BY BUILDING. B. THIS CONTRACTOR IS RESPONSIBLE FOR ADHERING TO THE BUILDING OWNER'S RULES AND REGULATIONS. ANY DISCREPANCIES BETWEEN THE CONTRACT DOCUMENTS AND THE BUILDING RULES AND REGULATIONS SHALL BE SUBMITTED IN WRITING TO THE ARCHITECT/ENGINEER FOR REVIEW, WITH BID SUBMISSION. C. COORDINATE WITH BUILDING OWNER FOR ANY SERVICE INTERRUPTION OF EXISTING SYSTEMS AND GIVE NOTICE AS REQUIRED BY BUILDING RULES AND REGULATIONS OR A MINIMUM OF TWO (2) DAYS PRIOR TO ANY WORK, WHICHEVER IS MORE STRINGENT. CONTRACTOR IS TO PERFORM WORK ON PREMIUM TIME, IF SO DIRECTED BY BUILDING OWNER, SO AS NOT TO DISTURB EXISTING TENANTS ON OTHER FLOORS. 1.04 SHOP DRAWINGS A. SUBMIT SHOP DRAWINGS CERTIFIED BY ALL TRADES THAT COORDINATION HAS BEEN COMPLETED. SUBMIT ALL CERTIFIED EQUIPMENT CUTS WITH CONSTRUCTION WIRING DIAGRAMS AND AUTOMATIC TEMPERATURE CONTROL REQUIREMENTS. SHOP DRAWINGS SUBMISSION SHALL INCLUDE, BUT NOT BE LIMITED TO, THE FOLLOWING: 1. DUCTWORK - PROVIDE DUCT SHOP STANDARDS AND LEAKAGE TEST CERTIFICATION, AS REQUIRED, AND 3/8 SCALE DUCT LAYOUT. 2. 2" CLASS: ALL OTHER LOW PRESSURE DUCTWORK. SEAL CLASS "C", LEAKAGE CLASS 24 (RECTANGU LAR) OR CLASS 12 (ROUND). 3. LEAKAGE TESTING ALL TESTING SHALL BE DONE IN THE PRESENCE OF THE ENGINEER OR OWNER'S REPRESENTATIVE. THE CONTRACTOR IS RESPONSIBLE FOR PROVIDING ALL COLLARS, CAPS, ELECTRIC POWER, ETC. NECESSARY TO PERFORM THE TESTS. THE CONTRACTOR IS ALSO RESPONSIBLE FOR SCHEDULING THE TEST NO LESS THAN THREE (3) BUSINESS DAYS PRIOR TO ITS INTENDED OCCURRENCE. LOW PRESSURE DUCTWORK (2"CLASS) SHALL BE TESTED ON AN AS-NEEDED BASIS AT THE ENGINEER'S DIRECTION. LEAKAGE TEST PROCEDURES SHALL FOLLOW THE OUTLINES AND CLASSIFICATIONS IN THE SMACNA HVAC DUCT LEAKAGE TEST MANUAL. IF SPECIMEN FAILS TO MEET ALLOTTED LEAKAGE LEVEL, THE CONTRACTOR SHALL MODIFY TO BRING IT INTO COMPLIANCE AND SHALL RETEST IT UNTIL ACCEPTABLE LEAKAGE IS DEMONSTRATED. TESTS AND NECESSARY REPAIR SHALL BE COMPLETED PRIOR TO CONCEALMENT OF DUCTS. A Division of The Wall Consulting Group, Inc. All Rights Reserved. 2007- 2010 231 West 29th Street - Suite 606, New York, NY 10001 Tel: 212 . 967 . TWIG / Fax: 212 . 967 . 8945 info@twigcon.com www.twigcon.com E. MATERIALS: 1. SHEET METAL: UNLESS OTHERWISE SPECIFIED OR INDICATED, DUCTS SHALL BE CONSTRUCTED OF HOTDIPPED GALVANIZED SHEETMETAL WITH G60 COMMERCIAL COATING ACCORDING TO ASTM 653 & A924. 2. BLACK IRON (CARBON STEEL): PROVIDE DUCTWORK OF BLACK IRON (CARBON STEEL), WHERE INDICATED. DUCTWORK SHALL BE BLACK IRON (CARBON STEEL) SHEET COMPLYING WITH ANSI/ASTM 415. PROVIDE FOR ALL KITCHEN EXHAUST AND FIELD FABRICATED LOW TEMPERATURE CHIMNEYS, BREECHING AND KITCHEN HOOD SYSTEMS. 3. IN WELDED CASES FOR ALL METAL DUCTWORK, THE FILLER ROD MATERIAL SHALL EQUAL OR EXCEED THE BASE METAL PROPERTIES. 4. WELDED DUCTWORK SHALL BE SEALED AIR, WATER AND GAS TIGHT. 2. PIPING LAYOUT AND APPURTENANCES - PROVIDE PIPING, VALVING, CHEMICAL TREATMENT, SHOP STANDARDS AND 3/8 SCALE PIPING LAYOUT WITH ALL VALVING. 5. FLEXIBLE CONNECTIONS AT FANS SHALL BE NEOPRENE COATED, FLAME RETARDANT GLASS FABRIC (COMPLYING WITH NFPA 90 AND 96), 30 OZ./SQ. YD. WITH SEWED AND CEMENTED SEAMS. 3. INSULATION FOR DUCTWORK, PIPING AND EQUIPMENT. 6. FLEXIBLE DUCTWORK SHALL NOT BE USED ON THIS PROJECT. 4. CERTIFIED AIR AND WATER BALANCING REPORT F. FABRICATION: 5. EQUIPMENT CATALOG CUTS FOR ALL ITEMS TO BE UTILIZED ON PROJECT (FANS, PUMPS, AC UNITS, VARIABLE FREQUENCY DRIVES, ETC.) 6. AIR OUTLETS (DIFFUSERS, REGISTERS, GRILLES, ETC.) 7. AUTOMATIC TEMPERATURE CONTROL DIAGRAMS, DEVICES AND SEQUENCE OF OPERATION 8. AS-BUILT DRAWINGS AT PROJECT COMPLETION OF THE INSTALLED CONDITION OF WORK. B. THE QUANTITY OF SHOP DRAWINGS SHALL AS A MINIMUM BE FOUR (4) COPIES OF 8-1/2"x11" SUBMISSIONS AND ONE (1) REPRODUCIBLE AND ONE (1) PRINT OF ALL DRAWINGS. SPECIFIC JOB REQUIREMENTS MAY BE MORE STRINGENT AND CONTRACTOR IS RESPONSIBLE TO OBTAIN REQUIREMENTS FROM CONSTRUCTION MANAGER, GENERAL CONTRACTOR OR ARCHITECT. 1. CONFORM TO SMACNA REQUIREMENTS FOR METAL THICKNESS, REINFORCING, JOINTS, AND SEALING FOR MAXIMUM STATIC PRESSURES INVOLVED. ALL SEAMS AND JOINTS SHALL BE SEALED AND TAPED. 2. ELBOWS SHALL CONFORM TO SMACNA REQUIREMENTS AND THE FOLLOWING: a. PROVIDE LONG RADIUS TYPE WITH CENTERLINE RADIUS MINIMUM 1.5 TIMES DUCT WIDTH. PROVIDE SHORT RADIUS OR SQUARE ELBOWS WHERE INDICATED OR WHERE REQUIRED TO FIT RESTRICTED SPACES. PROVIDE DOUBLE THICKNESS TURNING VANES ON ALL SHORT RADIUS AND MITERED ELBOWS. CONFORM TO SMACNA FOR THE NUMBER OF VANES FOR FITTINGS. 3. BRANCH CONNECTIONS: PROVIDE 45 DEGREE ENTRY OR CONICAL TAPS. PROVIDE RADIUS TYPE FITTINGS FOR DIVIDED FLOW BRANCHES. G. ACOUSTICALLY LINED DUCTWORK: 1.05 MAINTENANCE MANUALS A. SUBMIT FOUR (4) LOOSE-LEAF BOUND OPERATING AND MAINTENANCE MANUALS WITH INDEX AND INDEX TABS TO INCLUDE THE FOLLOWING: 1. OPERATING AND MAINTENANCE INSTRUCTIONS ON ALL SYSTEMS. 1. PROVIDE MAT-FACED GLASS DUCT LINER, 1-INCH THICK -2 LB/CF DENSITY. DUCT DIMENSIONS INDICATED ARE CLEAR (NET) INSIDE DIMENSIONS. FOR DUCT VELOCITIES GREATER THAN 2,000 FPM, FACE DUCTLINER WITH 24 GAUGE PERFORATED ALUMINUM OR GALVANIZED STEEL, FULLY COVERING DUCTLINER, AND SUPPORTED 12" ON CENTER. DO NOT EXTERNALLY INSULATE ACOUSTICALLY LINED DUCTWORK. CONFORM TO SMACNA REQUIREMENTS FOR INSTALLATION. PROVIDE ACOUSTICALLY LINED DUCT WHERE LISTED BELOW AND/OR SHOWN ON THE DRAWINGS: 2. MANUFACTURERS' CATALOG CUTS ON ALL EQUIPMENT. 3. AUTOMATIC TEMPERATURE CONTROL SYSTEMS WITH SEQUENCE OF OPERATIONS, CATALOG CUTS OF ALL DEVICES AND POINT-TO-POINT WIRING DIAGRAMS. 4. CERTIFIED FINAL AIR AND WATER BALANCING REPORT. a. ALL TRANSFER DUCTS b. WITHIN MINIMUM 20 FEET OF ALL AC UNIT DISCHARGES c. WITHIN MINIMUM 20 FEET OF FAN INLET AND DISCHARGES H. DUCT ACCESS DOORS: 5. DUCT AND PIPING AS-BUILT DRAWINGS WITH VALVE CHART AND KEY PLAN DRAWINGS INSERTED IN BINDER. 1. CONFORM TO SMACNA WITH PIANO HINGES, TWO SASH LOCKS AND DOOR GASKETS. SCREWED ACCESS PANELS ARE NOT PERMITTED. PROVIDE REMOVABLE ACCESS DOORS WHERE DOOR SWING CAN NOT BE ACCOMMODATED. 6. ALL ITEMS SUBMITTED FOR REVIEW IN SHOP DRAWING SECTION. 2. SIZE: MINIMUM 20" X 14" EXCEPT DUCTS LESS THAN 16", ONE DIMENSION 20" AND THE OTHER DIMENSION, 2" LESS THAN THE DUCT WIDTH. 1.06 AS-BUILT DRAWINGS A. CONTRACTOR SHALL MAINTAIN RECORD DRAWING PRINTS ON JOB SITE AND RECORD, AT TIME OF OCCURRENCE, DEVIATIONS FROM CONTRACT DOCUMENTS DUE TO FIELD COORDINATION, BULLETINS, OR ADDENDA. B. CONTRACTOR SHALL REVISE SHOP DRAWINGS TO CONFORM TO RECORD DRAWINGS AND SUBMIT AN AS-BUILT CONDITION (PIPING AND DUCTWORK) DRAWINGS UPON COMPLETION OF THE PROJECT. FINAL SUBMISSION OF REPRODUCIBLE ASBUILT DRAWINGS ARE TO BE SIGNED AND CERTIFIED BY INSTALLING CONTRACTOR THAT THIS IS THE AS-BUILT CONDITION OF THE WORK. 1.07 SERVICE AND WARRANTY (MAINTENANCE CONTRACT) A. THIS CONTRACTOR SHALL PROVIDE AS AN ADD ALTERNATE PRICE, A FULL ONE YEAR SERVICE AND WARRANTY OF ALL MECHANICAL COMPONENTS AND SYSTEMS, WITH PRICES FOR YEARS 2, 3 AND 4 FOLLOWING THIS FIRST YEAR. AT THE TIME OF ACCEPTANCE OF PROJECT, THE TENANT OR OWNER'S REPRESENTATIVE WILL DECIDE TO ACCEPT WHICH ALTERNATE, IF ANY. 1.08 SUBSTITUTIONS A. NO SUBSTITUTE MATERIAL OR MANUFACTURER OF EQUIPMENT SHALL BE PERMITTED WITHOUT A FORMAL WRITTEN SUBMITTAL TO THE ENGINEER WHICH INCLUDES ALL DIMENSIONAL, PERFORMANCE AND MATERIAL SPECIFICATIONS. ANY CHANGES IN LAYOUT, ELECTRICAL CHARACTERISTICS, STRUCTURAL REQUIREMENTS, OR DESIGN DUE TO THE USE OF A SUBSTITUTION SHALL BE SUBMITTED TO THE ENGINEER AS PART OF THIS PROPOSAL. THE CONTRACTOR TAKES FULL RESPONSIBILITY FOR THE SUBSTITUTION AND ALL CHANGES RESULTING FROM SUBSTITUTION. ALL ITEMS SHALL BE SUBMITTED FOR REVIEW IN CONJUNCTION WITH THE SUBMITTAL OF THE SUBSTITUTION. ANY SUBSTITUTION MUST BE SUBMITTED WITH AN EXPLANATION WHY A SUBSTITUTION IS BEING UTILIZED. IF THE SUBSTITUTED ITEM DEVIATES FROM THE SPECIFIED ITEM, THOSE DEVIATIONS ARE TO BE IDENTIFIED ON A LINE BY LINE BASIS. IF THE SUBSTITUTE IS BEING UTILIZED FOR FINANCIAL REASONS, THE ASSOCIATED CREDIT MUST BE SIMULTANEOUSLY SUBMITTED. B. ALL SUBSTITUTED EQUIPMENT SHALL CONFORM TO SPACE REQUIREMENTS AND PERFORMANCE REQUIREMENTS SHOWN ON CONTRACT DOCUMENTS. CONTRACTOR SHALL REPLACE ANY EQUIPMENT THAT DOES NOT MEET THESE REQUIREMENTS AT HIS OWN EXPENSE. ANY MODIFICATIONS TO ASSOCIATED SYSTEMS OR ADDITIONAL COSTS ATTRIBUTED TO THIS SUBSTITUTION SHALL BE AT THIS CONTRACTOR'S EXPENSE. SUBMISSIONS DATE rev no issue 02.14.11 1 FILING & PRICING 3. PROVIDE ACCESS DOORS: AT ENTERING AND LEAVING SIDES OF COILS IN DUCTS; AUTOMATIC DAMPERS ON LINKAGE SIDE, MANUAL VOLUME DAMPERS 2 SQ. FT. AND LARGER, FIRE DAMPERS, SMOKE DAMPERS, COMBINATION FIRE/SMOKE DAMPERS, SMOKE DETECTION HEADS, FAN BEARINGS ENCLOSED IN DUCTS, SUCTION AND DISCHARGE SIDES OF CEILING MOUNTED FANS, FILTERS, REHEAT COILS, AT ALL EQUIPMENT REQUIRING ACCESS AND AS INDICATED ON DRAWINGS. 2.02 INSULATION A. ALL INSULATION SHALL MEET THE REQUIREMENTS OF ASTM, NFPA NEW YORK STATE ENERGY CODE AND ALL AUTHORITIES HAVING JURISDICTION. ALL MECHANICAL INSULATION, (JACKETING, COVERINGS, ADHESIVES, MASTICS, FACINGS, TAPES, ETC.), SHALL HAVE RATINGS NOT EXCEEDING A "FLAME SPREAD" OF 25 OR LESS AND "SMOKE DEVELOPED" INDEX OF 50 OR LESS. B. BEFORE APPLYING INSULATION, ALL PRESSURE AND LEAK TESTS SHALL BE COMPLETED AND APPROVED. FURNISH AND INSTALL AS PER MANUFACTURERS REQUIREMENTS. project C. INSULATION FOR FITTINGS OR ACCESSORIES REQUIRING SERVICING OR INSPECTION SHALL HAVE INSULATION REMOVABLE AND REPLACEABLE WITHOUT DAMAGE. 375 Beach 92nd Street Queens, NY 11693 D. DUCT INSULATION: 1. GENERAL dwg title a. INSULATION SHALL BE APPLIED WITH MASTICS, ADHESIVES, COATINGS, WITH COVERS, WEATHERPROTECTION AND OTHER WORK AS REQUIRED BY MANUFACTURER'S RECOMMENDATIONS. DO NOT INSULATE SOUND LINED DUCTWORK. MATERIALS SHALL MEET REQUIREMENTS OF ADHESIVE AND SEALANT COUNCIL STANDARDS AND SMACNA. 1. KITCHEN EXHAUST a. KITCHEN EXHAUST DUCTWORK SHALL HAVE A MINIMUM INSULATION COVERING OF TWO INCHES OF CALCIUM SILICATE BLOCK, ATTACHED WITH 1" HIGH RIB COPPER STEEL LATH. FINISHED WITH TWO COATS OF CEMENT. INSURE THAT THE INSULATION EXTENDS THROUGH ALL WALL PENETRATIONS TO SEPARATE THE DUCTS FROM THE BUILDING CONSTRUCTION. C. CONTRACTOR SHALL SUBMIT BID BASED ON SPECIFIED ITEMS AND SHALL SUPPLY AS AN ALTERNATE PRICE ANY SUBSTITUTIONS. GROUND FLOOR MECHANICAL SPECIFICATIONS SHEET I seal & signature issue date 02/11/2011 project no. t10-12-0230 drawn by cadd checked by twig scale AS NOTED dwg. no. NYCECC NOTES: TO THE BEST OF MY KNOWLEDGE, BELIEF AND PROFESSIONAL JUDGMENT, THESE PLANS AND SPECIFICATIONS ARE IN COMPLIANCE WITH THE NEW YORK CITY ENERGY CONSERVATION CODE. THESE PLANS ARE APPROVED ONLY FOR THE WORK ON THE APPLICATION SPECIFICATION SHEET. ALL OTHER MATTERS SHOWN ARE NOT TO BE RELIED UPON OR TO BE CONSIDERED AS EITHER BEING APPROVED OR IN ACCORDANCE WITH APPLICABLE CODES. cad file sheet 3 of 8 375 Beach 92nd Street M-201.00.dwg NYC dob# project 375 Beach 92nd Street Queens, NY 11693 MECHANICAL SPECIFICATIONS - II 2. PROVIDE AS AN ALTERNATE FOR KITCHEN EXHAUST DUCT INSULATION A. KITCHEN EXHAUST DUCTWORK INSULATION SHALL BE IN DIRECT CONTACT WITH THE DUCT IT ENCLOSES. PROTECT EVERY PORTION OF THE DUCT WITH NO LESS THAN TWO (2) LAYERS FOR GREASE DUCT APPLICATIONS AND TWO (2) LAYERS FOR TWO (2) HOUR AIR DUCT ENCLOSURES. OVERLAP BOTH PERIMETER AND LONGITUDINAL JOINTS WITH AMINIMUM OF 3" PER LAYER OF MATERIAL. ALL KITECHN EXHAUST DUCT HANGERS SHALL BE WRAPPED WITH FIREMASTER DUCT WRAP TO MAINTAIN A 3-HOUR RATED SUPPORT AND THE MEA LISTING. B. ALL DUCT INSULATIONS SHALL BE IN STRICT ACCORDANCE TO MANUFACTURER'S RECOMMENDATIONS AND MEA LISTING, IN ORDER TO MAINTAIN VAPOR BARRIERS AND FIRE PROTECTION. 5. MOUNTING OF CEILING-SUPPORTED FANS, IN-LINE PUMPS, HEAT EXCHANGERS, AND AIR HANDLING UNITS SPRING ISOLATORS - (TYPE DNHS). d. INLETS AND OUTLETS SHALL HANDLE AIR QUANTITIES INDICATED AT OPERATING VELOCITIES WITH SOUND PRESSURE LEVEL NOT TO EXCEED NC-30, UNLESS NOTED OTHERWISE. 6. SUPPORT OF PIPING IN EQUIPMENT ROOMS AND WHERE EXPOSED ON ROOF e. DIFFUSERS, GRILLES AND REGISTERS SHALL BE INSTALLED WITH FACES SET LEVEL AND PLUMB AND MOUNTED TIGHTLY AGAINST MOUNTING SERVICE. a. ALL WATER PIPING OUTSIDE OF SHAFTS WITHIN 50 FEET OF CONNECTED ROTATING EQUIPMENT TO BE SUPPLIED WITH ISOLATORS. f. ALL AIR INLETS AND OUTLETS TO BE STEEL OR ALUMINUM IF EXPOSED TO MOISTURE UNLESS OTHERWISE INDICATED. FINISHES TO BE SELECTED BY ARCHITECT. b. HANGER ROD ISOLATORS (TYPE 30N) MOUNTINGS. g. DIFFUSERS, GRILLES AND REGISTERS SHALL BE MANUFACTURED BY TITUS OR ANEMOSTAT. c. FLOOR SUPPORTED PIPING ISOLATORS (TYPE SLR). C. TYPE D-3: TWO (2) LAYERS OF LIGHTWEIGHT DUCTWRAP, NON-ASBESTOS, HIGH TEMPERATURE, INORGANIC, CERAMIC FIBER BLANKET TOTALLY ENCAPSULATED IN FOIL/SCRIM HAVINGH A SERVICE TEMPERATURE RANGE UP TO 2300 DEG.F. D. PROVIDE AS AN ALTERNATE PANTRY EXHAUST DUCT INSULATION AS MANUFACTURED BY FIREMASTER DUCTWRAP: 3M COMPANY OR AS APPROVED. d. VERTICAL RISER PIPING ANCHOR AND GUIDES (TYPE ADA). 7. PROVIDE FLEXIBLE CONNECTIONS BETWEEN ALL FANS AND DUCTWORK (REFER TO DUCTWORK SECTION FOR SPECIFICATIONS. h. SUBMIT FOR APPROVAL A COMPLETE SCHEDULE OF ALL AIR INLETS AND OUTLETS TO BE USED ON PROJECT INCLUDING MANUFACTURERS MODELS, SIZES, PERFORMANCE, ACCESSORIES, ACOUSTIC INFORMATION, FINISHES, ETC., BEFORE RELEASE FOR FABRICATION. NOTE ANY DEVIATIONS FROM SPECIFICATIONS AND SCHEDULES SHALL BE INDICATED ON SUBMITTAL. architect 2. AIR INLET AND OUTLET DEVICES 2.05 TESTING AND BALANCING 2.03 ELECTRICAL WORK A. GENERAL A. GENERAL: 1. ELECTRICAL POWER WIRING SHALL BE PROVIDED BY THE ELECTRICAL CONTRACT; CONTROL WIRING SHALL BE BY THE HVAC CONTRACT. CONTROL WIRING SHALL BE DEFINED AS ANY 12V, 24V, OR 120V WIRING INSTALLED FOR PURPOSES OTHER THAN PROVIDING PRIMARY ELECTRICAL POWER TO EQUIPMENT. 2. DUCT MOUNTED SMOKE DETECTORS, WHERE REQUIRED, SHALL BE PROVIDED BY AND WIRED BY THE ELECTRICAL CONTRACTOR, AND MOUNTED BY THE HVAC CONTRACTOR. 3. ALL ELECTRICAL CONTROL WIRING SHALL COMPLY WITH LOCAL ELECTRICAL CODE, ALL AUTHORITIES HAVING JURISDICTION AND THE PROJECT ELECTRICAL SPECIFICATIONS. 4. MECHANICAL CONTRACTOR TO OBTAIN QUANTITY OF CONTROLLERS REQUIRED AND COORDINATE WITH ELECTRICAL CONTRACTOR FOR ALL OPERATING REQUIREMENTS, INTERLOCKS AND CONNECTIONS FOR STARTERS. 5. THE MECHANICAL CONTRACTOR SHALL PREPARE AND SUBMIT FOR APPROVAL POINT TO POINT, COMPLETELY COORDINATED WIRING DIAGRAMS AND INDICATE ALL SOURCE POWER REQUIREMENTS AND ALL FIELD WIRING TO BE PERFORMED BY THE ELECTRICAL CONTRACTOR. 6. WHERE EXISTING STARTERS ARE TO BE REUSED, THIS CONTRACTOR SHALL MAINTAIN ALL EXISTING CONTROL CONNECTIONS. WHERE NEW STARTERS ARE TO BE PROVIDED TO REPLACE EXISTING, THIS CONTRACTOR SHALL SURVEY THE EXISTING CONTROL CONNECTIONS AND PREPARE AN EXISTING CONTROL WIRING DIAGRAM PRIOR TO DEMOLITION FOR SUBMITTAL TO THE ENGINEER. THE NEW STARTERS SHALL BE PROVIDED WITH THE NECESSARY CONTACTS AND RELAYS REQUIRED TO RECONNECT THE EXISTING CONTROLS. PROVIDE ALL REQUIRED CONTACTS FOR UNIT START/STOP AND FIRE ALARM. B. MOTORS: 1. MOTORS SHALL HAVE THE ELECTRICAL CHARACTERISTICS AS LISTED ON THE DRAWINGS. COORDINATE ALL REQUIREMENTS WITH ELECTRICAL CONTRACTOR. ALL MOTORS SHALL COMPLY WITH NEMA MG-1 STANDARD AND SHALL BE OF THE HIGH EFFICIENCY TYPE AND MEET THE 1992 EPA ENERGY EFFICIENCY ACT AND UTILITY COMPANY REBATE REQUIREMENTS. 2. IF CONTRACTOR ELECTS TO SUBSTITUTE OR INCREASE MOTOR HORSEPOWER OVER THAT SPECIFIED, THE COST OF MOTOR AND ELECTRICAL CHANGES SHALL BE BORNE BY THIS CONTRACTOR. 1. TESTING AND BALANCING WORK SHALL BE PERFORMED BY AN INDEPENDENT COMPANY (NOT ASSOCIATED WITH THE HVAC CONTRACTOR), AABC CERTIFIED OR AS APPROVED BY THE ENGINEER BEFORE COMMENCEMENT OF WORK. APPROVED COMPANIES INCLUDE MERENDINO ASSOCIATES, R.H. MCDERMOTT, INTERNATIONAL TESTING AND BALANCING OR AS APPROVED BY THE ENGINEER AND BUILDING MANAGEMENT. b. ALL SUPPLY RETURN AND EXHAUST AIR INLETS AND OUTLETS SHALL BE PROVIDED WITH AN OPPOSED BLADE DAMPER AND GRID (ADJUSTABLE THROUGH THE FACE) FOR TRIM BALANCING. 2. AFTER ALL PROJECT HVAC WORK IS COMPLETE, TESTED AND IN FULL WORKING ORDER, THE AGENCY SHALL PERFORM THE BALANCING AND TESTING OF THE PROJECT HEATING, VENTILATING AND AIR CONDITIONING SYSTEMS. d. ONLY 4 WAY DIFFUSERS SHALL BE USED, PROVIDE BLANK OFF SHEET METAL BAFFLE FOR ALL 1WAY, 2-WAY AND 3-WAY DIFFUSERS. 3. UPON THE COMPLETION OF THE AIR CONDITIONING SYSTEM, THE BALANCING AGENCY SHALL PERFORM TESTING AND BALANCING AND COMPILE ALL TEST DATA IN A CERTIFIED REPORT AND SUBMIT FOUR (4) COPIES FOR REVIEW AND APPROVAL TO THE ENGINEER. 4. THE REPORT SHALL INCLUDE DESIGN AND ACTUAL READINGS FOR ALL EQUIPMENT AND LOCATION PLAN INDICATING WHERE ALL WORK HAS BEEN PERFORMED, AND METHODS OF BALANCING AND DETAILS OF INSTRUMENTS USED. 5. IF DISCREPANCIES EXIST IN THE REPORT THAT REQUIRE FIELD VERIFICATION, THE TESTING AND BALANCING COMPANY IN THE PRESENCE OF THE ENGINEER SHALL VISIT THE JOBSITE FOR FIELD VERIFICATION OF THE REPORT. 3. COMBINATION MAGNETIC STARTERS FOR ALL MOTORS SHALL HAVE THERMAL OVERLOAD, PILOT LIGHT, LOW VOLTAGE PROTECTION IN ALL THREE PHASES. INCLUDE A CONTROL TRANSFORMER FOR EACH MAGNETIC STARTER TO PROVIDE 120 VOLT CONTROL POWER WITH 3 SETS OF SPARE NORMALLY CLOSED OR NORMALLY OPEN CONTACTS. e. ALL LINEAR DIFFUSERS SHALL BE PROVIDED WITH CABLE OPERATED OPPOSED BLADE DAMPER ADJUSTABLE THROUGH THE FACE OF THE DIFFUSER. DAMPERS AND PLENUM TAPS SHALL BE SPACED AT A MAXIMUM OF 4 FEET ON CENTER. PROVIDE DIFFUSERS WITH ADJUSTABLE AIR PATTERN CONTROL VANES. F. KITCHEN EXHAUST FAN: (KX-1) 1. FURNISH AND INSTALL BACKWARD INCLINED CENTRIFUGAL UTILITY FAN TYPE-SWB, AS SCHEDULED ON THE DRAWINGS AND DESCRIBED HEREIN. THE EXHAUST FAN SHALL BE MANUFACTURER BY "GREENHECK" OR APPROVED EQUAL. 6. AFTER SUBMISSION OF THE FIELD VERIFIED BALANCING REPORT, THE AIR BALANCING COMPANY SHALL RETURN TO THE JOB SITE TO PERFORM TWO (2) OCCUPANT COMFORT BALANCES AS DIRECTED BY THE OWNER OR ENGINEER. 7. THE FINAL REPORT AFTER THE COMFORT BALANCE IS TO BE INCLUDED IN PROJECT OPERATING AND MAINTENANCE MANUAL. 3. THIS CONTROL CONTRACTOR SHALL FURNISH A VARIABLE SPEED SWITCH TO BE LOCATED AT THE FAN IN THE HUNG CEILING FOR PRESET SPEED CONTROL. 8. THE TESTING AND BALANCING AGENCY SHALL INCLUDE AS PART OF THEIR WORK AN EXTENDED WARRANTY OF 90 DAYS AFTER COMPLETION OF TEST AND BALANCE WORK. THE ENGINEER AT HIS DISCRETION DURING THE WARRANTY PERIOD MAY REQUEST A RECHECK, OR RESETTING OF ANY EQUIPMENT. THE MECHANICAL CONTRACTOR AND THE BALANCING CONTRACTOR SHALL PROVIDE THE NECESSARY TECHNICIANS TO FACILITATE THIS WORK. 4. BACKWARD INCLINED CENTRIFUGAL UTILITY FAN TYPE-SWB EXHAUST FANS SHALL BE PROVIDED WITH CONTROL INTERLOCKS TO THE KITCHEN HOOD EXHAUST SYSTEM. A Division of The Wall Consulting Group, Inc. All Rights Reserved. 2007- 2010 231 West 29th Street - Suite 606, New York, NY 10001 Tel: 212 . 967 . TWIG / Fax: 212 . 967 . 8945 info@twigcon.com www.twigcon.com 2.07 AUTOMATIC TEMPERATURE CONTROLS A. GENERAL: 9. BALANCING AGENCY SHALL PERMANENTLY MARK ALL ADJUSTMENT DEVICES (VALVES, DAMPERS, ETC.,) TO ENABLE THE SETTING TO BE RESTORED. B. AIR BALANCING 2. FURNISH MANUALLY OPERATED MOTOR STARTERS OF THE PROPER SIZE FOR ALL MOTORS LESS THAN 1/2 HP WHICH ARE NOT AUTOMATICALLY CONTROLLED. STARTERS FOR MOTORS 175 WATTS OR LESS SHALL CONSIST OF A SNAP SWITCH WITH THERMAL OVERLOAD PROTECTION WHERE SUCH PROTECTION IS NOT AN INTEGRAL PART OF THE MOTOR. c. SUPPLY REGISTERS SHALL HAVE TWO SETS OF DIRECTIONAL CONTROL BLADES. 