CITY OF CAPE TOWN PUBLIC TRANSPORT INFRASTRUCTURE AND SYSTEMS GRANT IRT / MyCiTi PROGRESS QUARTERLY REPORT JANUARY 2012 TO M ARCH 2012 Page i of 59 Project Quarterly Report Project Name: Integrated Rapid Transport System / MyCiTi Directorate: Transport, Roads & Major Projects Focus Area: IRT Project Development and Implementation Product: Quarterly Report for January to March 2012/ Monthly Progress Report No. 26 Prepared By: Document Owner(s) Project / Organisational Role J. Martheze City IRT Project Manager J Grimbeek PMIRT Project Manager Contributing Authors: Managers of Respective Sections Project Quarterly Report Version Control Version Date Author Change description V0 30 March 2012 Contributors Initial Draft V1.4 19 April 2012 D. Bosch/R. Kingma Final Draft V1.5 & V1.6 24 April 2012 D. Hugo / J. Martheze / J. Grimbeek Final Report ___________________________________ ____________________________________ Director IRT Implementation (D. Hugo) Director IRT Operations (A. Bassier) This Progress Report will be made available on the City of Cape Town’s website: www.capetown.gov.za/en/MyCiTi/Pages/monthlyprojectreports.aspx PURPOSE The Quarterly Report is a document prepared by MyCiTi / IRT Project Team for the purpose of regular recording and presenting the project status to the various City of Cape Town political and administrative oversight committees, the Department of Transport, Department of Finance, PGWC as well as other key stakeholder groups and interested parties. DISCLAIMER While ever effort has been made to present accurate and current information in this progress report, the City of Cape Town will not be held liable for the consequence of any decisions or actions taken by others who may utilise any information contained herein. Quarterly Report V1.5 January to March 2012 Page ii of 59 Table of Contents A. Introduction .............................................................................................................. 4 B. Project Background ................................................................................................. 4 B.1 Business Plan C. 5 Evaluation: Progress to Date ................................................................................... 6 C.1 Master Programme .................................................................................................. 6 Overview of Master Programme 6 C.2 Project Financials .................................................................................................... 8 Overview of Phase 1A Financials Project Estimate and Salient IRT Project Information: Phase 1A Project Cost Reporting Budget: Funding and Expenditure Authority Project Estimate and Future Funding Applications (DORA) Future Funding Applications (DORA) Key Financial Issues Stakeholders 8 8 9 10 12 12 12 12 C.3 Risk Management .................................................................................................. 18 Overview of Risk Management 18 C.4 Administration ........................................................................................................ 22 Overview of Human Resources Overview of Project Documentation Systems Overview of Accommodation 22 22 22 C.5 Procurement .......................................................................................................... 23 Overview of Procurement 23 C.6 Health and Safety .................................................................................................. 24 Overview of Health & Safety 24 C.7 System Planning .................................................................................................... 25 System Plan Overview Phase 1A Proposed Tariffs for 2012/13 Financial Year Phase 1B & 1C Serving the Metro South East 25 25 26 26 26 C.8 Infrastructure ......................................................................................................... 28 Overview Busway Civil Contracts & Stations Open Feeder Stop Contracts IRT Depot Contracts 28 28 29 29 C.9 Business Development .......................................................................................... 31 Overview of Business Development Amendments to the Business Plan Vehicle Procurement Contracts (VPCs) Vehicle Operator Contracts (VOCs) Station Management (SM) contract Automated Fare Collection (AFCs) Quarterly Report 31 31 31 32 32 32 V1.6 January to March 2012 Page iii of 59 Control Centre and Vehicle Tracking Advertising Management Contracts Further focus areas of the Business Development Team C.10 34 34 34 Industry Transition ......................................................................................... 36 Overview of Industry Transition Surveys for Market Share Compensation to Taxi Operators Notice in Media re Affected Operators Steps towards Compensation Surveys of Passengers on competing GABS routes C.11 36 36 36 36 36 MyCiTi Operations ......................................................................................... 37 Overview of MyCiTi Operations Summary of Passenger Numbers Operations Management Operational Resources Public Feedback C.12 37 37 39 39 40 Communications, Marketing & Branding ........................................................ 41 Overview of Communications & Marketing January 2012 February 2012 March 2012 D. Conclusions ........................................................................................................... 44 D.1. D.2 D.3 D.4 D.5 D.6 E. 41 41 41 42 Main Successes & Challenges of the Project Do the Outcomes justify the Costs? Were the Objectives Achieved within the specified Time & Budget? Embedding the Objectives in Local Institutions Preparation of Stakeholders Project Direction 44 44 44 44 45 45 Lessons Learnt & Recommendations .................................................................... 46 Annexure No. 1 – Grant Framework & Programme/ Project Design .............................. 48 Annexure No. 2 – Table of Indicators, MyCiTi ............................................................... 49 Annexure No. 3 – SCM BAC Summary Progress (January 2012) ................................. 53 Quarterly Report V1.6 January to March 2012 Page 4 of 59 A. Introduction The March 2012 Report is presented as a Quarterly Project Report for the period from 1 January 2012 to 31 March 2012, see below reporting table. It is prepared to record and to provide various National Departments, City Political and Administrative structures and other key stakeholders, with a summary of progress made to the end of the reporting period and to highlight any major issues and concerns that may impact on the project going forward. This report deals with Phase 1A (West Coast Corridor & CBD) of the MyCiTi project together with the initiation of the roll out of the system to other areas, such as the Metro South East. ANNUAL REPORT (June 2012) Quarterly Report Quarterly Report Quarterly Report Quarterly Report (September 2011) (December 2011) (March 2012) (June 2012) Abridged Progress Reports are prepared on a monthly basis and consolidated Project Reports are prepared on a quarterly basis. B. Project Background The City of Cape Town’s Integrated Rapid Transit (IRT) project, referred to as MyCiTi, is planned to transform the City’s current road based public transport system. This is to be accomplished through inter alia the provision of Bus Rapid Transit (BRT) services in dedicated right-of-ways, feeder bus services, automated fare systems, operating service contracts, institutional reform and the transformation of the existing public transport industry. The project is being undertaken under the auspices of the National Department of Transport’s (NDOT) Integrated Rapid Public Transport Project (IRPTN) programme. It is funded primarily through the Public Transport Infrastructure and System Grant (PTI&SG), the City’s rate funding and through fares paid by passengers. An interim MyCiTi starter service running between the CBD and Table View commenced in May 2011. The full service for Phase 1A will be completed by November 2013. Planning for the completion of Phase 1 and the commencement of Phase 2 is currently underway. Quarterly Report V1.5 January to March 2012 Page 5 of 59 B.1 Business Plan The MyCiTi / IRT Business Plan was adopted by Council in October 2010, which set the framework for Phase 1A of the project, including financial and time conditions. A copy of the Business Plan is available on the City of Cape Town’s website: http://www.capetown.gov.za/en/MyCiTi/Pages/Policies.aspx Amendments were approved at the February 2011 Council meeting to accommodate changes in the operating environment. A further update of the Business Plan is being prepared for submission to Council to address the requirements for designing and implementing the follow up phases of the system, including Phase 2 to the Metro South East. Quarterly Report V1.6 January to March 2012 Page 6 of 59 C. Evaluation: Progress to Date C.1 Master Programme Overview of Master Programme The summary sheet indicated below is based on the IRT MASTER PROGRAMME Rev K – September 2011. It reflects the status of the main workstreams. The team is in the process of identifying mitigating solutions to ensure Phase 1A is delivered by the original completion date of September 2013. A comparison with the approved baseline programme yields the following summary results: DESCRIPTION VEHICLE OPERATOR APPOINTMENTS STATUS Behind 7 weeks NOTES Long term contract negotiations delayed STATION MANAGEMENT SERVICES Behind 4 weeks Re-tendered & Re-programmed VEHICLE ACQUISITION On Track Feeder vehicle – on track. Trunk Vehicle Tender – in preparation. LAND PROCUREMENT On track In line with the Master Programme. TRANSPORT MANAGEMENT CENTRE Complete CCC - DESIGN CCC – CONSTRUCTION & IMPLEMENTATION AFC - DESIGN AFC – CONSTRUCTION & IMPLEMENTATION On track Behind 4 weeks On track Behind 5 weeks In line with Master Programme Delay to the manufacturing process and installation of equipment In line with Master Programme Delay to the start of manufacturing of equipment EIA / PLANNING APPROVAL Behind 5 weeks ATLANTIS CORRIDOR – DESIGN (HHO) ATLANTIS CORRIDOR – CONSTRUCTION INNER CITY DESIGN (GIBB) On track Behind 2 weeks Behind 2 weeks Behind 3 weeks Complete Complete Behind 2 weeks Adderley Street sub project – heritage process delays plan approval of works. In line with Master Programme Delays to civil construction project 262Q and the open feeders Delayed design due to heritage constraints and client negotiations Delays to Inner City Open and Closed feeder stops. INNER CITY – CONSTRUCTION STADIUM CIVIL WORKS (NS / AURECON) AIRPORT CIVIL WORKS (ASCH / ILISO) SUPERSTRUCTURES - TRUNK STATIONS & CLOSED FEEDERS NMT INTEGRATION Quarterly Report On track Inner City Superstructures behind schedule In line with Master Programme V1.6 January to March 2012 Page 7 of 59 Quarterly Report V1.6 January to March 2012 Page 8 of 59 C.2 Project Financials Overview of Phase 1A Financials This section addresses the IRT Project financials and covers the following: a. b. c. The project estimates and other salient information. The project cost report, including the value of work done, planned and projected cash flows and expected cost at completion. The City Budget · Funding and expenditure authority · Capital and operating expenditure d. Funding applications (DORA) e. Other key issues relating to the project financials A key aspect to note when reviewing this section is the difference between the information presented under the section addressing the Project Cost Report and that under the City Budget and Capital and Operating Expenditure reports. The former focus on actual value of work done and is used by the project team to manage cash flow and monitor and predict expenditure, to enable proactive interventions at a project level if necessary. The latter addresses the expenditure (payments) recorded in the City’s financial system and may lag behind the actual value of work done by up to two months or more. Project Estimate and Salient IRT Project Information: Phase 1A Project Duration: Phase 1A First IRT construction contract awarded 6 Oct 2008 Projected completion of Phase 1A as currently programmed (subject to PTISG funding being confirmed for 2012/13). 