VARIATION ORDERS IN UNIVERSITI TEKNOLOGI MALAYSIA (UTM) CONSTRUCTION PROJECTS NOR HAYATI BINTI IBRAHIM Laporan projek ini dikemukakan sebagai memenuhi sebahagian daripada syarat penganugerahan Ijazah Sarjana Sains (Pengurusan Pembinaan) Fakulti Kejuruteraan Awam Universiti Teknologi Malaysia NOVEMBER, 2006 DEDICATION For my beloved parents, my family, my lecturers, my friends and to all Muslims, ********** “And do not stretch your eyes after that with which We have provided different classes of them, (of) the splendour of this world’s life, that We may thereby try them, and the sustenance (given) by your Lord is better and more abiding” [Surah Ta-Ha, verse 131] ACKNOWLEDGEMENT Firstly, I desire to state my truthful gratitude to my supervisor Associate Professor Aziruddin Ressang for the guidance and motivation. The participating respondents from Harta Bina UTM, Consultants and Construction firms which involved in the survey and individual, which contributed, and supporting me in undertaking this research. I am thankful with the support. As a final point, appreciation to all friends and colleagues for their kindness. May Allah bless all of you. ABSTRACT The project holder have to believe that no construction method or for that matter the project, is free of variation and it’s afterward activity of claims. A document review was done for 18 numbers of construction contract documentation projects in Universiti Teknologi Malaysia (UTM) during the period of the Seventh Malaysian Plan from 1996 to 2000 with the total value of all projects in the excess RM100 million. The client, consultant and contractor become the main respondent target. In general, UTM’s construction projects of building works, renovation works and infrastructure works during Seventh Malaysian Plan are not impervious to variation orders. Every project of building works an average of RM 2.08 million is expend on variation orders and about RM 0.31 million is spent for every variation orders occurred in renovation and infrastructure works. All these have impacted the cost and the completion time of projects. This study has concluded the most numerous cause of variation orders in UTM construction projects which is inadequate consideration of design. Meanwhile, the top five of the effects of these variation orders are listed as followed; increase in project cost; delay in payment; procurement delay; logistic delay; completion schedule delay. The findings of this study also points out that the involvement of profession in the design phase and continuous coordination and direct communication are the two most considered factors to minimizing the happening of variation orders. ABSTRAK Industri pembinaan seolah-olah sudah tidak mampu mengelak dari terlibat dengan sebarang perubahan kerja terutamanya ketika berlangsungnya projek yang kemudiannya disusuli pula oleh pelbagai tuntutan. Ulangkaji dokumentasi pembinaan telah dilaksanakan terhadap 18 buah dokumen kontrak pembinaan Universiti Teknologi Malaysia (UTM) di dalam tempoh Rancangan Malaysia Ketujuh iaitu dari tahun 1996 hingga 2000 yang melebihi nilai RM 100 juta. Sasaran responden utama adalah terdiri dari klien, kontraktor dan perunding. Umumnya, keseluruhan projek pembinaan UTM ketika tempoh Rancangan Malaysia Ketujuh samada kerja-kerja yang melibatkan kerja-kerja bangunan, kerja ubahsuai dan kerja infrastruktur semuanya ada perubahan kerja. Mengikut anggaran, sebanyak RM2.05 juta akan dibelanjakan bagi perubahan kerja yang terlibat di setiap kerja bangunan, manakala lebih kurang RM0.31 juta pula dibelanjakan setiap kali perubahan kerja pada kerjakerja ubahsuai dan infrastruktur. Semua ini sudah tentu menjejaskan kos dan tempoh siap kerja bagi setiap projek yang terlibat. Kajian yang dilakukan telah menunjukkan punca utama yang mendorong berlakunya perubahan kerja adalah kerana pertimbangan yang kurang jitu ketika fasa rekabentuk. Sementara itu, lima (5) kesan besar yang timbul setelah berlakunya perubahan kerja disenaraikan sebagaimana berikut; meningkatnya kos projek; melambatkan proses bayaran; melambatkan pelaksanaan; mlambatkan logistik; dan melambatkan/menjejaskan jadual pelaksanaan. Dua (2) langkah telah dikenalpasti di dalam kajian ini yang mana berkemungkinan mampu untuk mengurangkan berlaku perubahan kerja di dalam sesebuah projek iaitu; penglibatlan semua profesion ketika fasa rekabentuk dan penyelenggaraan yang berterusan dan komunikasi langsung antara pihak yang terlibat. LIST OF CONTENT Title i Declaration ii Dedication iii Acknowledgement iv Abstract v Abstrak vi List of Figures x List of Tables xi CHAPTER I: INTRODUCTION 1.1 Introduction 1 1.2 Background of the problem 3 1.3 Objective of study 5 1.4 Scope of study 6 1.5 Significance of study 6 1.6 Research methodology 7 CHAPTER II: VARIATION ORDER – CAUSES AND EFFECTS 2.1 Introduction 9 2.2 Definition of variation order 10 2.3 Causes of Variation Orders 15 2.4 Effects of Variation Orders 19 2.5 Variation Claims Procedures under the PWD Standard Form 203 23 Summary CHAPTER III: RESEARCH DESIGN 3.1 Introduction 28 3.2 Research Design 28 3.3 Research Procedure 30 3.4 Data Gathering Process and Instrumentation 35 3.4.1 Document Study Design 37 3.4.2 Questionnaire Survey Design 40 3.4.3 Structured Interview Research Design 43 3.4.4 Summary 46 CHAPTER IV: RESEARCH ANALYSIS AND FINDINGS 4.1 Introduction 47 4.2 Respondent and primary source of information 48 4.3 Limitation of study 50 4.4 Data Analysis 50 4.4.1 1st Method: Frequency Analysis 50 4.4.2 2nd Method: Relative Index Analysis 51 4.4.3 3rd Method: Document Study Analysis 52 4.5 Research analysis of the construction contract document study 53 4.6 Research Findings of the Construction Contract Document Study 53 4.7 Research Analysis of the Respondent for Questionnaire and Interview 4.8 Research Findings of the Respondent for Questionnaire Survey and Interview 4.9 64 Research Findings of Effects of Variation Orders for Questionnaire Survey and Interview 4.13 59 Research Analysis of Effects of Variation Orders for Questionnaire Survey and Interview 4.12 59 Research Findings of Contribution Factors of Variation Orders for Questionnaire Survey and Interview 4.11 57 Research Analysis of Contribution Factors of Variation Orders for Questionnaire Survey and Interview 4.10 56 65 Research Analysis of Proposed Strategies to Minimize the Adverse Effects of Variation Orders for Questionnaire Survey and Interview 4.14 68 Research Findings of Proposed Strategies to Minimize the Adverse Effects of Variation Orders for Questionnaire 4.15 Survey and Interview 69 Summary 71 CHAPTER V: CONCLUSION 5.1 Introduction 72 5.2 1st Objective; To identify contribution factors of variation orders 72 5.3 2nd Objective; To study the effects of variation orders in construction Projects 5.4 74 3rd Objective; To propose strategies to minimize the adverse effects of variation orders 77 Bibliography 79 Appendix 87 LIST OF FIGURES Figure 1.1: Research methodology 8 Figure 2.1: Some of the events where the supervising officer shall issue instruction 13 Figure 2.2: Some of the events where the supervising officer is deemed to have given instructions 14 Figure 2.3: Some of the events where the supervising officer may issue instructions 14 Figure 2.4: Process from inception to site operations 16 Figure 2.5: Origin of variation 18 Figure 2.6: Variation order process 24 Figure 3.1: Research design 29 Figure 3.2: General research procedure 31 Figure 3.3: Research methodology phase 1 32 Figure 3.4: Research methodology phase 2 33 Figure 3.5: Research methodology phase 3 34 Figure 3.6: Research design procedure 35 Figure 4.1: Respondents categories 48 Figure 4.2: Types of contract document 54 Figure 4.3: Variation order value according to types of contract 54 Figure 4.4: Variation order value according to types of contract for every project 55 Figure 4.5: Respondent organization for questionnaire survey 57 Figure 4.6: Respondent profession for questionnaire survey 58 Figure 4.7: Reasons for providing a variation clause in a building contract 60 Figure 4.8: Reasons for claims by contractors 62 Figure 4.9: Greatest problem in contract management 63 Figure 4.10: Effects of variation orders 66 Figure 4.11: Strategies to minimize adverse effects of variation orders 70 Figure 5.1: Summaries of proposed strategy 78 LIST OF TABLES Table 1.1: The summaries of government allocation and expenditure for such development within Seventh Malaysian Plan, 1996-2000 7 Table 3.1: Instruments in data gathering process 36 Table 3.2: Principles of qualitative research 37 Table 3.3: Validity in qualitative research 38 Table 3.4: Procedure of document study 40 Table 3.5: Steps to design and manage questionnaire 41 Table 3.6: Questionnaire research design 41 Table 3.7: Questionnaire survey section 42 Table 3.8: Types of interview 44 Table 3.9: Do and Don’t during interview 45 Table 3.10: Structured interview design 46 Table 4.1: UTM construction projects during Seventh Malaysian Plan 49 Table 4.2: Document study general information tabulation 53 Table 4.3: Variation order value according to types of contract 54 Table 4.4: Causes of variation order used in questionnaire 56 Table 4.5: Reasons for providing a variation clause in a building contract 59 Table 4.6: Contribution factors of variation orders 61 Table 4.7: Reasons for claims by contractor 62 Table 4.8: Effects of variation orders 64 Table 4.9: Findings of effects of variation orders 65 Table 4.10: Best five overall score in effects of variation orders 66 Table 5.1: Contribution factors of variation orders 73 Table 5.2: Effects of variation orders 75 Table 5.3: Overall score in effects of variation orders 76 CHAPTER I INTRODUCTION 1.1 Introduction The construction industry has been consistently criticized for poor performance in attaining its client’s requirements. Time and cost overruns were predominately common and were well documented. The incidence and magnitude of variations was identified as a major cause and a focus of much of the criticism. Variation issued during the construction period are time consuming and costly. Thus accepted as an inevitable part of construction, variations are a major cause of disruption, delay and disputes and generate significant cost impact (Ibbs et al, 2001). Delay is generally acknowledged as the most common, costly, complex and risky problem encountered in Malaysian construction projects. Many of the problems were originated from the lack of knowledge and skills needed (Azhan, 2004). Most of the construction projects are often plagued with delays and cost overruns, revealing this shows that most of the construction of Government School Projects initiated by Ministry of Educations especially for the School Computer Laboratory Projects, were totally delays and Housing Quarters for Teachers only 412 units completed out of 1900 units targeted in the Seventh Malaysian’s Plan from 1996-2000 (Berita, March 2002). Yet no empirical method or tool, quantitative or otherwise, is available for managing or controlling them. By that, the conventional approach is to include a percentage of the project cost as contingency in the pre-contract budget for their occurrences. The allocated contingency based on this method is largely judgmental and arbitrarily allocated. However, construction projects are unique; as they may have distinctive set of objectives, require the application of new technology or technical approaches to achieve the required result, or even duplicate a given set of results in an entirely different environment. This uniqueness makes the conventional method based wholly on the project manager/supervisors' experience and intuition in danger of overly simplistic and unrealistic. The objectives of the contingency allocation are to ensure that the budget set aside for the project is realistic and sufficient enough to contain the risk of unforeseen cost increases. Therefore any realistic contingency must serves as a basis for decision making concerning financial viability of the variations, and a baseline for their control. The problem could become worse when there is a series of variations, when the programmed is affected and when the time spent by the contractor’s head office staff becomes totally disproportionate to the value of the contract. There are many reasons why variations occur. They may be due to extra work caused by subsurface conditions, errors in contract documents, additional quantities of works or materials, reduction of work, or lack of proper communication between the parties. There is room for improvement in present practices for keeping track of variations. Therefore, proposing some strategies to minimize the variation orders can be valuable. 1.2 Background of the problem Variations are inevitable in any construction project (Ibbs et al, 2001). Needs of the owner may change in the course of design or construction, market conditions may impose changes to the parameters of the project, and technological developments may alter the design and the choice of the engineer. The engineer's review of the design may bring about changes to improve or optimize the design and hence the operations of the project. Furthermore, errors and omissions in engineering or construction may force a change. All these factors and many others necessitate changes that are costly and generally un-welcomed by all parties. Variations in drawings and contract documents usually lead to a change in contract price or contract schedule. Variations also increase the possibility of contractual disputes (O’Brien, 1998). Typically, variations present problems to all the parties involved in the construction process. Variations can be originated from numerous factors pertinent to the construction projects. Development in the education sector and the new modes of teaching and learning advanced the need for renovation or extension of existing academic institutions. The change of space in academic institutions is required to cater for the new technology used. The construction of an institutional building poses risks common to any other large projects (Faizal, 2005) The construction process can be influenced by highly changing variables and unpredictable factors that could result from different sources. These sources include the performance of construction parties, availability of resources, environmental conditions, involvement of other parties and contractual relations. As a consequence of these sources, the construction of projects may face variations that could cause delay in the project completion time (Clough and Sears, 1994). Kumaraswamy et al (1998) studied claims for extension of time due to excusable delays in Hong Kong's civil engineering projects. Their findings suggested that 15-20 percent time over run was caused mainly by inclement weather. A total of 50 percent of the projects surveyed were delayed because of variations. The institutional projects would also experience similar delays due to variations and inclement weather as Malaysia is in the tropical zone. Kaming et al (1997) studied the factors influencing construction time and cost over runs for high-rise projects in Indonesia where 31 project managers working in high-rise buildings were surveyed. Kaming et al (1997) pointed out that the major factors influencing cost over run were material cost increase due to inflation, inaccurate material estimating and the degree of project complexity. In the case of time over run, the most important factors that caused delays were design changes, poor labour productivity, inadequate planning, and resource shortage. The magnitude of average schedule slippage due to variations was reported as 18 percent (CII, 1990; Zeitoun and Oberlender, 1993). The deviation (variation) cost amounted to an average of 14 percent of the total cost of the project. Although there have been cases where variation cost accounted for as high as 100 percent of the budgeted funds, the industry norm was about 10 percent. The impact of variations varies from one project to another. However, it is generally accepted that variations can affect construction projects with unpalatable consequences in time and cost (Hester et all, 1991; Ibbs et al, 2001). Variations are of two types, namely beneficial variations and detrimental variations. Beneficial variations are those that actually help to improve quality, reduce cost, schedule, or degree of difficulty in the project. Detrimental variations are those that reduce owner value or have a negative impact on a project. The project team should be able to take advantage of beneficial variations when the opportunity arises. The need to make changes on a construction project is a matter of practical reality. Even the most thoughtfully planned project may necessitate changes due to various factors. The variations can be minimized when the problem is studied collectively as early as possible, since the problems can be identified and beneficial variations can be made (CII, 1994). Variations are familiar in all types of construction projects. Variations in construction projects can cause substantial adjustment to the contract duration, total direct and indirect cost, or both. The variations and variation orders can be deleterious in any project, if not considered collectively by all participants. Most of University Teknologi Malaysia (UTM) construction projects were delayed with certain amount of variation order increasing from the original value of the contract sum. The focus of this study would be on the total value of all projects in the excess RM100 million with 18 numbers of projects received during the period of the Seventh Malaysian’s Plan from 1996-2000. Due to general background of the problems in the construction industry and the specific problems within the UTM construction scope, there is a cause for a study to be made on causes and effects of variation orders in UTM construction projects. 1.3 Objective of study The aim of this study is to identify and analyze the potential effects of variation orders in Malaysian construction projects. To achieve the above aim, the following objectives have been identified. 1. To identify contribution factors of variation orders. 2. To study the effects of variation orders in construction projects. 3. To propose strategies to minimize the adverse impact of variation orders. 1.4 Scope of study The scope of the study is focused on government projects. The imperative of the study would be reflected on the total value of all projects in the excess RM100 million with the projects reviewed during the time of the Seventh Malaysian Plan from 1996-2000, where most of the UTM construction projects were implemented during this period. 