2. PROVIDED BACKWARD INCLINED CENTRIFUGAL UTILITY FAN TYPE-SWB SHALL BE OF THE CENTRIFUGAL TYPE. THE FAN(S) SHALL BE PROVIDED WITH ACOUSTICALLY LINED CABINET, DUCTED INLET AND DISCHARGE CONFIGURATION, STARTER AND DISCONNECT AT THE UNIT. THE UNIT SHALL BE AMCA RATED FOR SOUND AND AIR PERFORMANCE UL OR C.S.A. LISTED AND OF THE CAPACITIES AND QUANTITIES INDICATED ON THE DRAWINGS. C. STARTERS: 1. EACH MOTOR EXCEPT AS NOTED, SHALL BE PROVIDED WITH A COMBINATION FUSED DISCONNECT AND ACROSS-THE-LINE MAGNETIC STARTER WITH PUSH BUTTON STATIONS MOUNTED ON COVER. COORDINATE REQUIREMENTS WITH ELECTRICAL CONTRACTOR. FOR AUTOMATICALLY OR REMOTELY CONTROLLED MOTORS, FURNISH HAND OFF AUTO (HOA) SELECTOR SWITCHES IN PLACE OF THE PUSH BUTTONS. a. PROVIDE DIFFUSERS, GRILLES AND REGISTERS FOR SUPPLY, RETURN AND EXHAUST INLETS AND OUTLETS, OF THE SIZE, TYPE, AND DESIGN INDICATED ON DRAWINGS. 1. HVAC CONTRACTOR SHALL ENSURE THAT A FIRST SET OF AIR FILTERS ARE IN PLACE, WHENEVER FANS ARE RUNNING AND REPLACED WITH A NEW CLEAN SET OF FILTERS BEFORE TESTING IS COMMENCED. 2. TEST, ADJUST, REPLACE SHEAVES, AND BALANCE ALL EQUIPMENT AND AIR DISTRIBUTION SYSTEMS TO PROVIDE AIR QUANTITIES INDICATED ON PLANS WITHIN PLUS OR MINUS 5 PERCENT. 3. TEST REPORT SHALL INCLUDE, BUT NOT BE LIMITED TO THE FOLLOWING: a. FLOW, LEAKAGE CLASS, TEMPERATURE, STATIC PRESSURE OF AIR AT ALL TRUNK DUCTS SERVING AREAS OF WORK. 1. FURNISH AND INSTALL AS HEREIN SPECIFIED, A COMPLETE AUTOMATIC TEMPERATURE CONTROL SYSTEM OF THE ELECTRIC AS REQUIRED MANUFACTURED BY HONEYWELL OR APPROVED EQUAL BY THE ENGINEER. MANUFACTURER SHALL BE APPROVED BY ENGINEER BEFORE COMMENCING WORK. 2. ALL TEMPERATURE CONTROL SYSTEMS AND COMPONENTS UNDER THIS SUBCONTRACT ARE TO BE FULLY MODULATING TYPE, EXCEPT WHERE NOTED OTHERWISE. THE SYSTEM SHALL BE COMPLETE IN ALL RESPECTS INCLUDING ALL ASSOCIATED CONTROL EQUIPMENT, THERMOSTATS, CONTROL VALVES, VALVE ACTUATORS, DAMPER OPERATORS, RELAYS, PILOT POSITIONERS, CONTROL WIRING, CONTROL AIR PIPING, SWITCHES, INTERLOCK WIRING, ELECTRICAL OR PNEUMATIC CONTROL COMPONENTS AND ASSOCIATED PIPING OR WIRING, APPURTENANCES, ETC., TO PROVIDE THE FUNCTIONS DESCRIBED IN THESE SPECIFICATIONS AND PLANS, REGARDLESS OF WHETHER OR NOT SAID DEVICE RELAY, ETC., IS SPECIFICALLY MENTIONED HEREAFTER. 3. THE SYSTEM SHALL BE SUPERVISED AND CHECKED OUT COMPLETELY IN ALL RESPECTS BY COMPETENT MECHANICS, REGULARLY EMPLOYED BY THE MANUFACTURER. b. TEMPERATURE OF AIR LEAVING OUTLETS AT TWO (2) TYPICAL AIR OUTLETS. 4. CONNECTION TO EXISTING SYSTEM c. QUANTITY OF AIR AT EACH AIR INLET AND OUTLET AFTER BALANCING. 4. ALL STARTERS SHALL BE ASSEMBLED AND INTERNALLY WIRED WITH ALL DEVICES IN CONFORMANCE WITH NEMA STANDARDS. 5. STARTERS FOR MOTORS 75 HP AND ABOVE SHALL BE SOLID STATE ELECTRONIC SOFT START TYPE STARTERS. 6. DISCONNECT SWITCHES ARE PROVIDED BY THE ELECTRICAL CONTRACTOR IF NOT INTEGRAL WITH EQUIPMENT. d. PROVIDE FOR ALL FANS, FAN MOTOR HP, AMPS, VOLTS, FAN RPM, CFM, INLET AND DISCHARGE STATIC PRESSURE, SHEAVE POSITION. e. PROVIDE FOR ALL AIR CONDITIONING UNITS, SUPPLY CFM, OUTSIDE AIR CFM, RETURN AIR CFM, MIXED AIR CFM. PROVIDE OUTSIDE AIR, MIXED AIR AND SUPPLY AIR TEMPERATURES (DRY BULB COOLING AND HEATING, WET-BULB-COOLING.) INDICATE UNIT OPERATING MODE DURING TEST. f. CALIBRATE ALL NEW AND EXISTING TO BE REUSED TERMINAL BOXES (VAV, FAN POWERED OR DUAL DUCT) AS REQUIRED TO MEET SPECIFIED MINIMUM/MAXIMUM CFM. D. ENCLOSURES: 1. PROVIDE ENCLOSURES FOR STARTERS SUITABLE FOR OPERATING ENVIRONMENT. ENCLOSURE'S SHALL BE NEMA 1 VENTILATED SHEETMETAL FOR INDOOR APPLICATION, NEMA 3R WITH ADDITIONAL GASKETING WEATHERPROOF RAINTIGHT ENCLOSURE FOR EXPOSED OUTDOOR SERVICE OR INDOOR SERVICE EXPOSED TO MOISTURE. PROVIDE DISCONNECT SWITCH ON ENCLOSURE AS REQUIRED FOR SERVICE. 2.04 VIBRATION ISOLATION PRODUCTS A. FURNISH AND INSTALL ALL NECESSARY VIBRATION ISOLATORS, VIBRATION HANGERS, MOUNTING PADS, RAILS, ETC., TO ISOLATE VIBRATION AND SOUND FROM BEING TRANSMITTED TO THE BUILDING CONSTRUCTION. ALL VIBRATION ISOLATION PRODUCTS SHALL BE SPECIFICALLY DESIGNED FOR THEIR INTENDED USE. B. MANUFACTURER OF VIBRATION ISOLATION EQUIPMENT SHALL HAVE THE FOLLOWING RESPONSIBILITIES: 1. DETERMINE VIBRATION ISOLATOR SIZES AND LOCATIONS. g. LISTING OF DESIGN AND ACTUAL READINGS AS WELL AS ALL MANUFACTURER'S DATA FOR EQUIPMENT. 2.06 EQUIPMENT A. PROVIDE ALL EQUIPMENT AND ACCESSORIES OF THE SIZES AND CAPACITIES AS SCHEDULED AND AS INDICATED ON THE DRAWINGS. B. INSTALL EQUIPMENT IN ACCORDANCE WITH APPROVED SHOP DRAWINGS, MANUFACTURERS RECOMMENDATIONS, INSTRUCTIONS, AND ALL AUTHORITIES HAVING JURISDICTION. C. PROVIDE EQUIPMENT SUPPORTS AND/OR MOUNTINGS AS INDICATED ON THE DRAWING, IN VIBRATION SPECIFICATION AND AS FOLLOWS: 2. PROVIDE SUITABLE PIPING AND EQUIPMENT VIBRATION ISOLATION SYSTEMS. 1. FLOOR MOUNTED EQUIPMENT - PROVIDE DIMENSIONS FOR A 4" CONCRETE HOUSEKEEPING PAD WITH ALL REQUIRED WATERPROOFING TO THE CONSTRUCTION MANAGER. 3. GUARANTEE SPECIFIED ISOLATION SYSTEM ATTENUATION AND DEFLECTION. 4. PROVIDE INSTALLATION INSTRUCTIONS, DRAWINGS AND FIELD SUPERVISION TO ASSURE PROPER INSTALLATION AND PERFORMANCE. STARTERS SHALL BE SELECTED TO SUIT MOTOR RUNNING AND STARTING CHARACTERISTICS. 2. EQUIPMENT ON FLOOR STANDS - PROVIDE FLOOR STAND OF STRUCTURAL STEEL OR STEEL PIPES AND FITTINGS AND BOLT TO FLOOR. C. ISOLATION SYSTEMS SHALL BE MANUFACTURED BY MASON INDUSTRIES OR APPROVED EQUAL BY THE ENGINEER. 4. CEILING MOUNTED EQUIPMENT - PROVIDE SUPPORTS WITH APPROVED SUITABLE ANCHORS SUSPENDED DIRECTLY FORM BUILDING STEEL STRUCTURE. D. MOUNTING TYPES: 1. STATIC DEFLECTION OF ISOLATORS SHALL BE A MINIMUM OF 90% EFFICIENT. PROVIDE CORROSION PROTECTION FOR EQUIPMENT MOUNTED OUTDOORS. 2. FLOOR MOUNTING OF CENTRIFUGAL FANS (3 HP AND LESS) SPRING ISOLATORS (TYPE SLF). 3. FLOOR AND ROOF MOUNTING OF FACTORY ASSEMBLED AIR HANDLING UNITS, AIR CONDITIONING UNITS, HEAT EXCHANGERS AND CONDENSING UNITS, - SPRING ISOLATORS (ROOF MOUNTED EQUIPMENT TYPE SLR), OR (INDOOR EQUIPMENT TYPE SLF). 4. FLOOR MOUNTING OF CENTRIFUGAL FANS (5 HP AND ABOVE) - SPRING ISOLATOR WITH INERTIA BASE (TYPE KSL). MOTOR HP UP TO 30 HP 3. ROOF MOUNTED EQUIPMENT - PROVIDE PREFABRICATED ISOLATED ROOF CURB WITH INTEGRAL VIBRATION ISOLATORS. REQUIRED MINIMUM CONCRETE INERTIA BASE THICKNESS 6" MINIMUM ISOLATION DEFLECTION 3/4" 5. PROVIDE SUPPLEMENTAL STEEL AS REQUIRED TO ADEQUATELY SUPPORT THE EQUIPMENT LOAD. D. EQUIPMENT SHALL BE INSTALLED WITH VIBRATION ISOLATION, REFER TO VIBRATION ISOLATION SECTION. E. DIFFUSERS, GRILLES AND REGISTERS: 1. GENERAL a. GRILLES, REGISTERS AND DIFFUSERS SHALL BE TESTED IN ACCORDANCE WITH ASHRAE STANDARD 70-1991 OR LATEST EDITION. THE MANUFACTURER SHALL PROVIDE PUBLISHED PERFORMANCE DATA FOR ALL AIR INLETS AND OUTLETS TO BE USED ON PROJECT AS PART OF SUBMISSION. b. MECHANICAL CONTRACTOR TO COORDINATE THE LOCATION OF DIFFUSERS, GRILLES AND REGISTERS WITH OTHER TRADES AND WITH CEILING AND WALL CONSTRUCTION. THE MECHANICAL CONTRACTOR TO VERIFY THAT ALL DIFFUSERS, GRILLES AND REGISTERS ARE COMPATIBLE WITH CEILING CONSTRUCTION TO WHICH THEY ARE TO BE INSTALLED. c. COORDINATE ALL WORK WITH GENERAL CONTRACTOR AND REFER TO ARCHITECTURAL DRAWINGS FOR EXACT LOCATION, LENGTHS AND FOR FRAMING AND MITERING ARRANGEMENTS THAT MAY DIFFER FROM THOSE SHOWN ON HVAC DRAWINGS. PROVIDE ALL REQUIRED GENERAL CONSTRUCTION, FRAMING, BLOCKING, PLASTERING AND SUPPORTS TO MATCH CEILING, SOFFIT OR WALL CONSTRUCTION AS PART OF PROJECT. a. IF NEW WORK IS TO CONNECT TO AN EXISTING SYSTEM, THE PROPOSED NEW SYSTEM TO BE INSTALLED SHALL BE FULLY COMPATIBLE WITH THE EXISTING SYSTEM. THE MANUFACTURER OF THE PROPOSED NEW SYSTEM SHALL PROVIDE ALL REQUIRED INTERFACES OR "GATEWAYS" TO ENSURE THAT THEIR SYSTEM IS FULLY COMPATIBLE. 5. THE CONTROL SYSTEMS SHALL BE IN ACCORDANCE WITH THE FOLLOWING DESCRIPTION OF SYSTEM OPERATIONS AND/OR DETAIL INFORMATION SHOWN ON THE PLANS AND AS DESCRIBED HEREIN. 6. THE MANUFACTURER OF THE AUTOMATIC CONTROL EQUIPMENT SHALL SUBMIT THE FOLLOWING FOR APPROVAL: A SCHEMATIC DIAGRAM OF EACH CONTROL SYSTEM WHICH SHALL INDICATE THE PROPER SEQUENCE OF OPERATION AND RANGE OF THE CONTROLS FOR ALL CYCLES. A COMPLETE DESCRIPTION OF THE AUTOMATIC OPERATION OF EACH SYSTEM. THE DESCRIPTION SHOULD INCLUDE THE DUTY OF EACH THERMOSTAT, VALVE, SWITCH, ETC., INCORPORATED IN THE CONTROL SYSTEM WITH A SCHEDULE AND ILLUSTRATION OF ALL CONTROL INSTRUMENTS AND EQUIPMENT INCLUDING CONTROL PANELS AND DEVICES FOR EACH SYSTEM. B. ELECTRIC WIRING: 1. ALL ELECTRICAL WORK (EXCEPT FOR MOTOR FEEDERS, WIRING BETWEEN MOTORS, MOTOR CONTROLLERS, FEEDER PANELS, FUSES, CIRCUIT BREAKERS AND BUS BARS) REQUIRED FOR THE AUTOMATIC TEMPERATURE CONTROL SYSTEM SHALL BE PROVIDED BY THIS CONTRACTOR. WORK SHALL INCLUDE BUT NOT BE LIMITED TO TIME SWITCHES, DAMPER MOTORS, DAMPER SWITCHES, ELECTRIC THERMOSTATS, ELECTRIC RELAYS, E/P SWITCHES, INTERLOCKING WIRING, WIRE, CONDUIT, ETC. SUBMISSIONS DATE rev no issue 02.14.11 1 FILING & PRICING 2. ALL 115 VOLT POWER REQUIRED FOR CONTROL PURPOSES SHALL BE PROVIDED BY THE CONTROL CONTRACTOR FROM A SOURCE ESTABLISHED BY THE ELECTRICAL CONTRACTOR. 3. THE CONTROL MANUFACTURER SHALL INCLUDE WIRING DIAGRAMS IN HIS SHOP DRAWINGS SUBMITTALS FULLY COORDINATED WITH THE ELECTRICAL CONTRACTORS WORK. IT SHALL BE THE AUTOMATIC TEMPERATURE CONTROL CONTRACTOR'S RESPONSIBILITY TO PROVIDE ALL WIRING AND CONDUIT AS REQUIRED TO ACHIEVE THE FUNCTION CALLED FOR IN THESE SPECIFICATIONS, CONFORMING WITH LOCAL CODES FOR MATERIAL AND INSTALLATION. THE ELECTRICAL SPECIFICATION FOR THE PROJECT ELECTRICAL WORK IS TO BE FOLLOWED. 4. FURNISH A CERTIFICATE INDICATING METHOD OF WIRING COMPLIANCE WITH LOCAL CODES AS PART OF FIRST SHOP DRAWING SUBMITTAL. C. ROOM THERMOSTAT AND SWITCH LOCATIONS: 1. ALL ROOM THERMOSTATS AND SWITCH LOCATIONS (WHETHER SHOWN ON PLANS OR NOT) SHALL BE SELECTED AND SUBMITTED BY THE TEMPERATURE CONTROL MANUFACTURER FOR APPROVAL BY THE ARCHITECT AND ENGINEER PRIOR TO ACTUAL INSTALLATION. project 375 Beach 92nd Street Queens, NY 11693 D. CONTROL VALVES: 1. ALL AUTOMATIC CONTROL VALVES SHALL BE OF THE ELECTRONIC TYPE, FULLY PROPORTIONING, UNLESS OTHERWISE SPECIFIED, QUIET IN OPERATION, AND SHALL BE ARRANGED TO FAIL SAFE, IN EITHER A NORMALLY OPEN OR NORMALLY CLOSED POSITION, IN THE EVENT OF POWER FAILURE. THE OPEN OR CLOSED POSITION SHALL BE AS SPECIFIED OR AS REQUIRED TO SUIT JOB CONDITIONS. PROVISIONS SHALL BE MADE FOR VALVES OPERATING IN SEQUENCE, WITH OTHER VALVES OR DAMPER OPERATORS TO HAVE ADJUSTABLE OPERATING RANGES AND STARTING POINTS TO PROVIDE FLEXIBILITY OF ADJUSTMENT IN SEQUENCING AND THROTTLING RANGE. MODULATING VALVES SHALL BE PROVIDED WITH PILOT POSITIONERS. VALVES SHALL BE SIZED BY THE TEMPERATURE CONTROL MANUFACTURER AND GUARANTEED TO MEET THE HEATING OR COOLING REQUIREMENTS AS SPECIFIED. ALL VALVE BODIES SHALL HAVE THE SAME PRESSURE CHARACTERISTICS AS THE PIPE IN WHICH IT IS INSTALLED. 2. VALVES 2 INCHES AND SMALLER UNLESS OTHERWISE SPECIFIED SHALL HAVE BRONZE BODIES WITH SCREWED CONNECTIONS. VALVES SHALL BE FISHER TYPE ED, WARREN TYPE 20/70, K&M SERIES GCG, OR AS APPROVED. dwg title GROUND FLOOR MECHANICAL SPECIFICATIONS SHEET II seal & signature issue date 02/11/2011 project no. t10-12-0230 drawn by cadd checked by twig scale AS NOTED dwg. no. NYCECC NOTES: TO THE BEST OF MY KNOWLEDGE, BELIEF AND PROFESSIONAL JUDGMENT, THESE PLANS AND SPECIFICATIONS ARE IN COMPLIANCE WITH THE NEW YORK CITY ENERGY CONSERVATION CODE. THESE PLANS ARE APPROVED ONLY FOR THE WORK ON THE APPLICATION SPECIFICATION SHEET. ALL OTHER MATTERS SHOWN ARE NOT TO BE RELIED UPON OR TO BE CONSIDERED AS EITHER BEING APPROVED OR IN ACCORDANCE WITH APPLICABLE CODES. cad file sheet 4 of 8 375 Beach 92nd Street M-202.00.dwg NYC dob# project 375 Beach 92nd Street Queens, NY 11693 MECHANICAL SPECIFICATIONS - III STEEL BODIES WITH FLANGED CONNECTIONS IN ACCORDANCE WITH THE PIPING SPECIFICATIONS. VALVES SHALL BE FISHER STYLE ED, WARREN TYPE 20/70 OR 1800 SERIES GCG, K & M SERIES GCG OR AS APPROVED. 4. CONTROL VALVES 4" AND LARGER UNLESS OTHERWISE SPECIFIED SHALL BE FISHER V100, K & M CPORTBALL, WARREN 3800 SERIES, OR AS APPROVED. 5. ALL BUTTERFLY CONTROL VALVES, WHERE SHOWN ON THE DRAWINGS OR SPECIFIED SHALL CONFORM WITH THE PIPING SPECIFICATION. 6. AUTOMATIC CONTROL VALVES EXPOSED TO THE ELEMENTS SHALL HAVE ELECTRIC ACTUATORS WITH ALL REQUIRED ACCESSORIES. architect E. AUTOMATIC DAMPERS: 1. PROVIDE CONTROLS FOR ALL THE AUTOMATIC DAMPERS, AS SPECIFIED IN THE DUCTWORK SECTION, AND SHOWN ON THE DRAWINGS. 2. CONTROL MOTORS OR ACTUATORS SHALL BE OF THE ELECTRONIC OR PNEUMATIC TYPE, UNLESS OTHERWISE NOTED, OF APPROPRIATE SIZE AND QUANTITIES TO PROVIDE TWO-POSITION OR PROPORTIONING CONTROL ACTION AS SPECIFIED. PROPORTIONING TYPE SHALL BE EQUIPPED WITH PILOT TYPE POSITIONERS. PILOT POSITIONERS SHALL BE SELECTED FOR VARIED SPRING RANGES AND ADJUSTABLE WITHOUT DISMANTLING POSITIONER AND CONTROL MOTOR. 3. AUTOMATIC DAMPERS EXPOSED TO THE ELEMENTS SHALL HAVE ELECTRIC ACTUATORS WITH ALL REQUIRED ACCESSORIES. F. CONTROL PANELS: A Division of The Wall Consulting Group, Inc. All Rights Reserved. 2007- 2010 1. FURNISH AND INSTALL IN THE MECHANICAL ROOM, AS HEREIN SPECIFIED, CONTROL PANELS OF STEEL, WITH WELDED ANGLE IRON BRACKETS, FOR WALL OR FLOOR MOUNTING. 231 West 29th Street - Suite 606, New York, NY 10001 Tel: 212 . 967 . TWIG / Fax: 212 . 967 . 8945 2. THE BASIC BACKGROUND COLOR OF THE PANEL SHALL BE AS APPROVED BY THE ARCHITECT AND ENGINEER. info@twigcon.com 3. PANELS SHOULD BE FULLY ENCLOSED, WITH HINGED LOCKING FRONT DOOR FOR EACH PANEL. THE PANEL SHALL CONTAIN ALL CONTROLLERS, RELAYS, SWITCHES, ETC. PROVIDE ENGRAVED NAMEPLATES TO LABEL THE CONTROLLED EQUIPMENT AND FOR EACH PANEL MOUNTED CONTROL DEVICE. PLASTIC LAMINATED CONTROL SCHEMATIC DRAWINGS FOR THE SYSTEM SHALL BE HUNG AT EACH LOCAL CONTROL PANEL. 4. DETAILS OF EACH OF THESE PANELS SHALL BE SUBMITTED FOR APPROVAL PRIOR TO FABRICATION. LOCATIONS OF EACH PANEL ARE TO BE CONVENIENT FOR ADJUSTMENT AND SERVICE AND ALL SUCH LOCATIONS ARE TO BE APPROVED PRIOR TO INSTALLATION. www.twigcon.com PART 3 SEQUENCE OF OPERATIONS: 3.01 KITCHEN EXHAUST FAN (KX-1) THE KITCHEN EXHAUST SYSTEM SHALL RUN WHENEVER GAS IS FLOWING IN THE KITCHEN OR THE DISHWASHER IS OPERATING. THE EXHAUST SYSTEM SHALL CONTINUE TO OPERATE FOR 15 MINUTES AFTER THE DISHWASHER HAS COMPLETED ITS CYCLE AND THE GAS FLOW HAS CEASED. THE KITCHEN EXHAUST SHALL HAVE CONTINUOUS POWER TO ALLOW THE UNIT TO PERFORM SCHEDULE WASH DOWN DURING THE NIGHT WHEN THE UNIT IS NOT IN OPERATION. PROVIDE (2) TWO SETS OF POSITIVE CONTACTS FOR THE FOLLOWINGS (1) AS SPARE, AND (1) FOR TIE-IN TO THE ANSUL FIRE SUPPRESSION SYSTEM, GIVING THE ANSUL THE ABILITY TO START AND STOP THE KITCHEN EXHAUST UNIT. PART 4 EXECUTION 4.01 DEMOLITION, REMOVAL AND RELOCATION A. REMOVAL, TEMPORARY CONNECTIONS AND RELOCATION OF CERTAIN EXISTING WORK WILL BE NECESSARY FOR THE INSTALLATION OF THE NEW SYSTEMS. ALL EXISTING CONDITIONS ARE NOT TO BE COMPLETELY DETAILED ON THE DRAWINGS. THE CONTRACTOR SHALL SURVEY THE SITE AND MAKE ALL NECESSARY CHANGES REQUIRED BASED ON EXISTING CONDITIONS FOR PROPER INSTALLATION OF NEW WORK. B. DISCONNECT, REMOVE AND/OR RELOCATE EXISTING MATERIAL, EQUIPMENT, AND OTHER WORK AS NOTED OR REQUIRED FOR PROPER INSTALLATION OF NEW SYSTEM. C. EQUIPMENT REQUIRED TO BE TEMPORARILY DISCONNECTED AND RELOCATED SHALL BE CAREFULLY REMOVED, STORED, CLEANED, REINSTALLED, RECONNECTED AND MADE OPERATIONAL. D. ALL EXISTING WORK NOT INDICATED FOR DEMOLITION SHALL BE PROTECTED FROM DAMAGE. WHERE EXISTING WORK TO REMAIN IS DAMAGED OR DISTURBED, CONTRACTOR SHALL REPAIR OR REPLACE TO OWNER'S AND BUILDING MANAGER'S SATISFACTION AT NO COST TO THE OWNER OR BUILDING MANAGEMENT. E. GENERAL CONTRACTOR TO REMOVE ALL CEILING IN AREAS WHERE NEW DUCTWORK OR PIPING IS TO BE INSTALLED OR EXISTING IS ALTERED, AS PER ARCHITECT'S INSTRUCTIONS. F. ALL NECESSARY CUTTING AND PATCHING TO ACCOMMODATE THE NEW HVAC WORK SHALL BE PERFORMED BY THIS CONTRACTOR AND COORDINATED WITH BUILDING MANAGEMENT SO AS TO MINIMIZE DISRUPTION OF EXISTING TENANTS AND SERVICES. RESTORE ALL ITEMS TO MATCH EXISTING CONDITIONS. G. ALL EXISTING MATERIAL AND EQUIPMENT TO BE REMOVED UNDER THIS CONTRACT WILL REMAIN THE PROPERTY OF THE OWNER OR SHALL BE LEGALLY DISPOSED OF BY THIS CONTRACTOR AS DIRECTED BY THE ARCHITECT OR OWNER. REFRIGERATION CONTAINED IN EXISTING EQUIPMENT TO BE REMOVED SHALL BE RECLAIMED OR LEGALLY DISPOSED OF IN ACCORDANCE WITH EPA REQUIREMENTS AND ASHRAE. H. PROVIDE FOR LEGAL REMOVAL AND DISPOSAL OF ALL RUBBISH AND DEBRIS FROM THE BUILDING AND SITE. COORDINATE ALL DEMOLITION AND REMOVALS WITH BUILDING MANAGEMENT. 4.02 CONNECTIONS TO EXISTING WORK A. PLAN INSTALLATION OF NEW WORK AND CONNECTIONS TO EXISTING WORK TO INSURE MINIMUM INTERFERENCE WITH REGULAR OPERATION OF EXISTING FACILITIES. ALL SYSTEM SHUTDOWNS AFFECTING OTHER AREAS SHALL BE COORDINATED WITH BUILDING MANAGEMENT. INSTALL ISOLATION VALVES AT POINT OF CONNECTION TO THE EXISTING PIPING. INSTALL ISOLATION DAMPERS AT CONNECTION TO EXISTING DUCTWORK. PROVIDE TEMPORARY DUCTWORK AND PIPING CONNECTIONS AS REQUIRED TO MINIMIZE SHUTDOWN TIME. SUBMISSIONS DATE rev no issue 02.14.11 1 FILING & PRICING B. CONNECT NEW WORK TO EXISTING WORK IN NEAT AND APPROVED MANNER. RESTORE EXISTING WORK DISTURBED WHILE INSTALLING NEW WORK TO ACCEPTABLE CONDITION AS DETERMINED BY ARCHITECT AND BUILDING MANAGER. C. MAINTAIN CONTINUOUS OPERATION OF EXISTING FACILITATES. 4.03 CHASING, CHOPPING OR CORE DRILLING A. PRIOR TO ANY CHASING, CHOPPING, OR CORE DRILLING BEING PERFORMED, THIS CONTRACTOR SHALL FIELD INVESTIGATE EXISTING CONDITIONS AND COORDINATE WITH ALL APPROPRIATE TRADES AND BUILDING MANAGEMENT TO ENSURE THAT WORK WILL BE IN HARMONY WITH OTHER WORK AND NOT AFFECT ANY EXISTING BUILDING SYSTEMS. THIS WORK MUST BE APPROVED BY BUILDING MANAGEMENT PRIOR TO PROCEEDING. 4.04 SYSTEM COMMISSIONING A. PRIOR TO FULL OPERATION, A COMPLETE DEMONSTRATION AND TESTING OF THE SYSTEM OPERATING FUNCTIONS AND ALARMS SHALL BE PERFORMED BY THIS CONTRACTOR IN THE PRESENCE OF THE OWNER'S REPRESENTATIVE AND ENGINEER. THIS TESTING SHALL TAKE PLACE AFTER HAVING SATISFACTORILY MET THE REQUIREMENTS OF SHOP DRAWING ACCEPTANCE. COMMISSIONING OF THE SYSTEMS SHALL BE SCHEDULED BEFORE SPACE IS OCCUPIED LEAVING ENOUGH TIME TO CORRECT SYSTEM DEFICIENCY'S AND AFTER SHOP DRAWING ACCEPTANCE. UPON SUCCESSFUL COMPLETION OF SYSTEM OPERATION, THE CONTRACTOR SHALL SUBMIT A STATEMENT STATING THAT THE FULL OPERATION OF ALL SYSTEMS, FUNCTIONS AND ALARMS HAS BEEN DEMONSTRATED AND ARE OPERATIONAL AS WELL AS A LISTING OF ALL SYSTEMS, ALARMS AND FUNCTIONS THAT HAVE BEEN COMMISSIONED. ALL ITEMS SHALL BE SUBMITTED FOR REVIEW AND ACCEPTANCE TO THE OWNER, OWNER'S REPRESENTATIVE AND ENGINEER BEFORE FINAL ACCEPTANCE CAN TAKE PLACE. project 375 Beach 92nd Street Queens, NY 11693 dwg title GROUND FLOOR MECHANICAL SPECIFICATIONS SHEET III seal & signature issue date 02/11/2011 project no. t10-12-0230 drawn by cadd checked by twig scale AS NOTED dwg. no. NYCECC NOTES: TO THE BEST OF MY KNOWLEDGE, BELIEF AND PROFESSIONAL JUDGMENT, THESE PLANS AND SPECIFICATIONS ARE IN COMPLIANCE WITH THE NEW YORK CITY ENERGY CONSERVATION CODE. THESE PLANS ARE APPROVED ONLY FOR THE WORK ON THE APPLICATION SPECIFICATION SHEET. ALL OTHER MATTERS SHOWN ARE NOT TO BE RELIED UPON OR TO BE CONSIDERED AS EITHER BEING APPROVED OR IN ACCORDANCE WITH APPLICABLE CODES. cad file sheet 5 of 8 375 Beach 92nd Street M-203.00.dwg NYC dob# project 375 Beach 92nd Street Queens, NY 11693 MECHANICAL GENERAL NOTES 1. PROVIDE ALL MATERIALS AND EQUIPMENT AND PERFORM ALL LABOR REQUIRED TO INSTALL COMPLETE AN OPERABLE HVAC SYSTEMS AS INDICATED ON THE DRAWINGS, AS SPECIFIED AND AS REQUIRED BY CODE. 2. CERTAIN ITEMS SUCH AS RISES AND DROPS IN DUCTWORK, ACCESS DOORS, VOLUME DAMPERS, ETC. ARE INDICATED ON THE CONTRACT DOCUMENT DRAWINGS FOR CLARITY FOR A SPECIFIC LOCATION REQUIREMENT AND SHALL NOT BE INTERPRETED AS THE EXTENT OF THE REQUIREMENT FOR THESE ITEMS. architect 3. ALL DUCTWORK DIMENSIONS, SHOWN ON THE DRAWINGS, ARE INTERNAL CLEAR DIMENSIONS AND DUCT SIZES SHALL BE INCREASED TO COMPENSATE FOR DUCT USING THICKNESS. 