30 Sep 2013 Costs of implementing Phase 1A Estimated infrastructure and vehicle costs (incl. VAT) Estimated transitional, design and implementation operating costs (incl. VAT) Estimated total cost of implementing Phase 1A (incl. VAT) Estimated Annual Operating Deficit of running Phase 1A as currently modelled (not escalated, excluded above, and excludes planned reallocated bus subsidies) [2] Expenditure 2008/09 FY R 3 894 million R 702 million R 4 596 million R 116 million pa R 248 million Expenditure 2009/10 FY R 846 million Expenditure 2010/11 FY Expenditure 2011/12 FY R 457 million Quarterly Report R 594 million V1.6 January to March 2012 Page 9 of 59 Total expenditure to date 2008/09 FY to 2011/12 FY on SAP as at 6th January 2012 Available assured funding from City and National received to date [3] R 2 145 million Estimated future expenditure for implementing Phase 1A (for the remainder of the 2011/12, 2012/13 and 2013/14 FY’s but excluding annual running cost) R 2 677 million Total indicative PTIS funding from National in the 2008/09 to 2013/14 financial years Estimated Total Project System Cost of Implementing Phase 1A R 5 965million[4] R 3 391 million R 4 596 million Table C.2.1: Salient Project Financial Information [2] This represents midway between the optimistic and pessimistic projections of operating costs as set out in par 9.5 of the updated Business Plan. [3] This excludes the R 368 million made available by the City to bridge the gap between the City and National financial years, which was recovered from the National PTI&S Grant after approval by Council in July 2010. [4] Based on the Division of Revenue Act (DoRA) gazetted on the 28 April 2011. This is an indication of all funding on this particular category of grant and does not imply that all funding is for the IRT project only. Project Estimates The above table includes the results of a major review of the transport and operating cost modelling for Phase 1A of the project, and includes the estimated cost of running the system once commissioned. It takes into account the estimated operating income and operating expenditure. This review included an audit of the system demand and cost modelling, with inputs and assumptions closely scrutinised. The review of the transport and cost model will improve the confidence and accuracy of the estimated operating cost of Phase 1A. The estimated total project system cost of implementing Phase 1A (reflected above) has remained as previously reported. The estimated annual operating deficit is pegged at the mid-point of a possible (modelled) deficit range. The Project Team is also reviewing other parts of the project, such as possible re-engineering of the infrastructure and value engineering to ensure that project costs are minimised without compromising project objectives. Project Cost Reporting The PMIRT team (Cape Town IRT Project Managers Joint Venture), in consultation with the IRT Project Team, has developed a detailed monthly cost accounting and reporting process, whereby monthly project costing is tabled and discussed at the monthly Client Project Management Meetings. This reporting details and consolidates all project cost activities and this is being used to accurately monitor and manage the project expenditure and cash flow, ensuring alignment with Council’s approved budgets. Further, this information forms a basis for the ongoing program evaluation and progress monitoring of Phase 1A, ensuring that funds will only be committed when secured. Quarterly Report V1.6 January to March 2012 Page 10 of 59 Aspects relating to the project expenditure profiles are graphically illustrated below (Refer to Graph C.2.1). Graph C.2.1 - The above graph represents an estimate of the operating and capital expenditure (planned payments) vs. the actual expenditure (payments made) that is recorded on the City’s SAP financial system. The targeted SAP line (which is a projected estimate of SAP expenditure), is indicated and the actual SAP expenditure is extracted from the City’s financial SAP system. As at the end of March 2012, the actual expenditure as recorded on SAP is tracking slightly below the estimated expenditure cashflow. Should actual expenditure track along the estimated line, it is expected that the overall expenditure for the financial year will be approximately 84% of the adjusted budget. This excludes additional allowances that are currently being assessed, such as additional vehicles and works on the various contracts. Budget: Funding and Expenditure Authority Operating The 2011/12 Operating Budget, approved by Council on the 8 June 2011, includes an annual budgetary provision for the establishment and ongoing management of the IRT Project Office. The organisational structures of both IRT Departments have been approved by Council. The recruitment and selection process to fill the approved organisational structure is under way. Budgetary provision for Grant Funded Operating projects, associated with the various streams within the IRT project, has also been included in the 2011/12 Operating Budget submitted to Council for Quarterly Report V1.6 January to March 2012 Page 11 of 59 approval. With the introduction of the MyCiTi Starter Service commencing on 9th May 2011, this project had a significant increase in expenditure levels as a result of the system operating costs incurred by the three vehicle operating companies. Capital As a result of the financial review of Phase 1A during 2009 and 2010, prior to the adoption of the Business Plan in October 2010 and based on our contractual commitments and future commitments, the capital programme for the implementation of Phase 1A was adjusted in line with the projected capital expenditure for the balance of the project. Budget: Capital and Operating Expenditure Progressive Capital Expenditure Report for 2008/09, 2009/10, 2010/11 & 2011/12 Table C.2.3 reflects capital expenditure from all sources (PTI&SG, CRR and EFF) relating to the IRT project. Individual projects are grouped according to their specific category or area. It should be noted that the budget for the 2011/2012 financial year in table C.2.3 reflects the adjusted budgetary provisions as approved by Council on 25 January 2012. The budget has been adjusted to more realistically reflect the latest expenditure projections for the year. Expenditure Report for Grant Funded Operating Projects Table C.2.4 reflects all operating expenditure, funded from grant funding, relating to the IRT project. Individual projects are grouped according to their specific area and relate primarily to the procurement of external service providers, except where stated otherwise. Expenditure and Revenue Report for the two IRT Departments Table C.2.5 reflects all operating expenditure and revenue relating to the running of the two IRT Departments (Implementation & Operations). Expenditure and revenue is summarised according to subjective categories. The table reflects the adjusted budget for 2011/2012 as approved by Council on 25 January 2012. As the implementation and operation of the MyCiTi bus service involves the setting up of new departments and structures and is a first for the City, it is to be expected that cost estimates will need adjustment as operations begin and new information becomes available. It is possible that further adjustments will be required as the service is rolled out and running costs become clearer. Operating Cost and Estimated Revenue for MyCiTi Starter Service Table C.2.6 reflects all operating costs (budgeted and actual) and all operating revenue (budgeted and actual) associated with the provision of the MyCiTi Starter Service, which commenced on 9th May 2011. The actual operating expenditure and revenue reflected in Table C.2.5 is also represented in Table C.2.3 Quarterly Report V1.6 January to March 2012 Page 12 of 59 Project Estimate and Future Funding Applications (DORA) Future Funding Applications (DORA) Table C.2.7 below reflects the actual DoRA allocations from the Department of Transport (DoT) towards public transport for the City as a whole. The information in the table below was gazetted in Parliament in April 2011, as part of the Division of Revenue Act (DoRA). Financial Year 2010/11 2011/12 2012/13 2013/14 Total DoRA – 28 April 2011 DoRA Update Feb 2012 Rm Rm 1 018 1 800 1580 1 600 1 018 1 800 1348 1 298 232 302 5 998 5 464 534 Decrease Rm Table C.2.7: Division of Revenue Act: City Allocations (2010/11 to 2012/13) Key Financial Issues VAT Recalculation A detailed assessment of the extent of VAT payment in relation to IRT / Non IRT elements has been undertaken by the City’s VAT unit in the Finance Directorate in consultation with SARS. A VAT recovery process was initiated for the first contracts to March 2010, and a claim to the value of R38.8 million has been submitted to SARS for recovery. Stakeholders Monthly Progress Report No. 25 for the period ending 29 February 2012 was submitted to the following Committees for their consideration during the March cycle of meetings: Portfolio Committees - Transport Roads & Major Projects; Finance Mayoral Committee Council This Progress Report (No. 26) is scheduled to serve before the abovementioned Committees during Council’s April 2012 cycle of meetings. Copies of the Project Progress Reports have been forwarded to the National Department of Transport and Province Government Western Cape (Transport Department) for their information. To keep these key stakeholders informed of project progress and of any issues that may arise during the execution of the project, minutes of the project’s Monthly Client/Management Meetings are distributed to both the Provincial Government Western Cape (Transport Department) and the National Department of Transport. Invitations to attend these meetings have been extended to both parties. Quarterly Report V1.6 January to March 2012 Page 13 of 59 Ongoing stakeholder meetings have been held or are planned with PRASA, PGWC, NDOT and relevant City Departments on the role of rail and other public transport services in the Integrated Public Transport Network (IPTN) for the City of Cape Town. Quarterly Report V1.6 January to March 2012 Page 14 of 59 Category WBS Project Description 2008/2009 Current Budget Actual 2009/2010 % Spend Current Budget Actual 2010/2011 % Spend Current Budget % Spend - - - IRT:Koeberg BRT Corridor:PTIF- - - - - - - - NG DOT PTI&SG C09.00419-F1 IRT:Granger Bay Blvd:PTIF 10 500 000 - - - - - - NG DOT PTI&SG C09.00487-F1 IRT:Klipfontein Corridor:PTIF - - - - - - NG DOT PTI&SG C09.00488-F1 IRT:Public Trsprt&Bus Upgr 20 000 on000 Corr:PTIF19 983 113 - - - - - - NG DOT PTI&SG C09.00489-F1 IRT:IntegratedFareManagement- System:PTIF - - - - - - NG DOT PTI&SG C09.00497-F1 IRT:PropertyAcquisition:PTIF 57 800 000 - - - - - - NG DOT PTI&SG C09.00498-F1 IRT:VehicleAcquisition:PTIF - - NG DOT PTI&SG C09.00499-F1 IRT:WestCoastCorridor:PTIF 90 000 000 89 999 969 100.0% NG DOT PTI&SG C09.00500-F1 IRT:AirportService:PTIF 2 000 000 2 000 000 100.0% - NG DOT PTI&SG C09.00501-F1 IRT:PropertyAcquisition:PTIF - - - NG DOT PTI&SG C10.00093-F1 IRT: Control Centre:PTIF - - NG DOT PTI&SG C10.00126-F1 IRT: Depot Infrastructure:Inner City - - NG DOT PTI&SG C10.10320-F1 IRT:PropertyAcquisition:PTIF - - 17 629 17 629 100.0% NG DOT PTI&SG C10.10327-F1 IRT:WestCoastCorridor:PTIF - - 51 941 535 50 633 467 97.5% 211 558 802 NG DOT PTI&SG C10.10350-F1 IRT:InnerCityService:PTIF - - 10 000 000 9 463 641 94.6% 7 907 362 NG DOT PTI&SG C10.10542-F1 IRT:AirportService:PTIF - - 6 000 000 6 000 000 100.0% 570 000 NG DOT PTI&SG C10.10581-F1 IRT:Public Trsprt&Bus Upgr on -Corr: - 2 000 000 1 677 149 83.9% 4 560 000 NG DOT PTI&SG C10.10582-F1 IRT:IntegratedFareManagement- System - 13 295 117 10 833 656 81.5% NG DOT PTI&SG C11.10123-F1 IRT: Control Centre - - - - 54 128 438 1 228 709 2.3% 127 173 688 75 038 879 59.0% NG DOT PTI&SG C11.10124-F1 IRT: Fare Collection - - - - 77 076 110 21 595 971 28.0% 39 712 639 34 720 992 87.4% NG DOT PTI&SG C11.10501-F1 IRT: FeederStations: InnerCity: -PTIF - - - 54 476 896 40 935 104 75.1% 80 245 332 20 364 996 25.4% NG DOT PTI&SG C11.10502-F1 IRT: Trunk Stations: PTIF - - - 57 474 780 1 099 673 1.9% 86 235 618 12 724 344 14.8% NG DOT PTI&SG C11.10504-F1 IRT: Depot Infrastruc: Potsdam -Depot: PTIF - - - 10 000 000 6 403 724 64.0% 66 817 124 49 178 594 73.6% NG DOT PTI&SG C11.10505-F1 IRT: Depot Infrastruc: Atlantis Depot: PTIF - - - 67 036 - 0.0% 32 727 765 2 754 548 8.4% NG DOT PTI&SG C11.10507-F1 IRT: NMT: PTIF - - - - 5 504 804 - 0.0% 15 452 003 2 897 766 18.8% NG DOT PTI&SG C11.10558-F1 IRT: Property Acquisition - - - - 4 500 000 NG DOT PTI&SG C11.10121-F1 - - - - - - - - - - 300 000 - NG DOT PTI&SG C12.10116-F1 IRT: Vehicle Acquisition IRT: Integr Rapid Transit Syst Phase2 IRT: Busways Phase2 - - - - - - 500 000 - NG DOT PTI&SG C12.10117-F1 IRT: Depots Phase2 NG DOT PTI&SG C12.10115-F1 Total NG DOT PTI&SG 99.9% - 57 202 138 - 99.0% - - 180 300 000 100.0% 179 685 220 76 500 000 63 888 232 83.5% 368 405 758 328 560 020 89.2% - - - - - - - - - - - - - - - - - - - - - 23 314 223 - - - - - CRR BRT SystemC09.00498-F2 IRT:VehicleAcquisition:CRR - - 25 000 000 23 260 345 93.0% CRR BRT SystemC09.00499-F2 IRT:West Coast Corridor:CRR 30 000 000 111 583 679 111 583 679 CRR BRT SystemC10.00093-F2 IRT: Control Centre:CRR - - 25 000 000 25 000 000 CRR BRT SystemC10.10337-F2 IRT:West Coast Corridor:CRR - - CRR BRT SystemC10.10579-F1 IRT: Traffic Management Centre: - CRR - CRR BRT SystemC10.10582-F2 IRT:IntegratedFareManagement- System 45 001 399 247 529 100.0% EFF C07.00002-F2 R27: Addtl lanes and intersection - impr EFF C09.00499-F3 IRT:WestCoastCorridor:EFF EFF C10.10112-F1 EFF EFF - - 247 529 Acquisition of Land - - 100.0% #DIV/0! - 6 840 000 103 271 298 200 000 -36.5% - C05.00951-F1 - - -3 693 819 100.0% EFF - 10 128 339 50 177 314 97.5% 0.0% 100.0% 96.7% 50 177 314 - - - 4 499 386 159 691 855 - 64 453 192 - 43 860 316 4 560 000 262 466 269 888 072 265 26 593 277 411 234 601 - - - - - - - - - - - 100.0% - - - - 100.0% - - - - - - - - - - - - - - - - 41 035 764 91.2% 7 704 883 5 511 049 71.5% 331 149 684 321 021 343 96.9% 10 128 339 -3 693 819 -36.5% 60.8% - - - 56.5% - 0.0% 66 682 409 - 45 000 000 - 86.9% 60.3% IRT:PropertyAcquisition:CRR 96.2% 183 861 872 397 198 399 IRT: Traffic Management 15Centre: 000 000 CRR 17 879 919 - 658 699 172 CRR BRT SystemC09.00497-F2 28 861 715 - 89.2% CRR BRT SystemC09.00486-F2 100.0% 64.4% 471 073 793 IRT:Integr Rapid Transit Syst(Ph1A) - 14 998 601 15 009 772 528 160 039 CRR BRT SystemC09.00313-F2 Total CRR BRT System - 4 635 868 27 269 350 - 99.7% 15 920 000 48 250 610 % Spend IRT:Integr Rapid Transit Syst(Ph1A):PTIF - - 86.1% Actual NG DOT PTI&SG C09.00352-F1 10 500 000 113 368 320 Current Budget NG DOT PTI&SG C09.00313-F1 - 131 640 721 2011/2012 Actual 0.0% 25.8% 0.0% 0.0% 0.0% 46.3% - - - - - - - - - - - - - - - - - - - - IRT: Project Office - - C12.10111-F1 Furniture and Computers - - - - - - 4 000 000 123 856 3.1% C12.10121-F1 Furniture and Computers - - - - - - 4 000 000 45 936 1.1% Total EFF 4 000 000 1 089 396 27.2% 228 213 -0 -19 070 - 247 529 247 529 100.0% 4 000 000 1 089 396 27.2% 228 213 -19 070 -8.4% 8 000 000 225 547 529 223 793 065 99.2% 863 309 723 793 184 532 91.9% 669 055 724 393 485 510 58.8% 896 072 265 Table C.2.3 : 2008/09, 2009/10, 2010/11 and 2011/12 (March 2012) – Capital Projects Progressive Capital Expenditure Quarterly Report -8.4% V1.5 January to March 2012 - 411 234 601 45.9% Page 15 of 59 Category WBS 2008/2009 2009/2010 2010/2011 Actual Actual Actual 18 191 590 2011/2012 Project Description Current Budget % Spend NG DOT PTI&SG G09.00068-F1 Integrated Rapid Tra 1 875 472 10 743 484 NG DOT PTI&SG G09.00097-F1 IRT:Prov of Prof Ser 1 651 103 2 000 000 - - - NG DOT PTI&SG G09.00099-F1 IRT:Prov of Prof Ser 10 403 662 4 999 121 - - - NG DOT PTI&SG G09.00100-F1 IRT:Prov of Prof Ser 6 321 511 3 000 000 - - - NG DOT PTI&SG G09.00101-F1 IRT:Prov of Prof Ser 1 616 594 1 491 694 - - NG DOT PTI&SG G11.00005-F1 IRT: Project Management - - NG DOT PTI&SG G11.00031-F1 IRT: Compensation & Scrapping Allowance - - NG DOT PTI&SG G11.00010-F1 IRT: Property Lease - - 6 378 893 NG DOT PTI&SG G11.00032-F1 IRT: Operating Management Unit - - 2 831 051 110 093 750 27 641 607 25.1% Total NG DOT PTI&SG 981 640 9 743 126 Actual 14 500 000 - - 36.2% 7 327 153 50.5% - 21 868 342 22 234 299 28 383 174 134 336 876 38 495 893 28.7% 21 868 342 22 234 299 28 383 174 134 336 876 38 495 893 28.7% Table C.2.4 : 2008/09, 2009/10, 2010/11 and 2011/12 (March 2012) – Grant Funded Operating Projects Expenditure Quarterly Report 3 527 133 V1.6 January to March 2012 Page 16 of 59 Category Department Cost Centre 2008/2009 2009/2010 2010/2011 Actual Actual Actual 2011/2012 Subjective Category Current Budget Actual % Spend Expenditure IRT: Implementation 19070167 Salaries & Wages - - 5 225 837 16 936 161 7 967 963 47.0% Expenditure IRT: Implementation 19070167 Social Contributions - - 398 093 460 256 874 995 190.1% Expenditure IRT: Implementation 19070167 General Expenses 45.2% Expenditure IRT: Implementation 19070167 Contracted Services Expenditure IRT: Implement 19070167 R+M (Primary) Expenditure IRT: Implementation 19070167 Secondary Total Implement. 