1.5 Significance of study As variation orders can have numerous negative effects to projects cost and schedule, this study is carried out to identified the major causes those contribute to variation orders and to study the effects of variation orders during the implementation of construction projects, which will be supportive for construction professionals in assessing and taking proactive measures for reducing the adverse impact of that. Noted that the Government had allocated for the five (5) years development about RM103.56billion, and RM 20.19billion from that amount were for education and training sector development. From RM145million that had been allotted to UTM construction projects, about RM108million had been laid out from RM105million (original contract). This amendment occurred because of variation order. Reflecting to variation order, almost RM3million could be saved if variation order can be controlled and this was one of the adverse effects that rise from variation order. The summaries of these situations are shown in Table 1.1. Table 1.1: The Summaries of Government Allocation and Expenditure for Such Development within Seventh Malaysian Plan, 1996-2000. Subject Allocation (RM) Expenditure (RM) By Sector : Education And Training 20.19 Billion 19.72 Billion UTM 145 Million 108 Million (Source: Harta Bina, UTM; RMK7, 1996-2000) 1.7 Research methodology The method used in conducting this study started with literature review. This followed with the document study, that are study, review and analyze of contract documents and final accounts that is related to variation orders. The document contract are treated as forbidden document and restricted therefore digital photo study are required to be employed where the document are not to be brought out from the particular area. The digital photo study of the contract document will be prepared similarly to the document study. Vital aspects of variation orders in the contract document will be identified and tabulated accordingly to their considerable. The focus of the research mainly concentrated at the client organization as the primary respondent where the contract document originated. Structured interviews are to be conducted with the professionals in the client organization who are involved in the construction process and contract administration. This will reveal the facts for the second objective that is the effects of variation orders in construction projects. In order to strengthen the data for the secondary respondent, telephone interview with the contractor and the consultant parties will be conducted. After the telephone interview, if the secondary respondents are cooperative and supportive, postal questionnaire will be sent to them for a better detailed exploration. Further structured interviews are deliberate for the secondary respondent where possible. Finally, matching methods were in use as in preceding step by performing structured interview and questionnaire in the client organization and telephone survey with the consultants and contractor to recognize strategies to minimize the adverse effects of variation orders. Advance analysis and synthesis of the documents will be prepared to identify the strategies that can be done. The proposed strategies to minimize the adverse impact of variation orders expose as a result. The summaries of research methodology are shown in figure below. Methodology Phase 1 Methodology Phase 2 Methodology Phase 3 Figure 1.1: Research Methodology CHAPTER II VARIATION ORDER – CAUSES AND EFFECTS 2.1 Introduction Variation orders are among the most significant sources of cost growth and disruptions to field productivity on construction projects. Two sources of variation orders exist on construction projects. Owner-generated variation orders are issued when an amendment to the project scope, design, or detailing is requested by the owner, and a change to the original contract agreement is required. Field- generated variations orders come up when problems and conflicts are detected in the field that requires a redesign or reconfiguration of the design. In both cases, variation orders can have numerous negative effects to projects cost and schedule. These negative effects are augmented depending on the timing of the variation order; with risky effects increasing the further the project progresses. Often called “unforeseen,” field generated variation orders are often highly disruptive to labour productivity, as one or more trades are strained to disrupt planned work sequences, and at times, complete rework. While owner generated variation orders are often predictable, field- generated variations orders often happen from design errors or a lack or coordination in contract documents, and are usually preventable. 2.3 Definition of variation order There is no one definition of what is a variation. Each standard form of building contract has its own definition but clearly ‘variation’, in generic sense, refers to any alteration to the basis upon which the contract was let. This means the term embraces not only changes to the work or matters appertaining to the work in accordance with the provisions of contract, but also changes to the contract conditions themselves. A variation can be taken to be any, a combination of any or all of the following: i. Variation in building projects may mean ‘the alteration or modification of the design, quality or quantity of the works, as shown upon the contract drawings and described by or referred to in the contract bills, and includes the addition, omission or substitution of any work, the alteration of the kind or standard of any of the materials as goods to be used in the works, and the removal from the site of any work materials or goods executed or brought thereon by the contractor for the purposes of the works other than work or material or goods which are not in accordance with the contract’ (Clause 24(a): JKR 203) ii. Variations in building projects together with instructions regarding the expenditure of provisional sums, prime cost sums and instructions concerning the nature of the work which are not specifically termed a variation in the contract documents. iii. Variation of contract in law, i.e. if both parties alter a contract document by agreement after execution of the original contract this is a variation of the contract terms or conditions. iv. Variation of price clause which enables the contract sum to be adjusted for rises and falls in the cost of labour or materials. It is clear that variations are directly attributed to matters not being as stated or as required in the contract documents. This happen either because circumstances actually change or because circumstances upon which the contract documents were based were misconstrued. The former is a matter which can easily appreciate and comprehend; nevertheless, it still has two distinct aspects. Firstly, circumstances may change in such a way, over which can have no control, that the documentation can now be seen to be defective. Alternatively, circumstances may require that the client determines a choice of action, with the resulting choice creating a variation. That documentation is erroneous because of misinterpretation, lack of skill or whatever, is more difficult to accept. Nevertheless, this problem exists and is often a direct result of how and when the design developed. For example, if a detail was believed to be complete it would be quantified and described accordingly, but the belief that it was complete might well be erroneous. Likewise, a detail known to be incomplete would on many occasions be assumed, quantified and described. Occasionally such items are identifiable and are marked as provisional, but frequently they are not, and there are instances where whole projects are documented on incomplete details and without any indication of that fact save the drawings themselves. Building and civil engineering contracts generally have within them express provisions enabling the supervising officer to issue instructions. It is accepted that building and civil engineering contracts have an implied term that the supervising officer shall issue instructions to the contractor whenever such instructions are required. This is an obligation upon the supervising officer and not a right. Clearly, the supervising officer must supply all drawings and information necessary for the execution of the works, but it is submitted that such drawings and information cannot change the obligations undertaken by the contractor, unless express provision is made within the contract or the contractor gives his consent. If this submission is correct then no implied term can give the supervising officer a general right to issue instructions. However, a term will be implied which compels the supervising officer to issue instructions whenever they are necessary for the proper performance and execution of the works. Failure of the supervising officer to give timely instructions may well give rise to a breach of an implied term. A distinction between a right and an obligation is necessary as it is of contractual significance. A term to the effect that the supervising officer will issue necessary instructions for the due performance will be implied in the absence of an express provision. It is necessary to consider what constitutes an instruction and to distinguish between the types of instructions from a supervising officer because whether an instruction exists is contractually significant, as is the type and form of the instruction. The contractor requires to receive the information in due time, and as long as he does he is not adversely affected by its issue. Thus the supervising officer is required to fulfill his obligation of providing sufficient details to enable the contractor to comply with his obligations. The use of the word ‘instruction’ in the express provision of PWD Standard Forms of Contract approximately equates to the ordinary definition given in The Concise Oxford Dictionary: a direction or order. However, it should be noted that not all directions are considered to be instructions – see clause 5 of PWD Standard Form 203. Instructions are often confused with variations or variation orders. An instruction may constitute a variation, and express authority to issue instructions requiring a variation is contained in all the PWD contracts under consideration. However, not all instructions will be variations. Many instructions are patently not variations yet contractors generally view a supervising officer’s instruction as a variation with the potential that offers for additional remuneration and/or extension of time. Figures 2.1 to 2.3 show some events which enable supervising officers to issue instructions with regard to stated issues. In some instances the issue of such instructions is discretionary, that is the supervising officer may, in other instances he shall issue instructions, and on other occasions he is deemed to have given an instruction. -Where the expenditure of provisional sums included either in the main contract or subcontract is required S.O. shall issue instruction -Notification by the contractor of a default by the original nominated subcontractor. -Nomination of nominated supplier. -Where the subcontractor validly determines his own employment. -Notification by the contractor of a discrepancy in or divergence between or within documents, including instructions (except where the instruction constitute a variation) any drawings or documents issued. -Where there is a divergence between the Statutory Requirement and other related documents and/or instruction requiring a variation. -Notification by the contractor of the existence of antiquities. -Failure of proposed nomination to proceed to contract. -Determination of subcontractors’ employment as a consequence of their own default. - Nomination of proposed subcontractor where an alternative method of nomination is adopted. -Determination of subcontractors’ employment arising from bankruptcy, insolvency and the like. Figure 2.1: Some of the events where the supervising officer shall issue instruction (Source : Peter R. Hibberd, 1986) -Where an error or omission in description or quantity exists. S.O. is deemed to have given instructions -Compliance with emergency conditions -Where the removal and disposal of debris or damaged work and other specified items occurring as a result of war damage has taken place. Figure 2.2: Some of the events where the supervising officer is deemed to have given instructions (Source : Peter R. Hibberd, 1986) -Removal and disposal of debris occasioned by an insurable peril. -Removal and disposal of debris or damage, protective work, as a consequence of the works sustaining war damage. S.O. may issue instructions -Postponement of any work. -Where documents necessary for the purposes of compiling the final account are to be sent to the quantity surveyor -Error in setting out where cost is not to be borne by contractor. -Exclusion of persons employed on the site. -Making good of defects, shrinkage or other faults which appear within the defects liability period. -Removal of work, materials or goods not in accordance with the contract. -Opening up for inspection or for arranging tests. Figure 2..3: Some of the events where the supervising officer may issue instructions (Source : Peter R. Hibberd, 1986) 2.3 Causes of Variation Orders Before a decision is made to build new or alter existing building clients must consider their needs carefully. In the first instance they must ask themselves why it is necessary to incur expenses, and usually alternative ways round the problem would be sought. Figure 2.4 shows the process from inception to site operations. The client’s objectives are considered by the design team and a continuous process of design takes place until no further modifications can be incorporated, even when considered, because constraints of time and cost finally draw the line. The point at which this happens is extremely variable, being partly dependent upon the make up and nature of the design team and partly upon their relationship with the client body. The fundamental issue is not, however whether the design is conclude before or after commencement of the works, but whether the contractual arrangement chosen is compatible with the extent and timing of such design. In other words, some contracts accommodate degrees of change more readily than others because they accept that change is part of the design process which continues after the contract is made. It is therefore essential that the professional advisers select the appropriate level of design and adopt the contractual arrangement to suit. The appropriate level of pre contract design is dependent upon the priorities that the client establishes (e.g. time, cost, and aesthetics), and the design team should always discuss these priorities fully with the client. Even where the design team concludes their design, it can be argued that the design process itself is still not complete because the contractor (not a member of the design team in traditional procedures) is responsible for the last level of design in many, if not all, instances. The level of design by the contractor may be a conscious decision. 4. What type of building 4. Preliminaries 1. It is necessary to build 5. Appointment of consultants 1. Outline planning 5. Report 2. Architect appointment INCEPTION 2. Can it be done? 6. Decision to continue with project 3. The brief FEASIBILITY 3. Site visit [BRIEFING] 3. Construct a Model 1. Detailed 4. Alternative proposals 2. Brief specifications SCHEME DESIGN [SKETCH PLAN] 1. Layout of building 2. Structural design OUTLINE PROPOSAL 3. Services requirement 5. Estimated costs 4. Cost checks 1. Production drawings 4. Contract particulars 1. Detail drawing for building control 2. Schedules PRODUCTION INFORMATION 5. NS/NSC 2. Structural calculations by i 3. Drawings by services 3. Specifications 3. Bill 4. Final client’s DETAIL DESIGN 4. Appointment of contractor 1. Tender list prepared BQ 2. Invitation to tender TENDER ACTION [WORKING DRAWINGS] 3. Programme of work 3. Contractor takes possession of site PROJECT PLANNING COMPLETION 1. Practical completion arrangement OPERATION ON SITE 1. Supervision of work 3. Bill Figure 2.4: Process from inception to site operations 1. Analyze final costs 2. Final inspections of works & certify 3. Handover to client 2. Working up and checking [SITE OPERATIONS] (Source: Forster, G. 1986) 2. Working up an checking 2. Finalize programe of work 4. Commencement of work on site 1. Project meeting 1. Take off from drawings etc. 2. Record for future FEEDBACK It may also be involuntary and determined by the expertise of the operatives employed, with the end product not necessarily achieving and absolute standard but failing within and acceptable tolerance. This element of design is generally limited but is still significant because the contractor will often suggest that if the supervising officer requires the work to be carried out in a way different from his assumption then this constitutes an instruction which causes a variation to the basis upon which the contract is let, therefore financial adjustment in favour of the contractor is required on the basis that the contractor’s assumption will always be the least expensive. It is evident that many changes to the works occur even though the clients’ brief remains the same; however, the client must be able to amend his brief as necessary. The amendment to the design brief will frequently result in a change to the work, and many practioners believe this latter point is why a variation clause exists. Matters of design in the widest sense are the major cause of variations but there are in addition matters which appertain to the works but do not affect its design. For instance, the area of site and its access, the sequence of operations, restrictions on working time and the like. These are issues that may require a variation because circumstances are not as they were when the contract documents were prepared or because they were not full appreciated at that time and were thus inaccurately recorded. It is possible for the client to avoid the consequences of some of these changes but he cannot where he warrants a particular situation or the law implies such a situation. In these circumstances the client will be considered in default and must have a means of overcoming the problem of his default and express provisions, permitting variations of this nature exist within the standard forms of contract. Variations arise for a variety of reasons. Some are foreseeable, others are not. Some result from a genuine change of circumstances and others from the design team’s own inadequacies. Figure 2.5 shows the origin of variations. It is regrettable that what evidence there is seems to suggest that the design teams are the main cause of the involuntary variation. 