4. PROVIDE ACCESS DOORS IN DUCTWORK TO PROVIDE ACCESS FOR ALL SMOKE DETECTORS, FIRE DAMPERS, SMOKE DAMPERS, VOLUME DAMPERS, HEATING COILS, AND OTHER ITEMS LOCATED IN THE DUCTWORK WHICH REQUIRE SERVICE AND/OR INSPECTION. 5. DUCT SMOKE DETECTORS SHALL BE FURNISHED AND WIRED BY THE ELECTRICAL CONTRACTOR. THE MECHANICAL CONTRACTOR SHALL BE RESPONSIBLE FOR MOUNTING THE SMOKE DETECTOR IN DUCTWORK AS SHOWN ON THE DRAWINGS AND IN ACCORDANCE WITH MANUFACTURER'S PRINTED INSTRUCTIONS. A Division of The Wall Consulting Group, Inc. All Rights Reserved. 2007- 2010 231 West 29th Street - Suite 606, New York, NY 10001 Tel: 212 . 967 . TWIG / Fax: 212 . 967 . 8945 info@twigcon.com www.twigcon.com 6. ALL DUCTWORK SHALL BE COORDINATED WITH ALL TRADES INVOLVED. OFFSETS IN DUCTS, INCLUDING DIVIDED DUCTS AND TRANSITIONS AROUND OBSTRUCTIONS, SHALL BE PROVIDED AT NO ADDITIONAL COST TO THE OWNER. 7. ALL KITCHEN EXHAUST DUCTWORK SHALL BE 10 GAUGE BLACK-IRON WITH WELDED JOINTS AND SEAMS AND INSULATED WITH A TWO-HOUR RATED INSULATION. 8. FINAL CONNECTIONS TO EXHAUST HOOD SHALL FIELD COORDINATED WITH APPROVED SHOP DRAWINGS. (TYP FOR ALL SUPPLY AND MAKEUP AIR CONNECTIONS. EXISTING TOILET EXHAUST TO REMAIN (TYP. FOR 4) EDH-1 6KW 8X6 KITCHEN EXHAUST DUCT (TYP. FOR 4) 20 X 8 (2000 CFM) RELOCATE EXISTING DUCTS AS REQUIRED TO ALLOW FOR KITCHEN EXHAUST INSTALLATION SUBMISSIONS 20 X 14 C.O. C.O. 16X16 UPTO KE-1 (2800 CFM) DATE rev no issue 02.14.11 1 FILING & PRICING C.O. 8X6 AT 6'-0" AFF HW BASE BOARD 5 EXISTING FURNACE 6 EXISTING FLUE 3 4 2 project 6X6 TOILET EXHAUST DUCT G 375 Beach 92nd Street Queens, NY 11693 GRAVITY DAMPER dwg title GROUND FLOOR MECHANICAL PLAN & NOTES TX-1 NEW FANTECH CEILING TOILET EXHAUST (150CFM) seal & signature issue date 02/11/2011 project no. t10-12-0230 drawn by cadd checked by twig scale AS NOTED dwg. no. GROUND FLOOR: MECHANICAL PLAN SCALE: 3/16" - 1'-0" NYCECC NOTES: TO THE BEST OF MY KNOWLEDGE, BELIEF AND PROFESSIONAL JUDGMENT, THESE PLANS AND SPECIFICATIONS ARE IN COMPLIANCE WITH THE NEW YORK CITY ENERGY CONSERVATION CODE. THESE PLANS ARE APPROVED ONLY FOR THE WORK ON THE APPLICATION SPECIFICATION SHEET. ALL OTHER MATTERS SHOWN ARE NOT TO BE RELIED UPON OR TO BE CONSIDERED AS EITHER BEING APPROVED OR IN ACCORDANCE WITH APPLICABLE CODES. cad file sheet 6 of 8 375 Beach 92nd Street M-301.00.dwg NYC dob# project 1 DUCT 2 TWO LAYERS FIREMASTER DUCT WRAP 3 4-1/4" FIREMASTER DUCT WRAP 4 1/4" 3M FIRE BARRIER 2000+ SILICONE 5 CONCRETE SLAB 375 Beach 92nd Street Queens, NY 11693 UPBLAST ROOF-MOUNTED EXHAUST FAN WITH BIRD SCREEN 2 40" MINIMUM 4 HINGED SUB-BASE 16 GAUGE WELDED BLACK STEEL EXHAUST DUCT ANCHOR FAN SECURELY TO VENTILATED PEDESTAL 5 3" MINIMUM AIR SPACE BETWEEN SIDES OF DUCT AND CURB. 3 PREFABRICATED ROOF CURB (18"HIGH) CANT STRIP AS REQUIRED UPBLAST ROOF EXHAUST FAN WITH RIGID INSULATION VENTILATED CURB. SEE DETAIL. architect 1 A A SEE SCHEDULES FOR SIZE OF EXHAUST DUCT 10'-0" MINIMUM FROM SHEETROCK ENCLOSURE SEE ARCHITECTURAL DRAWINGS AND KITCHEN EXHAUST HOOD DETAILS ADJACENT BUILDING, PROPERTY LINE, AIR INTAKE OR PARAPET. ROOF LINE FIREMASTER DUCT FLOOR/WALL THROUGH PENETRATION SYSTEM (FIREMASTER ALTERNATE TO CALCIUM-SILICATE INSULATION) 1. 2. 1/2" ROD WITH THREADED ENDS FOR SEISMIC BRACING. BOLT TO ROOF STRUCTURE AND TO EXHAUST HOOD. (4 PER HOOD, 1 AT EACH FIRE SPRINKLER HEAD IN EXHAUST DUCT BELOW ROOF DECK, BY FIRE SPRINKLER CONTRACTOR KITCHEN ROOF EXHAUST FAN DETAIL NOT TO SCALE A Division of The Wall Consulting Group, Inc. All Rights Reserved. 2007- 2010 231 West 29th Street - Suite 606, New York, NY 10001 Tel: 212 . 967 . TWIG / Fax: 212 . 967 . 8945 NOT TO SCALE info@twigcon.com www.twigcon.com AIR SPACE. (3" MIN., 12" MAX.) 6 7 1 DOOR HOLE 2 ACCESS FRAME WELDED TO DUCT 3 1/4" DIAMETER ALL THREAD RODS 4 ACCESS COVER - 16 GAUGE 1 HOOD 5 INSULATION PINS - WELDED 2 1st LAYER FIREMASTER DUCT WRAP 6 FIREMASTER DUCT WRAP 3 2nd LAYER FIREMASTER DUCT WRAP 7 FIREMASTER DUCT WRAP 1" OVERLAP 4 1st LAYER TRANSITION PATTERN FIREMASTER DUCT WRAP 8 FIREMASTER DUCT WRAP 1" OVERLAP 5 2nd LAYER TRANSITION PATTERN FIREMASTER DUCT WRAP 9 SPEED CLIPS 10 ALUMINUM TAPE AT EDGES 7 BANDING 11 SPOOL PIECES FOR THREADED RODS 8 ANCHOR FASTENER SYSTEM 12 1/4" DIAMETER WING NUTS 9 BAR STOCK 2"-3" WIDE, 1/8" THICK KITCHEN EXHAUST HOOD SHALL BE I.C.B.O. AND 6 12"x12" MINIMUM ACCESS PANEL BOTH SIDES OF DUCT. (TYP.) AUTOMATIC WET CHEMICAL FIRE SUPPRESSION SYSTEM SHALL BE INSTALLED IN ACCORDANCE WITH NFPA 96. GYPSUM BOARD 2 HR MINIMUM 3" MINIMUM OVERLAP 3. PROVIDE ACCESS OPENING FIRE RATED ENCLOSURE OPPOSITE DUCT ACCESS SEE ARCHITECTURAL DOORS, IN RATED ENCLOSURE. DRAWINGS. ACCESS DOORS TO MATCH ENCLOSURE IN FIRE PROTECTIVE RATING. 16 GAUGE WELDED BLACK STEEL GREASE DUCT 8 9 FIRE SPRINKLER HEAD IN EXHAUST DUCT ABOVE COLLAR, BY FIRE SPRINKLER CONTRACTOR RECTANGULAR DUCT PATTERN ROUND DUCT PATTERN 2 FLASH SOLID (16 GAUGE MIN.) 3 4 EXHAUST HOOD SEE SCHEDULES FOR DIMENSIONS 5 CEILING LINE CHANNEL SEISMIC BRACING BOLT TO METAL STUDS AND TO EXHAUST HOODS. FULL LENGTH 10 3" AIR SPACE. ALL SIDES TWO REQUIRED FOR EACH SIDE 11 STAINLESS STEEL ENCLOSURE TWO REQUIRED FOR EACH SIDE 12 STAINLESS STEEL PANEL. ALL PANEL. ALL SIDES. SIDES. RUN TO TOP OF TILE 6" MINIMUM OVERHANG ON ALL OPEN SIDES OF COOKING SURFACE 6'-6" TO FINISHED FLOOR. 4'-0" MAX. COOKING SURFACE , 2'-0" MIN. TO COOKING SURFACE. GREASE DUCT ACCESS DOOR ENCLOSURE INSTALLATION 3. (FIREMASTER ALTERNATE TO CALCIUM-SILICATE INSULATION) TERMINATION OF DUCT WRAP AT HOOD LOCATION 4. NOT TO SCALE INSTALLATION DETAIL (FIREMASTER ALTERNATE TO CALCIUM-SILICATE INSULATION) NOT TO SCALE SUBMISSIONS HANGER SIZES FOR RECTANGULAR DUCT MAX. SIDE HANGER 30" 1" X 18" GAGE STRAP 36" 1/4" ROUND ROD HORIZONTAL SUPPORT ANGLE NONE REQUIRED 1 1/2" X 1 1/2" X 1/8" MAXIMUM SPACING 10'-0" 8'-0" 48" 1/4" ROUND ROD 2" X 2" X 1/8" 8'-0" 60" 5/16" ROUND ROD 2" X 2" X 1/8" 8'-0" 3/8" ROUND ROD 2" X 2" X 1/8" 8'-0" 84" NO POP RIVETS ALLOWED 1 TWO LAYER FIREMASTER DUCT WRAP 2 ONE LAYER FIREMASTER DUCT WRAP 3 MECHANICAL FASTENERS & WASHERS 4 DUCT 5 RATED FLOOR SELF TAPPING CADMIUM PLATED HEX HEAD SHEET METAL SCREW STRAPS TO BE TIGHT AGAINST DUCT. DATE rev no issue 02.14.11 1 FILING & PRICING 4 project 2 375 Beach 92nd Street Queens, NY 11693 2 HANGER STRAPS TOP CHORD OF TRUSS dwg title 3 GROUND FLOOR MECHANICAL DETAILS 3 DUCT SUPPORT ANGLE BRACKET seal & signature 1" 5. DUCT STRAP HANGER DETAIL NOT TO SCALE 6. TYPICAL VERTICAL DUCT SUPPORT INSTALLATION DETAIL (FIREMASTER ALTERNATE TO CALCIUM-SILICATE INSULATION) NOT TO SCALE 7. issue date 02/11/2011 project no. t10-12-0230 drawn by cadd checked by twig KITCHEN EXHAUST HOOD DETAIL scale AS NOTED NOT TO SCALE dwg. no. NYCECC NOTES: TO THE BEST OF MY KNOWLEDGE, BELIEF AND PROFESSIONAL JUDGMENT, THESE PLANS AND SPECIFICATIONS ARE IN COMPLIANCE WITH THE NEW YORK CITY ENERGY CONSERVATION CODE. THESE PLANS ARE APPROVED ONLY FOR THE WORK ON THE APPLICATION SPECIFICATION SHEET. ALL OTHER MATTERS SHOWN ARE NOT TO BE RELIED UPON OR TO BE CONSIDERED AS EITHER BEING APPROVED OR IN ACCORDANCE WITH APPLICABLE CODES. cad file sheet 7 of 8 375 Beach 92nd Street M-401.00.dwg NYC dob# project 375 Beach 92nd Street Queens, NY 11693 DIFFUSER SCHEDULE (BASED ON TITUS) DESIGNATION NOMINAL OVERALL SIZE A 12x12 B NECK SIZE MIN-MAX CFM 0-120 12 121-210 12 0-150 12 151-250 13 251-385 15 385-525 16 526-725 18 8x6 0-150 12 12x6 151-250 15 12x8 251-350 16 12x10 351-430 16 18x8 431-525 17 18x10 526-665 18 36x24 2250 25 12x6 0-200 12 18x6 201-345 18 24x24 - C D - - TRG-A NOISE CRITERIA 18x10 345-600 18 24x12 601-950 19 TRG-B MODEL MANUFACTURER REMARKS OMNI TITUS CEILING DIFFUSER OMNI TITUS CEILING DIFFUSER architect 282RL TITUS 355RL TITUS DOUBLE DEFLECTION SUPPLY REGISTER DOUBLE DEFLECTION SUPPLY REGISTER A Division of The Wall Consulting Group, Inc. All Rights Reserved. 2007- 2010 355 RL TITUS TRANSFER GRILLE (BOTH SIDES OF WALL) info@twigcon.com 36x4 420 25 CT-580 TITUS TRANSFER GRILLE (BOTH SIDES OF WALL) CG-A - 12x12 300 21 355 RL TITUS CEILING RETURN GRILLE CG-B - 24x24 600 21 355 RL TITUS CEILING RETURN GRILLE 6 3 0-80 20 8 4 81-130 20 SEIHO PK SPOT DIFFUSER 10 5.5 131-330 20 16 8 331-600 20 - 0-300 21 T3-SQ-5 TITUS VAV DIFFUSER - 301-500 21 T3-SQ-5 TITUS VAV DIFFUSER S V 231 West 29th Street - Suite 606, New York, NY 10001 Tel: 212 . 967 . TWIG / Fax: 212 . 967 . 8945 www.twigcon.com NOTES: 1. ONLY 4-WAY DIFFUSERS SHALL BE USED, PROVIDE BLANK-OFF SHEETMETAL BAFFLE FOR ALL 1-WAY, 2-WAY AND 3-WAY DIFFUSERS. LOCAL MANUFACTURER'S REP: A.D.E. SYSTEMS, INC (516) 568-6500 ELECTRIC DUCT HEATER SCHEDULE (BASED ON WARREN TECHNOLOGY) DESIGNATION LOCATION EDH-1 18TH FLOOR SERVICE DUCT SIZE (IN) CFM KW FLA NO. OF STAGES ELECTRICAL MODEL AC-18-3 22x14 200 6 - 3 208/3/60 CBK-18 REMARKS NOTES: 1. DUCT SIZE TO BE INCREASED AT LOCATION OF DUCT HEATER. 3. THE ELECTRIC DUCT HEATER SHALL BE LOCATED NO CLOSER THAN 4 FT. DOWNSTREAM OR 2 FEET UPSTREAM FROM FAN OUTLET, ELBOW, ETC. 2. THE UNIT FEATURES/OPTIONS SHALL INCLUDE BUT NOT LIMITED TO: a. OVERHEAT CONTROLS b. STAGING CONTRACTORS FOR STAGES OF HEATING ELEMENT CONTROL c. AIRFLOW SWITCH d. FAN INTERLOCK RELAY e. CONTROL TRANSFORMERS AND TERMINAL BLOCK f. INTEGRAL DISCONNECT SWITCH g. SILENT ACTING MAGNETIC CONTACTORS 4. THIS CONTRACTOR SHALL COORDINATE THE INSTALLATION OF THE DUCT HEATER WITH THE CONTROLS CONTRACTOR AND THE ELECTRICAL CONTRACTOR. PROVIDE POINT-TO-POINT WIRING DIAGRAMS FOR COORDINATION. SUBMISSIONS LOCAL MANUFACTURER'S REP: DNT ENTERPRISES (212) 682-0797 DATE rev no issue 02.14.11 1 FILING & PRICING MAKE-UP AIR FAN SCHEDULE (BASED ON GREENHECK) DESIGNATION KE-1 SERVIDE EXHAUST CFM 2000 STATIC PRESSURE (IN W.G.) 2.25 ELECTRICAL 208/3/60 MOTOR (WATTS OR HP) 3 DRIVE BELT OR DIRECT CONTROL (SWITCH OR T-STAT) WEIGHT BELT FAN RELAY 313 MANUFACTURER/ MODEL GREENHECK CUBE-200HP REMARKS NOTES: 1. PROVIDE FACTORY SUPPLIED VARIABLE SPEED SWITCH MOUNTED TO FAN CASING FOR ALL DIRECT DRIVE FANS. 2. PROVIDE INTEGRAL DISCONNECT SWITCH. LOCAL MANUFACTURER'S REP: A.D.E. SYSTEMS, INC (516) 568-6500 project 375 Beach 92nd Street Queens, NY 11693 EXHAUST FAN SCHEDULE (BASED ON GREENHECK) DESIGNATION KE-1 SERVIDE EXHAUST CFM 2800 STATIC PRESSURE (IN W.G.) 2.25 ELECTRICAL 208/3/60 MOTOR (WATTS OR HP) 3 DRIVE BELT OR DIRECT CONTROL (SWITCH OR T-STAT) WEIGHT BELT FAN RELAY 313 dwg title MANUFACTURER/ MODEL GREENHECK CUBE-200HP REMARKS NOTES: GROUND FLOOR MECHANICAL SCHEDULES 1. PROVIDE FACTORY SUPPLIED VARIABLE SPEED SWITCH MOUNTED TO FAN CASING FOR ALL DIRECT DRIVE FANS. 2. PROVIDE INTEGRAL DISCONNECT SWITCH. LOCAL MANUFACTURER'S REP: A.D.E. SYSTEMS, INC (516) 568-6500 seal & signature issue date 02/11/2011 project no. t10-12-0230 drawn by cadd checked by twig scale AS NOTED dwg. no. NYCECC NOTES: TO THE BEST OF MY KNOWLEDGE, BELIEF AND PROFESSIONAL JUDGMENT, THESE PLANS AND SPECIFICATIONS ARE IN COMPLIANCE WITH THE NEW YORK CITY ENERGY CONSERVATION CODE. THESE PLANS ARE APPROVED ONLY FOR THE WORK ON THE APPLICATION SPECIFICATION SHEET. ALL OTHER MATTERS SHOWN ARE NOT TO BE RELIED UPON OR TO BE CONSIDERED AS EITHER BEING APPROVED OR IN ACCORDANCE WITH APPLICABLE CODES. cad file sheet 8 of 8 375 Beach 92nd Street M-601.00.dwg NYC dob# project FIRE ALARM LEGEND FIRE ALARM GENERAL NOTES FIRE ALARM NOTES 375 Beach 92nd Street Queens, NY 11693 1. REFER TO DRAWING E-101 FOR GENERAL NOTES. F WALL MOUNTED MANUAL FIRE PULL STATION - 48" A.F.F., U.O.N. F WALL MOUNTED FIRE SIGNAL COMBINATION STROBE/HORN - 80" A.F.F. OR 6" BELOW HUNG CEILING WHICHEVER IS LOWER. F WALL MOUNTED FIRE SIGNAL STROBE - 80" A.F.F. OR 6" BELOW HUNG CEILING WHICHEVER IS LOWER. S H D C SMOKE DETECTOR. 'C' INDICATES ABOVE CEILING. C HEAT DETECTOR. 'C' INDICATES ABOVE CEILING. R S DUCT MOUNTED SMOKE DETECTOR WITH SAMPLING TUBE. `R' DENOTES RETURN; `S' DENOTES SUPPLY ELECTRICAL CONTRACTOR SHALL VERIFY AND COORDINATE WITH BUILDING FIRE ALARM MAINTENANCE VENDOR (HONEYWELL 516 302 9433) FOR TYPE OF FIRE ALARM DEVICES TO BE USED. ALL NEW DEVICES INSTALLED SHALL BE COMPATIBLE AND CONSISTENT WITH THE EXISTING BUILDING FIRE ALARM SYSTEM INSTALLATION. FIRE ALARM RISER DIAGRAM SHOWN IS FOR GENERAL ARRANGEMENT AND SHALL BE USED FOR ESTIMATING ONLY. ELECTRICAL CONTRACTOR SHALL VERIFY EXISTING FIELD CONDITIONS AND OBTAIN POINT TO POINT WIRING DIAGRAM FROM BUILDING FIRE ALARM VENDOR PRIOR TO INSTALLATION, THAT IS CONSISTANT WITH LOCAL FIRE MARSHALLS OFFICE REQUIREMENTS. ELECTRICAL CONTRACTOR SHALL BE RESPONSIBLE THE SERVICES OF THE BASE BUILDING FIRE ALARM VENDOR TO DEVELOP AND DESIGN A CODE COMPLIANT, FULLY FUNCTIONAL FIRE ALARM SYSTEM, THE DESIGN DOCUMENTS INDICATE GENERAL INTENT OF AUDIO, VISUAL, AND ACTIVATION DEVICES. CONTRACTOR SHALL INCLUDE IN THEIR BID ALL DEVICES REQUIRED BY LOCAL FIRE ALARM INSPECTORS INCLUDING, BUT NOT LIMITED TO SMOKE DETECTORS, PULL STATIONS, WARDEN STATIONS, INTERFACE RELAYS, CONTROL PANELS, POWER BOOSTER PANELS, ETC. CONTRACTOR AND VENDOR SHALL ALSO INCLUDE ALL COMPONENTS TO UPGRADE THE EXISTING BASE BUILDING SYSTEM EXPANSION INCLUDING, BUT NOT LIMITED TO, RELAY CARDS, STROBE CONTROL PANELS, AMPLIFIERS, ETC... FIRE ALARM CONTROL PANEL. FACP ANN ALL PROGRAMMING MUST BE UNDERTAKEN BY THE BASE BUILDING FIRE ALARM VENDOR AND ALL FINAL TERMINATIONS MUST BE SUPERVISED (AS A MINIMUM) BY A FIRE ALARM VENDOR TECHNICIAN. ELECTRICAL CONTRACTOR SHALL RETAIN BUILDING FIRE ALARM VENDOR FOR THIS SCOPE. SUBMISSION OF BID ACKNOWLEDGES THAT ELECTRICAL CONTRACTOR HAS CONTACTED THE BASE BUILDING VENDOR AND HAS INCLUDED ALL COMPONENTS FOR A CODE COMPLIANT SYSTEM. ADDITIONAL CLAIMS FOR CHANGES IN VENDOR SCOPE OR ADDITIONAL DEVICES/COMPONENTS, UNLESS INITIATED BY TENANT, WILL NOT BE ACCEPTED. REMOTE ANNUNCIATOR PANEL. TS TAMPER SWITCH. WF WATER FLOW SWITCH. WP WARDEN PHONE/FIREMANS JACK ELECTRICAL CONTRACTOR SHALL BE RESPONSIBLE FOR FILING DRAWINGS AND NECESSARY DOCUMENTATION FOR PERMIT PRIOR TO THE COMMENCEMENT OF THE WORK . ALL PERMIT COSTS, INSPECTION FEES SHALL BE INCLUDED AS PART OF THIS CONTRACT. WHEN REQUIRED, THE CONTRACTOR SHALL RETAIN A LICENSED PROFESSIONAL ENGINEER TO SIGN AND SEAL THE DOCUMENTS. EXISTING NEW EXISTING TO BE REMOVED STROBES SHALL BE WIRED SO THAT THEY REMAIN ACTIVE AFTER SILENCE FUNCTION IS PERFORMED. INSTALL SMOKE DETECTORS A MINIMUM OF 3'-0" FROM ANY SUPPLY OR RETURN OPENING. ELECTRICAL CONTRACTOR SHALL BE RESPONSIBLE TO MAINTAIN AND PROTECT ALL FIRE ALARM SPEAKERS, SMOKE DETECTORS, FIRE WARDEN STATIONS AND OTHER FIRE ALARM SAFETY DEVICES IN OPERATION AT ALL TIMES. IF ANY PORTION OF THE FIRE ALARM SYSTEM IS DISABLED, NOTIFY BUILDING MANAGER IMMEDIATELY. IT IS THIS CONTRACTOR'S RESPONSIBILITY TO MAINTAIN OPERATION OF ALL EXISTING FIRE ALARM DEVICES AT ALL TIMES. ELECTRICAL CONTRACTOR MAY REUSE EXISTING SPEAKER OR STROBE CIRCUITS ON THE FLOOR AS LONG AS THEY ARE CODE COMPLIANT AND IN A FULLY FUNCTIONING CONDITION. IF CIRCUITS ARE NOT ADEQUATE TO SUPPORT LOAD, PROVIDE A MINIMUM OF TWO (2) CIRCUITS FOR FIRE ALARM SYSTEM SPEAKERS AND, A MINIMUM OF TWO (2) CIRCUITS FOR FIRE ALARM SYSTEM STROBES. CONNECT SPEAKERS AND STROBES ON ALTERNATING CIRCUITS SO THAT THE FAILURE OF ONE CIRCUIT WILL NOT DISABLE TOTAL ALARM AUDIBILITY THROUGHOUT THE FLOOR. DEVICES SHALL BE ALTERNATELY WIRED THROUGHOUT THE FLOOR SO THAT NO TWO DEVICES, ADJACENT TO EACH OTHER IN A GIVEN FIELD OF VIEW SHALL BE ON THE SAME CIRCUIT. SITE PLAN: 375 BEACH 92ND STREET, QUEENS , NY NORTH 75 3 T EE TR NS S 92 L NE N HA C A BE HC DR A ACU ADA AMP/AMPERE AIR CONDITIONING UNIT AMERICANS WITH DISABILITIES ACT AFF ABOVE FURNISHED FLOOR AHJ AUTHORITIES HAVING JURISDICTION AHU AIR HANDLING UNIT AWG AMERICAN WIRE GAUGE C, CDT CONDUIT CAC COMPUTER ROOM GRADE AIR CONDITIONING UNIT CKT CIRCUIT CU COPPER DGP DATA GATHERINE PANEL DWG DRAWING E EXISTING TO REMAIN EC ELECTRICAL CONTRACTOR EF EXHAUST FAN ELEC ELECTRICAL EM EMERGENCY (ER) EXISTING TO BE RELOCATED FA FIRE ALARM FBO FURNISHED BY OTHERS, INSTALLED AND WIRED BY THE ELECTRICAL CONTRACTOR FCO FUSED CUT OUT FCS FIRE COMMAND STATION FIBO FURNISHED AND INSTALLED BY OTHERS, WIRED BY THE ELECTRICAL CONTRACTOR FSD FIRE SMOKE DAMPER FT G, GND GEN HZ IG JB MAX MD MECH MER MTD (N) NE NIC NTS PB R RCU RE RM SD SPEC TTB TYP UON W WP X FEET GROUND GENERATOR HERTZ ISOLATED GROUND JUNCTION BOX MAXIMUM MOTORIZED DAMPER MECHANICAL MECHANICAL EQUIPMENT ROOM MOUNTED NEW NEW TO REPLACE EXISTING NOT IN CONTRACT NOT TO SCALE PULL BOX REMOVE EXISTING EQUIPMENT REMOTE COMPUTERIZED UNIT PANEL RELOCATED EXISTING (NEW LOCATION) ROOM SMOKE DETECTOR SPECIFICATION TERMINAL BOX TYPICAL UNLESS OTHERWISE NOTED WIRE WEATHERPROOF REMOVE PROVIDE REMOTE LED FOR FSD'S ABOVE HUNG CEILING. LED TO BE VISIBLE FROM TENANT SPACE TO INDICATE LOCATION/OPERATION. SHUTDOWN OF A/C UNITS SHALL BE PERFORMED VIA A RELAY INTERFACE WITH THE CLASS FIRE ALARM SYSTEM. A/C UNIT RE-START SHALL BE MANUAL AT THE UNIT. PROVIDE REQUIRED COMPONENTS IN A NEMA-1 ENCLOSURE PAINTED RED WITH A MOMENTARY PUSHBUTTON. PROVIDE AN ENGRAVED NAMEPLATE READING "A/C UNIT RESTART". RESTART BUTTON SHALL BE LOCATED ADJACENT TO UNIT SERVED. REMOTE RESTART LOCATED ON THE FIRE COMMAND STATION OR PREACTION CONTROL PANEL IS ALSO ACCEPTABLE. ALL FIRE ALARM SYSTEM SHUTDOWNS SHALL BE COORDINATED WITH THE BUILDING MANAGEMENT IN ADVANCE TO ALLOW ADEQUATE TIME FOR ANY TEMPORARY FIRE WATCHES TO BE SCHEDULED. 2. REFER TO SPECIFICATIONS FOR BASE BUILDING VENDOR DESIGN/BUILD REQUIREMENTS. 3. DOCUMENTS SHOW GENERAL LOCATIONS OF ACTIVATION & ANNUNCIATION DEVICES. CONTRACTOR SHALL COORDINATE WITH BASE BUILDING FIRE ALARM VENDOR FOR ALL SYSTEM ADDITIONS, UPGRADES, ETC. WHICH MAY BE REQUIRED BUT MAY NOT BE FULLY REPRESENTED IN THESE PLANS. REFER TO SPECIFICATION SECTIONS FOR CONTRACTOR/VENDOR DESIGN BUILD REQUIREMENTS. 4. CONTRACTOR SHALL NOT REMOVE ANY EXISTING BASE BUILDING FIRE ALARM DEVICE WITHOUT PRIOR APPROVAL BY THE BUILDING MANAGEMENT. 5. MAINTAIN THE OPERATION OF THE EXISTING FIRE ALARM SYSTEM AND WIRING. IF DEVICES ARE REMOVED DURING DEMOLITION OR CONSTRUCTION, THEY MUST BE COMPLETELY FUNCTIONAL PRIOR TO TENANT OCCUPANCY. COORDINATE NEW INSTALLATION WITH THE BUILDING MANAGEMENT COMPANY. 6. NEW FIRE ALARM STROBE DEVICES SHALL BE A MINIMUM OF 15/75 CANDELA PER ADA REQUIREMENTS. 7. NEW FIRE ALARM STROBE & SPEAKERS/STROBE DEVICES SHALL BE WALL OF COLUMN MOUNTED AT A MINIMUM OF 80 INCHES ABOVE THE FLOOR OR 6 INCHES BELOW CEILING WHICHEVER IS LOWER. 8. ALL FIRE ALARM WIRING SHALL BE TEFLON 'RED' APPROVED TO USE IN NEW YORK CITY. architect 9. IN THE ACCESSIBLE HUNG CEILING ROUTE FIRE ALARM WIRING EXPOSED, OTHERWISE IN CONDUIT. 10. ALL FIRE ALARM DEVICES & EQUIPMENT MUST BE BS&A AND M.E.A. APPROVED AND SHALL BE COMPATIBLE WITH BASE BUILDING FIRE ALARM SYSTEM AND SHALL MATCH BUILDING STANDARDS. COORDINATE WITH BUILDING FIRE ALARM VENDOR. STROBES & SPEAKER/STROBES SHALL HAVE WHITE FINISH, COORDINATE WITH ARCHITECT. 