22 618 052 39 709 150 23 736 885 29 362 854 13 282 633 2 305 700 13 589 116 288 215 2 550 000 1 330 398 5 904 18 685 6 667 19 996 487 481 420 748 427 797 916 38 504 579 23 884 381 62.0% 44 926 143 534 737 698 457 453 613 87 813 850 47 764 740 54.4% - 424 370 52.2% #DIV/0! Expenditure IRT: Operations 11120010 Salaries & Wages - - 3 295 173 26 975 591 12 654 693 46.9% Expenditure IRT: Operations 11120010 Social Contributions - - 34 931 61 669 455 336 738.4% Expenditure IRT: Operations 11120010 General Expenses - - 27 813 668 58 772 432 27 335 844 46.5% Expenditure IRT: Operations 11120010 Contracted Services - - 2 865 757 173 352 849 81 758 983 47.2% Expenditure IRT: Operations 11120010 R+M (Primary) - - 33 655 Expenditure IRT: Operations 11120010 Secondary - 86 951 26 959 054 26 625 856 12 321 658 46.3% - 86 951 61 002 237 285 788 397 134 690 173 47.1% 534 824 649 518 455 850 373 602 247 182 454 913 48.8% Total Operations Total Expenditure 44 926 143 Revenue IRT: Implementation 19070167 User Charges Revenue IRT: Implementation 19070167 Operating Grants 21 868 342 22 234 299 24 685 586 Revenue IRT: Implementation 19070167 Capital Grants 19 983 113 471 073 793 373 541 843 Revenue IRT: Implementation 19070167 Secondary Total Implement. - - 41 851 455 493 308 092 2 415 569 -1 400 642 997 - 24 773 126 - 163 659 12 708 873 #DIV/0! 51.3% - #DIV/0! - #DIV/0! 24 773 126 12 708 873 51.3% 61.6% Revenue IRT: Operations 11120010 User Charges - - 4 553 783 36 100 000 22 243 851 Revenue IRT: Operations 11120010 Operating Grants - - 1 390 608 130 372 832 5 860 102 Revenue IRT: Operations 11120010 Capital Grants - - 22 498 892 Revenue IRT: Operations 11120010 Other Income - - 1 627 399 - - 30 070 682 166 472 832 28 118 693 16.9% Total Operations - 4.5% - #DIV/0! 14 740 #DIV/0! Total Revenue 41 851 455 493 308 092 430 713 679 191 245 958 40 827 566 21.3% Net Cost to Rates -3 074 688 -41 516 557 -87 742 171 -182 356 289 -141 627 347 77.7% Table C.2.5 : 2008/09, 2009/10, 2010/11 and 2011/12 (March 2012) – Project Office Expenditure & Revenue Quarterly Report V1.6 January to March 2012 Page 17 of 59 Category Detail 2010/11 Plan (R m) gl's 2010/11 Actual (R m) 2011/12 Plan (R m) 2011/12 Actual (R m) Operating Costs Milestone 0 33.3 14.0 141.7 59.1 Milestone 1 401200, 401300, 401500, 411800, 414360, 455100 & 655100 - - 46.1 - Milestone 2 - - - - Start Up Cost 6.0 - - - IRT Operations Staff (ME) - - 13.0 - 39.3 14.0 200.8 59.1 5.6 4.6 28.4 14.8 Milestone 1 - - 26.2 - Milestone 2 - - - - Events & Charters Income 0.4 - 6.0 - Advertising - - 3.0 - Total Estimated Revenue 6.0 4.6 63.6 14.8 33.3 9.5 67.6 44.3 - 69.5 - Total Operational Cost Estimated Revenue Milestone 0 810850 & 810880 Operating Deficit (Rates) Operating Deficit (PTI&SG) - Table C.2.6: 2008/09, 2009/10, 2010/11 and 2011/12 (March 2012) – MyCiTi Starter Service Operating Costs & Estimated Revenue Quarterly Report V1.6 January to March 2012 Page 18 of 59 C.3 Risk Management Overview of Risk Management The risk report is currently updated on a monthly basis, adding new risks and updating the mitigating strategies for each item. With each analysis the mitigating factors of the previous report are updated and compared in order to review the status of the risk profile with the City. The major risks at present are (in order of priority): C3.1 Delays to the negotiations of the long term agreement with the Vehicle Operators. Primary Risk The interim contract with the Vehicle Operators was extended up to the end of April 2012. Extension of the interim contract from April 2012 to beyond December 2012 is critical to ensure that the continued operations of the MyCiTi service, as the long term contract has not been finalised. Should this not be achieved, a new interim contract would be required, which could lead to delays. With no contract in place, the system will not have an operator. Delays to the long term contracts have operational cost implications. Mitigating Measures The City plans to negotiate an extended interim contract, with minor adjustments. Secondary Risk Not reaching an agreement with operating companies, prior to the Milestone 1 roll out date and the end of the extended interim agreement. Interim contract might need to be extended further if the long term agreement is not in place by December 2012. The interim agreement needs to take into account a substantial increase in the amount of infrastructure to be managed. Mitigating Measures The extension of the interim contract and the revised programme, should allow enough float for a reasonable amount of fluctuation due to the multiple variables in the programme. Regular tracking and adjustment of the programme will be required. The Industry Transition and negotiating teams need to be strengthened. Quarterly Report V1.5 January to March 2012 Page 19 of 59 C3.2 Financial Management of OPEX: Primary Risk Not spending as planned, due to delays that exceed the allowed float in the Master Programme. Severe delays are currently experienced on the payment of: Compensation to the VOC's and the payment of Scrapping allowances. Not spending the funds, result in the IRT Phase 1A project deviating from its projected cashflow, which can lead to the underspending of funds allocated to a specific financial year. Underspending can cause the project to lose future funding. Mitigating Measures All effort is made to expedite the industry transition negotiations. There is an ongoing delay on reaching an agreement on Compensation. Early compensation for operators who agree to the terms of the long term contract will be allowed. Secondary Risk The operational cost was assessed and taking the SLA’s into account, revised to be within the available budget. The implementation of the internal changes is challenging, but feasible. There are still elements of the operational process that needs to be clarified through the SLA’s and Station Management Contract. Mitigating measures The City is in negotiation with N.D.O.T. to clarify the utilization of funds with regards to operational costs. Any deviation from the original N.D.O.T. application must be assessed and the impact of the changes on future operational expenditure needs to be determined and presented to all parties. C3.3 Financial Management of CAPEX Primary Risk The actual cost or updated costs of the Infrastructure projects are higher than the original estimates, resulting in deviation from projected spending targets. The overall contract can exceed the original estimated budget if the proposed savings identified, are not realised. Not spending as planned, due to variations in the contract value or delays can lead to underspending of funds allocated to a specific financial year. Underspending can cause the project to lose future funding. Mitigating measures The capital costs of the projects were updated, indicating that the committed contracts are predominantly within the revised spending targets, assuming that the proposed cost reductions can be realized. The proposed cost reductions are now in the process of being implemented. The professional team assists in tracking the overall cashflow projection against the actual spent values, to highlight possible risk areas in advance. Quarterly Report V1.6 January to March 2012 Page 20 of 59 C3.4 N.D.O.T. Funding Strategy. Primary Risk N.D.O.T. funding strategy is not in line with the City’s interpretation of the MFMA, i.e. City will not commit to multi-year expenditure without receipt of the required funding, whereas DORA refers only to indicative funding in outer years. Treasury will not release funding, unless the current funds has been spent or are planned to be spent within the applicable financial year, prior to the release of additional funding. Mitigating measures N.D.O.T. proposed that guarantees be put in place to secure funding. The guarantees from Treasury are critical, to ensure that the funding is secured for the committed projects, as well as project to be awarded in future. The IRT Project office is following up with N.D.O.T. with regards to the guarantees suggested at the last meeting. Receipted funds need to be spent prior to N.D.O.T. / Treasury releasing further funding. Cost control measures and work is being programmed to ensure that funding aligns with cashflow projections for the respective financial year, as opposed receipt of funding for the full contract value of multi-year contracts. The balance of funding to be guaranteed. C3.5 Inner City Depot - Risk of delays due to unearthing graves of historical artefacts. Primary Risk The proposed design indicates that some structures will be constructed on undisturbed soil, potentially digging into areas where historical artefacts may be found. This could result in construction delays. Any delays to the construction will increase the contract duration and influence sequencing, resulting in additional cost to the contract and disruption to the resident Vehicle Operator. Mitigating Measures Ideally the new design should not exceed the original building perimeter. If the proposed design needs to be constructed on undisturbed soil, the heritage consultant should start with trial holes as soon as possible. C3.6 Heritage approval process required for the IRT station in Adderley street Primary Risk The heritage approval process required for the station at Adderley attracted public comment and the resolution process can cause delays. Further delays to the process can cause this station to finish later than September 2013, thus increasing the overall project duration. Quarterly Report V1.6 January to March 2012 Page 21 of 59 Mitigating Measures The process is monitored very closely, but will need assistance from the city to expedite processes where possible. Notes: With reference to the Monthly Risk Profile below please note the following: The Monthly Profile is an average risk rating, taking the initial and mitigated values into account. An increase in the profile can be due to an increase in the amount of high risk items or be indicative of a need for more effective mitigation. The risk profile will improve with the confirmation of mitigating solutions that were or can be applied. Quarterly Report V1.6 January to March 2012 Page 22 of 59 C.4 Administration Overview of Human Resources Both the IRT organisational structures for Implementation and Operations Departments have been approved and posts advertised. Some of the critical posts have in the meantime been filled whilst others are at a quite advanced staged of being filled. In the light of the fact that some posts require specific skills, categorised as scarce skills, it will have to be re-advertised as no suitable candidates could be identified during the first round of advertisements. In other instances where suitable candidates could be identified but the remuneration offered was not acceptable to the successful candidates, consideration has been given to consider alternative offers of appointment by the delegated authority. A dedicated team of Human Resources practitioners are driving the recruitment and selection process for the filling of the vacant posts on the IRT organisational structures in consultation with the Line Managers involved. Overview of Project Documentation Systems A Work Group has been established and a programme of implementation finalized for the end of April 2012. The Sharepoint documentation sharing and collaboration platform is operational and will go live by 1 May 2012. Training for the users of the system has been undertaken. The main challenge will be to get users to change to the new system and use it as a primary business tool for interchanging of all information related to the IRT project. Archiving of older electronic information into the City’s SAP Records Management system will commence in the next reporting period. Overview of Accommodation Expansion of office accommodation in terms of IRT floor space, computer equipment and furniture for new staff members will now be completed by the end of the financial year 2012, in accordance with a revised agreed roll-out programme. The programme was revised due to a delay in relocating existing staff from their current location which had been identified and earmarked for the IRT Operations unit. The issue has now been resolved and will not impact on the core business function. The furniture and equipment fit-out required to the Traffic Management Centre (TMC) has been completed, and the TMC is now operational. Quarterly Report V1.6 January to March 2012 Page 23 of 59 C.5 Procurement Overview of Procurement The following statistics relate to the IRT procurement of goods and services, i.e. equipment, consultants and contractors, and have been drawn from a schedule of awards in terms of the IRT project: The percentage split between the total value of goods and services procured to date is: o o Consultants (Professional Service Providers) Contractors / Suppliers = 10.64 % = 89.36 % It must be note that the value of procured goods and services does include contingencies and VAT, and as such, this value exceeds actual expenditure and outstanding commitments. The value of awards made to Historically Disadvantaged Individuals (HDI) expressed as a percentage of the total value of awards made, as measured in terms of the City’s Supply Chain Management Policy: = 44.72 % NOTE: 1. The above statistics apply to the IRT project from its initiation in 2008 to present. 