2.4 Effects of Variation Orders Effects of variation orders were observed by many researchers (CII, 1986: CII, 1990: Clough and Sears, 1994: CII, 1994: Thomas and Napolitan, 1995: Fisk, 1997: Ibbs et. al., 1998). The 16 effects identified from the literature review are discussed below; Variations during the project may affect the project progress and quality (CII, 1994, Assaf et al, 1995). Time has an equivalent money value even if the professional team tries its best to keep the project completion schedule intact. However, only major variations during the project may affect the project completion time. The contractor would usually try to accommodate the variations by utilizing the free floats in the construction schedules. Hence, the variations affect the progress but without any delay in the project completion. The most common effect of variations, during the construction phase, is the increase in project cost (CII, 1990). Any major additions or alterations in the design may eventually increase the project cost (Clough and Sears, 1994). In every construction project, a contingency sum is usually allocated to cater for possible variations in the project, while keeping the overall project cost intact. Variations are frequent in complex technological projects (CII, 1995). Specialized manpower is one of the integral resources required for complex technological projects (Fisk, 1997). Depending on the nature, occasionally, the variations may require hiring new professionals or change in the entire project team. The project progress was expected to be greatly affected in cases where the new professionals were not readily available. Variations require processing procedures, paper work and reviews before they can even be implemented (O’Brien, 1998). The process and implementation of variations in construction projects would increase the overhead expenses for all the participants concerned. Normally these overhead charges are provided for from the contingency fund allocated for the construction project. Delay in payment occurred frequently due to variations in construction projects (CII, 1990. Variations may hinder the project progress, leading to delays in achieving the targeted milestones during construction (CII, 1995. Eventually, this may affect payment to the contractors. Occasionally this delay may cause severe problems that end up in delays in payment to the subcontractors; this is because main contractors may not be able to pay the subcontractors unless they get paid by the owner first. Variations, if frequent, may affect the quality of work adversely (Fisk, 1997). According to CII (1995), the quality of work was usually poor because of frequent variations because contractors tended to compensate for the losses by cutting corners. Interruption, delays and redirection of work that are associated with variation orders have a negative impact on labor productivity. These in turn can be translated into labor cost or dollar value (Ibbs, 1997). Hester et al (1991) argued that the productivity of workers was expected to be greatly affected in cases where they were required to work overtime for prolonged periods to compensate for schedule delays. Thomas and Napolitan (1995) concluded that variations normally led to disruptions and these disruptions were responsible for labor productivity degradation. The most significant types of disruptions were due to the lack of materials and information as well as the work out of sequence. Lack of material was reported as the most serious disruption. Hence, to manage variation, one needed to manage these disruptions. However, the disruptive effects could not be avoided in many instances. Variations which are imposed when construction is underway, may require revised procurement requests (O’Brien, 1998). Procurement delays can be frequent due to variations that require new materials and specialised equipment. Hester et al (1991) observed that procurement delays were common effects of variations related to new resources for construction projects. Rework and demolition are frequent occurrences due to variations in construction projects (Clough and Sears, 1994). Variations that are imposed when construction is underway or even completed, usually lead to reworks and delays in project completion (CII, 1994). Rework and demolition are potential effects of variations in construction, depending on the timing of the occurrence of the variations. These effects are to be expected due to variations during the construction phase. This is because the variations during the design phase do not require any rework or demolition on construction sites. Logistics delays may occur due to variations requiring new materials and equipment (Fisk, 1997). Hester et al (1991) observed that logistics delays were significant effects of variations in construction projects. Logistics delays were experienced in construction projects where variations in the construction phase required new materials, tools and equipments. Variations are referred to as a major source of construction claims and disputes (Fisk, 1997; Kumaraswamy et al, 1998). The claims and disputes may affect the firm's reputation adversely, leading to insolvency in severe cases. Variations also increase the possibility of professional disputes. Conventionally, variations present problems to all the parties involved in the construction process. Variations may affect the safety conditions in construction projects (O’Brien, 1998: Arain et. Al., 2004). This is because variations in construction methods, materials and equipment may require additional safety measures during the construction phase. Construction changes are a major source of construction dispute (Fisk, 1997). Eventually, variations may affect professional relations, leading to disputes. Clear procedures that are presented in the contract and fair allocation of risks can help in resolving disputes through negotiation rather than litigation (CII,1986: Arain et. Al., 2004). Additional payments for the contractor can be a potential effect of variations in construction projects. This is because variations are considered to be a common source of additional works for the contractor (O’Brien, 1998). Due to additional payments, the contractor looks forward to variations in the construction project. Like poor professional relations, disputes among professionals are also potential effects of frequent variations in construction projects. The disputes over variation orders and claims are inevitable and the variation clauses are often the source of project disputes (CII, 1986). Clear procedures presented in the contract and fair allocation of risks can help in resolving disputes through negotiation rather than litigation (CII, 1986). Frequent communication and strong coordination can assist in eliminating the disputes between professionals. Completion schedule delay is a frequent result of variations in construction projects (Ibbs, 1997). The magnitude of the schedule being delayed due to variations was reported by Zeitoun and Oberlender (1993) to be 9 percent of the original schedule for 71 fixed price projects studied. Kumaraswamy et. al. (1998) studied claims for extension of time due to excusable delays in Hong Kong's civil engineering projects. Their findings suggested that 50 percent of the projects surveyed were delayed because of variations 2.5 Variation Claims Procedures under the PWD Standard Form 203 Most standard forms of contract include a clause under which the employer or his representative is able to issue an instruction to the contractor to vary the works which are described in the contract. A change in shape of the scheme, the introduction of different materials, revised timing and sequence are all usually provided for by the variations clause. It will also usually include a mechanism for evaluating the financial effect of the variation and there is normally provision for adjusting the completion date. In the absence of such a clause the employer could be in a difficulty should a variation to the works be required. The contractor could either refuse to carry out the work or undertake the work or insist upon payment on a quantum merit or fair valuation basis. Calculation of the price for the extra work applying this method could involve payment well in excess of the contract rates. Even where a contract includes the usual variations clause there may be circumstances which could lead to additions or changes introduced by the employer which falls outside the variations clause. Contractors who find themselves with unattractive contract prices would find it to their advantage to be able to argue that a change introduced by the employer fell outside the variations clause thus leaving the way open to argue that payment for the change should be on a quantum merit or fair valuation basis. Figure 2.6 shows the variation orders process. Figure 2.6: Variation Order Process (Source: Baharuddin, 2005) Based on the Public Work Department (PWD) Standard Form 203, variation claims procedures should include; ü All work requiring work to be varied must be in writing. ü Oral instructions must be confirmed by the contractor within seven days. ü Where provisions of the contract empowers the S.O. to vary the work, he must comply with treasury instruction which stipulates that prior approval of the relevant authority must be obtained before an instruction requiring work to be varied may be issued. ü Treasury instruction also makes distinctions between variations form claims by the contractor and amendment of contract sums. Claims from contractor and adjustment of contract sum are exempted from prior approval need. Variations which result in reduction of contract sum are also exempted. ü The following are exempted from need for prior approval; § Claims by the contractor for loss and/or expense arising from; compliance with S.O. instruction, delay caused by the Government, discrepancies in or between documents of the contract document. § Claims by the contractor for fees and charges for permanent connection to public sewers and water and electricity mains. § Other claims expressed permitted under the contract. § Adjustment of contract sum for or due to; adjustment of P.C. and provisional sum, remeasured of work measured provisional, fluctuation of prices. § Variations which result in reduction of contract sums. ü Prior approval for variation work must be obtained from the relevant authority as follows; § State Head or Head of Special Unit of engineering department in committee: If the contract sum does not exceed RM5.0m and the proposed variation does not exceed 20% of the contract sum, or RM1.0m, whichever is lower. § Branch Director of engineering department in committee: If the contract sum does not exceed RM7.5m and the proposed variation does not exceed 20% of the contract sum, or RM1.5m, whichever is lower. § Deputy Director General of engineering department in committee:If the contract sum does not exceed RM10.0m and the proposed variation does not exceed 30% of the contract sum, or RM3.0m, whichever is lower. § Director General of engineering department in committee: If the contract sum does not exceed RM20.0m and the proposed variation does not exceed 30% of the contract sum, or RM6.0m, whichever is lower. § Secretary General of Minister of Finance: All other cases ü The treasury circular also required approval to be granted by committees rather than individual officers. ü Application for work to be varied before instruction can be issued must be submitted to the secretariat at the various states of other levels of JKR in four copies using standard application forms. Rules for variations in the standard conditions must be observed. ü Once approved, the instruction can be issued and work executed accordingly. However, before any certificate can be made, the measurement of the work must be made and a certificate of variation works prepared. This certificate must be signed by the S.O. and among the particulars required are the justification for the works, the S.O.’s instruction and details of the measurement. ü Adjustment of the contract sum is then made so that the contractor can be paid accordingly. This certificate of adjustment must be prepared whenever the contract sum need adjustment, i.e. after every variation issued. 2.6 Summary References have already been made to the causes and effects of variation orders. Any other change can only take place where there is agreement between the parties. It is possible for the parties to a contract to vary the terms of the contract, so long as they agree and so long as the variation is not legally invalid. Even where a variation is legally invalid it may still be honoured by the parties, the fact that it is not valid in law meaning only that the variation is not enforceable. There are a number of reasons why a variation may be invalid, for instance, if the essentials of a valid contract do not exist then the variation is invalid in law. The most commonly encountered reason for a variation of contract not to be valid is lack of consideration. A variation of contract must generally have some consideration, and where this does not exist a deed of variation would need to be executed in order for the variation to be enforced in law. A deed of variation overcomes lack of consideration because the law accepts that a deed, which is a contract under seal, does not require consideration for the contract to be valid. CHAPTER III RESEARCH DESIGN 3.3 Introduction Research design ties up all of the aspects in a research project jointly. A design is a plan for constructing the research structure using a succinct notation, that recapitulate a multifarious design structure proficiently, to show how all of the most important parts of the research project collaborate to attempt to address the central research objective. The structural approach to research design in this chapter will make clear to the detail process of the research procedural where the research methodology elucidates the common modus operandi of the research. 3.4 Research Design The compass of the research design is to generate some new knowledge. This, in theory, can take three main appearances; 1. Investigative Research Design 2. Constructive Research Design 3. Pragmatic Research Design - a new problem can be structured and identified. -a new solution to a problem can be developed. - Empirical proof on the practicability of an existing solution to a problem can be provided. Figure 3.1: Research Design (Stoner J.A.F.& Freeman R.E. 1992) Producing a competent research design is one of most problematical and highly constructive tasks that facilitate to simplify principles of design logic. The research design must be exact and greatly flexible. The design must be extroverted enough to adapt these very complexities while still pointing towards relevant data in the epistemological orientation. None of the above scope can cater the planned research in its category therefore, following discussion the focal arrangement of the research. The initiation was with the document study followed by research questionnaire, and structured interview that has driven the design of the study. It is implicit that the researcher’s personal qualities needed for flexible research design are commonly regarded as skills central to the combination of qualitative and quantitative research design procedure. Skills such as having an open and enquiring mind, being good listener, general sensitivity and responsiveness to contradictory evidence are relevant to the role of qualitative research analysis. In quantitative research analysis, it is a systematic scientific investigation to develop and employ mathematical models, theories and hypothesis pertaining to research design. The process of measurement is central to quantitative research because it provides the fundamental connection between empirical observation and mathematical expression of quantitative relationships. In the research design procedure, flexibility exists between both qualitative and quantitative approach where the employment of rating scale and proposed model reflect quantitative. The qualitative values are shown in document study and structured interview. Quantitative methods are efficient, but qualitative methods were used to get information that cannot obtain well with quantitative methods. Qualitative methods are used to study the construction contract document and human interaction behavior in interviews. Complex, understanding and opinions are not well captured by quantitative techniques. Qualitative methods study the variations of complex. By connecting quantitative data to qualitative methods, the flexibility enriches the results with people’s words and opinion. The usage of qualitative analysis techniques is therefore both inductive and interactive in flexibility with the usage of quantitative definite with mathematical models. 3.3 Research Procedure Research procedure is a systematic development of investigation planned to realize, infer and improve facts. This intellectual investigation procedure produces a greater understanding of problems or hypothesis and makes practical applications through theories, questioning and reasoning to achieve the research objectives hoping to produce some new knowledge. Generally, research procedure is understood to follow a certain structural process. Though step order may vary depending on the subject matter and researcher, the following steps are usually part of most formal research; Formation of the topic Hypothesis Conceptual definitions Operational definitions Conclusion Analysis of data Gathering data Operational definitions Figure 3.2: General Research Procedure (Stoner J.A.F.& Freeman R.E. 1992) Succeeding the reference provided these research procedures were further detailed to stipulate the intended method to accomplish specific objective stated. The initial research procedure started with the formulation of the research topic that is clearly explained in the first chapter of introduction. Following that, is background of the problems discuss construction industry problems and ending with UTM construction project taken as the scope of study. The research objectives were specifically design where it is systematically divided in three (3) stages in consecutive sequence. The first research objective is related to second and continuously interconnected to the third objective. Data obtain in the first objective is used in second objective and finally to justify the third objective. The designs were in continuous consecutive sequence. The first stage is to perform a document study. It is an aggregate in depth study of review, analyze and synthesis of the final account document content. In the various sections of the document the contribution factors of variation orders will be identified. The variety range of the factors will then be organize and assemble in tabulation form according to their important rating. The contribution factors of variation orders are to be further classified into their scale of important. The highly important factors are selected to be promoted and used in the next stage. The method used in conducting this research started with literature exploration of the electronic and hard copy media in answering the research objectives. This is followed with the document study; that are study, review, analyze of construction contract and final account document content that is related to contribution factors of variation orders. The documents are treated as controlled document and limited consequently digital photo study are required to be employed where the documents are not to be brought out from the specified area. The digital photo study of the contract document will be prepared similarly to the document study. Imperative aspects of contribution factors of variation orders in the documents will be identified and tabulated accordingly to their significant. The summaries of research methodology phase 1 are shown in figure below. 