11. LOCATIONS OF ALL DEVICES REQUIRE ARCHITECT'S/ENGINEER'S APPROVAL PRIOR TO INSTALLATION. CONTRACTOR SHALL LOCATE ALL DEVICES IN FIELD & OBTAIN ARCHITECT SIGN OFF PRIOR TO INSTALLATION OF ANY ROUGHING DEVICE. ANY DEVICES INSTALLED WITHOUT ARCHITECT'S APPROVAL THAT ARCHITECT/ENGINEER REQUESTS TO BE RELOCATED, SHALL BE MOVED AT NO ADDITIONAL COST. 12. ALL STROBE & SPEAKER/STROBE DEVICES, INSTALLED IN CONFERENCE ROOMS SHALL BE LOCATED ABOVE LIGHT SWITCHES. REFER TO ARCHITECTURAL DETAILS. A Division of The Wall Consulting Group, Inc. All Rights Reserved. 2007- 2010 13. SPEAKER/STROBE DEVICES SHALL BE INSTALLED IN ALL COMMON AREAS SO THAT NO SPACE IS MORE THAN 50 FEET FROM A SPEALER/STROBE DEVICE 231 West 29th Street - Suite 606, New York, NY 10001 Tel: 212 . 967 . TWIG / Fax: 212 . 967 . 8945 14. ALL STROBE LIGHTS WITHIN A GIVEN FIELD OF VIEW SHALL BE SYNCHRONIZED info@twigcon.com www.twigcon.com 15. ALL SMOKE DETECTORS SHALL BE LOCATED AND INSTALLED MORE THAN 3-FEET AWAY FROM AN AIR SUPPLY DIFFUSER. 16. A MINIMUM OF TWO (2) SPEAKER AND TWO (2) STROBE CIRCUITS SHALL BE INSTALLED THROUGHOUT FLOOR. DEVICES SHALL BE ALTERNATELY WIRED THROUGHOUT FLOOR SO THAT NO TWO DEVICES, ADJACENT TO EACH OTHER IN A GIVEN FIELD OF VIEW SHALL BE ON THE SAME CIRCUIT. 17. CONTRACTOR SHALL TRACE & REMOVE ALL EXISTING FIRE ALARM WIRING NO LONGER IN USE. 18. ALL EXISTING DUCT DETECTORS & FIRE DAMPERS SHALL REMAIN. 19. PROVIDE ALL NEW FIRE ALARM CABLING FOR ALL RELOCATED DEVICES. 20. ALL EXISTING FIRE ALARM WIRING, THAT IS TO REMAIN, SHALL BE PROPERLY SUPPORTED OR RE-SUPPORTED BY THIS CONTRACTOR. ALL CABLING, NEW IR EXISTING, SHALL BE INDEPENDENTLY SUPPORTED FROM SLAB OR BEAMS AT A MINIMUM OF 5 FEET ON CENTER. PROVIDE APPROVED BRIDAL RINGS OR OTHER APPROVED SUPPORTS AS REQUIRED. 21. ALL FIRE ALARM CABLING, PASSING THRU NON RATED SHEETROCK WALLS, SHALL PASS THRU WALL INDEPENDENT OF DUCTS, MC CABLING, SECURITY CABLING ETC. FIRE ALARM CABLING SHALL NOT TOUCH ANY OTHER SERVICE WHILE PASSING THRU WALLS. ELECTRICAL CONTRACTOR SHALL PROVIDE CONDUIT SLEEVES FOR ALL CABLING PASSING THUR SHEETROCK WALLS. AFTER ALARM INDICATION ALL FANS SHALL BE MANUALLY RESET INDEPENDENT OF FACP RESET. 22. REPLACE EXISTING FIRE ALARM DEVICE WITH NEW. AFTER THE SYSTEM MODIFICATIONS ARE COMPLETE, TEST ALL COMPONENTS IN ACCORDANCE WITH SEQUENCE OF OPERATION PRIOR TO FIRE INSPECTION. 23. REPLACE EXISTING SMOKE DETECTOR WITH NEW. CONNECT NEW SMOKE DETECTOR TO NEW WIRING AS REQUIRED AND REINSTALL IN NEW CEILING AT SAME LOCATION. 24. REMOVE EXISTING FIRE ALARM DEVICE AND REPLACE EXISTING WIRING TO KEEP CONTINUITY IN FIRE ALARM LOOP AS REQUIRED. CONTRACTOR SHALL FURNISH A COPY OF "FDNY LETTER OF APPROVAL" TO THE BUILDING MANAGEMENT. FIRE ALARM ABBREVIATIONS (NOT ALL ABBREVIATIONS ARE NECESSARILY USED ON THIS PROJECT) ALL DUCT MOUNTED SMOKE DETECTORS INSTALLED CONCEALED ABOVE HUNG CEILING, ETC, SHALL BE PROVIDED WITH A REMOTE LED TO PROVIDE A RAPID VISIBLE INDICATION OF THE DETECTOR LOCATION AND STATUS FROM THE OCCUPIED SPACE. REMOVE EXISTING FIRE ALARM DEVICES AND RELOCATE FOR REUSE AS PER DRAWINGS. (NOT ALL SYMBOLS ARE NECESSARILY USED ON THIS PROJECT) IC MA JA 'T' TAPPING OR SPLICING IS NOT ALLOWED. SPEAKER/STROBE UNITS SHALL NOT HAVE ANY OTHER DEVICES OR APPARATUS WITHIN FIVE (5) FEET OF DEVICE. ELECTRICAL CONTRACTOR MAY REUSE EXISTING SPEAKER OR STROBE CIRCUITS ON THE RESPECTIVE FLOOR AS LONG AS THEY ARE CODE COMPLIANT. IF CIRCUITS ARE NOT ADEQUATE TO SUPPORT LOAD, PROVIDE TWO (2) CIRCUITS FOR FIRE ALARM SYSTEM SPEAKERS AND, TWO (2) CIRCUITS FOR FIRE ALARM SYSTEM STROBES. CONNECT SPEAKERS AND STROBES ON ALTERNATING CIRCUITS SO THAT THE FAILURE OF ONE CIRCUIT WILL NOT DISABLE TOTAL ALARM AUDIBILITY THROUGHOUT THE FLOOR. AY AB ALL NEW FIRE ALARM CABLE SHALL BE RUN PARALLEL AND PERPENDICULAR NO DIAGONAL RUNS. SUPPORTS SHALL BE PROVIDED EVERY 5'-0" ON CENTER. SPEAKERS SHALL BE TAPPED TO PROVIDE 15dB ABOVE THE AMBIENT NOISE LEVEL. UNLESS OTHERWISE NOTED, SPEAKERS SHALL BE TAPPED AT 1/4 WATT MINIMUM IN OFFICE AREAS. CONTRACTOR SHALL PERFORM SOUND POWER TESTING BEFORE AND AFTER THE INSTALLATION IS COMPLETE AND SHALL ADJUST TAP SETTING AS REQUIRED TO OBTAIN THE REQUIRED SOUND LEVEL. ELECTRICAL CONTRACTOR SHALL FILE FORM A-433 "APPLICATION FOR ELECTRICAL INSPECTION" WITH THE BUREAU OF FIRE PREVENTION. ELECTRICAL CONTRACTOR SHALL THEN ACCOMPANY THE FIRE DEPARTMENT INSPECTOR DURING HIS INSPECTION OF THE SYSTEM. MAKE ALL ADJUSTMENTS REQUIRED BY THE INSPECTOR RESULTING FROM ISSUANCE OF "NOTICE OF DEFECTS" AND REQUEST FOR ADDITIONAL INSPECTIONS AS REQUIRED UNTIL A NON-CONDITIONAL APPROVAL IS RECEIVED FROM THE FIRE DEPARTMENT. END OF LINE RESISTOR BLOCK #: 16109 LOT #: 43 ALL WIRING INCLUDING GROUNDING TO BE INSTALLED ACCORDING TO THE LATEST VERSION OF THE NATIONAL ELECTRIC CODE. PROVIDE OUTLET BOXES, ETC... FOR ALL DEVICES AS REQUIRED. CARD READER CR FIRE ALARM CABLES SHALL COMPLY WITH THE FOLLOWING REQUIREMENTS: 1. 2. A MINIMUM AVERAGE INSULATION THICKNESS OF 15 MILS. 3. A MINIMUM AVERAGE JACKET THICKNESS OF 25 MILS. 4. THE COLOR OF THE CABLE SHALL BE RED. 5. THE CABLE SHALL BE TYPE FPLP (PLENUM TYPE) 6. THE CABLE SHALL BE VISIBLY MARKED EXTERNALLY "FIRE ALARM". 7. THE CABLE SHALL MEET THE ABOVE REQUIREMENTS AND HAVE UL 1424 AND UL 910 LISTING. 8. CABLES SHALL BE APPROVED FOR LOCAL AHJ. 9. CABLES SHALL BE LABELED "NYC CERTIFIED" AND INSTALLED IN ACCORDANCE WITH RS17-3 AND RS 17-5.OF THE BUILDING CODE OF NEW YORK CITY, DEPARTMENT OF BUILDINGS DIRECTIVES, NEW YORK CITY ELECTRICAL CODEM NFPA STANDARDS AND ALL OTHER APPLICABLE CODES AND REGULATIONS ALL FIRE ALARM DEVICES SHALL BE FLUSH MOUNTED, UNLESS OTHERWISE NOTED. ALL COST ASSOCIATED WITH CONNECTIONS AND REPROGRAMMING OF THE EXISTING FIRE ALARM SYSTEM TO BE PAID BY THIS CONTRACTOR, AND INCLUDED IN THE BASE BID. PUBLIC ADDRESS CEILING MOUNTED SPEAKER. S ALL EQUIPMENT SHALL BE UL LISTED, MEET REQUIREMENTS OF NFPA 72 AND 90 A, ALL APPLICABLE CODES AND LOCAL LAWS, AND BE INSTALLED AND CONNECTED IN ACCORDANCE WITH THE MANUFACTURER'S RECOMMENDATIONS AND INSTRUCTIONS. ALL FINAL CONNECTIONS TO BE MADE BY THIS CONTRACTOR WITH THE APPROVAL AND SUPERVISION OF THE BASE BUILDING FIRE ALARM SYSTEM VENDOR. FIRE ALARM SEQUENCE OF OPERATION FIRE ALARM DEMOLITION NOTES IN THE EVENT OF AN AUTOMATIC OR MANUAL FIRE ALARM DEVICE INITIATION ON THE FLOOR OR THE FLOOR BELOW THE FOLLOWING SHALL OCCUR: 1. PRIOR TO SUBMISSION OF THE BID, THIS CONTRACTOR SHALL VISIT THE SITE AND BECOME FAMILIAR WITH ALL EXISTING CONDITIONS TO DETERMINE THEIR IMPACT ON THE EXECUTION OF WORK IN THIS CONTRACT. 2. THE DEMOLITION WORK SHALL INCLUDE, BUT NOT BE LIMITED TO, ANY AND ALL MATERIALS, CONNECTIONS, EXTENSIONS, CUTTING, REPAIRING AND OTHER ELECTRICAL WORK, TEMPORARY OR PERMANENT, THAT MAY BE REQUIRED TO MAINTAIN SERVICE THROUGH THE COMPLETION OF THIS PROJECT. COORDINATE THE EXTENT OF THE DEMOLITION WORK WITH THE ARCHITECT. 3. EXISTING FEEDERS FIE ALARM CABLES PASSING THROUGH THE AREA OF DEMOLITION AND SERVING OCCUPIED ADJACENT AREAS AND/OR INTERFERING WITH THE NEW WORK SHALL BE TRACED AND RELOCATED BY THIS CONTRACTOR. ALL NECESSARY SHUTDOWNS REQUIRED TO PERFORM THIS WORK SHALL BE COORDINATED WITH THE BUILDING MANAGEMENT. 4. EXISTING BASE BUILDING FIRE ALARM SYSTEM DEVICES ARE TO REMAIN AND KEPT OPERATIONAL DURING ALL STAGES OF THE PROJECT. ALL DEVICES SHALL BE PROPERLY PROTECTED. OPERATION OF ANY MANUAL PULL STATION SHALL: 1. A. SOUND A "SLOW WHOOP ALARM TONE ON ALL VOICE/TONE ALARM SPEAKERS ON THE FLOOR OF ALARM INITIATION AND THE FLOOR ABOVE THE FLOOR OF THE ALARM INITIATION. SOUND AN ALERT TONE SIMULTANEOUSLY ON ALL OTHER FLOORS. B. FLASH ALL ALARM STROBE LIGHTS ON THE FLOOR OF ALARM AND THE FLOOR ABOVE. C. FLASH THE "FIRE" SIGN LOCATED IN THE PROXIMITY OF THE FIRE COMMAND STATION. D. AN ALARM SIGNAL SHALL BE TRANSMITTED TO AN APPROVED CENTRAL STATION VIA DEDICATED TELEPHONE LINES. ACTIVATION OF ANY AREA SMOKE DETECTOR (EXCLUDING ELEVATOR RELATED SMOKE DETECTORS) OR DUCT SMOKE DETECTOR AS A FLOOR RETURN DUCT SHALL AUTOMATICALLY: 2. A. SOUND A "SLOW WHOOP ALARM TONE ON ALL VOICE/TONE ALARM SPEAKERS ON THE FLOOR OF ALARM INITIATION AND THE FLOOR ABOVE THE FLOOR OF THE ALARM INITIATION. SOUND AN ALERT TONE SIMULTANEOUSLY ON ALL OTHER FLOORS. B. FLASH ALL ALARM STROBE LIGHTS ON THE FLOOR OF ALARM AND THE FLOOR ABOVE. C. FLASH THE "FIRE" SIGN LOCATED IN THE PROXIMITY OF THE FIRE COMMAND STATION. D. AN ALARM SIGNAL SHALL BE TRANSMITTED TO AN APPROVED CENTRAL STATION VIA DEDICATED TELEPHONE LINES. E. SHUTDOWN ALL AIR HANDLING SYSTEM OR UNITS (GREATER THAN 2,00CFM) LOCATED ON OR SERVING THE FLOOR OF ALARM INITIATION AND CLOSE ANY SMOKE OR FIRE/SMOKE DAMPERS RELATED TO THOSE SYSTEMS. F. RELEASE ALL MAGNETICALLY HELD DOORS ON THE FLOOR OF ALARM INITIATION. 1. A. SOUND A "SLOW WHOOP ALARM TONE ON ALL VOICE/TONE ALARM SPEAKERS ON THE FLOOR OF ALARM INITIATION AND THE FLOOR ABOVE THE FLOOR OF THE ALARM INITIATION. SOUND AN ALERT TONE SIMULTANEOUSLY ON ALL OTHER FLOORS. B. FLASH ALL ALARM STROBE LIGHTS ON THE FLOOR OF ALARM AND THE FLOOR ABOVE. C. D. E. FLASH THE "FIRE" SIGN LOCATED IN THE PROXIMITY OF THE FIRE COMMAND STATION. AN ALARM SIGNAL SHALL BE TRANSMITTED TO AN APPROVED CENTRAL STATION VIA DEDICATED TELEPHONE LINES. SHUTDOWN ALL AIR HANDLING SYSTEM OR UNITS (GREATER THAN 2,00CFM) LOCATED ON OR SERVING THE FLOOR OF ALARM INITIATION AND CLOSE ANY SMOKE OR FIRE/SMOKE DAMPERS RELATED TO THOSE SYSTEMS. rev no issue 02.14.11 1 FILING & PRICING PRIOR TO COMMENCEMENT OF DEMOLITION WORK, CONTRACTOR SHALL UNDERTAKE ELECTRICAL SURVEY TO TRACE ALL EXISTING CABLES. CONTRACTOR SHALL CLEARLY IDENTIFY ALL CABLES THAT SERVE EXISTING TO REMAIN DEVICES AND EQUIPMENT WITHIN OR OUTSIDE THE DEMISED AREA TO BE DEMOLISHED. THIS SHALL INCLUDE CABLES THAT PASS THROUGH AND/OR SERVE THE SPACE AND EXTEND OUTSIDE THE DEMISED AREA ON AND OFF THE FLOOR. FIRE ALARM DRAWING LIST OPERATION OF A TAMPER SWITCH WILL: 4. DATE FIRE ALARM PRE-DEMOLITION NOTES ACTIVATION OF A HVAC SYSTEM DUCT SMOKE DETECTOR UNIT SHALL: 3. SUBMISSIONS SHEET # DWG # DESCRIPTION 1 FA-101.00 GROUND LEVEL: FIRE ALARM - SYMBOLS & NOTES 2 FA-301.00 GROUND LEVEL: FIRE ALARM - PLAN, RISER & NOTES project 375 Beach 92nd Street Queens, NY 11693 A. ANNUNCIATE A SUPERVISORY CONDITION AT FIRE COMMAND STATION. B. TRANSMIT A SUPERVISORY SIGNAL TO THE CENTRAL STATION. LOSS OF NORMAL POWER, OPEN CIRCUIT OR CIRCUIT FAULTS IN ELECTRICALLY SUPERVISED CIRCUITS SHALL: 5. A. B. 6. dwg title SOUND AUDIBLE SIGNAL AT THE FIRE COMMAND STATION. TRANSMIT A SUPERVISORY INDICATION TO THE CENTRAL STATION AGENCY. GROUND FLOOR FIRE ALARM SYMBOLS & NOTES ACTIVATION OF ELEVATOR RECALL SMOKE DETECTOR SHALL: A. ACTIVATION OF ELEVATOR LOBBY SMOKE DETECTOR, SHAFT, PIT HEAT AND SMOKE DETECTOR SHALL ACTIVATE THE ELEVATOR RECALL SYSTEM. ACTIVATION OF THE FIRE ALARM SYSTEM ALSO SHALL ACTIVATE TH EELEVATOR RECALL SYSTEM AS WELL. UPON ACTIVATION OF RECALL, ELEVATOR SHALL RETURN TO A DESIGNATED FLOOR. PROVIDE MANUAL OVERRIDE FOR FIRE MARSHAL. SEQUENCE OF OPERATION FOR ELEVATOR RECALL SHALL BE AS DIRECTED BY FIRE MARSHAL. seal & signature issue date 02/11/2011 project no. t10-12-0230 drawn by cadd checked by twig scale AS NOTED dwg. no. NYCECC NOTES: TO THE BEST OF MY KNOWLEDGE, BELIEF AND PROFESSIONAL JUDGMENT, THESE PLANS AND SPECIFICATIONS ARE IN COMPLIANCE WITH THE NEW YORK CITY ENERGY CONSERVATION CODE. THESE PLANS ARE APPROVED ONLY FOR THE WORK ON THE APPLICATION SPECIFICATION SHEET. ALL OTHER MATTERS SHOWN ARE NOT TO BE RELIED UPON OR TO BE CONSIDERED AS EITHER BEING APPROVED OR IN ACCORDANCE WITH APPLICABLE CODES. cad file sheet 1 OF 2 375 Beach 92nd Street FA-101.00.dwg NYC dob# project 375 Beach 92nd Street Queens, NY 11693 GENERAL FIRE ALARM NOTES WP 1. FOR SYMBOL LIST ABBREVIATIONS AND FIRE ALARM NOTS REFER TO DRAWINGS FA-101 2. WHERE SHOWN ELECTRICAL CONTRACTOR SHALL COORDINATE INSTALLATION, WIRING AND TESTING WITH MECHANICAL CONTRACTOR. 3. ELECTRICAL CONTRACTOR SHALL PERFORM ALL WORK AND PAY ALL FEEDS REQUIRED TO RETAIN THE SERVICES OF THE EXISTING BUILDING FIRE ALARM SYSTEM SERVICE VENDOR TO PROGRAM AND TEST ALL ALARM AND COMMUNICATIONS DEVICES INSTALLED UNDER THIS CONTRACT. architect 4. FIRE ALARM DEVICE INSTALLATION SHALL COMPLY WITH 2008 NYC CONSTRUCTION CODES, ELECTRICAL WORK SHALL COMPLY WITH 1 RCNY 4000-06, EQUIPMENT / DEVICES USED SHALL BE BY APPROVED MANUFACTURERS AND SHALL BE LISTED FOR THEIR USE. A Division of The Wall Consulting Group, Inc. All Rights Reserved. 2007- 2010 231 West 29th Street - Suite 606, New York, NY 10001 Tel: 212 . 967 . TWIG / Fax: 212 . 967 . 8945 info@twigcon.com WP www.twigcon.com WARDEN PHONE/FIREMANS JACK WP WP SUBMISSIONS DATE rev no issue 02.14.11 1 FILING & PRICING GROUND FLOOR project DGP WP EXISTING FIRE ALARM SYSTEM CONTROL PANEL(S) (COORDINATE W/ FA VENDOR) "CLASSIC" 375 Beach 92nd Street Queens, NY 11693 dwg title GROUND FLOOR FIRE ALARM PLAN, RISER & NOTES FIRE ALARM PARTIAL RISER DIAGRAM N.T.S seal & signature issue date 02/11/2011 project no. t10-12-0230 drawn by cadd checked by twig scale AS NOTED dwg. no. GROUND FLOOR:FIRE ALARM PLAN SCALE: 3/16" - 1'-0" NYCECC NOTES: TO THE BEST OF MY KNOWLEDGE, BELIEF AND PROFESSIONAL JUDGMENT, THESE PLANS AND SPECIFICATIONS ARE IN COMPLIANCE WITH THE NEW YORK CITY ENERGY CONSERVATION CODE. THESE PLANS ARE APPROVED ONLY FOR THE WORK ON THE APPLICATION SPECIFICATION SHEET. ALL OTHER MATTERS SHOWN ARE NOT TO BE RELIED UPON OR TO BE CONSIDERED AS EITHER BEING APPROVED OR IN ACCORDANCE WITH APPLICABLE CODES. cad file sheet 2 of 2 375 Beach 92nd Street FA-301.00.dwg NYC dob# project 375 Beach 92nd Street Queens, NY 11693 PLUMBING NOTES PLUMBING LEGEND BUTTERFLY VALVE 1. ALL NEW HOT AND COLD WATER LINES TO BE COPPER TUBING AND SHALL ORIGINATE ON THE SAME FLOOR FROM THE NEAREST WET COLUMN WITH PROPER ACCESS FOR MAINTENANCE. IF ATTACHED OR DISSIMILAR METAL, A CORROSION INHIBITOR IS TO BE PROVIDED. PLUMBING LINE REPRESENTATION ELECTRONIC WATER COOLER GATE VALVE TWO-COMPARTMENT SINK EXISTING GATE VALVE THREE COMPARTMENT SINK PRESSURE REDUCING VALVE 2. INSULATE ALL WATER SUPPLY LINES. 3. WASTE LINES SHALL BE PROPERLY PITCHED TO PREVENT "TRAPPED" WATER. INSTALL WASTE LINE CONNECTIONS WITH WATER CLOSET EXISTING O,S & Y VALVE SLOP SINK MIXING VALVE SHOWER VALVE WITH HOSE BIBB AW BIDET EXISTING SANITARY OR STORM WATER PIPING ABOVE GROUND TO REMAIN EXISTING SANITARY OR STORM WATER PIPING BELOW GROUND TO REMAIN EXISTING PIPE TO BE REMOVED LAVATORY CLEAN OUT DECK PLATE PLUMBING DRAWING NOTATIONS TWO-COMPARTMENT SINK (ELEVATION) FUNNEL FLOOR DRAIN E, EDA WATER COOLER ELEVATION STRAINER WATER CLOSET (ELEVATION) LADDER DRAWING NOTE TAG SECTION DESIGNATION ON DRAWING WHERE SECTION IS CUT A-SECTION DESIGNATION B-DRAWING NO. MOP RECEPTOR (ELEVATION) PIPE UP BATHTUB (ELEVATION) 12. ALL VALVES ARE TO BE PROPERLY TAGGED. PIPE DROP TOP CONNECTION PLUMBING DEMOLITION NOTES CAP BIDET (ELEVATION) PLUG OUTLET ROOF DRAIN (ELEVATION) HOUSE TRAP PRIOR TO PROPOSAL SUBMISSION, THIS CONTRACTOR SHALL VISIT THE SITE TO REVIEW THE EXISTING CONDITIONS ASSOCIATED WITH THE SCOPE OF WORK AND ADJACENT AREAS TO ASCERTAIN THE DIFFICULTIES WHICH WILL AFFECT THE EXECUTION OF THE WORK OF THIS CONTRACT. SHOCK ABSORBER PIPE SENSOR WELL CLEAN OUT DECK PLATE CW COLD WATER DIA DIAMETER DN DOWN EWC ELECTRIC WATER COOLER FAI FRESH AIR INLET FD FLOOR DRAIN FFD FUNNEL FLOOR DRAIN FL FLOOR FS FLOOR SINK HB HOSE BIBB HW HOT WATER HWR architect HOT WATER RECIRCULATION IM ICE MAKER LAV LAVATORY LDR LADDER MIN MINIMUM MR MOP RECEPTOR NO NUMBER RD ROOF DRAIN RPZ REDUCED PRESSURE BACKFLOW PREVENTER RTU ROOF TOP UNIT A Division of The Wall Consulting Group, Inc. All Rights Reserved. 2007- 2010 info@twigcon.com S SANITARY SH SHOWER SS SERVICE SINK UR URINAL V 231 West 29th Street - Suite 606, New York, NY 10001 Tel: 212 . 967 . TWIG / Fax: 212 . 967 . 8945 www.twigcon.com VENT VB VACUUM BREAKER VTR VENT THRU ROOF W WASTE WH WALL HYDRANT WC WATER CLOSET (NOT ALL ABBREVIATIONS ARE NECESSARILY USED ON THIS PROJECT) WALL HUNG WATER CLOSET (ELEVATION) NYC BUILDING DEPARTMENT PLUMBING NOTES SITE PLAN: 375 BEACH 92ND STREET, QUEENS , NY PROTECTION OF PIPING AS OULINED IN SECTION PC305 SHALL BE PROVIDED AS REQUIRED. FLOW SWITCH 3. IN GENERAL, PIPING MATERIALS SHALL BE AS PER SECTION PC303. 4. CONSTRUCTION AND SPACING OF HANGERS AND SUPPORTS SHALL BE AS DIRECTED IN SECTION PC308. PRESSURE GAGE DOMESTIC WATER METER 5. WATER SUPPLY SYSTEM SHALL BE AS DIRECTED IN SECTIONS PC601 THROUGH PC613. VALVES SHALL BE PROVIDED AT RISERS AND ELSEWHERE AS PER SECTION PC606. 6. SANITARY MATERIALS, DRAINAGE, SIZING, GRADING, AND OFFSETS SHALL BE AS OULINED IN SECTIONS PC701 THROUGH PC715. 7. CLEAN-OUTS SHALL BE AS PER SECTION PC708. 8. TRAPS SHALL SHALL BE AS PER SECTION PC1002. 9. VENT MATERIALS, SIZING, GRADING, CONNECTIONS, LOCATIONS AND OFFSETS SHALL BE AS DIRECTED IN SECTIONS PC901 THROUGH PC919. (NOT ALL SYMBOLS ARE NECESSARILY USED ON THIS PROJECT) PLUMBING DRAWING LIST SHEET # DWG # 1 P-101.00 DESCRIPTION GROUND LEVEL: PLUMBING - SYMBOLS & NOTES 2 P-201.00 GROUND LEVEL: PLUMBING - SPECIFICATIONS I 3 P-301.00 GROUND LEVEL: PLUMBING - PLAN & NOTES P-501.00 GROUND LEVEL: PLUMBING - RISERS & NOTES 6 P-502.00 GROUND LEVEL: PLUMBING - RISERS & NOTES 5 37 L NE DATE rev no issue 02.14.11 1 FILING & PRICING DR AN H HC BE AC T 5 SUBMISSIONS EE GROUND LEVEL: PLUMBING - DETAILS M JA R ST P-401.00 AY AB AIC SN 4 10. SPECIAL AND MISCELLANEOUS PIPING SHALL BE AS DIRECTED IN SECTION PC1201 THROUGH 1203. NORTH 2. BLOCK #: 16109 LOT #: 43 92 F. PIPING FLOW DIRECTION PIPE SLEEVE B. REMOVE ALL FIXTURES AS NOTED ON THE ARCHITECTURAL PLANS. PROVIDE TEMPORARY COVERS FOR HOT, COLD AND SANITARY CONNECTIONS DURING NEW CONSTRUCTION. E. URINAL (ELEVATION) ALL PLUMBING WORK SHALL COMPLY WITH CHAPTER 4 OF THE 2008 NEW YORK CITY BUILDING CODE, AND CHAPTERS 1 THROUGH 13 OF THE NEW YORK CITY PLUMBING CODE. THERMOWELL D. LEADER DESIGNATION UNION ALL EXISTING WORK REQUIRED TO REMAIN BUT INTERFERING WITH PROPOSED NEW PLUMBING (AS WELL AS ELECTRICAL, MECHANICAL AND GENERAL CONSTRUCTION WORK) SHALL BE RELOCATED AND RECONNECTED USING MATERIALS CONFORMING TO STANDARDS OF THIS CONTRACT. c. ALL EXISTING BUILDING VALVES FOR DOMESTIC WATER MAINS AT SHAFTS ARE TO REMAIN. WATER CLOSET (ELEVATION) 1. A. b. CONTRACTOR TO CONTACT BUILDING MANAGEMENT AND TENANT REGARDING REMOVAL SCOPE OF WORK TO MAINTAIN CONTINUITY OF ALL SERVICES TO ALL TENANTS WHO ARE TO REMAIN OPERATIONAL AND NOT BE AFFECTED BY DEMOLITION WORK. PLUMBING RISER DESIGNATION PIPE GUIDE THERMOMETER REMOVE ALL ABANDONED BASE BUILDING PIPING BACK TO THE EXISTING WET COLUMNS OR SHAFTS, OR AS NOTED ON DRAWINGS. FIRE STANDPIPE RISER DESIGNATION CODP VACUUM BREAKER SCOPE OF WORK a. REVISION SYMBOL SLOP SINK (ELEVATION) VACUUM BREAKER C. DEMOLITION WORK SHALL INCLUDE ALL MATERIALS, LABOR, EXTENSIONS, CONNECTIONS, CUTTING, REPAIRING, ADAPTING AND OTHER PLUMBING WORK REQUIRED TO MAINTAIN SERVICE PENDING THE COMPLETION OF THE PERMANENT WORK. COORDINATE THE EXTENT OF DEMOLITION WORK WITH THE ARCHITECT AND BUILDING MANAGEMENT. C. REMOVE BASE BUILDING PIPING AS INDICATED BELOW: REMOVE AND PATCH EXISTING WORK FRESH AIR INLET B. SUBMISSION OF A PROPOSAL WILL BE CONSTRUED AS EVIDENCE THAT THE ABOVE SITE EXAMINATION HAS BEEN MADE AND LATER CLAIMS WILL NOT BE RECOGNIZED FOR EXTRA LABOR, EQUIPMENT OR MATERIALS REQUIRED BECAUSE OF DIFFICULTIES ENCOUNTERED WHICH COULD HAVE BEEN FORESEEN HAD SUCH AN EXAMINATION BEEN MADE. 2. LAVATORY (ELEVATION) THREE COMPARTMENT SINK (ELEVATION) CLEANOUT GENERAL A. KITCHEN SINK (ELEVATION) POINT OF NEW CONNECTION TO EXISTING WORK BOTTOM CONNECTION 14. HOT WATER HEATERS SERVING PRIVATE BATHROOMS, KITCHENS, ETC. ARE TO BE SUPPLIED FROM THE WET COLUMN THAT SUPPLIES THE COLD WATER TO THESE AREAS. 