2. A schedule of all the appointments made in terms is appended as ANNEXURE 3 to this report. Quarterly Report V1.6 January to March 2012 Page 24 of 59 C.6 Health and Safety Overview of Health & Safety Feedback on the Occupational Health and Safety for IRT is given at the monthly IRT Client Management meetings. The areas covered include: 1. IRT Project Office (Safety Report Feedback) 2. IRT Construction Contracts 3. IRT Operations Construction Contracts Independent Health and Safety Agents are appointed for each contract, and submit detailed safety reports on a monthly basis to the relevant City contract manager. The contract managers provide summary and exception / incident reports for inclusion in the monthly IRT Progress Report. Overall we can report that during the reporting period a number of minimal non-compliance issues were identified. Infringements were immediately attended to and resolved satisfactorily. Operational MyCiTi Contracts Full H&S assessments of the VOC operations continue. Similarly, summary and exception reports are provided for inclusion in the monthly IRT Progress Reports. The overall station compliance is good. The following graphs indicate the overall average H&S compliance of the stations for the period January to March 2012, and the depots and workshops for March. Items are classified according to their impact on the system and are rectified by the VOC’s accordingly in the week following the assessment. Quarterly Report V1.5 January to March 2012 Page 25 of 59 C.7 System Planning System Plan Overview Phase 1A Phase 1A implementation is scheduled to be rolled out in 5 milestones, namely Milestone 0 to 4. Milestone 0 is currently operational. The remaining milestones will be rolled out as follows: Milestone Milestone 1 Description of services provided Programme Dates Reasons Business Plan Updated Plan Milestone 0 plus The permanent Inner City feeders covering entire inner city areas plus a link to Hout Bay. 9m feeder busses will be operational. Existing Interim feeders in Table View will continue in support of the Table View Trunk service Dec 2011 Oct 2012 Delay in award of AFC and CCC contracts (appeals) Expected delay in negotiating VOC long term contracts Delays to closed feeder projects, due to stakeholder, heritage and EIA constraints Plus: Feb 2012 Dec 2012 Longer than anticipated construction period for Racecourse Road contract. July 2012 Feb 2013 Appeal against the award of R27 north trunk contract Permanent Table View feeders to serve the Table View trunk and provide a distribution service within the Table View area. Milestone 2 Opportunity to commence City to Montague Gardens trunk along Racecourse Road supported by a feeder btw Montague Gardens and Century City Plus: Atlantis Trunk via Melkbosstrand to Montague Gardens and Cape Town Feeders within Atlantis serving trunk and local travel desires. Milestone 3 Quarterly Report V1.6 January to March 2012 Page 26 of 59 Plus: Sep 2013 Nov 2013 The Potsdam Road tender had to be retracted, due to a substantial scope change to this section of the project as a result of the implications to relocate informal dwellings from the affected road reserve. Trunk from Bayside to the CBD is extended from Bayside to Du Noon. Interim feeder between Du Noon to Montague Gardens (this can be introduced earlier as part of milestone 2 or 3) Milestone 4 Proposed Tariffs for 2012/13 Financial Year In March 2012, COUNCIL approved the proposed MyCiTi tariffs for public participation for the 2012/ 13 financial year. The Tariffs is following a public participation process for final approval by COUNCIL in June 2012. A copy of the report is available on the City of Cape Town website (COUNCIL Agenda’s). Phase 1B & 1C It is proposed that Phase 1B comprise of the following services: Trunk service between Du Noon to Century City via Montague Gardens Feeder services from Summer Greens, Edgemead & Richwood to Century City Feeder service between Montague Gardens to Maitland and Salt Rive Rail stations via Koeberg and Voortrekker Roads. System planning is currently investing options of linking Hout Bay & Imizamo Yethu to Wynberg and if found viable will be categorised as Phase 1C. Serving the Metro South East Phase 2 is defined as the Metro South East (MSE) area and is responsible for the majority of the total public transport activity in the metropolitan area. Years of planning, research and investigation have identified critical missing transport links in the public transport system serving the MSE which could be served by BRT. These missing links and the impact thereof are clearly shown in the following figure which describes the rail system (city’s transport backbone) in terms of utilisation over capacity on the rail network; Quarterly Report V1.6 January to March 2012 Page 27 of 59 The Khayelitsha to CBD Rail service is running at over capacity (dark shade) until it connects with northern lines towards Bellville and Southern lines towards Claremont and Wynberg. This dynamic identifies the actual desire for movement towards the Bellville and Wynberg/ Claremont area but due to the lack of a direct transport links to these areas, commuters travel a roundabout way to their final destination. It is therefore planned that BRT would be implemented to address these critical public transport missing links as schematically shown above. Over time, the road based public transport demand between the MSE and the Cape Town CBD has grown significantly. This is due to passengers moving from rail to both bus and mini-bus taxi services because of the lack of capacity and perceived safety and security concerns by passengers on the rail system. Until these concerns have been addressed, there will always be a requirement to provide road based public transport alternative to the CBD. Accordingly PRASA has responded in their recent Rail Plan by identifying the Chris Hani (Khayelitsha) to CBD rail service as a ‘modernisation and demonstration’ project. Until then, an interim express BRT service is proposed to be fully operational by December 2013. Any infrastructure built and fleet procured for this express service will be common for future MSE trunk services and therefore will not result in abortive expenditure. The express services must be planned together with the development of the following prioritised public transport corridors from the MSE to: Wynberg / Claremont Bellville via Symphony Way West Coast via Nigeria Way (Langa) and Jan Smuts Drive CBD via Klipfontein Road) Please note that the above proposals are conceptual only and subject to further detailed investigation. The brief for professional services for the Full Phase system planning and design is currently being finalised, with the scheduled consultant award scheduled for July 2012. This appointment will also include the conceptual and detail design of one the above corridors which will allow construction of this corridor to commence by the end of 2013. Quarterly Report V1.6 January to March 2012 Page 28 of 59 C.8 Infrastructure Overview All Atlantis corridor busway contracts for Phase 1A are now under construction. Atlantis and Melkbosstrand contracts (262Q) construction commenced in October 2011. Works related to the Potsdam Road contract commenced on 5 March 2012.. The Inner City bus-ways, particularly around Adderley Street are currently pending the heritage public participation process which requires that the cenotaph be removed and relocated. A decision on this matter is projected for May 2012. Any delay will result in this station being completed beyond the Phase 1A Milestone 4 scheduled date. Queens Beach Station and Roadway works tender is underway and construction is expected to commence in May 2012. V&A Waterfront station construction and civil works can commence as soon as negotiations between CoCT and the V&AW have been concluded. Design of the all Atlantis Corridor stations are progressing well and design delivery should be achieved for Blaauwberg, Atlantis and Potsdam Road stations. Design for the Inner City station on Adderley Street is still on hold pending resolution of the HIA assessment. Queens Beach, which had to be designed to accommodate special requirements from neighbouring properties, is yet to be finalised. Busway Civil Contracts & Stations 112Q-R27 North at Sundown & Sunningdale Roads On programme for completion by April 2012, excluding stations. Operation on this route is aligned with Milestone 3. 113Q-Non Motorised Transport (Table View / Milnerton areas) Works have been completed. Contract has however been extended to cater for landscaping maintenance. 128Q-Racecourse Road, Milnerton Contract extension of time 54 days granted. Current completion date scheduled for September 2012, with stations scheduled to be complete by then. System is scheduled to be operational along this route from early 2013. 262Q- Atlantis & Melkbos Civil Works around Stations Services clashes at Melkbos are projected to have a 42-day impact on the completion of the contract. The completion of Melkbos station will not be achieved for Milestone 3. Project completion estimated to be in February 2013. An interim stop will be adopted for start up of Milestone 3. Atlantis civils and station works are scheduled for completion by September 2012, and operational for Milestone 3. 437Q-Blaauwberg Road On programme for completion by May 2013. The successful integrated management of traffic during the relocation of the Chevron pipeline at Table View Station was completed in February 2012. The focus is on the section from Pentz / Raatz to Wood Drive, as the stations are required for operations early in 2013. Quarterly Report V1.6 January to March 2012 Page 29 of 59 154Q-Potsdam Road Scheduled to commence in March 2012. Relocation of illegal dwellings and removal of illegal electrical cables is critical for construction in the applicable area. Open Feeder Stop Contracts Construction of the Open Feeder Stops in the Inner City, Table View and Atlantis is still being met with some resistance from local residents wrt to stop location and design type. This is being addressed through a public notification process and well as various meetings with the local rate payers associations. It is noted that a 60 Day Extension of Time (EOT) Claim that was submitted by Group 5 for the Inner City Feeders has been adjudicated, and an award of 16 days was granted. A further claim (1B) for additional cost incurred due to a reduction in the scope of work has been submitted and is currently being evaluated. 375Q-Table View Feeder Stops Works are currently on programme for completion by November 2012. Table View closed feeder station due for completion by September 2012. Operation of this station is in line with completion of Stations along Blaauwberg Road, i.e. Wood, which is scheduled for early 2013. 469Q-Atlantis Feeder Stops On programme for completion by end of 2012. 319Q- Inner City Feeder Stops Currently the contract is running two days behind the programme completion of end February 2013. Extent of individual stop construction delayed due to clash of underground services and shortage of bitumen. Gardens feeder station retail under consideration with the approvals authority. Adderley Feeder Station – currently undergoing a public participation process to relocate the Cenotaph. Queens Beach Feeder Station construction scheduled to commence mid 2012. V&A Waterfront Station – pending agreement with V&AW regarding costs and design set back lines. IRT Depot Contracts The construction of the Stables Bus Depot is well advanced with revised completion of all portions now planned for the end of May 2012, as a result of the liquidation of the aluminium shopfront contractor. The Atlantis bus depot site was handed over to Power Construction during January 2012, with construction well underway. The Inner City Bus Depot Phase 2 tender closed mid January 2012, and the second letter was issued to Civils 2000 at the end of March 2012. Construction is scheduled to commence April 2012. 170Q - Stables Depot Noted that the slow progress of works remains a concern and the recent liquidation of Winlite, the glazing contractor, will have an impact on the completion date of the works. Expect occupation of Depot from June 2012. Quarterly Report V1.6 January to March 2012 Page 30 of 59 191Q - Inner City Depot Works are scheduled to commence in April 2012, and Autopax are well in the process of vacating the premises. Late design change requests by the Operator, may result in a completion of portions of the contract being delayed. 