7th Malaysian Plan 1996-2000 [DOCUMENT STUDY] Review OBJECTIVE 1 Analysis Contribution Factors of Variation Orders Synthesis 18 Documents RM100Million METHODOLOGY PHASE 1 Figure 3.3: Research Methodology Phase 1 The promoted, highly important contribution factors of variation orders are then put to test in their effects of variation orders. This is simply to identify the effects of variation orders within the studied document. Structured interview and questionnaire will be employed within the client organization primarily and consultant and contractor organization secondarily to discover the effects of variation orders. Where face to face structured interview were not possible, to further reinforced the data, telephone interview with selected relevant contractor and the consultant will be conducted. The highly related and significant sections of the documents are then exposed to the next stage. The focus of the research mainly concentrated at the client organization as the primarily respondent where the contract and final account documents originated. Structured interviews and questionnaire (5 Scale Likert) are to be conducted with the professionals in the client organization who are involved in the construction process and contract administration. This will reveal the facts for the second objective that is the effects of variation orders. In order to strengthen the data for the secondary respondent, telephone interview with the contractor and the consultant parties will be conducted. After the telephone interviews, if the secondary respondents are accommodating and supportive, postal questionnaire will be sent to them for a better specific investigation. Further structured interviews are intended for the secondary respondent where possible. The summaries of research methodology phase 2 are shown in figure below. PRIMARY RESPONDENT [Harta Bina] STRUCTURED INTERVIEW OBJECTIVE 2 Effects of Variation Orders QUESTIONNAIRE (5 Scale Likert) SECONDARY RESPONDENTS [Contractor Consultant] METHODOLOGY PHASE 2 Figure 3.4: Research Methodology Phase 2 The final stage of the study is to propose strategies to minimize the adverse effect of variation orders. Similar methods were employed as in previous stage by conducting structured interview and questionnaire within the client organization and the telephone survey with the consultants and contractors organization. The proposal of the strategies minimizes the adverse effect of variation orders will be made accordingly. Finally, the research identifies the possible of strategies in order to minimize the adverse effects of variation orders. Matching methods were employed as in previous step by performing structured interview and questionnaire in the client organization and telephone survey with the consultants and contractors. Further analysis and synthesis of the strategies to minimize the adverse effects of variation orders will be prepared to distinguish the strategies that can be done. The proposed strategies to minimize the adverse effects of variation orders unveil consequently. The summaries of research methodology phase 3 are shown in figure below. PRIMARY RESPONDENT [Harta Bina] OBJECTIVE 3 Proposed strategies to minimize variation orders. SECONDARY RESPONDENTS [Contractor Consultant] STRUCTURED INTERVIEW QUESTIONNAIRE (5 Scale Likert) ANALYSIS METHODOLOGY PHASE 3 Figure 3.5: Research Methodology Phase 3. The data gathering process and instrumentation will detailed in the following sub topic. The whole discussions of research design procedure are represented graphically in the following figure. Methodology Phase 1 Methodology Phase 2 Methodology Phase 3 Figure 3.6: Research Design Procedure 3.4 Data Gathering Process and Instrumentation Instrumentation and process of gathering data is the most arduous and exclusive phase in a research design and it be worthy of cautiously planned as shown in above figure. All the other processes were evidently clarify and discussed in various chapter in this write up. For this research design chapter, the focus will only be concentrated on data gathering instrumentation and process. In many manners, the data gathering instrumentation and process were related with operations that come before and after it in the research design shown. If there are weaknesses in the preceding operations, it heralds difficulties in answering the research questions and the objective, thus, the need for redesign of the data gathering instrumentation, and if data collecting is haphazard, there will be problems in the later research analysis. To address sufficiently the research design a variety of data collection methods and instruments can be use. These methods and instruments are not specific to any one design but provide data that when used in combinations will address the research questions. Examples of each of these instruments, for the purpose of data gathering process, which are commonly used by scholars. Action Research Case Study Classification Experience And Intuition Mathematical Experiments Interviews Map Making Models And Simulation Participant Physical Traces Observation Analysis Statistical Surveys Table 3.1: Instruments in Data Gathering Process (Stoner J.A.F, 1992) Etc. 3.4.5 Document Study Design All research is interpretive, guide by a set of beliefs and feelings about the world and how it should be understood and studied (Denzin & Lincoln, 1994). Document study is qualitative research that is defined as a process used to expand the perception of complex documentation in ways that cannot be understood with numbers. An analysis without numbers bluntly explained. Qualitative research has many features, each with its own theoretical and epistemological orientation, each exploring different issues and positing different kinds of concept. Qualitative researchers recognize that knowledge and understanding are contextually and historically grounded as well as linguistically constituted including phrase and verses. Many genres of qualitative research have become linked to issue of social change as scholars experiment with the boundaries of interpretation and sometime gather in a scope to be represented by key words. Qualitative researchers are guided by highly abstract principles which integrate the belief about; Ontology The philosophical study of existence and the nature of reality. The branch of philosophy dealing with the origin, Epistemology nature and limits of human knowledge. Any specific theory of the nature of human knowledge. Methodology The processes we use to develop our knowledge. Table 3.2: Principles of qualitative research. (Denzin & Lincoln, 1994) As the qualitative researchers are guided by highly abstract principles, the validity of the findings was arbitrary. Argument in various points of view can be posted arguing the flaws of the findings and leading it to astray. However, the following tables were generally accepted to be the common method of validation of the process. The table will be used for the purpose of validation in this research design. Descriptive The factual accuracy of the account as reported by the qualitative researcher. The degree to which the participants’ viewpoints, Interpretive thoughts, intentions, and experiences are accurately understood and reported by the qualitative researcher. The degree to which a theory or theoretical explanation Theoretical developed from a research study fits the data and is, therefore, credible and defensible. The degree to which a researcher is justified in concluding that an observed relationship is causal. Internal More often, qualitative researchers are concerned with studying and understanding a process rather than identifying possible cause and effect relationships. External validity is important when the researcher wants to generalize from a set of research findings to External other people, settings and times. Typically, generalizability is not the major purpose of qualitative research. Table 3.3: Validity in Qualitative Research. (Denzin & Lincoln, 1994) The object of a document study is to learn from a primary source of the principal task of historical study to recover and interpret the physical remains of the past. It is a qualitative analysis process that originator to quantitative, statistical work, a process to make the tacit foundations of an issue explicit, a process to deepen the understanding of verses and phrase that cannot be understood with numbers, a process that figure out what to count and what to compute. There are 18 numbers documents study of UTM construction contract document between the periods from 1996-200 of the Seventh Malaysian Plan with a total cost in the excess RM100 million as shown in Appendix 1. The objects of the document study are to identify the contribution factors of variation orders. The construction contract documents were informative and massive weighing not less than 4kg. Having 18 numbers of the document is enormously abundant to conduct a proper document study without the right procedure to approach the situation. Even handling the document around during studying process required huge table area a strenuous action when moving them from places. The following are the steps design to approach the document study procedure. The processes are similar to the research methodology phase 1 in figure 3.3. Procedure of Document Study; Step 1: Review It is a strategic grouping of the 18 contract document with their similarity of content and types of construction. Where the documents are control and limited digital photograph of the document were taken to study the content. As the document were collected and arrange accordingly on a huge table area the process of analyzing can begin. Step 2: Analysis Analyzing procedure is to open up each and every document to construed and interpreted verses and phrase in order to identify the contribution orders of variation orders. It is time consuming process to read the documents in similar manner to a proof reading process. Further evaluations were made following the marked pages for the chosen verses and phrase, the citation were meticulously done word by word to ensure their relatedness to the contribution factors of variation orders. After that the following procedure were to select the related verses an phrase and typed in Microsoft Word to proceed to next step. Step 3: Synthesis Where the selected verses and phrase are yet to type in Microsoft Word the highlighting procedure to identify key word related to the planning and control function were done in the contract document. The final procedures are the reevaluation and selection of the definitive key word to be used in the questionnaire survey. The questionnaire survey using the selected key word will validate and verify the research procedure in the document study accordingly to validity process as shown in table 3.1. Table 3.4: Procedure of Document Study 3.4.6 Questionnaire Survey Design Questionnaires are the simplest method to collect data from a huge number of respondents. A well-designed questionnaire that is used effectively can gather information on both the overall performance of the test system as well as information on specific components of the system. If the questionnaire includes demographic questions on the participants, they can be used to correlate performance and satisfaction with the test system among different grouped of users. It is important to remember that a questionnaire should be viewed as a multistage process beginning with definition of the aspects to be examined and ending with interpretation of the results. Every step needs to be designed carefully because the final results are only as good as the weakest link in the questionnaire process. The steps required to design and manage a questionnaire include; a. Defining the objective of the survey b. Determining the sampling group c. Writing the questionnaire d. Administering the questionnaire e. Interpretation of the results Table 3.5: Steps to design and manage questionnaire Questionnaire research design proceeds in an orderly and specific manner. Each item in the flow chart depends upon the successful completion of all the previous items A. Define Goals And Objective B. Design Methodology C. Determine Feasibility D. Develop Instrument E. Select Sample F. Conduct Pilot Test G. Revise Instruments H. Conduct Research I. Analyze Data J. Prepare Report Table 3.6: Questionnaire research design This discussion will concentrate on how to formulate the questionnaire design for the research based on the above mention general guide lines. The questionnaire survey design were intended to be as simple as possible but to be massive in information gathering in two pages single piece of paper. This will camouflage the complicated nature of the questionnaire as it is done in a single piece of paper. There is no fill in the blanks method of questions, but all are the rating scale technique where mathematical formulation leads to specific conclusion comparing to the opinion study of fill in the blank methods. All questions are directed to answer the objectives. The questionnaire survey was divided in 5 sections. a. General statement. b. Respondent general information. c. Objective 1: Contribution factors of variation orders. d. Objective 2: Effects of variation orders. e. Objective 3: Strategies to minimize the adverse effects of variation orders. Table 3.7: Questionnaire survey The responses to the questionnaire is based on Likert’s scale of five ordinal measures which is from one (1) to five (5) according to the level of effects of variation orders attributed to the question. Ordinal scale of 1 to 5 1 2 3 4 5 Increasing degree of effects of variation orders Figure 3.7: Five ordinal measures of agreement by Likert Scale 5= Highly effected 4= High effected 3= Medium effected 2= Low effected 1= Least effected Responses to the questionnaire were then analyzed. The analysis included ranking the factors in terms of degree of effecting. The main approach used to analyze the data is by using the Relative Index (RI) technique (Azhan, 2004). In the computation of the Relative Index the following formula was used; RI = ( 5n5 + 4n4 + 3n3 + 2n2 + n ) 5 (n5 + n4 + n3 + n2 + n ) Where; RI = relative Index n5, n4, n3 … = number of responding indices. The computation of the RI using this formula will yield the value of RI ranging from 0.2 to 1.0. The values 0.2 represent the lowest strength and the value 1.0 representing the maximum strength. 3.4.7 Structured Interview Research Design Interviewing is a common significant method to obtain comprehensive information from a single respondent or groups of respondent. It is very valuable to achieve expert opinions on the subject or talk to someone knowledgeable about a topic. There are several different types of interviews based on the technology available for interaction as follows (Arsham H, 2002); Face to face, interviews are to sit down and talk with someone. They are beneficial because the adaptation of Face To Face questions to the answer of the person being interview. Recording equipment may be required for the interview and it is highly recommended to bring two recording devices in case one fails. Phone interview can be used when to interview someone who is geographically far away, who is too busy to meet and Phone to talk with, or who does not want to use internet technology. A special recording device may be required to be use with most phone systems. Email interviews are less personal than face-to-face or phone interviews, but highly convenient for most individuals. Not much information can be obtained from someone in an email Email interview because it is not feasible to ask follow up questions or play off the interviewee’s responses. However, email interviews are useful because they are already in a digital format. It is also possible to interview someone via an instant messaging service such as MSN Messenger, ICQ or AOL Instant Messenger. These interviews allow a person to talk to Chat/Messaging people at great distances and give the benefit of adapting the questioning based on the responses receive. Where researcher and/or respondent are not fluent at typing, however the information obtain may not get as lengthy responses from this option. Table 3.8: Types of interview Arsham H (2002) also clarify the Do’s and Don’t during interview session; DO -be careful of the types of question ask. DON’T -pester or push the person in a interview. If the person does not want to talk about an issue, respect the desire. -start the interview with some small talk -stick to the questions rigidly. If an to give both the researcher and the interesting subject comes up that person to be interview a chance to get relates to the research, ask additional comfortable. questions about it. -bring redundant recording equipment in -allow the person that being interview case something happens to one of the to continually get off topic. If the recording devices conversation drifts, ask follow up questions to redirect the conversation to the subject at hand. -pay attention to what is being said during the interview and follow up responses that sound interesting. -come to the interview prepared. Learn as much as possible about the person that are going to interview takes place so that the questions can be tailored to them. Table 3.9: DO and DON’T during interview According to the general guideline provided and the previously discussed questionnaire survey design, the structured interview design was basically similar in format. The structured interview design was divided in 5 sections; all of the questions were open ended with some question having proposed multiple choice answers; a. General statement. b. Respondent general information. c. Objective 1: Contribution factors of variation orders. d. Objective 2: Effects of variation orders. e. Objective 3: Strategies to minimize the adverse effects of variation orders. Table 3.10: Structured interview design 3.4.8 Summary Research design is a long process that demands careful attention. The research design initially started from the first chapter in bits and pieces explain in the design that goes right though this chapter in describing means and ways in the creation of the whole research. The entire research designs were comprehensively describes in the research design procedure. Every research design topic started with a short literature review that continues with a precise step by step design interconnected directly to this research. Document study, questionnaire design, and structured interview were elaborated in immense aspect. By this clarification, it is easier to understand the proceeding chapter. CHAPTER IV RESEARCH ANALYSIS AND FINDINGS 4.2 Introduction This chapter analyses the data collected from the document study, questionnaires and structured interviews. The methods used are Frequency Analysis and Relative Index Analysis. The collected data from the questionnaires were tabulated and analyzed according to their ranking on relative index. Bar charts and pie charts created from their rating scale shown to represent their ranking. Interviews from respondents are presented, together with relationship with document study and questionnaires. The objective of this chapter is to identify the highest ranked factors for discussion and to find correlations with findings from the document study, structured interviews and proposed 4.2 Respondent and primary source of information The targeted respondents were divided into two categories as shown in Figure 4.1; Primary Respondent (1) Client; Harta Bina UTM Secondary Respondent (2) Consultant and (3) Contractor Figure 4.1: Respondents categories Primary respondents are personnel from Harta Bina Structural Organization. 