1. NEW ACID WASTE PIPING EXISTING VENT PIPING TO REMAIN URINAL FLOOR DRAIN 13. ANY WET COLUMNS USED SHOULD BE PROVIDED WITH A 24" x 24" STEEL SURFACE MOUNTED ACCESS DOOR. COFFEE MAKER BATHTUB WATER CLOSET (FLUSH TANK) 11. PRIVATE BATHROOMS MUST BE INSTALLED ON MINIMUM 4" WASTE LINE. CM EXISTING HOT WATER RECIRCULATION PIPING TO REMAIN WATER CLOSET (FLUSH VALVE-WALL HUNG) STRAINER 10. PLUMBER SHALL BE RESPONSIBLE THAT ENTIRE INSTALLATION IS IN ACCORDANCE WITH LOCAL AND STATE CODES. NEW HOT WATER PIPING WITH TEMPERATURE MAINTENANCE CABLE EXISTING COLD WATER PIPING TO REMAIN STRAINER WITH BLOW OFF VALVE 9. ALL WATER SHUTDOWNS TO BE COORDINATED THROUGH THE BUILDING MANAGER. ALL WATER SHUTDOWNS ARE TO BE PERFORMED OR SUPERVISED BY BUILDING PERSONNEL, AT THE DISCRETION OF THE BUILDING MANAGER. BACKFLOW PREVENTER EXISTING HOT WATER PIPING TO REMAIN SOLENOID VALVE 8. ALL NEW PIPES ARE TO BE SUPPORTED FROM SLAB OR STEEL BEAMS, NOT FROM EXISTING PIPES OR DUCT WORK. BFP NEW GAS LINE G KITCHEN SINK O,S & Y VALVE 7. INDIVIDUAL SHUT-OFF VALVES MUST BE SUPPLIED AND INSTALLED FOR EACH NEW FIXTURE, INCLUDING WATER COOLERS. NEW HOT WATER PIPING NEW SANITARY OR STORM WATER PIPING BELOW GROUND MOP RECEPTOR PLUG VALVE 6. ALL NEW HOT AND COLD WATER LINES ATTENDANT FITTINGS MUST BE PROPERLY INSULATED AND COVERED. ABOVE FINISHED FLOOR NEW SANITARY OR STORM WATER PIPING ABOVE GROUND LAVATORY BALL VALVE 5. WHEN CONNECTING NEW HOT AND COLD WATER LINES TO EXISTING RISERS, CONTRACTORS SHALL LEAVE A PLUGGED VALVED OUTLET FOR EACH, FOR FUTURE USE. AFF NEW VENT PIPING MOP RECEPTOR EXISTING CHECK VALVE 4. RETAIN EXISTING CLEAN OUT CONNECTIONS AND PROVIDE CLEAN OUT CONNECTIONS AT NEW FITTINGS. NEW COLD WATER PIPING NEW HOT WATER RECIRCULATION CHECK VALVE PLUMBING ABBREVIATIONS PROVIDE ADDITIONAL SUPPORT FOR ALL EXISTING PIPING TO REMAIN WHICH ARE AFFECTED BY DEMOLITION OF EXISTING CEILING AND PARTITIONS. project ALL MATERIALS AND EQUIPMENT SHALL BE DISPOSED OF IN ACCORDANCE WITH APPLICABLE LAWS AND ENVIRONMENTAL REGULATIONS. 375 Beach 92nd Street Queens, NY 11693 COORDINATE WITH OWNER TO DETERMINE WHETHER EQUIPMENT IS TO BE TURNED OVER FOR FUTURE USE AND STORED IN THEIR ASSOCIATED STORAGE LOCATIONS. dwg title GROUND FLOOR PLUMBING SYMBOLS & NOTES seal & signature issue date 02/11/2011 project no. t10-12-0230 drawn by cadd checked by twig scale AS NOTED dwg. no. NYCECC NOTES: TO THE BEST OF MY KNOWLEDGE, BELIEF AND PROFESSIONAL JUDGMENT, THESE PLANS AND SPECIFICATIONS ARE IN COMPLIANCE WITH THE NEW YORK CITY ENERGY CONSERVATION CODE. THESE PLANS ARE APPROVED ONLY FOR THE WORK ON THE APPLICATION SPECIFICATION SHEET. ALL OTHER MATTERS SHOWN ARE NOT TO BE RELIED UPON OR TO BE CONSIDERED AS EITHER BEING APPROVED OR IN ACCORDANCE WITH APPLICABLE CODES. cad file sheet 1 of 6 375 Beach 92nd Street P-101.00.dwg NYC dob# PLUMBING SPECIFICATIONS project PLUMBING SPECIFICATIONS PART I - GENERAL 1.01 DESCRIPTION A. THE PLUMBING CONTRACTOR SHALL BE A LICENSED INSTALLER OF PLUMBING SYSTEMS IN THE CITY OF NEW YORK B. ALL WORK SHALL COMPLY WITH THE REQUIREMENTS OF THE NEW YORK CITY BUILDING CODE. C. THE ARCHITECT'S SPECIFICATIONS AS APPLICABLE ARE PART OF THIS CONTRACT. D. THE CONTRACTOR IS ADVISED TO CLOSELY COORDINATE HIS WORK WITH THE BUILDING ENGINEER, SO THAT THE INTERRUPTION OF EXISTING BUILDING SERVICES, IN ORDER TO CONNECT NEW PIPING TO EXISTING SHALL BE MADE AT SUCH TIME AS TO CAUSE THE LEAST INTERFERENCE WITH ESTABLISHED BUILDING OPERATING PROCEDURE. CONTRACTOR SHALL NOT INTERRUPT THE SERVICES WITHOUT EXPRESS WRITTEN PERMISSION OF THE OWNER. E. WORK IN CEILING OF TENANT SPACE ON FLOOR BELOW MUST TAKE PLACE BEFORE OR AFTER TENANT'S NORMAL BUSINESS HOURS AND SHALL BE CONSIDERED OVERTIME WORK. ALL CEILINGS DAMAGED MUST BE RESTORED TO ORIGINAL CONDITION. 1.07 LAWS, ORDINANCES, ETC. A. THE WORK OF THIS CONTRACTOR MUST COMPLY WITH ALL LOCAL LAWS, ORDINANCES AND RULES. THIS CONTRACTOR MUST HAVE THE NECESSARY INSPECTIONS MADE BY THESE AUTHORITIES, PAY ALL THE REQUIRED FEES, AND FURNISH THE OWNER WITH CERTIFICATES OF APPROVAL BEFORE FINAL PAYMENT ON THIS CONTRACT IS MADE. HE SHALL APPLY, PAY FOR, AND OBTAIN ALL PERMITS. 1.08 SUPERVISION A. THIS CONTRACTOR SHALL HAVE A COMPETENT FOREMAN IN RESPONSIBLE CHARGE OF THE WORK WHO SHALL BE ON THE SITE DURING THE INSTALLATION OF THE MATERIAL FURNISHED UNDER THIS SPECIFICATION UNTIL SAME HAS BEEN PUT IN COMPLETE OPERATIVE CONDITION AND ACCEPTED BY THE OWNER. 1.09 CUTTING AND PATCHING A. THIS CONTRACTOR SHALL DO ALL CUTTING AND PATCHING FOR PLUMBING WORK AND SHALL COORDINATE SAME WITH ALL OTHER TRADES. ALL CUTTING SHALL BE SUBJECT TO TRADE REGULATIONS. NO CUTTING OF STRUCTURAL MEMBERS SHALL BE DONE WITHOUT THE APPROVAL OF THE ARCHITECT. PART 2 - MATERIAL 1.02 VERIFYING CONDITIONS A. EXAMINE ALL DRAWINGS COVERING THE WORK OF THIS SECTION AND REFER TO ALL OTHER DRAWINGS, INCLUDING ARCHITECTURAL, MECHANICAL, AND ELECTRICAL DRAWINGS, WHICH MAY AFFECT THE WORK OF THIS SECTION OR REQUIRE COORDINATION BY SAME. B. BEFORE STARTING ANY WORK, EXAMINE EXISTING CONDITIONS, AND THOROUGHLY CHECK DRAWINGS, DIMENSIONS, SPECIFICATIONS, AND ADJOINING OR UNDERLYING CONDITIONS IN WHICH THE WORK OF THIS SECTION IS TO BE PERFORMED. C. REPORT, IN WRITING, TO THE ARCHITECT ANY AND ALL CONDITIONS WHICH MAY INTERFERE WITH OR OTHERWISE AFFECT OR PREVENT THE PROPER EXECUTION AND COMPLETION OF THE WORK OF THIS SECTION. DO NOT COMMENCE WORK UNTIL ANY AND ALL SUCH CONDITIONS HAVE BEEN CORRECTED BY THE TRADE OR TRADES RESPONSIBLE. 2.01 GENERAL A. THE PLUMBING SYSTEMS SHALL BE COMPLETE WITH ALL PIPES, FITTINGS, TRAPS, SUPPLIES, VALVES, HANGERS AND SUPPORTS, INSULATION, ETC. AND ALL OTHER ITEMS NECESSARY FOR COMPLETE, SATISFACTORY OPERATING AND APPROVED TYPE SYSTEM. B. ALL PIPE FITTINGS, VALVES, FIXTURES, HANGERS, SUPPORTS, INSULATION, ETC. SHALL CONFORM TO THE REQUIREMENTS OF THE NEW YORK CITY BUILDING CODE. 2.02 SOIL, WASTE, AND VENT PIPE AND FITTINGS A. ALL ABOVE GROUND SOIL, WASTE, AND VENT PIPING SHALL BE "NO-HUB" CAST IRON PIPE AND FITTINGS EXCEPT AS NOTED OTHERWISE. D. FAILURE TO NOTIFY THE ARCHITECT OF UNSATISFACTORY CONDITIONS WILL BE CONSTRUED AS AN ACCEPTANCE OF ALL CONDITIONS. B. ALL JOINTS AND CONNECTIONS SHALL BE ASSEMBLED BY MEANS OF SEALING SLEEVES AND STAINLESS STEEL CLAMPS AND SHIELD ASSEMBLIES. E. THE EXECUTION OF THE WORK OF THIS SECTION CONSTITUTES ACCEPTANCE OF THE BASE OR ADJOINING WORK AND OTHER CONDITIONS AS BEING SATISFACTORY IN EVERY RESPECT AND LATER CLAIMS OF DEFECTS IN SUCH CASES WILL NOT BE ALLOWED. C. PIPE AND FITTINGS SHALL BE CENTRAL FOUNDRY COMPANY, TYLER PIPE COMPANY, EAST PENN FOUNDRY OR APPROVED EQUAL. F. THE DRAWINGS INDICATE AND THE SPECIFICATIONS DESCRIBE THE GENERAL ARRANGEMENT AND THE APPROXIMATE LOCATION OF EQUIPMENT, FIXTURES, PIPING, ETC. EXACT LOCATIONS MAY BE ADJUSTED IN THE FIELD TO SUIT EXISTING CONDITIONS. G. THE CONTRACTOR SHALL, WITHOUT EXTRA COST TO THE OWNER, MAKE ALL REASONABLE MODIFICATIONS IN THE WORK AS MAY BE REQUIRED TO PREVENT CONFLICT WITH THE WORK OF OTHER TRADES, OR FOR THE PROPER INSTALLATION OF THE WORK. 1.03 SHOP DRAWINGS AND SAMPLES A. SUBMIT SHOP DRAWINGS AND SAMPLES WITH ALL DETAILS AND INFORMATION, AS REQUIRED FOR THE WORK OF THIS SECTION AND IN ACCORDANCE WITH GENERAL CONDITIONS OR AS REQUESTED BY THE ARCHITECT OR ENGINEER. B. SUBMIT FOR APPROVAL; SAMPLES OF MATERIALS, AFFIDAVITS, CERTIFICATES, ETC., AS REQUIRED BY THE GENERAL CONDITIONS OR AS REQUESTED BY THE ARCHITECT OR ENGINEER. C. SUBMIT FOR APPROVAL SHOP DRAWINGS AND CATALOG CUTS OF THE FOLLOWING: 1. 2. 3. 4. 5. 6. 7. PLUMBING FIXTURES AND EQUIPMENT. VALVES. PIPE AND FITTINGS. HANGERS. INSULATION HW HEATER & RECIRCULATION PUMP VACUUM BREAKERS 8. PIPING LAYOUT 9. GREASE TRAPS 10. SEWAGE EJECTOR 1.04 AS-BUILT DRAWINGS A. PREPARE AND SUBMIT "AS-BUILT" DRAWINGS AT THE COMPLETION OF THE PROJECT. 1.05 TESTS A. THE PLUMBING SYSTEMS SHALL BE INSPECTED AND TESTED IN ACCORDANCE WITH REQUIREMENTS OF THE NEW YORK CITY BUILDING CODE. 1.06 CLEANING A. ALL PIPING, FIXTURES, EQUIPMENT, ETC., INSTALLED UNDER THIS CONTRACT SHALL BE THOROUGHLY CLEANED AND PROTECTED DURING CONSTRUCTION AND PUT INTO FIRST-CLASS OPERATING CONDITION BEFORE BEING OFFERED FOR ACCEPTANCE. B. UPON COMPLETION OF ALL WORK, THE PLUMBING CONTRACTOR SHALL THOROUGHLY CLEAN ALL PLUMBING FIXTURES, SINKS AND TRIM AND LEAVE ALL ITEMS READY FOR USE BY THE OWNER. ALL FLOOR DRAINS SHALL BE CLEANED AND MANUFACTURERS PROTECTIVE COVERINGS SHALL BE REMOVED. D. EXPOSED PIPE TO BE CHROME PLATED. UNDERGROUND AND WHERE INDICATED 2.03 SOIL, WASTE, VENT AND LEADER PIPE AND FITTINGS A. ALL UNDERGROUND SOIL, WASTE, VENT AND LEADER PIPING SHALL BE APPROVED BELL AND SPIGOT CAST IRON SOIL PIPE AND FITTINGS. B. ALL JOINTS AND CONNECTION SHALL BE MADE BY THE USE OF DOUBLE-SEAL NEOPRENE CAST IRON SOIL PIPE GASKETS,ALABAMA PIPE COMPANY "DUAL-TITE" APPROVED OTHER. C. PIPE AND FITTINGS SHALL BE CENTRAL FOUNDRY COMPANY, ALABAMA PIPE COMPANY, EAST PENN FOUNDRY, OR APPROVED OTHER. 2.04 COLD WATER AND HOT WATER PIPE AND FITTINGS C. WHERE PIPES ARE TO BE INSULATED, THE HANGERS SHALL BE OF AMPLE SIZE TO PROVIDE FOR THE COVERING SPECIFIED AND BE PROVIDED WITH GALVANIZED STEEL INSULATION SHIELDS. D. ALL HANGERS, RODS, BEAM CLAMPS, ETC. SHALL BE SHOP ZINC COATED. E. ALL HORIZONTAL COPPER TUBING SHALL BE SUPPORTED BY HANGERS NOT OVER SIX (6) FEET APART FOR PIPING 1-1/4 INCH AND SMALLER AND NOT OVER TEN (10) FEET APART FOR PIPING 1-1/2 INCH AND LARGER. ALL BRANCHES SHALL HAVE SEPARATE HANGERS. HANGERS SHALL BE CLEVIS TYPE WITH COPPER BOTTOM SUPPORT. IF CHANNEL OR ANGLE IRON TRAPEZE HANGERS ARE USED, THE SPACE ON HANGERS FOR THE COPPER TUBING SHALL BE WRAPPED WITH LEAD SHIELDS TO ISOLATE TUBING. F. IN AREAS OF STEEL CONSTRUCTION, PIPE HANGERS SHALL BE SUPPORTED BY BEAM CLAMPS. COORDINATE WITH ENGINEER FOR MAXIMUM LOADING. BEAM CLAMPS SHALL BE STEEL WITH BOLT, NUT AND SOCKET THREADED FOR ROD CONNECTION AND SHALL BE F & S MANUFACTURING COMPANY FIG. #45, CENTRAL IRON, GRINNELL COMPANY, OR APPROVED EQUAL. 2.06 INSULATION A. COVER ALL HOT WATER AND HOT WATER RECIRCULATION PIPE WITH 1 INCH THICK AND ALL COLD WATER PIPE WITH 1/2 INCH THICK MANVILLE MICRO-LOK AP-T PLUS FIBERGLASS INSULATION. FITTINGS AND VALVES SHALL BE INSULATED WITH MANVILLE ZESTON 2000 PVC INSULATED FITTING COVERS. INSTALL ALL INSULATION AS PER MANUFACTURERS RECOMMENDATIONS. ALL INSULATION MATERIAL SHALL COMPLY WITH THE NEW YORK CITY BUILDING CODE REQUIREMENT OF A FLAME SPREAD RATING NOT TO EXCEED 25 AND A SMOKE DEVELOPED RATING NOT TO EXCEED 50. 2.07 VALVES A. STOP VALVES, EXCEPT FIXTURE STOPS, ON HOT AND COLD WATER LINES 2 IN. AND SMALLER SHALL BE FULL PORT 400 LB. NON-SHOCK BRONZE BALL VALVES, NIBCO T-595-Y FOR THREADED CONNECTIONS, AND NIBCO S-595-Y FOR COPPER TO COPPER, OR APPROVED OTHER. B. GLOBE VALVES UP TO AND INCLUDING 3 IN. SHALL BE SCREW-OVER BONNET, COMPOSITION DISC, BRASS, NIBCO T-211 FOR THREADED CONNECTIONS AND S-211 FOR SOLDER CONNECTIONS, OR APPROVED OTHER. OTHER. C. CHECK VALVES SHALL BE OF THE SWING-TYPE, SIZES UP TO AND INCLUDING 3 IN. SHALL BE ALL BRASS, 125 LB. S.W.P., NIBCO T-413 FOR THREADED CONNECTIONS AND NIBCO S-413 FOR SOLDER CONNECTIONS, OR APPROVED 2.08 VALVE TAGS AND CHART A. EACH VALVE, EXCEPT VALVES AT FIXTURES, SHALL HAVE A 2 INCH DIAMETER BRASS TAG WITH 1 INCH HIGH NUMERAL STAMPED THEREON, SECURED TO THE VALVE BY MEANS OF BRASS S HOOK OR BRASS CHAIN. EACH SYSTEM TO HAVE A LETTER DESIGNATION AS WELL. B. THE CONTRACTOR SHALL FURNISH AN APPROVED, NEATLY DRAWN VALVE CHART, PROPERLY FRAMED, SHOWING THE USE AND LOCATION OF EACH VALVE THAT IS TAGGED. 2.09 SHOCK ARRESTORS A. SHOCK ARRESTORS SHALL BE JONESPEC MODEL #55000 SERIES. SEE PLANS FOR EXACT MODEL NO. 2.10 BACKFLOW PREVENTION DEVICE A. VACUUM BREAKER (TYPE"A") - CAST BRASS C.P. IF EXPOSED TO PUBLIC VIEW SIMILAR TO WATTS NO. 288A. (NOT SUBJECT TO CONSTANT PRESSURE.) B. VACUUM BREAKER (TYPE"B") - CAST BRASS CHROME PIPE IF EXPOSED TO PUBLIC VIEW SIMILAR TO WATTS NO. 909-S. B. ALL SUPPLIES THROUGH WALLS TO FIXTURES SHALL BE 85% RED BRASS WITH THREADED BRASS FITTINGS. ALL EXPOSED PIPING IN FINISHED SPACES SHALL BE CHROME PLATED 85% RED BRASS. D. VACUUM BREAKER (TYPE"D") - CAST BRASS C.P. IF EXPOSED TO PUBLIC VIEW SIMILAR TO WATTS NO. N9C. (CONSTANT PRESSURE V.B.) 2.05 HANGERS AND SUPPORTS A. FURNISH ALL NECESSARY HANGERS, SUPPORTS, INSERTS, CLAMPS, ETC. AS REQUIRED. ALL HANGERS AND SUPPORTS SHALL BE OF HEAVY CONSTRUCTION AND SUITABLE FOR THE SIZE OF PIPE TO BE SUPPORTED. ALL INSERTS AND HANGERS SHALL BE INSTALLED TO CLEAR WORK OF OTHER TRADES. B. ALL HORIZONTAL CAST IRON PIPING SHALL BE SUPPORTED ON FIVE (5) FOOT CENTERS AND AT ALL JOINTS. ALL HORIZONTAL SCREWED PIPING SHALL BE SUPPORTED BY HANGERS SPACED NOT OVER TEN (10) FEET APART. ALL BRANCHES SHALL HAVE SEPARATE HANGERS. HANGERS SHALL BE CLEVIS TYPE, CONSTRUCTED OF HEAVY BAR STEEL STOCK, WITH PROPER SIZE SUSPENSION ROD AND LOCKNUTS. WHERE PIPING IS SUPPORTED FROM THE FLOOR, PROVIDE ADJUSTABLE PIPE SADDLE SUPPORT WITH U-BOLT. D. INDIRECT WASTE FLOOR DRAINS SHALL BE J.R. SMITH FIG. 3610-F11-B WITH 8" ROUND TOP, AND SEDIMENT BUCKET. E. FLOOR SINK SHALL BE JAY R. SMITH FIG. 3430-13 PORCELAIN ENAMELED INDIRECT WASTE FLOOR DRAIN WITH 3/4 ACID RESISTANT PORCELAIN ENAMELED GRATING WITH FLASHING FLANGE AND BOTTOM DOME STRAINER. SET RIM 1" ABOVE FINISHED FLOOR. F. FUNNEL FLOOR SHALL BE J.R. SMITH FIG. 3510-F11-B WITH F-37 7" ANTI SPLASH RIM AND SEDIMENT BUCKET. SET ANTI-SPLASH RIM FLUSH WITH THE FINISH FLOOR. 2.13 FILTERS A. CUNO "AQUA-PURE" MODEL SS1HA STAINLESS STEEL WITH AP117 CARTRIDGE - FURNISH ONE ADDITIONAL REPLACEMENT CARTRIDGE FOR EACH FILTER PROVIDED. FOLLOW MANUFACTURERS RECOMMENDATION FOR FILTER CHANGE SCHEDULE. 2.14 GUARANTEE A. THIS CONTRACTOR SHALL GUARANTEE FOR A PERIOD OF ONE (1) YEAR FROM DATE OF ACCEPTANCE BY THE OWNERS, ALL MATERIALS, APPARATUS AND WORKMANSHIP WHETHER FURNISHED BY HIMSELF OR BY HIS SUBCONTRACTORS AND HE SHALL REPLACE OR REPAIR IN A MANNER APPROVED BY THE ARCHITECTS, WITHOUT COST TO THE OWNER, ANY PARTS OR PARTS OF THE WORK WHICH MAY PROVE DEFECTIVE OR UNSATISFACTORY WITHIN THE PERIOD OF THE GUARANTEE. B. WHERE SPECIAL GUARANTEES COVERING INSTALLATION, OPERATION OR PERFORMANCE OF ANY SYSTEMS OR APPLIANCES FURNISHED UNDER THIS CONTRACTOR ARE REQUIRED, THE FULL RESPONSIBILITY FOR THE FULFILLMENT OF SUCH GUARANTEES MUST BE ASSUMED BY THE CONTRACTOR, WHO SHALL OBTAIN WRITTEN GUARANTEES, IN TRIPLICATE, WHICH SHALL BE FILED WITH THE ARCHITECT BEFORE FINAL ACCEPTANCE. TEMPERATURE RANGES OF 135 DEGREES F. TO 140 DEGREES F. THE AQUASTAT SHALL BE GUARANTEED TO OPERATE WITHIN A MAXIMUM RANGE OF PLUS OR MINUS 2 DEGREE F OF THE SETTING. C. PROVIDE SUITABLE "HAND-OFF-AUTOMATIC" SWITCH TO NEMA 1 ENCLOSURE MOUNTED ADJACENT TO CIRCULATOR. 2.22 SEWAGE EJECTOR A. FURNISH AND INSTALL AS SHOWN ON PLANS A DUPLEX VSA-4F-1-4 SUSPENDED. WET-PIT SEWAGE PUMP UNIT AS MANUFACTURED BY FEDERAL PUMP CORP. EACH PUMP SHALL BE RATED 100 GPM AT 23 FEET TOTAL DYNAMIC HEAD SHALL HAVE A 4" DISCHARGE AND BE BUILT FOR A 5'-0" DEEP BASIN. IMPELLERS SHALL BE CAST IRON NON SLOG BALANCED DESIGN: SHAFTS CARBONSTEEL SIZED FOR MAXIMUM LOAD: THRUST BEARING BALL TYPE MOUNTED IN MOISTURE -PROOF HOUSINGS MOUNTED ABOUVE THE SUSPENSION PLATE: CASTINGS SMOOTH-PASSAGECAST IRON WITH RENEWABLE BRONZE SLEEVE BEARING:RENEWABLE BRONZ SLEEVE INTERMEDIATEBEARINGS PROVIDE FOR EACH FOUR OF UNSUPPORTED SHAFT LENGTH: FLEXIBLE GREASE LINE SHALLBE PROVIDED FOR EACH SHAFT BEARING: SUSPENSION PLATE CAST IRON WITH STRENGTHENINGRIBS: SUSPENSION LEG SECTION CAST CAST IRON WITH INTEGRAL CAST FLANGES ON EACH END: DISHAGRE STEEL PIPE STEEL WITH EXPANSION JOINTS AT BOTH ENDS: TOP DISCHARGE CONNECTION architect MOTORS SHALL BE 1 HP 3 PHASE CYCLES 208 VOLTS R.P.M. OPEN, DRIP PROOF BALL BEARING TYPE. FURNISH A PEDESTAL MOUNTED ALTERNATING FLOAT SWITCH TO ALTERNATE THE OPERATION OF THE PUMPS AND PROVIDE SIMULATANEOUS OPERATION WHEN REQUIRED. FURNISH A PEDASTALL MOUNTED AUXILIARY FLOAT SWITCH TO TURN ON BOTH PUMPS IF THE ALTERNATING FLOAT SWITCH IS INOPERATIVE. THE ALTERNATING ANDAUXILIARY FLOAT SWITCHES SHALL HAVE COPPER FLOATS, BRASS RODS, ADJUSTABLE STOPS, GALVANIZED ROD GUIDES AND SHALL BE EQUAL TO FEDERAL TYPE FS-4. PROVIDE D-1100 DUPLEX CONTROL PANEL. C. CONTRACTOR WILL BE RESPONSIBLE FOR ALL LEAKS IN ALL PIPES FOR A PERIOD OF ONE YEAR FROM THE DATE OF COMPLETION OF WORK UNDER THIS CONTRACT. CONTRACTOR SHALL REPAIR AT NO COST TO THE OWNER, ALL SUCH LEAKS WHICH OCCUR AFTER COMPLETION OF THIS CONTRACT UPON 24 HOURS NOTICE THEREOF BY THE CONSTRUCTION MANAGER/GENERAL CONTRACTOR. LEAKS WHICH OCCUR PRIOR TO THE COMPLETION OF THIS CONTRACT SHALL BE REPAIRED AT ONCE. CONTRACTOR IS RESPONSIBLE FOR ANY DAMAGE CAUSED BY SUCH LEAKS AND THE REPAIR THEREOF AND WILL REIMBURSE THE CONSTRUCTION MANAGER/GENERAL CONTRACTOR FOR ALL EXPENSE INCURRED THEREBY. A Division of The Wall Consulting Group, Inc. All Rights Reserved. 2007- 2010 231 West 29th Street - Suite 606, New York, NY 10001 Tel: 212 . 967 . TWIG / Fax: 212 . 967 . 8945 info@twigcon.com www.twigcon.com - END - 2.15 HOSE BIBBS A. HOSE BIBBS SHALL BE CHICAGO FAUCET CO., NO. 293-6, POLISHED CHROME, OR APPROVED OTHER, WITH WATTS REGULATOR CO. NO BAC, 3/4" HOSE END VACUUM BREAKER. 2.16 UNDER COUNTER ICE MAKER (FURNISHED BY OTHERS) A. INSTALL THE UNDER COUNTER ICE MAKERS WHERE INDICATED ON THE DRAWING. PROVIDE 1/2" COLD WATER WITH GATE VALVE AND EXTEND 1" INDIRECT WASTE TO THE ADJACENT FLOOR DRAIN. 2.17 DISHWASHER (FURNISHED BY OTHERS) A. INSTALL DISHWASHER WHERE INDICATED ON THE DRAWINGS. PROVIDE NEW, ALL ROUGHING AND 1/2" HW SUPPLY WITH GATE VALVE, CHECK VALVE AND VACUUM BREAKER. EXTEND AND CONNECT HOSE TO "T" TAILPIECE AT SINK WASTE. 2.18 PLUMBING FIXTURES AND EQUIPMENT A. DOMESTIC COLD WATER, HOT WATER AND HOT WATER CIRCULATION PIPE SHALL BE TYPE "L", HARD DRAWN, COPPER TUBING WITH WROUGHT BRONZE FITTINGS FOR 150 POUND WATER WORKING PRESSURE AND WITH JOINTS OF 95-5 (TIN-ANTIMONY) SOLDER. NO SOLDER CONTAINING LEAD IS PERMITTED. D. DISINFECTION THE POTABLE WATER SYSTEM SHALL BE DISINFECTED PRIOR TO USE BY A METHOD OF DISINFECTION IN ACCORDANCE WITH THE NEW YORK CITY BUILDING CODE RS 16, P107-27. THE POTABLE WATER PURITY TEST RESULT FROM A NEW YORK CITY CERTIFIED TESTER SHALL BE SUBMITTED FOR ENGINEER'S REVIEW AND APPROVAL. 375 Beach 92nd Street Queens, NY 11693 C. VACUUM BREAKER - CAST BRASS CHROME PIPE IF EXPOSED TO PUBLIC VIEW SIMILAR TO WATTS NO. 800MCQT. (CONSTANT PRESSURE VACUUM BREAKER). 2.11 CONNECTION TO MISCELLANEOUS EQUIPMENT A. PROVIDE ALL NECESSARY PIPE, FITTINGS, VALVES, ETC. EXCEPT AS OTHERWISE SPECIFIED AND MAKE ALL FINAL PLUMBING PIPING CONNECTIONS, INCLUDING WASTE, VENT, HOT AND COLD WATER, ETC., TO ALL EQUIPMENT REQUIRING SAME, FURNISHED "UNDER ANOTHER SECTION OF THE SPECIFICATIONS ". 