43Q - Atlantis Depot Contract works has commenced on 9 January 2012. Final construction programme still to be agreed, however there has been minor slippage on the provisional programme, which the contractor advises can be made up. Quarterly Report V1.6 January to March 2012 Page 31 of 59 C.9 Business Development Overview of Business Development The Business development work stream is primarily responsible for planning the process of operating MyCiTi, including the preparation of major operational tenders and contacting of the MyCiTi service providers and for the design and procurement of the technology systems. It is also responsible for integration of the operations and the infrastructure work of the IRT from an operations perspective and for planning the MyCiTi system from a business point of view. The contracted and “to be” contracted MyCiTi service providers include the Vehicle Operating Companies, the Station Management Contactor, the Control Centre and Automated Fare System Contactors. The technology systems being designed and procured include: The MyCiTi buses and related technology; The control centre equipment i.e. tracking systems, information and communication systems and associated intelligent transport systems (ITS) and supporting information technology systems; The automated fare collection systems i.e. fare validation systems and gates, fare media electronic smart cards and supporting information technology systems. Amendments to the Business Plan The Business Plan for Phase 1A was approved by Council in October 2010. Council approved two sets of amendments subsequently, and these are available from http://www.capetown.gov.za/en/irt, by clicking on Business Plan and then on Amendments to the Business Plan. There have been no amendments to the Business Plan during the reporting period. Vehicle Procurement Contracts (VPCs) The MyCiTi vehicle fleet for Phase 1A is being procured through three procurement contacts: Supplementing the initial order of 43 trunk service buses an order for the acquisition of an additional 10 x 12-metre, high-floor trunk vehicles was placed in mid-2011. These vehicles have now been delivered and after final acceptance testing entered service in March 2012. A contract for the supply of 190 x 9-meter, low-entry feeder buses was awarded in 2011. The buses will be supplied in a CKD (complete knockdown) kit form and the first buses are currently being assembled in Elsies River, providing local employment opportunities. The delivery of the first buses is anticipated to commence in May 2012 (subject to possible shipping delays), and planned delivery will continue over a period of 7 months. Representatives from the IRT Project Office and from the City’s Technical Services Department inspected the production prototype at Optare’s factory in Leeds, UK which proved to be extremely beneficial in that a number of production issues could be resolved. Quarterly Report V1.6 January to March 2012 Page 32 of 59 A tender is being prepared to procure the balance of high-floor trunk service bus fleet for Phase 1. Two issues which could significantly affect the procurement of the buses are the volatility in foreign currency and changes in legislation pertaining to local content. With regard to the current contracts, forward Forex cover has been secured for the imported components, as per standard operating procedures. With regard to local content, this could affect delivery lead times, given that manufacturers may have to retool/equip their manufacturing plant to comply with new requirements. In response longer lead times for manufacture are planned for future vehicle contracts. Although regulations pertaining to local content were to be promulgated on 7 December 2011, this has been delayed. Vehicle Operator Contracts (VOCs) During the reporting period the business development team focused primarily on the following two areas relevant to the VOCs; Drafting documentation forming the basis of the long term Vehicle Operator (VO) Contracts comprising the Prospectus and the Contract itself. In particular, the Prospectus which provides an overview of the IRT structure in which the VO will be operating, as well as detailed system information as required by the VOCs to cost their operations during the longterm contract period, has undergone a number of iterations as the team refined the bus service and the model for contracting the VO services. It is now envisaged that the Prospectus will be finalised for distribution to the VOCs toward the end of April 2012 when the process of tender and negotiations for the long term VO contracts will commence. Extension of the current Interim VO contracts to cater for the period up to the point that the long term VO agreements are in place. This required extensive assessment and negotiation to cater for the operation of a feeder bus service which is in addition to the trunk service they are currently operating. The agreement is expected to be finalised in time for the conclusion of the contract by end April 2012. Station Management (SM) contract The Station Management tender that was originally advertised on 4 November 2011 was cancelled on 28 February 2012 to allow amendments to be made to the tender design. This contract is planned to be re-advertised during April / May 2012. Automated Fare Collection (AFCs) Significant changes occurred regarding the fare system during the reporting period. TRANSITION FROM THE INTERIM PAPER TICKET SYSTEM Initially, when the Milestone 0 starter service commenced in May 2011, an interim paper ticket system was used. From November 2011 this was replaced in a phased manner by EMV-compliant electronic cards until 28 January 2012, when acceptance of paper tickets came to an end (bar a few exceptions). From this date payment can be made only by using such cards, which must generally be obtained or topped-up prior to boarding a bus or entering a station. EMV stands for Europay / Quarterly Report V1.6 January to March 2012 Page 33 of 59 MasterCard / Visa, which sets the standard for banking media, designed partially for use in a transport environment, and is required by NDOT regulations. The card provided by MyCiTi for this purpose is called the myconnect card, but EMV compliant cards provided by others can also be used, and have to be bought by passengers at a present cost of R22. In the three months from December to February 2012 two free “emergency tickets” per passenger were issued with each myconnect card. The main reason for issuing these tickets was to assist passengers if they found themselves caught in the system with no value on their card, and no chance of being able to top up – i.e. to help them learn the system. From the beginning of March no emergency tickets are being issued together with a newly purchase card, although such tickets issued before can still be used until 30 June. AUTOMATED FARE SYSTEM By end March 41 951 myconnect cards have been issued. In January, a total number of 138 354 transactions were made by passengers using their myconnect cards on the MyCiTi system, 307 531 in February and 337 647 in March. Other EMV cards are currently being used by passengers on the MyCiTi system to pay for their fares, namely the Tap-i-fare card and the ABSA One Touch card. However, the extent of use of these cards on the MyCiTi system is negligible in comparison to the myconnect card. There have been numerous technical challenges which have had to be overcome during this first quarter. In particular, this related to the need for improved systems internal to ABSA (who is contracted to provide the services regarding the card), the need to develop additional protocols as issues and problems surfaced, and the failure of staff operating the MyCiTi system to follow the operational protocols correctly. Furthermore, there were unforeseen difficulties related to the equipment on the bus, for example, where the collection of dust in the cradles coated the contact points resulting in the validators not being properly charged by the bus. The development towards the full implementation of the AFC system, i.e. distance base fares, is underway. However, there are some challenges ahead related particularly to the overarching capabilities of the NDOT data structure, the development of a single trip solution for the ‘once off’ users of the MyCiTi system and the integration between the fare system equipment on the bus and the control centre equipment for the calculation of distance based fares, and measures to address fare evasion. Continued effort is still being put into the establishment of the ABSA retail footprint for the selling of cards and loading of value. By end March, there were only 13 retailers actively performing these functions. In an attempt to ease the points of sale and loading of value in the vicinity of the V&A Waterfront, the AFC Contractors have set up a desk to perform these functions at the Information Centre in the V&A Waterfront. A significant step was made during the reporting period when the City signed off on the design of special gates, and the final order for these gates was placed - see figure below. Quarterly Report V1.6 January to March 2012 Page 34 of 59 Graphic indication of Station Access Gates Control Centre and Vehicle Tracking INTERIM SYSTEM The electronic tracking of the 42 MyCiTi buses as well as the close circuit television (CCTV) surveillance remains unchanged, with schedule non-compliance by the VOCs (minor at this stage) being dealt with manually. ELECTRONIC CONTROL CENTRE In this first quarter, the emphasis has been on the installation of ITS equipment on the buses and stations. The base system is in place and operational at the Transport Management Centre (TMC). During March, eight System Controllers were employed and comprehensively trained in operating the control centre system. These Controllers are currently operating from the TMC in two shifts of 4 Controllers per day. Comprehensive training was also provided to 21 drivers and 19 VOC Supervisors in the use of the mobile touch terminal (MTT) on the bus. The reason for training the VOC Supervisors is so that they become the ‘trainers’ moving forward. Advertising Management Contracts The tender for management of the MyCiTi advertising opportunities closed on the 7 February 2012 and the assessment process is currently under way. It is anticipated that the appointment will be made during May 2012. Further focus areas of the Business Development Team During the reporting period the Business Development division also addressed the following: Amendments to the terms and conditions of the myconnect card are being prepared, and the MyCiTi Rules are being revised. Quarterly Report V1.6 January to March 2012 Page 35 of 59 The tender for the supply of professional and specialised services, including the development of a business plan for future phases closed on 27 January 2012 and the quality assessment of the tenderers is currently under way. Quarterly Report V1.6 January to March 2012 Page 36 of 59 C.10 Industry Transition Overview of Industry Transition Surveys for Market Share Compensation to Taxi Operators Final adjusted survey results were issued to directly affected minibus-taxi operators and the two bus companies in November 2011. All adjusted survey results and fare revenue were agreed upon by all affected operators. However, at the time of writing this report the City was still in clarification discussion with one association. This allowed the City to determine market share based on fare revenue, which had been shared with operators on 18 November 2011. Notice in Media re Affected Operators On 16 September 2011 the City published a formal notice in the press addressed to individual taxi operators and taxi associations, inviting those who considered themselves to be directly or partially affected to indicate the reasons why they consider themselves affected; and inviting holders of operating licences in listed routes to inspect lists of affected operators to determine whether they are on those lists, and to advise the City if they are not. The notice and related documents are available at www.capetown.gov.za/en/irt. Steps towards Compensation The City has requested all directly affected taxi associations to hold special general meetings to decide formally on an allocation formula for the distribution of the compensation pots, once determined by the City and offered to each association. The Registrar of Taxi Associations will oversee these meetings. The associations are also required to submit to the City proof that at least the holders of 80% of operating licences in the association support the allocation formula. This process has now been concluded with most of the associations. Thereafter the City’s compensation offers will be finalised. In order to finalise the compensation offers, the City planned to conduct a series of additional surveys, using selected operators, to determine specific cost inputs into compensation model. These surveys have now been concluded on most of the routes and the results incorporated into cost model. Surveys of Passengers on competing GABS routes The agreement between GABS, Province and the City provides that on routes overlapping with the MyCiTi starter services, occupancy rates must be surveyed and GABS routes with low occupancy levels should be discontinued. A survey of Golden Arrow Bus Services (GABS) routes overlapping with MyCiTi services was conducted in August 2011 and the results were reported previously. As a result of this process, 22 of the 56 trips per day operated by GABS in the area were discontinued with effect from December 2011 / January 2012. Further surveys will be conducted to reassess the occupancy rate, which could result in further decisions to reduce GABS bus trips. Quarterly Report V1.6 January to March 2012 Page 37 of 59 C.11 MyCiTi Operations Overview of MyCiTi Operations Summary of Passenger Numbers Since its launch in May 2010 until March 2012, over 3.2 million passenger journeys1 have been made on the MyCiTi rapid transit system, many of whom use its rapid bus service on the dedicated bus lanes. This includes transport services during the Soccer World Cup, passengers who made use of MyCiTi buses during events at the Cape Town Stadium and those who made use of event services offered with chartered buses. Between January and March 2012 there were approximately 800 000 passenger journeys on regular services (Table View-Civic Trunk service, Inner City Feeder and Table View Feeders), a slight decrease on the 885 000 figure reported in the previous quarter. During March 2012 the airport route showed a good increase in ridership again after taking a dip in the early part of the year. Ridership has only slightly decreased from 34 214 in the last quarter to 32 856 in this quarter. Trips on the Tap-ifare alternative card system or other contactless cards are not reflected in these figures. All these figures are based on ticket sales. The following graph indicates the renewed increase in airport ridership. MyCiTi Airport Service: passengers per month 14000 12000 10000 8000 6000 4000 2000 Mar-12 Jan-12 Feb-12 Dec-11 Oct-11 Nov-11 Sep-11 Jul-11 Aug-11 Jun-11 May-11 Apr-11 Mar-11 Feb-11 Jan-11 Dec-10 Nov-10 Oct-10 Sep-10 Jul-10 Aug-10 Jun-10 May-10 0 Figure 1. Airport to CBD IRT service: Monthly Ticket Sales The graph below indicates the approximate ridership on the Table View-Civic Trunk Service, the Inner City Feeder and the Table View Feeder services. 