3 personal identified related to the research mainly from the Contract Unit where the construction contract document were prepared, all of them participate in the questionnaire survey and structured interview for the purpose to acquire expert knowledge and opinion. Secondary respondents are consultant and contractors in the construction industry in general and some of them were related to the construction contract case study in minor parts. The total number of respondent from both categories counted 24 numbers. The primary source of information were 18 numbers of UTM Construction Contract Document between the periods from 1996 to 2000 of the Seventh Malaysian Plan with a total cost in the excess RM100 million as shown in Table 4.1; No. 1 2 3 4 5 6 7 8 9 10 11 12 13 14 15 16 17 18 Project’s Name Bangunan Tambahan Fakulti Kejuruteraan Kimia dan Sumber Asli Bangunan Tambahan Fakulti Sains Komputer dan Sistem Maklumat Bangunan Tambahan Fakulti Kejuruteraan Awam Bangunan Tambahan Fakulti Kejuruteraan Mekanikal Bangunan Tambahn Fakulti Kejuruteraan Elektrik Institut Ibnu Sina dan Tanah Runtuh Ibnu Sina Bangunan Palapes Bangunan Makmal Kaji Terbang Fakulti Kejuruteraan Mekanikal Sistem Bekalan Air G.I.S. Intra Elektrik Infra Telefon Bangunan Pusat Pengajian Siswazah (Baki Kerja) Pusat Komupter (D07) Bangunan Tambahan Fakulti Alam Bina Ubahsuai Fakulti Sains (C08) Ubahsuai Fakulti Ukur (B08) Bangunan Stor Pusat Total Contract Amount (RM) Contract Amount after Adjustment (RM) V.O Value (RM) 3,405,401.30 3,724,027.95 318,626.65 10,689,000.00 11,205,508.92 516,508.92 10,347,454.47 11,137,770.66 790,316.19 6,980,000.00 8,142,732.61 1,162,732.61 2,398,929.43 2,545,821.93 146,892.50 6,075,586.84 7,095,759.22 1,020,172.38 1,467,923.20 1,477,418.91 9,495.71 30,969,915.64 30,761,562.44 (208,353.20) 4,861,606.60 4,969,636.00 108,029.40 6,600,000.00 6,287,754.70 (312,245.30) 2,400,000.00 2,733,984.80 333,984.80 1,003,123.80 1,169,609.97 166,486.17 5,395,537.30 4,704,485.92 (691,051.38) 2,512,106.96 2,139,620.46 (372,486.50) 5,931,600.00 5,273,863.42 (657,736.58) 1,528,513.50 1,981,318.73 452,805.23 1,787,756.10 1,653,423.83 (134,332.27) 1,297,305.45 1,331,193.10 33,887.65 105,651,760.59 108,335,493.57 2,683,732.98 Table 4.1: UTM construction projects during Seventh Malaysian Plan 4.3 Limitation of study The research is limited to the Document Study of the 18 numbers of UTM construction contract document mentioned, the questionnaire and the structural interview conducted. 4.5 Data Analysis The collected data from the questionnaires were analyzed in two methods. These are Frequency Analysis and Relative Index Analysis. Frequency analysis is used as preliminary analysis. This method will show the frequency and the percentage. The frequencies are represented in the form of tables, pie charts and bar chart. In order to generate the result, the researcher used Microsoft Excel. 4.5.1 1st Method: Frequency Analysis Frequency analysis is a method to decompose a function, wave, or signal into its frequency components so that it is possible to have a frequency spectrum (Aminudin, 2006). The frequency analysis is used to represent results of data analysis of the number of frequency of response that the respondents give to different variables in the questionnaire survey and structural interview. The result has been tabulated in the form of frequency number and percentage according to total respondents. For graphic result presentation, pie chart and bar chart have been used as the summary. 4.5.2 2nd Method: Relative Index Analysis In Relative Index Analysis, the results are further summarized to attain the level of importance in evaluating the effects of variation orders. The respondents were requested to judge and weigh up the effects of variation orders accordingly to their experience and generally to Malaysian construction industry scenario. The evaluations were based on five-point scale starting with 1 for least effected to 5 for very highly effected. The data collected on the degree of effected of variation orders were tabulated based on the number of responses for each category of degree of effected of variation order. Based on the frequency analysis the relative index was then calculated to determine the ranking of each effects of variation orders being considered. The relative index analysis for variable is calculated by using the formula below (Azhan, 2004); RI = ( 5n5 + 4n4 + 3n3 + 2n2 + n ) 5 (n5 + n4 + n3 + n2 + n ) Where; RI = relative Index n5, n4, n3 … = number of responding indices. The computation of the Relative Index using this formula will yield the value of RI ranging from 0.2 to 1.0. The values 0.2 represent the lowest strength and the value 1.0 representing the maximum strength. 4.4.3 3rd Method: Document Study Analysis The general definition of a document study is to learn from a primary source of the principal task of historical study to recover and interpret the physical remains of the past. The objects of the document study analysis here are to identify the contributing factors of variation orders within its content. Procedure of Document Study Step 1; [Review] - Strategic grouping - Similarity of content - Digital photograph study (due to control and limited document) Step 2; [Analysis] - Construed and deduced words to identify the contribution factors of variation orders. - Evaluate word by word related to the contributing factors of variation orders. - Select the related factors. Step 3; [Synthesis] - Elimination of duplication, similarity and same meaning. - Summary and counting factors - Reevaluation and selection for key word to be used in the questionnaire. Figure 4.1: Procedure of Document Study 4.6 Research analysis of the construction contract document study The document study analysis were applied to 18 numbers documents study of UTM construction contract document between the period from 1996-2000 of the Seventh Malaysian Plan with a total cost in the excess RM100 million. The construction contract documents were immense with data, information, contract, bill and drawings. The documents studied were the original document, signed and stamped and were a legal original copy document at law. The documents were strict, limited and controlled document that need to be handle with care. Apart from that, certain data were private and confidential and not to become public information. The above document study procedure must be followed to manage the substantial information and size of the 18 numbers of the contract document properly. 4.6 Research Findings of the Construction Contract Document Study Below is the document study findings of the general important summary for the 18 construction contract document and the details were shown in Table 4.1. UTM Construction Contract Document during 7th Malaysian Plan Contract document (nos) Building works (nos) Renovation works (nos) Infrastructure works (nos) Contract amount (RM million) V.O. Value (RM million) Total Contract Amount (RM million) Total Contract Amount-after adjustment (RM million) Total Variation Amount (RM million) Contract duration (week) 18 12 2 4 1.00 – 31.00 33k - 1.20 105.65 108.34 2.69 10-95 Table 4.2: Document study general information tabulation The construction contract document shown to be well rounded consisting mainly new buildings work at 67% and the other contract document are reference to be compared to the buildings work contract document. Infrastructure works (nos), 4, 22% Renovation works (nos), 2, 11% Building works (nos), 12, 67% Figure 4.2: Types of contract document Below is the document study of the variation orders value according to types of contract identified within 18 contract documents. RM (million) Contract Amount Contract amount after adjustment V.O. Value 87.47 89.55 2.08 Renovation works 3.32 3.63 0.31 Infrastructure works 14.86 15.16 0.3 105.65 108.34 2.69 Types of contract Building works Total Table 4.3: Variation order value according to types of contract 2.5 2.08 2 1.5 RM (million) 1 0.5 0.31 0.3 Renovation works Infrastructure works 0 Building works Types of Work Figure 4.3: Variation order value according to types of contract Below is the document study of the variation orders value according to types of contract for every UTM’s projects identified within 18 contract documents. Infrastructure works, 0.08, 20% Building works , 0.17, 41% Renovation works, 0.16, 39% Figure 4.4: Variation order value according to types of contract for every project The variation order value shown to be well rounded consisting mainly new buildings work at 41% (RM0.17 million) for every UTM construction projects and the other variation order values are reference to be compared to the variation order value of buildings work. Below is the document study of the causes of variation order identified within 18 contract document shown in Table 4.1. 1 2 3 4 5 6 7 8 9 10 Causes of Variation Order Client - forced Client - choice Designer Contractor Inadequate consideration of design Defects in documentation Incorrect assessment of brief Defects in design Unnecessary Management Unforeseen Table 4.4: Causes of variation order used in questionnaire The document study findings show that ten (10) causes of variation orders in answering the first objective. Due to the causes, it is further synthesis to ten (10) selected causes of variation orders that are to be used in questionnaire for the verification and validation process to evaluate their degree of important. 4.7 Research Analysis of the Respondent for Questionnaire and Interview Questionnaires were start on to primary respondent (client; Harta Bina UTM) and secondary respondent (consultants and contractors). Personals identified in contract unit, where the construction contract documents were prepared and all of participates in the questionnaire survey meaning 100% feedback obtained from primary respondents. A set questionnaire was sent at random to more than 92 firms and construction organization around Johore and Kuala Lumpur of various sizes. About 21 or 23% (all fully answered) of the questionnaires sent were returned. The analysis was based on the 21 set of answered questionnaires sent were returned. Though the sample size is too small to be considered representative, times constraint left the researcher with no option but to use it. Most of the secondary respondents were quantity surveyors followed by engineers where others are supplementary. The respondents in both categories are well knowledge. The total numbers of all respondents are 24. The respondents are needed to tick at the appropriate rating scale within the specific contributing factors and effects of variation orders. 4.8 Research Findings of the Respondent for Questionnaire Survey and Interview Research findings of the respondents for questionnaire survey will be spilt in two main categories; (1) Respondent Organization, and (2) Respondent Profession. 1. By Organization Client 13% Organization Frequency Percentage Consultant Contractor 15 6 62 25 Client 3 13 24 100 Contractor 25% Figure 4.5: Respondent organization for questionnaire survey Consultant 62% The representatives distribution of the respondents by organization are quite realistic showing the largest amount are the consultant 62%, followed by contractor 25% and the client 13%. The consultant of a standard building construction project would be architect, the engineer and the quantity surveyor. By that the allotment of the respondents by organization is assume to be delegate and applicable for the analysis. 2. By Profession Profession Project Manager Engineer Quantity Surveyor Project Manager 8% Frequency Percentage 2 6 8 25 16 67 24 100 Engineer 25% Quantity Surveyor 67% Figure 4.6: Respondent profession for questionnaire survey Changeable profession represent by the questionnaire survey where the uppermost were quantity surveyor 67% the large numbers were inevitable because the profession who produce the contract document were the quantity surveyor. The quantity surveyors were the most requires and accessible profession as they obviously realize the questionnaire survey and talented to answer without much enquiry to the researcher. The following largest respondents by profession were the engineer, 25%, because of their understandable perceptive of variation order comparatively to quantity surveyor. Their lack of understanding to the content of the construction contract document obstructs their willingness to contribute in the questionnaire survey. 4.16 Research Analysis of Contribution Factors of Variation Orders for Questionnaire Survey and Interview To identify contributing factors of variation orders in contract documents where research procedure was done during the document study process discovered ten (10) factors to be used in the questionnaire as explain before and shown in Table 4.4. 4.17 Research Findings of Contribution Factors of Variation Orders for Questionnaire Survey and Interview The amendment to the design brief will frequently result in a change to the work, and many practitioners believe this latter point is why a variation clause exists. The table and figure below summarize answers to the question: What is the most significant reason for a variation clause? Percentage Contractual safeguard to contractors Client changing mind – choice Client changing mind - forced Defects in design Inadequate consideration – competence Designer’s choice Design team’s inability to define problem Design team’s inability to decide solution Unforeseen event Constraint of pre contract time 4 21 8 8 17 13 4 8 4 13 100 Table 4.5: Reasons for providing a variation clause in a building contract Reasons for providing a variation clause Constraint of pre contract time 13% Contractual safeguard to contractors 4% Client changing mind – choice 21% Unforeseen event 4% Design team’s inability to decide solution 8% Design team’s inability to define problem 4% Client changing mind forced 8% Designer’s choice 13% Defects in design 8% Inadequate consideration – competence 17% Figure 4.7: Reasons for providing a variation clause in a building contract Interestingly, the reasons given do not seem to stand up in practice and Table 4.6 indicates the actual reasons why variations were occurring on a range of projects which used contract based upon complete design. Contribution Factors Document Review Frequency Percentage Yes No Total Questionnaire Frequency Percentage Client - forced 7 11 18 6 1 4 Client - choice 16 2 18 13 2 8 Designer 17 1 18 14 5 21 Contractor 10 8 18 8 1 4 Inadequate consideration of design 18 0 18 15 6 25 17 1 18 14 4 17 6 12 18 5 1 4 Defects in design 16 2 18 13 2 8 Unnecessary 6 12 18 5 1 4 Unforeseen 8 10 18 7 1 4 123 57 100 24 100 Defects in documentation Incorrect assessment of brief Table 4.6: Contributing factors of variation orders The table above shows that the highest score for contribution factors of variation order either by document review or questionnaire is in adequate consideration of design, closely followed by designer, and then followed by defects in documentation. Both these tables and figure show that while the design team believes the client predominantly creates variations, the facts suggest otherwise. The design team must therefore examine their activities critically and ensure that they do not mislead or misinform the client in an attempt to cover their own inadequacies, indirectly created by the client. The client may give insufficient pre-contract time for complete design and in these circumstances the designer should either inform the client that complete design is not practicable or, alternatively, suggest commencement of the project with an incomplete design solution and using the appropriate contractual arrangement. Response by (percentage) Reason Quantity Surveyors Others All Delay caused by design team 19 12.5 17 Variation order 25 37.5 29 Nomination; subcontractor/supplier 6 0 4 Errors in documentation 0 12.5 4 Unforeseen events 25 25 25 Commercial/tendering process 19 12.5 17 Other 6 0 4 100 100 100 Table 4.7: Reasons for claims by contractors Commercial / tendering process 17% Unforeseen events 25% Errors in documentation 4% Other Nomination 4% 4% Figure 4.8: Reasons for claims by contractors Delay caused by design team 17% Variation 29% Response by (percentage) Reason Quantity Surveyors Others 31.25 25 29 Claim 12.5 25 17 Delay 18.75 25 21 12.5 12.5 12 18.75 12.5 17 6.25 0 4 100 100 100 Variation Nomination Personalitites Other Other 4% All Variation 29% Personalitites 17% Nomination 12% Delay 21% Claim 17% Figure 4.9: Greatest problem in contract management Max Abrahamson states in his book Engineering Law that most of the employment given to the legal profession by engineering work is to do with disputes about variations. Presumably this is an opinion gained from personal experience but there is some indirect support for the view in Table 4.7, Figure 4.8 and 4.9. Table 4.7 and Figure 4.8 give the responses from a cross-section of the industry and clients, with the responses from quantity surveyor and others given as separate groupings. This table shows that variations are clearly thought to be a major cause of claims by contractors. The table also shows the actual reasons given and that the respondents distinguished between variations, errors in documentation and unforeseen events. Taking the usual definition incorporated in the various standard forms of contract, however, the majority of the responses appearing in the table as errors in documentation and many of the items appearing as unforeseen events would in fact be considered as variations. If one takes these into consideration, it is evident that the other causes of claim are relatively small in number. It is therefore not surprising that Figure 4.9 shows the greatest problem in contract management to be variations. If the majority of claims by contractors and the greatest problem in contract management are both caused by variations, then either variations must be reduced or eliminated, or a better legal and practical framework must be created so that they can be dealt with more effectively and presumably, equitably. 