2.12 DRAINS A. IN GENERAL DRAINS SHALL BE JOSAM, ZURN, SMITH OR APPROVED OTHER. B. UNLESS OTHERWISE NOTED DRAINS SHALL BE DUCO COATED, CAST IRON, DOUBLE DRAINAGE PATTERNS, HUB AND SPIGOT, UNLESS OTHERWISE NOTED. DRAINS SHALL BE EQUIPMENT TO THE FIGURE NUMBERS SHOWN AND OF SIZE REQUIRED. C. FLOOR DRAINS SHALL BE JAY R. SMITH FIG. NO. 2005-A WITH SEDIMENT BUCKET, UNDER DECK CLAMP AND 8" DIAMETER NICKEL BRONZE TOP, WITH NO-HUB OUTLET CONNECTION. A. PLUMBING CONTRACTOR SHALL FURNISH AND INSTALL ALL PLUMBING FIXTURES AND APPLIANCES, UNLESS OTHERWISE NOTED, AND MAKE ALL FINAL CONNECTIONS AS REQUIRED. FIXTURE AS SELECTED BY ARCHITECT SUBMISSIONS 2.19 GREASE TRAP FURNISH & INSTALL JR SMITH 8050-ARO-B 100 LB GREASE TRAP, LIFT OUT SEDIMENT BUCKET, AND FLOW CONTROL FITING. DATE rev no issue 02.14.11 1 FILING & PRICING 2.20 HOT WATER HEATER A. WATER HEATER SHALL BE COMMERCIAL ELECTRIC MODEL DVE-120-30 AS MANUFACTURED BY THE A.O.SMITH MANUFACTURING COMPANY. HAVING AN INPUT OF (30) KW, 123 VOLTS, THREE PHASE AND A RECOVERY HEATER SHALL BE PREWIRED AND FACTORY TESTED AND IS U.L. LISTED. TANK SHALL BE LINED WITH A DOUBLE COATING OF EXCLUSIVE RHEEMGLASS HIGH TEMPERATURE GLASS FORMULA AND FURNISHED WITH AN ANDOE ROD RIGIDLY SUPPORTED. TANK SHALL BE DESIGNED FOR 150 PSI WORKING PRESSURE. TANK SHALL BE INSULATED WITH R-FOAM INSULATION AND BE DESIGNED TO MEET THE STANDBY LOSS REQUIREMENTS OF ASHRAE STANDARD 90. WATER HEATER TANK SHALL BE COVERED BY A LIMITED THREE YEAR WARRANTY AGAINST TANK FAILURE. MEA No. 177-83-E. project 375 Beach 92nd Street Queens, NY 11693 2.21 HOT WATER CIRCULATOR dwg title A. PROVIDE, WHERE INDICATED ON THE DRAWINGS, BELL AND GOSSETT, OR APPROVED OTHER, ALL BRONZE IN-THE-LINE CIRCULATOR, DIRECT CONNECTED TO 1/6HP, 100 V, SINGLE PHASE, 60 HERTZ MOTOR. PUMP SHALL BE SERIES SC-75 CAPABLE OF CIRCULATING 5 GALLONS PER MINUTE AT 8 FOOT OF HEAD PRESSURE. GROUND FLOOR PLUMBING SPECIFICATIONS B. CIRCULATING PUMP SHALL BE CONTROLLED BY MEANS OF AN IMMERSION TYPE AQUASTAT WITH VISIBLE SCALE AND DETACHABLE WELL, WHICH SHALL BE INSTALLED IN THE CIRCULATING LINE NEAR THE SUCTION INLET OF THE PUMP. THE AQUASTAT SHALL OPERATE ON 110 VOLTS AND SHALL BE SO DESIGNATED AND CONNECTED THAT THE CIRCULATING MOTOR WILL START AND STOP WITHIN THE seal & signature issue date 02/11/2011 project no. t10-12-0230 drawn by cadd checked by twig scale AS NOTED dwg. no. NYCECC NOTES: TO THE BEST OF MY KNOWLEDGE, BELIEF AND PROFESSIONAL JUDGMENT, THESE PLANS AND SPECIFICATIONS ARE IN COMPLIANCE WITH THE NEW YORK CITY ENERGY CONSERVATION CODE. THESE PLANS ARE APPROVED ONLY FOR THE WORK ON THE APPLICATION SPECIFICATION SHEET. ALL OTHER MATTERS SHOWN ARE NOT TO BE RELIED UPON OR TO BE CONSIDERED AS EITHER BEING APPROVED OR IN ACCORDANCE WITH APPLICABLE CODES. cad file sheet 2 of 6 375 Beach 92nd Street P-201.00.dwg NYC dob# project 375 Beach 92nd Street Queens, NY 11693 PLUMBING FIXTURE SCHEDULE PIPE SIZE (INCH) TRAP WASTE VENT C.W. MARK FIXTURE WC-1 WATER CLOSET INT. L-1 LAVATORY 1 1/2 1 1/2 1 1/2 L-2 LAVATORY 1 1/2 1 1/2 1 1/2 SS-1 SERVICE SINK 3 3 FD-1 FLOOR DRAIN 2 FS-1 FLOOR SINK KS-1 KS-2 H.W. GENERAL PIPING NOTES REMARKS 1. PROVIDE ALL MATERIALS AND EQUIPMENT AND PERFORM ALL LABOR REQUIRED TO INSTALL COMPLETE AND OPERABLE PIPING SYSTEMS AS INDICATED ON THE DRAWING. - FLUSH VALVE, HANDICAPPED 1/2 1/2 WALL MOUNT, HANDICAPPED 1/2 1/2 COUNTER MOUNT, HANDICAPPED 2 1/2 1/2 W/ WIRE GUARD 2 2 - - W/ DEEP SEAL P-TRAP 2 2 2 - - W/ DEEP SEAL P-TRAP KITCHEN SINK 2 2 2 1/2 1/2 TWO COMP., W/ DISPOSAL KITCHEN SINK 2 2 2 1/2 1/2 ONE COMP., W/ DISPOSAL 4 2 NOTE: CONTRACTOR TO FIELD VERIFY THE LOCATIONS AND EXISTING CONDITIONS OF PLUMBING RISERS AND PIPING TO BE RE-USED PRIOR TO SUBMISSION OF THE BID. 1/2 2. UNLESS OTHERWISE NOTED, ALL PIPING IS OVERHEAD, TIGHT TO THE UNDERSIDE OF STRUCTURE/SLAB, WITH SPACE FOR INSULATION AS SPECIFIED. 3. INSTALL PIPING SO THAT ALL VALVES, STRAINERS, UNIONS, TRAPS, FLANGES AND OTHER APPURTENANCES REQUIRING ACCESS ARE ACCESSIBLE. 4. ALL PIPING WORK SHALL BE COORDINATED WITH ALL TRADES INVOLVED OFFSETS IN PIPING AROUND OBSTRUCTIONS SHALL BE PROVIDED AT NO ADDITIONAL COST TO THE OWNER. architect 5. LOCATIONS OF EXISTING SANITARY SOIL AND VENT STACKS, HOT AND COLD WATER RISERS ARE APPROXIMATE. THE PLUMBING CONTRACTOR SHALL FIELD VERIFY EXACT LOCATIONS OF PLUMBING STACKS BEFORE COMMENCING HIS WORK. EXISTING 3 COMP SINK A Division of The Wall Consulting Group, Inc. All Rights Reserved. 2007- 2010 231 West 29th Street - Suite 606, New York, NY 10001 Tel: 212 . 967 . TWIG / Fax: 212 . 967 . 8945 info@twigcon.com www.twigcon.com KS-2 KS-1 HS HAND SINK FD-1 1 2"CW 1" GAS CONNECT TO EXISTING HW/CW SUBMISSIONS DATE rev no issue 02.14.11 1 FILING & PRICING FD-1 FD-1 CONNECT TO EXISTING GAS KS-1 3 COMP SINK WITH FLOOR MOUNTED EXISTING GREASE TRAP BELOW SS-1 L-1 WC-1 CONNECT TO EXISTING HW/CW CONNECT TO EXISTING HW/CW project 375 Beach 92nd Street Queens, NY 11693 FD (EXIST.) FD (EXIST.) dwg title GROUND FLOOR PLUMBING DOMESTIC WATER PIPING PLAN 1 21" M2 M M seal & signature issue date 02/11/2011 project no. t10-12-0230 drawn by cadd checked by twig scale AS NOTED M1 1" GAS SERVICE W/REG AND VENT 2"WATER MAIN METER dwg. no. GROUND FLOOR: PLUMBING DOMESTIC WATER PIPING PLAN SCALE: 3/16" = 1'-0" NYCECC NOTES: TO THE BEST OF MY KNOWLEDGE, BELIEF AND PROFESSIONAL JUDGMENT, THESE PLANS AND SPECIFICATIONS ARE IN COMPLIANCE WITH THE NEW YORK CITY ENERGY CONSERVATION CODE. THESE PLANS ARE APPROVED ONLY FOR THE WORK ON THE APPLICATION SPECIFICATION SHEET. ALL OTHER MATTERS SHOWN ARE NOT TO BE RELIED UPON OR TO BE CONSIDERED AS EITHER BEING APPROVED OR IN ACCORDANCE WITH APPLICABLE CODES. cad file sheet 3 of 6 375 Beach 92nd Street P-301.00.dwg NYC dob# project 375 Beach 92nd Street Queens, NY 11693 PLUMBING FIXTURE SCHEDULE PIPE SIZE (INCH) TRAP WASTE VENT C.W. MARK FIXTURE WC-1 WATER CLOSET INT. L-1 LAVATORY 1 1/2 1 1/2 1 1/2 L-2 LAVATORY 1 1/2 1 1/2 1 1/2 SS-1 SERVICE SINK 3 3 FD-1 FLOOR DRAIN 2 FS-1 FLOOR SINK KS-1 KS-2 H.W. GENERAL PIPING NOTES REMARKS 1. PROVIDE ALL MATERIALS AND EQUIPMENT AND PERFORM ALL LABOR REQUIRED TO INSTALL COMPLETE AND OPERABLE PIPING SYSTEMS AS INDICATED ON THE DRAWING. - FLUSH VALVE, HANDICAPPED 1/2 1/2 WALL MOUNT, HANDICAPPED 1/2 1/2 COUNTER MOUNT, HANDICAPPED 2 1/2 1/2 W/ WIRE GUARD 2 2 - - W/ DEEP SEAL P-TRAP 2 2 2 - - W/ DEEP SEAL P-TRAP KITCHEN SINK 2 2 2 1/2 1/2 TWO COMP., W/ DISPOSAL KITCHEN SINK 2 2 2 1/2 1/2 ONE COMP., W/ DISPOSAL 4 2 NOTE: CONTRACTOR TO FIELD VERIFY THE LOCATIONS AND EXISTING CONDITIONS OF PLUMBING RISERS AND PIPING TO BE RE-USED PRIOR TO SUBMISSION OF THE BID. 1/2 2. UNLESS OTHERWISE NOTED, ALL PIPING IS OVERHEAD, TIGHT TO THE UNDERSIDE OF STRUCTURE/SLAB, WITH SPACE FOR INSULATION AS SPECIFIED. 3. INSTALL PIPING SO THAT ALL VALVES, STRAINERS, UNIONS, TRAPS, FLANGES AND OTHER APPURTENANCES REQUIRING ACCESS ARE ACCESSIBLE. 4. ALL PIPING WORK SHALL BE COORDINATED WITH ALL TRADES INVOLVED OFFSETS IN PIPING AROUND OBSTRUCTIONS SHALL BE PROVIDED AT NO ADDITIONAL COST TO THE OWNER. architect 5. LOCATIONS OF EXISTING SANITARY SOIL AND VENT STACKS, HOT AND COLD WATER RISERS ARE APPROXIMATE. THE PLUMBING CONTRACTOR SHALL FIELD VERIFY EXACT LOCATIONS OF PLUMBING STACKS BEFORE COMMENCING HIS WORK. A Division of The Wall Consulting Group, Inc. All Rights Reserved. 2007- 2010 231 West 29th Street - Suite 606, New York, NY 10001 Tel: 212 . 967 . TWIG / Fax: 212 . 967 . 8945 info@twigcon.com www.twigcon.com FD-1 2"CW CO FS-1 CONNECT TO EXISTING WASTE (BELOW) AND VENT (ABOVE) SUBMISSIONS DATE rev no issue 02.14.11 1 FILING & PRICING FD-1 FD-1 L-1 WC-1 CONNECT TO EXISTING WASTE (BELOW) AND VENT (ABOVE) project 375 Beach 92nd Street Queens, NY 11693 dwg title GROUND FLOOR PLUMBING SANITARY PIPING LAYOUT seal & signature issue date 02/11/2011 project no. t10-12-0230 drawn by cadd checked by twig scale AS NOTED dwg. no. GROUND FLOOR: PLUMBING SANITARY PIPING PLAN SCALE: 3/16" =1'-0" NYCECC NOTES: TO THE BEST OF MY KNOWLEDGE, BELIEF AND PROFESSIONAL JUDGMENT, THESE PLANS AND SPECIFICATIONS ARE IN COMPLIANCE WITH THE NEW YORK CITY ENERGY CONSERVATION CODE. THESE PLANS ARE APPROVED ONLY FOR THE WORK ON THE APPLICATION SPECIFICATION SHEET. ALL OTHER MATTERS SHOWN ARE NOT TO BE RELIED UPON OR TO BE CONSIDERED AS EITHER BEING APPROVED OR IN ACCORDANCE WITH APPLICABLE CODES. cad file sheet 4 of 6 375 Beach 92nd Street P-302.00.dwg NYC dob# project 375 Beach 92nd Street Queens, NY 11693 POLISHED CHROME FINISHED 1 1/2" VENT (MIN.) (IN WALL) WALL REF ARCH 2" X 1 1/4" (FOR LAVS AND EDFS) 2" X 1 1/2" (FOR SINKS AND EYEWASHES) SANITARY TAPPED TEE. 1 1/4" (LAVS & EDFS) 1 1/2" (SINKS & EW) POLISHED CHROME PLATED P-TRAP 2'-0" x 2'-0" BLOCKOUT FLOOR LINE NON TRAFFIC GRATE TRAFFIC GRATE FLASHING CLAMP 2" WASTE (MIN.) (IN WALL) FULL GRATE UNLESS OTHERWISE SCHEDULED OR SPECIFIED DRAIN BODY 2" x 3" REDUCER REQUIRED FOR ALL FLOOR SINKS FOR COMBINATION WASTE AND VENT SYSTEM DOME STRAINER architect FLOOR SINK OUTLET (2" MINIMUM) NO HUB CLAMP (TYP.) 3" WASTE MINIMUM POLISHED CHROME PLATED BRASS NIPPLE 1/2" RAISED FLANGE POLISHED CHROME PLATED CAST BRASS ESCUTCHEON WITH SET SCREW A Division of The Wall Consulting Group, Inc. All Rights Reserved. 2007- 2010 2 1. 3. TYPICAL DRAIN PIPING DETAIL NOT TO SCALE FLOOR SINK DETAIL NOT TO SCALE 231 West 29th Street - Suite 606, New York, NY 10001 Tel: 212 . 967 . TWIG / Fax: 212 . 967 . 8945 info@twigcon.com STANDARD WEIGHT STEEL PIPE SLEEVE TO PASS PIPE "ELKAY" WATER FILTER WATER SENTRY Vll UNION TERMINATE SLEEVE FLUSH WITH FINISHED WALL SURFACES 3/4" IPS 1/2" C.W. SEAL OR CAULK SLEEVES THRU FIRE WALLS IN A SMOKE TIGHT MANNER. REFER TO SPECIFICATIONS TO FIXTURE www.twigcon.com SLEEVES ANS ESCUTCHEONS A. SLEEVES FOR PIPING THROUGH MASONRY WALLS SHALL BE SCHEDULE 40, STANDARD GALVANIZED STEEL PIPE; IN FRAMED PARTITIONS SHALL BE 20 GAUGE SHEET METAL. THE SPACE BETWEEN THE PIPE AND ITS SLEEVE SHALL NOT EXCEED ONE-HALF INCH. THE SLEEVE SHALL HAVE A SUFFICIENT LENGTH TO BE FLUSH WITH THE FINISHED WALL SURFACE. B. EXPOSED PIPING PASSING THROUGH WALLS, FLOORS OR CEILING SHALL BE FITTED WITH CHROMIUM-PLATED CAST BRASS ESCUTCHEONS WITH FASTENING SET SCREWS. CUTTING AND PATCHING A. PIPING PASSING THROUGH WALLS SHALL HAVE A TRIM OPENING CUT NO GREATER THAN NECESSARY FOR THE INSTALLATION OF A SLEEVE SECURED THEREIN. B. PIPING PASSING THROUGH CONCRETE FLOORS SHALL HAVE AN OPENING CORE DRILLED SO THAT THE SPACE BETWEEN THE OPENING AND THE PIPE SHALL NOT EXCEED ONE-HALF INCH. C. ANNULAR SPACES BETWEEN PIPING AND SLEEVES OR CORE DRILLED FLOOR OPENINGS SHALL BE PACKED WITH MINERAL WOOL AND SEALED, TO RETAIN THE FIRE INTEGRITY OF THE WALLS AND FLOORS, WITH A NON-HARDENING COMPOUND SIMMILAR OR EQUAL TO DUXSEAL AS MANUFACTURED BY THE J.M. CLIPPER CORP. 1/2" CLEAR MAXIMUM FINISHED ESCUTCHEON PLATE FLUSH AGAINST WALL AND OF SIZE TO COMPLETELY COVER OPENING (TYP. FOR EACH SIDE) ADAPTER AS REQUIRED 13" MIN. CLEARANCE FINISHED WALL SURFACE CONCEALED PIPING 4. 5. POINT-OF-USE DOMESTIC WATER FILTER NOT TO SCALE PIPING EXPOSED TO VIEW TYPICAL DETAIL OF PIPE INSTALLATION THRU' RATED WALL NOT TO SCALE WOOD JOIST 3 4 20" 20" OR TRUSS ATTACHMENT DHW DCW NOTE: ALL EXPOSED PIPING AND FITTING SHALL BE CHROME PLATED. SUPPORT SINK AGAINST WALL WITH "Z" CLAMPS SUPPLIED BY SINK MANUFACTURER. SIDE BEAM PIPING TO BE CONCEALED IN WALL. 20" STAINLESS STEEL 3 COMPARTMENT SINK SUBMISSIONS BOLT SIZES IN ACCORDANCE WITH NFPA-13 CHICAGO FAUCET, SERVICE SINK FITTING #897, (BY CONTR.) STORAGE REEL (BY OWNER) UNDER RIGHT DRAIN BOARD. TYPICAL FOR ALL 3-COMP. SINKS DATE rev no issue 02.14.11 1 FILING & PRICING THREADED ROD ADJUSTABLE SWIVEL LOOP HANGER DOUBLE LOCKNUTS CLEVIS HANGER SHEET ROCK CEILING TYPE L HARD DRAWN COPPER FLOOR LINE AIR GAP FLOOR SINK GALVANIZED METAL SHIELD INSULATION SUPPLY STOPS project 3/16"X1-1/2" 3/16"X2" WOOD SCREW TOGGLE BOLT INTO BOTTOM OF JOIST WITH INCOMPRESSIBLE INSULATING BLOCK AT HANGER PIPE DIAMETER PATCH AND REPAIR 20 GAUGE GALVANIZED CEILING TO MATCH SHEET METAL SECURITY EXISTING WITHOUT INCOMPRESSIBLE INSULATING BLOCK AT HANGER SHIELD THICKNESS PIPE DIAMETER SHIELD LENGTH UP TO 3" 12" 18 USSG 6" 18 USSG 4" TO 6" 8" 16 USSG 4" 15" 16 USSG 12" 16 USSG 5" 18" 21" 16 USSG 24" 14 USSG 6" DECO SHIELD IS APPROVED SHIELD THICKNESS UP TO 3" 8" & LARGER SHIELD PAINTED TO MATCH SHIELD LENGTH NOTES: 375 Beach 92nd Street Queens, NY 11693 8"& LARGER dwg title GROUND FLOOR PLUMBING DETAILS 16 USSG FOR ALL PIPE 2" AND SMALLER SHIELD SHALL COVER ALL EXPOSED PIPING. 6. 3 COMPARTMENT SINK CONNECTION DETAIL NOT TO SCALE 7. TYPICAL PIPE SUPPORT & SHIELD DETAIL NOT TO SCALE 1. HANGER, ROD AND INSERT SHALL BE DIPPED IN ZINC CHROMATE PRIMER PRIOR TO INSTALLATION. 8. seal & signature TYPICAL INSULATED PIPE SUPPORT NOT TO SCALE issue date 02/11/2011 project no. t10-12-0230 drawn by cadd checked by twig scale AS NOTED dwg. no. NYCECC NOTES: TO THE BEST OF MY KNOWLEDGE, BELIEF AND PROFESSIONAL JUDGMENT, THESE PLANS AND SPECIFICATIONS ARE IN COMPLIANCE WITH THE NEW YORK CITY ENERGY CONSERVATION CODE. THESE PLANS ARE APPROVED ONLY FOR THE WORK ON THE APPLICATION SPECIFICATION SHEET. ALL OTHER MATTERS SHOWN ARE NOT TO BE RELIED UPON OR TO BE CONSIDERED AS EITHER BEING APPROVED OR IN ACCORDANCE WITH APPLICABLE CODES. cad file sheet 5 of 6 375 Beach 92nd Street P-401.00.dwg NYC dob# project 375 Beach 92nd Street Queens, NY 11693 CONNECT TO EXISTING RISERS architect ~ ~ EXISTING 34" HW/CW EXISTING 34" HW/CW 1/2" 1" 1" 3a 5" 1" 5 3b ~~ ~~ 1" 1/2" 1r" ~~ ~~ 5" ~~ ~ ~ 1" LAV 1" 24 WC 25 25 A Division of The Wall Consulting Group, Inc. All Rights Reserved. 2007- 2010 1/2" 231 West 29th Street - Suite 606, New York, NY 10001 Tel: 212 . 967 . TWIG / Fax: 212 . 967 . 8945 GROUND FLOOR info@twigcon.com www.twigcon.com VACUUM BREAKER TO ICE MAKER DOMESTIC WATER RISER DIAGRAM NOT TO SCALE 1 21" 11" ~ ~ ~ ~ ~ ~ ~ ~ ~ ~ 5 3b 3a 2" CONNECT TO EXISTING 2" VENT 1 21" 25 24 25 WC C.O 3" FS 3"FD 3"FD GROUND FLOOR EXISTING 4" WASTE PIPING ~ ~ ~ ~ ~ ~ ~ ~ ~ ~ ~ ~ ~ ~ EXISTING 4" W EXISTING 4" WASTE PIPING SANITARY RISER DIAGRAM NOT TO SCALE PLUMBING FIXTURE SCHEDULE STOVE TOP EXISTING 34" GAS CONNECT TO EXISTING GAS 1 41" 3/4" 3/4" 3/4" 3/4" 3/4" 3/4" 3/4" 20 1 2 3A 3b 4 WATER CLOSET INT. 4 2 1/2 - FLUSH VALVE, HANDICAPPED WC-2 WATER CLOSET INT. 4 2 1/2 - FLUSH VALVE L-1 LAVATORY 1 1/2 1/2 WALL MOUNT, HANDICAPPED 1 1/2 SS-1 SERVICE SINK 3 3 FD-1 FLOOR DRAIN 3 FD-2 FLOOR DRAIN FS-1 M EXIST. 5 EXIST. WC-1 TRAP 1 1/2 3/4" M FIXTURE LAVATORY 1 21" 3/4" PIPE SIZE (INCH) WASTE VENT C.W. MARK L-2 1 1/2 1 1/2 REMARKS SUBMISSIONS 1/2 1/2 COUNTER MOUNT, HANDICAPPED 2 1/2 1/2 W/ WIRE GUARD 3 2 - - W/ DEEP SEAL P-TRAP 4 4 2 - - W/ DEEP SEAL P-TRAP FLOOR SINK 2 2 2 - - W/ DEEP SEAL P-TRAP TD-1 TRENCH DRAIN 4 4 2 - - W/ DEEP SEAL P-TRAP WF-1 WASH FOUNTAIN 2 DF-1 DRINK FOUNTAIN 2 2 WH-1 WATER HEATER - - KS-1 KITCHEN SINK 2 KS-2 KITCHEN SINK HA-1 HAMMER ARES 2 1 1/2 1/2 H.W. 2 3/4 3/4 HANDICAPPED 1 1/2 1/2 - HANDICAPPED - 1 1 W/ EXPANSION TANK 2 2 1/2 1/2 TWO COMP., W/ DISPOSAL 2 2 2 1/2 1/2 ONE COMP., W/ DISPOSAL - - - 3/4 3/4 END OF EACH LINE DATE rev no issue 02.14.11 1 FILING & PRICING GROUND FLOOR 3 4" (TYP.) 1" GAS W/REG+ VENT FROM SERVICE UTILITY EXISTING BOILERS+HOT WATER HEATERS ~ LAV 1 21" ~ ~ ~ ~ 11" CONNECT TO EXISTING 2" VENT ~ CONNECT TO EXISTING 2" VENT NEW ADA BATH NOTE: CONTRACTOR TO FIELD VERIFY THE LOCATIONS AND EXISTING CONDITIONS OF PLUMBING RISERS AND PIPING TO BE RE-USED PRIOR TO SUBMISSION OF THE BID. project 375 Beach 92nd Street Queens, NY 11693 dwg title GROUND FLOOR PLUMBING RISER DIAGRAMS seal & signature GAS RISER DIAGRAM NOT TO SCALE issue date 02/11/2011 project no. t10-12-0230 drawn by cadd checked by twig scale AS NOTED dwg. no. NYCECC NOTES: TO THE BEST OF MY KNOWLEDGE, BELIEF AND PROFESSIONAL JUDGMENT, THESE PLANS AND SPECIFICATIONS ARE IN COMPLIANCE WITH THE NEW YORK CITY ENERGY CONSERVATION CODE. THESE PLANS ARE APPROVED ONLY FOR THE WORK ON THE APPLICATION SPECIFICATION SHEET. ALL OTHER MATTERS SHOWN ARE NOT TO BE RELIED UPON OR TO BE CONSIDERED AS EITHER BEING APPROVED OR IN ACCORDANCE WITH APPLICABLE CODES. cad file sheet 6 of 6 375 Beach 92nd Street P-501.00.dwg NYC dob# SPRINKLER HEAD LOCATIONS SPRINKLER DEMOLITION NOTES 1. AREAS WITH SUSPENDED CEILINGS - AREAS WITH NO SUSPENDED CEILINGS STANDARD UPRIGHT - RELIABLE MODEL GFR 'QUICK RESPONSE', AUTOMATIC SPRINKLER, 1/2" ORIFICE, 5.6 K FACTOR, NYC MEA NUMBER 258-93-E B. SPRINKLER DESIGN CRITERIA BUILDING IS CLASSIFIED IN 'E' OCCUPANCY GROUP (LIGHT HAZARD) WITH INCIDENTAL STORAGE SPACES AND MECHANICAL SPACES (CLASSIFIED AS ORDINARY HAZARD GROUP 1). THERE ARE NO AREAS CLASSIFIED AS 'EXTRA HAZARD' C. LIGHT HAZARD OCCUPANCY(OFFICE AREAS, TOILET ROOMS LOBBY AREAS)) 1500 SQ. FT. (REMOTE AREA) AREA OF APPLICATION: 225 SQ. FT. MAXIMUM COVERAGE PER SPRINKLER: 0.10 GPM PER SQUARE FOOT DESIGN DENSITY: 15'-0" MAXIMUM SPACING BETWEEN SPRINKLERS: 1/2 OF ALLOWABLE DISTANCE BETWEEN SPRINKLERS DISTANCE BETWEEN SPRINKLERS & WALLS: 2. ORDINARY HAZARD (GROUP 1) OCCUPANCY(STORAGE ROOMS, MECHANICAL & ELECTRICAL EQUIPMENT SPACES) B. C. SITE PLAN: 375 BEACH 92ND STREET, QUEENS , NY SUBMISSION OF A PROPOSAL WILL BE CONSTRUED AS EVIDENCE THAT THE ABOVE SITE EXAMINATION HAS BEEN MADE AND LATER CLAIMS WILL NOT BE RECOGNIZED FOR EXTRA LABOR, EQUIPMENT OR MATERIALS REQUIRED BECAUSE OF DIFFICULTIES ENCOUNTERED WHICH COULD HAVE BEEN FORESEEN HAD SUCH AN EXAMINATION BEEN MADE. DEMOLITION WORK SHALL INCLUDE ALL MATERIALS, LABOR, EXTENSIONS, CONNECTIONS, CUTTING, REPAIRING, ADAPTING AND OTHER FIRE PROTECTION WORK REQUIRED TO MAINTAIN SERVICE PENDING THE COMPLETION OF THE PERMANENT WORK. COORDINATE THE EXTENT OF DEMOLITION WORK WITH THE ARCHITECT AND BUILDING MANAGEMENT. ALL EXISTING WORK REQUIRED TO REMAIN BUT INTERFERING WITH PROPOSED NEW FIRE PROTECTION (AS WELL AS ELECTRICAL, MECHANICAL AND GENERAL CONSTRUCTION WORK) SHALL BE RELOCATED AND RECONNECTED USING MATERIALS CONFORMING TO STANDARDS OF THIS CONTRACT. REMOVE ALL SPRINKLER HEADS, PIPING, VALVING AND HANGERS ASSOCIATED WITH PIPING TO BE REMOVED BACK TO MAINS. IDENTIFY ALL PIPING BY SERVICE TYPE AND CAP AT MAINS. REMOVE EXISTING SPRINKLER WORK AS INDICATED BELOW: a. b. NORTH BLOCK #: 16109 LOT #: 43 c. D. E. AY AB JA PRIOR TO PROPOSAL SUBMISSION, THIS CONTRACTOR SHALL VISIT THE SITE TO REVIEW THE EXISTING CONDITIONS ASSOCIATED WITH THE SCOPE OF WORK AND ADJACENT AREAS TO ASCERTAIN THE DIFFICULTIES WHICH WILL AFFECT THE EXECUTION OF THE WORK OF THIS CONTRACT. IC MA F. G. REMOVE ALL EXISTING SPRINKLER WORK BACK TO RISER AND CAP, OR AS NOTED ON DRAWINGS. CONTRACTOR TO CONTACT BUILDING MANAGEMENT AND TENANT REGARDING REMOVAL SCOPE OF WORK TO MAINTAIN CONTINUITY OF ALL SERVICES TO ALL TENANTS WHO ARE TO REMAIN OPERATIONAL AND NOT BE AFFECTED BY DEMOLITION WORK. ALL EXISTING BUILDING SPRINKLER VALVES SHALL REMAIN. PROVIDE ADDITIONAL SUPPORT FOR ALL EXISTING PIPING TO REMAIN WHICH ARE AFFECTED BY DEMOLITION OF EXISTING CEILING AND PARTITIONS. ALL MATERIALS AND EQUIPMENT SHALL BE DISPOSED OF IN ACCORDANCE WITH APPLICABLE LAWS AND ENVIRONMENTAL REGULATIONS. COORDINATE WITH OWNER TO DETERMINE WHETHER EQUIPMENT IS TO BE TURNED OVER FOR FUTURE USE AND STORED IN THEIR ASSOCIATED STORAGE LOCATIONS. WHEN EXISTING SPRINKLER SYSTEM IS DEACTIVATED THIS CONTRACTOR TO PROVIDE A TEMPORARY SPRINKLER LOOP AROUND THE CORE OR PROVIDE A 24 HOUR FIRE-WATCH UNTIL NEW SPRINKLER SYSTEM BECOMES ACTIVE. INCLUDE ALL IN BID PRICE. SPRINKLER NOTES 1. 5 37 SN 92 R N D EL ET RE ST AN H HC THIS CONTRACTOR SHALL PROVIDE FIRE PROTECTION THROUGHOUT THE ENTIRE SPACE WITHIN THE SCOPE OF WORK AS REQUIRED BY THE LOCAL CODES, LOCAL FIRE DEPARTMENT REGULATIONS, BUILDING MANAGEMENT REQUIREMENTS AND NFPA 13 FOR THE DURATION OF THE PROJECT. ANY TEMPORARY FIRE PROTECTION SHALL BE REMOVED UPON ACTIVATION OF PERMANENT FIRE PROTECTION SYSTEM. THE INSTALLATION COMPONENT, SIZING, SPACING, CLEARANCES, POSITION AND TYPE OF SYSTEMS SHALL CONFORM TO APPENDIX Q SECTION BC Q102 AND SECTION BC 903. 