1 The term ‘passenger journey’ is defined below Quarterly Report V1.6 January to March 2012 Page 38 of 59 Figure 2. Assumed passenger journeys based on ticket sales: MyCiTi services for Table View-Civic Trunk, Inner City and Table View Feeder services) A ‘passenger journey’ is a journey a passenger makes travelling on one or more MyCiTi services from their origin to their destination, irrespective of how many times they transfer. For example, a passenger who travels on a feeder bus in Table View, then transfers to a trunk bus to the Civic Centre Station, and then to a feeder bus to the Waterfront is counted as only one passenger journey. Trips made as part of event services and on the airport route are added to the other passenger journeys. Notes re the table above: The numbers above have been calculated using ticket sales, assuming that one third of passengers use only feeders and that two thirds use trunk and feeders or only trunks. This assumption is based on initial surveys and will be tested with further surveys. Marketing campaigns are well under way to explain the myconnect card and new fare system to customers. The transition from the paper tickets at the end of January has gone very well and a team has been set up to deal with complaints and queries relating to the card. Summary of EMV card validations: Month Regular services (excl airport & events) Airport Jan 2012 Feb 2012 Mar 2012 Total (Route) 131 754 321 935 340 061 694 023 161 1 222 1 381 2 764 Total (Month) 131 975 323 157 341 442 696 787 Quarterly Report V1.6 January to March 2012 Page 39 of 59 The next graph indicates the revenue income versus Vehicle Operator operating costs (i.e. excluding fixed costs) of the service. Graph indicating Revenue vs Direct Vehicle Operator Expenditure excl fixed costs R 4 500 000.00 R 4 000 000.00 R 3 500 000.00 R 3 000 000.00 R 2 500 000.00 R 2 000 000.00 R 1 500 000.00 R 1 000 000.00 R 500 000.00 R 0.00 June 2011 July 2011 August 2011 Ticket Revenue September October 2011 November 2011 2011 Payment to VOCs (km + driver costs) December 2011 January 2012 Operations Management A number of operational changes have been made to improve the frequency and time table adherence of the MyCiTi service. Table View congestion on Gie and Blaauwberg Roads continue to cause problems with the F14 and F15 services, but ways of dealing with these issues are being looked at. The following table indicates the compliance of our busses against the present timetables. There has been a slight improvement on some of the routes since the last quarter. The overall target is to beat the London Transport figure of 85%. Averages Averages Averages % On-Time (2.59 min early to 5.59 min late vs. time table time) July to September 2011 T1 Airport F1 F14 F15 F16 87% 64% 88% 79% 57% 67% October to December 2011 88% 99% 92% 75% 72% 78% January to March 2012 87% 95% 90% 75% 78% 79% Operational Resources The City has undergone a recruitment drive to fill permanent positions within the operations team. Interviews have been taking place in this quarter with at least 4 permanent placements due to be made in April and May. Quarterly Report V1.6 January to March 2012 Page 40 of 59 Public Feedback A key focus to enabling the system to improve relies on the feedback from the general public. Data is being compiled from calls being received from the public at the Transport Information Centre. The majority of comments and complaints have related to implementation of the EMV card (as reflected in “ticket irregularities”). Corrections have been made and this has resulted in a reduction in such complaints towards the end of this reporting period. IRT Monthly Feedback 01 January 2012 - 31 March 2012 700 600 500 400 300 200 100 0 Quarterly Report V1.6 January to March 2012 Page 41 of 59 C.12 Communications, Marketing & Branding Overview of Communications & Marketing January 2012 The month of January was complicated in terms of communication, given the need for broad, widespread information dissemination about the switch from paper tickets to the myconnect card, but realising that most people are still on leave until the middle of the month. Following on from an extensive advertising campaign in November/December further adverts were placed in newspapers, both communities and dailies, editorials, and radio adverts to name a few During January a media briefing was also arranged to allow Councillor Herron, as well as representatives from ICT-Works, the card supplier ABSA bank and the National Department of Transport to speak to the media and the public about the implementation of the card and take questions. Media Releases and Media Engagement Media releases issued from 1 – 31 January 2012: 6 January 11 January 13 January 17 January 17 January 17 January 20 January 25 January 30 January 31 January Get a myconnect card by 15 January and stand a chance to win a six month free bus pass MyCiTi bus ridership figures for December 2011 MyCiTi bus myconnect card figures released Construction begins on permanent MyCiTi feeder station in Table View Myconnect benefits MyCiTi passengers Mayco recommends council postpone MyCiTi tariff increases MyCiTi ticket sales end as myconnect kicks in Cape Town recognized for its sustainable transport efforts at international transport conference City to brief media on roll out of MyCiTi’s myconnect card Myconnect: setting the trend for public transport (press conference press release) The January edition of the MyCiTi e-newsletter was prepared with a focus on the launch of the new Optare Solo 9m feeder buses, more information on the myconnect card, that paper tickets are no longer accepted as a form of fare payment for trips on MyCiTi, and construction information for work underway in the Table View and inner city areas. February 2012 The primary communication focus for February 2012 was threefold: The myconnect card still featured prominently in our advertising, and media queries; The numerous events unfolding in and around Cape Town offered an opportunity to do some targeted advertising for the MyCiTi bus services; Behavioural adverts, reminding motorists and pedestrians to be aware of the changed traffic signals and only to proceed when it is indicated as safe for them to do so. This month also saw Premier Helen Zille participate in a cycle race against a MyCiTi bus and a private car in peak traffic which formed part of her training for the upcoming Argus Cycle Tour next month. The purpose of this event was also to demonstrate that public transport is the most efficient Quarterly Report V1.6 January to March 2012 Page 42 of 59 form of travelling to and from the city centre. The results: The bus arrived at the Civic centre station within 39 minutes, the Premier took 49 minutes and the car took 57 minutes to make the same journey. Media Releases and Media Engagement Media releases issued from 1 – 29 Feb 2012: 3 February 3 February 6 February 6 February 7 February 8 February 15 February 15 February 16 February 16 February 21 February 21 February 22 February 22 February 24 February City acts against motorists driving in MyCiTi bus lanes MyCiTi taking steps to fix feeder route delays in Table View area Bitumen shortage continues, City reprioritising roadworks Road closures State of the Nation Address/Opening of Parliament and rehearsals Cycling in Cape Town “Share the Road” City welcomes taxi industry's TAP-i-FARE™ payment card Traffic advisory Racecourse Road closures Cllr Herron to conduct site visit and provide update on City’s NMT programme Gardens residents warned of work on MyCiTi bus station this weekend Cape Town’s NMT network extending across Cape Town City warns of week-long road closure around Table View MyCiTi station Premier Zille and Cllr Herron to race a MyCiTi bus and car from Table View on their bicycles Premier Zille and Cllr Herron race a MyCiTi bus to town City to host Rail Summit to further develop Comprehensive Integrated Transport Plan SPEECH BY MAYORAL COMMITTEE MEMBER FOR TRANSPORT, ROADS AND STORMWATER, Councillor Brett Herron, speaking at the Rail Summit held in the Civic Centre on 24 February 2012 The February edition of the MyCiTi e-newsletter focused on the changeover from paper tickets to the myconnect card, construction for the new routes in the inner city area and the smaller buses for feeder routes that are being built locally. March 2012 March saw the development of communications materials and media information pieces focusing on the emerging retail footprint for the myconnect card and the revised fares structures. Public meetings were held on 28 and 29 March for the city bowl and Sea Point areas, timed with the publication of wrap-arounds for community newspapers in the City Bowl, West Coast and Hout Bay. Planning and development work for the new MyCiTi website, direct marketing campaign and marketing research project continues. Media Releases and Media Engagement Media releases issued from 1 – 31 March 2012: 5 March 8 March 12 March 12 March 15 March 22 March 22 March Quarterly Report Cape Argus Cycle Tour - Free Transport and Road Closure Information Moving Cape Town’s Cenotaph – your chance to comment Roadworks at Gardens MyCiTi Station from 16 – 18 March Construction in Table View – Keeping the public informed UPDATE!!! Roadworks at Gardens MyCiTi Station from 16 – 18 March Cape Town Carnival 2012 - Public Transport and Road Closure Information City reminds Capetonians of basic road safety rules V1.6 January to March 2012 Page 43 of 59 27 March 28 March 28 March 30 March MyCiTi Public Meetings in Sea Point and the City Bowl STATEMENT BY COUNCILLOR BRETT HERRON, MAYORAL COMMITTEE MEMBER FOR TRANSPORT, ROADS AND STORMWATER: Update on the City of Cape Town’s dispute with SANRAL on toll roads TABLING OF THE DRAFT BUDGET BY EXECUTIVE MAYOR OF CAPE TOWN, ALDERMAN PATRICIA DE LILLE, AT THE COUNCIL MEETING 28 MARCH 2012 An Evening with the Eagles - Public Transport and Road Closure Information The March edition of the MyCiTi e-newsletter focused on the proposed devolution of transport planning to the City’s authority, the bid to turn our cities from car-centred places to ones where public transport and the interests of all residents take preference. Quarterly Report V1.6 January to March 2012 Page 44 of 59 D. Conclusions D.1. Main Successes & Challenges of the Project The following can be described as the main successes of the project: Ridership since May 2011 has reached 2 million; Support by the general public for the IRT has exceeded expectations; The vehicle operators have responded to the business opportunities offered and are delivering a high-level service. The provision of the myconnect card for users of the BRT system will provide banking type debit facilities to a large portion of the metropolitan population that as yet does not have access to such arrangements. The challenges to the project are: Continued improvement of communication to the general public as well as affected parties; Roll out to the main metropolitan areas to the south east is to be prioritized; Smoother vehicle operator negotiations without further delays; Local bus industry were unprepared for the feeder vehicle tender due to limited opportunity to match specifications for low floor and special needs passenger requirements, and inability of their existing vehicle being able to operate safely in built-up CBD and residential areas (tracking and vehicle size). The myconnect card banking charges are a concern to users. Creation and user acceptance of an internet based Document Management & Collaboration system. D.2 Do the Outcomes justify the Costs? Based on the present day successes to date, the outcomes for this quarterly period continue to justify the costs. D.3 Were the Objectives Achieved within the specified Time & Budget? The planned IRT project objectives for this reporting period have been achieved, but process delays were incurred on spend and roll-out of a limited number of project activities. D.4 Embedding the Objectives in Local Institutions Service Level Agreements are well developed to formalize structures between City departments and external stakeholders. Quarterly Report V1.6 January to March 2012 Page 45 of 59 D.5 Preparation of Stakeholders In the implementation of the IRT system in Cape Town, local taxi operators received training and guidance for transition to vehicle operator contracts. Bus industry consultations were held and tasked with assessing the ability of the local industry to take up the challenge of the feeder bus roll-out to match specifications and requirements. Ongoing and regular consultations are held with local communities, local businesses, organizations such as Cape Town Partnership, ACSA, PRASA and also included local developers such as the V&A Waterfront and Century City, amongst others. D.6 Project Direction Whilst focus remains on achieving the targets for completion of Phase 1A, reviews will be undertaken in regard to bus technologies available for trunk and feeder routes. No re-orientation is currently planned for the IRT Project. Strategic planning is in progress for the roll out of other phases, namely; Phase 1B – Dunoon to Century City Trunk and associated Feeders Phase 1C – Hout Bay to Wynberg Feeder Phase 2 (Express) – Metro South East Express Service to CBD Phase 2A – Landsdown Wetton Corridor Trunk and associated Feeders Quarterly Report V1.6 January to March 2012 Page 46 of 59 E. Lessons Learnt & Recommendations The team has learnt lessons from the outcomes of the project in regard to the following elements: Organisational structure Project management o Implementation of a Document Management System from start of the project. o Internal Communications Vehicles o Vehicle acquisition o Vehicle Specifications o Tyre Wear o Fleet management System Planning & Infrastructure o Trunk Extensions o Review of High Floor bus o Fare Structure & design o Universal Access o New fleet type o Data Collection o System Demand Modelling o Virtual BRT lanes o Intersection & signal treatment o Non Motorised Transport treatment o Depot design o Pavement design, delineators & Colourisation o Urban design & landscaping o Bikeways o Feeder service design & priority o Station design Quarterly Report V1.6 January to March 2012 Page 47 of 59 Business Planning & Operations