4.18 Research Analysis of Effects of Variation Orders for Questionnaire Survey and Interview To identify effects of variation orders in contract documents where research procedure was done during the document study process discovered sixteen (16) effects to be used in the questionnaire as shown in table below. No. 1 2 3 4 5 6 7 8 9 10 11 12 13 14 15 16 Effects description Progress is affected but without any delay Increase in project cost. Hiring new professionals Increase in overhead expenses Delay in payment. Quality degradation. Productivity degradation Procurement delay. Rework and demolition. Logistics delays. Damage to firm's reputation Poor safety conditions. Poor professional relations Additional payments for contractor. Disputes among professionals. Completion schedule delay. Table 4.8: Effects of variation orders 4.19 Research Findings of Effects of Variation Orders for Questionnaire Survey and Interview The table below shows the findings of effects of variation orders accordingly to their degree of important. Frequency Analysis (FA) 1 2 3 4 5 Total Least Low Medium High Extreme FA effect effect Effect Effect effect delay 10 6 6 1 1 24 0.408333 Increase in project cost. 0 0 0 4 20 24 0.966667 Hiring new professionals 5 2 9 8 0 24 0.566667 Increase in overhead expenses 3 3 7 6 5 24 0.658333 Delay in payment. 0 0 0 11 13 24 0.908333 Quality degradation. 10 7 4 1 2 24 0.416667 Productivity degradation 5 10 9 0 0 24 0.433333 Procurement delay. 0 0 3 12 9 24 0.850000 Rework and demolition. 0 5 0 14 5 24 0.758333 Logistics delays. 0 0 5 12 7 24 0.816667 Damage to firm's reputation 4 3 5 7 5 24 0.650000 Poor safety conditions. 11 8 4 0 1 24 0.366667 Poor professional relations 0 0 23 1 0 24 0.608333 Additional payments for contractor. 1 1 1 20 1 24 0.758333 Disputes among professionals. 3 1 3 17 0 24 0.683333 Completion schedule delay. 0 5 3 4 12 24 0.791667 Effects description RI Progress is affected but without any Table 4.9: Effects of variation orders 0.7917 Completion schedule delay. 0.6833 Disputes among professionals. 0.7583 Additional payments for contractor. 0.6083 Poor professional relations Effect description Poor safety conditions. 0.3667 0.65 Damage to firm's reputation Logistics delays. 0.8167 0.7583 Rework and demolition. 0.85 Procurement delay. 0.4333 Productivity degradation 0.4167 Quality degradation. 0.9083 Delay in payment. 0.6583 Increase in overhead expenses Hiring new professionals 0.5667 0.9667 Increase in project cost. Progress is affected but without any delay 0.4083 0 0.2 0.4 0.6 0.8 1 Relative Index (RI) Figure 4.10: Effects of variation orders Referring to bar chart Figure 4.10 the highest degree of important rated is increase in project cost (RI=0.9667), closely followed by delay in payment (RI=0.9083). The 3rd ranked by procurement delay with RI: 0.8500. Effect Description Scoring Increase in project cost 0.9667 1st rank Delay in payment 0.9083 2nd rank Procurement delay 0.8500 3rd rank Logistics delay 0.8167 4th rank Completion schedule delay 0.7917 5th rank Table 4.10: Best five (5) overall score in effects of variation orders 1.2 Table above shows the top five (5) score in determining the most frequently occurred of effects of variation orders; those are; 1st rank; Increase in project cost is the most common effect of variations, during the construction phase. Any major additions or alterations in the design may eventually increase the project cost. In every construction project, a contingency sum is usually allocated to cater for possible variations in the project, while keeping the overall project cost intact. According to the survey findings, the most frequent effect of variation orders was the increase in project cost. It was not unexpected for the project cost to increase due to frequent variations in the project. This was because the variation orders may affect the project's total direct and indirect costs. Therefore, any major addition or alteration in the design may eventually increase the project cost. In every construction project, a contingency sum is usually allocated to cater for possible variations in the project, while keeping the overall project cost intact. However, frequent major variations may lead to cost overrun in the contingency sum. 2nd rank; Delay in payment occasionally may cause severe problems that end up in delays in payment to the subcontractors; this is because main contractors may not be able to pay the subcontractors unless they get paid by the owner first. 3rd rank; Procurement delays can be frequent due to variations that require new materials and specialized equipment. Procurement delays were common effects of variations related to new resources for construction projects. 4th rank; Logistics delays were significant effects of variations in construction projects. Logistics delays were experienced in construction projects where variations in the construction phase required new materials, tools and equipments. 5th rank; Completion schedule delay is a frequent result of variations in construction projects. The magnitude of the schedule being delayed due to variations was reported by many construction industry practitioners. The fifth most frequent effect of variation orders was the completion schedule delay. Major variations may affect the project adversely, leading to delays in the project completion. Furthermore, frequent minor variations can also affect the project adversely depending on the timing of the occurrence of the variations. This is because the impact of a variation in design during the construction phase can be more severe than in the design phase. 4.20 Research Analysis of Proposed Strategies to Minimize the Adverse Effects of Variation Orders for Questionnaire Survey and Interview The respondents are required to fill in a blank of an open question with appropriate answer and suitable opinion of strategy in order to decrease the adverse effects of variation orders based on their experiences and awareness. In face-to-face interviews the respondents has been asked about their views with regard to their expectation for the understanding of contract documents and the main point are the strategies to reduce the adverse effect of variation orders. When the interviews are to sit down and talk with someone about their knowledge and expert opinion, it is highly favourable because the modification of questions to the answer of the person being interview with reference to their understanding of the subject matter. Due to the private and confidential nature of the interview, recording equipment is not used but all obligatory notes were taken on a prepared structured interview form. 4.21 Research Findings of Proposed Strategies to Minimize the Adverse Effects of Variation Orders for Questionnaire Survey and Interview Proposed strategies are suggested based on the findings of the research; · The involvement of the professionals in the design phase would assist in clarifying the project objectives and in identifying the noncompliance with their requirements at the early stage. Eventually, this may help in eliminating the occurrence of variations, arising from errors and design discrepancies, during the construction stage where the impact of the variations can be severe. · Continuous coordination and direct communication will not only eliminate design discrepancies and errors as well as omissions in design but also provide an opportunity for professionals to review the contract documents thoroughly that would help in eliminating the variations arising because of conflicts in contract documents. · The controls for the frequent change in design by consultant, and inadequate working drawing details would be through systematic detailing of design. This will provide an opportunity for the consultant to review and finalize the design during the design phase. This would assist in reducing the variation occurrences during the construction phase where the impact of variations can be severe. · Clear and thorough project brief would assist in eliminating variations arising because of the unclear scope of work for the contractor. This was because a clear and thorough project brief can eliminate variations that may arise due to unclear project objectives. Eventually, this may assist in developing a clear scope of work for the professionals. · Fair allocation of risks can help in resolving disputes through negotiation rather than litigation since construction changes were a major source of construction dispute. In summary, these five most popular suggested strategies by both categories of respondents (primary respondents and secondary respondents) in order to decrease the adverse effects of variation order are shown in figure below. Fair allocation of risks Clear and thorough project brief Systematic detailing of design Continuous coordination and direct communication Involvement of the professionals in the design phase Figure 4.11: Strategies to minimize adverse impacts of variation order 4.22 Summary Research analysis and findings are established with source of data and respondent to create the limitation of study. The general method of the analysis of data such as frequency analysis, relative index analysis, and the usage of Microsoft Excel were described. Document study procedures are explained, continuing with structured interview including the last of research analysis and findings are the proposed strategies of reducing adverse effects of variation orders. Sequences of explanation are exclusively described within each research analysis and research findings sections. The clarity of elaboration is further enhanced by the diagrammatic illustration of bar chart, pie chart and tables. The findings data in this chapter are then brought forward to the next chapter of discussion and conclusion. CHAPTER V CONCLUSION 5.1 Introduction The discussion and conclusion will merge and summarize all central part subjects in various segments of this master project write up, where the ideas initially generate in the background problems that induce the conjectural structure formation which in turn generate the hypothesis and research question. Research methodology was successively arranged in three (3) stages to counter the objective presented in the research analysis and findings. Discussion and conclusion are to recapitulate all the above topics earlier discussed. 5.5 1st Objective; To identify contribution factors of variation orders The first phase of research methodology is as shown in Chapter III; Figure 3.3, applied to achieve the 1st objective is document study where the findings shows that 18 contract document studied has identified ten (10) factors that contribute to variation orders as shown in table below. These all factors are then used in the questionnaire survey. The surveys verify all the selected factors when the respondents evaluate their degree of important and the findings show that all the factors were considered to be important by the respondents, revealed as summary of contribution factors of variation orders where the highest score is inadequate consideration of design. Contribution Factors of Variation Order 1 Client - forced 2 Client - choice 3 Designer 4 Contractor 5 Inadequate consideration of design 6 Defects in documentation 7 Incorrect assessment of brief 8 Defects in design 9 Unnecessary 10 Unforeseen Management Table 5.1: Contribution factors of variation order The factors determined are also supported by the document study and the interviews with experienced personnel from the client, consultant and contractor. Their views have supported the responses that inadequate consideration of design is a significant factor. The design team believes the client predominantly creates variations, the facts suggest otherwise as proved in chapter IV. The design team must therefore examine their activities in detail and ensure that they do not mislead or misinform the client in an attempt to cover their own inadequacies, indirectly created by the client. The client may give insufficient pre-contract time to complete design and in these circumstances the designer should either inform the client that complete design is not practicable or, alternatively, suggest commencement of the project with an incomplete design solution and using the appropriate contractual arrangement. Chapter IV (Table 4.7 and Figure 4.8) gives the responses from a cross-section of the industry and clients, with the responses from quantity surveyor and others given as separate groupings. This table shows that variations are clearly thought to be a major cause of claims by contractors. The table also shows the actual reasons given and that the respondents distinguished between variations, errors in documentation and unforeseen events. Taking the usual definition incorporated in the various standard forms of contract, however, the majority of the responses appearing in the table as errors in documentation and many of the items appearing as unforeseen events would in fact be considered as variations. If one takes these into consideration, it is evident that the other causes of claim are relatively small in number. It is therefore not surprising that those findings in preceding chapter show the greatest problem in contract management to be variation orders. If the majority of claims by contractors and the greatest problem in contract management are both caused by variations, then either variations must be reduced or eliminated, or a better legal and practical framework must be created so that they can be dealt with more effectively and presumably, equitably. 5.6 2nd Objective; To study the effects of variation orders in construction projects With reference to the second phase of the research methodology (Chapter III; Figure 3.4) to accomplish the above objective, the following discussion and conclusion were mainly based on questionnaire survey and secondly on structured interviews continuing the essential facts found in the Document Study process. To identify the effects of variation orders in construction projects where research procedure was done during the document study process, discovered sixteen (16) effects to be used in the questionnaire as shown in table below. Effects description 1 Progress is affected but without any delay 2 Increase in project cost. 3 Hiring new professionals 4 Increase in overhead expenses 5 Delay in payment. 6 Quality degradation. 7 Productivity degradation 8 Procurement delay. 9 Rework and demolition. 10 Logistics delays. 11 Damage to firm's reputation 12 Poor safety conditions. 13 Poor professional relations 14 Additional payments for contractor. 15 Disputes among professionals. 16 Completion schedule delay. Table 5.2: Effects of variation orders Referring to bar chart in Chapter IV; Figure 4.10 the highest degree of important rated is increase in project cost with Relative Index (RI) 0.9667, closely followed by delay in payment (RI=0.9083). Table below shows the top five (5) overall score in effects of variation orders voted by respondents. Effect Description Scoring Increase in project cost 0.9667 1st rank Delay in payment 0.9083 2nd rank Procurement delay 0.8500 3rd rank Logistics delay 0.8167 4th rank Completion schedule delay 0.7917 5th rank Table 5.3: Best five (5) overall score in effects of variation orders Increase in project cost is the most frequent effect of variations, during the construction phase. Any major additions or alterations in the design may eventually increase the project cost. In every construction project, a contingency sum is usually allocated to cater for possible variations in the project, while keeping the overall project cost integral. According to the survey findings, the most recurrent effect of variation orders was the increase in project cost. It was not surprising for the project cost to increase due to numerous variations in the project. This was because the variation orders may affect the project's total direct and indirect costs. For that reason, any major addition or alteration in the design may ultimately increase the project cost. In every construction project, a contingency sum is usually allocated to accommodate for possible variations in the project, while keeping the overall project cost intact. On the other hand, frequent major variations may lead to cost overrun in the contingency sum. 5.7 3rd Objective; To propose strategies to minimize the adverse effects of variation orders Finally, the third phase of research methodology is the ultimate strategy (Chapter III; Figure 3.5) to cater the stated objective, the strategy is the combination of all method demonstrated. The research analysis process done has make known ten (10) contribution factors of variation orders and sixteen (16) effects of variation orders in construction projects. However, the discussion and conclusion were profoundly based on the questionnaire survey and structured interview, supported by document study to be able to propose strategy to reduce adverse effects of variation orders. Variation orders can be minimize if all the parties involve in the projects are aware that preliminary work before tendering is carried out, for example detailed site and soil investigations. It cannot be more stressing that more time is needed to carry out detailed project scooping and a longer lead time is required. As a final point, the findings of the research proposed five (5) approaches to deduce the undesirable effects of variation orders in construction projects are publicized as below; (1) The participation of the professionals in the design phase would assist in clarifying the project objectives and in identifying the noncompliance with their requirements at the early stage. Eventually, this may aid in eliminating the occurrence of variations, arising from errors and design discrepancies, during the construction stage where the impact of the variations can be severe. (2) Constant coordination and direct communication will not only abolish design discrepancies and errors as well as omissions in design but also provide an opportunity for professionals to review the contract documents thoroughly that would help in eliminating the variations arising because of conflicts in contract documents. (3) The controls for the recurrent change in design by consultant, and inadequate working drawing details would be through systematic detailing of design. This will provide an opportunity for the consultant to review and finalize the design during the design phase. This would assist in reducing the variation occurrences during the construction phase where the impact of variations can be severe. (4) Clear and thorough project brief would assist in eliminating variations arising because of unclear scope of work for the contractor. This was because a clear and thorough project brief can eliminate variations that may arise due to unclear project brief. Eventually, this may assist in developing a clear scope of work for the consultants. (5) Fair allocation of risks can help in resolving disputes through negotiation rather than litigation since construction changes were a major source of construction dispute. All these described points simplify view in figure below. On the whole, this study has achieved all its objectives. Fair allocation of risks Clear and thorough project brief Systematic detailing of design Continuous coordination and direct communication Involvement of the professionals in the design phase Figure 5.1: Strategies to minimize adverse impacts of variation order 6.0 REFERENCES / BIBLIOGRAPHY Abd. Majid M.Z. and McCaffer R. (1998). Factors of Non-excusable Delays That Influence Contractors’ Performance: Journal of Management In Engineering. Vol. 14, issue 3: page 42-49. Adhikari. D.K. and Manavazhi M.R. (2001). Material and Equipment Procurement Delays in Highway Projects in Nepal: International Journal of Project Management. Vol. 20: page 627-632. Aibinu A.A. and Jagboro G.O. (2002). The Effects of Construction Delays on Project delivery in Nigerian Construction Industry: International Journal of Project Management. Vol. 20: page 593-599. Akintola A.