2. ONLY APPROVED MATERIALS SHALL BE USED AS PER CHAPTER 6 OF APPENDIX Q SECTION BC Q102. 3. DIRECT CONNECTION OF SPRINKLERS TO THE PUBLIC WATER SYSTEM SHALL CONFORM TO SECTION BCQ 102.1 SEE 15.2.1 AND 15.1.1 (d). 4. SPRINKLER SHALL BE PROTECTED AGAINST FREEZING AND INJURY AS PER APPENDIX Q BC Q102. SEC. 8.15.3 AND 6.2.8. 5. INSPECTIONS AND TESTS OF SPRINKLERS SHALL BE CONDUCTED AS PER SEC. 901.5 AND APPENDIX Q SEC. BC Q102. CH. 16. 6. THE OCCUPANCY OF THE AREAS TO BE SPRINKLERED IN ACCORDANCE WITH SECTIONS 5.2 AND A.5.2 OF APPENDIX Q SECTION BCQ102. 7. WATER SUPPLY TEST PIPES AND GAUGES SHALL BE PROVIDED AS PER SECTION 8.16.1 AND 8.16.4 OF APPENDIX Q SECTION BC Q102. 8. 9. PIPING, FITTING, SPECIFICATIONS, PIPE SCHEDULES, SYSTEM TEST PIPES, PROTECTION AGAINST CORROSION, DAMAGE, VALVES, HANGERS, SPRINKLER GUARDS AND SHIELDS SHALL BE AS PER APPENDIX Q SECTION BC Q102, CHAPTERS 6 AND 9. STOCK OF EXTRA SPRINKLERS SHALL BE FURNISHED AS PER SECTION 6.2.9 APPENDIX Q SECTION BC Q102 (REQUIRED FOR EACH TEMPERATURE RATING). 10. SPRINKLER ALARM WILL BE IN ACCORDANCE WITH SECTION 8.16.1 OF APPENDIX Q SECTION BC Q102. 3. 12. ALL BLIND SPACES EXCEEDING 6" IN WIDTH OR DEPTH WHICH CONTAIN COMBUSTIBLE MATERIAL WILL BE SPRINKLERED. 13. ALL PIPING PASSING THROUGH WALLS WILL COMPLY WITH SECTION BC712. 14. THERE IS NO HIGH PILED STORAGE AS DEFINED IN SECTION 3-3.12 OF APPENDIX Q SECTION BC Q102. NEW YORK CITY ADDITIONAL SPRINKLER NOTES NOTES: MODIFICATION OF AN EXISTING SYSTEM REFERENCES: BUILDING CODE, 2008 EDITION AND NFiPA-13-2002 AS MODIFIED BY THE NEW YORK CITY BUILDING CODE SEC 903 AND APPENDIX Q. 2. SPRINKLER HEAD ORIFICE SIZES, TYPE, AND DEFLECTOR POSITIONS FOR MODIFICATIONS OF AN EXISTING SYSTEM SHALL REMAIN THE SAME. SPRINKLER MODIFICATIONS SHALL NOT ALTER THE TYPE OF SPRINKLER SYSTEM. 3. SPRINKLER PIPING RELOCATION SHALL NOT AFFECT THE OPERATION OF THE SPRINKLER SYSTEM. 4. THE HAZARD OCCUPANCY FOR THIS SPRINKLER SYSTEM UNDER THIS APPLICATION SHALL REMAIN THE SAME. 5. SPRINKLER MODIFICATIONS SHALL NOT AFFECT THE HYDRAULICALLY DESIGNED AREA OF APPLICATION OF THE FLOOR. SPECIAL INSPECTIONS - NYC ONLY SPRINKLER SYSTEM 1. 2. NEW AND ALTERED SPRINKLER SYSTEMS SHALL BE INSPECTED IN ACCORDANCE WITH NYC BUILDING CODE SECTION 903. THIS CONTRACTOR OR PERMIT HOLDER FOR THE SPRINKLER WORK SHALL PERFORM ALL REQUIRED ACCEPTANCE TESTS, COMPLETE AND SIGN THE APPROPRIATE CONTRACTOR'S MATERIAL AND TEST CERTIFICATES. THE SPECIAL INSPECTOR SHALL WITNESS ALL REQUIRED TESTS AND SHALL VERIFY THAT ALL INSTALLATIONS OF ALL MATERIALS, FITTINGS, HANGERS, ASSEMBLIES AND SIGNAGE ARE IN ACCORDANCE WITH THE APPROVED CONSTRUCTIONS DOCUMENTS AND THE CONTRACTOR HAS TRANSMITTED REQUIRED MAINTENANCE LITERATURE AND INSTRUCTIONS TO THE OWNER. THE SPECIAL INSPECTOR SHALL VERIFY THE MATERIAL AND TEST CERTIFICATION FORMS HAVE BEEN TRANSMITTED TO THE FIRE DEPARTMENT AND THE DEPARTMENT OF BUILDINGS. THE SPECIAL INSPECTOR SHALL BE HIRED DIRECTLY BY THE OWNER OR THE GENERAL CONTRACTOR. COST FOR THE SPECIAL INSPECTOR SHALL BE INCLUDED AS PART OF THE SPRINKLER CONTRACTORS OVERALL BID AND BE BROKEN OUT SO THE OWNER AND OR GENERAL CONTRACTOR CAN HIRE THE SPECIAL INSPECTOR DIRECTLY WITH THE FUNDS PROVIDED UNDER THE SPRINKLER CONTRACTORS BID. 2. NEW AND ALTERED STANDPIPE SYSTEMS SHALL BE INSPECTED IN ACCORDANCE WITH NYC BUILDING CODE SECTION 905. THIS CONTRACTOR OR PERMIT HOLDER FOR THE STANDPIPE WORK SHALL PERFORM ALL REQUIRED ACCEPTANCE TESTS, COMPLETE AND SIGN THE APPROPRIATE CONTRACTOR'S MATERIAL AND TEST CERTIFICATES. THE SPECIAL INSPECTOR SHALL WITNESS ALL REQUIRED TESTS AND SHALL VERIFY THAT ALL INSTALLATIONS OF ALL MATERIALS, FITTINGS, HANGERS, ASSEMBLIES AND SIGNAGE ARE IN ACCORDANCE WITH THE APPROVED CONSTRUCTIONS DOCUMENTS AND THE CONTRACTOR HAS TRANSMITTED REQUIRED MAINTENANCE LITERATURE AND INSTRUCTIONS TO THE OWNER. THE SPECIAL INSPECTOR SHALL VERIFY THE MATERIAL AND TEST CERTIFICATION FORMS HAVE BEEN TRANSMITTED TO THE FIRE DEPARTMENT AND THE DEPARTMENT OF BUILDINGS. H EXISTING HEAD TO BE REMOVED AND CAPPED R 4. STANDPIPE SYSTEMS IN BUILDINGS USE FOR HIGH-PILED COMBUSTIBLE STORAGE SHALL BE IN ACCORDANCE WITH THE NYC FIRE CODE. 5. INSTALLATION OF STANDPIPE SYSTEMS SHALL COMPLY WITH THE SPECIAL INSPECTION REQUIREMENTS OF CHAPTER 17 OF NYC BUILDING CODE. NEW CONCEALED PENDENT SPRINKLER HEAD 6. CONSTRUCTION DOCUMENTS FOR STANDPIPE SYSTEMS SHALL CONTAIN PLANS THAT INCLUDE THE INFORMATION AND DATA LISTED IN SEC. 905.1.1 OF NYC BUILDING CODE. EXISTING PENDENT SPRINKLER HEAD 7. ANY SPACE OR ROOM THAT CONTAINS EQUIPMENT OF SUCH NATURE THAT THE USE OF WATER WOULD BE INEFFECTIVE IN FIGHTING A FIRE THEREIN OR WOULD BE OTHERWISE HAZARDOUS, SHALL HAVE A CONSPICUOUS SIGN ON EACH DOOR OPENING ON SUCH SPACE OR ROOM STATING THE NATURE OF THE USE AND THE WARNING: "IN CASE OF FIRE, USE NO WATER." SMOKE DETECTOR NEW CONCEALED PENDENT SPRINKLER HEAD-PREACTION P STANDPIPE SYSTEMS SHALL BE INSTALLED WHERE REQUIRED BY SECTION 905.3.1 THROUGH 905.3.6 AND IN THE LOCATIONS INDICATED IN SECTIONS 905.4, 905.5 AND 905.6. 9. STANDPIPE SYSTEMS ARE PERMITTED TO BE COMBINED WITH AUTOMATIC SPRINKLER SYSTEMS. SEC. 905.3 OF NYC BUILDING CODE. HEAT DETECTOR SPRINKLER PREACTION VALVE SPRINKLER DELUGE VALVE 11. architect SPRINKLER DRY PIPE VALVE 10. THE LOCATION OF CLASS I STANDPIPE HOSE CONNECTION SHALL COMPLY WITH SEC. 905.4 OF NYC BUILDING CODE. MANUAL PULL STATION MANUAL ABORT STATION WHERE THE MOST REMOTE PORTION OF A FLOOR OR STORY IS MORE THAN 150 FEET FROM A HOSE CONNECTION, ADDITIONAL HOSE CONNECTIONS SHALL BE PROVIDED IN APPROVED LOCATIONS, SEC. 905.4. FIRE HOSE CABINET 12. CLASS I MANUAL DRY STANDPIPES ARE ALLOWED IN OPEN PARKING GARAGE, SHALL BE PROVIDED THAT THE HOSE CONNECTIONS ARE LOCATED AS REQUIRED FOR CLASS II STANDPIPES IN ACCORDANCE WITH SEC. 905.5. FIRE HOSE RACK FIRE HOSE RACK/SPRINKLER 13. STANDPIPE OUTLETS MAY BE OMITTED IN PORTIONS OF FIRST FLOORS OR BASEMENTS THAT ARE COMPLETELY SEPARATED FROM THE ENTRANCE HALL OR ENCLOSED STAIRWAYS LEADING TO THE UPPER FLOORS, PROVIDED THAT POTABLE FIRE EXTINGUISHERS ARE INSTALLED, SUBJECT TO THE APPROVAL OF THE FIRE COMMISSIONER, SEC. 905.3.1. SIAMESE CONNECTION SPRINKLER PLUG FIRE EXTINGUISHER 16. PREACTION TROUBLE HORN A Division of The Wall Consulting Group, Inc. All Rights Reserved. 2007- 2010 FLOOR CONTROL VALVE ASSEMBLY (FCVA) VALVE TAMPER SWITCH 17. ALL PIPES PASSING THROUGH FOUNDATION WALLS SHALL BE PROTECTED AS PROVIDED BY SECTION 305.5 OF THE PLUMBING CODE. 18. THIS APPLICATION IS NOT FILED AS A RESULT OF BY THE FIRE COMMISSIONER AS AUTHORIZED BY BS&A TO MODIFY THE CERTIFICATE OF OCCUPANCY NOR IS SUCH ACTION PENDING. 19. ALL VALVES SHALL BE IDENTIFIED AS REQUIRED BY SECTION 6-7.4 OF APPENDIX Q SECTION BC Q102. 20. DRAINAGE SHALL CONFORM TO SECTION 8.15.2 OF APPENDIX Q SECTION BC Q102. 21. A ONE PIECE REDUCING FITTING OF GOOD DESIGN SHOULD BE USED WHEREVER A CHANGE IS MADE IN THE SIZE OF PIPE, AS PER SECTION 6.4.6 OF APPENDIX Q SECTION BCQ102. 22. ALL VALVES ON CONNECTIONS TO WATER SUPPLY TO SPRINKLER SHALL BE APPROVED OS&Y OR APPROVED INDICATOR TYPE. 25. PROVISIONS SHALL BE MADE TO FACILITATE FLUSHING SYSTEM PIPING BY PROVIDING FLUSHING CONNECTION CONSISTING OF A CAPPED NIPPLE 4" LONG ON END OF A CROSS MAIN AS PER SECTION 9.14.16 OF APPENDIX Q SECTION BCQ102. CLASS I STANDPIPE HOSE CONNECTIONS SHALL BE PROVIDED IN ALL LOCATIONS PER SEC. 905.4 OF NYC BUILDING CODE. info@twigcon.com 18. SPRINKLER LINE REPRESENTATION PROTECTION OF RISERS AND LATERALS OF CLASS I STANDPIPE SYSTEM SHALL COMPLY WITH SEC. 905.4.1 OF NYC BUILDING CODE. NEW SPRINKLER PIPING EXISTING SPRINKLER PIPING 19. CLASS II STANDPIPE HOSE CONNECTIONS SHALL BE ACCESSIBLE AND LOCATED SO THAT ALL PORTIONS OF THE BUILDING ARE WITHIN 30 FEET (9144 mm) OF A NOZZLE ATTACHED TO 100 FEET (30480 mm) OF HOSE. EXISTING SPRINKLER PIPING TO BE REMOVE AND DISCARDED REMOVE EXISTING SPRINKLER HEAD AND ASSOCIATED DROP NIPPLES BACK TO HORIZONTAL PIPING AND EXTEND NEW PIPING TO NEW HEAD LOCATION AS REQUIRED. 20. IN FULLY SPRINKLERED BUILDINGS HAVING A COMBINED STANDPIPE SYSTEM THAT IS HYDRAULICALLY CALCULATED, THE MINIMUM STANDPIPE SIZE IN BUILDINGS WITH FLOOR HEIGHTS LESS THAN 150 FT. ABOVE THE LOWEST LEVEL OF FIRE DEPARTMENT VEHICLE ACCESS SHALL BE 4 IN. SEC. 7.6.3 OF APPENDIX Q. SPRINKLER DRAWING NOTATIONS 21. CLASS III STANDPIPE SYSTEMS SHALL HAVE HOSE CONNECTIONS LOCATED AS REQUIRED FOR CLASS I STANDPIPES IN SEC. 905.4 AND SHALL HAVE CLASS II HOSE CONNECTIONS AS REQUIRED IN SEC. 905.5. 22. CABINETS CONTAINING FIRE-FIGHTING EQUIPMENT SUCH AS STANDPIPES, FIRE HOSES, FIRE EXTINGUISHERS OR FIRE DEPARTMENT VALVES SHALL NOT BE BLOCKED FROM USE OR OBSCURED FROM VIEW. # DRAWING NOTE TAG A B SECTION DESIGNATION ON DRAWING WHERE SECTION IS CUT A-SECTION DESIGNATION B-DRAWING NO. STANDPIPE SYSTEMS ARE REQUIRED DURING CONSTRUCTION, ALTERATION AND DEMOLITION OPERATIONS SHALL BE PROVIDED IN ACCORDANCE WITH SEC. 3303.8 OF NYC BUILDING CODE. 24. SPRINKLER RISER DESIGNATION 26. SPRINKLER SHALL BE AN APPROVED TYPE AS PER SECTION 8.3 OF APPENDIX Q SECTION BC Q102. CLASS II STANDPIPE SYSTEMS ARE PERMITTED FOR HIGH PILE AND RACK STORAGE OCCUPANCIES ONLY. SEC. 3.3.27.2 OF APPENDIX Q. 25. REVISION SYMBOL 27. TEMPERATURE RATING SHALL COMPLY WITH SECTION 8.3 OF APPENDIX Q SECTION BC Q102. FITTINGS SHALL BE EXTRA-HEAVY PATTERN WHERE PRESSURES EXCEED 175 PSI (12.1 BAR). SEC. 4.3.3 OF NFPA 14-2003. 26. PROTECTION OF STANDPIPE SYSTEM WHERE A STANDPIPE OR LATERAL PIPE THAT IS NORMALLY FILLED WITH WATER PASSES THROUGH AN AREA SUBJECT TO FREEZING TEMPERATURES IT SHALL BE PROTECTED TO MAINTAIN THE TEMPERATURE OF THE WATER IN THE PIPING BETWEEN 40 F AND 120 F (4.4 C AND 48.9 C). SEC. 6.1.2.3 OF NFPA 14-2003. 28. 18" MINIMUM CLEARANCE TO BELOW SPRINKLER DEFLECTOR AS PER SECTION 8.5.6 OF APPENDIX Q SECTION BC Q102. 27. FIRE DEPARTMENT CONNECTIONS SHALL BE LOCATED NOT LESS THAN 18 IN. NOR MORE THAN 36 IN. ABOVE THE LEVEL OF THE ADJOINING GROUND, SIDEWALK OR GRADE SURFACE. SEC. 6.3.6 OF NFPA 14-2003. 30. SPRINKLER SYSTEM COMPLIES WITH NFPA 13-2002 AS MODIFIED BY APPENDIX Q SECTION BCQ102. 28. 31. SOURCES OF WATER SUPPLY FOR SPRINKLER SYSTEMS AS PER CHAPTER 15 OF APPENDIX Q SECTION BC Q102. THE MAXIMUM PRESSURE AT ANY POINT IN THE SYSTEM AT ANY TIME SHALL NOT EXCEED 350 PSI (24.1 BAR). SEC. 7.2 OF NFPA 14-2003. 29. BRANCH LINE SHALL BE SIZED BASED ON THE HYDRAULIC CRITERIA ESTABLISHED IN SEC. 7.8 & 7.10 BUT NOT LESS THAN 144" IN. (65 mm). SEC. 7.6.4 OF NFPA 14-2003. 32. PIPE SCHEDULE SYSTEMS SHALL BE IN ACCORDANCE WITH SECTION 14.5 OF APPENDIX Q SECTION BC Q102. 33. AUTOMATIC INTERLOCK CUTOFF SWITCH FOR VENTILATION WILL CONFORM TO CHAPTER 6 OF THE MECHANICAL CODE (APPLICABLE ONLY IF THERE IS AN AIR SYSTEM UTILIZING RECIRCULATED AIR AND REQUIRING A THERMOSTATIC DEVICE). 30. 31. 34. HYDRAULICALLY DESIGNED SPRINKLER SYSTEMS SHALL BE IN ACCORDANCE WITH CHAPTER 14 OF APPENDIX Q SECTION BCQ102. 35. MINIMUM BRANCH PIPE SIZE TO BE ONE INCH (1"). 36. THIS APPLICATION IS MADE ONLY FOR WORK INDICATED ON THE SPECIFICATION SHEET. ALL OTHER MATTERS SHOWN ARE NOT TO BE RELIED UPON OR TO BE CONSIDERED AS EITHER BEING APPROVED OR IN ACCORDANCE WITH APPLICABLE CODES. www.twigcon.com PREACTION 10" BELL/STROBE ALARM 23. 29. SPACING AND LOCATION OF SPRINKLERS SHALL COMPLY WITH CHAPTER 8 OF APPENDIX Q SECTION BCQ102. 231 West 29th Street - Suite 606, New York, NY 10001 Tel: 212 . 967 . TWIG / Fax: 212 . 967 . 8945 PREACTION 6" BELL FOR SUPERVISION 17. WHERE THE ROOF HAS A SLOPE OF LESS THAN 4 IN 12, EACH STANDPIPE SHALL BE PROVIDED WITH A HOSE CONNECTION LOCATED EITHER ON THE ROOF OR AT THE HIGHEST LANDING OF STAIRWAYS WITH STAIR ACCESS TO THE ROOF. AN ADDITIONAL HOSE CONNECTION SHALL BE PROVIDED AT THE TOP OF THE MOST HYDRAULICALLY REMOTE STANDPIPE FOR TESTING PURPOSE. 32. HYDRAULICALLY DESIGNED STANDPIPE SYSTEMS SHALL BE DESIGNED TO PROVIDE THE WATER FLOW RATE AT A MINIMUM RESIDUAL PRESSURE OF 65 PSI (4.5 BAR) AT THE OUTLET OF THE HYDRAULICALLY MOST REMOTE 144 IN. (65 mm) & 144 IN. (38 mm) HOSE CONNECTION. SEC. 7.8.1.1 OF OF NFPA 14-2003. AT THE TOP OF THE HIGHEST RISER THERE SHALL BE PROVIDED ABOVE THE MAIN ROOF LEVEL A THREE WAY MANIFOLD EQUIPPED WITH THREE 144 IN. HOSE VALVE WITH HOSE VALVE CAPS. SEC. 7.3.2.2 OF APPENDIX Q. WHERE THE RESIDUAL PRESSURE AT A 144 IN. (40 mm) OUTLET ON A HOSE CONNECTION EXCEED 100 PSI (6.9 BAR), AN APPROVED PRESSURE RESTRICTED DEVICE SHALL BE PROVIDED. SEC. 7.8.3.1 OF NFPA 14-2003. 34. FOR CLASS I AND CLASS III SYSTEMS THE MINIMUM FLOW RATE FOR THE HYDRAULICALLY MOST REMOTE STANDPIPE SHALL BE 500 GPM (1893 L/MIN) SEC. 7.10.1.1.1 OF NFPA 14-2003. 35. 36. 37. 38. POINT OF NEW CONNECTION TO EXISTING WORK SPRINKLER ABBREVIATIONS AFF ABOVE FINISHED FLOOR FHR FIRE HOSE RACK FSC FIRE HOSE CABINET FSP FIRE STANDPIPE TS TAMPER SWITCH WF WATERFLOW SWITCH SUBMISSIONS HOSE CONNECTIONS AND HOSE STATIONS SHALL BE UNOBSTRUCTED AND SHALL BE LOCATED NOT LESS THAN 3 FT. (0.9 M) OR MORE THAN 5 FT. (1.5 m) ABOVE THE FLOOR. SEC. 7.3.1 OF NFPA 14-2003. 33. STANDPIPE SYSTEM 1. THE LOCATION OF FIRE DEPARTMENT HOSE CONNECTIONS SHALL BE APPROVED BY THE FIRE COMMISSIONER PER SEC 905.1 OF NYC BUILDING CODE. 8. 375 Beach 92nd Street Queens, NY 11693 NEW UPRIGHT HEAD 15. UNDERGROUND BUILDINGS SHALL BE EQUIPPED THROUGHOUT WITH A CLASS I AUTOMATIC WET OR MANUAL WET. 24. HANGERS SHOULD BE SUPPORTED BY WROUGHT IRON U TYPE OR APPROVED ADJUSTABLE HANGERS. HANGERS SHALL BE OF THE TYPE APPROVED FOR USE WITH THE PIPE OR TUBE INVOLVED, AS PER CHAPTER 9 OF APPENDIX Q SECTION BC Q102. SPRINKLER PIPE SIZES SHOWN ARE FOR COST ESTIMATING ONLY, AND FOR FILING WITH THE BUILDING DEPARTMENT. THIS CONTRACTOR IS TO PROVIDE THEIR OWN HYDRAULIC CALCULATIONS TO VERIFY PIPE SIZING AND INCLUDE ANY INCREASED/DECREASED PIPE SIZING WITHIN THEIR CONTRACT PRICE. STANDPIPE SYSTEM COMPONENTS AND HARDWARE SHALL BE IN ACCORDANCE WITH CHAPTER 4 OF NFPA 14-2003 AND APPENDIX Q OF NYC BUILDING CODE. 16. AS PER SECTION BC903.1.2 PROVIDE DEPARTMENT OF WATER SUPPLY LETTER WITH FLOW TEST DATA IF THERE IS A DIRECT CONNECTION TO THE STREET WATER SUPPLY. CONTRACTOR SHALL COORDINATE ALL NEW WORK WITH NEW WORK OF OTHER TRADES AND EXISTING CONDITIONS. 5. 3. project EXISTING SIDEWALL SPRINKLER HEAD 14. STAGES GREATER THAN 1,000 SQUARE FEET IN AREA SHALL BE EQUIPPED WITH A CLASS III WET STANDPIPE SYSTEM WITH 1.5-INCH AND 2.5-INCH (38 mm AND 64 mm) HOSE CONNECTIONS ON EACH SIDE OF THE STAGE. 23. DRAIN VALVES AND TEST VALVES SHALL BE APPROVED TYPE AS PER SECTION 6.7.3 OF APPENDIX Q SECTION BC Q102. MINIMUM PIPE SIZE TO ANY SPRINKLER HEAD SHALL BE 1 INCH. 2. THE COMPLETE STANDPIPE SYSTEM COMPLY WITH THE FULL REQUIREMENTS OF N.Y.C. BUILDING CODE SEC. 905, APPENDIX Q AND NFPA 14-2003. 15. DISTANCE OF SPRINKLERS FROM HEAT SOURCE SHALL BE AS PER TABLES 9.3.2.5 (a) AND 8.3.2.5 (b). SHALL ALLOW FOR ALL REQUIRED FITTINGS TO ACHIEVE THIS AND INCLUDE THIS IN THEIR CONTRACT PRICE. 4. 1. SPRINKLER LEGEND NEW SIDEWALL SPRINKLER HEAD 1. 11. SPACING, LOCATION AND POSITION OF SPRINKLER WILL BE AS PER SECTION 8 OF APPENDIX Q SECTION BCQ102. 2. AC BE 1. SCOPE OF WORK A. AREA OF APPLICATION: 1500 SQ. FT. (REMOTE AREA) MAXIMUM COVERAGE PER SPRINKLER: 130 SQ. FT. DESIGN DENSITY: 0.15 GPM PER SQUARE FOOT SPACING BETWEEN SPRINKLERS: 15'-0" MAXIMUM DISTANCE BETWEEN SPRINKLERS & WALLS: 1/2 OF ALLOWABLE DISTANCE BETWEEN SPRINKLERS NEW YORK CITY DOB STANDPIPE NOTES GENERAL A. RECESSED PENDENT - RELIABLE MODEL G4A 'QUICK RESPONSE CONCEALED AUTOMATIC SPRINKLER, 1/2" ORIFICE, 5.6 K FACTOR, NYC MEA NUMBER 258-93-E NEW YORK CITY DOB SPRINKLER NOTES SPRINKLER DRAWING LIST SHEET # DWG # DATE rev no issue 02.14.11 1 FILING & PRICING DESCRIPTION 1 SP-101.00 GROUND LEVEL: SPRINKLER - SYMBOLS & NOTES 2 SP-201.00 GROUND LEVEL: SPRINKLER - SPECIFICATIONS 3 SP-301.00 GROUND LEVEL: SPRINKLER - PIPING PLAN & NOTES 4 SP-401.00 GROUND LEVEL: SPRINKLER - DETAILS WHERE A HORIZONTAL STANDPIPE ON A CLASS I AND CLASS III SYSTEM SUPPLIES THREE OR MORE HOSE CONNECTIONS ON ANY FLOOR, THE MINIMUM FLOW RATE FOR THE HYDRAULICALLY MOST DEMANDING HORIZONTAL STANDPIPE SHALL BE 750 GPM (2840 L/MIN). SEC. 7.10.1.1.2 OF NFPA 14-2003. project THE MINIMUM FLOW RATE FOR ADDITIONAL STANDPIPES SHALL BE 250 GPM PER STANDPIPE WITH THE TOTAL NOT TO EXCEED 1250 GPM OR 1000 GPM FOR BUILDINGS SPRINKLERED THROUGHOUT. SEC. 7.10.1.1.3 OF NFPA 14-2003. 375 Beach 92nd Street Queens, NY 11693 CLASS I AND CLASS III STANDPIPES IN BUILDINGS WITH FLOOR HEIGHTS LESS THAN 150 FT. ABOVE GRADE PLANE SHALL BE AT LEAST 4 INCHES IN SIZE. STANDPIPES IN BUILDINGS WITH FLOOR HEIGHTS GREATER THAN 150 FT ABOVE GRADE PLANE SHALL BE NO LESS THAN 6 INCHES IN DIAMETER. SEC. 7.6.1 OF APPENDIX Q. dwg title GROUND FLOOR SPRINKLER SYMBOLS & NOTES VALVES CONTROLLING WATER SUPPLIES SHALL BE SUPERVISED IN THE OPEN POSITION SO THAT A CHANGE IN THE NORMAL POSITION OF THE VALVE WILL GENERATE A SUPERVISORY SIGNAL AT THE SUPERVISING STATION REQUIRED BY SECTION 903.4. WHERE A FIRE ALARM SYSTEM IS PROVIDED, A SIGNAL SHALL ALSO BE TRANSMITTED TO THE CONTROL UNIT. 39. INSTALLATION OF STANDPIPE SYSTEMS SHALL COMPLY WITH THE SPECIAL INSPECTION REQUIREMENTS OF CHAPTER 17 OF NYC BUILDING CODE. seal & signature 40. STANDPIPE SYSTEM SPECIAL INSPECTIONS SHALL BE PERFORMED IN ACCORDANCE WITH SECTION [BC 1704.22] OF THE 2008 NYC BUILDING CODE. THE SPECIAL INSPECTOR SHALL BE HIRED DIRECTLY BY THE OWNER OR THE GENERAL CONTRACTOR. COST FOR THE SPECIAL INSPECTOR SHALL BE INCLUDED AS PART OF THE STANDPIPE CONTRACTORS OVERALL BID AND BE BROKEN OUT SO THE OWNER AND OR GENERAL CONTRACTOR CAN HIRE THE SPECIAL INSPECTOR DIRECTLY WITH THE FUNDS PROVIDED UNDER THE STANDPIPE CONTRACTORS BID. issue date 02/11/2011 project no. t10-12-0230 drawn by cadd checked by twig scale AS NOTED dwg. no. NYCECC NOTES: TO THE BEST OF MY KNOWLEDGE, BELIEF AND PROFESSIONAL JUDGMENT, THESE PLANS AND SPECIFICATIONS ARE IN COMPLIANCE WITH THE NEW YORK CITY ENERGY CONSERVATION CODE. THESE PLANS ARE APPROVED ONLY FOR THE WORK ON THE APPLICATION SPECIFICATION SHEET. ALL OTHER MATTERS SHOWN ARE NOT TO BE RELIED UPON OR TO BE CONSIDERED AS EITHER BEING APPROVED OR IN ACCORDANCE WITH APPLICABLE CODES. cad file sheet 1 of 4 375 Beach 92nd Street SP-101.00.dwg NYC dob# project 375 Beach 92nd Street Queens, NY 11693 SECTION OF THE SPECIFICATION". SPRINKLER SPECIFICATIONS PART 2 - MATERIALS PART I - GENERAL 1.01 REQUIREMENTS A. THE SPRINKLER CONTRACTOR SHALL BE A LICENSED, AUTHORIZED INSTALLER OF SPRINKLER SYSTEMS & SHALL HAVE HAD A MINIMUM OF FIVE YEARS EXPERIENCE IN THE INSTALLATION OF SPRINKLER SYSTEMS IN THE CITY OF NEW YORK. B. BEFORE SUBMITTING HIS BID, THE SPRINKLER CONTRACTOR SHALL VISIT THE SITE AND SHALL FULLY FAMILIARIZE HIMSELF WITH THE STRUCTURAL LAYOUT OF THE EXISTING BEAMS IN RELATIONSHIP TO THE NEW HVAC DUCT LAYOUT & NEW LIGHTING CEILING HEIGHTS & BECOME FAMILIAR WITH THE DIFFICULTIES THAT WILL ATTEND THE EXECUTION OF THIS WORK. CONTRACTOR SHALL PERFORM THIS PRIOR TO SUBMITTING HIS PROPOSAL. SUBMITION OF A PROPOSAL WILL BE CONSTRUED AS EVIDENCE THAT SUCH AN EXAMINATION HAS BEEN MADE & LATER CLAIMS WILL NOT BE RECOGNIZED FOR EXTRA LABOR, EQUIPMENT OR MATERIALS REQUIRED BECAUSE OF DIFFICULTIES ENCOUNTERED WHICH COULD HAVE BEEN FORESEEN HAD SUCH AN EXAMINATION BEEN MADE. C. UPON REVIEW OF SPRINKLER DRAWINGS PRIOR TO SUBMITTING HIS PROPOSAL, THE SPRINKLER CONTRACTOR SHALL INFORM ARCHITECT AND/OR ENGINEER OF ANY DISCREPANCIES OR REQUEST CLARIFICATION IN WRITING, IF NECESSARY, CONCERNING THE INTENT OF THE PLANS & SPECIFICATION TO PROVIDE A COMPLETE SPRINKLER INSTALLATION. LATER CLAIMS WILL NOT BE RECOGNIZED FOR EXTRA LABOR, EQUIPMENT OR MATERIALS SHOULD SUCH PROCEDURE NOT BE FOLLOWED. D. THE SCHEDULING OF THE SPRINKLER WORK SHALL BE COORDINATED WITH THE BUILDING OWNER, WITH OTHER CONTRACTOR AND WITH THE CLIENT. E. NECESSARY SHUT-DOWNS OF BASE BUILDING SPRINKLER SYSTEM MUST BE COORDINATED WITH THE BUILDING OWNER AND CLIENT. SHUT-DOWNS OF BASE BUILDING SYSTEMS SHALL TAKE PLACE AFTER OR BEFORE NORMAL BUSINESS HOURS AND SHALL BE CONSIDERED OVERTIME WORK. 1.02 WORK INCLUDED A. WORK SHALL INCLUDE ALL SPRINKLER WORK FURNISHED & INSTALLED FOR THE CLIENT. 