o Station Management o Automated Fare Collection The technical difficulties associated with the handheld AFC validators on the bus were underestimated – simply, due to the fact that because this is the first of its kind in the world there is no established knowledge pool to make use of for resolving such difficulties quickly. The City is now starting to build that knowledge base; The AFC contractor has underestimated the resources required for the rolling out of the retail footprint. This has resulted in the City being compromised where passenger accessibility to acquiring the card and topping up is concerned – more time and resources should be allocated within the AFC contractor to finding more creative ways of attracting retailers; o Advertising/ Bus stops o Vehicle Operating Contracts o Industry transition o Operating deficit o Control Centre o System Operation Planning Marketing & Communications o Provide users of the system better access to system information including schedule information, route information etc. through social media (Facebook, Twitter and others). o A standard tailored approach be developed for informing communities about planned services and construction. o Messaging and public engagement with the public be simple, clear and concise. o Realize the value of properly using social media for reputational risk management. o Integrate the communications function into every element of the project’s development stages and planning. o The communications team needs to be able to advise other project members to any potential crises in future development stages. Quarterly Report V1.6 January to March 2012 Page 48 of 59 Annexure No. 1 – Grant Framework & Programme/ Project Design Purpose of the Project: The MyCiTi project of the City of Cape Town (the City) represents two crucial, related components which contribute to realising the vision of improved public transport shared by national government and the City. Firstly, the project is implementing a major new road based (bus rapid transit) component of a multi-modal integrated public transport system for the City; Secondly, through the MyCiTi project, the City is beginning to establish the capability to take responsibility for running a multi-modal city-wide public transport network in line with the intentions of national policy and the NLTA, which seeks to devolve such responsibility to the cities and the transformation the current road based public transport industry Outcomes/Outputs/Indicators: Please refer to the table of indicators as shown below. Key Activities: Please refer to the Master Programme (Point C.2) and Annexure 1 (Table of Indicators). Assumptions & Risks: The following key assumptions have been applied to the planned development and implementation of Phase 1A and further phases of the MyCiTi IRT project; a. b. c. d. e. f. Quarterly Report Capital funding via PTI&SG for the project will continue beyond the current approved DORA grant allocations and on the same basis as present. The fare revenue will be as modelled. The risk that the modelled fare revenue is not realised or the operating deficit is higher than projected, shall be shared between the City and PTISG. A significant portion of the operating costs not covered by fare revenue and MyCiTi advertising and other concessions will be covered by the PTISG until replaced by a municipal public transport operating grant. Existing public transport users will migrate to the MyCiTi system and 7% of existing car users (choice users) will shift to the new MyCiTi public Transit mode. The existing public transport industry (bus and taxi industry) will be willing partners in the transformation process and will operate the MyCiTi services. V1.6 January to March 2012 Page 49 of 59 Annexure No. 2 – Table of Indicators, MyCiTi Quarterly Report V1.5 January to March 2012 Page 50 of 59 Quarterly Report V1.6 January to March 2012 Page 51 of 59 Quarterly Report V1.6 January to March 2012 Page 52 of 59 Quarterly Report V1.5 January to March 2012 Page 53 of 59 Annexure No. 3 – SCM BAC Summary Progress (January 2012) TENDER NO. F/YEAR TYPE - 2007/2008 Single Source Appointment of Service Provider 204S/2007/08 2007/2008 Award of Tender 266C/2007/08 2007/2008 Award of Tender 27Q/2008/09 2008/2009 Award of Tender 80Q/2008/09 2008/2009 Award of Tender 77Q/2008/09 2008/2009 Award of Tender 131C/2008/09 2008/2009 123C/2008/09 2008/2009 133C/2008/09 2008/2009 128C/2008/09 2008/2009 127C/2008/09 2008/2009 139Q/2008/09 2008/2009 Award of Tender 144Q/2008/09 2008/2009 Award of Tender 163Q/2008/09 2008/2009 Award of Tender 135C/2008/09 2008/2009 - 2008/2009 319Q/2008/09 2008/2009 - 2008/2009 - 2008/2009 390Q/2008/09 2008/2009 - 2009/2010 563N/2008/09 2009/2010 Quarterly Report Appointment of Consultant / Service Provider Appointment of Consultant / Service Provider Appointment of Consultant Appointment of Consultant / Service Provider Appointment of Consultant / Service Provider Appointment of Consultant Request for Deviation (above R200 000.00 Award of Tender PROJECT DESCRIPTION Authority to Appoint Dr Lloyd Wright, International Transport Expert, as a Technical Specialist Advisor, to the City of Cape Town, to Guide and Advise on the Planning, Design, Programming and Implementation of the Bus Rapid Transport Components of the Public Transport Implementation Action Plan, Phase 1 (2007 - 2010) Provision of Professional Services : Integrated Rapid Transit System : Operational Plan Provision of Professional Services : Integrated Rapid Transit System : Business Plan (Project Report Stage) Construction of Public Transport Corridor through Culemborg from Church Street to the N1 Underpass : Roadworks, Relocation of Railways, Viaduct and Appurtenant Works Construction of Public Transport Corridor through Paarden Eiland from the N1 Underpass to Milner Road: New Bridge Structure over Salt River Canal (World Cup 2010 Project) Construction of Public Transport Corridor through the Paarden Eiland Railway Spur from the N1 Underpass to Milner Road : Roadworks, Services Accommodation and Appurtenant Works AUTHOR / PROJECT MANAGER AGENDA ITEM RESOLUTION D Cupido 06/08/2007 Approved Ron Haiden 18/12/2007 Approved Ron Haiden 17/03/2008 Approved Cobus Hugo 06/10/2008 Approved Cobus Hugo 17/11/2008 Approved Cobus Hugo 17/11/2008 Approved Provision of Professional Services : Process Manager Jonathan Louw 17/11/2008 Approved Provision of Professional Services : Road Work Engineer John Martheze 17/11/2008 Approved Provision of Professional Services : Implementation of the Integrated Rapid Transit System : Non-Motorised Transport Specialist Jonathan Louw 17/11/2008 Approved Provision of Professional Services : IRT : Business Manager Jonathan Louw 17/11/2008 Approved Provision of Professional Services : Implementation of the Integrated Rapid Transit System : Industry Transition Specialist Jonathan Louw 17/11/2008 Approved Cobus Hugo 08/12/2008 Approved Cobus Hugo 15/12/2008 Approved Cobus Hugo 15/12/2008 Approved Jonathan Louw 15/12/2008 Approved Provision of Professional Services: Implementation of Integrated John Martheze 09/03/2009 Rapid Transport System - Communications Consultant Approved Construction of Public Transport Corridor along Route R27 from Racecourse Road to Blaauwberg Road: Roadworks, Services Accommodation and Appurtenant Works Construction of Public Transport Corridor through Culemborg from Old Marine Drive to Church Street: Roadworks, Relocation of Railways, Service Accommodation and Appurtenant Works Construction of Public Transport Corridor along Route R27 from Milner Street to Racecourse Road : Roadworks, Services Accommodation and Appurtenant Works Provision of Professional Services: Implementation of the Integrated Rapid Transit System: Design Specialist Construction of Atlantis Integrated Rapid Transport Corridor : Old Marine Drive to Heernegracht: Roadworks, Service Cobus Hugo Accommodation and Appurtenant Works Electronic Fare Collection (EFC) Project: Provision of Professional Francois Nell Services 2010 World Cup Project Request for Deviation Request for Increase In Integrated Rapid Transport / 2010 World Cup: N1 Corridor Contract Sum and Priority Projects - Culemborg / Koeberg / R27 Corridor : Increase or Period (above In Professional Fees R200 000.00) Cape Town Integrated Rapid Transport System (Phase 1A) Award of Tender Major Stations Superstructures Appointment of ACSA to Undertake Implementation of the Cape Town International Airport IRT Station Sub-Structure and Associated Road Works on Behalf of the City of Cape Town Supply and Delivery of Kassel Kerbs for Integrated Rapid Transport Stations 23/03/2009 Approved 20/04/2009 Approved Dave Buerger 08/06/2009 Approved Dave Buerger 29/06/2009 Approved Dave Buerger 06/07/2009 Approved Dave Buerger 20/07/2009 Approved V1.5 January to March 2012 Page 54 of 59 TENDER NO. F/YEAR TYPE - 2009/2010 Request for Deviation 556N/2008/09 2009/2010 Award of Tender 17Q/2009/10 2009/2010 Award of Tender - 2009/2010 Request for Deviation and/or Condonation 139Q/2008/09 2009/2010 Request for Deviation 17Q/2009/10 2009/2010 Award of Tender - 2009/2010 - 2009/2010 - 2009/2010 - 2009/2010 319Q/2008/09 2010/2011 86Q/2009/10 2010/2011 - 2010/2011 123C/2008/09 2010/2011 133C/2008/09 2010/2011 127C/2008/09 2010/2011 CM 08/03/09 2010/2011 17Q/2009/10 2010/2011 77Q/2008/09 2010/2011 77Q/2008/09 2010/2011 Quarterly Report Request for Increase In Contract Sum (above R200 000.00) Request for Authority to Negotiate and for Consequential Deviation (above R200 000.00) Condonation Request for Single Source Selection (under R200 000) Request for Increase in Contract Sum and/or Period (above R200 000) Acceptance of Tender : Contractor (CIDB) Request for Single Source Selection (above R200 000) Request for Increase in Contract Sum and/or Period (above R200 000) Request for Increase in Contract Sum and/or Period (above R200 000) Request for Increase in Contract Sum and/or Period (above R200 000) Request for Increase in Contract Sum and/or Period (above R200 000) Request for Increase in Contract Sum and/or Period (above R200 000) Request for Increase in Contract Sum and/or Period (above R200 000) Request for Deviation and/or Condonation (above R200 000) PROJECT DESCRIPTION AUTHOR / PROJECT MANAGER Dave Buerger AGENDA ITEM Inner City Link Infrastructure Projects (2010 World Cup & IRT : 31/08/2009 Increase in Fees for Professional Services Supply of Public Transport Vehicles for 2010 Trunk Services John Martheze 30/11/2009 Appointment of Volvo South Africa (Pty) Ltd Construction of Access Road and Upgrading of the Inner City Bus Dave Buerger 14/12/2009 Depot in Napier Street, Cape Town (IRT Project) R031000379 - Due Diligence Exercise on the Integrated Rapid Transport System (IRT) Louise Muller RESOLUTION Approved Approved Approved 14/12/2009 Approved 14/12/2009 Approved 08/02/2010 Approved Request for Increase in Contract Sum : Contract for the Cape Town International Airport IRT Station Sub-Structure and Dave Buerger Associated Road Works being Undertaken by Airports Company South Africa (ACSA) on behalf of the City of Cape Town 08/02/2010 Approved 2010 World Cup IRT-Related Transport Event Services: Operator Abdul Bassier Contract (Excluding Test Event 1 & 2) 22/02/2010 Approved Transport Management Support (Technical and Administrative) Louis Haultzhauzen 23/03/2010 Approved Integrated Rapid Transit: Appointment of Project Management Consultant Services John Martheze n/a Approved Construction of Atlantis Integrated Rapid Transport Corridor Old Marine Drive to Heerengracht - Roadworks, Service Accommodation and Appurtenant Works Dave Buerger 12.07.2010 Approved Construction of Inner City Integrated Rapid Transport System from Hertzog Boulevard along Heerengracht, Fountain Circle and Hans Strijdom Avenue up to Bree Street, Cape Town Dave Buerger 19.07.2010 Approved Integrated Rapid Transit: Appointment of Professional Services for Business and Operations Planning Support: D R Bosch John Martheze 26/07/2010 Approved Integrated Rapid Transit Project Phase 1A: Increase in Contract Sum for the Following Professional Services Contract - Road Work Engineer John Martheze 02/08/2010 Approved Integrated Rapid Transit Project Phase 1A: Increase in Contract Sum for the Following Professional Services Contract - Non Motorised Transport Specialist John Martheze 02/08/2010 Approved Integrated Rapid Transit Project Phase 1A: Increase in Contract Sum for the Following Professional Services Contract - Industry Transition Specialist John Martheze 02/08/2010 Approved Integrated Rapid Transit Project Phase 1A: Increase in Contract Sum for the Following Professional Services Contract Communications Consultant John Martheze 02/08/2010 Approved Construction of Public Transport Corridor along Route R27 from Racecourse Road to Blaauwberg Road: Roadworks, Services Cobus Hugo Accommodation and Appurtenant Works : Increase in Contract Sum Construction of Access Road and Upgrading of the Inner City Bus Dave Buerger Depot in Napier Street, Cape Town (IRT Project) Construction of Access Road and Upgrading of the Inner City Bus Bertie Byker Depot in Napier Street, Cape Town 16.08.2010 Approved Construction of Public Transport Corridor through Paarden Eiland from the N1 Underpass to Milner Road: Road Works, Services Accommodation and Appurtenant Works Buerger, Dave 13.09.2010 Approved Construction of Public Transport Corridor through Paarden Eiland from the N1 Underpass to Milner Road: Road Works, Services Accommodation and Appurtenant Works Buerger, Dave 13.09.2010 Approved V1.6 January to March 2012 Page 55 of 59 TENDER NO. F/YEAR - 2010/2011 17Q/2009/10 2010/2011 511C/2009/10 2010/2011 - 2010/2011 319Q/2008/09 2010/2011 24G/2009/10 2010/2011 25G/2009/10 2010/2011 163Q/2008/09 2010/2011 139Q/2008/09 2010/2011 113Q/2010/11 2010/2011 112Q/2010/11 2010/2011 123C/2008/09 2010/2011 127C/2008/09 2010/2011 133C/2008/09 2010/2011 AE-CM08/03/09 2010/2011 SCMB 16/01/09 2010/2011 DEVIATION / CONDONATION 2010/2011 128Q/2010/11 2010/2011 Quarterly Report TYPE Request for Deviation and/or Condonation (above R200 000) Request for Deviation and/or Condonation (above R200 000) Acceptance of Tender : Consultant/Profes