(1994) “Design and Build: A Survey of Construction Contractors’ Views” J. Const. Mgmt and Eco. Volume 12, 155-165 Al-Khalil M.I. and Al-Ghafly M.A (1999). Delay in Public Utility Projects in Saudi Arabia: International Journal of Project Management. Vol. 17, No. 2: page 101-106. Al-Momani,A., (2000), “ Construction Delay: a quantitative analysis”, International Journal of Project Management, 2000, 18:51-59. Aminuddin Ali. (2006). Exploitation of Contract Document for Construction Project Planning and Controlling. FKA. UTM Skudai. Ashley D. B., Laurie C. S. dan Jaselskis E. J. (1987) “Determinants of Construction Project Success” ASCE, J. of Mgmt in Engrg. Vol. 15 No. 2, 69-79 Assaf S.A, Bubshait A.A., Atiyah S., and Al-Shahri M. (2001). The management of construction company overhead costs: International Journal of Project Managemnet. Vol. 19, page 295-303. Assaf, S.A., Al-Khalil, M., and A-Hazmi, M., (1995), “Causes of delay in large building construction projects”, Journal of Management in Engineering, ASCE, March/April, 1995, pp 45-50. Azhan Seth. (2004). The Effects of Delays in Construction Industry. FKA. UTM Skudai. Baden Hellard R (1995) “Project Partnering: Principle and Practice” Thomas Telford Publication, London Baden-Hellard R (1988) “Managing Construction Conflict” Longman Group UK Ltd UK Bambang Trigunarsyah (2004). Constructability Practices among Construction Contractors in Indonesia: Journal of Construction Engineering; September/October 2004, page 657-669 Bennett J dan Grice T (1992) “Procurement System for Building” in Brandon, PS (ED). “Quantity Surveying Technique New Directions”. Blackwell Science Ltd, London Chan A. P. C., Chan. D. W. M., Chiang Y. H., Tang B. S., Chan E. H. W., dan Ho K. S. K (2004) “Exploring Critical Success Factors for Partnering in Construction Projects” ASCE, J. of Constr. Engrg. and Mgmt., Vol. 130 No. 1, 188-198 Chan A.P.C, Scott D., dan Chan A.P.L (2004) “Factors Affecting the Success of A Construction Project” ASCE, J. of Const. Engrg. and Mgmt., Vol. 130 No. 1, 153-155 Chan A.P.C, Scott D., dan Lam E.W.M (2002) “Framework of Success Criteria for Design/Build Projects” ASCE, J. of Mgmt in Engrg. Vol. 18 No 3., 120-128 Chan A.P.C., Ho D.C.H dan Tam C.M (2001) “ Design and Build Project Success Factors: Multivariate Analysis” J. Constr. Engrg. and Mgmt., ASCE, Vol. 127 No. 2, 93-100 Chan A.P.C., Ho D.C.K. dan Tam C. M. (2001) “Effects of Interorganizational Teamwork on Project Outcome” ASCE, J. of Mgmt in Engrg, Vol 17 No. 1, 34-40 Charted institute of building (CIOB). 1987. Managing construction worldwide; productivity and human factors in construction. International council for building research studies and documentation. London. Cheng E. W. L., Li H. dan Love P. E. D (2000) “Establishment of Critical Success Factors for Construction Partnering” ASCE, J. of Mgmt in Engrg, Vol 16 No.2, 84-92 CIDB Construction Industry Review 2001/2002 CII (1986), Impact of Various Construction Contract Types and Clauses on Project Performance, Construction Industry Institute, University of Texas at Austin, Austin, TX, . CII (1990), The Impact of Changes on Construction Cost and Schedule, Construction Industry Institute, University of Texas at Austin, Austin, TX, . CII (1990), The Impact of Changes on Construction Cost and Schedule, Construction Industry Institute, University of Texas at Austin, Austin, TX, . CII (1994), Project Change Management, Construction Industry Institute, University of Texas at Austin, Austin, TX, . CII (1995), Qualitative Effects of Project Changes, Construction Industry Institute, University of Texas at Austin, Austin, TX, . CIRIA (1983) “A Client’s Guide to Traditional Contract of Building”CIRIA, Special Pub 29 London Clamp H dan Cox S (1989) “Which Contract: Choosing Appropriate building Constract” RIBA Pub. London Clough, R.H., Sears, G.A. (1994), Construction Contracting, 6th ed., John Wiley & Sons Inc., New York, NY, . Cook E. L dan Hancher D. E (1989) “Partnering: Contracting for the Future” ASCE, J. of Mgmt in Engrg, Vol 6 No. 4, 431-445 Cooke, B. (1979). Cost and financial control for construction firms. The Macmillan press ltd. London Dallaire, D. (1974). Thermal Power Plants: Key Problems, Trends. Civil Engineering. ASCE. Pp 35- 39. Dennis F Turner. (1984). standard contracts for building. Longman Inc. New York Dennis L. Mulvey (1998). Project Delivery Trends: A Contractors Assessment: Journal of Management In Engineering. page 51-53. Eldin N. N.(1988) “Constructibility Improvement of Projects Design” ASCE, J. of Const. Engrg. and Mgmt., Vol. 114 No. 4 Fergusen N. S., Langford D. A. dan Chan W.M (1995) “Emperical Study of Tendering Practice of Dutch Municipailties for the Procurement of Civil- Engineering Contracts” Elsevier Science Ltd., Int. J. of Project Mgmt., Vol. 13 No. 3, 157-161 Flora G., Ernzen J.J., dan Schexnayder C. (1998) “ Field-Level Management’s Perspective of Design/Build” ASCE, J. of Prac. Perd. On Struc. Design and Const., Vol 3 No. 4, 180-185 Forster, G. 1986. Building organization and procedures. Longman Inc. New York Frank J (1992) “Building Procurement Systems”. 2nd edition Ascot Chatered Ins. Of Building (CIOB) Frederick E. G dan nancy E. J (2000) ‘”Construction Project Management”. New Jersey. Prentice Hall,Inc Frimpong, Y., Oluwoye, J., and Crawford, L., (2003), “Causes of delay and cost overruns in construction of groundwater projects in a developing countries; Ghana as a case study”, International Journal of Project Management, 2003, 21:321-326. Hester, W., Kuprenas, J.A., Chang, T.C. (1991), Construction Changes and Change Orders: Their Magnitude and Impact, University of California, Berkeley, CA, . Hibberd, Peter R. (1986). Variations in construction contracts. William Collins sons & co ltd. London. Ibbs, C.W. (1997a), "Change's impact on construction productivity", Journal of Construction Engineering and Management, Vol. 123 No.1, pp.89-97. Ibbs, C.W. (1997b), "Quantitative impacts of project change: size issues", Journal of Construction Engineering and Management, Vol. 123 No.3, pp.308-11. Ibbs, C.W., Lee, S.A., Li, M.I. (1998), "Fast tracking's impact on project change", Project Management Journal, Vol. 29 No.4, pp.35-41. Ibbs, C.W., Wong, C.K., Kwak, Y.H. (2001), "Project change management system", Journal of Management in Engineering, Vol. 17 No.3, pp.159-65. Ivor H. Seeley. 1993. civil engineering contract administration and control. The Macmillan press ltd. London Jack Rizzo (1998). Design and build alternative: A contracting method: Journal of Management In Engineering. page 44-47. Johns G. T. (1994) “Managing the Behaviour of People Working in Teams” Elsevier Science Ltd., Int. J. of Project Mgmt., Vol. 13 No. 1, 33-38 Jung Y. and Woo S (2004). Flexible Work Breakdown Structure for Integrated Cost and Schedule Control: Journal of Construction Engineering; September/October, page 616-625 Kamaruddin md. Ali, (1993). tender dan kontrak pembinaan; penyediaan dan pengendalian. Dewan bahasa pustaka, kuala Lumpur. Kaming, P.F., Olomolaiye, P.O., Holt, G.D., Harris, F.C. (1997), "Factors influencing construction time and cost overruns on high rise projects in Indonesia", Construction Management and Economics, Vol. 15 No.1, pp.83-94. Khang D.B., and Myint Y.M (1999). Time, cost and quality trade off in project management: a case study: International Journal of Project Management. Vol. 17, page 249-256. Koushki, P.A., Al- Rashid, K., and Kartam, N., (2005), “ Delays and cost increase in the construction of private residential projects in Kuwait”, Construction Management and Economics, March 2005, 23-285-294. Koushki, P.A., and Kartam, N., (2004), “Impact of construction materials on project time and cost in Kuwait”, Engineering, Construction and Management, 2004, 11 (2): pp126-132. Kraiem, Z.M. (1987). Concurrent Delays in Construction Projects. Journal of Construction Engineering and Managemnet. ASCE, Vol.113, No. 4, page 591-601 Kumaraswamy M.M and Chan D.W.M (1998). An Evaluation of Construction Time Performance in the Building Industry: Building and Environment. Vol. 31, No. 6: page 569-578. Kumaraswamy M.M and Chan D.W.M (2002). Compressing construction durations: lessons learned from Hong Kong building projects; International Journal of Project Managemnet. Vol. 20, page 23-35. Kumaraswamy M.M and Yogeswaran K. (2003). Substantiation and assessment of claims for extension of time.; International Journal of Project Managemnet. Vol. 21, page 27-38. Kumaraswamy, M.M, and Chan, D.W.M., (1998), “Contributors to construction delays”, Construction Management and Economics, 1998, 16:17-29. Kumaraswamy, M.M., Miller, D.R.A., Yogeswaran, K. (1998), "Claims for extensions of time in civil engineering projects", Construction Management and Economics, Vol. 16 No.3, pp.283-94. Laufer A. dan Cohenca D. (1990) “ Factors Affecting Construction-Planning Outcomes” ASCE, J. of Constr. Engrg. and Mgmt., Vol. 116 No. 1, 135-155 Lim E. C. dan Alum J (1995) “ Construction Productivity: Issues Encountered by Contractors in Singapore” Elsevier Science Ltd., Int. J. of Project Mgmt., Vol. 13 No. 1, 51-57 Ling F. Y. Y., Chan S. L. Chong. E dan Ee L. P. (2004) “Predicting Performance of Design-Build and Design- Bid-Build Projects” ASCE, J. of Constr. Engrg. and Mgmt., Vol. 130 No. 1, 75-83 Long N.D., Ogunlana S.,Quang T. and Lam K.C. (2004). Large construction projects in developing countries: a case study from Vietnam: International Journal of Project Managemnet. Vol. 22, page 553-561. Loosemore M (1998) “The Three Ironies of Crisis Management in Construction Projects” Elsevier Science Ltd., Int. J. of Project Mgmt., Vol. 16 No. 3, 139-144 Mahmoud-Jouini S.B., Midler C., and Garel G (2004): Time-to- market vs. time-todelivery Managing speed in Engineering, Procurement and Construction projects.: International Journal of Project Management. Vol. 22, page 359-367. Manavazhi M.R. and Adhikari D.K. (2002). Material and equipment procurement delays in highways projects in Nepal: International Journal of Project Managemnet. Vol. 20, page 627-632. Mastermann J W E (1992) “ An Introduction to Building Procurement Systems” E & FN Spin, London Mezher T.M., and Tawil W., (1998); “Causes of delays in the construction industry in Libanon”, Engineering Construction and Architectural Management Journal, 1998, 5 (3): 251-60. Mohsini R A dan Davidson C H (1999) “ Building Procurement: Key to Improved Performance.” Building Research and Info 29/3 106-113 Molenaar K. R., Songer A. D., dan Barash M. (1999) “Public Sector Design/Build Evolution and Performance” ASCE, J. of Mgmt in Engrg. Vol. 15 No. 2, 54-62 Moore R F C (1984) “Response to Change: The Development of Non Traditional Forms of Contract” Ascot Chatered Ins. Of Building (CIOB) Munns A. K. (1995) “Potential Influence of Trust on the Successful Completion of a Project” Elsevier Science Ltd., Int. J. of Project Mgmt., Vol. 13 No. 1, 19-23 Napthine R. dan Smart R (1995) “Design and Build-Lessons from the UK Channel Tunnel Terminal” Proc. Instn. Civ Engnrs., Sept, 123-130 Ndekugri I. dan Turner A. (1994) “ Building Procurement by Design and Build Approach” ASCE, J. of Const. Engrg. and Mgmt., Vol. 120 No. 2, 243-255 NEDO (1991) “ Partnering : Contract Without Conflict”. National Economical Development Office (NEDO), London Nigel M.R., Anthony P.L., George Tan K.H., Chan R. (1996). Construction Law in Singapore and Malaysia. 2nd ed. Butterworths Tolley. O'Brien, J.J. (1998), Construction Change Orders, McGraw Hill, New York. Odeh, A. M., and Bataineh, H. T., (2002), “Causes of construction delay: traditional contracts”, International Journal of Project Management, 2002, 20: 67-73. Ogunlana, S.O., Promkuntong, K., and Jearkjirm, V., (1996); “ Construction delays in a fast- growing economy: comparing Thailand with other economies”, International Journal of Project Management, 1996, 14(1): 37-45. Okpala, D.C., and Aniekwu, A.N.(1998). Causes ogf High Cost of Construction in Nigeria. Journal of Construction Engineering; ASCE, Vol 114, No. 2, page 223-244 Palaneeswaran E. dan Kumaraswamy M. M (2000)“ Contractor Selection for Design/Build Projects” ASCE, J. of Constr. Engrg. and Mgmt., Vol. 126 No. 5, 331339 Parfitt M.K. dan Sanvindo V.E (1993) “Checklist of Critical Success Factors for Building Projects”. ASCE, J. of Mgmt in Engrg, Vol 9 No. 3, 243-249. Pinto J. K. dan Slevin D. P. (1988) “Critical Success Factors Accross the Project Life Cycle” Proj Mgmt J. Vol. 19 No. 3. 67-75 Pocock J. B., Liu L. Y dan Kim M. K (1997) “Impact of Management Approach on Project Interaction and Performance” ASCE, J. of Const. Engrg. and Mgmt., Vol. 123 No. 4, 411-418 Riaf, N., Arditi, D., and Mohammadi, J. (1991). A Conceptual Model For Claim Management in Construction: An AI Approach. Journal of Computers. RIBA (1980) “RIBA Plan of Work for Design Team Operation” in Powell J (ed) “ Handbook of Architect Practice and Management” RIBA Pub London 347-373 Sanvindo V., Grobler F. Parfitt K., Guvenis M. dan Coyle M (1992)“Critical Success Factors for Construction Projects”. ASCE, J. of Const. Engrg. and Mgmt., Vol. 118 No. 1, 94-111 Sawczuk B (1996) “Risk Avoidance for the Building Team” E & FN Spin, London Songer A.D., dan Molenaar K. R. (1997). “Project Characterictics for Successful Public-Sector Design-Build” J. Constr. Engrg. and Mgmt., ASCE, Vol. 123 No. 1, 3440 Songer A.D., dan Molenaar K. R. (1998). “Model For Public Sector Design-Build Project Selection” ASCE, J. of Constr. Engrg. and Mgmt., Vol. 124 No. 6, 467-479 Stephen O. Ogunlana and Krit Promkuntong (1996). Construction delays in a fast growing economy: comparing Thailand and other economies. International Journal of Project Management. Vol. 14, No.1: page 37-45. Syed M. Ahmed, Salman Azhar, Pragnya Kappagantula, and Dharam Gollapudi (2003). Delays in Construction: A brief study of the Florida Construction Industry: ASC Proceedings of the 39th Annual Conference. April 10-12; page 257-266 The CIDB Directory 2003-3004 (The Nation Builders, Contractotors, Construction Materials,Plant and Equipment)”CIDB Thomas S N, Thanh D L and Swee E C (2003) “ A Case-Based Procurement Advisory System for Construction” Journal of Advance Engineering Software. pg 429-438 Tiong R. L. K. (1996) “CSFs in Competitive Tendering and Negotiation Model for BOT Projects”. ASCE, J. of Constr. Engrg. and Mgmt., Vol. 122 No. 3, 205-211 Tse R.Y.C., and Love P.E.D. (2001). An Economic Analysis Of The Effect Of Delays on Project Costs: Journal of Construction Research. Vol. 4, No. 2, page 155-1 Turner A (1990) “Building Procurement” Mac Millan Edu. Ltd. London Weston D. C. dan Gibson G. E. (1993) “Partnering-Project Performance in U.S. Army Corps of Engineers” ASCE, J. of Mgmt in Engrg, Vol 9 No. 4, 410-425. Wong P (2002) “Malaysian Conctruction Industry-Review and Outlook” Journal of Malaysian Master Builder.3rd Quarter Edition. pg 69-76 Yates J.K. (1995) “Use of Design/Build in E/C Industry” ASCE, J. of Mgmt in Engrg, Vol 11 No. 6, 33-38 Yates, J.K. (1993). Construction Decision Support System for Delay Analysis. Journal of Construction Engineering and Management. ASCE, Vol. 119. No. 2, page 226-243 Zeitoun, A., Oberlender, G. (1993), Early Warning Signs of Project Changes, Oklahoma State University, Stillwater, OK, . No. COMPANY PHONE FAX NO EMAIL STATE 1 YONG DAN MOHAMAD FAIZ SDN BHD 03-22828838 03-22831836 ymfkl@tm.net.my Kuala Lumpur 2 JURUKUR BAHAN BERSATU 03-79812566 03-79818567 jubb@tm.net.my Kuala Lumpur 3 JUB BERSATU SDN BHD 03-79812566 03-79818567 jubb@tm.net.my Kuala Lumpur 4 PCM KOS PERUNDING 03-6329969 03-6369969 pcmkos@yahoo.com Kuala Lumpur 5 PERUNDING AZATECH SDN BHD 03-91713550 03-91713544 azatech@pc.jaring.my Kuala Lumpur 6 FPS KONSULTANT 03-91318787 03-91318759 jubfqs@jubtps.po.my Kuala Lumpur 7 CS PERUNDING JURUKUR BAHAN 03-91316918 03-91306918 cskee@tm.net.my Kuala Lumpur 8 UKUR BAHAN KELANA 03-91715033 03-91715033 ubk34@hotmail.com Kuala Lumpur 9 TZA ASSOCIATEA SDN. BHD. 03-92836253 02-92833255 tza_qs@tm.net.my Kuala Lumpur 10 JUB SEGAR 03-92811210 03-92823207 jubsegar@tm.net.my Kuala Lumpur 11 EFCT KONSULT 03-9811210 03-9823207 - Kuala Lumpur 12 MSA ASSOCIATES 03-42707020 03-42707021 msmn60@hotmail.co, Kuala Lumpur 13 THL CONSULTANTS 03-40238289 03-40211289 th199@tm.net.my Kuala Lumpur 14 RK PARTNERSHIP 03-41433763 03-41494239 rkpartnership@pd.jaring.my Kuala Lumpur 15 RAK ASSOCIATES 03-4142300 03-41421311 rosliak@yahoo.com Kuala Lumpur 16 MM QUANTITY SURVEYORS 03-41438963 03-41088963 - Kuala Lumpur 17 JURUKUR BAHAN PENDITA 03-41438268 03-41438276 JUBPO1@tm.net.my Kuala Lumpur 18 ICS INTEGRATED COST SURVEYORS 03-41427876 03-41487188 - Kuala Lumpur 19 HAH ASSOCIATES 03-41497110 03-41481678 hahqs@tm.net.my Kuala Lumpur 20 ABD RAHIM KADIR & ASSOCIATES 03-41494082 03-41494239 - Kuala Lumpur 21 PERUNDING SHS 012-3762998 03-40124789 pshs@pd.jaring.my Kuala Lumpur 22 ZAIM AZIZ CONSULT 03-61886814 03-61886814 - Kuala Lumpur 23 O & Z ASSOCIATES 03-41052404 03-41071970 onzqs@hotmail.com Kuala Lumpur No. COMPANY PHONE FAX NO EMAIL STATE 24 MN ASSOCIATES 03-41052404 03-40171970 mdrhk@tm.net.my Kuala Lumpur 25 JUB CONTRACT CONSULTANCY S/B 03-41085018 03-41085018 - Kuala Lumpur 26 HMR & ASSOCIATES 03-40229644 03-40229644 hmr8470@pd.jaring.my Kuala Lumpur 27 HALIM ASSOCIATES 03-40229644 03-40244794 abhaabra@tm.net.my Kuala Lumpur 28 EDDIE JASMIN CONSULTING 03-410963267 03-41071524 wej@pd.faring.my Kuala Lumpur 29 ARH JURUKUR BAHAN SDN BHD 03-41068192 03-41068190 arh@tm.net.my Kuala Lumpur 30 AIA ASSOCIATES 03-41077961 03-41078962 - Kuala Lumpur 31 KOS KONSORTIUM SDN BHD 03-4231932 03-4231933 kkqs@tm.net.my Kuala Lumpur 32 JURUKUR BAHAN PROJEK 03-40211775 03-40233453 shchai@pc.jaring.my