1. ALL WORK SHALL COMPLY WITH REQUIREMENTS OF THE NEW YORK CITY BUILDING CODE. 2. WORK SHALL ALSO INCLUDE THE REMOVAL OF EXISTING SPRINKLER PIPING AS NOTED, HEADS, AND SUPPORTS AS NOTED. B. SPRINKLER HEAD LAYOUT SHALL BE BASED ON THE LOCATIONS INDICATED ON THE PLANS, & SHALL BE INSTALLED WITH NO TOLERANCE FROM THE CENTER OF CEILING TILE. THE SPRINKLER CONTRACTOR SHALL COORDINATE HIS WORK WITH EXISTING CONDITIONS & WITH WORK OF ALL OTHER CONTRACTORS. THE CONTRACTOR SHALL NOTIFY THE ENGINEER OF ANY CONFLICTS IN WRITING BETWEEN THE OTHER TRADES BEFORE INSTALLATION OF THE SPRINKLER SYSTEM. C. SPRINKLER SYSTEM SHALL BE: 1. A MODIFICATION TO A PIPE SCHEDULE DESIGNED SYSTEM IN ACCORDANCE WITH THE STANDARDS OF THE NATIONAL FIRE PROTECTION ASSOCIATION & THE BUILDING CODE OF THE CITY OF NEW YORK. 2. DESIGN SYSTEM TO CONFORM WITH BUILDING STRUCTURAL, MECHANICAL & ELECTRICAL SYSTEMS, EITHER EXISTING OR PROPOSED. D. THESE DRAWINGS ARE DIAGRAMMATIC AND INDICATE THE GENERAL LOCATION OF WORK. SCALED DIMENSIONS SHALL NOT BE USED. ANY DIMENSIONS NOT SHOWN SHALL BE OBTAINED FROM THE ARCHITECTURAL DRAWINGS. FOR EXACT LOCATIONS, MOUNTING HEIGHTS, ETC., REFER TO ARCHITECTURAL DRAWINGS AND DETAILS. ALL DIMENSIONS, ETC., SHALL BE VERIFIED BY FIELD CHECK. 1.03 SHOP DRAWINGS AND DATA A. THE CONTRACTOR SHALL SUBMIT, FOR APPROVAL, FULLY COORDINATED SHOP DRAWINGS, & CATALOG CUTS OF THE FOLLOWING: 1. PIPE AND FITTINGS 2. SPRINKLER HEADS 2.01 GENERAL A. THE SPRINKLER SYSTEM SHALL BE COMPLETE WITH ALL PIPE, FITTINGS, VALVES, DRAINAGE SYSTEM & VALVES, SPRINKLER HEADS, HANGERS AS REQUIRED, VALVE TAGS, ETC., & ALL OTHER RELATED EQUIPMENT, APPARATUS, AND MATERIAL ITEMS NECESSARY FOR COMPLETE, SATISFACTORY OPERATING & APPROVED TYPE SYSTEM. B. ALL PIPE FITTINGS, HANGERS, SUPPORTS, SPRINKLER HEADS, ETC.,SHALL CONFORM TO THE NEW YORK CITY BUILDING CODE AND NATIONAL FIRE PROTECTION ASSOCIATION'S REQUIREMENTS AS TO TYPES OF MATERIALS, ARRANGEMENT, SIZES & INSTALLATION EXCEPT THAT NO FACE OR FLUSH BUSHING SHALL BE USED. REDUCING FITTINGS SHALL BE PROVIDED IN LIEU OF BUSHINGS. 2.02 SPRINKLER PIPING A. 4. SPRINKLER AND PIPING LAYOUT B. PIPE/GROOVED (STANDARD/LIGHTWALL): CARBON STEEL, A-53B/A-106B - ROLL OR CUT GROOVED-ENDS AS APPROPRIATE TO PIPE MATERIAL, WALL THICKNESS, PRESSURES, SIZE AND METHOD OF JOINING. PIPE ENDS TO BE GROOVED IN ACCORDANCE TO ANSI/AWWA C-606. MECHANICAL COUPLINGS FOR JOINING CARBON STEEL PIPE 1. A. THE SPRINKLER CONTRACTOR SHALL FILE ALL REQUIRED DRAWINGS AND SPECIFICATIONS WITH THE NEW YORK CITY BUILDING DEPARTMENT AND BE RESPONSIBLE FOR OBTAINING FINAL APPROVAL. 1.05 INSPECTION AND TESTING MECHANICAL COUPLINGS: MECHANICAL COUPLINGS SHALL BE MANUFACTURED IN TWO SEGMENTS OF CAST DUCTILE IRON, CONFORMING TO ASTM A-536, GRADE 65-45-12. GASKETS SHALL BE PRESSURE-RESPONSIVE SYNTHETIC RUBBER, GRADE TO SUIT THE INTENDED SERVICE, CONFORMING TO ASTM D-2000. MECHANICAL COUPLING BOLTS SHALL BE ZINC PLATED (ASTM B-633) HEAT TREATED CARBON STEEL TRACK HEAD CONFORMING TO PHYSICAL PROPERTIES OF ASTM A-449, MINIMUM TENSILE STRENGTH 110,000 PSI. a. A. THE SPRINKLER SYSTEM SHALL BE INSPECTED & TESTED IN ACCORDANCE WITH THE REQUIREMENTS OF THE NEW YORK CITY BUILDING CODE. RIGID TYPE: 1) B. THE SPRINKLER SYSTEM SHALL BE SUBJECTED TO A HYDROSTATIC PRESSURE TEST FOR A PERIOD OF TWO HOURS AT A PRESSURE OF AT LEAST 200 PSI OR 50 PSI IN EXCESS OF THE MAXIMUM PRESSURE TO BE MAINTAINED WHEN THE MAXIMUM PRESSURE IN THE SYSTEM IS IN EXCESS OF 150 PSI AS PER NFPA. 2) C. BEFORE SPRINKLER SYSTEM IS CONCEALED, THE BUILDING DEPARTMENT SHALL BE NOTIFIED THAT THE SYSTEM IS READY FOR INSPECTION AND TESTING. THE BUILDING DEPARTMENT INSPECTOR SHALL WITNESS THE TEST. FINAL APPROVAL OF THE SPRINFINAL APPROVAL OF TEST. FINAL APPROVEL OF THE SPRINKLER SYSTEM SHALL BE OBTAINED FROM BUILDING DEPARTMENT. 3) b. 1.06 FLUSHING 2. A. ALL FIRE PROTECTION PIPING SHALL BE FLUSHED OUT IN ACCORDANCE WITH REQUIREMENTS OF THE NATIONAL FIRE PROTECTION ASSOCIATION CODES No.131989 EDITION. 3. C. D. STANDARD RIGID JOINTS SHALL BE VICTAULIC STYLE 005, IN SIZES 5" THROUGH 8" (FIRELOCK 005) OR 07 (ZERO-FLEX). HOUSINGS SHALL BE CAST WITH OFFSETTING, ANGLE-PATTERN BOLT PADS TO PROVIDE SYSTEM RIGIDITY AND SUPPORT AND HANGING IN ACCORDANCE WITH NFPA 13. RIGID COUPLINGS SHALL REQUIRE VISUAL PAD-TO-PAD VERIFICATION OF COMPLETE INSTALLATION. FLEXIBLE TYPE: USE IN SEISMIC AREAS WHERE REQUIRED BY NFPA 13. VICTAULIC STYLE 75 OR 77. MECHANICAL COUPLINGS GASKET: PRESSURE-RESPONSIVE, SYNTHETIC RUBBER RATER FOR USE WITH THE HOUSINGS. FIRE PROTECTION SERVICE TEMPERATURE RANGE GASKET TECCOMMENDATIONS DRY SYSTEMS AMBIENT FLUSHSEAL, GRADE EPDM, TYPE A FLUSHSEAL, GRADE L, SILICONE GRADE EPDM, TYPE A AMBIENT FLANGE ADAPTERS: FOR USE WITH GROOVED END PIPE AND FITTINGS, FOR MATING TO ANSI CLASS 125 / 150 FLANGES. VICTAULIC STYLE 741 OR 744. FOR MATING TO ANSI CLASS 300 FLANGES USE VICTAULIC STYLE 743. VICTAULIC GROOVED END FITTINGS: FITTINGS SHALL BE CAST OF DUCTILE IRON CONFORMING TO ASTM A-536, GRADE 65-45-12 FORGED STEEL CONFORMING TO ASTM A-234 GRADE WPB 0.375" WALL (9,53 MM WALL), OR FABRICATED FROM STD. WT. CARBON STEEL PIPE CONFORMING TO ASTM A-53, TYPE F, E OR S, GRADE B. FITTINGS PROVIDED WITH AN ALKYD ENAMEL FINISH OR HOT DIP GALVANIZED TO ASTM A-153. ZINC ELECTROPLATED FITTINGS AND COUPLINGS CONFORM TO ASTM B633. VICTAULIC HOLE-CUT BRANCH OUTLETS: 1. a. 2. STRAPLESS OUTLET: 1/2" OR 3/4" NPT OUTLET ON 4" (DN100) AND LARGER HEADER SIZES RATED FOR 300 PSI. VICTAULIC STYLE 923. 3. STRAPLESS THERMOMETER OUTLET: TO ACCOMMODATE INDUSTRIAL GLASS BULB THERMOMETERS WITH STANDARD 1-1/4"-18 NEF 2B EXTRA FINE THREAD AND 6" NOMINAL BULB LENGTH ON 4" (DN100) AND LARGER HEADER SIZES RATED FOR 300 PSI. VICTAULIC VIC-O-WELL STYLE 924 architect A. VICTAULIC SPRINKLER HEADS: DIE-CAST BRASS FRAME, TEFLON ENCAPSULATED BELLEVILLE SPRING SEAL AND FRANGIBLE GLASS BULB. BODY CAST WITH HEX SHAPED WRENCH BOSS. (SPRINKLERS SHALL NOT CONTAIN O-RINGS.) QUICK OR STANDARD RESPONSE TYPE. 1. A Division of The Wall Consulting Group, Inc. All Rights Reserved. 2007- 2010 231 West 29th Street - Suite 606, New York, NY 10001 Tel: 212 . 967 . TWIG / Fax: 212 . 967 . 8945 info@twigcon.com www.twigcon.com GUARDS AND ESCUTCHEONS: GUARDS AND ESCUTCHEONS SHALL BE LISTED, SUPPLIED, AND APPROVED FOR USE WITH THE SPRINKLER BY THE SPRINKLER MANUFACTURER. 2.04 CUTTING AND PATCHING A. DO ALL CUTTING NECESSARY FOR THE INSTALLATION OF SPRINKLER WORK. ACCURATELY LAYOUT WORK FOR WHICH CUTTING IS REQUIRED, SO AS TO AVOID UNNECESSARY LARGE OPENINGS. CUTTING OF BEAMS, JOISTS, FLOORS OR WALLS OF THE BUILDING WILL NOT BE PERMITTED EXCEPT AFTER RECEIVING APPROVAL OF THE BUILDING MANAGER. B. ROUGH PATCHING WILL BE DONE BY THIS CONTRACTOR IN A MANNER TO ACCOMODATE FINISHED PATCHING WORK. FINISHED PATCHING WILL BE DONE "UNDER ANOTHER 2.05 INSERTS, HANGERS, ETC. INSTALLATION READY: RIGID JOINTS SHALL BE VICTAULIC FIRELOCK EZ STYLE 009H, IN SIZES 1-1/4" THROUGH 4", WHICH SHALL BE DESIGNED FOR DIRECT "STAB" INSTALLATION ONTO GROOVED PIPE WITHOUT PRIOR DISASSEMBLY OF THE COUPLING. HOUSINGS SHALL BE CAST WITH OFFSETTING, ANGLE-PATTERN BOLT PADS. FREEZER APPLICATIONS WATER / WET SYSTEMS HEADER CONNECTIONS FOR SPRINKLERS, DROP NIPPLES, SPRIGS, GAUGES, AND DRAINS ON 1-1/4" THROUGH 2-1/2" HEADER PIPING. OUTLETS SHALL BE MANUFACTURED FROM DUCTILE IRON CONFORMING TO ASTM ASTM A-536, GRADE 65-45-12, WITH SYNTHETIC RUBBER GASKET, AND HEAT TREATED CARBON STEEL ZINC PLATED BOLTS AND NUTS CONFORMING TO PHYSICAL PROPERTIES OF ASTM A-183. VICTAULIC FIRELOCK OUTLET TEE STYLE 922. 2.03 SPRINKLER HEADS 1.0 IPS GROOVED PIPING SYSTEM: VICTAULIC GROOVED MECHANICAL PIPE COUPLINGS, FITTINGS, VALVES AND OTHER GROOVED COMPONENTS MAY BE USED AS AN OPTION TO WELDING, THREADING OR FLANGED METHODS. ALL GROOVED COMPONENTS SHALL BE OF ONE MANUFACTURER AND SHALL BE UL LISTED AND/OR FM GLOBAL APPROVED. GROOVED END PRODUCT MANUFACTURER TO BE ISO-9001 CERTIFIED. GROOVED COUPLINGS SHALL MEET THE REQUIREMENTS OF NFPA-13. ACCEPTABLE MANUFACTURES ARE VICTAULIC COMPANY OF AMERICA OR APPROVED EQUAL BY ENGINEER. 3. HANGERS AND SUPPORTS 1.04 BUILDING DEPARTMENT FILING, PERMITS, AND CERTIFICATES b. BOLTED BRANCH OUTLET: BRANCH REDUCTIONS ON 2" THROUGH 8" HEADER PIPING. BOLTED BRANCH OUTLETS SHALL BE MANUFACTURED FROM DUCTILE IRON CONFORMING TO ASTM ASTM A-536, GRADE 65-45-12, WITH SYNTHETIC RUBBER GASKET, AND HEAT TREATED CARBON STEEL ZINC PLATED BOLTS AND NUTS CONFORMING TO PHYSICAL PROPERTIES OF ASTM A-183. VICTAULIC STYLE 920 / 920N. A. ALL SPRINKLER PIPING SHALL BE SUBSTANTIALLY SUPPORTED AND SHALL COMPLY WITH THE STANDARDS OF THE NATIONAL FIRE PROTECTION ASSOCIATION FOR THE INSTALLATION OF SPRINKLER SYSTEMS AND AS REQUIRED BY THE NEW YORK CITY BUILDING CODE AND FACTORY MUTUAL. B. HANGERS & THEIR COMPONENTS SHALL BE FERROUS. HANGERS SHALL BE ADJUSTABLE, FLAT IRON TYPE OR CLEVIS TYPE. C. SPRINKLER PIPING OR HANGERS SHALL NOT BE USED TO SUPPORT NON-SYSTEM COMPONENTS. D. SPRINKLER PIPING SHALL BE SUBSTANTIALLY SUPPORTED FROM THE BUILDING STRUCTURE WHICH MUST SUPPORT THE ADDED LOAD OF THE WATER-FILLED PIPE PLUS A MINIMUM OF 250 LBS. APPLIED AT THE POINT OF HANGING. E. SPRINKLER PIPING SHALL BE SUPPORTED INDEPENDENTLY OF THE CEILING SHEATHING. F. WHEN SPRINKLER PIPING IS INSTALLED BELOW DUCTWORK, PIPING SHALL BE SUBSTANTIALLY SUPPORTED FROM THE BUILDING STRUCTURE, NOT FROM THE DUCTWORK. G. MAXIMUM DISTANCE BETWEEN HANGERS SHALL NOT EXCEED 12 FEET FOR 1" AND 1-1/4" SIZES OR 15 FEET FOR SIZES 1-1/2" AND LARGER. H. EXPANSION SHIELDS FOR SUPPORTING PIPES UNDER CONCRETE CONSTRUCTION MAY BE USED IN A HORIZONTAL POSITION IN THE SIDES OF BEAMS. IN CONCRETE HAVING GRAVEL OR CRUSHED STONE AGGREGATE, EXPANSION SHIELDS MAY BE USED IN THE VERTICAL POSITION TO SUPPORT PIPES 4" OR LESS IN DIAMETER. SUBMISSIONS 2.06 ESCUTCHEONS A. PROVIDE ESCUTCHEONS ON ALL EXPOSED PIPING PASSING THROUGH WALLS, PARTITIONS, FLOORS AND CEILINGS. ESCUTCHEON SHALL BE HELD IN PLACE BY INTERNAL TENSION OR SET SCREW. DATE rev no issue 02.14.11 1 FILING & PRICING 2.07 GUARANTEE A. GUARANTEE FOR A PERIOD OF ONE (1) YEAR FROM THE DATE OF ACCEPTANCE BY THE OWNER, ALL MATERIALS, APPARATUS AND WORKMANSHIP WHETHER FURNISHED BY HIMSELF OR BY HIS SUBCONTRACTORS & HE SHALL REPLACE OR REPAIR IN A MANNER APPROVED BY THE ARCHITECTS, WITHOUT COST TO THE OWNER, ANY PART OR PARTS OF THE WORK WHICH MAY PROVE DEFECTIVE OR UNSATISFACTORY WITHIN THE PERIOD OF THE GUARANTEE. 2.08 AS-BUILT DRAWINGS project A. PREPARE & SUBMIT "AS-BUILT" DRAWINGS AT THE COMPLETION OF THE PROJECT. 375 Beach 92nd Street Queens, NY 11693 dwg title GROUND FLOOR SPRINKLER SPECIFICATIONS seal & signature issue date 02/11/2011 project no. t10-12-0230 drawn by cadd checked by twig scale AS NOTED dwg. no. NYCECC NOTES: TO THE BEST OF MY KNOWLEDGE, BELIEF AND PROFESSIONAL JUDGMENT, THESE PLANS AND SPECIFICATIONS ARE IN COMPLIANCE WITH THE NEW YORK CITY ENERGY CONSERVATION CODE. THESE PLANS ARE APPROVED ONLY FOR THE WORK ON THE APPLICATION SPECIFICATION SHEET. ALL OTHER MATTERS SHOWN ARE NOT TO BE RELIED UPON OR TO BE CONSIDERED AS EITHER BEING APPROVED OR IN ACCORDANCE WITH APPLICABLE CODES. cad file sheet 2 of 4 375 Beach 92nd Street SP-201.00.dwg NYC dob# project 375 Beach 92nd Street Queens, NY 11693 GENERAL SPRINKLER PIPING NOTES 1. PROVIDE ALL MATERIALS AND EQUIPMENT AND PERFORM ALL LABOR REQUIRED TO INSTALL COMPLETE AND OPERABLE PIPING SYSTEMS AS INDICATED ON THE DRAWING. 2. UNLESS OTHERWISE NOTED, ALL PIPING IS OVERHEAD, TIGHT TO THE UNDERSIDE OF STRUCTURE/SLAB, WITH SPACE FOR INSULATION AS SPECIFIED. 3. INSTALL PIPING SO THAT ALL VALVES, STRAINERS, UNIONS, TRAPS, FLANGES AND OTHER APPURTENANCES REQUIRING ACCESS ARE ACCESSIBLE. 4. ALL PIPING WORK SHALL BE COORDINATED WITH ALL TRADES INVOLVED OFFSETS IN PIPING AROUND OBSTRUCTIONS SHALL BE PROVIDED AT NO ADDITIONAL COST TO THE OWNER. architect 5. NEW SHEET-ROCK CEILING SHALL COMPLY WITH MINIMUM 1-HR RATED CEILING IN COMPLIANCE WITH APPLICABLE BUILDING CODES. A Division of The Wall Consulting Group, Inc. All Rights Reserved. 2007- 2010 231 West 29th Street - Suite 606, New York, NY 10001 Tel: 212 . 967 . TWIG / Fax: 212 . 967 . 8945 ORDINARY HAZARD PIPE SCHEDULE # OF SPRINKLER HEADS PIPE SIZE 2 1" 3 1-1/4" 5 1-1/2" 10 2" 20 2-1/2" 40 3" 65 3-1/2" info@twigcon.com www.twigcon.com NOTES: CONNECT TO EXISTING SPRINKLER SYSTEM PIPES SIZES SHOWN ARE BASED ON DESIGN PIPING LAYOUTS ONLY. ACTUAL PIPE SIZES SHALL BE DETERMINED BY CONTRACTORS HYDRAULIC CALCULATIONS BASED ON HIS INSTALLATION DRAWINGS. CONTRACTOR SHALL ALLOW FOR THIS AND INCLUDE THIS ON HIS CONTRACTOR PRICE. 6X6 EXHAUST 4" 1 1/4" SPRINKLER SCOPE OF WORK LOCATION EXISTING TO REMAIN REMOVED RELOCATED GROUND FLOOR 0 0 0 NEW 5 REMARKS ALL SPRINKLER HEADS PROVIDED ARE NEW SUBMISSIONS NOTES: DATE rev no issue 02.14.11 1 FILING & PRICING 1. ALL NEW SPRINKLER HEADS SHALL BE BASED ON VICTAULIC OR APPROVED EQUAL 4" LOCAL MANUFACTURER REPRESENTATIVE: VICTAULIC (516)297 -9637 4" 1 1/2" project 375 Beach 92nd Street Queens, NY 11693 1" dwg title GROUND FLOOR SPRINKLER PLAN & NOTES 56 PSI FCVA seal & signature EXISTING 1 1/2" DRAIN issue date 02/11/2011 project no. t10-12-0230 drawn by cadd checked by twig scale AS NOTED dwg. no. GROUND FLOOR: SPRINKLER PLAN SCALE: 3/16" = 1'-0" NYCECC NOTES: TO THE BEST OF MY KNOWLEDGE, BELIEF AND PROFESSIONAL JUDGMENT, THESE PLANS AND SPECIFICATIONS ARE IN COMPLIANCE WITH THE NEW YORK CITY ENERGY CONSERVATION CODE. THESE PLANS ARE APPROVED ONLY FOR THE WORK ON THE APPLICATION SPECIFICATION SHEET. ALL OTHER MATTERS SHOWN ARE NOT TO BE RELIED UPON OR TO BE CONSIDERED AS EITHER BEING APPROVED OR IN ACCORDANCE WITH APPLICABLE CODES. cad file sheet 3 of 4 375 Beach 92nd Street SP-301.00.dwg NYC dob# 1/2"x2" REDUCING TEE OR ELBOW NOTES: MANUFACTURER: VICTAULIC MODEL#: V3415-SR, V3416-QR MEA#: 62-99-E VICTAULIC SUBMITTAL # 40.33 1 1/8" NOTES: MANUFACTURER: VICTAULIC MODEL#: V3801-SR, V3802-QR MEA#: 62-99-E VICTAULIC SUBMITTAL #40.50 1 15/16" project 375 Beach 92nd Street Queens, NY 11693 EXISTING WF STEEL MEMBER "C" CLAMP FINISHED CEILING CONCRETE ANCHOR HILTI-KWICK BOLT, SERIES HDI, OR APPROVED EQUAL. INSTALLATION SHALL BE IN ACCORDANCE WITH THE MANUFACTURER'S RECOMMENDATION 1/8" 4"-12" PER NFPA 2-3/8" DIA. COVER CEILING HOLE COUPLER STEEL RESTRAINING STRAP SPRINKLER CUP ASSEMBLY ROD (SIZE AS REQUIRED) CASTING SPRINKLER PIPE CLEVIS HANGER COVER PLATE ASSEMBLY TYPICAL CEILING TILE 1/2" COVER MAX. ADJUSTMENT TYPICAL HANGER DETAILS 2. NOT TO SCALE 2 3/8" Max. Hole 2" Min. Hole 2 15/16" architect 3/16" 0.7500 3/16" 3-1/4" DIA. 1. 2-7/16" FACE OF FITTING TO CLG. DIMENSION MAX. CONCRETE CLAB TYPICAL CONCEALED SPRINKLER HEAD DETAIL 3. NOT TO SCALE SIDEWALL SPRINKLER DETAIL NOT TO SCALE A Division of The Wall Consulting Group, Inc. All Rights Reserved. 2007- 2010 NOTES: MANUFACTURER: VICTAULIC MODEL#: V3605-SR, V3606-QR MEA#: 62-99-E VICTAULIC SUBMITTAL # 40.60 STANDARD WEIGHT STEEL PIPE SLEEVE TO PASS PIPE TERMINATE SLEEVE FLUSH WITH FINISHED WALL SURFACES VARIES SEAL OR CAULK SLEEVES THRU FIRE WALLS IN A SMOKE TIGHT MANNER. REFER TO SPECIFICATIONS www.twigcon.com VARIES VARIES TEE WITH SAME OUTLET SIZE AS SPRINKLER THREAD SIZE. SEE "IMPORTANT INSTALLATION INFORMATION", SUBMITTAL 40.33 C EXISTING 1" NPT BRANCH MAIN 1 3/4" MIN. DIA. HOLE IN CEILING "A" (MIN. 1 1/4") FINISHED WALL SURFACE CONCEALED PIPING info@twigcon.com EXISTING ELBOW 1/2" CLEAR MAXIMUM FINISHED ESCUTCHEON PLATE FLUSH AGAINST WALL AND OF SIZE TO COMPLETELY COVER OPENING (TYP. FOR EACH SIDE) 231 West 29th Street - Suite 606, New York, NY 10001 Tel: 212 . 967 . TWIG / Fax: 212 . 967 . 8945 Ceiling PIPING EXPOSED TO VIEW NOTES: Ceiling 1" SYSTEM VICTAULIC STYLE 922 FIRELOCK OUTLET TEE/ 920 MECHANICAL TEE 1 1/2" TOTAL ADJUSTMENT DROP NIPPLE Ceiling SLEEVES AND ESCUTCHEONS 1" x 1/2" A. SLEEVES FOR PIPING THROUGH MASONRY WALLS SHALL BE SCHEDULE 40, STANDARD GALVANIZED STEEL PIPE; IN FRAMED PARTITIONS SHALL BE 20 GAUGE SHEET METAL. THE SPACE BETWEEN THE PIPE AND ITS SLEEVE SHALL NOT EXCEED ONE-HALF INCH. THE SLEEVE SHALL HAVE A SUFFICIENT LENGTH TO BE FLUSH WITH THE FINISHED WALL SURFACE. 4" MAX. COUPLING ESCUTCHEON 2 1/2" MIN. B. EXPOSED PIPING PASSING THROUGH WALLS, FLOORS OR CEILING SHALL BE FITTED WITH CHROMIUM-PLATED CAST BRASS ESCUTCHEONS WITH FASTENING SET SCREWS. CUTTING AND PATCHING A. PIPING PASSING THROUGH WALLS SHALL HAVE A TRIM OPENING CUT NO GREATER THAN NECESSARY FOR THE INSTALLATION OF A SLEEVE SECURED THEREIN. EXISTING SPRINKLER SUSPENDED CEILING HEAD TO BE BE REMOVED B. PIPING PASSING THROUGH CONCRETE FLOORS SHALL HAVE AN OPENING CORE DRILLED SO THAT THE SPACE BETWEEN THE OPENING AND THE PIPE SHALL NOT EXCEED ONE-HALF INCH. VICTAULIC MODEL V3605 SR MODEL V3606 QR NEW SPRINKLER HEAD VICTAULIC MODEL V3801 - V3802 MEA#: 62-99-E VICTAULIC SUBMITTAL #40.50 C. ANNULAR SPACES BETWEEN PIPING AND SLEEVES OR CORE DRILLED FLOOR OPENINGS SHALL BE PACKED WITH MINERAL WOOL AND SEALED, TO RETAIN THE FIRE INTEGRITY OF THE WALLS AND FLOORS, WITH A NON-HARDENING COMPOUND SIMMILAR OR EQUAL TO DUXSEAL AS MANUFACTURED BY THE J.M. CLIPPER CORP. 3 7/32" DIAMETER SLEEVE & SKIRT 4. TYPICAL DETAIL OF PIPE INSTALLATION THRU RATED WALL NOT TO SCALE ARM OVER DETAIL 5. 6. NOT TO SCALE NOTES: MANUFACTURER: VICTAULIC MODEL#: V2703-SR, V2704-QR MEA#: 62-99-E VICTAULIC SUBMITTAL #40.10 SPRINKLER LOOP MAIN 1" DRAIN VALVE WITH CAPPED HOSE END OUTLET DRY PENDANT SPRINKLER DETAIL SUBMISSIONS NOT TO SCALE PRODUCT LEGEND 1 DRAIN RISER 2 RISER 3 VICTAULIC MECH TEE STYLE 920 4 VICTAULIC 747M RISER MANIFOLD (*1) 5 VICTAULIC 705 BUTTERFLY VALVE (*2) 6 VICTAULIC 001 ELBOW 7 VICTAULIC 009H RIGID COUPLING (OR) 005 8 VICTAULIC 177 (OR) 75 FLEXIBLE COUPLING (SEISMIC APPLICATION - NOT SHOWN) 9 UL/FM APPROVED FLOW SWITCH (SYSTEM SENSOR WDF) 10 PRESSURE GAUGE 11 TO SPRINKLER SYSTEM * 1 VICTAULIC SUBMITTAL #10.96 * 2 VICTAULIC SUBMITTAL #10.81 FLOOR CONTROL VALVE ASSEMBLY DATE rev no issue 02.14.11 1 FILING & PRICING NOTES: MANUFACTURER: VICTAULIC 705 - MEA#: 276-99-E 747M - MEA#: 230-96-E SPRINKLER CROSS MAIN project 375 Beach 92nd Street Queens, NY 11693 SUSPENDED CEILING dwg title GROUND FLOOR SPRINKLER DETAIILS seal & signature 1"x 1/2" REDUCING ELL OR TEE 7. TYPICAL: "AUXILIARY" SPRINKLER DRAIN VALVE-DETAIL NOT TO SCALE 8. TYPICAL UPRIGHT SPRINKLER HEAD DETAIL NOT TO SCALE 9. TYPICAL FLOOR CONTROL VALVE ASSEMBLY issue date 02/11/2011 project no. t10-12-0230 drawn by cadd checked by twig scale AS NOTED dwg. no. NOT TO SCALE NYCECC NOTES: TO THE BEST OF MY KNOWLEDGE, BELIEF AND PROFESSIONAL JUDGMENT, THESE PLANS AND SPECIFICATIONS ARE IN COMPLIANCE WITH THE NEW YORK CITY ENERGY CONSERVATION CODE. THESE PLANS ARE APPROVED ONLY FOR THE WORK ON THE APPLICATION SPECIFICATION SHEET. ALL OTHER MATTERS SHOWN ARE NOT TO BE RELIED UPON OR TO BE CONSIDERED AS EITHER BEING APPROVED OR IN ACCORDANCE WITH APPLICABLE CODES. cad file sheet 4 of 4 375 Beach 92nd Street SP-401.00.dwg NYC dob#