sional Service Provider (CIDB) PROJECT DESCRIPTION Post 2010 World Cup IRT-Related Public Transport Services AUTHOR / PROJECT MANAGER Bassier, Abdul Appointment of Consultant for Supervision of Final Design, Request for Single Supply, Installation and Commissioning of Advanced Public Source Selection Transport, Information and Security Management Systems on (above R200 000) Busses, Stations and in the Transport Management Centre Request for Increase in Construction of Atlantis Integrated Rapid Transport Corridor Contract Sum Old Marine Drive to Heerengracht - Roadworks, Service and/or Period Accommodation and Appurtenant Works (above R200 000) Acceptance of Design, Supply, Delivery, Installation, Testing, and Tender : Goods Commissioning of the IRT Fare System, the Supply and and/or Stores Distribution of Fare Cards, and the Provision of Maintenance Items and other Related Services Acceptance of Design, Supply, Delivery, Installation, Testing, Commissioning Tender : Goods and Maintenance of the IRT Control Centre Hardware and and/or Stores Software Systems Items Request for Increase in Construction of Public Transport Corridor along Route R27 from Contract Sum Milner Road to Racecourse Road and/or Period (above R200 000) Request for Construction of Public Transport Corridor along Route R27 from Increase in Racecourse Road to Blaauwberg Road: Road Works, Services Contract Sum Accommodation and Appurtenant Works, Alternative 2 : Asphalt and/or Period Intersections (above R200 000) Acceptance of Construction of Non-Motorised Transport Infrastructure within Tender : 500m of the Atlantis Integrated Rapid Transit Bus Stations: Contractor (CIDB) Culemborg, Paarden Eiland to Racecourse Road, Sunset Beach Acceptance of Construction of Atlantis Integrated Rapid Transport Corridor Tender : R27 from Blaauwberg Road to Sandown Road (North) Contractor (CIDB) Request for Increase in Integrated Rapid Transit Project : Phase 1A : Professional Service Contract Sum Appointments - Road Work Engineer and/or Period (above R200 000) Request for Increase in Integrated Rapid Transit Project : Phase 1A: Professional Service Contract Sum Appointments - Industry Transition Specialist and/or Period (above R200 000) Request for Increase in Integrated Rapid Transit Project : Phase 1A: Professional Service Contract Sum Appointments - Non Motorised Transport Specialist and/or Period (above R200 000) Request for Increase in Integrated Rapid Transit Project : Phase 1A: Professional Service Contract Sum Appointments - Communications Consultant and/or Period (above R200 000) Request for Increase in Integrated Rapid Transit Project : Phase 1A: Professional Service Contract Sum Appointments - Business and Operations Planning Support and/or Period (above R200 000) Request for Integrated Rapid Transit System : Business Plan: Appointment of Deviation and/or Multi-Disciplinary Consultant Consortium to Undertake Condonation Additional Work (above R200 000) Acceptance of Construction of Transport Corridor along Racecourse Road from Tender : R27 to Omuramba Road: Roadworks, Services Accommodation Contractor (CIDB) and Appurtenant Works RESOLUTION 13.09.2010 Approved 11.10.2010 Approved Martheze, John 18.10.2010 Approved Greenwood, Chantal 18.10.2010 Approved Buerger, Dave 01.11.2010 Approved Greenwood, Chantal 08.11.2010 Approved Greenwood, Chantal 08.11.2010 Approved Buerger, Dave 08.11.2010 Approved Buerger, Dave 15.11.2010 Approved Hugo, Cobus 13.12.2010 Approved Hugo, Cobus 13.12.2010 Approved Hugo, Dave / 13.12.2010 Martheze, John Approved Hugo, Dave / 13.12.2010 Martheze, John Approved Hugo, Dave / 13.12.2010 Martheze, John Approved Hugo, Dave / 13.12.2010 Martheze, John Approved Hugo, Dave / 13.12.2010 Martheze, John Approved Bassier, Abdul 13.12.2010 Approved Hugo, Cobus 24.01.2011 Approved Construction of Access Road and Upgrading of the Inner City Bus Byker, Bertie Depot in Napier Street, Cape Town Provision of Professional Project Management Services: Integrated Rapid Transit System (Phase 1A) AGENDA ITEM V1.6 January to March 2012 Page 56 of 59 TENDER NO. F/YEAR 170Q/2010/11 2010/2011 390Q/2008/09 2010/2011 - 2010/2011 24G/2009/10 2010/2011 563N/2008/09 2010/2011 CONSEQUENTIAL 2010/2011 DEVIATION 204S/2007/08 CONDONATION 2010/2011 DEVIATION and/or CONDONATION 2010/2011 DEVIATION and/or CONDONATION 2010/2011 DEVIATION and/or CONDONATION 2010/2011 DEVIATION and/or CONDONATION 2010/2011 262Q/2010/11 2010/2011 86Q/2009/10 2010/2011 - 2010/2011 556N/2008/09 DEVIATION and/or CONDONATION 2010/2011 375Q/2010/11 2010/2011 DEVIATION 2010/2011 Quarterly Report TYPE Acceptance of Tender : Contractor (CIDB) Request for Increase in Contract Sum and/or Period (above R200 000) Request for Increase in Contract Sum and/or Period (above R200 000) Acceptance of Tender : Goods and/or Stores Items Request for Increase in Contract Sum and/or Period (above R200 000) Request for Authority to Negotiate in Terms of National Land Transport Act and For Consequential Deviation (above R200 000) Request for Deviation and/or Condonation (above R200 000) Request for Deviation and/or Condonation (above R200 000) Request for Deviation and/or Condonation (above R200 000) Request for Deviation and/or Condonation (above R200 000) Request for Deviation and/or Condonation (above R200 000) Acceptance of Tender : Contractor (CIDB) Request for Increase in Contract Sum and/or Period (above R200 000) Request for Increase in Contract Sum and/or Period (above R200 000) Request for Deviation and/or Condonation (above R200 000) Acceptance of Tender : Contractor (CIDB) Request for Deviation and/or Condonation (above R200 000) AUTHOR / PROJECT MANAGER Hugo, Cobus 31.01.2011 Approved Buerger, Dave 31.01.2011 Approved Contract for the Cape Town International Airport IRT Station Sub-Structure and Associated Road Works being Undertaken by Buerger, Dave Airports Company South Africa (ACSA) on behalf of the City of Cape Town : Increase in Final Contract Sum 07.02.2011 Approved Design, Supply, Delivery, Installation, Testing and Commissioning of the IRT Fare System, the Supply and Distribution of Fare Cards, and the Provision of Maintenance and Other Related Services Greenwood, Chantal 28.02.2011 Approved Supply and Delivery of Kassel Kerbs for the Integrated Rapid Transport Stations Buerger, Dave 22/03/2011 Approved MyCiTi Phase 1A: Interim Vehicle Operator Contracts Starting from April/May 2011 Bassier, Abdul 22.03.2011 Approved Authority to Negotiate Provision of Professional Services: Integrated Rapid Transit System : Operational Plan - Request for Condonation for Increase in Contract Period Fortune, Gershwin 28.03.2011 Approved MyCiTi Phase 1A: Interim Vehicle Operator Contracts Bassier, Abdul 29.04.2011 Approved MyCiTi Phase 1A: Interim Vehicle Operator Contracts Bassier, Abdul 29.04.2011 Approved MyCiTi Phase 1A: Interim Vehicle Operator Contracts Bassier, Abdul 29.04.2011 Approved MyCiTi Phase 1A: Extension of Existing Vehicle Operator Contract Period Bassier, Abdul 29.04.2011 Approved Construction of Atlantis Integrated Rapid Transport Infrastructure: Trunk Route Stations, Roadworks and Services in Hugo, Cobus Melkbosstrand and Atlantis 03.05.2011 Approved Construction of Inner City Integrated Rapid Transport System from Hertzog Boulevard along Heerengracht, Fountain Circle and Hans Strijdom Avenue up to Bree Street, Cape Town Buerger, Dave 03.05.2011 Approved Printing of MyCiTi Bus Tickets Malan, Danie 30.05.2011 Approved Supply of Public Transport Vehicles for 2010 Trunk Services: Acquisition of Additional Vehicles and Ancillary Services Martheze, John 13.06.2011 Approved Integrated Rapid Transit System Phase 1A: Construction of Bus Stop Infrastructure in Table View and Milnerton Hugo, Cobus 20.06.2011 Approved Communication and Marketing Services Provided to the IRT Project Team Hatton, Kylie 20.06.2011 Approved PROJECT DESCRIPTION Construction of the Stables Bus Depot (Potsdam Road) Cape Town Integrated Rapid Transport System (Phase 1A): Major Station Superstructures V1.6 AGENDA ITEM RESOLUTION January to March 2012 Page 57 of 59 TENDER NO. F/YEAR DEVIATION 2010/2011 DEVIATION 2010/2011 - 2010/2011 123C/2008/09 DEVIATION 2010/2011 127C/2008/09 DEVIATION 2010/2011 133C/2008/09 DEVIATION 2010/2011 391Q/2010/11 2011/2012 DEVIATION 2011/2012 DEVIATION 2011/2012 437Q/2010/11 2011/2012 469Q/2010/11 2011/2012 DEVIATION : SOLE 2011/2012 PROVIDER 371G/2010/11 2011/2012 SINGLE SOURCE SELECTION 2011/2012 SINGLE SOURCE SELECTION 2011/2012 371G/2010/11 2011/2012 86Q/2009/10 2011/2012 DEVIATION and/or CONDONATION 2011/2012 43Q/2011/12 2011/2012 Quarterly Report TYPE Request for Deviation and/or Condonation (above R200 000) Request for Deviation and/or Condonation (above R200 000) Request for Increase in Contract Sum and/or Period (above R200 000) Request for Deviation and/or Condonation (above R200 000) Request for Deviation and/or Condonation (above R200 000) Request for Deviation and/or Condonation (above R200 000) Acceptance of Tender : Contractor (CIDB) Request for Deviation and/or Condonation (above R200 000) Request for Deviation and/or Condonation (above R200 000) Acceptance of Tender : Contractor (CIDB) Acceptance of Tender : Contractor (CIDB) Request for Deviation : Sole Provider (above R200 000) Acceptance of Tender : Goods and/or Stores Items Request for Increase in Contract Sum and/or Period (above R200 000) Request for Increase in Contract Sum and/or Period (above R200 000) Acceptance of Tender : Goods and/or Stores Items Request for Increase in Contract Sum and/or Period (above R200 000) Request for Deviation and/or Condonation (above R200 000) Acceptance of Tender : Contractor (CIDB) PROJECT DESCRIPTION AUTHOR / PROJECT MANAGER AGENDA ITEM RESOLUTION Communication and Marketing Services Provided to the IRT Project Team Hatton, Kylie 20.06.2011 Approved Communication and Marketing Services Provided to the IRT Project Team Hatton, Kylie 20.06.2011 Approved Integrated Rapid Transit System: Business Plan : Extension of Contract Period of Multi-Disciplinary Consultant Consortium Bassier, Abdul 20.06.2011 Approved Road Engineer and Non-Motorised Transport Specialist: Integrated Rapid Transit Project: Phase 1A Hugo, Dave 20.06.2011 Approved Road Engineer and Non-Motorised Transport Specialist: Integrated Rapid Transit Project : Phase 1A Hugo, Dave 20.06.2011 Approved Road Engineer and Non-Motorised Transport Specialist: Integrated Rapid Transit Project : Phase 1A Hugo, Dave 20.06.2011 Approved Construction of Inner City Integrated Rapid Transport System Open Feeder Bus Stops Hugo, Cobus 04.07.2011 Approved Management Support for Roll Out of Milestone Zero (0) of Integrated Rapid Transport (IRT) Project Kingma, Ronald 18.07.2011 Approved Maintenance and Non Warranty Repair of IRT Station Band Structure and Automatic Doors Hugo, Dave 25.07.11 Approved Construction of Atlantis Integrated Rapid Transport Corridor: Blaauwberg Road from R27 to Potsdam Road Hugo, Cobus 10.08.2011 Approved Integrated Rapid Transit System Phase 1A Construction of Bus Stop Infrastructure in Atlantis and Melkbos Hugo, Cobus 10.08.2011 Approved Maintenance and Non Warranty Repair of IRT Station Band Structure and Automatic Doors Hugo, Dave 22.08.2011 Approved Supply of Public Transport Vehicles and Ancillary Services for the Martheze, John 05.09.2011 IRT System Approved Authority to Negotiate Integrated Rapid Transit System: Automatic Fare Collection Professional Services Contract 26.09.2011 Awaiting Resolution 03.10.2011 Awaiting Resolution Greenwood, Chantal Inner City Link Infrastructure Projects (2010 World Cup and IRT) Buerger, Dave Supply of Public Transport Vehicles and Ancillary Services for the Martheze, John 31.10.2011 IRT System Approved Construction of Inner City Integrated Rapid Transport System from Hertzog Boulevard along Heerengracht, Fountain Circle and Hans Strijdom Avenue up to Bree Street, Cape Town Buerger, Dave 31.10.2011 Approved Phase 1A: Integrated Rapid Transport System: Culemborg / Koeberg / R27 Corridor : Request for Deviation in Terms of Buerger, Dave MFMA Section 33 Review Process and Increase in Contract Sum for Professional Fees 31.10.2011 Approved 31.10.2011 Approved Construction of the Atlantis Bus Depot Leendertz, David V1.6 January to March 2012 Page 58 of 59 TENDER NO. F/YEAR DEVIATION and/or CONDONATION 2011/2012 DEVIATION and/or CONDONATION 2011/2012 474S/2010/11 2011/2012 - 2011/2012 - 2011/2012 60S/2011/12 2011/2012 154Q/2011/12 2011/2012 191Q/2011/12 2011/2012 231L/2011/12 2011/2012 Quarterly Report TYPE Request for Deviation and/or Condonation (above R200 000) Request for Deviation and/or Condonation (above R200 000) Acceptance of Tender Request for Increase in Contract Sum and/or Period (above R200 000) Request for Increase in Contract Sum and/or Period (above R200 000) Acceptance of Tender : Service Contractor Acceptance of Tender : Contractor (CIDB) Acceptance of Tender : Contractor (CIDB) Acceptance of Tender : Income PROJECT DESCRIPTION Shuttle Service for IRT Night Shift Staff AUTHOR / PROJECT MANAGER Wyngaard, Christopher AGENDA ITEM RESOLUTION 31.10.2011 Approved Integrated Rapid Transit System: Business Plan: Extension of Contract of Multi-Disciplinary Consultant Consortium Bassier, Abdul 07.11.2011 Approved Provision of Communication Services to the Integrated Rapid Transit Initiative, MyCiTi K Hatton 12.12.2111 Approved Integrated Rapid Transit Project: Phase 1A : Business and Operations Planning Support Hugo, Dave 12.12.2011 Approved Management Support for Roll Out of Milestone Zero (0) of Integrated Rapid Transport (IRT) Project Kingma, Ron 12.12.2011 Approved Armed Banking Carrier Service for the City of Cape Town's IRT Cash Receiving Points Kingma, Ron 16.01.2012 Approved Construction of Atlantis Integrated Rapid Transport Corridor : Potsdam Road from Blaauwberg Road to Usasaza Road, Du Noon Hugo, Cobus 13.02.2012 Approved Construction of Integrated Rapid Transport Ssytem Inner City Bus Depot at Napier Street, Cape Town - Phase 2 Byker, Bertie 27.02.2012 Approved Request for Proposal for Managing MYCITI Advertising Opportunities for the City of Cape Town Bosch, Dawie 26.03.2012 Approved Authority to Negotiate V1.6 January to March 2012