Kuala Lumpur 33 PERUNDING BE SDN BHD 03-62802450 03-62801450 perundingpe@yahoo.com Kuala Lumpur 34 KUMPULAN SEPAKAT KONSULT 03-62729975 03-63722027 sepakat@maxis.net.my Kuala Lumpur 35 KH ALLIANCE QUANTITY SURVEYORS 019-8187444 03-40228231 - Kuala Lumpur 36 A.M. DEWAN ASSOCIATES 03-78743792 03-78743792 - Kuala Lumpur 37 TS ASSOCIATES 03-90804399 03-9075245 tsimdak@tm.net.my Kuala Lumpur 38 MAA ASSOCIATES 019-6435166 - - Kuala Lumpur 39 A&CO JURU UKUR BAHAN 03-40454070 03-40454060 acqsxxi@hotmail.com Kuala Lumpur 40 AMER & ASSOCIATES 03-20951200 03-20955652 amer-jb@consultant.com Kuala Lumpur 41 C.G. LEE & ASSOCIATES 03-62015816 03-62015816 - Kuala Lumpur 42 VM CONSULTANT 03-21612063 03-21617530 vmcon@tm.net.my Kuala Lumpur 43 PHANG YUEN LOONG & RAKAN 03-27152723 03-27152713 echpmsb@po.jaring.my Kuala Lumpur 44 JUBC SDN BHD 03-27102660 03-27102671 - Kuala Lumpur 45 ASP ASSOCIATES 03-2452033 03-2422716 siewpinghung@hotmail.com Kuala Lumpur 46 JURUKUR BAHAN H&A 03-41433354 03-41435355 hnaqs@pd.jaring.my Kuala Lumpur 47 HASHIM & LIM SDN 03-40428664 03-40428689 - Kuala Lumpur 48 GABUNGAN JURUKUR BAHAN 03-41075970 03-41073044 - Kuala Lumpur No. COMPANY PHONE FAX NO EMAIL STATE 49 JURUKUR BAHAN FPS SDN BHD 03-91318787 03-91318759 jubfps@jubfps.po.my Kuala Lumpur 50 EL PERUNDING JURUKUR BAHAN 03-79820362 03-79820316 - Kuala Lumpur 51 ALPHA-OMEGA MATRIX 03-62759880 03-62721008 - Kuala Lumpur 52 DAINNA BAHARUDDIN CONSULTANCY 03-92214335 03-92230746 dbc_qs@tm.net.my Kuala Lumpur 53 JUB SEKUTU SDN 03-92845533 03-92832201 - Kuala Lumpur 54 JUB PADU SDN BHD 03-21612063 03-21622085 jubsb@tm.net.my Kuala Lumpur 55 C.N.H JURUKUR BAHAN 03-92237412 03-92237415 alchchia@pd.jaring.my Kuala Lumpur 56 IHSAN DCWC SDN BHD 03-42806659 03-42806657 idcwc@po.jaring.my Kuala Lumpur 57 INTRACOST CONSULT 03-7725581 03-77257228 intracost@hotmail.com Kuala Lumpur 58 Y.S CHAN & ASSOCIATES 03-62776133 03-62779133 ysca@fishnet.net.my Kuala Lumpur 59 CPK ASSOCIATES 03-79815864 03-79848081 edicon@pd.jaring.my Kuala Lumpur 60 PERUNDING KOS CSS 03-62769823 03-62733673 pkcss2001@yahoo.com Kuala Lumpur 61 BAHARUDDIN ALI & LOW SDN BHD 03-92853744 03-92855452 balow@balow.po.my Kuala Lumpur 62 AZMAN & TAY ASSOCIATES SDN BHD 03-62010117 - - Kuala Lumpur 63 UKUR BAHAN KONSULT 03-77298100 03-77271636 - Kuala Lumpur 64 JURUKUR BAHAN AAR 03-41088933 03-41083770 qsaar@po.jaring.my Kuala Lumpur 65 ASA-CM JURUKUR BAHAN 03-41085823 03-41085834 - Kuala Lumpur 66 PERUNDING KOS PUTRA 03-41490971 03-41490976 pkputra@tm.net.my Kuala Lumpur 67 DESIGN COST CONSULTANT 03-41079722 03-41079685 - Kuala Lumpur 68 ZAKARIA-LEE & PARTNERS SDN BHD 03-9173471 03-91739199 zaklee@tm.net.my Kuala Lumpur 69 PERUNDING BE 03-62802450 03-62801450 haneeta@tm.net.my Kuala Lumpur 70 MEGA QS 03-77262985 03-77261572 - Kuala Lumpur No. COMPANY PHONE FAX NO EMAIL STATE 71 AT ASSOCIATES 03-40414798 03-40414779 - Kuala Lumpur 72 KPK QUANTITY SURVEYORS SDN BHD 03-21668000 03-21668228 kpk@popl.jaring.my Kuala Lumpur 73 PERUNDING UNIKON 03-40416991 03-40414837 unikon@streamyk.my Kuala Lumpur 74 SAFIAN IBRAHIM BERSEKUTU 03-62776133 03-62779133 - Kuala Lumpur 75 FAR CONSULTANT 03-41057366 03-41071631 farconsultant@hotmail.com Kuala Lumpur 76 RM ASSOCIATES 03-40241906 03-40242963 - Kuala Lumpur 77 JUB PRIMA 03-23002398 03-23009398 kotaprima@maxis.net.my Kuala Lumpur 78 HR ASSOCIATES 03-2219971 03-2220658 - Kuala Lumpur 79 CKP NIZARUDDIN JURUKUR BAHAN 03-41083302 03-41083317 ckpnkk@tm.net.my Kuala Lumpur 80 JURUKUR BAHAN L&T 03-79819648 03-79810856 - Kuala Lumpur 81 PERUNDING C&T MANAGEMENT 03-21635848 03-21641537 hhkwan@pc.jaring.my Kuala Lumpur 82 KCL QS KONSULT 03-62722023 03-62722027 kclqs@tm.net.my Kuala Lumpur 83 PERUNDING KOS T&K SDN. BHD. 03-62035113 03-62035112 pkt@pc.jaring.my Kuala Lumpur 84 JUB CENTRAL SDN. BHD. 03-21635848 03-21641537 pctm@po.jaring.my Kuala Lumpur 85 KRISTAL PADU KONSULT - - konsult@tm.net.my Kuala Lumpur 86 AAH ASSOCIATES 03-61878213 03-61879213 - Kuala Lumpur 87 PHAN KIM SWEE & ASSOCIATES 03-20954284 03-20954284 - Kuala Lumpur 88 KUMPULAN PERUNDING IHSAN 03-41052404 03-41073971 - Kuala Lumpur 89 O & C JURUKUR BAHAN 03-21672588 - - Kuala Lumpur 90 FENDI CONSULT 03-90565866 03-90565766 - Kuala Lumpur 91 QS ASSOCIATES 03-77289955 03-77288779 - Kuala Lumpur 92 PERUNDING NFL SDN. BHD. 03-22833503 03-22826075 pnfl@po.jaring.my Kuala Lumpur 93 JUB WAJA 03-62772977 03-62756355 kcngoo@qsinfo.com.my Kuala Lumpur No. COMPANY PHONE FAX NO EMAIL STATE 94 JURUKUR BAHAN UTAMA 03-4089882 03-4078385 jbukl@pd.jaring.my Kuala Lumpur 95 SUKAT BAHAN M'SIA, SBM HOUSE 03-22744211 03-22744108 sbmsb@po.jaring.my Kuala Lumpur 96 Q-TECH 03-41492255 03-41496108 qtech@tm.net.my Kuala Lumpur 97 PAKATAN INTERNATIONAL 03-42563733 03-42568122 pakatan@tm.net.my Kuala Lumpur 98 YING & MOHD FAIZ SDN. 03-22828838 03-22831863 ymfkl@tm.net.my Kuala Lumpur 99 AMD ASSOCIATES 03-77292582 03-77287159 - Kuala Lumpur 100 MEOR ASSOCIATES 03-42522657 03-42576760 - Kuala Lumpur 101 PERUNDING DMA 03-77263800 03-77267800 - Kuala Lumpur 102 PERUNDING PQS 03-40424132 03-40414299 pqssb@maxis.net.my Kuala Lumpur 103 Q & C JURUKUR PERUNDING 03-92828899 03-92816040 qnc@pd.jaring.my Kuala Lumpur 104 LIM TENG HOOI & CO. 03-42563629 03-42514118 pom@tm.net.my Kuala Lumpur 105 M. H. PERUNDING JURUKUR BAHAN 03-92227861 03-92228786 - Kuala Lumpur 106 JURUKUR BAHAN CONSULT 03-27102660 03-27102671 jubc@po.jaring.my Kuala Lumpur 107 KOS KONSORTIUM 03-40231932 03-40231933 - Kuala Lumpur 108 QS-BINA CONSULTANT 07-2415652 07-2415659 - Johor 109 KHAFFEE PERUNDING 07-2383481 07-2320780 - Johor 110 JY COST PLAN CONSULTANTS 07-5203949 07-5203950 jyjb@tm.net.my Johor 111 KONSULT MQS 07-3518731 07-3518731 - Johor 112 K-QS SERVICES 07-3331411 07-3329368 kqss@pd.jaring.my Johor 113 MY JURU UKUR BAHAN PERUNDING 07-55444550 07-5544550 emwhy2000@hotmail.com Johor 114 JB BERGABUNG 07-3322006 07-3325255 jbb@pd.jaring.mu Johor 115 KUMPULAN QS SERVICES 07-3338793 07-3329368 annkiat@pc.jaring.my Johor 116 MCSK QUANTITY SURVEYORS 07-3512377 - - Johor 117 JURUKUR CEM 07-881789 - - Johor 118 HAIKAL JURUTERA PERUNDING SDN. BHD. 07-5568910 - - Johor 119 LING & WONG PERUNDING SDN. BHD. 07-3887708 07-3887706 - Johor No. COMPANY PHONE FAX NO EMAIL STATE 120 MUHIBBAH ENGINEERING (M) SDN. BHD 07-5073829 07-5073796 - Johor 121 PERUNDING AMIN SDN. BHD. 07-5591524 07-5565899 - Johor 122 PERUNDING MMT 07-5545200 07-5546200 - Johor 123 PERUNDING SEJATI SDN. BHD. 07-3538033 07-3539033 - Johor 124 PERUNDING UEP 07-5572987 07-5572987 - Johor 125 REKANAN JURUTERA PERUNDING 07-3332145 07-3338548 - Johor 126 T.P. TAY JURUTERA PERUNDING 07-4335832 - - Johor 127 ADDING BUILDERS SDN. BHD. Johor 128 AFICO HOLDINGS (M) SDN. BHD. Johor 129 AGAR SINAR SDN. BHD. Johor 130 ALAF JITU SDN. BHD. Johor 131 ANTARA BESTARI CONSTRUCTION SD. BHD. Johor 132 ANTARA KOH (M) SDN. BHD. Johor 133 ANTARA TERBAIK SDN. BHD. Johor VO Sebab VO Tebang pokok sediada di tapak kedudukannya terlalu hampir dengan bangunan, melebarkan jln masuk ke pencawang elektrik kpd 5.50m dan perubahan laluan longkang sediada. a) Tambahan bilik PABX dan setor aras tanah Works to be carried out as per Construction drawing. b) Tambah 3 unit r.c. platform Works to be carried out as per Construction drawing. c) Tambah 8 unit bilik rangkaian komputer, 2 bilik di setiap aras. Works to be carried out as per Construction drawing. b) Ganti semua bingkai kayu yang akan dipasang pada dinding gypsum board kepada bingkai kayu aluminium tidak sesuai digunakan pada dinding gypsum kerana kekuatan bhn gypsum board yg lemah utk digandingkan dgn h.w. frame. Kesan kemasan juga kurang menarik. c) Tukar gypsum board partition di bahagian hadapan 14 unit bilik pensyarah aras tanah kepada dinding bata. sebahagian dinding terdedah kepada cahaya d) Pinda ruang bilik pensyarah dengan keluasan asal 13.081m2 kepada 9 bilik 17.62m2, 9 bilik 21.62m2. a) Tambah 3 point paip bekalan air di makmal sains bangunan, makmal alam sekitar dan makmal senibina lanskap. pertukaran status bilik pensyarah kepada PM dan prof; naik pangkat Works to be carried out as per Construction drawing. b) Tambah 3 point floor trap and plumping pipe di makmal alam sekitar dan makmal senibina lanskap. Works to be carried out as per Construction drawing. a) Ganti gypsum board partition dengan dinding bata di bilik pensyarah c) Batalkan 3 pintu di makmal sains bangunan dan makmal sains alam sekitar, dan 2 pintu di ruang laluan. d) Tambah 8 pintu di makmal sains bangunan, makmal pengangkutan, makmal teknologi maklumat, makmal perbandaran, makmal sains alam sekitar dan makmal senibina lanskap. Works to be carried out as per Construction drawing. e) Tambah dinding bata di makmal teknologi maklumat dan makmal senibina lanskap. Works to be carried out as per Construction drawing. f) Tambah gypsum board partition dan 1200mm high fixed glass window dan aluminium frame double leaf door di makmal sians bangunan, makmal pengangkutan, makmal teknologi maklumat, makmal perbandaran, makmal sains alam sekitar. 4.f Works to be carried out as per Construction drawing. a) Batalkan 1 unit aluminium frame sliding window di makmal sains bangunan. pasang aircond b) Batalkan 2 unit aluminium frame sliding window di makmal pengangkutan. pasang aircond c) Batalkan 2 unit aluminium frame sliding window di makmal perbandaran. pasang aircond d) Batalkan 1 unit aluminium frame sliding window di makmal sains alam sekitar. pasang aircond e) Tambah 2 unit aluminium frame sliding window di makmal teknologi maklumat. Works to be carried out as per Construction drawing. f) Tambah 2 unit aluminium frame sliding window di makmal tsenibina lanskap. Works to be carried out as per Construction drawing. a) Pasang waterproofing greenseal B-2 di lantai simen tandas bagi menggantikan dampproof. ganti damproof dgn waterproofing b) Tambah r.c. gutterdi atas riser. Works to be carried out as per Construction drawing. Batalkan 4 unit urinal di tandas lelaki dan menganjakkan concrete bench ke tepi dinding. Tambah bil. bilik air a) Tambahan kerja bagi rasuk, tiang dan papak di aras berikut; ground beam, 1st floor beam, 2nd floor beam, 3rd floor beam dan lower roof beam. Works to be carried out as per Construction drawing. b) Perubahan rasuk pada ground beam 8.b Ubah rasuk a) Perubahan terhadap piawaian struktur bagi keperluan laluan air conditioning di aras 1 floor beam dan 2nd floor beam. Ubah piawaian bg keperluan laluan air conditioning a) Pertambahan perincian lintol 9.6m. b) Perubahan dan pertambahan rasuk serta papak di aras 2nd floor beam. a) Pembatalan rasuk. b) Perubahan bagi kedudukan rasuk bumbung. a) Penambahan dan perubahan rasuk di lower roof beam key plan (3). b) Perubahan rasuk dan tiang di roof beam key plan. c) Perubahan rasuk di lower roof beam key plan (4). tukar jenis pintu tukar jenis pintu a) Pinda piawaian struktur rasuk di aras 2 dan tambah papak konkrit. tukar piawaian rasuk b) Tambah 6 unit r.c. plinth dan tambah 4 unit rasuk sediada untuk menyokong tangki air. Works to be carried out as per Construction drawing. c) Menutup lourved pada ruang makmal yang berhawa dingin dengan boral boars. Penebukan slab di bahagian atas flat slab kawasan bilik stor dan bilik betworking yang mesti dilengkapi dengan penutup m.s. plate, m.s. cat ladder, sepanjang 600mm dan concrete slab disebabkan keperluan bagi laluan masuk ke tangki air di aras lambung. a) Bina concrete bench, lab sing. Works to be carried out as per Construction drawing. b) Tambah railing pada tingkap kaca penuh 1 tingkap. Works to be carried out as per Construction drawing. c) Pasang siling gantung gypsum board pada 2 bilik mesyuarat pada aras tanah. Pasang air cond d) Pasang concrete slab pada setiap riser yang dilindungi oleh pintu rintangan api. Works to be carried out as per Construction drawing. a) Batalkan sebahagian bumbung Tukar kepada r.c. flat roof b) Pindaan terhadap piawaian struktur trench dan asas banguan bagi pencawang elektrik UTM kerana pindaan lukisan susnatur untuk pencawang elektrik. Kerja cerucuk remeasurement of quantites WBLFF remeasurement of quantites Kerja-kerja luar remeasurement of quantites * Site preparation and earthwork remeasurement of quantites * Turfing and softlanscaping remeasurement of quantites * Road, hardstanding, Pavement. remeasurement of quantites * Fencing and gate. remeasurement of quantites * Surface water drainange. remeasurement of quantites Sewerage remeasurement of quantites * External Water Supply remeasurement of quantites Peninggalan kerja supply and fix approved natural anodized aluminium frame fix lourves. remeasurement of quantites Pelarasan wang peruntukan sementara dan wang kos prima. remeasurement of quantites Perubahan kerja untuk kerja-kerja mekanikal. remeasurement of quantites Perubahan kerja untuk kerja-kerja elektrik. remeasurement of quantites Pelarasan turun naik harga. remeasurement of quantites Pelarasan keuntungan kepada kontraktor utama. remeasurement of quantites PPJHK-1 PPK APK APP 1 Tebang pokok sediada di tapak 2 a) Tambahan bilik PABX dan setor aras tanah 2.a b) Tambah 3 unit r.c. platform 2.b c) Tambah 8 unit bilik rangkaian komputer, 2 bilik di setiap aras. 2.c 3 4 5 a) Ganti gypsum board partition dengan dinding bata di bilik pensyarah b) Ganti semua bingkai kayu yang akan dipasang pada dinding gypsum board kepada bingkai kayu aluminium c) Tukar gypsum board partition di bahagian hadapan 14 unit bilik pensyarah aras tanah kepada dinding bata. d) Pinda ruang bilik pensyarah dengan keluasan asal 13.081m2 kepada 9 bilik 17.62m2, 9 bilik 21.62m2. a) Tambah 3 point paip bekalan air di makmal sains bangunan, makmal alam sekitar dan makmal senibina lanskap. b) Tambah 3 point floor trap and plumping pipe di makmal alam sekitar dan makmal senibina lanskap. 1 3.a 3.b 3.c 3.d 4.a 4.b c) Batalkan 3 pintu di makmal sains bangunan dan makmal sains alam sekitar, dan 2 pintu di ruang laluan. 4.c d) Tambah 8 pintu di makmal sains bangunan, makmal pengangkutan, makmal teknologi maklumat, makmal perbandaran, makmal sains alam sekitar dan makmal senibina lanskap. 4.d e) Tambah dinding bata di makmal teknologi maklumat dan makmal senibina lanskap. 4.e f) Tambah gypsum board partition dan 1200mm high fixed glass window dan aluminium frame double leaf door di makmal sians bangunan, makmal pengangkutan, makmal teknologi maklumat, makmal perbandaran, makmal sains alam sekitar. 4.f 4.f a) Batalkan 1 unit aluminium frame sliding window di makmal sains bangunan. b) Batalkan 2 unit aluminium frame sliding window di makmal pengangkutan. 5.a 5.b TOLAK TAMBAH (RM) JUMLAH - 4,916.25 4,916.25 139.56 4,228.96 4,089.40 - 1,969.88 1,969.88 - 6,000.00 6,000.00 3,536.00 2,966.60 (569.40) 7,984.00 20,908.10 12,924.10 7,686.70 4,770.90 (2,915.80) 7,326.10 - (7,326.10) - 315.00 315.00 - 742.00 742.00 2,010.40 - (2,010.40) 3,285.00 2,642.60 (642.40) - 3,214.80 3,214.80 - 16,377.40 16,377.40 - - - - - - c) Batalkan 2 unit aluminium frame sliding window di makmal perbandaran. d) Batalkan 1 unit aluminium frame sliding window di makmal sains alam sekitar. 6 e) Tambah 2 unit aluminium frame sliding window di makmal teknologi maklumat. f) Tambah 2 unit aluminium frame sliding window di makmal tsenibina lanskap. a) Pasang waterproofing greenseal B-2 di lantai simen tandas bagi menggantikan dampproof. b) Tambah r.c. gutterdi atas riser. 5.c 5.d 5.e 5.f 7 8 a) Tambahan kerja bagi rasuk, tiang dan papak di aras berikut; ground beam, 1st floor beam, 2nd floor beam, 3rd floor beam dan lower roof beam. 8.a b) Perubahan rasuk pada ground beam 8.b 8.b 9 a) Perubahan terhadap piawaian struktur bagi keperluan laluan air conditioning di aras 1 floor beam dan 2nd floor beam. 9.a 10 a) Pertambahan perincian lintol 9.6m. 10.a b) Perubahan dan pertambahan rasuk serta papak di aras 2nd floor beam. 10.b a) Pembatalan rasuk. 12.a b) Perubahan bagi kedudukan rasuk bumbung. 12.b a) Penambahan dan perubahan rasuk di lower roof beam key plan (3). 13.a b) Perubahan rasuk dan tiang di roof beam key plan. 13.b c) Perubahan rasuk di lower roof beam key plan (4). 13.c Tukar jenis pintu 14.a 11 12 13 14 a) Pinda piawaian struktur rasuk di aras 2 dan tambah papak konkrit. b) Tambah 6 unit r.c. plinth dan tambah 4 unit rasuk sediada untuk menyokong tangki air. c) Menutup lourved pada ruang makmal yang berhawa dingin dengan boral boars. 16.a 16.b 16.c - - - - 1,095.00 815.00 280.00 1,095.00 815.00 - 3,288.00 3,288.00 - 1,741.11 1,741.11 3,484.52 - (3,484.52) 5,026.99 9,358.55 4,331.56 32.64 50.56 17.92 84,358.30 87,235.91 2,877.61 450.00 450.00 10,235.40 10,679.50 444.10 2,343.84 - (2,343.84) 4,007.60 3,958.08 (49.52) 4,984.17 6,649.88 1,665.71 27,699.41 29,940.06 2,240.65 11,127.15 11,598.28 471.13 5,286.00 2,078.60 (3,207.40) 1,863.30 3,085.20 1,221.90 - 1,121.06 1,121.06 - 1,508.00 1,508.00 6.b 7 - 280.00 6.a Batalkan 4 unit urinal di tandas lelaki dan menganjakkan concrete bench ke tepi dinding. - - 15 16 18 Penebukan slab di bahagian atas flat slab kawasan bilik stor dan bilik betworking yang mesti dilengkapi dengan penutup m.s. plate, m.s. cat ladder, sepanjang 600mm dan concrete slab disebabkan keperluan bagi laluan masuk ke tangki air di aras lambung. 17.a a) Bina concrete bench, lab sing. 19.a b) Tambah railing pada tingkap kaca penuh 1 tingkap. 19.b c) Pasang siling gantung gypsum board pada 2 bilik mesyuarat pada aras tanah. 19.c d) Pasang concrete slab pada setiap riser yang dilindungi oleh pintu rintangan api. 19.d a) Batalkan sebahagian bumbung dan tambah r.c. flat roof. 20.a b) Pindaan terhadap piawaian struktur trench dan asas banguan bagi pencawang elektrik UTM kerana pindaan lukisan susnatur utntuk pencawang elektrik. 20.b - 1,174.22 2,204.60 1,174.22 (2,204.60) - 1,472.00 1,472.00 331.20 3,715.20 3,384.00 530.85 530.85 2,022.78 1,349.53 (673.25) 4,068.47 7,556.97 3,488.50 - PPJHK-2 PPK - APK APP POTONGAN TAMBAHAN (RM) JUMLAH - Pengukuran semula Kerja cerucuk 303,714.10 WBLFF 274,673.00 (29,041.10) 45,093.77 47,712.65 2,618.88 - 51,264.30 52,887.50 1,623.20 8,348.90 16,568.90 8,220.00 85,905.78 80,447.88 (5,457.90) 10,506.50 9,130.60 (1,375.90) 18,252.30 22,531.50 4,279.20 33,245.50 51,747.30 18,501.80 36,334.00 40,955.82 4,621.82 Kerja-kerja luar * Site preparation and earthwork * Turfing and softlanscaping * Road, hardstanding, Pavement. * Fencing and gate. * Surface water drainange. Sewerage * External Water Supply PPJHK-3 PPK APK Peninggalan kerja supply and fix approved natural anodized aluminium frame fix lourves. APP POTONGAN 57,984.00 TAMBAHAN (RM) - JUMLAH (57,984.00) PPJHK-4 PPK APK APP Pelarasan wang peruntukan sementara dan wang kos prima. POTONGAN TAMBAHAN (RM) 2,003,820.00 1,363,588.15 POTONGAN TAMBAHAN (RM) JUMLAH (640,231.85) PPJHK-5 PPK APK APP Perubahan kerja untuk kerja-kerja mekanikal. - 14,380.00 JUMLAH 14,380.00 PPJHK-6 PPK APK APP Perubahan kerja untuk kerja-kerja elektrik. POTONGAN 121,049.00 TAMBAHAN (RM) - JUMLAH (121,049.00) PPJHK-7 PPK APK APP Pelarasan turun naik harga. POTONGAN - TAMBAHAN (RM) 81,635.86 JUMLAH 81,635.86 PPJHK-8 PPK APK Pelarasan keuntungan kepada kontraktor utama. APP POTONGAN 1,210.49 TAMBAHAN (RM) 143.80 JUMLAH (1,066.69)